FIDICSilver 2017
FIDICSilver 2017
Conditions of
Contract for EPC/Turnkey
Projects
CONTENTS
1 GENERAL PROVISIONS • . . • • • . . • • . . • • • . • • • . . • • • • . . . • • • . • • . . • 1
1.1 Definitions
1.2 Interpretation
1.3 Notices and Other Communications
1.4 Law and Language
1.5 Priority of Documents
1.6 Contract Agreement
1.7 Assignment
1.8 Care and Supply of Documents
1.9 Employer's Use of Contractor's Documents
1.10 Contractor's Use of Employer's Documents
1.11 Confidentiality
1.12 Compliance with Laws
1.13 Joint and Several Liability
1.14 Limitation of Liability
1.15 Contract Termination
5 DESIGN .................................................. 32
(})
~-?
12.1 Procedure for Tests after Completion
sr 12.2 Delayed Tests
L ..
12.3 Retesting
12.4 Failure to Pass Tests after Completion
(!)
19 INSURANCE ••••••••••••••••••.••••••.••••..••••..••••.••• 89
20.1 Claims
20.2 Claims For Payment and/or EOT
Gen al Provisions
1.1
Definitions In the Contract the following words and expressions shall have the meanings stated,
except where the context requires otherwise
·' :E
er
1.1.2 "Base Date" means the date 28 days before the latest date for submission 2
of the Tender.
1 .1 .3 "Claim" means a request or assertion by one Party to the other Party for
an entitlement or relief under any Clause of these Conditions or otherwise
in connection with, or arising out of, the Contract or the execution of the
Works.
1.1 .7 "Contract" means the Contract Agreement, any addenda referred to in the
Contract Agreement, these Conditions, the Employer's Requirements, the
Schedules, the Tender, the JV Undertaking (if applicable) and the further
documents (if any) which are listed in the Contract Agreement.
1.1.8 "Contract Agreement" means the agreement entered into by both Parties
in accordance with Sub-Clause 1.6 [Contract Agreement], including any
annexed memoranda.
1.1.9 "Contract Data" means the pages, entitled contract data which constitute
Part A of the Particular Conditions.
1 .1 .10 "Contract Price" means the agreed amount stated in the Contract
Agreement for the execution of the Works, and includes adjustments (if any)
in accordance with the Contract.
1 .1 .16 "Cost" means all expenditure reasonably incurred (or to be incurred) by the
Contractor in performing the Contract, whether on or off the Site, including
taxes, overheads and similar charges, but does not include profit. Where the
Contractor is entitled under a Sub-Clause of these Conditions to payment of
Cost, it shall be added to the Contract Price.
1 .1 .17 "Cost Plus Profit" means Cost plus the applicable percentage for profit
stated in the Contract Data (if not stated, five percent (5%)). Such percentage
shall only be added to Cost, and Cost Plus Profit shall only be added to the
Contract Price, where the Contractor is entitled under a Sub-Clause of these
Conditions to payment of Cost Plus Profit.
1.1.18 "Country" means the country in which the Site (or most of it) is located,
where the Permanent Works are to be executed.
1 .1.20 "DAAB Agreement" means the agreement signed or deemed to have been
signed by both Parties and the sole member or each of the three members
(as the case may be) of the DMB in accordance with Sub-Clause 21.1
[Constitution of the DMB] or Sub-Clause 21.2 [Failure to Appoint OMB
Member(s)], incorporating by reference the General Conditions of Dispute
Avoidance/Adjudication Agreement contained in the Appendix to these
General Conditions with such amendments as are agreed.
1.1.21 "Date of Completion" means the date stated in the Taking-Over Certificate
issued by the Employer; or, if the last paragraph of Sub-Clause 10.1 [Taking
Over the Works and Sections] applies, the date on which the Works or Section
are deemed to have been completed in accordance with the Contract; or,
if taking over of part(s) of the Works is permitted under Sub-Clause 10.2
[Taking Over of Parts of the Works], the date on which such part(s) are taken
over or used by the Employer.
1 .1 .23 "Daywork Schedule" means the document entitled daywork schedule (if
any) included in the Contract, showing the amounts and manner of payments
to be made to the Contractor for labour, materials and equipment used for
daywork under Sub-Clause 13.5 [Daywork].
1.1.25 "Delay Damages" means the damages for which the Contractor shall be
liable under Sub-Clause 8.8 [Delay Damages] for failure to comply with
Sub-Clause 8.2 [Time for Completion].
(a) one Party makes a claim against the other Party (which may be a
Claim, as defined in these Conditions, or a matter to be determined by
the Employer's Representative under these Conditions, or otherwise);
(b) the other Party (if the Employer, under Sub-Clause 3.5.2 [Employer's
Representative's determination] or otherwise) rejects the claim in
whole or in part; and
(c) the first Party does not acquiesce (if the Contractor, by giving a
NOD under Sub-Clause 3.5.5 [Dissatisfaction with Employer's
Representative's determination] or otherwise),
provided however that a failure by the other Party to oppose or respond to the
claim, in whole or in part, may constitute a rejection if, in the circumstances,
the DAAB or the arbitrator(s), as the case may be, deem it reasonable for it
to do so.
1.1.27 "Employer" means the person named as the employer in the Contract
Agreement and the legal successors in title to this person.
1.1 .34 "Extension of Time" or "EOT" means an extension of the Time for
Completion under Sub-Clause 8.5 [Extension of Time for Completion].
1.1 .35 "FIDIC" means the Federation lnternationale des lngenieurs-Conseils, the
International Federation of Consulting Engineers.
1.1 .36 "Final Statement" means the Statement defined in Sub-Clause 14.11 .2
[Agreed Final Statement].
1 .1.37 "Foreign Currency" means a currency in which part (or all) of the Contract
Price is payable, but not the Local Currency.
1.1 .39 "Goods" means Contractor's Equipment, Materials, Plant and Temporary
Works, or any of them as appropriate.
1.1 .41 "JV Undertaking" means the letter provided to the Employer as part of the
Tender setting out the legal undertaking between the two or more persons
constituting the Contractor as a JV. This letter shall be signed by all the
persons who are members of the JV, shall be addressed to the Employer
and shall include:
1.1.43 "Laws" means all national (or state or provincial) legislation, statutes, acts,
decrees, rules, ordinances, orders, treaties, international law and other laws,
and regulations and by-laws of any legally constituted public authority.
1.1.45 "Materials" means things of all kinds (other than Plant), whether on the Site
or otherwise allocated to the Contract and intended to form or forming part
of the Permanent Works, including the supply-only materials (if any) to be
supplied by the Contractor under the Contract.
1.1 .49 "Notice of Dissatisfaction" or "NOD" means the Notice one Party may give
to the other Party if it is dissatisfied, either with an Employer's Representative's
determination under Sub-Clause 3.5 [Agreement or Determination] or with a
DAAB's decision under Sub-Clause 21.4 [Obtaining DAAB's Decision].
1.1.51 "Party" means the Employer or the Contractor, as the context requires.
"Parties" means both the Employer and the Contractor.
1.1 .52 "Performance Certificate" means the certificate issued by the Employer
(or deemed to be issued) under Sub-Clause 11.9 [Performance Certificate].
1 .1 .55 "Permanent Works" means the works of a permanent nature which are to
be executed by the Contractor under the Contract.
1.1 .56 "Plant" means the apparatus, equipment, machinery and vehicles (including
any components) whether on the Site or otherwise allocated to the Contract
and intended to form or forming part of the Permanent Works.
1.1 .58 "Provisional Sum" means a sum (if any) which is specified in the Contract
by the Employer as a provisional sum, for the execution of any part of the
Works or for the supply of Plant, Materials or services under Sub-Clause
13.4 [Provisional Sums].
1.1.59 "QM System" means the Contractor's quality management system (as may
be updated and/or revised from time to time) in accordance with Sub-Clause
4.9.1 [Quality Management System].
1.1.60 "Retention Money" means the accumulated retention moneys which the
Employer retains under Sub-Clause 14.3 [Application for Interim Payment]
and pays under Sub-Clause 14.9 [Release of Retention Money].
1.1.65 "Schedule of Rates and Prices" means the document(s) entitled schedule
of rates and prices (if any) in the Schedules.
1.1 .66 "Section" means a part of the Works specified in the Contract Data as a
Section (if any).
1.1.67 "Site" means the places where the Permanent Works are to be executed
and to which Plant and Materials are to be delivered, and any other places
specified in the Contract as forming part of the Site.
1.1 .68 "Special Provisions" means the document (if any), entitled special
provisions which constitutes Part B of the Particular Conditions.
1.1 .72 "Temporary Works" means all temporary works of every kind (other than
Contractor's Equipment) required on Site for the execution of the Works.
1.1 .73 "Tender" means the Contractor's signed offer for the Works, the JV
Undertaking (if applicable) and all other documents which the Contractor
submitted with the Tender (other than these Conditions, the Schedules and
the Employer's Requirements, if so submitted), as included in the Contract.
1.1 .74 "Tests after Completion" means the tests (if any) which are stated in the
Specification and which are carried out in accordance with the Special
Provisions after the Works or a Section (as the case may be) are taken over
under Clause 10 [Employer's Taking Over].
1.1.76 "Time for Completion" means the time for completing the Works or a
Section (as the case may be) under Sub-Clause 8.2 [Time for Completion],
as stated in the Contract Data as may be extended under Sub-Clause 8.5
[Extension of Time for Completion], calculated from the Commencement
Date.
1.1.79 "Works" mean the Permanent Works and the Temporary Works, or either of
them as appropriate.
1.2
Interpretation In the Contract, except where the context requires otherwise:
(a) words indicating one gender include all genders; and "he", "his" and
"himself" shall be read as "he/she", "his/her" and "himself/herself"
respectively;
(b) words indicating the singular also include the plural and words
indicating the plural also include the singular;
(c) provisions including the word "agree", "agreed" or "agreement"
require the agreement to be recorded in writing;
(d) "written" or "in writing" means hand-written, type-written, printed or
electronically made, and resulting in a permanent record;
(e) "may" means that the Party or person referred to has the choice of
whether to act or not in the matter referred to;
(D "shall" means that the Party or person referred to has an obligation
under the Contract to perform the duty referred to;
(g) "consent" means that the Employer or the Contractor (as the case
may be) agrees to, or gives permission for, the requested matter;
(h) "including", "include" and "includes" shall be interpreted as not being
limited to, or qualified by, the stated items that follow;
(i) words indicating persons or parties shall be interpreted as referring
to natural and legal persons (including corporations and other legal
entities); and
G) "execute the Works" or "execution of the Works" means the design,
construction and completion of the Works and the remedying of any
defects.
In any list in these Conditions, where the second-last item of the list is
followed by "and" or "or" or "and/or" then all of the list items going before
this item shall also be read as if they are followed by "and" or "or" or "and/
or" (as the case may be).
The marginal words and other headings shall not be taken into consideration
in the interpretation of these Conditions.
All Notices, and all other types of communication referred to above, shall not
be unreasonably withheld or delayed.
1.4
Law and Language The Contract shall be governed by the law of the country (or other jurisdiction)
stated in the Contract Data (if not stated, the law of the Country), excluding
any conflict of law rules.
The ruling language of the Contract shall be that stated in the Contract Data
(if not stated, the language of these Conditions). If there are versions of any
The language for communications shall be that stated in the Contract Data.
If no language is stated there, the language for communications shall be the
ruling language of the Contract.
1.5
Priority of Documents The documents forming the Contract are to be taken as mutually explanatory
of one another. If there is any conflict, ambiguity or discrepancy, the priority
of the documents shall be in accordance with the following sequence:
1.6
Contract Agreement The Contract shall come into full force and effect on the date stated in the
Contract Agreement. The costs of stamp duties and similar charges (if any)
imposed by law in connection with entry into the Contract Agreement shall
be borne by the Employer.
1.7
Assignment Neither Party shall assign the whole or any part of the Contract or any benefit
or interest in or under the Contract. However, either Party:
(a) may assign the whole or any part of the Contract with the prior
agreement of the other Party, at the sole discretion of such other
Party; and
(b) may, as security in favour of a bank or financial institution, assign
the Party's right to any moneys due, or to become due, under the
Contract without the prior agreement of the other Party.
1.8
Care and Supply
of Documents Each of the Contractor's Documents shall be in the custody and care of
the Contractor, unless and until submitted to the Employer. The Contractor
shall supply to the Employer one paper-original, one electronic copy (in the
form as specified in the Employer's Requirements or, if not stated, a form
acceptable to the Employer) and additional paper copies (if any) as stated in
the Contract Data of each of the Contractor's Documents.
1.9
Employer's Use of
Contractor's Documents As between the Parties, the Contractor shall retain the copyright and other
intellectual property rights in the Contractor's Documents and other design
documents made by (or on behalf of) the Contractor.
The Contractor shall be deemed (by signing the Contract Agreement) to give
to the Employer a non-terminable transferable non-exclusive royalty-tree
licence to copy, use and communicate the Contractor's Documents and
such other design documents, including making and using modifications of
them. This licence shall:
1.10
Contractor's Use of
Employer's Documents As between the Parties, the Employer shall retain the copyright and other
intellectual property rights in the Employer's Requirements and other
documents made by (or on behalf o~ the Employer. The Contractor may, at
the Contractor's cost, copy, use and communicate these documents for the
purposes of the Contract.
These documents (in whole or in part) shall not, without the Employer's
prior consent, be copied, used or communicated to a third party by the (/)
;?
Contractor, except as necessary for the purposes of the Contract. er.:
0LL
1.11 -·-----···------~-··-·--·-··---
Confidentiality The Contractor shall disclose all such confidential and other information
as the Employer may reasonably require in order to verify the Contractor's
compliance with the Contract.
The Contractor shall treat all documents forming the Contract as confidential,
except to the extent necessary to carry out the Contractor's obligations
under the Contract. The Contractor shall not publish, permit to be published,
or disclose any particulars of the Contract in any trade or technical paper or
elsewhere without the Employer's prior consent.
The Employer and the Employer's Personnel shall treat all information
provided by the Contractor and marked "confidential", as confidential. The
Employer and the Employer's Personnel shall not disclose or permit to be
disclosed any such information to third parties, except as may be necessary
when exercising the Employer's rights under Sub-Clause 15.2 [Termination
for Contractor's Default].
i .12
Compliance with Laws The Contractor and the Employer shall, in performing the Contract,
comply with all applicable Laws. Unless otherwise stated in the Employer's
Requirements:
(a) the Employer shall have obtained (or shall obtain) the planning,
zoning or building permit or similar permits, permissions, licences
and/or approvals for the Permanent Works, and any other permits,
permissions, licenses and/or approvals described in the Employer's
Requirements as having been (or being) obtained by the Employer.
The Employer shall indemnify and hold the Contractor harmless
against and from the consequences of any delay or failure to do so,
(a) the members of the JV shall be jointly and severally liable to the
Employer for the performance of the Contractor's obligations under
the Contract;
(b) the JV leader shall have authority to bind the Contractor and each
member of the JV; and
(c) neither the members nor (if known) the scope and parts of the Works
to be carried out by each member nor the legal status of the JV shall
be altered without the prior consent of the Employer (but such consent
shall not relieve the altered JV from any liability under sub-paragraph
(a) above).
1.14
Limitation of liability Neither Party shall be liable to the other Party for loss of use of any Works,
loss of profit, loss of any contract or for any indirect or consequential loss
or damage which may be suffered by the other Party in connection with the
Contract, other than under:
shall not exceed the sum stated in the Contract Data or (if a sum is not so
it
C'
u...
stated) the Contract Price stated in the Contract Agreement.
This Sub-Clause shall not limit liability in any case of fraud, gross negligence,
deliberate default or reckless misconduct by the defaulting Party.
Contract Termination Subject to any mandatory requirements under the governing law of the
Contract, termination of the Contract under any Sub-Clause of these
Conditions shall require no action of whatsoever kind by either Party other
than as stated in the Sub-Clause.
2.1
Right of Access to the Site The Employer shall give the Contractor right of access to, and possession
of, all parts of the Site within the time (or times) stated in the Contract Data.
The right and possession may not be exclusive to the Contractor. If, under
the Contract, the Employer is required to give (to the Contractor) possession
of any foundation, structure, plant or means of access, the Employer shall
do so in the time and manner stated in the Employer's Requirements.
However, the Employer may withhold any such right or possession until the
Performance Security has been received.
If no such time is stated in the Contract Data, the Employer shall give the
Contractor right of access to, and possession of, the Site with effect from
the Commencement Date.
However, if and to the extent that the Employer's failure was caused by
any error or delay by the Contractor, including an error in, or delay in the
submission of, any of the applicable Contractor's Documents, the Contractor
shall not be entitled to such EOT and/or Cost Plus Profit.
If, under the Contract, the Employer is required to give to the Contractor
possession of any foundation, structure, plant or means of access in
2.2
Assistance If requested by the Contractor, the Employer shall promptly provide
reasonable assistance to the Contractor so as to allow the Contractor to
obtain:
(a) copies of the Laws of the Country which are relevant to the Contract
but are not readily available; and
(b) any permits, permissions, licences or approvals required by the Laws
of the Country (including information required to be submitted by the
Contractor in order to obtain such permits, permissions, licences or
approvals):
(i) which the Contractor is required to obtain under Sub-Clause
1 .12 [Compliance with Laws];
(ii) for the delivery of Goods, including clearance through customs;
and
(iii) for the export of Contractor's Equipment when it is removed from
the Site.
2.4
Employer's Financial
Arrangements The Employer's arrangements for financing the Employer's obligations under
the Contract shall be detailed in the Contract Data.
If the Employer intends to make any material change (affecting the Employer's
ability to pay the part of the Contract Price remaining to be paid at that time as
estimated by the Employer) to these financial arrangements, or has to do so
because of changes in the Employer's financial situation, the Employer shall
immediately give a Notice to the Contractor with detailed supporting particulars.
If the Contractor:
2.5
Site Data and
Items of Reference The Employer shall have made available to the Contractor for information,
before the Base Date, all relevant data in the Employer's possession on
the topography of the Site and on sub-surface, hydrological, climatic and
environmental conditions at the Site. The Employer shall promptly make
available to the Contractor all such data which comes into the Employer's
possession after the Base Date.
The original survey control points, lines and levels of reference (the "items of
reference" in these Conditions) shall be specified in the Employer's Requirements.
2.6
Employer-Supplied Mate rials
and Employer's Equipment If Employer-Supplied Materials and/or Employer's Equipment are listed in
the Employer's Requirements for the Contractor's use in the execution of the
Works, the Employer shall make such materials and/or equipment available
to the Contractor in accordance with the details, times, arrangements, rates
and prices stated in the Employer's Requirements.
player's Administration
3.1
The Employer's Representative The Employer shall appoint the Employer's Representative who, except
as otherwise stated in these Conditions, shall be deemed to act on the
Employer's behalf under the Contract.
The Employer's Representative shall be vested with, and (unless and until
the Employer notifies the Contractor otherwise) shall be deemed to have, the
full authority of the Employer under the Contract except in respect of Clause
15 [Termination by Employer].
(a) carry out the duties assigned to him/her, and exercise the authority
The Employer shall not replace the Employer's Representative with a person
(whether a legal entity or a natural person) against whom the Contractor has
raised reasonable objection by a Notice under this Sub-Clause.
3.2
Other Employer's Personnel The Employer or the Employer's Representative may from time to time
assign duties and delegate authority to assistants, and may also revoke
such assignment or delegation, by giving a Notice to the Contractor of
the name, assigned duties and delegated authority of the assistant. The
assignment, delegation or revocation shall not take effect until this Notice
has been received by the Contractor.
