Professional Documents
Culture Documents
Par1v1 PDF
Par1v1 PDF
BIDDING DOCUMENT
For
Procurement
Of
Works of
Construction of Works of Water Supply Production and Distribution Network Improvements
with house service connections for nonrevenue water reduction and continuous water
supply and Providing Sewer Network with House sewer connections along with
construction of Sewage Treatment Plant & Sewerage Pumping Station and all allied Works
and operation services of the entire system for 10 years at Sardarshahar (Churu).
Country: India
Preface
This Bidding Document for the Procurement of Works has been prepared by
Rajasthan Urban Infrastructure Development Project (RUIDP) and is based on the
Standard Bidding Document for the Procurement of Works (SBD Works) issued by the
Asian Development Bank dated May, 2018.
ADB’s SBD Works has the structure and the provisions of the Master Procurement
Document entitled “Bidding Documents for the Procurement of Works”, prepared by
multilateral development banks and other public international financial institutions,
except where ADB-specific considerations have required a change.
Table of Clauses
A. General .........................................................................................................................................1-5
1. Scope of Bid ............................................................................................................................1-5
2. Source of Funds ......................................................................................................................1-5
3. Fraud and Corruption ..............................................................................................................1-5
4. Eligible Bidders .......................................................................................................................1-8
5. Eligible Materials, Equipment, and Services...........................................................................1-9
(a) the term “in writing” means communicated in written form and
delivered against receipt;
(b) except where the context requires otherwise, words indicating the
singular also include the plural and words indicating the plural also
include the singular; and
(c) “day” means calendar day.
2. Source of Funds 2.1 The Borrower or Recipient (hereinafter called “Borrower”) indicated in
the BDS has applied for or received financing (hereinafter called
“funds”) from the Asian Development Bank (hereinafter called “ADB”)
toward the cost of the project named in the BDS. The Borrower intends
to apply a portion of the funds to eligible payments under the
contract(s) for which this Bidding Document is issued.
2.2 Payments by the ADB will be made only at the request of the Borrower
and upon approval by ADB in accordance with the terms and
conditions of the Financing Agreement between the Borrower and ADB
(hereinafter called “Financing Agreement”), and will be subject in all
respects to the terms and conditions of that Financing Agreement. No
party other than the Borrower shall derive any rights from the
Financing Agreement or have any claim to the funds.
3. Fraud and 3.1 ADB’s Anticorruption Policy requires Borrowers (including beneficiaries
Corruption of ADB-financed activity), as well as Bidders, Suppliers, and
Contractors under ADB-financed contracts, observe the highest
standard of ethics during the procurement and execution of such
contracts. In pursuance of this policy, ADB
(a) defines, for the purposes of this provision, the terms set forth
below as follows:
(i) “corrupt practice” means the offering, giving, receiving, or
soliciting, directly or indirectly, anything of value to influence
improperly the actions of another party;
(ii) “fraudulent practice” means any act or omission, including a
misrepresentation, that knowingly or recklessly misleads, or
attempts to mislead, a party to obtain a financial or other
benefit or to avoid an obligation;
1
Whether as a Contractor, Subcontractor, Consultant, Manufacturer or Supplier, or Service Provider; or in any other capacity
(different names are used depending on the particular Bidding Document).
(e) will have the right to require that a provision be included in bidding
documents and in contracts financed by ADB, requiring Bidders,
suppliers and contractors to permit ADB or its representative to
inspect their accounts and records and other documents relating to
the bid submission and contract performance and to have them
audited by auditors appointed by ADB.
3.2 All Bidders, consultants, contractors, suppliers, and other third parties
engaged or involved in ADB-related activities have a duty to cooperate
fully in any screening or investigation when requested by ADB to do
so. Such cooperation includes, but is not limited to, the following:
3.3 All Bidders, consultants, contractors and suppliers shall ensure that, in
its contract with its sub-consultants, sub-contractors and other third
parties engaged or involved in ADB-related activities, such sub-
consultants, sub-contractors and other third parties similarly undertake
the foregoing duty to cooperate fully in any screening or investigation
when requested by ADB to do so.
3.4 The Employer hereby puts the Bidder on notice that the Bidder or any
joint venture partner of the Bidder (if any) may not be able to receive
any payments under the Contract if the Bidder or any of its joint
venture partners, as appropriate, is, or is owned (in whole or in part) by
a person or entity subject to applicable sanctions.
3.5 Furthermore, Bidders shall be aware of the provision stated in
Subclause 1.15 and 15.6 of the Conditions of Contract.
4. Eligible Bidders 4.1 A Bidder may be a natural person, private entity, or government-owned
enterprise subject to ITB 4.5—or any combination of them with a
formal intent to enter into an agreement or under an existing
agreement in the form of a Joint Venture. In the case of a Joint
Venture,
4.2 A Bidder, and all parties constituting the Bidder, shall have the
nationality of an eligible country, in accordance with Section 5 (Eligible
Countries). A Bidder shall be deemed to have the nationality of a
country if the Bidder is a citizen or is constituted, incorporated, or
registered, and operates in conformity with the provisions of the laws of
that country. This criterion shall also apply to the determination of the
nationality of proposed subcontractors or suppliers for any part of the
Contract including related services.
4.3 A Bidder shall not have a conflict of interest. All Bidders found to have
a conflict of interest shall be disqualified. A Bidder may be considered
to be in a conflict of interest with one or more parties in the bidding
process if any of, including but not limited to, the following apply:
(a) they have controlling shareholders in common; or
(b) they receive or have received any direct or indirect subsidy from
any of them; or
(c) they have the same legal representative for purposes of this bid; or
(d) they have a relationship with each other, directly or through
common third parties, that puts them in a position to have access
to material information about or improperly influence the bid of
another Bidder, or influence the decisions of the Employer
regarding this bidding process; or
(e) a Bidder participates in more than one bid in this bidding process,
either individually or as a partner in a joint venture, except for
alternative offers permitted under ITB 13 of the Bidding Document.
This will result in the disqualification of all Bids in which it is
involved. However, subject to any finding of a conflict of interest in
terms of ITB 4.3(a)-(d) above, this does not limit the participation
of a Bidder as a Subcontractor in another Bid or of a firm as a
Subcontractor in more than one Bid; or
(f) a Bidder, joint venture partner, associates, parent company, or any
affiliated entity, participated as a Consultant in the preparation of
the design or technical specifications of the works that are the
subject of the Bid; or
(g) a Bidder was affiliated with a firm or entity that has been hired (or
is proposed to be hired) by the Employer or Borrower as Engineer
for the contract; or
(h) a Bidder would be providing goods, works, or non-consulting
4.6 A Bidder shall not be under suspension from bidding by the Employer
as the result of the execution of a Bid–Securing Declaration.
5. Eligible Materials, 5.1 The materials, equipment, and services to be supplied under the
Equipment and Contract shall have their origin in eligible source countries as defined
Services in ITB 4.2 above and all expenditures under the Contract will be limited
to such materials, equipment, and services. At the Employer’s request,
Bidders may be required to provide evidence of the origin of materials,
equipment, and services.
5.2 For purposes of ITB 5.1 above, “origin” means the place where the
materials and equipment are mined, grown, produced, or
manufactured, and from which the services are provided. Materials and
equipment are produced when, through manufacturing, processing, or
substantial or major assembling of components, a commercially
recognized product results that differs substantially in its basic
characteristics or in purpose or utility from its components.
6. Sections of 6.1 The Bidding Document consist of Parts I, II, and III, which include all
Bidding Document the sections indicated below, and should be read in conjunction with
any addenda issued in accordance with ITB 8.
6.2 The IFB issued by the Employer is not part of the Bidding Document.
6.3 The Employer is not responsible for the completeness of the Bidding
Document and their addenda, if they were not obtained directly from
the source stated by the Employer in the IFB.
