Professional Documents
Culture Documents
NUGUID v. CARIÑO
NUGUID v. CARIÑO
SUPREME COURT
Manila
EN BANC
FELIX, J.:
This is an appeal filed by the Nuguid brothers from the order of the Court of First
Instance of Manila in Civil Case No. 18337, denying their motion for
reconsideration dated November 29, 1954, of the order of the Court of
November 4, 1953, reviving its previous decision rendered in this case, on the
ground that said motion was not filed in accordance with law. The facts of the
case are as follows:
On May 19, 1952, two Nuguid brothers, both practicing civil engineers, entered
into a contract with Venancio Carino whereby the latter undertook to supply the
former with the necessary labor for the carpentry, masonry, tinsmithing,
plumbing, electrical installation and painting jobs in the construction of a two-
story house for a certain Celedonio de la Paz at Colorado St., Manila. For this
undertaking, Cariño was to receive the sum of P4,600, payable in 5 installments.
The records do not show when the work started but it does appear that sometime
in November, 1952, the construction work was disrupted. On December 9, 1952,
the Nuguid brothers instituted Civil Case No. 18337 in the Court of First Instance
of Manila, entitled Nuguid & Nuguid vs. Venancio Cariño, for specific
performance and damages, alleging that on November 20, 1952, defendant
abandoned the construction project and failed to provide the labor necessary for
the completion thereof as agreed upon in the contract between them; that
plaintiffs had to take over and supervise the construction in order to finish it on or
before December 4, 1952; that because of defendant's alleged abandonment of the
work, plaintiffs failed to finish the same on time despite their efforts, for which
reason, they were paying liquidated damages to the owner of the house in the
amount of P30 for every day of delay. It was thus prayed that defendant be
required to comply with the obligation imposed upon him by the contract and/or
defendant be ordered to pay plaintiffs the sum of P989.50 representing the
expenses incurred by plaintiffs for the payment of labor necessary to complete the
construction work; for their professional fee for having supervised the
construction at the rate of P50 a day from November 20, 1952, until the final
completion thereof; for the total amount of liquidated damages that they would
pay to the owner of the house at the rate of P30 a day from December 4, 1952,
until the work was finally terminated; for attorney's fees and such other relief as
may be just and equitable in the premises.
Defendant timely filed his answer denying the allegation that he abandoned the
construction work, contending in turn that his laborers were always on the
construction site but plaintiffs provided them no materials to work on; that such
failure of plaintiffs to furnish the materials caused the delay in the completion of
the construction. As counterclaim, defendant charged that plaintiffs were still
under obligation to them in the sum of P811.05, although he admitted having
already received the amount of P3,687.95. He also charged, a special defense, that
plaintiffs had no legal capacity to sue because the complaint was in the name of
Nuguid & Nuguid which did not appear to be either a natural or juridical person.
In praying for the dismissal of the complaint, defendant asked that plaintiffs be
ordered to pay the amount of P811.05 representing the unpaid wages of laborers;
for attorney's fees and costs.
The case was duly set for hearing and in view of plaintiffs' failure to appear, the
Court, upon motion of defendant, declared them in default and proceeded to
receive defendant's evidence to support the latter's counterclaim. And in a
decision dated June 17, 1953, the Court dismissed the complaint and ordered
plaintiffs to pay to defendant the sum of P811.05, with legal interest from the date
of the filling of the counterclaim until the amount due was fully satisfied, plus
attorney's in the sum of P200 and the costs of the suit.
Upon receipt of the decision, plaintiffs filed a motion for relief under Rule 38 on
the ground of accident, which was granted by the Court and its previous decision
was consequently set aside. However, on November 4, 1954, the scheduled date
of hearing, as plaintiffs once again failed to appear, the Court revived its decision
of June 17, 1953, and ordered the same to be executory in 30 days. From this
order, plaintiffs once more filed a motion for reconsideration dated November 29,
1954, alleging that the original lawyer handling that case withdrew therefrom
without informing the plaintiffs of the date of the hearing; that it was only upon
receipt of the order reviving the previous decision that plaintiffs learned of it and
contracted the services of a new counsel; that said circumstances may be
considered as excusable negligence and accident. It was, therefore, prayed that the
order be reconsidered and plaintiffs be allowed to present their evidence.
It appears that when the aforementioned motion of November 29, 1954, was
filed, no affidavit of merit was incorporated therein, although on the date set for
the hearing of said motion, plaintiffs filed an affidavit of merit stating their valid
defenses against defendant's contentions. On December 27, 1954, the lower Court
issued an order denying said motion for the reason that it was not presented in
accordance with the Rules of Court. Plaintiffs thus appealed to the Court of
Appeals, but as the main question involved therein was purely of law, said
Tribunal certified the case to us pursuant to Section 17-(6) of Republic Act 296.
SEC. 3. When petition filed; contents and verification. — A petition provided for
in either of the preceding sections of this rule must be verified, filed within sixty
days after the petitioner learns of the judgment, order or other proceeding to be
set aside, and not more than six months after such judgment or order was entered,
or such proceeding was taken; and must be accompanied with affidavits showing
the fraud, accident, mistake, or excusable negligence relied upon, and the facts
constituting the petitioner's good and substantial cause of action or defense, as the
case may be, which he may prove of his petition be granted.
While plaintiffs do not deny that when their motion for reconsideration was filed
there was no affidavit of merit attached thereto, they argue that the subsequent
filing of such an affidavit on the date of the hearing of the motion, without
defendant's objection and before the Court could pass upon the same, may be
considered to have "accompanied" the motion for reconsideration and may,
therefore, be treated as substantial compliance with the requirement of the law.
The word "accompany" has been variably defined as "to cause to be attended by
or as by a companion; to go along with; to consort with (Webster's New
International Dictionary, Second edition, p. 16); and it has been judicially defined
in cases involving varied facts, one of which is — a motion based on answer
already deposited with the clerk of court is accompanied by copy of answer (Los
Angeles Country vs. Lewis, 179 Cal. 398, 177 p. 154, 155). In the light of the
foregoing definitions and considering that the affidavit of merit was presented for
incorporation before the Court could determine and pass upon the merit of the
same, and presumably with the assent of defendant (since he failed to register his
opposition thereto), the filing of said affidavit of merit may be considered for all
legal intent and purposes, as having "accompanied" the motion for relief involved
herein.
We find, however, that the aforesaid affidavit of merit falls short of the
requirement of the law. Under our Rules of Court, an affidavit of merit must not
only contain facts constituting the movant's good and substantial defenses but
must also state the nature and character of the fraud, accident, mistake or
excusable negligence on which the motion for relief was based. An examination of
the affidavit of merit filed by plaintiffs-appellants reveals that while it sets down
plaintiffs' defenses against the claims of defendant, it does not specify or state the
accident or negligence supporting their prayer for relief. It is true that the accident
or excusable negligence is mentioned in the motion for reconsideration as the
alleged withdrawal of their attorney without notifying them of the date of the
hearing, yet We shall not forget that even if the affidavit of merit were in
conformity with the provisions of the Rules of Court, the granting or denial of a
motion for relief largely depends upon the discretion of the Court and under the
circumstances of the case, We cannot declare that the lower Court abused its
discretion in issuing the order denying the motion for reconsideration.
Wherefore, the order appealed from is hereby affirmed, with costs against
appellants. It is so ordered.