However, the Employer's Representative shall not delegate the authority to:
3.3
Delegated Persons All persons, including the Employer's Representative and assistants, to whom
duties have been assigned or authority has been delegated by a Notice of
delegation given under Sub-Clause 3.1 [The Employer's Representative] or
Sub-Clause 3.2 [Other Employer's Personne~ (as the case may be), shall
only be authorised to issue instructions and communications and/or to give
Notices to the Contractor to the extent defined by the Notice of delegation.
Any acceptance, agreement, approval, check, certificate, comment, consent,
disapproval, examination, inspection, instruction, Notice, No-objection,
record(s) of meeting, permission, proposal, record, reply, report, request,
Review, test, valuation, or similar act (including the absence of any such act)
by a delegated person, in accordance with the Notice of delegation, shall
have the same effect as though the act had been an act of the Employer.
However:
3.4
Instructions The Employer may, through the Employer's Representative or an assistant as
stated below, issue to the Contractor (at any time) instructions which may be
necessary for the execution of the Works, all in accordance with the Contract.
Each instruction shall state the obligation(s) to which it relates and the Sub-Clause
(or other term of the Contract) in which the obligation(s) are specified.
The Contractor shall only take instructions from the Employer's Representative
or an assistant to whom the appropriate authority to give instruction has
been delegated by a Notice given under Sub-Clause 3.2 [Other Employer's
Personne~.
3.5
Agreement or Determination When carrying out his/her duties under this Sub-Clause, the Employer's
Representative shall not be deemed to act for the Employer.
The Employer's Representative shall consult with both Parties jointly and/
or separately, and shall encourage discussion between the Parties in an
endeavour to reach agreement. The Employer's Representative shall
commence such consultation promptly to allow adequate time to comply
If agreement is achieved within the time limit for agreement under Sub-Clause
3.5.3 [Time limits], the Employer's Representative shall give a Notice to both
u Parties of the agreement, which agreement shall be signed by both Parties.
()
z This Notice shall state that it is a "Notice of the Parties' Agreement" and shall
r.3 include a copy of the agreement.
5
('.'5
If:
(a) no agreement is achieved within the time limit for agreement under
Sub-Clause 3.5.3 [Time limits]; or
(b) both Parties advise the Employer's Representative that no agreement
can be achieved within this time limit
whichever is the earlier, the Employer's Representative shall give a Notice
to the Parties accordingly and shall immediately proceed under Sub-Clause
3.5.2 [Employer's Representative's determination].
The Employer's Representative shall make a fair determination of the matter or Claim,
in accordance with the Contract, taking due regard of all relevant circumstances.
Within the time limit for determination under Sub-Clause 3.5.3 [Time limits],
the Employer's Representative shall give a Notice to both Parties of his/her
determination. This Notice shall state that it is a "Notice of the Employer's
Representative's Determination", and shall describe the determination in
detail with reasons and detailed supporting particulars.
The Employer's Representative shall within 7 days after finding the error, or
after receiving a Notice under sub-paragraph (b) above (as the case may be),
give a Notice to both Parties of the corrected agreement or determination.
Thereafter, the corrected agreement or determination shall be treated as the
agreement or determination for the purpose of these Conditions.
(a) the dissatisfied Party may give a NOD to the other Party, with a copy
to the Employer's Representative;
(b) this NOD shall state that it is a "Notice of Dissatisfaction with the
Employer's Representative's Determination" and shall set out the
reason(s) for dissatisfaction;
(c) this NOD shall be given within 28 days after receiving the Employer's
Representative's Notice of the determination under Sub-Clause 3.5.2
[Employer's Representative's Determination] or, if applicable, his/
(ii) this part(s), and any other parts of the determination that are affected
by such part(s) or rely on such part(s) for completeness, shall be
deemed to be severable from the remainder of the determination; and
(iii) the remainder of the determination shall become final and binding on
both Parties as if the NOD had not been given.
In the event that a Party fails to comply with an agreement of the Parties under
this Sub-Clause 3.5 or a final and binding determination of the Employer's
Representative, the other Party may, without prejudice to any other rights it
may have, refer the failure itself directly to arbitration under Sub-Clause 21.6
[Arbitration] in which case the first and the third paragraphs of Sub-Clause
21.7 [Failure to Comply with DMB's Decision] shall apply to such reference
in the same manner as these paragraphs apply to a final and binding decision
of the DAAB.
3.6
Either Party may require the other Party to attend a management meeting
to discuss arrangements for future work and/or other matters in connection
with execution of the Works.
The Employer shall keep a record of each management meeting and supply
copies of the record to those attending. At any such meeting, and in the
record, responsibilities for any actions to be taken shall be in accordance
with the Contract.
T ntractor
4.1
Contractor's
General Obligations The Contractor shall execute the Works in accordance with the Contract.
When completed, the Works (or Section or major item of Plant, if any) shall be
fit for the purpose(s) for which they are intended, as defined and described
in the Employer's Requirements or, where no purpose(s) are so defined and
described, fit for their ordinary purpose(s).
The Works shall include any work which is necessary to satisfy the Employer's
Requirements and Schedules, or is implied by the Contract, and all works
which (although not mentioned in the Contract) are necessary for stability or
for the completion, or safe and proper operation, of the Works.
The Contractor shall be responsible for the adequacy, stability and safety of
all the Contractor's operations and activities, of all methods of construction
and of all the Works.
(!)
4.2
Performance The Contractor shall obtain (at the Contractor's cost) a Performance Security
to secure the Contractor's proper performance of the Contract, in the
amount and currencies stated in the Contract Data. If no amount is stated in
the Contract Data, this Sub-Clause shall not apply.
The Contractor shall ensure that the Performance Security remains valid and
enforceable until the issue of the Performance Certificate and the Contractor
has complied with Sub-Clause 11.11 [Clearance of Site]. If the terms of
the Performance Security specify an expiry date, and the Contractor has
not become entitled to receive the Performance Certificate by the date 28
days before the expiry date, the Contractor shall extend the validity of the
Performance Security until the issue of the Performance Certificate and the
Contractor has complied with Sub-Clause 11.11 [Clearance of Site].
The Employer shall not make a claim under the Performance Security, except for
amounts to which the Employer is entitled under the Contract in the event of:
L....J
()
z (a) failure by the Contractor to extend the validity of the Performance
q Security, as described in this Sub-Clause, in which event the Employer
may claim the full amount (or, in the case of previous reduction(s), the
0
full remaining amount) of the Performance Security;
{b) failure by the Contractor to pay the Employer an amount due, as agreed
or determined under Sub-Clause 3.5 [Agreement or Determination] or
01
agreed or decided under Clause 21 [Disputes and Arbitration], within
2 42 days after the date of the agreement or determination or decision
0:.:
C.~J
:.~ ..
or arbitral award (as the case may be);
(c) failure by the Contractor to remedy a default stated in a Notice given
under Sub-Clause 15.1 [Notice to Correct] within 42 days or other
time (if any) stated in the Notice;
{d) circumstances which entitle the Employer to terminate the Contract
under Sub-Clause 15.2 [Termination tor Contractor's Default],
irrespective of whether a Notice of termination has been given; or
(e) if under Sub-Clause 11.5 [Remedying of Detective Work off Site] the
Contractor removes any defective or damaged Plant from the Site,
failure by the Contractor to repair such Plant, return it to the Site,
reinstall it and retest it by the date of expiry of the relevant duration
stated in the Contractor's Notice (or other date agreed by the
Employer).
The Employer shall indemnify and hold the Contractor harmless against and
from all damages, losses and expenses (including legal fees and expenses)
resulting from a claim under the Performance Security to the extent that the
Employer was not entitled to make the claim.
(i) in the final payment to the Contractor under Sub-Clause 14.13 [Final
Payment]; or
(ii) if the Contract is terminated, in payment due to the Contractor
under Sub-Clause 15.4 [Payment after Termination tor Contractor's
Default], Sub-Clause 15. 7 [Payment after Termination tor Employer's
Convenience], Sub-Clause 16.4 [Payment after Termination by
Contractor], Sub-Clause 18.5 [Optional Termination], or Sub-Clause
18.6 [Re/ease from Performance under the Law] (as the case may be).
(a) within 21 days after the issue of the Performance Certificate and the
Contractor has complied with Sub-Clause 11.11 [Clearance of Site];
or
(b) promptly after the date of termination if the Contract is terminated
in accordance with Sub-Clause 15.5 [Termination tor Employer's
Convenience], Sub-Clause 16.2 [Termination by Contractor],
Sub-Clause 18.5 [Optional Termination] or Sub-Clause 18.6 [Re/ease
from Performance under the Law].
The Contractor shall not, without the Employer's prior consent, revoke the
appointment of the Contractor's Representative or appoint a replacement
(unless the Contractor's Representative is unable to act as a result of death,
illness, disability or resignation, in which case his/her appointment shall be
deemed to have been revoked with immediate effect and the appointment
of a replacement shall be treated as a temporary appointment until the
Employer gives his/her consent to this replacement, or another replacement
is appointed, under this Sub-Clause).
Unless otherwise agreed by the Employer, the whole time of the Contractor's
Representative shall be given to directing the Contractor's performance of
the Contract. The Contractor's Representative shall act for and on behalf
of the Contractor at all times during the performance of the Contract,
including issuing and receiving all Notices and other communications under
Sub-Clause 1 .3 [Notices and Other Communications] and for receiving
instructions under Sub-Clause 3.4 [Instructions].
(a) the authority to issue and receive Notices and other communications
under Sub-Clause 1 .3 [Notices and Other Communications]; and
(b) the authority to receive instructions under Sub-Clause 3.4
[Instructions]),
to any suitably competent and experienced person and may at any time
revoke the delegation. Any delegation or revocation shall not take effect until
the Employer has received a Notice from the Contractor's Representative,
naming the person, specifying the powers, functions and authority being
delegated or revoked, and stating the timing of the delegation or revocation.
4.4
Subcontractors The Contractor shall not subcontract:
(a) works with a total accumulated value greater than the percentage
stated in the Contract Data of the Contract Price stated in the Contract
Agreement (if no such percentage is stated, the whole of the Works);
or
(b) any part of the Works for which subcontracting is not permitted as
stated in the Contract Data.
The Contractor shall be responsible for the work of all Subcontractors, for
managing and coordinating all the Subcontractors' works, and for the acts
or defaults of any Subcontractor, any Subcontractor's agents or employees,
as if they were the acts or defaults of the Contractor.
Where specified in the Contract Data, the Contractor shall give a Notice to
the Employer not less than 28 days before:
4.5
Nominated
Subcontractors In this Sub-Clause, "nominated Subcontractor" means a Subcontractor
named as such in the Employer's Requirements or whom the Employer,
under Sub-Clause 13.4 [Provisional Sums], instructs the Contractor to
employ as a Subcontractor.
(a) there are reasons to believe that the Subcontractor does not have
sufficient competence, resources or financial strength;
(b) the subcontract does not specify that the nominated Subcontractor
shall indemnify the Contractor against and from any negligence or
misuse of Goods by the nominated Subcontractor, the nominated
Subcontractor's agents and employees; or
(c) the subcontract does not specify that, for the subcontracted work
(including design, if any), the nominated Subcontractor shall:
(i) undertake to the Contractor such obligations and liabilities
as will enable the Contractor to discharge the Contractor's
corresponding obligations and liabilities under the Contract; and
The Contractor shall pay to the nominated Subcontractor the amounts due
in accordance with the subcontract. These amounts plus other charges shall
be included in the Contract Price in accordance with sub-paragraph (b} of
Sub-Clause 13.4 [Provisional Sums], except as stated in Sub-Clause 4.5.3
[Evidence of Payments].
Thereafter, the Employer shall give a Notice to the Contractor stating the
amount paid directly to the nominated Subcontractor by the Employer and,
in the next interim payment after this Notice, shall include this amount as a
deduction under sub-paragraph (b} of Sub-Clause 14.6.1 [Notice of Interim
Payment].
4.6
Co~operation The Contractor shall, as specified in the Employer's Requirements or
as instructed by the Employer, co-operate with and allow appropriate
opportunities for carrying out work by:
4.7
Setti11g Out The Contractor shall set out the Works in relation to the items of reference
under Sub-Clause 2.5 [Site Data and Items of Reference].
(a) verify the accuracy of all these items of reference before they are used
for the Works;
(b) rectify any error in the items of reference, positions, levels, dimensions
or alignment of the Works; and
(c) be responsible for the correct positioning of all parts of the Works.
4.8
Health arid Safety
Obligations The Contractor shall:
(a) comply with all applicable health and safety regulations and Laws;
(b) comply with all applicable health and safety obligations specified in
the Contract;
(c) comply with all directives issued by the Contractor's health and
safety officer (appointed under Sub-Clause 6. 7 [Health and Safety of
Personnem;
(d) take care of the health and safety of all persons entitled to be on the
Site and other places (if any) where the Works are being executed;
(e) keep the Site, Works (and the other places (if any) where the Works
are being executed) clear of unnecessary obstruction so as to avoid
danger to these persons;
(t) provide fencing, lighting, safe access, guarding and watching of:
(i) the Works, until the Works are taken over under Clause 10
[Employer's Taking Over]; and
(ii) any part of the Works where the Contractor is executing
outstanding works or remedying any defects during the DNP; and
(g) provide any Temporary Works (including roadways, footways, guards
and fences) which may be necessary, because of the execution of the
Works, for the use and protection of the public and of owners and
occupiers of adjacent land and property.
Within 21 days of the Commencement Date and before commencing any
construction on the Site, the Contractor shall submit to the Employer for
information a health and safety manual which has been specifically prepared
for the Works, the Site and other places (if any) where the Contractor intends
to execute the Works. This manual shall be in addition to any other similar
document required under applicable health and safety regulations and Laws.
The health and safety manual shall set out all the health and safety
requirements:
The QM System shall be in accordance with the details stated in the Employer's
Requirements (if any) and shall include the Contractor's procedures:
(a) to ensure that all Notices and other communications under Sub-Clause
1.3 [Notices and Other Communications], Contractor's Documents,
as-built records, O&M Manuals, and contemporary records can be
traced, with full certainty, to the Works, Goods, work, workmanship
or test to which they relate;
(b) to ensure proper coordination and management of interfaces between
the stages of execution of the Works, and between Subcontractors;
and
(c) for the submission of Contractor's Documents to the Employer for
Review.
The Contractor shall carry out internal audits of the QM System regularly, and
at least once every 6 months. The Contractor shall submit to the Employer
a report listing the results of each internal audit within 7 days of completion.
Each report shall include, where appropriate, the proposed measures to
improve and/or rectify the QM System and/or its implementation.
4.10
Use of Site Data The Contractor shall be responsible for verifying and interpreting all data
made available by the Employer under Sub-Clause 2.5 [Site Data and Items
of Reference].
4.11
Sufficiency of the
Contract Price The Contractor shall be deemed to have satisfied himself/herself as to the
correctness and sufficiency of the Contract Price stated in the Contract
Agreement.
Unless otherwise stated in the Contract, the Contract Price stated in the
Contract Agreement shall be deemed to cover all the Contractor's obligations
under the Contract and all things necessary for the proper execution of the
Works in accordance with the Contract.
4.12
Unforeseeable Difficulties Except as otherwise stated in the Particular Conditions:
4.13
Rights of Way and Facilities The Contractor shall bear all costs and charges for special and/or temporary
rights-of-way which may be required for the purposes of the Works, including
those for access to the Site.
The Contractor shall also obtain, at the Contractor's risk and cost, any
additional facilities outside the Site which may be required for the purposes
of the Works.
The Contractor shall indemnify and hold the Employer harmless against and
from all damages, losses and expenses (including legal fees and expenses)
resulting from any such unnecessary or improper interference.
4.15
Access Route The Contractor shall be deemed to have been satisfied, at the Base Date,
as to the suitability and availability of the access routes to the Site. The
Contractor shall take all necessary measures to prevent any road or bridge
from being damaged by the Contractor's traffic or by the Contractor's
Personnel. These measures shall include the proper use of appropriate
vehicles (conforming to legal load and width limits (if any) and any other
restrictions) and routes.
(a) the Contractor shall (as between the Parties) be responsible for repair
of any damage caused to, and any maintenance which may be
required for the Contractor's use of, access routes;
(b) the Contractor shall provide all necessary signs or directions along
access routes, and shall obtain any permissions or permits which
may be required from the relevant authorities, for the Contractor's use
of routes, signs and directions;
(c) the Employer shall not be responsible for any third party claims which
may arise from the Contractor's use or otherwise of any access route;
(d) the Employer does not guarantee the suitability or availability of
particular access routes; and
(e) all Costs due to non-suitability or non-availability, for the use required
by the Contractor, of access routes shall be borne by the Contractor.
4.16
Transport of Goods The Contractor shall:
(a) give a Notice to the Employer not less than 21 days before the date
on which any Plant, or a major item of other Goods (as specified in the
Employer's Requirements), will be delivered to the Site;
(b) be responsible for packing, loading, transporting, receiving, unloading,
storing and protecting all Goods and other things required for the Works;
(c) be responsible for customs clearance, permits, fees and charges
related to the import, transport and handling of all Goods, including
all obligations necessary for their delivery to the Site; and
(d) indemnify and hold the Employer harmless against and from all
damages, losses and expenses (including legal fees and expenses)
resulting from the import, transport and handling of all Goods, and
Contractor's The Contractor shall be responsible for all Contractor's Equipment. When
brought on to the Site, Contractor's Equipment shall be deemed to be
exclusively intended for the execution of the Works. The Contractor shall
not remove from the Site any major items of Contractor's Equipment without
the Employer's consent. However, consent shall not be required for vehicles
i .... )
transporting Goods or Contractor's Personnel off Site.
~
'-...)
4.18
Protection of
the Environment The Contractor shall take all necessary measures to:
The Contractor shall ensure that emissions, surface discharges, effluent and
any other pollutants from the Contractor's activities shall exceed neither the
values indicated in the Employer's Requirements, nor those prescribed by
applicable Laws.
4.19
Temporary Utilities The Contractor shall, except as stated below, be responsible for the provision
of all temporary utilities, including electricity, gas, telecommunications, water
and any other services the Contractor may require for the execution of the
Works.
The following provisions of this Sub-Clause shall only apply if, as stated
in the Employer's Requirements, the Employer is to provide utilities for the
Contractor's use. The Contractor shall be entitled to use, for the purposes
of the Works, the utilities on the Site for which details and prices are given
in the Employer's Requirements. The Contractor shall, at the Contractor's
risk and cost, provide any apparatus necessary for the Contractor's use of
these services and for measuring the quantities consumed. The apparatus
provided for measuring quantities consumed shall be subject to the
Employer's consent. The quantities consumed (if any) during each period
of payment stated in the Contract Data (if not stated, each month) shall be
measured by the Contractor, and the amount to be paid by the Contractor
for such quantities (at the prices stated in the Employer's Requirements)
shall be included in the relevant Statement.
4.20
Progress Reports Monthly progress reports, in the format stated in the Employer's Requirements
(if not stated, in a format acceptable to the Employer) shall be prepared by
the Contractor and submitted to the Employer. Each progress report shall
Reporting shall continue until the Date of Completion of the Works or, if
outstanding work is listed in the Taking-Over Certificate, the date on which
such outstanding work is completed. Unless otherwise stated in the
Employer's Requirements, each progress report shall include:
4.21
Security of the Site The Contractor shall be responsible for the security of the Site, and:
4.22
Contractor's Operations
on Site The Contractor shall confine the Contractor's operations to the Site, and
to any additional areas which may be obtained by the Contractor and
acknowledged by the Employer as working areas. The Contractor shall take
At all times, the Contractor shall keep the Site free from all unnecessary
obstruction, and shall properly store or remove from the Site any Contractor's
Equipment (subject to 4.17 [Contractor's Equipment]) and/or surplus
materials. The Contractor shall promptly clear away and remove from the
Site any wreckage, rubbish, hazardous waste and Temporary Works which
f.. .. ) are no longer required.