6.4 The Bidder is expected to examine all instructions, forms, terms, and
specifications in the Bidding Document. Failure to furnish all
information or documentation required by the Bidding Document may
result in the rejection of the bid.
7.2 The Bidder is advised to visit and examine the Site of Works and its
surroundings and obtain for itself on its own responsibility all
information that may be necessary for preparing the Bid and entering
into a contract for construction of the Works. The costs of visiting the
Site shall be at the Bidder’s own expense.
7.3 The Bidder and any of its personnel or agents will be granted
permission by the Employer to enter its premises and lands for the
purpose of such visit, but only upon the express condition that the
Bidder, its personnel, and agents will release and indemnify the
Employer and its personnel and agents from and against all liability in
respect thereof, and will be responsible for death or personal injury,
loss of or damage to property, and any other loss, damage, costs, and
expenses incurred as a result of the inspection.
7.5 The Bidder is requested to submit any questions in writing, to reach the
Employer not later than 1 week before the meeting.
7.6 Minutes of the pre-bid meeting, including the text of the questions
raised, without identifying the source, and the responses given,
together with any responses prepared after the meeting, will be
transmitted promptly to all Bidders who have acquired the Bidding
Document in accordance with ITB 6.3. Any modification to the Bidding
Document that may become necessary as a result of the pre-bid
meeting shall be made by the Employer exclusively through the issue
of an addendum pursuant to ITB 8 and not through the minutes of the
pre-bid meeting.
8. Amendment of 8.1 At any time prior to the deadline for submission of Bids, the Employer
Bidding Document may amend the Bidding Document by issuing addenda.
8.2 Any addendum issued shall be part of the Bidding Document and shall
be communicated in writing to all who have obtained the Bidding
Document from the Employer in accordance with ITB 6.3.
C. Preparation of Bids
9. Cost of Bidding 9.1 The Bidder shall bear all costs associated with the preparation and
submission of its Bid, and the Employer shall in no case be responsible
or liable for those costs, regardless of the conduct or outcome of the
bidding process.
10. Language of Bid 10.1 The Bid, as well as all correspondence and documents relating to the
bid exchanged by the Bidder and the Employer, shall be written in the
language specified in the BDS. Supporting documents and printed
literature that are part of the Bid may be in another language provided
they are accompanied by an accurate translation of the relevant
passages in the language specified in the BDS, in which case, for
purposes of interpretation of the Bid, such translation shall govern.
11. Documents 11.1 The Bid shall comprise two envelopes submitted simultaneously, one
Comprising the called the Technical Bid containing the documents listed in ITB 11.2
Bid and the other the Price Bid containing the documents listed in ITB
11.3, both envelopes enclosed together in an outer single envelope.
12. Letters of Bid and 12.1 The Letters of Technical Bid and Price Bid, and the Schedules,
Schedules including the Bill of Quantities, shall be prepared using the relevant
forms furnished in Section 4 (Bidding Forms). The forms must be
completed without any alterations to the text, and no substitutes shall
be accepted. All blank spaces shall be filled in with the information
requested and as required in the BDS.
13. Alternative Bids 13.1 Unless otherwise indicated in the BDS, alternative Bids shall not be
considered.
13.2 When alternative times for completion are explicitly invited, a statement
to that effect will be included in the BDS, as will the method of
evaluating different times for completion.
13.3 Except as provided under ITB 13.4 below, Bidders wishing to offer
technical alternatives to the requirements of the Bidding Document
must first price the Employer’s design as described in the Bidding
Document and shall further provide all information necessary for a
13.4 When specified in the BDS, Bidders are permitted to submit alternative
technical solutions for specified parts of the Works. Such parts will be
identified in the BDS and described in Section 6 (Employer’s
Requirements). The method for their evaluation will be stipulated in
Section 3 (Evaluation and Qualification Criteria).
14. Bid Prices and 14.1 The prices and discounts quoted by the Bidder in the Letter of Price
Discounts Bid and in the Bill of Quantities shall conform to the requirements
specified below.
14.2 The Bidder shall fill in rates and prices for all items of the Works
described in the Bill of Quantities. Items against which no rate or price
is entered by the Bidder will not be paid for by the Employer when
executed and shall be deemed covered by the rates for other items
and prices in the Bill of Quantities.
14.3 The price to be quoted in the Letter of Price Bid, in accordance with
ITB 12.1, shall be the total price of the Bid, excluding any discounts
offered. Absence of the total bid price in the Letter of Price Bid may
result in the rejection of the Bid.
14.4 The Bidder shall quote any discounts and the methodology for their
application in the Letter of Price Bid, in accordance with ITB 12.1.
14.5 The prices shall be either fixed or adjustable as specified in the BDS.
(a) In the case of Fixed Price, prices quoted by the Bidder shall be
fixed during the Bidder’s performance of the contract and not
subject to variation on any account. A Bid submitted with an
adjustable price will be treated as nonresponsive and rejected.
(b) In the case of Adjustable Price, prices quoted by the Bidder shall
be subject to adjustment during performance of the contract to
reflect changes in the cost elements such as labor, material,
transport, and contractor’s equipment in accordance with the
provisions of the Conditions of Contract. A Bid submitted with a
fixed price will be treated as non-responsive and be rejected. The
Bidder shall furnish the indexes and weightings for the price
adjustment formulas in the Tables of Adjustment Data included in
Section 4 (Bidding Forms) and the Employer may require the
Bidder to justify its proposed indexes and weightings. Any bid that
omits indexes and weightings shall be subject to clarification with
the Bidder.
14.6 If so indicated in ITB 1.1, bids are being invited for individual contracts
or for any combination of contracts (packages). Bidders wishing to
offer any price reduction for the award of more than one Contract shall
specify in their bid the price reductions applicable to each package, or
14.7 All duties, taxes, and other levies payable by the Contractor under the
Contract, or for any other cause, as of the date 28 days prior to the
deadline for submission of bids, shall be included in the rates and
prices and the total Bid Price submitted by the Bidder.
15. Currencies of Bid 15.1 The unit rates and the prices shall be quoted by the Bidder entirely in
and Payment the currency specified in the BDS.
15.2 Bidders shall indicate the portion of the bid price that corresponds to
expenditures incurred in the currency of the Employer’s country in the
Schedule of Payment Currencies included in Section 4 (Bidding
Forms).
15.7 Bidders should note that during the progress of the Works, the foreign
currency requirements of the outstanding balance of the Contract Price
may be adjusted by agreement between the Employer and the
Contractor in order to reflect any changes in foreign currency
requirements for the Contract, in accordance with Subclause 14.15 of
the Conditions of Contract. Any such adjustment shall be effected by
comparing the percentages quoted in the bid with the amounts already
used in the Works and the Contractor's future needs for imported
items.
16. Documents 16.1 The Bidder shall furnish a Technical Proposal including a statement of
Comprising the work methods, equipment, personnel, schedule, and any other
Technical information as stipulated in Section 4 (Bidding Forms), in sufficient
Proposal detail to demonstrate the adequacy of the Bidders’ proposal to meet
the work requirements and the completion time.
17. Documents 17.1 To establish its qualifications to perform the Contract in accordance
Establishing the with Section 3 (Evaluation and Qualification Criteria) the Bidder shall
Qualifications of provide the information requested in the corresponding information
the Bidder sheets included in Section 4 (Bidding Forms).
18. Period of Validity 18.1 Bids shall remain valid for the period specified in the BDS after the bid
of Bids submission deadline date prescribed by the Employer. A bid valid for a
shorter period shall be rejected by the Employer as nonresponsive.
19. Bid Security/Bid- 19.1 Unless otherwise specified in the BDS, the Bidder shall furnish as part
Securing of its Bid, in original form, either a Bid-Securing Declaration or a bid
Declaration security as specified in the BDS. In the case of a bid security, the
amount and currency shall be as specified in the BDS.
is executed.
