Clause 16
Clause 16
Summary
Sub-Clause 16.1 deals with the Contractor’s right to suspend work in the event that
the Engineer fails to certify in accordance with Sub-Clause 14.6 [Payment
Certificates] or the Employer fails to comply with Sub-Clause 2.4 [Employer’s
Financial Arrangements] or Sub-Clause 14.7 [Payment]. Prior to the Contractor
suspending work it must give 21 days’ notice. The right to suspend does not affect
the Contractor’s entitlement to terminate or claim financing charges. In the event
that the Contractor suffers delay or cost as a result of suspension it must give notice
under Sub-Clause 20.1 [Contractor’s Claims].
Sub-Clause 16.2 deals with the Termination by the Contractor. There are seven
grounds specified. In most cases the Contractor may give 14 days’ notice if it
intends to terminate the contract; however, where there has been a prolonged
suspension under Sub-Clause 8.11 [Prolonged Suspension] or, inter alia, bankruptcy,
liquidation, insolvency or receiving or administration orders have been made
against the Employer then the Contractor may by notice terminate immediately.
Sub-Clause 16.3 deals with Cessation of Work by the Contractor and Removal of
the Contractor’s Equipment. This Sub-Clause applies where the termination takes
place under Sub-Clause 15.5 [Employer’s Entitlement to Termination]; Sub-Clause
16.2 [Termination by Contractor]; or Sub-Clause 19.6 [Optional Termination,
Payment and Release].
Sub-Clause 16.4 deals with Payment on Termination. Once termination under Sub-
Clause 16.2 [Termination by Contractor] has taken effect then the Contractor is
entitled to the return of the Performance Security; payment in accordance with
Sub-Clause 19.6 [Optional Termination, Payment and Release] and loss of profit or
other loss and damage sustained by the contractor as a result of termination.
Origin of clause
Clause 16 of FIDIC 1999 had its origins in clause 69 of the FIDIC 4th edition. The right
to suspend as well as terminate was included in the 4th edition.
Cross-references
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
The Contractor has the right under the Contract to suspend in only 3 circumstances and in
each of these circumstances the right only comes into effect once the Contractor has
given notice to the Employer (note not to the Engineer). The right is then to suspend
work or reduce the rate of work.
The Sub-Clause is rather unclear on what is intended by the reduction of the rate of work.
The concept covers a wide range of changes – from a slight go slow to a virtual cessation.
Nor is it clear how proportional the reduction of the rate of work must be. If the breach
justifying the reduction is minimal can the Contractor slow to virtual crawl – or must the
breach be quite substantial in order to justify such a major reduction? In cases of
termination the courts have construed fault clauses in a commercial way so as to exclude
reliance on trivial breaches. This stems from the often followed approach of Lord
Diplock in Antaios Compania Naviera SA v Salen Rederierna AB. 1 Similarly, Akenhead
J. in the English High Court, when considering the FIDIC Red Book, stated “The parties
can not sensibly have thought (objectively) that a trivial contractual failure in itself could
lead to contractual termination.” 2 There is no reason why these principles should not be
equally applicable to suspension. A Contractor who does not act proportionately stands
the risk of being accused of being in breach of Sub-Clause 15.2 (demonstrating an
intention not to continue performance of his obligations under the contract) and facing a
termination notice from the Employer. Even if the Employer does not go this far it may
well later argue that any delay was caused not by the suspension but by the Contractor’s
unjustifiable slowing down of the Works and that there should therefore be no extension
of time.
1
[1985] AC 191 at 201D
2
Obrascon Huarte Lain SA v Her Majesty's Attorney General for Gibraltar [2014] EWHC 1028 (TCC) at
[321]
2
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
Sub-Clause 14.6 sets out the complex arrangements for certification which are the pre-
requisite for the Employer’s obligation to pay. The process is described in the
commentary on Sub-Clause 14.6. As can be seen there is plenty of scope for the
Engineer to delay issue of Interim Payment Certificates without failing to follow the
contractual procedures. The question therefore is – what is the Contractor’s position if
the Engineer fails for good reason or, at least for an arguable reason, to issue the IPC?