~
\..:)
4.23
Archaeological and
All fossils, coins, articles of value or antiquity, and structures and other
remains or items of geological or archaeological interest found on the Site
shall be placed under the care and authority of the Employer. The Contractor
shall take all reasonable precautions to prevent Contractor's Personnel or
other persons from removing or damaging any of these findings.
If the Contractor suffers delay and/or incurs Cost from complying with
the Employer's instructions, the Contractor shall be entitled subject to
Sub-Clause 20.2 [Claims For Payment and/or E01] to EOT and/or payment
of such Cost.
D
5.i
General Design
Obligations The Contractor shall be deemed to have scrutinised, prior to the Base Date,
the Employer's Requirements (including design criteria and calculations, if
any).
The Contractor shall carry out, and be responsible for, the design of the
Works and for the accuracy of such Employer's Requirements (including
design criteria and calculations), except as stated in this Sub-Clause below.
The Employer shall not be responsible for any error, inaccuracy or omission
of any kind in the Employer's Requirements as originally included in the
Contract and shall not be deemed to have given any representation of
accuracy or completeness of any data or information, except as stated in
this Sub-Clause below. Any data or information received by the Contractor,
from the Employer or otherwise, shall not relieve the Contractor from the
Contractor's responsibility for the execution of the Works.
(a) portions, data and information which are stated in the Contract as
being immutable or the responsibility of the Employer,
(b) definitions of intended purposes of the Works or any parts thereof,
(c) criteria for the testing and performance of the completed Works, and
(d) portions, data and information which cannot be verified by the
Contractor, except as otherwise stated in the Contract.
5.2
Contractor's
Documents The Contractor's Documents shall comprise the documents:
The Contractor shall prepare all Contractor's Documents, and any other
documents necessary to complete and implement the design during
execution of the Works and to instruct the Contractor's Personnel.
The Employer shall, within the Review Period, give a Notice to the Contractor:
If the Employer gives no Notice within the Review Period, the Employer
shall be deemed to have given a Notice of No-objection to the Contractor's
Document (provided that all other Contractor's Documents on which that
Contractor's Document relies (if any) have been given, or are deemed to
have been given, a Notice of No-objection).
If the Employer gives a Notice under sub-paragraph (b) above, the Contractor
shall:
5.2.3 Construction
5.3
Contractor's Undertaking The Contractor undertakes that the design, the Contractor's Documents,
the execution of the Works and the completed Works will be in accordance
with:
5.4
Technical Standards
and Regulations The Contractor's Documents, the execution of the Works and the completed
Works (including defects remedied by the Contractor) shall comply with the
Country's technical standards, building, construction and environmental
Laws, Laws applicable to the product being produced from the Works, and
other standards specified in the Employer's Requirements, applicable to the
Works, or defined by applicable Laws.
All these technical or other standards and Laws shall, in respect of the
Works, and each Section, be those in force when the Works or Section are
taken over under Clause 10 [Employer's Taking Over].
5.5
Training If no training of employees of the Employer (and/or other identified
personnel) by the Contractor is specified in the Employer's Requirements,
this Sub-Clause shall not apply.
The Contractor shall carry out training of employees of the Employer (and/or
other personnel identified in the Employer's Requirements) in the operation
and maintenance of the Works, and any other aspect of the Works, to the
extent specified in the Employer's Requirements.
5.6
As-Built Records If no as-built records to be prepared by the Contractor are specified in the
Employer's Requirements, this Sub-Clause shall not apply.
The Contractor shall submit to the Employer under Sub-Clause 5.2.2 [Review
by Employer]:
(a) the as-built records for the Works or Section (as the case may be)
before the commencement of the Tests on Completion; and
{b) updated as-built records to the extent that any work is executed by
the Contractor:
(i) during and/or after the Tests on Completion, before the issue of
any Taking-Over Certificate under Sub-Clause 10.1 [Taking Over
the Works and Sections]; and
(ii) after taking over under Sub-Clause 10 .1 [Taking Over the Works
and Sections], before the issue of the Performance Certificate.
5.7
Operation and
Maintenance Manuals If no operation and maintenance manuals to be prepared by the Contractor
are specified in the Employer's Requirements, this Sub-Clause shall not apply.
The format and other relevant details of the O&M Manuals shall be as stated
in the Employer's Requirements and, in any case, these manuals shall:
If during the Tests on Completion any error or defect is found in the provisional
O&M Manuals, the Contractor shall promptly rectify the error or defect at the
Contractor's risk and cost.
5.8
Design Errrcw If errors, omissions, ambiguities, inconsistencies, inadequacies or other defects
are found in the Contractor's design and/or the Contractor's Documents, they
and the Works shall be corrected in accordance with Sub-Clause 7 .5 [Defects
and Rejection]. If such Contractor's Documents were previously the subject of
a Notice of No-objection given (or deemed to be given) by the Employer under
Sub-Clause 5.2.2 [Review by Employer], the provisions of Sub-Clause 5.2.2
shall apply as if the Employer had given a Notice in respect of the Contractor's
Documents under sub-paragraph (b) of Sub-Clause 5.2.2.
St nd Labour
6.1
Engagement of
Staff and Labour Except as otherwise stated in the Specification, the Contractor shall make
arrangements for the engagement of all Contractor's Personnel, and for their
payment, accommodation, feeding, transport and welfare.
6.2
Rates of Wages and
Conditions of Labour The Contractor shall pay rates of wages, and observe conditions of labour,
which comply with all applicable Laws and are not lower than those
established for the trade or industry where the work is carried out.
6.3
Recruitment of Persons The Contractor shall not recruit, or attempt to recruit, staff and labour from
amongst the Employer's Personnel.
6.4
Labom Laws The Contractor shall comply with all the relevant labour Laws applicable
to the Contractor's Personnel, including Laws relating to their employment
(including wages and working hours), health, safety, welfare, immigration
and emigration, and shall allow them all their legal rights.
The Contractor shall require the Contractor's Personnel to obey all applicable
Laws, including those concerning health and safety at work.
6.5
Working Hours No work shall be carried out on the Site on locally recognised days of rest,
or outside the normal working hours stated in the Contract Data, unless:
6.6
Facilities for
Staff and labour Except as otherwise stated in the Employer's Requirements, the Contractor
shall provide and maintain all necessary accommodation and welfare facilities
for the Contractor's Personnel.
6.7
Health and Safety
of Personnel In addition to the requirements of Sub-Clause 4.8 [Health and Safety
Obligations], the Contractor shall at all times take all necessary precautions to
maintain the health and safety of the Contractor's Personnel. In collaboration
with local health authorities, the Contractor shall ensure that:
(a) medical staff, first aid facilities, sick bay, ambulance services and
any other medical services stated in the Employer's Requirements
are available at all times at the Site and at any accommodation for
Contractor's and Employer's Personnel; and
(b) suitable arrangements are made for all necessary welfare and hygiene
requirements and for the prevention of epidemics.
The Contractor shall appoint a health and safety officer at the Site, responsible
for maintaining health, safety and protection against accidents. This officer shall:
Throughout the execution of the Works, the Contractor shall provide whatever
is required by this person to exercise this responsibility and authority.
6.8
Contractor's
Superintendence From the Commencement Date until the issue of the Performance Certificate,
the Contractor shall provide all necessary superintendence to plan, arrange,
direct, manage, inspect, test and monitor the execution of the Works.
(a) who are fluent in or have adequate knowledge of the language for
communications (defined in Sub-Clause 1.4 [Law and Language]);
and
(b) who have adequate knowledge of the operations to be carried out
(including the methods and techniques required, the hazards likely to
be encountered and methods of preventing accidents),
for the satisfactory and safe execution of the Works.
6.9
Contractor's Personnel The Contractor's Personnel (including Key Personnel, if any) shall be
appropriately qualified, skilled, experienced and competent in their respective
trades or occupations.
The Employer may require the Contractor to remove (or cause to be removed)
any person employed on the Site or Works, including the Contractor's
Representative and Key Personnel (if any), who:
6.10
Contractor's Records Unless otherwise proposed by the Contractor and agreed by the Employer,
in each progress report under Sub-Clause 4.20 [Progress Reports], the
Contractor shall include records of:
6.11
Disorderly Conduct The Contractor shall at all times take all necessary precautions to prevent
any unlawful, riotous or disorderly conduct by or amongst the Contractor's
Personnel, and to preserve peace and protection of persons and property
on and near the Site.
Key Personnel If no Key Personnel are specified in the Employer's Requirements this
Sub-Clause shall not apply.
The Contractor shall appoint the natural persons named in the Tender to the
positions of Key Personnel. If not so named, or if an appointed person fails
to act in the relevant position of Key Personnel, the Contractor shall submit
to the Employer for consent the name and particulars of another person the
Contractor proposes to appoint to such position. If consent is withheld or
subsequently revoked, the Contractor shall similarly submit the name and
particulars of a suitable replacement for such position.
If the Employer does not respond within 14 days after receiving any such
submission, by giving a Notice stating an objection to the appointment of
such person (or replacement) with reasons, the Employer shall be deemed
to have given the Employer's consent.
The Contractor shall not, without the Employer's prior consent, revoke the
appointment of any of the Key Personnel or appoint a replacement (unless
the person is unable to act as a result of death, illness, disability or resignation,
in which case the appointment shall be deemed to have been revoked with
immediate effect and the appointment of a replacement shall be treated as
a temporary appointment until the Employer gives his/her consent to this
replacement, or another replacement is appointed, under this Sub-Clause).
All Key Personnel shall be based at the Site (or, where Works are being
executed off the Site, at the location of the Works) for the whole time that the
Works are being executed. If any of the Key Personnel is to be temporarily
absent during execution of the Works, a suitable replacement shall be
temporarily appointed, subject to the Employer's prior consent.
All Key Personnel shall be fluent in the language for communications defined
in Sub-Clause 1.4 [Law and Language].
7.2
Sam pies The Contractor shall submit the following samples of Materials, and relevant
information, to the Employer for consent prior to using the Materials in or for
the Works:
Each sample shall be labelled as to origin and intended use in the Works.
7.3
inspection The Employer's Personnel shall, during all the normal working hours stated
in the Contract Data and at all other reasonable times:
(a) have full access to all parts of the Site and to all places from which
natural Materials are being obtained;
(b) during production, manufacture and construction (at the Site and, to
the extent specified in the Employer's Requirements, elsewhere), be
entitled to:
(i) examine, inspect, measure and test (to the extent stated in the
Employer's Requirements) the Materials, Plant and workmanship,
(ii) check the progress of manufacture of Plant and production and
manufacture of Materials, and
(iii) make records (including photographs and/or video recordings);
and
(c) carry out other duties and inspections, as specified in these Conditions
and the Employer's Requirements.
The Contractor shall give the Employer's Personnel full opportunity to carry
out these activities, including providing safe access, facilities, permissions
and safety equipment.
The Contractor shall give a Notice to the Employer, stating the time and
place for the specified testing of any Plant, Materials and other parts of the
Works. This Notice shall be given in reasonable time, having regard to the
location of the testing, for the Employer's Personnel to attend.
The Employer may, under Clause 13 [Variations and Adjustments], vary the
location or timing or details of specified tests, or instruct the Contractor
to carry out additional tests. If these varied or additional tests show that
the tested Plant, Materials or workmanship is not in accordance with the
Contract, the Cost and any delay incurred in carrying out this Variation shall
be borne by the Contractor.
The Employer shall give a Notice to the Contractor of not less than 72 hours
of the Employer's intention to attend the tests. If the Employer does not
attend at the time and place stated in the Contractor's Notice under this
Sub-Clause, the Contractor may proceed with the tests, unless otherwise
instructed by the Employer. These tests shall then be deemed to have been
made in the Employer's presence. If the Contractor suffers delay and/or
incurs Cost from complying with any such instruction or as a result of a
delay for which the Employer is responsible, the Contractor shall be entitled
subject to Sub-Clause 20.2 [Claims For Payment and/or E071 to EOT and/
or payment of Cost Plus Profit.
The Contractor shall promptly forward to the Employer duly certified reports
of the tests. When the specified tests have been passed, the Employer shall
endorse the Contractor's test certificate, or issue a test certificate to the
Contractor, to that effect. If the Employer has not attended the tests, the
Employer shall be deemed to have accepted the readings as accurate.
Sub-Clause 7.5 [Defects and Rejection] shall apply in the event that any
Plant, Materials and other parts of the Works fails to pass a specified test.
7.5
Defects and Rejection If, as a result of an examination, inspection, measurement or testing, any
Plant, Materials, design or workmanship is found to be defective or otherwise
not in accordance with the Contract, the Employer shall give a Notice to the
Contractor describing the item of Plant, Materials, design or workmanship
that has been found to be defective. The Contractor shall then promptly
prepare and submit a proposal for necessary remedial work.
If the Contractor fails to promptly submit a proposal (or revised proposal) for
remedial work, or fails to carry out the proposed remedial work to which the
Employer has given (or is deemed to have given) a Notice of No-objection,
the Employer may:
7,6
Remedial Work In addition to any previous examination, inspection, measurement or testing,
or test certificate or Notice of No-objection by the Employer, at any time
before the issue of the Taking-Over Certificate for the Works the Employer
may instruct the Contractor to:
(a) repair or remedy (if necessary, off the Site), or remove from the Site
and replace any Plant or Materials which are not in accordance with
the Contract;
(b) repair or remedy, or remove and re-execute, any other work which is
not in accordance with the Contract; and
(c) carry out any remedial work which is urgently required for the safety
of the Works, whether because of an accident, unforeseeable event
or otherwise.
The Contractor shall comply with the instruction as soon as practicable and
not later than the time (if any) specified in the instruction, or immediately if
urgency is specified under sub-paragraph (c) above.
The Contractor shall bear the cost of all remedial work required under this
Sub-Clause, except to the extent that any work under sub-paragraph (c)
above is attributable to:
(i) any act by the Employer or the Employer's Personnel. If the Contractor
suffers delay and/or incurs Cost in carrying out such work, the Contractor
shall be entitled subject to Sub-Clause 20.2 [Claims For Payment and/or
E07] to EQT and/or payment of such Cost Plus Profit; or
(ii) an Exceptional Event, in which case Sub-Clause 18.4 [Consequences
of an Exceptional Event] shall apply.
1.7
5
(J Ownership of Plant
and Materials Each item of Plant and Materials shall, to the extent consistent with the
mandatory requirements of the Laws of the Country, become the property of
the Employer at whichever is the earlier of the following times, free from liens
and other encumbrances:
~
CL
()
L.. .. (a) when it is delivered to the Site;
(b) when the Contractor is paid the value of the Plant and Materials under
Sub-Clause 8.11 [Payment for Plant and Materials after Employer's
Suspension]; or
(c) when the Contractor is paid the amount determined for the Plant and
Materials under Sub-Clause 14.5 [Plant and Materials intended for the
Works].
7.8
Royalties Unless otherwise stated in the Employer's Requirements, the Contractor
shall pay all royalties, rents and other payments for:
The Contractor shall commence the execution of the Works on, or as soon
as is reasonably practicable after, the Commencement Date and shall then
proceed with the Works with due expedition and without delay.
8.2
Time for Completion The Contractor shall complete the whole of the Works, and each Section (if any),
within the Time for Completion for the Works or Section (as the case may be),
including completion of all work which is stated in the Contract as being required
for the Works or Section to be considered to be completed for the purposes of
taking over under Sub-Clause 10.1 [Taking Over the Works and Sections].
Unless otherwise stated in the Particular Conditions, the Contractor shall also
submit a revised programme which accurately reflects the actual progress of
the Works, whenever any programme ceases to reflect actual progress or is
otherwise inconsistent with the Contractor's obligations.
(a) the Commencement Date and the Time for Completion, of the Works
and of each Section (if any);
(b) the date right of access to and possession of (each part o~ the Site
is to be given to the Contractor in accordance with Sub-Clause 2.1
[Right of Access to the Site];
(c) the order in which the Contractor intends to carry out the Works,
including the anticipated timing of each stage of design, preparation and
submission of Contractor's Documents, procurement, manufacture,
inspection, delivery to Site, construction, erection, installation, work to
be undertaken by any nominated Subcontractor (as defined in Clause
4.5 [Nominated Subcontractors]), testing, commissioning and trial
operation;
(d) the Review periods under Sub-Clause 5.2.2 [Review by Employer],
and periods for Review for any other submissions specified in the
Employer's Requirements or required under these Conditions;
(e) the sequence and timing of inspections and tests specified in, or
required by, the Contract;
(~ for a revised programme: the sequence and timing of the remedial
work (if any) to which the Employer has given a Notice of No-objection
under Sub-Clause 7.5 [Defects and Rejection] and/or the remedial
work (if any) instructed under Sub-Clause 7.6 [Remedial Work];
(g) all activities (to the level of detail specified in the Employer's
Requirements), logically linked and showing the earliest and latest start
and finish dates for each activity, the float (if any), and the critical path(s);
(h) the dates of all locally recognised days of rest and holiday periods (if
any);
(i) all key delivery dates of Plant and Materials;
0) for a revised programme and for each activity: the actual progress
to date, any delay to such progress and the effects of such delay on
other activities (if any); and
(k) a supporting report which includes:
(i) a description of all the major stages of the execution of the
Works;
(ii) a general description of the methods which the Contractor
intends to adopt in the execution of the Works;
(iii) details showing the Contractor's reasonable estimate of the
number of each class of Contractor's Personnel, and of each
type of Contractor's Equipment, required on the Site, for each
major stage of the execution of the Works;
The Employer shall Review the initial programme, and each revised
programme, submitted by the Contractor and may give a Notice to the
Contractor stating the extent to which it does not comply with the Contract
or ceases to reflect actual progress or is otherwise inconsistent with the
Contractor's obligations. If the Employer gives no such Notice:
If, at any time, the Ernployer gives a Notice to the Contractor that the
Programme fails (to the extent stated) to comply with the Contract or ceases
to reflect actual progress or is otherwise inconsistent with the Contractor's
obligations, the Contractor shall within 14 days after receiving this Notice
submit a revised programme to the Employer in accordance with this
Sub-Clause.
8.4
Advance Waming Each Party shall advise the other Party in advance of any known or probable
future events or circumstances which may:
8.5
Extension of Time
for Completion The Contractor shall be entitled subject to Sub-Clause 20.2 [Claims
For Payment and/or EOT] to Extension of Time if and to the extent that
completion for the purposes of Sub-Clause 10 .1 [Taking Over the Works and
Sections] is or will be delayed by any of the following causes:
©FIDIC2017
46 Conditions of Contract for EPC!furnkey Projects
(c) any delay, impediment or prevention caused by or attributable to
the Employer, the Employer's Personnel, or the Employer's other
contractors on the Site (or any Unforeseeable shortages in the
availability of Employer-Supplied Materials, if any, caused by epidemic
or governmental actions).
When determining each EOT under Sub-Clause 20.2 [Claims For Payment and/
or E07], the Employer's Representative shall review previous determinations
under Sub-Clause 3.5 [Agreement or Determination] and may increase, but
shall not decrease, the total EOT.
8.6
Delays Caused
by Authorities If:
(a) the Contractor has diligently followed the procedures laid down by the
relevant legally constituted public authorities or private utility entities in
the Country;
(b) these authorities or entities delay or disrupt the Contractor's work;
and
(c) the delay or disruption was Unforeseeable,
then this delay or disruption will be considered as a cause of delay under
sub-paragraph (b) of Sub-Clause 8.5 [Extension of Time for Completion].