19.3 If a bid security is specified pursuant to ITB 19.1, the bid security shall
be, at the Bidder’s option, in any of the following forms:
19.4 Unless otherwise specified in the BDS, any Bid not accompanied by a
substantially compliant bid security or Bid-Securing Declaration, if one
is required in accordance with ITB 19.1, shall be rejected by the
Employer as nonresponsive.
19.5 If a bid security is specified pursuant to ITB 19.1, the bid security of
unsuccessful Bidders shall be returned promptly upon the successful
Bidder’s furnishing of the performance security pursuant to ITB 45.
19.6 If a bid security is specified pursuant to ITB 19.1, the bid security of the
successful Bidder shall be returned promptly once the successful
Bidder has signed the Contract and furnished the required
performance security.
19.7 The bid security may be forfeited or the Bid Securing Declaration
executed,
(a) if notwithstanding ITB 24.3, a Bidder withdraws its bid during the
period of bid validity specified by the Bidder on the Letters of
Technical Bid and Price Bid, except as provided in ITB 18.2; or
(b) if the successful Bidder fails to
(i) sign the Contract in accordance with ITB 44;
(ii) furnish a performance security in accordance with ITB 45;
(iii) accept the arithmetical correction of its Bid in accordance with
ITB 34; or
(iv) furnish a domestic preference security, if so required.
19.8 If the bid security is required as per ITB 19.1, the bid security of a Joint
Venture shall be in the name of the Joint Venture that submits the Bid.
If the Joint Venture has not been legally constituted at the time of
bidding, the bid security shall be in the name of any or all of the Joint
Venture partners. If the Bid-Securing Declaration is required as per ITB
20. Format and 20.1 The Bidder shall prepare one original set of the Technical Bid and one
Signing of Bid original set of the Price Bid comprising the Bid as described in ITB 11
and clearly mark it “ORIGINAL - TECHNICAL BID” and “ORIGINAL -
PRICE BID.” Alternative Bids, if permitted in accordance with ITB 13,
shall be clearly marked “ALTERNATIVE.” In addition, the Bidder shall
submit copies of the Technical and Price Bids, in the number specified
in the BDS, and clearly mark each of them “COPY.” In the event of any
discrepancy between the original and the copies, the original shall
prevail.
20.2 The original and all copies of the Bid shall be typed or written in
indelible ink and shall be signed by a person duly authorized to sign on
behalf of the Bidder. This authorization shall consist of a written
confirmation as specified in the BDS and shall be attached to the bid.
The name and position held by each person signing the authorization
must be typed or printed below the signature. If a Bidder submits a
deficient authorization, the Bid shall not be rejected in the first
instance. The Employer shall request the Bidder to submit an
acceptable authorization within the number of days as specified in the
BDS. Failure to provide an acceptable authorization within the
prescribed period of receiving such a request shall cause the rejection
of the Bid. If either the Letter of Technical Bid or Letter of Price Bid or
Bid-Securing Declaration (if applicable) are not signed, the Bid shall be
rejected.
21.3 The outer envelopes and the inner envelopes containing the Technical
Bid shall bear a warning not to open before the time and date for the
opening of Technical Bid, in accordance with ITB 25.1.
21.4 The inner envelopes containing the Price Bid shall bear a warning not
to open until advised by the Employer in accordance with ITB 25.7.
21.5 If all envelopes are not sealed and marked as required, the Employer
will assume no responsibility for the misplacement or premature
opening of the Bid.
22. Deadline for 22.1 Bids must be received by the Employer at the address and no later
Submission of than the date and time indicated in the BDS.
Bids
22.2 The Employer may, at its discretion, extend the deadline for the
submission of Bids by amending the Bidding Document in accordance
with ITB 8, in which case all rights and obligations of the Employer and
Bidders previously subject to the deadline shall thereafter be subject to
the deadline as extended.
23. Late Bids 23.1 The Employer shall not consider any Bid that arrives after the deadline
for submission of bids, in accordance with ITB 22. Any bid received by
the Employer after the deadline for submission of Bids shall be
declared late, rejected, and returned unopened to the Bidder.
24. Withdrawal, 24.1 A Bidder may withdraw, substitute, or modify its Bid – Technical or
Substitution, and Price – after it has been submitted by sending a written notice, duly
Modification of signed by an authorized representative, and shall include a copy of the
Bids authorization in accordance with ITB 20.2, (except that withdrawal
notices do not require copies). The corresponding substitution or
modification of the Bid must accompany the respective written notice.
All notices must be
25. Bid Opening 25.1 The Employer shall open the Technical Bids in public at the address,
on the date and time specified in the BDS in the presence of Bidders`
designated representatives and anyone who chooses to attend. Any
specific electronic bid opening procedures required if electronic bidding
is permitted in accordance with ITB 21.1, shall be as specified in the
BDS. The Price Bids will remain unopened and will be held in custody
of the Employer until the specified time of their opening. If the
Technical Bid and the Price Bid are submitted together in one
envelope, the Employer may reject the entire Bid. Alternatively, the
Price Bid may be immediately resealed for later evaluation.
25.5 All other envelopes holding the Technical Bids shall be opened one at
a time, and the following read out and recorded:
Only Technical Bids and alternative Technical Bids read out and
recorded at bid opening shall be considered for evaluation. Unless
otherwise specified in the BDS, all pages of the Letter of Technical Bid
are to be initialed by at least three representatives of the Employer
25.6 The Employer shall prepare a record of the opening of Technical Bids
that shall include, as a minimum, the name of the Bidder and whether
there is a withdrawal, substitution, or modification; alternative
proposals; and the presence or absence of a bid security or Bid-
Securing Declaration, if one was required. The Bidders’
representatives who are present shall be requested to sign the record.
The omission of a Bidder’s signature on the record shall not invalidate
the contents and effect of the record. A copy of the record shall be
distributed to all Bidders who submitted Bids on time, and posted
online when electronic bidding is permitted.
25.7 At the end of the evaluation of the Technical Bids, the Employer will
invite bidders who have submitted substantially responsive Technical
Bids and who have been determined as being qualified for award to
attend the opening of the Price Bids. The date, time, and location of
the opening of Price Bids will be advised in writing by the Employer.
Bidders shall be given reasonable notice of the opening of Price Bids.
25.8 The Employer will notify Bidders in writing who have been rejected on
the grounds of their Technical Bids being substantially nonresponsive
to the requirements of the Bidding Document and return their Price
Bids unopened.
25.9 The Employer shall conduct the opening of Price Bids of all Bidders
who submitted substantially responsive Technical Bids, in the
presence of Bidders` representatives who choose to attend at the
address, on the date, and time specified by the Employer. The Bidder’s
representatives who are present shall be requested to sign a register
evidencing their attendance.
25.10All envelopes containing Price Bids shall be opened one at a time and
the following read out and recorded:
Only Price Bids discounts, and alternative offers read out and
recorded during the opening of Price Bids shall be considered for
evaluation. Unless otherwise specified in the BDS, all pages of the
Letter of Price Bid and Bill of Quantities are to be initialed by at least
three representatives of the Employer attending bid opening. No Bid
shall be rejected at the opening of Price Bids.
25.11The Employer shall prepare a record of the opening of Price Bids that
shall include, as a minimum, the name of the Bidder, the Bid Price (per
lot if applicable), any discounts, and alternative offers. The Bidders’
representatives who are present shall be requested to sign the record.
The omission of a Bidder’s signature on the record shall not invalidate
the contents and effect of the record. A copy of the record shall be
26. Confidentiality 26.1 Information relating to the examination, evaluation, comparison, and
postqualification of Bids and recommendation of contract award, shall
not be disclosed to Bidders or any other persons not officially
concerned with such process until information on the Contract award is
communicated to all Bidders.