The right to suspend arises if the Engineer simply “fails” to issue the IPC so it may be
arguable that any failure to issue an IPC entitles the Contractor to give notice of
suspension. It would be a brave Contractor who proceeded on this basis – because
failure of the Contractor to proceed with the Works is a ground for Employer termination
under Clause 15(2)(c)(i).
However the Engineer should not delay issuing a Payment Certificate, however much he
may consider he needs more information once it is clear that the Contractor intends to
exercise his right to suspend. The Payment Certificate need be for no more than the
Engineer fairly determines to be due.
(b) If the Employer fails to comply with Sub-Clause 2.4 [Employer’s Financial
Arrangements]
As noted under Sub-Clause 2.4, there is no limit to the number of requests that a
Contractor can make under this provision, nor need the Contractor be reasonable in
making his requests. A Contractor who wishes to irritate the Employer is given a very
good opportunity to do so – because the Employer dare not ignore such requests for fear
of giving the Contractor the right to suspend or reduce the rate of work.
Sub-Clause 2.4, moreover, contains two Employer obligations; the first is to provide
reasonable evidence that financial arrangements have been made and are being
maintained that will enable the Employer to pay the Contract Price; the second is to give
detailed particulars to the Contractor if he intends to make any material change to his
financial arrangements. The consequences of the Employer being in breach of the first
provision are clear; although what amounts to reasonable evidence is a matter of fact. 3
They are not so clear in respect of the second. If, for example, the Employer has at some
stage in the Contract formed an intention to make a material change to his financial
circumstances but has failed to notify the Contractor and has then gone ahead with the
3
See NH International (Caribbean) Ltd v National Insurance Property Development Co. Ltd [2015] UKPC
37
3
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
It is unclear whether Sub-Clause 16.1 is intended to deal with this situation as it provides
that any notice of suspension or intention to reduce work is conditional on the Employer
providing reasonable evidence under Sub-Clause 2.4. In the situation described above
the Employer can never provide “reasonable evidence”. Does this mean that the
Contractor has no right to suspend or that the Employer can do nothing to prevent him
having the right to suspend? The Sub-Clause provides no clear answer.
Sub-Clause 14.7 obliges the Employer to make payments 28 days (in the case of the
advance payment) or 56 days after the Engineer receives the Statement and supporting
documents.
As explained in the discussion of Sub-Clause 14.7 this sub-clause can, potentially, prove
to be unfair to the Employer. Under Sub-Clause 14.7, the amount the Employer is
obliged to pay is that certified in the Interim or Final Payment Certificate but he is
obliged to make that payment 56 days after the Engineer receives the Statement and
supporting documents. In circumstances where the Statement and supporting documents
contain errors, which the Engineer asks the Contractor to correct before issuing the
Interim Payment Certificate, the Employer’s obligation to pay, and the Contractor’s right
to suspend, can come into effect before the Interim Payment Certificate can be issued. If
the statement is correctly completed and there is no problem with the supporting
documents but the Engineer has not certified within 56 days of receipt of the Statement
and supporting documents then, in order to avoid the Contractor taking advantage of the
right to suspend where the Engineer has still failed to certify correctly the Employer will
need to pay the full amount claimed by the Contractor in the statement. Any
overpayment can be recovered in the next interim payment.
The notice under Sub-Clause 16.1 is a clear condition precedent to the Contractor’s right
to suspend. The Contractor has no right to use a breach by the Employer which might
otherwise give rise to a right to suspend as an excuse for suspending or slowing progress
unless he has given notice as required.
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
Consequences of Notice
On the expiry of the notice the Contractor is entitled to suspend work or reduce the rate
of work as specified in the notice.
Once the notice is complied with the Contractor is required to resume work “as soon as is
reasonably practicable.” How long this will take will depend on the circumstances – the
extent of the suspension or reduction in rate, the time it has lasted for, the logistics of
resuming work and any circumstances which have occurred in the meantime.