8.7
Rate of Progress If, at any time:
(a) actual progress is too slow to complete the Works or a Section (if any)
within the relevant Time for Completion; and/or
(b) progress has fallen (or will fall) behind the Programme (or the initial
programme if it has not yet become the Programme) under Sub-Clause
8.3 [Programme],
other than as a result of a cause listed in Sub-Clause 8.5 [Extension of Time
for Completion], then the Employer may instruct the Contractor to submit,
under Sub-Clause 8.3 [Programme], a revised programme describing
the revised methods which the Contractor proposes to. adopt in order to
expedite progress and complete the Works or a Section (if any) within the
relevant Time for Completion.
Unless the Employer gives a Notice to the Contractor stating otherwise, the
Contractor shall adopt these revised methods, which may require increases
in the working hours and/or in the numbers of Contractor's Personnel and/or
the Goods, at the Contractor's risk and cost. If these revised methods cause
the Employer to incur additional costs, the Employer shall be entitled subject
to Sub-Clause 20.2 [Claims For Payment and/or E07] to payment of these
costs by the Contractor, in addition to Delay Damages (if any).
These Delay Damages shall be the only damages due from the Contractor tor
the Contractor's failure to comply with Sub-Clause 8.2 [Time for Completion],
other than in the event of termination under Sub-Clause 15.2 [Termination for
Contractor's Default] before completion of the Works. These Delay Damages
shall not relieve the Contractor from the obligation to complete the Works,
or from any other duties, obligations or responsibilities which the Contractor
may have under or in connection with the Contract.
This Sub-Clause shall not limit the Contractor's liability tor Delay Damages
in any case of fraud, gross negligence, deliberate default or reckless
misconduct by the Contractor.
Employer's Suspension The Employer may at any time instruct the Contractor to suspend progress
of part or all of the Works, which instruction shall state the date and cause
of the suspension.
During such suspension, the Contractor shall protect, store and secure such
part or all of the Works (as the case may be) against any deterioration, loss
or damage.
To the extent that the cause of such suspension is the responsibility of the
Contractor, Sub-Clauses 8.10 [Consequences of Employer's Suspension],
8.11 [Payment for Plant and Materials after Employer's Suspension] and
8.12 [Prolonged Suspension] shall not apply.
8.10
Consequences of
Employer's Suspension If the Contractor suffers delay and/or incurs Cost from complying with an
Employer's instruction under Sub-Clause 8.9 [Employer's Suspension] and/
or from resuming the work under Sub-Clause 8.13 [Resumption of Work],
the Contractor shall be entitled subject to Sub-Clause 20.2 [Claims For
Payment and/or EOT] to EOT and/or payment of such Cost Plus Profit.
8.11
Payment for Plant and Materials
after Employer's Suspension The Contractor shall be entitled to payment of the value (as at the date of
suspension instructed under Sub-Clause 8.9 [Employer's Suspension]) of
Plant and/or Materials which have not been delivered to Site, if:
© FIDIC 2017 Conditions of Contract for EPC!furnkey Projects
48
(a) the work on Plant, or delivery of Plant and/or Materials, has been
suspended for more than 28 days and
(i) the Plant and/or Materials were scheduled, in accordance with
the Programme, to have been completed and ready for delivery
to the Site during the suspension period; and
(ii) the Contractor provides the Employer with reasonable evidence
that the Plant and/or Materials comply with the Contract; and
{b) the Contractor has marked the Plant and/or Materials as the
Employer's property in accordance with the Employer's instructions.
8.12
Prolonged Suspension If the suspension under Sub-Clause 8.9 [Employer's Suspension] has
continued for more than 84 days, the Contractor may give a Notice to the
Employer requesting permission to proceed.
If the Employer does not give a Notice under Sub-Clause 8.13 [Resumption
of Work] within 28 days after receiving the Contractor's Notice under this
Sub-Clause, the Contractor may either:
(a) agree to a further suspension, in which case the Parties may agree
the EOT and/or Cost Plus Profit (if the Contractor incurs Cost), and/or
payment for suspended Plant and/or Materials, arising from the total
period of suspension;
or (and if the Parties fail to reach agreement under this sub-paragraph (a))
(b) after giving a (second} Notice to the Employer, treat the suspension
as an omission of the affected part of the Works (as if it had been
instructed under Sub-Clause 13.3.1 [Variation by Instruction])
with immediate effect including release from any further obligation
to protect, store and secure under Sub-Clause 8.9 [Employer's
Suspension]. If the suspension affects the whole of the Works, the
Contractor may give a Notice of termination under Sub-Clause 16.2
[Termination by Contractor].
8.13
Resumption of Work The Contractor shall resume work as soon as practicable after receiving a
Notice from the Employer to proceed with the suspended work.
At the time stated in this Notice (if not stated, immediately after the Contractor
receives this Notice), the Contractor and the Employer shall jointly examine
the Works and the Plant and Materials affected by the suspension. The
Employer shall record any deterioration, loss, damage or defect in the Works
or Plant or Materials which has occurred during the suspension and shall
provide this record to the Contractor. The Contractor shall promptly make
good all such deterioration, loss, damage or defect so that the Works, when
completed, shall comply with the Contract.
n Completion
9.1
Contractor's Obligations The Contractor shall carry out the Tests on Completion in accordance with
this Clause and Sub-Clause 7.4 [Testing by the Contractor], after submitting
the documents under Sub-Clause 5.6 [As-Built Records] and Sub-Clause
5.7 [Operation and Maintenance Manuals].
The Employer may Review the proposed test programme and may give a
Notice to the Contractor stating the extent to which it does not comply with
the Contract. Within 14 days after receiving this Notice, the Contractor shall
revise the test programme to rectify such non-compliance. If the Employer
gives no such Notice within 14 days after receiving the test programme (or
revised test programme), the Employer shall be deemed to have given a
Notice of No-objection. The Contractor shall not commence the Tests on
Completion until a Notice of No-objection is given (or is deemed to have
been given) by the Employer.
(a) pre-commissioning tests (on or off the Site, as appropriate), which shall
include the appropriate inspections and ("dry" or "cold") functional
tests to demonstrate that each item of the Works or Section can
safely undertake the next stage under sub-paragraph (b) below;
(b) commissioning tests, which shall include the operational tests
specified in the Employer's Requirements to demonstrate that the
Works or Section can be operated safely and as specified in the
Employer's Requirements, under all available operating conditions;
and
(c) trial operation (to the extent possible under available operating
conditions), which shall demonstrate that the Works or Section
perform reliably and in accordance with the Contract.
The tests of each stage described in sub-paragraphs (b) and (c) above shall not
be commenced until the Works or Section have passed the previous stage.
During trial operation, when the Works or Section (as the case may be) are operating
under stable conditions, the Contractor shall give a Notice to the Employer that
they are ready for any other Tests on Completion, including performance tests.
Performance tests shall be carried out to demonstrate whether the Works
or Section comply with the performance criteria specified in the Employer's
Requirements and with the Schedule of Performance Guarantees.
Any product produced by, and any revenue or other benefit resulting from,
trial operation under this Sub-Clause shall be the property of the Employer.
9.2 --------------·---·
Delayed Tests If the Contractor has given a Notice under Sub-Clause 9.1 [Contractor's
Obligations] that the Works or Section (as the case may be) are ready for
Tests on Completion, and these tests are unduly delayed by the Employer's
Personnel or by a cause for which the Employer is responsible, Sub-Clause
10.3 [Interference with Tests on Completion] shall apply.
If the Contractor fails to carry out the Tests on Completion within this period
of 21 days:
(a) after a second Notice is given by the Employer to the Contractor, the
Employer's Personnel may proceed with the tests;
(b) the Contractor may attend and witness these tests;
(c) within 28 days of these tests being completed, the Employer shall
send a copy of the test results to the Contractor; and
(d) if the Employer incurs additional costs as a result of such testing,
the Employer shall be entitled subject to Sub-Clause 20.2 [Claims
For Payment and/or Eon to payment by the Contractor of the costs
reasonably incurred.
9.3
Retesting If the Works, or a Section, fail to pass the Tests on Completion, Sub-Clause
7 .5 [Defects and Rejection] shall apply. The Employer or the Contractor may
require these failed tests, and the Tests on Completion on any related work,
to be repeated under the same terms and conditions. Such repeated tests
shall be treated as Tests on Completion for the purposes of this Clause.
9.4
Failure to Pass Tests
on Completion If the Works, or a Section, fail to pass the Tests on Completion repeated
under Sub-Clause 9.3 [Retesting], the Employer shall be entitled to:
In the event of sub-paragraph (d) above, the Contractor shall then proceed in
accordance with all other obligations under the Contract, and the Employer
shall be entitled subject to Sub-Clause 20.2 [Claims For Payment and/or
E071 to payment by the Contractor or a reduction in the Contract Price as
described under sub-paragraphs (b)(i) or (b)(ii) of Sub-Clause 11 .4 [Failure to
Remedy Defects], respectively. This entitlement shall be without prejudice to
any other rights the Employer may have, under the Contract or otherwise.
0 Taking Over
10.1
Taldng Over the
Works and Sections Except as stated in Sub-Clause 9.4 [Failure to Pass Tests on Completion]
and Sub-Clause 10.2 [Taking Over of Parts of the Works], the Works shall be
taken over by the Employer when:
(a) the Works have been completed in accordance with the Contract,
including the passing of the Tests on Completion and except as
allowed in sub-paragraph (i) below;
(b) if applicable, the Employer has given (or is deemed to have given)
a Notice of No-objection to the as-built records submitted under
sub-paragraph (a) of Sub-Clause 5.6 [As-Built Records];
(c) if applicable, the Employer has given (or is deemed to have given) a
Notice of No-objection to the provisional O&M Manuals for the Works
submitted under Sub-Clause 5.7 [Operation and Maintenance Manuals];
(d) if applicable, the Contractor has carried out the training as described
under Sub-Clause 5.5 [Tr'aining]; and
(e) a Taking-Over Certificate for the Works has been issued, or is deemed
to have been issued in accordance with this Sub-Clause.
The Contractor may apply for a Taking-Over Certificate by giving a Notice to
the Employer not more than 14 days before the Works will, in the Contractor's
opinion, be complete and ready for taking over. If the Works are divided into
Sections, the Contractor may similarly apply for a Taking-Over Certificate for
each Section.
If any part of the Works is taken over under Sub-Clause 10.2 [Taking Over of
Parts of the Works], the remaining Works or Section shall not be taken over until
the conditions described in sub-paragraphs (a) to (e) above have been fulfilled.
The Employer shall, within 28 days after receiving the Contractor's Notice, either:
(i) issue the Taking-Over Certificate to the Contractor, stating the date on
which the Works or Section were completed in accordance with the
Contract, except for any minor outstanding work and defects (as listed
in the Taking-Over Certificate) which will not substantially affect the safe
use of the Works or Section for their intended purpose (either until or
If the Employer does not issue the Taking-Over Certificate or reject the
Contractor's application within this period of 28 days, and if the conditions
described in sub-paragraphs (a) to (d) above have been fulfilled, the Works
or Section shall be deemed to have been completed in accordance with the
Contract on the fourteenth day after the Employer receives the Contractor's
Notice of application and the Taking-Over Certificate shall be deemed to
have been issued.
10.2
Taking Over of
Parts of the Works Parts of the Works (other than Sections) shall not be taken over or used by
the Employer, except as may be stated in the Employer's Requirements or
as may be agreed by both Parties.
10.3
Interference with
Tests on Completion If the Contractor is prevented, for more than 14 days (either a continuous
period, or multiple periods which total more than 14 days), from carrying
out the Tests on Completion by the Employer's Personnel or by a cause for
which the Employer is responsible (including any performance test that is not
possible due to available operating conditions during trial operation):
(a) the Contractor shall carry out the Tests on Completion as soon as
practicable and, in any case, before the expiry date of the relevant
DNP; and
(b) if the Contractor suffers delay and/or incurs Cost as a result of being
so prevented, the Contractor shall be entitled subject to Sub-Clause
20.2 [Claims For Payment and/or E01l to EOT and/or payment of
such Cost Plus Profit.
(i) the Contractor and the Employer's Personnel shall jointly inspect the
defect or damage;
(ii) the Contractor shall then prepare and submit a proposal for necessary
remedial work; and
(iii) the second, third and fourth paragraphs of Sub-Clause 7.5 [Defects
and Rejection] shall apply.
11.2
Cost of Remedying
Defects All work under sub-paragraph (b) of Sub-Clause 11.1 [Completion of
Outstanding Work and Remedying Defects] shall be executed at the risk and
cost of the Contractor, if and to the extent that the work is attributable to:
(a) the design of the Works, other than a part of the design for which the
Employer is responsible (if any);
(b) Plant, Materials or workmanship not being in accordance with the
Contract;
(c) improper operation or maintenance which was attributable to matters
for which the Contractor is responsible (under Sub-Clause 5.5
[Training], Sub-Clause 5.6 [As-Built Records] and/or Sub-Clause 5.7
[Operation and Maintenance Manuals] or otherwise); or
(d) failure by the Contractor to comply with any other obligation under the
Contract.
If the Contractor considers that the work is attributable to any other cause,
the Contractor shall promptly give a Notice to the Employer and the
Employer's Representative shall proceed under Sub-Clause 3.5 [Agreement
or Determination] to agree or determine the cause (and, for the purpose of
Sub-Clause 3.5.3 [Time limits], the date of this Notice shall be the date of
commencement of the time limit for agreement under Sub-Clause 3.5.3). If
it is agreed or determined that the work is attributable to a cause other than
those listed above, Sub-Clause 13.3.1 [Variation by Instruction] shall apply
as if such work had been instructed by the Employer.
11.3 - - - - - - - -..-·-----------··-----------------··
Extension of Defects
Notification Period The Employer shall be entitled to an extension of the DNP for the Works or a
Section (or a part of the Works, if Sub-Clause 10.2 [Taking Over of Parts of
the Works] applies):
(a) if and to the extent that the Works, Section (or the part of the Works) or
a major item of Plant (as the case may be, and after taking over) cannot
be used for the intended purpose(s) by reason of a defect or damage
which is attributable to any of the matters under sub-paragraphs (a)
to (d) of Sub-Clause 11.2 [Cost of Remedying Defects]; and
(b) subject to Sub-Clause 20.2 [Claims For Payment and/or EOT].
However, a DNP shall not be extended by more than a period of two years
after the expiry of the DNP stated in the Contract Data.
The Contractor shall also provide any further details that the Employer may
reasonably require.
When the Employer gives consent (which consent shall not relieve the
Contractor from any obligation or responsibility under this Clause), the
Contractor may remove from the Site such items of Plant as are defective
or damaged. As a condition of this consent, the Employer may require the
Contractor to increase the amount of the Performance Security by the full
replacement cost of the defective or damaged Plant.
11.6
Further Tests
Remedying Defects Within 7 days of completion of the work of remedying of any defect or
-~damage, the Contractor shall give a Notice to the Employer describing the
remedied Works, Section and/or Plant and the proposed repeated tests
(under Clause 9 [Tests on Completion] or Clause 12 [Tests after Completion],
as applicable). If the Employer does not respond within 14 days after
receiving this Notice, by giving a Notice to the Contractor objecting to such
proposed repeated testing and/or instructing the repeated tests that are
necessary to demonstrate that the remedied Works, Section and/or Plant
comply with the Contract, the Employer shall be deemed to have agreed
with the Contractor's proposed repeated testing.
If the Contractor fails to give such a Notice within the 7 days, the Employer
may give a Notice to the Contractor, within 14 days after the defect or damage
is remedied, instructing the repeated tests that are necessary to demonstrate
that the remedied Works, Section and/or Plant comply with the Contract.
All repeated tests under this Sub-Clause shall be carried out in accordance
with the terms applicable to the previous tests, except that they shall be
carried out at the risk and cost of the Party liable, under Sub-Clause 11.2
[Cost of Remedying Defects], for the cost of the remedial work.
11.7
Right of Access
after Taking Over Until the date 28 days after issue of the Performance Certificate, the
Contractor shall have the right of access to all parts of the Works and to
records of the operation, maintenance and performance of the Works,
except as may be inconsistent with the Employer's reasonable security
restrictions. .
(a) the Contractor shall request access by giving a Notice to the Employer,
describing the parts of the Works and/or records to be accessed,
the reasons for such access, and the Contractor's preferred date
for access. This Notice shall be given in reasonable time in advance
of the preferred date for access, taking due regard of all relevant
circumstances including the Employer's security restrictions; and
(b) within 7 days after receiving the Contractor's Notice, the Employer
shall give a Notice to the Contractor either:
(i) stating the Employer's consent to the Contractor's request; or
(ii) proposing reasonable alternative date(s), with reasons. If the
Employer fails to give this Notice within the 7 days, the Employer
shall be deemed to have given consent to the Contractor's ;JJ
;~
access on the preferred date stated in the Contractor's Notice. U,
f2
If the Contractor incurs additional Cost as a result of any unreasonable delay
by the Employer in permitting access to the Works or such records by the
Contractor, the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or E071 to payment of any such Cost Plus Profit.
n.s
Cont1·actor to Search The Contractor shall, if instructed by the Employer, search for the cause of
any defect, under the direction of the Employer. The Contractor shall carry
out the search on the date(s) stated in the Employer's instruction or other
date(s) agreed with the Employer.
If the Contractor fails to carry out the search in accordance with this
Sub-Clause, the search may be carried out by the Employer's Personnel.
The Contractor shall be given a Notice of the date when such a search will
be carried out and the Contractor may attend at the Contractor's own cost. If
the defect is to be remedied at the cost of the Contractor under Sub-Clause
11.2 [Cost of Remedying Defects], the Employer shall be entitled subject
to Sub-Clause 20.2 [Claims For Payment and/or EO?l to payment by the
Contractor of the costs of the search reasonably incurred by the Employer.
11.9
Performance Certificate Performance of the Contractor's obligations under the Contract shall not
be considered to have been completed until the Employer has issued the
Performance Certificate to the Contractor, stating the date on which the
Contractor fulfilled the Contractor's obligations under the Contract.
The Employer shall issue the Performance Certificate to the Contractor (with
a copy to the DAAB) within 28 days after the latest of the expiry dates of the
Defects Notification Periods, or as soon thereafter as the Contractor has:
11.10
Unfulfilled Obligations After the issue of the Performance Certificate, each Party shall remain liable
for the fulfilment of any obligation which remains unperformed at that time.
For the purposes of determining the nature and extent of unperformed
obligations, the Contract shall be deemed to remain in force.
However in relation to Plant, the Contractor shall not be liable for any defects
or damage occurring more than two years after expiry of the DNP for the
Plant except if prohibited by law or in any case of fraud, gross negligence,
deliberate default or reckless misconduct.
11.11
Clearance of Site Promptly after the issue of the Performance Certificate, the Contractor shall:
If the Contractor fails to comply with sub-paragraphs (a), (b) and/or (c) above
within 28 days after the issue of the Performance Certificate, the Employer
may sell (to the extent permitted by applicable Laws) or otherwise dispose
of any remaining items and/or may reinstate and clean the Site (as may be
necessary) at the Contractor's cost.
Completion
12.1
Procedure for Tests
after Completion If Tests after Completion are specified in the Employer's Requirements, this
Clause shall apply.
The Employer shall provide all electricity, water, sewage (if applicable), fuel,
consumables, materials, and make the Employer's Personnel and Plant
available for the Tests after Completion. The Contractor shall:
The results of the Tests after Completion shall be compiled and evaluated
by both Parties. Appropriate account shall be taken of the effect of the
Employer's prior use of the Works.
12.2
Delayed Tests If the Contractor has given a Notice under sub-paragraph (c) of Sub-Clause
12.1 [Procedure for Tests after Completion] that the Works or Section (as
the case may be) are ready for Tests after Completion, and the Contractor
is prevented from carrying out the Tests after Completion, or these tests are
unduly delayed, by the Employer's Personnel or by a cause for which the
Employer is responsible:
(a) the Contractor shall carry out the Tests after Completion as soon as
practicable and, in any case, before the expiry date of the relevant
DNP; and
(b) if the Contractor incurs Cost as a result of any such prevention and/
or delay, the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or EQT] to payment of such Cost Plus
Profit.