26.3 Notwithstanding ITB 26.2, from the time of bid opening to the time of
Contract award, if any Bidder wishes to contact the Employer on any
matter related to the bidding process, it may do so in writing.
27. Clarification of 27.1 To assist in the examination, evaluation, and comparison of the
Bids Technical and Price Bids, the Employer may, at its discretion, ask any
Bidder for a clarification of its Bid. Any clarification submitted by a
Bidder that is not in response to a request by the Employer shall not be
considered. The Employer’s request for clarification and the response
shall be in writing. No change in the substance of the Technical Bid or
prices in the Price Bid shall be sought, offered, or permitted, except to
confirm the correction of arithmetic errors discovered by the Employer
in the evaluation of the Price Bids, in accordance with ITB 33.
27.2 If a Bidder does not provide clarifications of its Bid by the date and time
set in the Employer’s request for clarification, its Bid may be rejected.
28. Deviations, 28.1 During the evaluation of Bids, the following definitions apply:
Reservations, and
Omissions (a) “Deviation” is a departure from the requirements specified in the
Bidding Document;
(b) “Reservation” is the setting of limiting conditions or withholding
from complete acceptance of the requirements specified in the
Bidding Document; and
(c) “Omission” is the failure to submit part or all of the information or
documentation required in the Bidding Document.
29. Examination 29.1 The Employer shall examine the Technical Bid to confirm that all
of Technical Bids documents and technical documentation requested in ITB 11.2 have
been provided, and to determine the completeness of each document
submitted.
29.2 The Employer shall confirm that the following documents and
information have been provided in the Technical Bid. If any of these
documents or information is missing, the offer shall be rejected.
30.3 The Employer shall examine the technical aspects of the Bid submitted
in accordance with ITB 16, Technical Proposal, in particular, to confirm
that all requirements of Section 6 (Employer’s Requirements) have
been met without any material deviation, reservation, or reservation.
31. Nonmaterial 31.1 Provided that a Bid is substantially responsive, the Employer may
Nonconformities waive any nonconformities in the Bid that do not constitute a material
deviation, reservation, or omission.
32. Qualification of 32.1 The Employer shall determine to its satisfaction during the evaluation
the Bidder of Technical Bids whether Bidders meet the qualifying criteria specified
in Section 3 (Evaluation and Qualification Criteria).
33. Subcontractors 33.1 Unless otherwise stated in the BDS, the Employer does not intend for
the contractor to execute any specific elements of the Works through
nominated subcontractors.
33.2 If subcontractors are proposed for any of the key activities listed in
Section 3 – Evaluation and Qualification Criteria 2.4.2, they shall be
considered as “Specialist Subcontractors” and shall meet qualification
requirements for the relevant key activities.
34. Correction of 34.1 During the evaluation of Price Bids, the Employer shall correct
Arithmetical arithmetical errors on the following basis:
Errors
(a) If there is a discrepancy between the unit price and the total price
that is obtained by multiplying the unit price and quantity, the unit
price shall prevail and the total price shall be corrected, unless in
the opinion of the Employer there is an obvious misplacement of
the decimal point in the unit price, in which case the total price as
quoted shall govern and the unit price shall be corrected.
(b) If there is an error in a total corresponding to the addition or
subtraction of subtotals, the subtotals shall prevail and the total
shall be corrected.
(c) If there is a discrepancy between the bid price in the Summary of
Bill of Quantities and the bid amount in item (c) of the Letter of
Price Bid, the bid price in the Summary of Bill of Quantities will
prevail and the bid amount in item (c) of the Letter of Price Bid will
be corrected.
(d) If there is a discrepancy between words and figures, the amount in
words shall prevail, unless the amount expressed in words is
related to an arithmetic error, in which case the amount in figures
shall prevail subject to (a), (b) and (c) above.
34.2 If the Bidder that submitted the lowest evaluated bid does not accept
the correction of errors, its Bid shall be disqualified and its bid security
35. Conversion to 35.1 For evaluation and comparison purposes, the currency(ies) of the Bid
Single Currency shall be converted into a single currency as specified in the BDS.
36. Domestic 36.1 Unless otherwise specified in the BDS, domestic preference shall not
Preference apply.
37. Evaluation and 37.1 The Employer shall use the criteria and methodologies listed in this
Comparison of Clause. No other evaluation criteria or methodologies shall be
Price Bids permitted.
37.2 To evaluate the Price Bid, the Employer shall consider the following:
(a) the bid price, excluding Provisional Sums and the provision, if any,
for contingencies in the Summary Bill of Quantities, but including
Daywork items, where priced competitively;
(b) price adjustment for correction of arithmetic errors in accordance
with ITB 34.1;
(c) price adjustment due to discounts offered in accordance with ITB
14.4;
(d) converting the amount resulting from applying (a) to (c) above, if
relevant, to a single currency in accordance with ITB 35;
(e) adjustment for nonmaterial nonconformities in accordance with ITB
31.3;
(f) assessment whether the bid is abnormally low in accordance with
ITB 38; and
(g) application of all the evaluation factors indicated in Section 3
(Evaluation and Qualification Criteria).
38. Abnormally Low 38.1 An abnormally low bid is one where the bid price, in combination with
bids other elements of the bid, appears to be so low that it raises concerns as
to the capability of the Bidder to perform the contract for the offered bid
price.
38.2 When the offered bid price appears to be abnormally low, the
Employer shall undertake a three-step review process as follows:
(a) identify abnormally low costs and unit rates by comparing them
38.4 After examining the explanation given and the detailed the price
analyses presented by the bidder, the Employer may:
(a) accept the bid, if the evidence provided satisfactorily accounts for
the low bid price and costs, in which case the bid is not considered
abnormally low;
(b) accept the bid, but require that the amount of the performance
security be increased at the expense of the bidder to a level
sufficient to protect the Employer against financial loss. The
amount of the performance security shall generally be not more
than 20% of the contract price; or
(c) reject the bid if the evidence provided does not satisfactorily
account for the low bid price, and make a similar determination for
the next ranked bid, if required.
39. Unbalanced or 39.1 If the Bid, which results in the lowest evaluated Bid Price, is seriously
Front-Loaded Bids unbalanced or front loaded in the opinion of the Employer, the
Employer may require the Bidder to produce detailed price analyses
for any or all items of the Bill of Quantities, to demonstrate the internal
consistency of those prices with the construction methods and
schedule proposed, as well as the pricing and sources of materials,
equipment and labor.
39.2 After the evaluation of the information and detailed price analyses
presented by the Bidder, the Employer may as appropriate:
40. Employer’s Right 40.1 The Employer reserves the right to accept or reject any Bid, and to
to Accept Any Bid, annul the bidding process and reject all Bids at any time prior to
and to Reject Any contract award, without thereby incurring any liability to Bidders. In
or All Bids case of annulment, all Bids submitted and specifically, bid securities,
shall be promptly returned to the Bidders.
41. Notice of Intention 41.1 If Standstill provisions apply as specified in the BDS, the standstill
for Award of period shall be defined in the BDS to specify the duration subsequent
Contract to notification of intention for award of contract (before making the
actual contract award) within which any unsuccessful bidder can
challenge the proposed award.
F. Award of Contract
42. Award Criteria 42.1 The Employer shall award the Contract to the Bidder whose offer has
been determined in line with ITB 37 to 39 above to be the lowest
evaluated Bid and is substantially responsive to the Bidding Document,
provided further that the Bidder is determined to be qualified to perform
the Contract satisfactorily.
43. Notification of 43.1 Prior to the expiration of the period of bid validity and upon expiry of
Award the standstill period specified in ITB 41.1, or upon satisfactory
resolution of a complaint filed within standstill period, if applicable, the
Employer shall transmit the Notification of Award (using the form
included in Section 9 (Contract Forms)) to the successful Bidder, in
writing, that its Bid has been accepted.