Under Clause 17.2 the Contractor has full responsibility for the care of the Works from
the Commencement Date until the issue of the Taking-Over Certificate. During this
period the Contractor is responsible for rectifying any loss or damage at his own cost.
(See commentary on the effect of Clause 17.2 on the Contractor’s obligations under
Clause 19.2 [Force Majeure]). The consequence is that suspension under Clause 16.1
does not give the Contractor the right to abandon the Site. Indeed a failure to care for the
Works during a period of justified suspension might give the Employer the right to
terminate under Sub-Clause 15.2 (b).
Notice of Claim
In order to claim an extension of time, cost or profit the Contractor must give notice
under Sub-Clause 20.1. The time when the Contractor became aware or should have
become aware of the event or circumstance will be when the suspension or reduction in
work rate period commences. The Contractor should not be required to give notice
earlier because, although he will be aware as soon as the circumstances which give him
the right to give notice under Sub-Clause 16.1 that he might become entitled to suspend
or reduce the rate of work, he cannot be certain that such a right has come into existence
until the Employer has failed to comply with the notice.
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
When the Contractor exercises its rights under this Sub-Clause it can expect to have to
justify its position at least before a DAB and probably in arbitration. A ground for
termination which may seem clear at the time notice is given may seem not so clear once
the whole situation has been considered in the greatest detail by a tribunal, following
detailed work by lawyers for both sides. Contractors need to be cautious when using
their rights to terminate. Even though there may be a fundamental ground for terminating
it is good tactics, and reduces the risk of the process, for the Contractor to identify as
many grounds as possible under the terms of Clause 16.2.
Some grounds are clearer than others. Where the basis of termination is a matter of
opinion (for example an allegation that the Employer has failed to perform one or more
of his obligations), the risk is higher than if the ground can be objectively measured (for
example failure on the part of the Engineer to issue a Payment Certificate within the time
allowed).
A general issue which arises under this Sub-Clause is whether a breach by the Engineer
might qualify as a breach by the Employer and justify termination in those circumstances
where an Employer breach would justify termination. Under Sub-Clause 3.1 (a) the
Engineer when carrying out his duties under the Contract is “deemed to act for the
Employer.” This would seem to suggest that if the Engineer acts in a positive way in
breach of the Contract, his breach is to be treated as that of the Employer. More
commonly, however, the Contractor’s complaint against the Engineer is one of failure to
perform his obligations under the Contract – failure to certify, failure to make a
Determination fairly, failure to provide designs or other documents on time. When
failing to act as appropriate is the Engineer still carrying out his duties under the Contract
6
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
There are seven grounds for Termination by Contractor specified. Each is considered
below.
(a) the Contractor does not receive the reasonable evidence within 42 days after
giving notice under Sub-Clause 16.1 in respect of a failure to comply with Sub-
Clause 2.4 [Employers Financial Arrangements]
Sub-Clause 16.1 is a pre-requisite to the Contractor exercising its rights to suspend but is
also the pre-requisite to the Contractor exercising its rights to terminate under this
provision. The Clause was probably drafted with the thought in mind that the Contractor
would give a 21 day notice of suspension, then suspend and then, after a further 21 days
have the right to terminate. In fact there is nothing to stop the Contractor giving a 42 day
notice of suspension under Sub-Clause 16.1, then (if the required certificate is not given )
immediately giving notice of termination as well as suspending. As noted above, there is
no limit on the number of requests a contractor can make under Sub-Clause 2.4, nor any
requirement of reasonableness – thus a Contractor could use the provision to harass and
annoy an Employer to the point where he stops responding to the requests. Since Sub-
Clause 16.1 requires a minimum notice period of 21 days, a cunning Contractor who has
been looking for an excuse to terminate might decide to give the Employer 43 days notice
to provide evidence in the expectation that the Employer will wait for the last day to
provide the evidence. By the time the Employer had responded, the Contractor’s right to
terminate would have come into effect.