12.3
Retesting Subject to Sub-Clause 12.4 [Failure to Pass Tests after Completion], if the
Works, or a Section, fail to pass the Tests after Completion:
If and to the extent that this failure and retesting are attributable to any of
the matters listed in sub-paragraphs (a) to (d) of Sub-Clause 11.2 [Cost of
Remedying Defects] and cause the Employer to incur additional costs, the
Employer shall be entitled subject to Sub-Clause 20.2 [Claims For Payment
and/or E01] to payment of these costs by the Contractor.
12.4
Failure to Pass
Tests after If:
(a) the Works, or a Section, fail to pass any or all of the Tests after
Completion; and
(b) applicable Performance Damages are set out in the Schedule of
Performance Guarantees .
the Employer shall be entitled subject to Sub-Clause 20.2 [Claims For
Payment and/or E01] to payment of these Performance Damages by the
Contractor in full satisfaction of this failure. If the Contractor pays these
Performance Damages to the Employer during the DNP, then the Works or
Section shall be deemed to have passed these Tests after Completion.
If the Works, or a Section, fail to pass a Test after Completion and, by giving
a Notice to the Employer, the Contractor proposes to make adjustments or
modifications to the Works or such Section {including an item of Plant):
(a) the varied work was Unforeseeable having regard to the scope and
nature of the Works described in the Employer's Requirements;
(b) the Contractor cannot readily obtain the Goods required for the
Variation;
(c) it will adversely affect the Contractor's ability to comply with
Sub-Clause 4.8 [Health and Safety Obligations] and/or Sub-Clause
4 .18 [Protection of the Environment];
(d) it will have an adverse impact on the achievement of the Schedule of
Performance Guarantees; or
(e) it may adversely 'affect the Contractor's obligation to complete the
Works so that they shall be fit for the purpose(s) for which they are
intended under Sub-Clause 4.1 [Contractor's General Obligations].
Promptly after receiving this Notice, the Employer shall respond by giving
a Notice to the Contractor cancelling, confirming or varying the instruction.
Any instruction so confirmed or varied shall be taken as an instruction under
Sub-Clause 13.3.1 [Variation by instruction].
13.2
Value Engineering The Contractor may, at any time, submit to the Employer a written proposal
which (in the Contractor's opinion) will, if adopted:
The proposal shall be prepared at the cost of the Contractor and shall
include the details as stated in sub-paragraphs (a) to (c) of Sub-Clause
13.3.1 [Variation by Instruction].
(i) the Contractor shall submit any further particulars that the Employer
may reasonably require; and
(ii) then the third paragraph of Sub-Clause 13.3.1 [Variation by Instruction]
shall apply which shall include consideration by the Employer of the
sharing (if any) of the benefit, costs and/or delay between the Parties
stated in the Particular Conditions.
Variation Procedure Subject to Sub-Clause 13.1 [Right to Vary], Variations shall be initiated by the
Employer in accordance with either of the following procedures:
The Contractor shall proceed with execution of the Variation and shall within
28 days (or other period proposed by the Contractor and agreed by the
Employer) of receiving the Employer's instruction, submit to the Employer's
Representative detailed particulars including:
Thereafter, the Contractor shall submit any further particulars that the
Employer's Representative may reasonably require.
For each item of work forming part (or all) of a Variation, the appropriate rate or
price for the item shall be the rate or price specified for such item in the Schedule
of Rates and Prices or, if there is no such item, the rate or price specified for similar
work. However, a new rate or price shall be appropriate for an item of work tf no u ..
rate or price for this item is specified in the Schedule of Rates and Prices and no
specified rate or price is appropriate because the item of work is not of similar
character, or is not executed under similar conditions, as any item in the Contract.
Each new rate or price shall be derived from any relevant rates or prices
in the Schedule of Rates and Prices, with reasonable adjustments taking
account of all relevant circumstances. If no rates or prices are relevant for the
derivation of a new rate or price, it shall be derived from the Cost Plus Profit
of executing the work.
Until such time as the adjustments under sub-paragraph (ii) above are agreed
or determined, the Employer shall assess a provisional rate or price for the
purposes of interim payment under Sub-Clause 14.6 [Interim Payment].
If the Employer does not give consent to the proposal, with or without
comments, and if the Contractor has incurred Cost as a result of
submitting it, the Contractor shall be entitled subject to Sub-Clause
20.2 [Claims For Payment and/or E01] to payment of such Cost.
General Conditions © FIDIC 2017
63
13.4
Pn::n.risional Sums Each Provisional Sum shall only be used, in whole or in part, in accordance
with the Employer's instructions, and the Contract Price shall be adjusted
accordingly. The total sum paid to the Contractor shall include only such
amounts for the work, supplies or services to which the Provisional Sum
relates, as the Employer shall have instructed.
Ii
For each Provisional Sum, the Employer may instruct:
()
z<J'
(a) work to be executed (including Plant, Materials or services to be
d
0 supplied) by the Contractor, and for which adjustments to the
Contract Price and the Schedule of Payments (if any) shall be agreed
or determined under Sub-Clause 13.3.1 [Variation by Instruction];
and/or
(b) Plant, Materials, works or services to be purchased by the Contractor
from a nominated Subcontractor (as defined in Sub-Clause 4.5
[Nominated Subcontractors]) or otherwise, and for which there shall
be included in the Contract Price:
(i) the actual amounts paid (or due to be paid) by the Contractor;
and
(ii) a sum for overhead charges and profit, calculated as a percentage
of these actual amounts by applying the relevant percentage rate
(if any) stated in the applicable Schedule. If there is no such rate,
the percentage rate stated in the Contract Data shall be applied.
Each Statement that includes a Provisional Sum shall also include all
applicable invoices, vouchers and accounts or receipts in substantiation of
the Provisional Sum.
13.5 --------·---·----·--~-·---·------····-------
Daywork If a Daywork Schedule is not included in the Contract, this Sub-Clause shall
not apply.
For work of a minor or incidental nature, the Employer may instruct that a Variation
shall be executed on a daywork basis. The work shall then be valued in accordance
with the Daywork Schedule, and the following procedure shall apply.
Before ordering Goods for such work (other than any Goods priced in the
Daywork Schedule), the Contractor shall submit one or more quotations from
the Contractor's suppliers and/or subcontractors to the Employer. Thereafter,
the Employer may instruct the Contractor to accept one of these quotations
(but such instruction shall not be taken as an instruction under Sub-Clause
4.5 [Nominated Subcontractors]). If the Employer does not so instruct the
Contractor within 7 days of receiving the quotations, the Contractor shall be
entitled to accept any of these quotations at the Contractor's discretion.
Unless otherwise stated in the Daywork Schedule, the rates and prices in the
Daywork Schedule shall be deemed to include taxes, overheads and profit.
13.6
Adjustments for
r.h:tinr1"'<::: in Laws Subject to the following provisions of this Sub-Clause, the Contract Price
shall be adjusted to take account of any increase or decrease in Cost
resulting from a change in:
(a) the Laws of the Country (including the introduction of new Laws and
the repeal or modification of existing Laws);
(b) the judicial or official governmental interpretation or implementation of
the Laws referred to in sub-paragraph (a) above;
(c) any permit, permission, license or approval obtained by the Employer
or the Contractor under sub-paragraph (a) or (b), respectively, of
Sub-Clause 1.12 [Compliance with Laws]; or
(d) the requirements for any permit, permission, licence and/or approval
to be obtained by the Contractor under sub-paragraph (b) of
Sub-Clause 1.12 [Compliance with Laws],
made and/or officially published after the Base Date, which affect the
Contractor in the performance of obligations under the Contract. In
this Sub-Clause "change in Laws" means any of the changes under
sub-paragraphs (a), (b), (c) and/or (d) above.
13.7
Adjustments for
Changes in Cost If there are no schedule(s) of cost indexation in the Particular Conditions, this
Sub-Clause shall not apply.
The amounts payable to the Contractor shall be adjusted for rises or falls in
the cost of labour, Goods and other inputs to the Works, by the addition or
deduction of the amounts calculated in accordance with the schedule(s) of
cost indexation in the Particular Conditions.
To the extent that full compensation for any rise or fall in Costs is not covered
by this Sub-Clause or other Clauses of these Conditions, the Contract Price
stated in the Contract Agreement shall be deemed to have included amounts
to cover the contingency of other rises and falls in costs.
Until such time as each current cost index is available, the Employer
shall use a provisional index for the purpose of interim payments under
Sub-Clause 14.6 Unterim Payment]. When a current cost index is available,
the adjustment shall be recalculated accordingly.
If the Contractor fails to complete the Works within the Time for Completion,
adjustment of prices thereafter shall be made using either:
(a) each index or price applicable on the date 49 days before the expiry
of the Time for Completion of the Works; or
(b) the current index or price
whichever is more favourable to the Employer.
(a) payment for the Works shall be made on the basis of the lump
sum Contract Price stated in the Contract Agreement, subject to
adjustments, additions (including Cost or Cost Plus Profit to which
the Contractor is entitled under these Conditions) and/or deductions
in accordance with the Contract;
(b) the Contractor shall pay all taxes, duties and fees required to be paid
by the Contractor under the Contract, and the Contract Price shall not
be adjusted for any of these costs, except as stated in Sub-Clause
13.6 [Adjustments for Changes in Laws]; and
(c) if any quantities are set out in a Schedule, they shall not be taken as
the actual and correct quantities of the Works which the Contractor
is required to execute, and they shall be used only for the purpose(s)
stated in the Schedule and for no other purpose(s).
The Contractor shall obtain (at the Contractor's cost) an Advance Payment
Guarantee in amounts and currencies equal to the advance payment, and
shall submit it to the Employer. This guarantee shall be issued by an entity
and from within a country (or other jurisdiction) to which the Employer gives
consent, and shall be based on the sample form included in the tender
documents or on another form agreed by the Employer (but such consent
and/or agreement shall not relieve the Contractor from any obligation under
this Sub-Clause).
The Contractor shall ensure that the Advance Payment Guarantee is valid
and enforceable until the advance payment has been repaid, but its amount
may be progressively reduced by the amount repaid by the Contractor.
If the terms of the Advance Payment Guarantee specify its expiry date, and
the advance payment has not been repaid by the date 28 days before the
expiry date:
(a) the Contractor shall extend the validity of this guarantee until the
advance payment has been repaid;
(b) the Contractor shall immediately submit evidence of this extension to
the Employer; and
(c) if the Employer does not receive this evidence 7 days before the
expiry date of this guarantee, the Employer shall be entitled to claim
under the guarantee the amount of advance payment which has not
been repaid.
The Employer shall make the advance payment within 14 days after:
(a) the Employer has received both the Performance Security and the
Advance Payment Guarantee, in the form and issued by an entity
in accordance with Sub-Clause 4.2.1 [Contractor's Obligations] and
Sub-Clause 14.2.1 [Advance Payment Guarantee] respectively; and
(b) the Employer has received the Contractor's application for the advance
payment under Sub-Clause 14.2.1 [Advance Payment Guarantee].
14.2.3 Repayment of Advance Payment
(a) deductions shall commence with the interim payment in which the
total of all interim payments in the same currency as the advance
If the advance payment has not been repaid before the issue of the
Taking-Over Certificate for the Works, or before termination under Clause
15 [Termination by Employer], Clause 16 [Suspension and Termination by
Contractor] or Clause 18 [Exceptional Events] (as the case may be), the
whole of the balance then outstanding shall immediately become due and
payable by the Contractor to the Employer.
14.3
Application for
Interim Payment The Contractor shall submit a Statement to the Employer after the end of the
period of payment stated in the Contract Data (if not stated, after the end of
each month). Each Statement shall:
The Statement shall include the following items, as applicable, which shall be
expressed in the various currencies in which the Contract Price is payable, in
the sequence listed:
(i) the estimated contract value of the Works executed, and the
Contractor's Documents produced, up to the end of the period of
payment (including Variations but excluding items described in
sub-paragraphs (ii) to (x) below);
(ii) any amounts to be added and/or deducted for changes in Laws under
Sub-Clause 13.6 [Adjustments tor Changes in Laws], and for changes
in Cost under Sub-Clause 13.7 [Adjustments for Changes in Cost];
(iii) any amount to be deducted for retention, calculated by applying the
percentage of retention stated in the Contract Data to the total of the
amounts under sub-paragraphs (i), (ii) and (vi) of this Sub-Clause, until
the amount so retained by the Employer reaches the limit of Retention
Money (if any) stated in the Contract Data;
(iv) any amounts to be added and/or deducted for the advance payment
and repayments under Sub-Clause 14.2 [Advance Payment];
(v) any amounts to be added and/or deducted for Plant and Materials
under Sub-Clause 14.5 [Plant and Materials intended tor the Works];
(vi) any other additions and/or deductions which have become due under
the Contract or otherwise, including those under Sub-Clause 3.5
[Agreement or Determination];
(vii) any amounts to be added for Provisional Sums under Sub-Clause
13.4 [Provisional Sums];
14.4
Schedule of If the Contract includes a Schedule of Payments specifying the instalments
in which the Contract Price will be paid then, unless otherwise stated in this
Schedule:
(a) the Employer has received the Performance Security in the form, and
issued by an entity, in accordance with Sub-Clause 4.2.1 [Contractor's
obligations]; and
(b) the Contractor has appointed the Contractor's Representative in
accordance with Sub-Clause 4.3 [Contractor's Representative].
The Employer shall, within 28 days after receiving a Statement and supporting
documents, give a Notice to the Contractor:
(a) stating the amount which the Employer fairly considers to be due for
the interim payment; and
(b) including any additions and/or deductions which have become due
under Sub-Clause 3.5 [Agreement or Determination] or under the
Contract or otherwise,
with detailed supporting particulars (which shall identify any difference
between a notified amount and the corresponding amount in the Statement
and give the reasons for such difference).
The Employer may withhold an interim payment which would (after retention
and other deductions) be less than the minimum amount of interim payment
(if any) stated in the Contract Data. In this event, the Employer shall promptly
give a Notice to the Contractor accordingly.
An interim payment shall not be withheld for any other reason, although:
For each amount so withheld, in the supporting particulars for the interim
payment the Employer shall detail his/her calculation of the amount and
state the reasons for it being withheld.
(a) the Contractor is not satisfied that this next interim payment includes
the identified amounts; and
(b) the identified amounts do not concern a matter for which the
Employer's Representative is already carrying out his/her duties under
Sub-Clause 3.5 [Agreement or Determination]
the Contractor may, by giving a Notice, refer this matter to the Employer's
Representative and Sub-Clause 3.5 [Agreement or Determination] shall
apply (and, for the purpose of Sub-Clause 3.5.3 [Time limits], the date
the Employer's Representative receives this Notice shall be the date of
commencement of the time limit for agreement under Sub-Clause 3.5.3).
14.7
Payment The Employer shall pay to the Contractor:
(a) the advance payment within the period stated in Sub-Clause 14.2.2
[Advance Payment];
(b) the interim payment due under:
(i) Sub-Clause 14.6 [Interim Payment], within the period stated in
the Contract Data (if not stated, 56 days) after the Employer
receives the Statement and supporting documents; or
(ii) Sub-Clause 14.13 [Final Payment], within the period stated in the
Contract Data (if not stated, 42 days) after the Employer receives
the Partially Agreed Final Statement (or, if sub-paragraph (ii) of
Sub-Clause 14.13 applies, within 84 days after the Employer
receives the draft final Statement that is deemed to be a Partially
Agreed Final Statement); and
(c) the Final Payment under Sub-Clause 14.13 [Final Payment] within the
period stated in the Contract Data (if not stated, 56 days) after the
Employer:
(i) receives the Final Statement (or if the second paragraph of
Sub-Clause 14.13 applies, after the expiry of 14 days after the
Employer issues the Notice stating the Final Payment); and
(ii) receives (or the Contractor is deemed to have issued) the
discharge under Sub-Clause 14.12 [Discharge].
Payment of the amount due in each currency shall be made into the bank
account, nominated by the Contractor, in the payment country (for this
currency) specified in the Contract.
14.8
Delayed Payment If the Contractor does not receive payment in accordance with Sub-Clause
14. 7 [Payment], the Contractor shall be entitled to receive financing charges
compounded monthly on the amount unpaid during the period of delay.
Unless otherwise stated in the Contract Data, these financing charges shall
be calculated at the annual rate of three percent (3%) above:
(i) the need for the Contractor to submit a Statement or any formal u
Notice (including any requirement to comply with Sub-Clause
20.2 [Claims For Payment and/or EOT]); and
(ii) prejudice to any other right or remedy.
14.9
Release of
Retention After the issue of the Taking-Over Certificate for:
(a) the Works, the Contractor shall include the first half of the Retention
Money in a Statement; or
(b) for a Section, the Contractor shall include the relevant percentage of
the first half of the Retention Money in a Statement.
After the latest of the expiry dates of the Defects Notification Periods,
the Contractor shall include the second half of the Retention Money in a
Statement promptly after such latest date. If a Taking-Over Certificate was
(or was deemed to have been) issued for a Section, the Contractor shall
include the relevant percentage of the second half of the Retention Money in
a Statement promptly after the expiry date of the DNP for the Section.
In the next interim payment after the Employer receives any such Statement,
the Employer shall release the corresponding amount of Retention Money.
However, when considering the amount to be due for release of Retention
Money under Sub-Clause 14.6 Unterim Payment], if any work remains to be
executed under Clause 11 [Defects after Taking Over] or Clause 12 [Tests
after Completion], the Employer shall be entitled to withhold the estimated
cost of this work until it has been executed.
The relevant percentage for each Section shall be the percentage value of
the Section as stated in the Contract Data. If the percentage value of a
Section is not stated in the Contract Data, no percentage of either half of the
Retention Money shall be released under this Sub-Clause in respect of such
Section.
14.10
Statement at Completion Within 84 days after the Date of Completion of the Works, the Contractor
shall submit to the Employer a Statement at completion with supporting
documents, in accordance with Sub-Clause 14.3 [Application for Interim
Payment], showing:
(a) the value of all work done in accordance with the Contract up to the
Date of Completion of the Works
(b) any further sums which the Contractor considers to be due at the
Date of Completion of the Works; and
(c) an estimate of any other amounts which the Contractor considers
have or will become due after the Date of Completion of the Works
14.11
Final Statement Submission by the Contractor of any Statement under the following
provisions of this Sub-Clause shall not be delayed by reason of any referral
under Sub-Clause 21.4 [Obtaining DMB's Decision] or any arbitration under
Sub-Clause 21.6 [Arbitration].
Within 56 days after the issue of the Performance Certificate, the Contractor
shall submit to the Employer, a draft final Statement.
Except for any amount under sub-paragraph (iii) above, if the Employer
disagrees with or cannot verify any part of the draft final Statement, the
Employer shall promptly give a Notice to the Contractor. The Contractor
shall then submit such further information as the Employer may reasonably
require within the time stated in this Notice, and shall make such changes in
the draft as may be agreed between them.
14.12
Discharge When submitting the Final Statement or the Partially Agreed Final Statement
(as the case may be), the Contractor shall submit a discharge which confirms
that the total of such Statement represents full and final settlement of all
moneys due to the Contractor under or in connection with the Contract.
This discharge may state that the total of the Statement is subject to any
payment that may become due in respect of any Dispute for which a DAAB
proceeding or arbitration is in progress under Sub-Clause 21.6 [Arbitration]
and/or that it becomes effective after the Contractor has received:
(a) full payment of the total amount stated in the Final Statement; and
(b) the Performance Security.