44. Signing of 44.1 Promptly after notification, the Employer shall send the successful
Contract Bidder the Contract Agreement.
45. Performance 45.1 Within 28 days of the receipt of notification of award from the
Security Employer, the successful Bidder shall furnish the performance security
in accordance with the conditions of contract, subject to ITB 38 and 39,
using for that purpose the Performance Security Form included in
Section 9 (Contract Forms), or another form acceptable to the
Employer. If the institution issuing the performance security is located
outside the country of the employer, it shall have a correspondent
financial institution located in the country of the employer to make it
enforceable.
45.3 The above provision shall also apply to the furnishing of a domestic
preference security if so required.
46. Bidding-Related 46.1 The procedures for dealing with Bidding-related Complaints arising out
Complaints of this bidding process are specified in the BDS.
A. General
ITB 1.1 The number of the Invitation for Bids (IFB) is: RSTDIP/OCB/08
ITB 1.1 The Employer is: Executing Agency, the Local Self Government Department
of the State of Rajasthan. The authorized representative of the Employer is
Project Director, Rajasthan Urban Infrastructure Development Project or its
successor agency.
The name of the open competitive bidding (OCB): Water supply and sewerage
ITB 1.1 works:
(viii) The complete Bidding Document can be viewed/ downloaded by the Bidder
from the e-procurement website. Bidders are required to download, print, fill-up,
sign and scan the bidding forms (Section 4), for upload in the relevant envelopes
in the above website. (As indicated in ITB Clause 12.1 the forms must be
completed without any alteration to the text and no substitute shall be accepted.)
(ix) In regard to addendum or addenda, the onus is on the bidder to download and
understand the addendum or addenda issued by the Employer through the above
e-procurement website. The Employer should not be faulted for bidder’s failure to
download the addendum or addenda.
(x) To participate in e-bidding, Bidders have to pay a non-refundable document
and processing fee of INR 10,000 (USD 315 or equivalent) through demand draft
(DD) issued in favor of the Project Director, RUIDP and INR 1000 (or equivalent
US$) in favour of MD, RISL, both payble at Jaipur.
(xi) Only those bids that are marked by the system as submitted, as acknowledged
with bid submission reference, will be considered for opening.
ITB 2.1 The name of the Project is: Rajasthan Secondary Town Development
Investment Program (RSTDIP)
Part 2 is for Price Bid which includes Price Bid form, Preamble to Bill of Quantities
and Bill of Quantities.
ITB 6.3 The Bidding Document, its addenda and other documents and information arising
out of or related to the requirements of the Bidding Document will be posted on e-
procurement website (www.eproc.rajasthan.gov.in).
ITB 7.1 For clarifications, bidder will submit the written queries to RUIDP through email,
fax, courier or deliver personally. Written response to queries will be published on
e-proc website.
For clarification purposes only, the Employer’s address is:
Attention: Addl. Project Director,
Rajasthan Urban Infrastructure Development Project,
AVS Building, 1st Floor, Jawahar Circle,
JLN Marg, Malviya Nagar,
JAIPUR – 302017,
Country: India.
Telephone: +91 141 2548404.
Fax: +91 141 2721919
A pre-bid meeting shall take place at the following date, time, and location:
ITB 7.4
Date : 26 March, 2019
Time: 15:00 hrs.
Place: Conference hall,
Rajasthan Urban Infrastructure Development Project,
AVS Building, 1st Floor, Jawahar Circle,
JLN Marg, Malviya Nagar,
JAIPUR – 302017,
Country: India.
Telephone: +91 141 2548404.
Bidders are advised to either attend the pre-bid meeting, or to submit their queries
by fax letter to Project Director or by e-mail to [email protected] or
[email protected] . There will be no online pre-bid meeting.
A site visit shall be organized by the Employer at the following date, time:
Date : 27 March, 2019
Time: 12:00hrs
Meeting point in the town will be informed to the bidders.
ITB 7.6 The Employer shall publish the Minutes of the Meeting at the Employer’s tender
website (e-proc) indicated in ITB 1.2 of the BDS
The Employer shall publish the Addendum or addenda at the Employer’s website
(e-proc) indicated in ITB 1.2 of the BDS.
The Employer should not be faulted for bidder’s failure to download the
addendum or addenda.
C. Preparation of Bids
ITB 12.1 The letter of Technical Bid, Price Bid and Bid forms furnished in section 4 shall be
downloaded, typed or written in indelible ink, signed by a person duly authorized
to sign on behalf of the Bidder, scan and then uploaded on e-proc website. The
BOQ template must not be modified/replaced by the bidder and the same should
be uploaded after filling the relevant columns, else the bidder is liable to be
rejected for that tender. Bidders are allowed to enter the Bidder Name and Values
only.
ITB 13.4 Alternative technical solutions shall be permitted for the following parts of the
Works: None
Unit rates and prices for all items of the Works described in the Bill of Quantities
shall be expressed in positive values. If unit rates and prices are expressed in
negative values, the bid will be rejected.
the Contractor.
Government of India has issued amendment in notifications. Entire clause will be
read along with recent Notification No. 10/2017 – Central Excise dated 30th June,
17; Notification No. 44/2017 – Customs dated 30th June, 2017 and Notification
No. 16/2017 – Central tax (rate) dated 28th June 2017.
Government has introduced Goods and Service Tax (GST). Bidders will take into
account the impact of GST on works in their bid price.
The unit rate and the prices shall be quoted by the bidder entirely in currency of
ITB 15.1
the Employer’s country (i.e. Indian Rupees (INR))
The rates of exchange shall be the selling rates 28 days prior to the deadline for
ITB 15.4
submission of bids published by Reserve Bank of India.
The bid validity period shall be 150 (One hundred fifty) days.
ITB 18.1
A bid security shall be required. Bid securing declaration shall not be accepted.
ITB 19.1
Amount and currency of bid security shall be: INR 30 million as a part of the bid
in its original form.
validity, or (ii) does not provide sufficient identification of the Bidder (including,
without limitation, failure to indicate the name of the Joint Venture or, where the
Joint Venture has not yet been constituted, the names of all future Joint Venture
Partners), the Employer shall request the Bidder to submit a compliant bid
security within fifteen (15) days of receiving such a request. Failure to provide a
compliant bid security within the prescribed period of receiving such a request
shall cause the rejection of the Bid.
Bidders should login to the website using their User ID and password
The Bidders must submit bids online following the instructions appearing on the
screen. Detailed guidelines for e-procurement are also available on the e-
procurement portal on www.eproc.rajasthan.gov.in.
here is no limit on the size of the file uploaded at the server end. However, the
upload is decided on the Memory available at the Client System as well as the
Network bandwidth available at the client side at that point of time. In order to
reduce the file size, bidders are suggested to scan the documents in 75-100 DPI
so that the clarity is maintained and also the size of file also gets reduced. This
will help in quick uploading even at very low bandwidth speeds.
The bidders are advised to download the BOQ excel sheets from the portal and
fill their rates in excel sheet. Bidder shall not modify the BOQ like Item
Description, quantity, etc and should not rename the excel sheet.
The downloaded Bid forms shall be typed or written in indelible ink and shall
be signed by a person duly authorized to sign on behalf of the Bidder
For documents related to Price Bid, Bidders shall take due precaution to upload
Technical Bid documents and Price Bid documents onto the separate envelopes
defined in the e-procurement website, on or before the deadline for Bid
submission specified in ITB 22.1 of the BDS. (The system will automatically lock
the tender and disallow bid submission after the deadline for submission of bids.)