(b) The Engineer fails within 56 days after receiving a Statement and supporting
documents, to issue the relevant Payment Certificate
See the commentary on Sub-Clauses 14.6 and 16.1 for the problems this requirement may
cause the Employer even if the Engineer believes that he has not received all the
documentation necessary to enable him to issue a Payment Certificate.
In order to protect the Employer’s position the Engineer must not delay more than 56
days before issuing his Payment Certificate, however inadequate he believes the
justification. The Certificate need only be for the amount the Engineer fairly considers to
be due.
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
The expiry of time under Sub-Clause 14.7 for Advance Payments is 42 days after the
issuing of the Letter of Acceptance or 21 days after receipt of the required documents
(See Sub-Clause 14.7(a)). For other payments it is 56 days after the Engineer receives
the Contractor’s Statement and supporting documents.
See the commentary on Sub-Clauses 14.7 and 16.1 for comment on the possible problems
between the obligation for the Employer to receive a Payment Certificate before making
payment and the possible right of the Engineer to delay issuing such a Certificate. If the
Engineer has not issued a Payment Certificate (however right he may be in not doing so),
it may be necessary for the Employer to pay the amount demanded in the Contractor’s
Statement in order to avoid the Contractor having the right to terminate.
The final words in brackets carry a warning for the Employer. The Employer cannot
recover amounts due to him except by following the procedure set out in Sub-Clause 2.5
– i.e. giving notice of claim and then waiting for the Engineer’s Determination. If he
does recover by reducing a payment in breach of this procedure, the Contractor gains the
right to terminate.
Moreover, and more dangerously for the Employer, if the Engineer’s Determination is
later challenged before the DAB and the DAB sets it aside in whole or in part, the DAB’s
decision will be binding immediately and, until the Employer pays the balance of the
relevant IPC, the Contractor has the right to terminate. This right will apply immediately
the DAB’s decision is given.
This is a highly dangerous situation for an Employer who is aware that the Contractor is
looking for a way to escape its contractual obligations. Thus, if an Employer has made a
deduction following an Engineer’s Determination and the Contractor challenges the claim
before a DAB, the Employer needs to consider reimbursing the Contractor at least in the
interim prior to the DAB giving its decision. If the decision then goes in the Employer’s
favour it can deduct the amount due from the next following Interim Payment Certificate.
(d) The Employer substantially fails to perform his obligations under the Contract.
This provision is not the mirror image of the Employer’s right to terminate under Sub-
Clause 15.2(b) – the nearest equivalent, which instead requires the Employer to show that
the Contractor has plainly demonstrated his intention not to continue performance of his
8
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
The Sub-Clause is not entirely clear. Is the requirement that the Employer substantially
fails to perform an obligation, several obligations or all obligations?
The meaning may depend on what the adverb “substantially” qualifies. Does it qualify
only the verb “fails” or does it qualify the compound verb “fails to perform”. If the only
requirement is for the Contractor to show that the Employer has substantially failed in
one respect, then the right would come into play when the Employer had substantially
failed to meet an individual obligation. If the requirement is that the Contractor shows
that the Employer has substantially failed to perform his obligations the right to terminate
would only come into effect when the substantiality is applied to the whole package of
obligations under the Contract.
There was no equivalent provision in the 4th edition of FIDIC, so there is no experience
as to how this may be interpreted. Under the 4th edition, the equivalent provision (Clause
63.1), giving the Employer the right to terminate the Contractor, referred to persistently
or flagrantly neglecting to comply with any of his obligations under the Contract. This
has been generally interpreted as giving the right to terminate when the Contractor had
failed to perform any single obligation, though again it could be interpreted to come into
effect when the Contractor was not performing any obligations at all. Since the
interpretation of this clause has tended to recognise that persistent or flagrant failure to
comply with an individual obligation gives rise to a right to terminate, it might be
tempting to assume that the substantially in Sub-Clause 16.2(d) qualifies only “failure”,
and not “failure to perform his obligations” and would therefore apply even if there was
one substantial breach.