If the Contractor fails to submit this discharge, the discharge shall be deemed
to have been submitted and to have become effective when the conditions of
sub-paragraphs (a) and (b) have been fulfilled. If no Final Statement has been
submitted by the Contractor and the second paragraph of Sub-Clause 14.13
[Anal Payment] applies, the discharge shall be deemed to have been issued
by the Contractor after the Contractor has received the Final Payment under
the second paragraph of Sub-Clause 14.13 and the Performance Security.
A discharge under this Sub-Clause shall not affect either Party's liability
or entitlement in respect of any Dispute for which a DAAB proceeding or
arbitration is in progress under Clause 21 [Disputes and Arbitration].
14.13
Final Payment Within 28 days after receiving the Final Statement or the Partially Agreed
Final Statement (as the case may be), and the discharge under Sub-Clause
14.12 [Discharge], the Employer shall give a Notice to the Contractor stating:
(a) the amount which the Employer fairly considers is finally due, including
any additions and/or deductions which have become due under
Sub-Clause 3.5 [Agreement or Determination] or under the Contract
or otherwise; and
(b) after giving credit to the Employer for all amounts previously paid by
the Employer and for all sums to which the Employer is entitled, and
after giving credit to the Contractor for all amounts (if any) previously
paid by the Contractor and/or received by the Employer under the
Performance Security, the balance (if any) due from the Employer to
the Contractor or from the Contractor to the Employer, as the case
may be (the "Final Payment" in these conditions),
with detailed supporting particulars.
If the Contractor has not submitted a draft final Statement within the time
specified under Sub-Clause 14.11.1 [Draft Final Statement], the Employer
If:
14.14
Cessation of
The Employer shall not be liable to the Contractor for any matter or thing under
or in connection with the Contract or execution of the Works, except to the
extent that the Contractor shall have included an amount expressly for it in:
Unless the Contractor makes or has made a Claim under Sub-Clause 20.2
[Claims For Payment and/or E07] in respect of an amount or amounts
included in the Final Payment within 56 days of receiving the Final Payment
the Contractor shall be deemed to have accepted the Final Payment as
correct. The Employer shall then have no further liability to the Contractor,
other than to return the Performance Security to the Contractor.
However, this Sub-Clause shall not limit the Employer's liability under the
Employer's indemnification obligations, or the Employer's liability in any case
of fraud, gross negligence, deliberate default or reckless misconduct by the
Employer.
14.15
Currencies of Payment The Contract Price shall be paid in the currency or currencies named in the
Contract Data. If more than one currency is so named, payments shall be
made as follows:
(a) if the Contract Price stated in the Contract Agreement was expressed
in Local Currency only or in Foreign Currency only:
(i) the proportions or amounts of the Local and Foreign Currencies,
and the fixed rates of exchange to be used for calculating the
payments, shall be as stated in the Contract Data, except as
otherwise agreed by both Parties;
(ii) payments and deductions under Sub-Clause 13.4 [Provisional
Sums] and Sub-Clause 13.6 [Adjustments for Changes in Laws]
shall be made in the applicable currencies and proportions; and
(iii) other payments and deductions under sub-paragraphs (i) to (iv) of
Sub-Clause 14.3 [Application for Interim Payment] shall be made
in the currencies and proportions specified in sub-paragraph (a)
(i) above;
,n by Employer
15.1
Notice to Co1·1i'ect If the Contractor fails to carry out any obligation under the Contract the
Employer may, by giving a Notice to the Contractor, require the Contractor
to make good the failure and to remedy it within a specified time ("Notice to
Correct" in these Conditions).
The time specified in the Notice to Correct shall not imply any extension of
the Time for Completion.
15.2
Termination for
Contractor's Default Termination of the Contract under this Clause shall not prejudice any other
rights of the Employer under the Contract or otherwise.
The Employer shall be entitled to give a Notice (which shall state that it is
given under this Sub-Clause 15.2.1) to the Contractor of the Employer's
intention to terminate the Contract or, in the case of sub-paragraph (t), (g) or
(h) below a Notice of termination, if the Contractor:
15.2.2 Termination
After termination under this Sub-Clause, the Employer may complete the
Works and/or arrange for any other entities to do so. The Employer and/or
these entities may then use any Goods, Contractor's Documents and other
design documents made by or on behalf of the Contractor to complete the
Works.
After such completion of the Works, the Employer shall give another Notice
to the Contractor that the Contractor's Equipment and Temporary Works
will be released to the Contractor at or near the Site. The Contractor shall
then promptly arrange their removal, at the risk and cost of the Contractor.
However, if by this time the Contractor has failed to make a payment due to
the Employer, these items may be sold (to the extent permitted by applicable
Laws) by the Employer in order to recover this payment. Any balance of the
proceeds shall then be paid to the Contractor.
i5.3 ---------------
Valuation after Termination
for Contractor's Default After termination of the Contract under Sub-Clause 15.2 [Termination for
Contractor's Default], the Employer's Representative shall proceed under
Sub-Clause 3.5 [Agreement or Determination] to agree or determine the
value of the Permanent Works, Goods and Contractor's Documents, and
any other sums due to the Contractor for work executed in accordance with
the Contract (and, for the purpose of Sub-Clause 3.5.3 [Time limits], the
date of termination shall be the date of commencement of the time limit for
agreement under Sub-Clause 3.5.3).
This valuation shall include any additions and/or deductions, and the balance
due (if any), by reference to the matters described in sub-paragraphs (a) and
(b) of Sub-Clause 14.13 [Final Payment].
15.4
Payment after Termination
for Contractor's Default The Employer may withhold payment to the Contractor of the amounts
agreed or determined under Sub-Clause 15.3 [Valuation after Termination for
Contractor's Default] until all the costs, losses and damages (if any) described
in the following provisions of this Sub-Clause have been established.
15.5
Termination for
Employer's Convenience The Employer shall be entitled to terminate the Contract at any time for the
Employer's convenience, by giving a Notice of such termination to the Contractor
(which Notice shall state that it is given under this Sub-Clause 15.5).
After giving a Notice to terminate under this Sub-Clause, the Employer shall
immediately:
Termination under this Sub-Clause shall take effect 28 days after the later
of the dates on which the Contractor receives this Notice or the Employer
returns the Performance Security. Unless and until the Contractor has
received payment of the amount due under Sub-Clause 15.6 [Valuation after
Termination for Employer's Convenience], the Employer shall not execute
(any part ot) the Works or arrange for (any part ot) the Works to be executed
by any other entities.
the Contractor may, not less than 21 days after giving a Notice to the
Employer (which Notice shall state that it is given under this Sub-Clause
16.2
Termination by Contractor Termination of the Contract under this Clause shall not prejudice any other
rights of the Contractor, under the Contract or otherwise.
16.2.1 Notice
The Contractor shall be entitled to give a Notice (which shall state that it is
given under this Sub-Clause 16.2.1) to the Employer of the Contractor's
intention to terminate the Contract or, in the case of sub-paragraph (n (ii), (g),
(h) or (i) below a Notice of termination, if:
(a) the Contractor does not receive the reasonable evidence within 42
days after giving a Notice under Sub-Clause 16.1 [Suspension by
Contractor] in respect of a failure to comply with Sub-Clause 2.4
[Employer's Financial Arrangements];
(b) the Contractor does not receive a payment under Sub-Clause 14. 7
[Payment] within 42 days after the expiry of the relevant period for
payment stated in Sub-Clause 14.7;
(c) the Employer fails to comply with:
(i) a binding agreement, or final and binding determination under
Sub-Clause 3.5 [Agreement or Determination]; or
(ii) a decision of the DAAB under 21.4 [Obtaining DMB's Decision]
(whether binding or final and binding)
and such failure constitutes a material breach of the Employer's
obligations under the Contract;
(d) the Employer substantially fails to perform, and such failure constitutes
a material breach of, the Employer's obligations under the Contract;
(e) the Contractor does not receive a Notice of the Commencement Date
under Sub-Clause 8.1 [Commencement of Works] within 84 days
after both Parties have signed the Contract Agreement;
(n the Employer:
(i) fails to comply with Sub-Clause 1.6 [Contract Agreement], or
(ii) assigns the Contract without the required agreement under
Sub-Clause 1.7 [Assignment];
(g) a prolonged suspension affects the whole of the Works as described
in sub-paragraph (b) of Sub-Clause 8.12 [Prolonged Suspension];
(h) the Employer becomes bankrupt or insolvent; goes into liquidation,
administration, reorganisation, winding-up or dissolution; becomes
16.2.2 Termination
If the Contractor suffers delay and/or incurs Cost during the above period of
14 days, the Contractor shall be entitled subject to Sub-Clause 20.2 [Claims
For Payment and/or EQT] to EOT and/or payment of such Cost Plus Profit.
Contractor's Obligations
After Termination After termination of the Contract under Sub-Clause 15.5 [Termination tor
Employer's Convenience], Sub-Clause 16.2 [Termination by Contractor] or
Sub-Clause 18.5 [Optional Termination], the Contractor shall promptly:
(a) cease all further work, except for such work as may have been
instructed by the Employer for the protection of life or property or
for the safety of the Works. If the Contractor incurs Cost as a result
of carrying out such instructed work the Contractor shall be entitled
subject to Sub-Clause 20.2 [Claims For Payment and/or EOT] to be
paid such Cost Plus Profit;
(b) deliver to the Employer all Contractor's Documents, Plant, Materials
and other work for which the Contractor has received payment; and
(c) remove all other Goods from the Site, except as necessary for safety,
and leave the Site.
16.4
Payment after
Termination by Contractor After termination under Sub-Clause 16.2 [Termination by Contractor], the
Employer shall promptly:
17.2
liability for
Care of the Works The Contractor shall be liable for any loss or damage caused by the
Contractor to the Works, Goods or Contractor's Documents after the issue
of a Taking-Over Certificate. The Contractor shall also be liable for any loss or
damage, which occurs after the issue of a Taking-Over Certificate and which
arose from an event which occurred before the issue of this Taking-Over
Certificate, for which the Contractor was liable.
17.3
Intellectual and Industrial
Property In this Sub-Clause, "infringement" means an infringement (or alleged
infringement) of any patent, registered design, copyright, trademark, trade
name, trade secret or other intellectual or industrial property right relating to
the Works; and "claim" means a third party claim (or proceedings pursuing a
third party claim) alleging an infringement.
Whenever a Party receives a claim but fails to give notice to the other Party
of the claim within 28 days of receiving it, the first Party shall be deemed to
have waived any right to indemnity under this Sub-Clause.
The Employer shall indemnify and hold the Contractor harmless against and
from any claim (including legal fees and expenses) alleging an infringement
which is or was:
The Contractor shall indemnify and hold the Employer harmless against
and from any other claim (including legal fees and expenses) alleging an
infringement which arises out of or in relation to:
17.4
indemnities by Contractor The Contractor shall indemnify and hold harmless the Employer, the
Employer's Personnel, and their respective agents, against and from all
third party claims, damages, losses and expenses (including legal fees and
expenses) in respect of:
G')
(a) bodily injury, sickness, disease or death of any person whatsoever
il:
() arising out of or in the course of or by reason of the Contractor's
execution of the Works, unless attributable to any negligence, wilful
act or breach of the Contract by the Employer, the Employer's
Personnel, or any of their respective agents; and
(b) damage to or loss of any property, real or personal (other than the
Works), to the extent that such damage or loss:
(i) arises out of or in the course of or by reason of the Contractor's
execution of the Works, and
(ii) is attributable to any negligence, wilful act or breach of the
Contract by the Contractor, the Contractor's Personnel, their
respective agents, or anyone directly or indirectly employed by
any of them.
The Contractor shall also indemnify and hold harmless the Employer against all
acts, errors or omissions by the Contractor in carrying out the Contractor's design
obligations that result in the Works (or Section or Part or major item of Plant, if any),
when completed, not being fit for the purpose(s) for which they are intended under
Sub-Clause 4.1 [Contractor's General Obligations].
17.5
Indemnities by Employer The Employer shall indemnify and hold harmless the Contractor, the
Contractor's Personnel, and their respective agents, against and from all
third party claims, damages, losses and expenses (including legal fees and
expenses) in respect of:
17.6
Shared Indemnities The Contractor's liability to indemnify the Employer, under Sub-Clause 17.4
Undemnities by Contractor] and/or under Sub-Clause 17.3 Untel/ectual and
Industrial Property Rights], shall be reduced proportionately to the extent that
any event described under sub-paragraphs (a) to(~ of Sub-Clause 17.2 [Liability
for Care of the Works] may have contributed to the said damage, loss or injury.
I Events
18.1
Exceptional Events "Exceptional Event" means an event or circumstance which:
An Exceptional Event may comprise but is not limited to any of the following
events or circumstances provided that conditions (i) to (iv) above are satisfied:
18.2
Notice of
an Exceptional Event If a Party is or will be prevented from performing any obligations under the
Contract due to an Exceptional Event (the "affected Party" in this Clause),
then the affected Party shall give a Notice to the other Party of such an
Exceptional Event, and shall specify the obligations, the performance of
which is or will be prevented (the "prevented obligations" in this Clause).
This Notice shall be given within 14 days after the affected Party became
aware, or should have become aware, of the Exceptional Event, and the
affected Party shall then be excused performance of the prevented obligations
from the date such performance is prevented by the Exceptional Event. If this
Notice is received by the other Party after this period of 14 days, the affected
Party shall be excused performance of the prevented obligations only from the
date on which this Notice is received by the other Party.
However, the obligations of either Party to make payments due to the other
Party under the Contract shall not be excused by an Exceptional Event.
18.3
Duty to Minimise Each Party shall at all times use all reasonable endeavours to minimise any
delay in the performance of the Contract as a result of an Exceptional Event.
If the Exceptional Event has a continuing effect, the affected Party shall give
further Notices describing the effect every 28 days after giving the first Notice
under Sub-Clause 18.2 [Notice of an Exceptional Event].
The affected Party shall immediately give a Notice to the other Party when the
affected Party ceases to be affected by the Exceptional Event. If the affected
Party fails to do so, the other Party may give a Notice to the affected Party
stating that the other Party considers that the affected Party's performance
is no longer prevented by the Exceptional Event, with reasons.
18.4
Consequences of
an Exceptional Event If the Contractor is the affected Party and suffers delay and/or incurs Cost
by reason of the Exceptional Event of which he/she gave a Notice under
Sub-Clause 18.2 [Notice of an Exceptional Event], the Contractor shall be
entitled subject to Sub-Clause 20.2 [Claims For Payment and/or E011 to:
18.5
Optional Termination If the execution of substantially all the Works in progress is prevented for a
continuous period of 84 days by reason of an Exceptional Event of which
Notice has been given under Sub-Clause 18.2 [Notice of an Exceptional
Event], or for multiple periods which total more than 140 days due to the
same Exceptional Event, then either Party may give to the other Party a
Notice of termination of the Contract.
In this event, the date of termination shall be the date 7 days after the Notice is
received by the other Party, and the Contractor shall proceed in accordance
with Sub-Clause 16.3 [Contractor's Obligations After Termination].
(a) the amounts payable for any work carried out for which a price is
stated in the Contract;
(b) the Cost of Plant and Materials ordered for the Works which have
been delivered to the Contractor, or of which the Contractor is liable
to accept delivery. This Plant and Materials shall become the property
of (and be at the risk of) the Employer when paid for by the Employer,
and the Contractor shall place the same at the Employer's disposal;
18.6
Release from Performance
under the Law In addition to any other provision of this Clause, if any event arises outside the
control of the Parties (including, but not limited to, an Exceptional Event) which:
(a) makes it impossible or unlawful for either Party or both Parties to fulfil
their contractual obligations; or
(b) under the law governing the Contract, entitles the Parties to be
released from further performance of the Contract,
and if the Parties are unable to agree on an amendment to the Contract that
would permit the continued performance of the Contract, then after either
Party gives a Notice to the other Party of such event:
(i) the Parties shall be discharged from further performance, and without
prejudice to the rights of either Party in respect of any previous breach
of the Contract; and
(ii) the amount payable by the Employer to the Contractor shall be the
same as would have been payable under Sub-Clause 18.5 [Optional
Termination], and such amount shall be paid by the Employer, as if the
Contract had been terminated under that Sub-Clause.
Ins a
19.1
General Requirements Without limiting either Party's obligations or responsibilities under the
Contract, the Contractor shall effect and maintain all insurances for which
the Contractor is responsible with insurers and in terms, both of which shall
be subject to consent by the Employer. These terms shall be consistent with
terms (if any) agreed by both Parties before the date that both Parties signed
the Contract Agreement.
The insurances required to be provided under this Clause are the minimum
required by the Employer, and the Contractor may, at the Contractor's own
cost, add such other insurances that the Contractor may deem prudent.
If the Contractor fails to effect and keep in force any of the insurances required
under Sub-Clause 19.2 [Insurances to be provided by the Contractor] then,
and in any such case, the Employer may effect and keep in force such
insurances and pay any premium as may be necessary and recover the
same from the Contractor from time to time by deducting the amount(s) so
paid from any moneys due to the Contractor or otherwise recover the same
as a debt from the Contractor. The provisions of Clause 20 [Employer's and
Contractor's Claims] shall not apply to this Sub-Clause.
(j)
2 If either the Contractor or the Employer fails to comply with any condition of
§ the insurances effected under the Contract, the Party so failing to comply
'
shall indemnify the other Party against all direct losses and claims (including
legal fees and expenses) arising from such failure.
The permitted deductible limits allowed in any policy shall not exceed the
amounts stated in the Contract Data (if not stated, the amounts agreed with
the Employer).
Where there is a shared liability the loss shall be borne by each Party in
proportion to each Party's liability, provided the non-recovery from insurers
has not been caused by a breach of this Clause by the Contractor or the
Employer. In the event that non-recovery from insurers has been caused by
such a breach, the defaulting Party shall bear the loss suffered.
lnsurarnce to be provided
by the Corrl:rnctor The Contractor shall provide the following insurances:
The Contractor shall insure and keep insured in the joint names of the
Contractor and the Employer from the Commencement Date until the date
of the issue of the Taking-Over Certificate for the Works:
(a) the Works and Contractor's Documents, together with Materials and
Plant for incorporation in the Works, for their full replacement value.
The insurance cover shall extend to include loss and damage of any
part of the Works as a consequence of failure of elements defectively
designed or constructed with defective material or workmanship; and
(b) an additional amount of fifteen percent (15%) of such replacement
value (or such other amount as may be specified in the Contract Data)
to cover any additional costs incidental to the rectification of loss or
damage, including professional fees and the cost of demolition and
removal of debris.
However, the insurance cover provided by the Contractor for the Works may
exclude any of the following:
(i) the cost of making good any part of the Works which is defective
(including defective material and workmanship) or otherwise does not
comply with the Contract, provided that it does not exclude the cost
of making good any loss or damage to any other part of the Works
attributable to such defect or non-compliance;
(ii) indirect or consequential loss or damage including any reductions in
the Contract Price for delay;
(iii) wear and tear, shortages and pilferages; and
(iv) unless otherwise stated in the Contract Data, the risks arising from
Exceptional Events.
19.2.2 Goods
The Contractor shall insure, in the joint names of the Contractor and the
Employer, the Goods and other things brought to Site by the Contractor
to the extent specified and/or amount stated in the Contract Data (if not
specified or stated, for their full replacement value including delivery to Site).
The Contractor shall maintain this insurance from the time the Goods are
delivered to the Site until they are no longer required for the Works.
To the extent, if any, that the Contractor is responsible for the design of
part of the Permanent Works under Sub-Clause 4.1 [Contractor's General
Obligations], and/or any other design under the Contract, and consistent with
the indemnities specified in Clause 17 [Care of the Works and Indemnities]:
The Contractor shall maintain this insurance for the period specified in the
Contract Data.