It is important to note that, the bidder has to Click on the Freeze Bid Button, to
ensure that he/she completes the Bid Submission Process. Bids Which are not
Frozen are considered as Incomplete/Invalid bids and are not considered for
evaluation purposes.
The bidder should see that the bid documents submitted should be free from virus
and if the documents could not be opened, due to virus, during tender opening,
the bid is liable to be rejected.
Bidders shall upload their bids in formats, which can be opened and read by open
standard interfaces.
Bidders shall not lock electronic files uploaded in their proposal with passwords of
their choice. The Employer reserves the right to reject password locked files
outright
Employer shall not accept any responsibility for failures or breakdowns for
systems other than in those systems strictly within the control of Employer and its
e-Procurement service provider. However, a helpline center is provided to help
the bidders by the e-Procurement service provider.
Bidders shall take due care to ensure purchase of Digital Signature Certificates
requisite for tender submission in the e-Procurement portal, availability of internet
connectivity and requisite client software.
(ii) Technical bid shall be submitted in Envelope “A” and Envelope “B” and shall
comprise the following:
Envelope “A” - Bidder shall upload scanned copies of the following:
Letter of Technical Bid
Power of Attorney in original duly attested by Notary. In case of
partnership firm / limited company / group of companies, a power of
attorney for the person authorised to sign shall be issued by all the
partners.
Cost of Bid document in form of Demand Draft (DD) for INR 10,000/-
(USD 315 or equivalent) issued in favor of Project Director, RUIDP,
payable at Jaipur and RISL Fee in form of DD for Rs. 1000/- (or
At same date and time of the on-line submission, the originals of documents to be
submitted in envelope “A”, as described in ITB 11.2, are to be submitted manually
in a sealed envelope (marked “ORIGINAL – SUPPORTING DOCUMENTS OF
BID” shall bear the name and address of the Bidder; be addressed to the
Employer in accordance with ITB 22.1; and bearing the specific identification of
this bidding process indicated in the ITB 1.1)
(iv) Submission of Price Bids. Digitally signed, scanned copies of the Price Bid,
in accordance with ITB 11.3, shall be uploaded in the relevant envelope in the
Employer’s website indicated in ITB 1.2 of the BDS.
ITB 21.4
Clause not applicable.
their bids by logging at the eproc website indicated in ITB 1.2 of the BDS, no later
than the deadline for submission of bid, as indicated in ITB 22.1.
Add the following at the end of sub clause
ITB 24.3
Bids withdrawn in accordance with above procedure shall remain encrypted.
ITB 25.1 Delete ITB 25.1, 25.2, 25.3, 25.4 and 25.5 and replace with the following:
2. The Employer shall open the Technical Bids, online, in public at the
address, on the date, and time specified above, in the presence of Bidder’s
authorized / designated representatives and anyone who choose to attend. Also,
Bidders has the option to view, online, the status of the bid opening at the
Employer’s website indicated in ITB 1.2 of the BDS. After opening of Technical
Bids, Bidders also has the option to view the bid documents of their competitors
online from their respective logins under the link “(Bid Opening) Live”. Documents
uploaded by Bidders during bid submission under the non-statutory link cannot be
viewed by their competitors. Bidders are hereby informed to load sensitive
documents under the non-statutory link.
5. The Price Bids will remain unopened and encrypted in the Employer’s
website indicated in ITB 1.2 of the BDS, until the specified time of their opening.
6. On-line opening of the Price Bids shall follow the procedures provided in
ITB Clauses 25.9, 25.10, and 25.11.
If the Technical Bid and the Price Bid are submitted together in the same on-line
folder, the Employer will reject the entire Bid.
The Letter of Technical Bid shall be initialed by Authorized representatives of the
ITB 25.5
Employer attending Bid opening.
The Letter of Price Bid and Bill of Quantifies shall be initialed by at least 2
ITB 25.10
representative of the Employer attending Bid opening
The currency that shall be used for bid evaluation and comparison purposes to
ITB 35.1
convert all bid prices expressed in various currencies into a single currency is:
Indian Rupee
The source of the selling exchange rate shall be: Reserve Bank of India
The date for the selling exchange rate shall be: 28 days prior to bid submission
deadline.
ITB 41.1 Standstill provisions shall apply. The duration of standstill period will be 15 days
from the date of notice of intention for award of contract.
The Employer shall, at the start of the standstill period, notify in writing each
bidder that submitted a bid, of its intention to award a contract to the successful
bidder at the end of standstill period. The notification (using the form included in
Section 9 (Contract Forms)) shall include the following information:
(c) the name and evaluated prices of each Bid that was evaluated;
(d) the name of bidders whose bids were rejected and the reasons for their
rejection;
(e) the name of the winning Bidder, and the price it offered, as well as the
duration and summary scope of the contract awarded; and
(f) a statement of the reason(s) the bid of the unsuccessful bidder to whom the
notification is addressed was unsuccessful, unless the price information under
(e) of this paragraph already reveals the reason.
F. Award of Contracts
insert the following as instruction on the publication of contract award.
ITB 43.4 The Employer shall publish the Contract Award Notice at the Employer’s
website indicated in ITB 1.2 of the BDS
ITB 46.1 The procedures for Bidding-related Complaints are referenced in the
“Procurement Regulations for ADB Borrowers (Appendix 7).” The Bidder should
submit its complaint following these procedures, in writing, to:
Table of Criteria
2. Qualification......................................................................................................... 3-4
2.1Eligibility .......................................................................................................................................3-4
2.1.1 Nationality .........................................................................................................................3-4
2.1.2Conflict of Interest ................................................................................................................3-4
2.1.3ADB Eligibility.......................................................................................................................3-4
2.1.4Government-Owned Enterprise ...........................................................................................3-4
2.1.5United Nations Eligibility ......................................................................................................3-4
2.4ConstructionExperience .............................................................................................................3-9
2.4.1Contracts of Similar Size and Nature...................................................................................3-9
2.4.2Construction Experience in Key Activities .........................................................................3-11
1. Evaluation
In addition to the criteria listed in ITB 37.2 (a)–(f), other relevant factors are as follows:
“Pursuant to ITB 31.3, the cost of all quantifiable nonmaterial nonconformities shall be evaluated,
including omissions in Daywork where competitively priced but excluding omission of prices in
the Bill of Quantities. The Employer will make its own assessment of the cost of any nonmaterial
nonconformities and omissions for the purpose of ensuring fair comparison of Bids.”
Guaranteed power consumption Cost: Since the power consumption for operation and
maintenance of the, Water pumping station (WPS), Sewerage Treatment Plant (STP), Sewage
Pumping Station (SPS) varies from bidder to bidder; therefore, differential power consumption
costs will be evaluated and shall be added to the Bid price for evaluation. Factors, which will be
used in calculating, is the estimated net total cost of the electricity required of, WPS, STP, SPS
during 10 years O&M period (after design build period) with a tariff of Rs 9 per KWH (for
evalaution purpose) for rated flows provided in TECH 1 of, Section 4.
Present Value (PV) of (O&M): All annual future costs to be discounted to present value with the
rate at ten (10) percent per annum calculated for the period of 10 years (annuity factor for 10
years at 10% discount = 6.1445). Present Value (PV) of (O&M) shall be added to the Bid price
for evaluation.
Power consumption for yard lighting shall not be taken into consideration for evaluation
purposes.
Cost loading will be worked out, on the basis of lowest power consumption among the bidders,
at designed flow rates of WPS, STP, SPS provided by bidder.
Bidders shall provide information on guaranteed power consumption at various flow rates in
formats provided in TECH 1 of Section 4.
O&M costs includes cost loading due to differential power consumption, on the basis of lowest
power consumption among the bidders, at designed flow rates of WPS, STP, SPS provided by
bidder.