However it seems more likely that the provision was intended to apply only where the
Employer was effectively demonstrating that it had no intention of performing all its
obligations under the Contract, rather than one obligation under it. The following reasons
point in this direction:
• The other provisions of Sub-Clause 16.2 provide adequate reasons for termination
in most circumstances. There is no good policy reason to allow a termination for
a breach, however substantial, of what might be quite a minor contractual
obligation. For example Sub-Clause 16.2(e) (see below) would be entirely
unnecessary if Sub-Clause 16.2 allowed termination for a substantial breach of
any single obligation.
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
This is a provision which may be breached by the Engineer on the Employer’s behalf. In
this case it is very clear that a failure to meet obligations is the foundation of the right to
terminate. However it is only when he is carrying out duties or exercising authority that
the Engineer is deemed to act for the Employer under Sub-Clause 3.1. A failure by the
Engineer to act therefore probably does not entitle the Contractor to terminate.
(e) The Employer fails to comply with Sub-Clause 1.6 [Contract Agreement] or Sub-
Clause 1.7 [Assignment].
Sub-Clause 1.6 incorporates two obligations – for the Parties to enter a Contract
Agreement within 28 days after the Letter of Acceptance and for the Employer to bear
any costs of stamp duty etc.
Fortunately the Sub-Clause is easily complied with – the consequences for breach are
extraordinarily draconian. In normal circumstances the submission of a tender and the
10
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
Sub-Clause 1.7 is clear but Employers undergoing corporate reorganisation will need to
take care to ensure that no assignment takes place without the agreement of the other
party.
(g) The Employer becomes bankrupt or insolvent, goes into liquidation, has a
receiving or administration order made against him, compounds with his
creditors, or carries on business under a receiver, trustee or manager for the
benefit of his creditors, or if any act is done or event occurs which (under
applicable Laws )has a similar effect to any of these acts or events.
This is a mirror image of the equivalent provision in Sub-Clause 15.2 – see comment
under that Clause.
Once one of these events has occurred the Contractor has the right, upon giving 14 days
notice (or on a notice having an immediate effect in the case of (f) and (g)) to the
Employer, to terminate the Contract.
The language here is identical to that under Sub-Clause 15.2 and the interpretation of the
Clause will be the same.
Once the event giving rise to the right to terminate has occurred, there is nothing in the
clause which seems to prevent the Contractor holding the threat of termination over the
Employer indefinitely thereafter. Used in this way, a petty failure of compliance with
Sub-Clause 1.6 [Contract Agreement] would effectively give the Contractor a right to
terminate at will with all the financial consequences at any time thereafter. A tribunal
sympathetic to an Employer could however imply a requirement that the Contractor act
reasonably promptly or not at all unless the Employer's default was a continuing one. In
11
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
This provision applies in all those circumstances where the termination is not the result of
Contractor fault. Upon termination under Sub-Clause 15.5 [Employer’s Entitlement to
Termination]; Sub-Clause 16.2 [Termination by Contractor] or Sub-Clause 19.6
[Optional Termination, Payment and Release] the Contractor shall promptly:
“(a) cease all further work, except for such work as may have been instructed by the
Engineer for the protection of life or property or for the safety of the Works,
(b) hand over Contractor’s Documents, Plant, Materials and other work, for which
the Contractor has received payment, and
(c) remove all other Goods from the Site, except as necessary for safety, and leave
the Site.”
Under 16.3(b) the Contractor is required to hand over Contractor’s Documents, Plant,
Materials and other work, for which the Contractor has received payment. It may not be
clear what amongst these items, the Contractor has been paid for.
There should be no such problem with Plant and Materials which are defined as items
which are to be incorporated into the Permanent Works.
4
(1988) 46 BLR 19
12
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
However, if the issue of what the Contractor is required to hand over causes arguments
because of the above issues then this ought ultimately to be capable of being resolved
under Sub-Clause 16.4 or Sub-Clause 19.6 which deal with payment on termination.