The Contractor shall insure, in the joint names of the Contractor and the
Employer, against liabilities for death or injury to any person, or loss of or
damage to any property (other than the Works) arising out of the performance
of the Contract and occurring before the issue of the Performance Certificate,
other than loss or damage caused by an Exceptional Event.
The insurance policy shall include a cross liability clause such that the insurance
shall apply to the Contractor and the Employer as separate insureds.
Such insurance shall be effected before the Contractor begins any work on
the Site and shall remain in force until the issue of the Performance Certificate
and shall be for not less than the amount stated in the Contract Data (if not
stated, the amount agreed with the Employer).
The Contractor shall effect and maintain insurance against liability for claims,
damages, losses and expenses (including legal fees and expenses) arising
out of the execution of the Works in respect of injury, sickness, disease or
death of any person employed by the Contractor or any of the Contractor's
other personnel.
The Employer shall also be indemnified under the policy of insurance, except
that this insurance may exclude losses and claims to the extent that they
arise from any act or neglect of the Employer or of the Employer's Personnel.
The insurance shall be maintained in full force and effect during the whole
time that the Contractor's Personnel are assisting in the execution of the
Works. For any person employed by a Subcontractor, the insurance may be
effected by the Subcontractor, but the Contractor shall be responsible for
the Subcontractor's compliance with this Sub-Clause.
The Contractor shall provide all other insurances required by the Laws of
the countries where (any part of) the Works are being carried out, at the
Contractor's own cost.
(a) if the Employer considers that the Employer is entitled to any additional
payment from the Contractor (or reduction in the Contract Price) and/
or to an extension of the DNP;
(b) if the Contractor considers that the Contractor is entitled to any
additional payment from the Employer and/or to EOT; or
(c) if either Party considers that he/she is entitled to another entitlement
or relief against the other Party. Such other entitlement or relief
In the case of a Claim under sub-paragraph (c) above, where the other Party
has disagreed with the requested entitlement or relief (or is deemed to have
disagreed if he/she does not respond within a reasonable time), a Dispute
shall not be deemed to have arisen but the claiming Party may, by giving a
Notice refer the Claim to the Employer's Representative and Sub-Clause 3.5
[Agreement or Determination] shall apply. This Notice shall be given as soon
as practicable after the claiming Party becomes aware of the disagreement
(or deemed disagreement) and shall include details of the claiming Party's
case and the other Party's disagreement (or deemed disagreement).
The claiming Party shall give a Notice to the other Party, describing the event
or circumstance giving rise to the cost, loss, delay or extension of DNP for
which the Claim is made as soon as practicable, and no later than 28 days
after the claiming Party became aware, or should have become aware, of
the event or circumstance (the "Notice of Claim" in these Conditions).
If the claiming Party fails to give a Notice of Claim within this period of 28
days, the claiming Party shall not be entitled to any additional payment,
the Contract Price shall not be reduced (in the case of the Employer as the
claiming Party), the Time for Completion (in the case of the Contractor as
the claiming Party) or the DNP (in the case of the Employer as the claiming
Party) shall not be extended, and the other Party shall be discharged from
any liability in connection with the event or circumstance giving rise to the
Claim.
If the other Party considers that the claiming Party has failed to give the
Notice of Claim within the period of 28 days under Sub-Clause 20.2.1 [Notice
of Claim] the other Party shall, within 14 days after receiving the Notice of
Claim, give a Notice to the claiming Party accordingly (with reasons).
If the other Party does not give such a Notice within this period of 14 days,
the Notice of Claim shall be deemed to be a valid Notice.
If the claiming Party receives a Notice from the other Party under this
Sub-Clause and disagrees with the other Party or considers there are
circumstances which justify late submission of the Notice of Claim, the
Without admitting the Employer's liability, the Employer may monitor the
Contractor's contemporary records and/or instruct the Contractor to
keep additional contemporary records. The Contractor shall permit the
Employer to inspect all these records during normal working hours (or at
other times agreed by the Contractor), and shall if instructed submit copies
to the Employer. Such monitoring, inspection or instruction (if any) by the
Employer shall not imply acceptance of the accuracy or completeness of the
Contractor's contemporary records.
(a) a detailed description of the event or circumstance giving rise to the Claim;
(b) a statement of the contractual and/or other legal basis of the Claim;
(c) all contemporary records on which the claiming Party relies; and
(d) detailed supporting particulars of the amount of additional payment
claimed (or amount of reduction of the Contract Price in the case of the
Employer as the claiming Party), and/or EOT claimed (in the case of the
Contractor) or extension of the DNP claimed (in the case of the Employer).
Within either:
(i) 84 days after the claiming Party became aware, or should have become
aware, of the event or circumstance giving rise to the Claim, or
(ii) such other period (if any) as may be proposed by the claiming Party
and agreed by the other Party
the claiming Party shall submit to the Employer's Representative a fully
detailed Claim.
If within this time limit the claiming Party fails to submit the statement under
sub-paragraph (b) above, the Notice of Claim shall be deemed to have
lapsed, it shall no longer be considered as a valid Notice, and the Employer's
Representative shall, within 14 days after this time limit has expired, give a
Notice to the claiming Party accordingly.
If the Employer's Representative does not give such a Notice within this
period of 14 days, the Notice of Claim shall be deemed to be a valid Notice.
If the other Party disagrees with such deemed valid Notice of Claim the other
Party shall give a Notice to the Employer's Representative which shall include
details of the disagreement. Thereafter, the agreement or determination of
the Claim under Sub-Clause 20.2.5 [Agreement or determination of the
Claim] shall include a review by the Employer's Representative of such
disagreement.
If the event or circumstance giving rise to the Claim has a continuing effect,
Sub-Clause 20.2.6 [Claims of continuing effect] shall apply.
(a) the additional payment (if any) to which the claiming Party is entitled
(or the reduction of the Contract Price (in the case of the Employer as
the claiming Party); and/or
(b) the extension (if any) of the Time for Completion (before or after its expiry)
under Sub-Clause 8.5 [Extension of Time for Completion] (in the case
of the Contractor as the claiming Party), or the extension (if any) of the
DNP (before its expiry) under Sub-Clause 11.3 [Extension of Defects
Notification Perioc/j (in the case of the Employer as the claiming Party),
to which the claiming Party is entitled under the Contract.
If, having received the fully detailed Claim under Sub-Clause 20.2.4 [Fully
detailed Claim], or in the case of a Claim under Sub-Clause 20.2.6 [Claims
of continuing effect] an interim or final fully detailed Claim (as the case may
be), the Employer's Representative requires necessary additional particulars:
(i) he/she shall promptly give a Notice to the Contractor, describing the
additional particulars and the reasons for requiring them;
(ii) he/she shall nevertheless give his/her response on the contractual or
other basis of the Claim, by giving a Notice to the Contractor, within
The DAAB shall comprise, as stated in the Contract Data, either one suitably
qualified member (the "sole member") or three suitably qualified members
(the "members"). If the number is not so stated, and the Parties do not agree
otherwise, the DAAB shall comprise three members.
The sole member or three members (as the case may be) shall be selected (f)
from those named in the list in the Contract Data, other than anyone who is ft
()
unable or unwilling to accept appointment to the DAAB. LL
If the DAAB is to comprise three members, each Party shall select one
member for the agreement of the other Party. The Parties shall consult both
these members and shall agree the third member, who shall be appointed to
act as chairperson.
The DAAB shall be deemed to be constituted on the date that the Parties
and the sole member or the three members (as the case may be) of the
DAAB have all signed a DAAB Agreement.
i
The terms of the remuneration of either the sole member or each of the three
members, including the remuneration of any expert whom the DAAB consults,
shall be mutually agreed by the Parties when agreeing the terms of the DAAB
Agreement. Each Party shall be responsible for paying one-half of this remuneration.
If at any time the Parties so agree, they may appoint a suitably qualified
person or persons to replace any one or more members of the DAAB.
Unless the Parties agree otherwise, a replacement DAAB member shall be
appointed if a member declines to act or is unable to act as a resulfof death,
illness, disability, resignation or termination of appointment. The replacement
member shall be appointed in the same manner as the replaced member was
required to have been selected or agreed, as described in this Sub-Clause.
Unless otherwise agreed by bot1h Parties, the term of the DAAB (including
the appointment of each member) shall expire either:
(a) on the date the discharge shall have become, or deemed to have
become, effective under Sub-Clause 14.12 [Discharge]; or
(b) 28 days after the DAAB has given its decision on all Disputes, referred
to it under Sub-Clause 21.4 [Obtaining DMB's Decision] before such
discharge has become effective,
whichever is later.
Failure to Appoint
DAAB Member(s} If any of the following conditions apply, namely:
(a) if the DAAB is to comprise a sole member, the Parties fail to agree the
appointment of this member by the date stated in the first paragraph
of Sub-Clause 21.1 [Constitution of the DAAB]; or
{b) if the DAAB is to comprise three persons, and if by the date stated in
the first paragraph of Sub-Clause 21.1 [Constitution of the DAAB]:
(i) either Party fails to select a member (for agreement by the other
Party);
(ii) either Party fails to agree a member selected by the other Party;
and/or
(iii) the Parties fail to agree the appointment of the third member (to
act as chairperson) of the DAAB;
(c) the Parties fail to agree the appointment of a replacement within 42
days after the date on which the sole member or one of the three
members declines to act or is unable to act as a result of death,
illness, disability, resignation, or termination of appointment; or
(d) if, after the Parties have agreed the· appointment of the member(s)
or replacement, such appointment cannot be effected because
one Party refuses or fails to sign a DAAB Agreement with any such
member or replacement (as the case may be) within 14 days of the
other Party's request to do so,
then the appointing entity or official named in the Contract Data shall, at the
request of either or both Parties and after due consultation with both Parties,
appoint the member(s) of the DAAB (who, in the case of sub-paragraph {d)
above, shall be the agreed member(s) or replacement). This appointment
shall be final and conclusive.
(i) the monthly services fee and daily fee shall be as stated in the terms
of the appointment; and
(ii) the law governing the DAAB Agreement shall be the governing law of
the Contract defined in Sub-Clause 1.4 [Law and Language].
Such joint request may be made at any time, except during the period that the
Employer's Representative is carrying out his/her duties under Sub-Clause
3.5 [Agreement or Determination] on the matter at issue or in disagreement
unless the Parties agree otherwise.
Such informal assistance may take place during any meeting, Site visit or
otherwise. However, unless the Parties agree otherwise, both Parties shall be
present at such discussions. The Parties are not bound to act on any advice
given during such informal meetings, and the DAAB shall not be bound in any
future Dispute resolution process or decision by any views or advice given
during the informal assistance process, whether provided orally or in writing.
21.4
Obtaining DAAB's Decision If a Dispute arises between the Parties then either Party may refer the Dispute
to the DAAB for its decision (whether or not any informal discussions have
been held under Sub-Clause 21 .3 [Avoidance of Disputes]) and the following
provisions shall apply.
The reference of a Dispute to the DAAB under this Sub-Clause shall, unless
prohibited by law, be deemed to interrupt the running of any applicable
statute of limitation or prescription period.
Both Parties shall promptly make available to the DAAB all information,
access to the Site, and appropriate facilities, as the DAAB may require for
the purposes of making a decision on the Dispute.
Unless the Contract has already been abandoned or terminated, the Parties
shall continue to perform their obligations in accordance with the Contract.
However, if at the end of this period, the due date(s) for payment of any DAAB
member's invoice(s) has passed but such invoice(s) remains/remain unpaid,
the DAAB shall not be obliged to give its decision until such outstanding
invoice(s) has/have been paid in full, in which case the DAAB shall give its
decision as soon as practicable after payment has been received.
The decision shall be given in writing to both Parties, shall be reasoned, and
shall state that it is given under this Sub-Clause.
The decision shall be binding on both Parties, who shall promptly comply
with it whether or not a Party gives a NOD with respect to such decision
under this Sub-Clause.
(a) such Party may give a NOD to the other Party, with a copy to the DAAB;
(b) this NOD shall state that it is a "Notice of Dissatisfaction with the
DAAB's Decision" and shall set out the matter in Dispute and the
reason(s) for dissatisfaction; and
(c) this NOD shall be given within 28 days after receiving the DAAB's
decision.
If the DAAB fails to give its decision within the period stated in Sub-Clause
21.4.3 [The DMB's decision], then either Party may, within 28 days after
this period has expired, give a NOD to the other Party in accordance with
sub-paragraphs (a) and (b) above.
If the dissatisfied Party is dissatisfied with only part(s) of the DAAB's decision:
21.5
Amicable Settlement Where a NOD has been given under Sub-Clause 21.4 [Obtaining DMB's
Decision], both Parties shall attempt to settle the Dispute amicably before
the commencement of arbitration. However, unless both Parties agree
otherwise, arbitration may be commenced on or after the twenty-eighth
(28th) day after the day on which this NOD was given, even if no attempt at
amicable settlement has been made.
21.6
Arbitration Unless settled amicably, and subject to Sub-Clause 3.5.5 [Dissatisfaction
with Employer's Representative's determination], Sub-Clause 21.4.4
[Dissatisfaction with DMB's decision], Sub-Clause 21.7 [Failure to Comply
with DMB's Decision] and Sub-Clause 21.8 [No DMB In Place], any Dispute
in respect of which the DAAB's decision (if any) has not become final and
binding shall be finally settled by international arbitration. Unless otherwise
agreed by both Parties:
(a) the Dispute shall be finally settled under the Rules of Arbitration of the
International Chamber of Commerce;
(b) the Dispute shall be settled by one or three arbitrators appointed in
accordance with these Rules; and
(c) the arbitration shall be conducted in the ruling language defined in
Sub-Clause 1.4 [Law and Language].
The arbitrator(s) shall have full power to open up, review and revise any
certificate, determination (other than a final and binding determination),
instruction, opinion or valuation of the Employer and/or of the Employer's
Representative, and any decision of the DAAB (other than a final and
binding decision) relevant to the Dispute. Nothing shall disqualify the natural
person(s) who has/have acted on behalf of the Employer under the Contract
from being called as witness(es) and giving evidence before the arbitrator(s)
on any matter whatsoever relevant to the Dispute.
In any award dealing with costs of the arbitration, the arbitrator(s) may take
account of the extent (if any) to which a Party failed to cooperate with the
other Party in constituting a DAAB under Sub-Clause 21 .1 [Constitution of
the DMB] and/or Sub-Clause 21.2 [Failure to Appoint DMB Member(s)].
21.7
Failure to Comply
with DAAB's Decision In the event that a Party fails to comply with any decision of the DAAB, whether
binding or final and binding, then the other Party may, without prejudice to
any other rights it may have, refer the failure itself directly to arbitration under
Sub-Clause 21.6 [Arbitration] in which case Sub-Clause 21.4 [Obtaining
DMB's Decision] and Sub-Clause 21.5 [Amicable Settlement] shall not
apply to this reference. The arbitral tribunal (constituted under Sub-Clause
21.6 [Arbitration]) shall have the power, by way of summary or other
expedited procedure, to order, whether by an interim or provisional measure
or an award (as may be appropriate under applicable law or otherwise), the
enforcement of that decision.
In the case of a binding but not final decision of the DAAB, such interim or
provisional measure or award shall be subject to the express reservation that
the rights of the Parties as to the merits of the Dispute are reserved until they
are resolved by an award.
21.8
No DAAB In Place If a Dispute arises between the Parties in connection with, or arising out of,
the Contract or the execution of the Works and there is no DAAB in place
(or no DAAB is being constituted), whether by reason of the expiry of the
DAAB's appointment or otherwise:
1
Definitions 1.1 "General Conditions of Dispute Avoidance/Adjudication Agreement"
or "GCs" means this document entitled "General Conditions of Dispute
Avoidance/Adjudication Agreement", as published by FIDIC.
1.2 In the DAA Agreement (as defined below) and in the GCs, words and
expressions which are not otherwise defined shall have the meanings
assigned to them in the Contract (as defined in the DAA Agreement).
1.3 "DAAB's Activities" means the activities carried out by the DAAB in
accordance with the Contract and the GCs, including all Informal Assistance,
meetings (including meetings and/or discussions between the DAAB members
in the case of a three-member DAAB), Site visits, hearings and decisions.
1 .6 "Term of the DAAB" means the period starting on the Effective Date (as
defined in Sub-Clause 2.1 below) and finishing on the date that the term of
the DAAB expires in accordance with Sub-Clause 21 .1 [Constitution of the
DAAB] of the Conditions of Contract.
1.7 "Notification" means a notice in writing given under the GCs, which shall be:
2
General Provisions 2.1 The DAA Agreement shall take effect:
(a) in the case of a sole-member DAAB, on the date when the Employer,
the Contractor and the DAAB Member have each signed (or, under
the Contract, are deemed to have signed) the DAA Agreement; or
(b) in the case of a three-member DAAB, on the date when the Employer,
the Contractor, the DAAB Member and the Other Members have
each signed (or under the Contract are deemed to have signed) a
DAA Agreement.
2.2 Immediately after the Effective Date, either or both Parties shall give a
Notification to the DAAB Member that the DAA Agreement has come into
effect. If the DAAB Member does not receive such a notice within 182 days
after entering into the DAA Agreement, it shall be void and ineffective.
3
Warranties 3.1 The DAAB Member warrants and agrees that he/she is, and will remain at
all times during the Term of the DAAB, impartial and independent of the
Employer, the Contractor, the Employer's Personnel and the Contractor's
Personnel (including in accordance with Sub-Clause 4.1 below).
3.2 If, after signing the DAA Agreement (or after he/she is deemed to have signed
the DAA Agreement under the Contract), the DAAB Member becomes aware
of any fact or circumstance which might:
3.3 When appointing the DAAB Member, each Party relies on the DAAB
Member's representations that he/she is:
4.1 Further to Sub-Clauses 3.1 and 3.2 above, the DAAB Member shall:
(a) have no financial interest in the Contract, or in the project of which the
Works are part, except for payment under the DAA Agreement;
(b) have no interest whatsoever (financial or otherwise) in the Employer, the
Contractor, the Employer's Personnel or the Contractor's Personnel;
(c) in the ten years before signing the DAA Agreement, not have
been employed as a consultant or otherwise by the Employer, the
Contractor, the Employer's Personnel or the Contractor's Personnel;
(d) not previously have acted, and shall not act, in any judicial or arbitral
capacity in relation to the Contract;
(e) have disclosed in writing to the Employer, the Contractor and the
Other Members (if any), before signing the DAA Agreement (or before
he/she is deemed to have signed the DAA Agreement under the u ..
Contract) and to his/her best knowledge and recollection, any:
(i) existing and/or past professional or personal relationships with
any director, officer or employee of the Employer, the Contractor,
the Employer's Personnel or the Contractor's Personnel (including
as a dispute resolution practitioner on another project),
(ii) facts or circumstances which might call into question his/her
independence or impartiality, and
(iii) previous involvement in the project of which the Contract forms
part;
(f) not, while a DAAB Member and for the Term of the DAAB:
(i) be employed as a consultant or otherwise by, and/or
(ii) enter into discussions or make any agreement regarding future
employment with
the Employer, the Contractor, the Employer's Personnel or the Contractor's
Personnel, except as may be agreed by the Employer, the Contractor and
the Other Members (if any); and/or
(g) not solicit, accept or receive (directly or indirectly) any gift, gratuity,
commission or other thing of value from the Employer, the Contractor,
the Employer's Personnel or the Contractor's Personnel, except for
payment under the DAA Agreement.