A. KWH consumption per Annum = 365 X Average KWH per day by 10 years (Average of
1st, 5th and 10th year )quoted by Bidder under TECH-1
B. Guaranteed Power Cost (INR) per Annum = A (KWH per Annum) X 9
C. Power Cost Discounted at
present value @10% annuity factor =B (Guaranteed Power Cost (INR) per Annum) X6.1445
D. Cost Loading for individual bidder = C (Discounted Power Cost for the bidder )–
Lowest discounted Power Cost among all responsive bidders
This cost will be added in the evaluated bid price of the bidder.
2. Qualification
2.1 Eligibility
2.1.1 Nationality
Nationality in accordance with must meet must meet must meet not Forms
requirement requirement requirement applicable
ITB Subclause 4.2. ELI - 1; ELI - 2
with attachments
Non-performance of a contract Must meet Must meet Must meet N/A Form CON-1
requirement requirement requirement
did not occur as a result of
contractor default since 1st
March, 2014.
Not under suspension based on must meet must meet must meet not Letter of Technical
requirement requirement requirement applicable Bid
execution of a Bid-Securing
Declaration pursuant to ITB 4.6.
All pending litigation and must meet not must meet not Form CON - 1
requirement applicable requirement applicable
arbitration, if any, shall be
treated as resolved against the
Bidder and so shall in total not
represent more than 50 % of the
Bidder’s net worth calculated as
the difference between total
assets and total liabilities.
Submission of audited financial must meet not must meet not Form FIN - 1 with
requirement applicable requirement applicable attachments
statements or, if not required by
the law of the Bidder’s country,
other financial statements
acceptable to the Employer, for
the last 3 Years (Financial Year
* 2015-16 to 2017-18; or as per
international practice to
demonstrate the current
soundness of the Bidder’s
financial position. As a
minimum, the Bidder’s net worth
for the last year calculated as
the difference between total
assets and total liabilities should
be positive.
* The fiscal year (FY) of the Government of India and its agencies begins on 1 April and ends on 31 March. “FY” before a
calendar year denotes the year in which the fiscal year starts, e.g., FY2015-16 begins on 1 April 2015 and ends on 31
March 2016.
Foreign bidders may use other internationally accepted Financial year (FY). In case of non availability of data for the
current year, data of previous year will be considered.
Minimum average annual must meet must meet must meet must meet Form FIN - 2
requirement requirement
construction turnover, of INR 25 percent atleast 40
745 million or its equivalent of the percent
calculated as total certified requirement of the
requirement
payments received for contracts
in progress or completed, within
the last 3 years (Financial Year
2015-16,2016-17 and 2017-18)
or as per International practice).
Note:
(1) The fiscal year (FY) of the Government of India and its agencies begins on 1 April and ends on 31 March.
“FY” before a calendar year denotes the year in which the fiscal year starts, e.g., FY2015-16 begins on 1
April 2015 and ends on 31 March 2016.
**substantially completed means (i) the contractor has completed the works but could not commission the
same because of hindrances beyond the control of contractor or (ii) contractor has completed and
commissioned the works at least for the amount required for qualification, out of large size contract
For the above or other contracts executed during must meet must meet Form EXP - 2
requirement requirement
the period stipulated in 2.4.1.1 above, a minimum
construction experience in the following key
activities:
Note:
1. Experience of the bidder earned by him as the JV partner or subcontractor will be considered to the
limit of its share in the completed works shown in that JV or consortium agreement.
Section 4
Bidding Forms
Personnel ............................................................................................................................ 8
Form FIN-6: Sample Form for assured Revolving line of credit facility ............................. 23
To:
The Project Director,
Rajasthan Urban Infrastructure Development Project
First Floor, AVS Building, Jawahar Circle,
JLN Marg, Malviya Nagar, Jaipur,
(a) We have examined and have no reservations to the Bidding Documents, including
Addenda issued in accordance with Instructions to Bidders (ITB) 8;
(b) We offer to execute in conformity with the Bidding Documents the following Works:
…………………………………………………………………………………………………
(c) Our Bid consisting of the Technical Bid and the Price Bid shall be valid for a period of
150 days from the date fixed for the bid submission deadline in accordance with the
Bidding Documents, and it shall remain binding upon us and may be accepted at any
time before the expiration of that period;
(d) Our firm, including any Subcontractors or Suppliers for any part of the Contract, have
nationalities from eligible countries in accordance with ITB 4.2.
(e) We, including any Subcontractors or Suppliers for any part of the contract, do not have
any conflict of interest in accordance with ITB 4.3.
(f) We are not participating, as a Bidder, either individually or as partner in a joint venture,
in more than one Bid in this bidding process in accordance with ITB 4.3(e), other than
alternative offers submitted in accordance with ITB 13.
(g) Our firm, joint venture partners, associates, parent company, its affiliates or
subsidiaries, including any Subcontractors or Suppliers for any part of the contract, are
not subject to, or not controlled by any entity or individual that is subject to, a temporary
suspension or a debarment imposed by the Asian Development Bank or a debarment
imposed by the Asian Development Bank in accordance with the Agreement for Mutual
Enforcement of Debarment Decisions between the Asian Development Bank and other
development banks.1.
(h) Our firm, joint venture partners, associates, parent company, affiliates or subsidiaries,
including any Subcontractors or Suppliers for any part of the Contract, are not, or have
never been, temporarily suspended, debarred, declared ineligible, or blacklisted by the
employer’s country, any international organization, and other donor agency.
1
These institutions include African Development Bank, European Bank for Reconstruction and Development (EBRD),
Inter-American Development Bank (IADB), and the World Bank Group. According to paragraph 9 of the Agreement,
other international financial institutions may join upon the consent of all Participating Institutions and signature of a
Letter of Adherence by the international financial institution substantially in the form provided (Annex B to the
Agreement). Upon adherence, such international financial institution shall become a Participating Institution for
purposes of the Agreement. Bidders are advised to check www.adb.org/integrity for updates.
Contract Package: RSTDIP/SRD/01
4
Section-4: Bidding Forms
(i) Our firm’s, joint venture partners’, associates’, parent company’s affiliates’ or
subsidiaries’, including any Subcontractors or Suppliers key officers and directors
have not been [charged or convicted] of any criminal offense (including felonies and
misdemeanors) or infractions/violations of ordinance which carry the penalty of
imprisonment.
Bid Security
Bank Guarantee
Date: .....................................................................................................................................................................................................................
We have been informed that . . . . . name of the Bidder. . . . . (hereinafter called "the Bidder")
has submitted to you its bid dated . . . . . . . . . (hereinafter called "the Bid") for the execution
of . . . . . . . . name of contract . . . . . . . under Invitation for Bids No. . . . . . . . . . (“the IFB”).
Furthermore, we understand that, according to your conditions, bids must be supported by
a bid guarantee.
At the request of the Bidder, we . . . . . name of Bank. . . . . hereby irrevocably undertake to
pay you any sum or sums not exceeding in total an amount of . . . . . . . . . .amount in figures . .
. . . . . . . (. . . . . . .amount in words . . . . . . . )upon receipt by us of your first demand in writing
accompanied by a written statement stating that the Bidder is in breach of its obligation(s)
under the bid conditions, because the Bidder:
(a) has withdrawn its Bid during the period of bid validity specified by the Bidder in the
Letter of Technical and Price Bid; or
(b) does not accept the correction of errors in accordance with the Instructions to Bidders
(hereinafter “the ITB”); or
(c) having been notified of the acceptance of its Bid by the Employer during the period of
bid validity, (i) fails or refuses to execute the Contract Agreement, or (ii) fails or refuses
to furnish the Performance Security, in accordance with the ITB or (iii) fails or refuses to
furnish a domestic preference security, if required.