However these provisions by no means deal with all payment obligations following a
termination which is not the Contractor’s fault.
Under Sub-Clause 16.3(c) the Contractor is required to remove all other Goods from the
Site, except as necessary for safety, and leave the Site. If the termination is disputed, the
Employer may seek to prevent the Contractor from removing its equipment. In such a case
the Contractor’s claim against the Employer would be one in tort for trespass to goods. In
Final Award in Case 6216 5 an ICC arbitral tribunal had to consider whether it had
jurisdiction to deal with a claim which arose out of a tort. The tribunal held that the FIDIC
dispute resolution provisions were sufficiently wide enough to allow them to resolve the
tort claim, applying English law
Under Sub-Clause 16.3(b) the Contractor will have handed over only the items for which
he has received payment. However under Sub-Clause 19.6(a) he is entitled to be paid for
work done and under Sub-Clause 19.6(b) to be paid for Plant and Materials ordered for
the Works. He is then required to hand over anything paid for by the Employer. Thus it
is possible that the Contractor will, under Sub-Clause 16.3 be required to take away
certain Plant and Materials, but under Sub-Clause 19.3, be entitled to be paid for them
5
ICC International Court of Arbitration Bulletin Vol.13, No 2, p.58
13
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
Sub-Clause 16.4 (c) requires the Employer to pay loss of profit or other loss or damage
sustained by the Contractor as a result of this termination. In this it contrasts with a
termination under Sub-Clauses 15.5 and 19.6 under which only cost is paid. From an
Employer’s point of view a termination under Sub-Clause 15.5 (which is always the
Employer’s right) or Clause 19.6 (which is possible though unlikely) or of course Sub-
Clause 15.2 will be substantially preferable to a Contractor’s termination under Clause
16.2. This may open an interesting strategy for the Employer of which the Contractor
needs to be cautious.
This issue was recently addressed by the English High Court in TSG Building Services
PLC v South Anglia Housing Ltd.6 In this case there was a clause which provided that
the parties should work together in “the spirit of trust, fairness and co-operation....within
the scope of their agreed roles, expertise and responsibilities....and in all matters
governed by the Contract they shall act reasonably.....” (Clause 1.1). It was argued that
this clause prevented one party from terminating at convenience in an unreasonable way.
The judge held that the provision of “reasonableness” did not apply to the termination at
convenience clause. The court concluded that either party could terminate for any or no
reason. The clause provided an “unconditional and unqualified right” meaning that
termination under the contract was properly effected by South Anglia with no
compensation payable to TSG Building Services. The court also found that Clause 1.1
should be interpreted narrowly to apply only to matters within the context of that clause
so that good faith did not extend to the whole contract. In countries where there is an
express statutory requirement of good faith then it may still be possible to run an
argument that an Employer faced with termination for default cannot terminate at
convenience to avoid paying to the contractor additional losses.
The type of “loss of profit or other loss or damage sustained by the Contractor” was
considered in the case NI Property Development Company Ltd v NH (International)
6
[2013] EWHC 1151 (TCC)
14
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.
‘Other loss or damage’ is a vague term which may have different meanings in different
jurisdictions. Under most common law jurisdictions they will be limited to losses which
were within the contemplation of the parties at the time the contract was entered into and
will exclude losses which are too remote. However it is likely to cover the Contractor’s
direct and indirect losses caused by the need to terminate the contract early. Payment
under Sub-Clause 16.4 is excluded from the limitation of liability provisions in Sub-
Clause 17.6 [Limitation of Liability] and payment under this Sub-Clause is not intended
to form part of the Contract Price. 8
7
(2008) High Court of Trinidad and Tobago
8
Bouygues SA & Herve Pomerleau Int. Inc v Shanghai Links Executive Community Ltd [1998] 4 HKC 206
and see Sub-Clause 14.1 [The Contract Price]
15
The content of this commentary is not legal advice. You should always consult a suitably qualified lawyer regarding a
particular legal issue or problem that you have. Please contact us if you require legal assistance.