5
General Obligations
of the DAAB Member 5.1 The DAAB Member shall:
(a) comply with the GCs, the DAAB Rules and the Conditions of Contract
that are relevant to the DAAB's Activities;
(b) not give advice to the Employer, the Contractor, the Employer's
Personnel or the Contractor's Personnel concerning the conduct of
the Contract, except as required to carry out the DAAB's Activities;
(c) ensure his/her availability during the Term of the DAAB (except in
exceptional circumstances, in which case the DAAB Member shall give
a Notification without delay to the Parties and the Other Members (if
any) detailing the exceptional circumstances) for all meetings, Site visits,
hearings and as is necessary to comply with sub-paragraph (a) above;
(d) become, and shall remain for the duration of the Term of the DAAB,
knowledgeable about the Contract and informed about:
6
General
of the Parties 6.1 Each Party shall comply with the GCs, the DAAB Rules and the Conditions
of Contract that are relevant to the DAAB's Activities. The Employer and the
Contractor shall be responsible for compliance with this provision by the
Employer's Personnel and the Contractor's Personnel, respectively.
6.2 Each Party shall cooperate with the other Party in constituting the DAAB,
under Sub-Clause 21.1 [Constitution of the DMB] and/or Sub-Clause 21.2
[Failure to Appoint DMB Member(s)] of the Conditions of Contract, without
delay.
6.4 The Parties, the Employer's Personnel and the Contractor's Personnel shall
not request advice from or consultation with the DAAB Member regarding
the Contract, except as required for the DAAB Member to carry out the
DAAB's Activities.
6.5 At all times when interacting with the DAAB, each Party shall not compromise
the DAAB's warranty of independence and impartiality under Sub-Clause
3.1 above.
6.6 In addition to providing documents under Rule 4.3 of the DAAB Rules, each
Party shall ensure that the DAAB Member remains informed as is necessary
to enable him/her to comply with sub-paragraph (d) of Sub-Clause 5.1
above.
7
Confidentiality 7.1 Subject to Sub-Clause 7.4 below, the DAAB Member shall treat the details
of the Contract, all the DAAB's Activities and the documents provided under
Rule 4.3 of the DAAB Rules as private and confidential, and shall not publish
or disclose them without the prior written consent of the Parties and the
Other Members (if any).
7.4 If a DMB Member is replaced under the Contract, the Parties and/or the Other
Members (if any) shall disclose details of the Contract, the documents provided
under Rule 4.3 of the DMB Rules and previous DMB's Activities (including
decisions, if any) to the replacement DMB Member as is necessary in order to:
(a) enable the replacement DMB Member to comply with sub-paragraph u..
(d) of Sub-Clause 5.1 above; and
(b) ensure consistency in the manner in which the DMB's Activities are
conducted following such replacement.
8.2 The Employer and the Contractor hereby jointly and severally indemnify and
hold the DMB Member harmless against and from all damages, losses and
expenses (including legal fees and expenses) resulting from any claim from
which he/she is relieved from liability under Sub-Clause 8.1 above.
9
Fees and Expenses 9.1 The DMB Member shall be paid as follows, in the currency named in the
OM Agreement:
(a) a monthly fee, which shall be a fixed fee as payment in full for:
(i) being available on 28-days' notice for all meetings, Site visits and
hearings under the DMB Rules (and, in the event of a request
under Rule 3.6 of the DMB Rules, being available for an urgent
meeting or Site visit);
(ii) becoming and remaining knowledgeable about the Contract,
informed about the progress of the Works and maintaining
a current working file of documents, in accordance with
sub-paragraph (d) of Clause 5.1 above;
(iii) all office and overhead expenses including secretarial services,
photocopying and office supplies incurred in connection with his/
her duties; and
(iv) all services performed hereunder except those referred to in
sub-paragraphs (b) and (c) of this Clause.
(b) a daily fee, which shall be considered as payment in full for each day:
(i) or part of a day, up to a maximum of two days' travel time in each
direction, for the journey between the DAAB Member's home
and the Site, or another location of a meeting with the Parties
and/or the Other Members (if any);
(ii) spent on attending meetings and making Site visits in accordance
with Rule 3 of the DAAB Rules, and writing reports in accordance
with Rule 3.1 O of the DAAB Rules;
(iii) spent on giving Informal Assistance;
(iv) spent on attending hearings (and, in the case of a three-member
DAAB, attending meeting(s) between the DAAB Members in
accordance with sub-paragraph (a) of Rule 8.2 of the DAAB
Rules, and communicating with the Other Members), and
preparing decisions; and
(v) spent in preparation for a hearing, and studying written
documentation and arguments from the Parties submitted in
accordance with sub-paragraph (c) of Rule 7 .1 of the DAAB Rules;
(c) all reasonable expenses, including necessary travel expenses (air
fare in business class or equivalent, hotel and subsistence and other
direct travel expenses, including visa charges) incurred in connection
with the DAAB Member's duties, as well as the cost of telephone
calls (and video conference calls, if any, and internet access), courier
charges and faxes. The DAAB Member shall provide the Parties with
a receipt for each item of expenses;
(d) any taxes properly levied in the Country on payments made to the
DAAB Member (unless a national or permanent resident of the
Country) under this Sub-Clause 9.1.
9.2 Subject to Sub-Clause 9.3 below, the amounts of the DAAB Member's
monthly fee and daily fee, under Sub-Clause 9.1 above, shall be as specified
in the DAA Agreement signed (or, under the Contract, deemed to have been
signed) by the Parties and the DAAB Member.
9.3 If the Parties and the DAAB Member have agreed all other terms of the DAA
Agreement but fail to jointly agree the amount of the monthly fee or the daily
fee in the DAA Agreement (the "non-agreed fee" in this Sub-Clause):
9.4 The DAAB Member shall submit invoices for payment of the monthly fee
and air fares quarterly in advance. Invoices for other expenses and for daily
fees shall be submitted following the conclusion of a meeting, Site visit or
hearing; and following the giving of a decision or an informal written note
(under Rule 2.1 of the DAAB Rules). All invoices shall be accompanied by
a brief description of the DAAB's Activities performed during the relevant
period and shall be addressed to the Contractor.
9.5 The Contractor shall pay each of the DAAB Member's invoices in full within
28 days after receiving each invoice. Thereafter, the Contractor shall apply
to the Employer (in the Statements under the Contract) for reimbursement of
one-half of the amounts of these invoices. The Employer shall then pay the
Contractor in accordance with the Contract.
9.6 If the Contractor fails to pay to the DAAB Member the amount to which he/
she is entitled under the DAA Agreement within the period of 28 days stated
in Sub-Clause 9.5 above, the DAAB Member shall inform the Employer
who shall promptly pay the amount due to the DAAB Member and any
other amount which may be required to maintain the function of the DAAB.
Thereafter the Employer shall, by written request, be entitled to payment
from the Contractor of:
The Employer shall be entitled to such payment from the Contractor without
any requirement to comply with Sub-Clause 20.2 [Claims For Payment and/
or Eon of the Conditions of Contract, and without prejudice to any other
right or remedy.
9. 7 If the DAAB Member does not receive payment of the amount due within 56
days after submitting a valid invoice, the DAAB Member may:
(a) not less than 7 days after giving a Notification to the Parties and the
Other Members (if any), suspend his/her services until the payment is
received; and/or
(b) resign his/her appointment by giving a Notification under Sub-Clause
10.1 below.
10
Resignation
and Termination 10.1 The DAAB Member may resign at any time for any reason, by giving a
Notification of not less than 28 days (or other period as may be agreed by the
Parties) to the Parties and to the Other Members (if any). During this period the
General Conditions © FIDIC 2017
109
Parties shall take the necessary steps to appoint, without delay, a replacement
DAAB Member in accordance with Sub-Clause 21.1 [Constitution of the
DAAB] of the Conditions of Contract (and, if applicable, Sub-Clause 21.2
[Failure to Appoint DMB Member(s)] of the Conditions of Contract).
10.2 On expiry of the period stated in Sub-Clause 10.1 above, the resigning
DAAB Member's DAA Agreement shall terminate with immediate effect.
However (except if the DAAB Member is unable to act as a result of illness
or disability) if, on the date of the DAAB Member's notice under Sub-Clause
10.1 above, the DAAB is dealing with any Dispute under Sub-Clause 21.4
--'
(:5 [Obtaining OAAB's Decision] of the Conditions of Contract, the DAAB
Member's resignation shall not take effect and his/her DAA Agreement shall
not terminate until after the DAAB has given all the corresponding decisions
in accordance with the Contract.
10.3 At any time the Parties may jointly terminate the DAA Agreement by giving a
Notification of not less than 42 days to the DAAB Member.
10.4 If the DAAB Member fails, without justifiable excuse, to comply with
Sub-Clause 5.1 above, the Parties may, without prejudice to their other rights
or remedies, jointly terminate his/her DAA Agreement by giving a Notification
(by recorded delivery) to the DAAB Member. This notice shall take effect
when it is received by the DAAB Member.
10.5 If either Party fails, without justifiable excuse, to comply with Clause 6 above,
the DAAB Member may, without prejudice to his/her other rights or remedies,
terminate the DAA Agreement by giving a Notification to the Parties. This
notice shall take effect when received by both Parties.
10.6 Any resignation or termination under this Clause shall be final and binding
on the Parties and the DAAB Member. However, a notice given under
Sub-Clause 10.3 or 10.4 above by either the Employer or the Contractor,
but not by both, shall be of no effect.
10.9 Subject to any mandatory requirements under the governing law of the
DAA Agreement, termination of the DAA Agreement under this Clause shall
require no action of whatsoever kind by the Parties or the DAAB Member (as
the case may be) other than as stated in this Clause.
11
Challenge 11.1 The Parties shall not object against the DAAB Member, except that either
Party, or in the case of a three-member DAAB the Other Members jointly,
shall be entitled to do so for an alleged lack of independence or impartiality or
otherwise in which case Rule 10 Objection Procedure and Rule 11 Challenge
Procedure of the DAAB Rules shall apply.
©FIDIC 2017 Conditions of Contract for EPC/Turnkey Projects
110
11 .2 The decision issued under Rule 11 of the DAAB Rules (the "Decision on the
Challenge" in the GCs) shall be final and conclusive.
11.3 At any time before the Decision on the Challenge is issued, the challenged
DAAB Member may resign under Sub-Clause 10.1 above and, in such case,
the challenging Party shall inform the International Chamber of Commerce
(ICC). However, Sub-Clause 10.2 shall not apply to such resignation and the
resigning DAAB Member's DAA Agreement shall terminate with immediate
effect.
11.4 Unless the challenged DAAB Member has resigned, or his/her DAA
Agreement has been terminated under Sub-Clause 10.3 above, the DAAB
Member and the Other Members {if any) shall continue with the DAAB's
Activities until the Decision on the Challenge is issued.
12
Disputes under
the DAA Agreement Any dispute arising out of or in connection with the DAA Agreement, or the
breach, termination or invalidity thereof, shall be finally settled by arbitration
under the Rules of Arbitration of the International Chamber of Commerce
2017 by one arbitrator appointed in accordance with these Rules of
Arbitration, and Article 30 and the Expedited Procedure Rules at Appendix
VI of these Rules of Arbitration shall apply.
Rule2
Avoidance of 2.1 Where Sub-Clause 21 .3 [Avoidance of Disputes] of the Conditions of Contract
applies, the DAAB (in the case of a three-member DAAB, all three DAAB
Members acting together) may give Informal Assistance during discussions
at any meeting with the Parties (whether face-to-face or by telephone or by
video conference) or at any Site visit or by an informal written note to the
Parties.
3 .2 As soon as practicable after the DAAB is appointed, the DAAB shall convene a
face-to-face meeting with the Parties. At this meeting, the DAAB shall establish
a schedule of planned meetings and Site visits in consultation with the Parties,
which schedule shall reflect the requirements of Rule 3.3 below and shall be
subject to adjustment by the DAAB in consultation with the Parties.
3.3 The DAAB shall hold face-to-face meetings with the Parties, and/or visit the
Site, at regular intervals and/or at the written request of either Party. The
frequency of such meetings and/or Site visits shall be:
3.4 In addition to the face-to-face meetings referred to in Rules 3.2 and 3.3
above, the DAAB may also hold meetings with the Parties by telephone or
video conference as agreed with the.Parties (in which case each Party bears
the risk of interrupted or faulty telephone or video conference transmission
and reception).
3.6 Either Party may request an urgent meeting or Site visit by the DAAB. This
shall be a written request and shall give reasons for the urgency of the
meeting or Site visit. If the DAAB agrees that such a meeting or Site visit is
urgent, the DAAB Members shall use all reasonable endeavours to:
3. 7 The time of, and agenda for, each meeting and Site visit shall be set by the
DAAB in consultation with the Parties.
3.8 Each meeting and Site visit shall be attended by the Employer and the
Contractor.
(a) personal safety equipment, security controls (if necessary) and site
transport for each Site visit;
(b) meeting room/conference facilities and secretarial and copying
services for each face-to-face meeting; and
(c) telephone conference or video conference facilities for each meeting
by telephone or video conference.
3.10 At the conclusion of each meeting and Site visit and, if possible before leaving
the venue of the face-to-face meeting or the Site (as the case may be) but in
any event within 7 days, the DAAB shall prepare a report on its activities during
the meeting or Site visit and shall send copies of this report to the Parties.
Rule4
Communications
and Documentation 4.1 The language to be used:
(a) in all communications to and from the DAAB and the Parties (and, in
the case of a three-member DAAB, between the DAAB Members);
(b) in all reports and decisions issued by the DAAB; and
(c) during all Site visits, meetings and hearings relating to the DAAB's
Activities
4.2 All communications and/or documents sent between the DAAB and a
Party shall simultaneously be copied to the other Party. In the case of a
three-member DAAB, the sending Party shall send all communications and/
4.3 The Parties shall provide the DAAB with a copy of all documents which the
DAAB may request, including:
and any other document relevant to the performance of the Contract and/
or necessary to enable the DAAB to become and remain informed about the
matters described in sub-paragraphs (d)(i) to (d)(iii) of Sub-Clause 5.1 of the
GCs.
Rule5
Powers of the i)AAB 5.1 In addition to the powers granted to the DAAB under the Conditions of
Contract, the General Conditions of the DAA Agreement and elsewhere in
these Rules, the Parties empower the DAAB to:
6.2 The DAAB shall act fairly and impartially between the Parties and, taking due
regard of the period under Sub-Clause 21.4.3 [The DMB's decision] of the
Conditions of Contract and other relevant circumstances, the DAAB shall:
(!)
(a) give each Party a reasonable opportunity (consistent with the 10
()
expedited nature of the DAAB proceeding) of putting forward its case U ..
(a) decide on the date and place for any hearing, in consultation with the
Parties;
(b) decide on the duration of any hearing;
(c) request that written documentation and arguments from the Parties
be submitted to it prior to the hearing;
(d) adopt an inquisitorial procedure during any hearing:
(e) request the production of documents, and/or oral submissions by
the Parties, at any hearing that the DAAB considers may assist ih
exercising the DAAB's power under sub-paragraph (g) of Rule 5.1
above;
(f) request the attendance of persons at any hearing that the DAAB
considers may assist in exercising the DAAB's power under
sub-paragraph (g) of Rule 5.1 above;
(g) refuse admission to any hearing, or audience at any hearing, to
any persons other than representatives of the Employer and the
Contractor;
(h) proceed in the absence of any party who the DAAB is satisfied
received timely notice of the hearing;
(i) adjourn any hearing as and when the DAAB considers further
investigation by one Party or both Parties would benefit resolution
of the Dispute, for such time as the investigation is carried out, and
resume the hearing promptly thereafter.
7 .2 The DAAB shall not express any opinions during any hearing concerning the
merits of any arguments advanced by either Party in respect of the Dispute.
7.3 The DAAB shall not give any Informal Assistance during a hearing, but if the
Parties request Informal Assistance during any hearing:
(a) the hearing shall be adjourned for such time as the DAAB is giving
Informal Assistance;
Rule 8 ------------------------------···--···----------·---·--····-----·--·-------·-··-·-·---··-·----------·--
The DAAB's Decision 8.1 The DAAB shall make and give its decision within the time allowed under
Sub-Clause 21.4 [Obtaining DMB's Decision] of the Conditions of Contract,
or other time as may be proposed by the DAAB and agreed by the Parties in
writing.
8.3 If, after giving a decision, the DAAB finds (and, in the case of a three-member
DAAB, they agree unanimously or by majority) that the decision contained
any error:
8.4 If, within 14 days of receiving a decision from the DAAB, either Party finds
a typographical, clerical or arithmetical error in the decision, that Party may
request the DAAB to correct such error. This shall be a written request and
shall clearly identify the error.
8.5 If, within 14 days of receiving a decision from the DAAB, either Party believes
that such decision contains an ambiguity, that Party may request clarification
from the DAAB. This shall be a written request and shall clearly identify the
ambiguity.
8.7 5
If the DAAB issues an addendum to its original decision under Rule 8.3 (J
or 8.6 above, such an addendum shall form part of the decision and the
period stated in sub-paragraph (c) of Sub-Clause 21.4.4 [Dissatisfaction
with DMB's decision] of the Conditions of Contract shall be calculated from
the date the Parties receive this addendum. (f)
~
CL
Rule 9 0
!J ..
(a) the period under Sub-Clause 21.4.3 [The DMB's decision] of the
Conditions of Contract shall be temporarily suspended; and
(b) when a replacement DAAB Member is appointed in accordance
with Sub-Clause 21.1 [Constitution of the DMB] of the Conditions
of Contract, the full period under Sub-Clause 21.4.3 [The DMB's
decision] of the Conditions of Contract shall apply from the date of
this replacement DAAB Member's appointment.
9.2 In the case of a three-member DAAB and if one DAAB Member's DAA
Agreement is terminated as a result of resignation or termination under
Clause 10 of the GCs, the Other Members shall continue as members of the
DAAB except that they shall not conduct any hearing or make any decision
prior to the replacement of the DAAB Member unless otherwise agreed
jointly by the Parties and the Other Members.
Rule 10 --·-··---·-------·-------·------·-------------··-----------··----------·--·-----------·-···--------------
Challenge Procedure 10.1 The following procedure shall apply to any objection against a DAAB
Member:
(a) the objecting Party shall, within 7 days of becoming aware of the facts
and/or events giving rise to the objection, give a Notification to the
DAAB Member of its objection. This Notification shall:
(i) state that it is given under this Rule;
(ii) state the reason(s) for the objection;
(iii) substantiate the objection by setting out the facts, and describing
the events, on which the objection is based, with supporting
particulars; and
(iv) be simultaneously copied to the other Party and the Other
Members;
(b) within 7 days after receiving a notice under sub-paragraph (a) above,
the objected DAAB Member shall respond to the objecting Party.
This response shall be simultaneously copied to the other Party and
the Other Members. If no response is given by the DAAB Member
Cl
-.
Advance Payment 14.2 67 ()
·~v'
Payment 14.7 72
Payment after Termination by the Contractor 16.4 83
Payment, Currencies of 14.15 76
Payment, Delayed 14.8 72
Payment, Final 14.13 76
Payment, Interim 14.6 71
Payments, Schedule of 14.4 69
Performance Certificate 11.9 57
Performance Security 4.2 21
Samples 7.2 41
Schedule of Payments 14.4 75
Search, Contractor to 11.8 63
Security of the Site 4.21 31
Security, Performance 4.2 23
Setting Out 4.7 26
Site, Clearance of 11.11 58
Site, Contractor's Operations on 4.22 31
Site Data, Use of 4.10 28
Site Data and Items of Reference 2.5 15
Site, Right of Access to the 2.1 15
Site, Security of the 4.21 36
Staff and Labour, Engagement of 6.1 37
Staff and Labour, Facilities for 6.6 38
Statement at Completion 14.10 73
Statement, Final 14.11 74
Subcontractors 4.4 24
C1
Taking Over of Parts of the Works 10.2 53 '.:J
CJ
Taking Over the Works and Sections 10.1 52
Taking Over: Surfaces Requiring Reinstatement 10.4 59
Technical Standards and Regulations 5.4 35
Temporary Utilities 4.19 30 (fj