This guarantee will expire: (a) if the Bidder is the successful Bidder, upon our receipt of
copies of the Contract Agreement signed by the Bidder and the Performance Security
issued to you upon the instruction of the Bidder; or (b) if the Bidder is not the successful
Bidder, upon the earlier of (i) our receipt of a copy of your notification to the Bidder of the
name of the successful Bidder; or (ii) 28 days after the expiration of the Bidder’s bid.
Consequently, any demand for payment under this guarantee must be received by us at the
office on or before that date.
This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication
No. 4581.
Note: All italicized text is for use in preparing this form and shall be deleted from the final document.
1
Or 758 as applicable.
Technical Proposal
Personnel
Equipment
Site Organization
Method Statement
Mobilization Schedule
Construction Schedule
Others
Personnel
1. Title of position*
Name
2. Title of position*
Name
3. Title of position*
Name
4. Title of position*
Name
5. Title of position*
Name
6. Title of position*
Name
Name
Position
Professional qualifications
Address of employer
Fax E-mail
Equipment
Item of Equipment
Address of owner
Fax Telex
Site Organization
1. The Bidder shall supply a table of personnel and a chart showing the proposed organization
to be established for (i) carrying out the construction works during all phases of works like
mobilization; preparation of Service Improvement Plan; design built period (development
period) and operation and maintenance period separately.
Method Statement
1. The activities for methodology shall include following:
Work plan:
1. The Contractors will submit detailed work plan as part of Technical proposal covering all
sections of work to achieve sectional and full work key milestones as shown in Employer’s
Requirement
Mobilization Schedule
1. The Bidder shall submit mobilization and de-mobilization schedule of personnel and
equipments in detail for all phases of works. The mobilization schedule should include
mobilization of skilled and unskilled manpower, different machineries and equipment,
materials, as required in each Phase.
Construction Schedule
1. The Bidder shall prepare and submit overall construction schedule. The construction
schedule shall be designed and documented in a series of tasks and task assignments
complete with projected completion target dates with the aid of computer operated
management software like Microsoft project office, Primavera or latest by using Gantt charts
and PERT diagrams to allow all factors to know their contribution towards fulfilling the
Employer’s Requirement.
Bidder’s Qualification
To establish its qualifications to perform the contract in accordance with Section 3 (Evaluation
and Qualification Criteria) the Bidder shall provide the information requested in the
corresponding Information Sheets included hereunder.
Bidder’s Information
In case of Joint
Venture, legal name
of each partner
Bidder’s country of
constitution
Bidder’s year of
constitution
Bidder’s legal
address in country of
constitution
Bidder’s authorized
representative
(name, address,
telephone numbers,
fax numbers, e-mail
address)
Attached are copies of the following original documents.
1. In case of single entity, articles of incorporation or constitution of the legal entity named
above, in accordance with ITB 4.1 and 4.2.
2. Authorization to represent the firm or Joint Venture named above, in accordance with ITB
20.2.
3. In case of Joint Venture, letter of intent to form Joint Venture or Joint Venture agreement, in
accordance with ITB 4.1.
4. In case of a government-owned enterprise, any additional documents not covered under 1
above required to comply with ITB 4.5.
Joint Venture
Partner’s or Specialist
Subcontractor’s legal
name
Joint Venture
Partner’s or Specialist
Subcontractor’s
country of constitution
Joint Venture
Partner’s or Specialist
Subcontractor’s year
of constitution
Joint Venture
Partner’s or Specialist
Subcontractor’s legal
address in country of
constitution
Joint Venture
Partner’s or Specialist
Subcontractor’s
authorized
representative
information
(name, address,
telephone numbers,
fax numbers, e-mail
address)
Attached are copies of the following documents.
1. Articles of incorporation or constitution of the legal entity named above, in accordance with ITB 4.1 and ITB 4.2.
2. Authorization to represent the firm named above, in accordance with ITB 20.2.
3. In the case of government-owned enterprise , documents establishing legal and financial autonomy and compliance
with commercial law, in accordance with ITB 4.5.
Specialist Subcontractor is a specialist enterprise engaged for highly specialized processes that
cannot be provided by the main Contractor.
Each Bidder must fill out this form in accordance under Criterion 2.2.1 and 2.2.3 of Section 3
(Evaluation and Qualification Criteria) to describe any history of non-performing contracts and
pending litigation or arbitration formally commenced against it.
In case of a Joint Venture, each Joint Venture Partner must fill out this form separately and
provide the Joint Venture Partner’s name below:
No non-performing contracts.
Below is a description of non-performing contracts involving the Bidder (or each Joint Venture member if Bidder is a Joint
Venture).
Amount of
non-
performed Total
Year Description
portion of Contract
contract ($ Amount ($
equivalent) equivalent)
[insert
Contract Identification: [indicate complete contract name/ number, and any [insert [insert
year] other identification] amount] amount]
Name of Employer: [insert full name]
Address of Employer: [insert street/city/country]
Reason(s) for non-performance: [indicate main reason(s)]
Below is a description of all pending litigation and Arbitration involving the Bidder (or each Joint Venture
member if Bidder is a Joint Venture).
Value of
Value of
Pending
Pending
Year Matter in Dispute Claim as a
Claim in INR
Percentage
Equivalent
of Net Worth
Table 2 of this form shall only be included if Criterion 2.2(b) of Section 3 (Evaluation and Qualification Criteria) is
applicable.
In case of joint ventures, each Joint Venture Partner must fill out this form separately, and
provide the Joint Venture Partner name below:
Attached are copies of audited financial statements (balance sheets including all related notes,
and income statements) for the last 3 years, as indicated above, complying with the following
conditions.
Unless otherwise required by Section 3 of the Bidding Document, all such documents reflect
the financial situation of the legal entity or entities comprising the Bidder and not the Bidder’s
parent companies, subsidiaries or affiliates.
Historic financial statements must be audited by a certified accountant.
Historic financial statements must be complete, including all notes to the financial
statements.
Historic financial statements must correspond to accounting periods already completed and
audited (no statements for partial periods shall be requested or accepted).
Note: The fiscal year (FY) of the Government of India and its agencies begins on 1 April and ends
on 31 March. “FY” before a calendar year denotes the year in which the fiscal year starts, e.g.,
FY2015-16 begins on 1 April 2015 and ends on 31 March 2016. Foreign bidders may use other
internationally accepted Financial year (FY).
The information supplied should be the Annual Turnover of the Bidder or each member of a
Joint Venture in terms of the amounts billed to clients for each year for work in progress or
completed, converted to Indian Rupees at the rate of exchange at the end of specified rate.
In case of joint ventures, each Joint Venture Partner must fill out this form separately, and
provide the Joint Venture Partner name below:
2015-16
2016-17
2017-18
Note:
1. The fiscal year (FY) of the Government of India and its agencies begins on 1 April and ends on 31
March. “FY” before a calendar year denotes the year in which the fiscal year starts, e.g., FY2015-16
begins on 1 April 2015 and ends on 31 March 2016. Foreign bidders may use other internationally
accepted Financial year (FY).
2. In case the construction turnover is not specifically defined in audited balance sheet, the bidder shall
have to additionally submit a certification from chartered accountant clearly depicting the receipt
from construction work only out of total receipts
In case of joint ventures, each Joint Venture Partner must fill out this form separately and provide
the Joint Venture Partner name below:
Financial Resources
No. Source of financing Amount (INR Equivalent)
1 Working Capital (to be taken from FIN-1)
2 Revolving line of credit facility from the banks
3 Fund based unutilized credit line from the bank
Non Fund based unutilized credit line from the bank (Limited
4 to 50 % of total financial resources requirement)
Total Available Financial Resources
NOTE:
Available Financial Resources with the bidder will include sum of (1) Working capital (Current
assets – Current Liability) from latest audited balance sheet as on 31st March (2) Fund
based unutilized credit facilities from the Banks as available on the bid submission date on
the Bank’s letter head (3) Non fund based unutilized credit facilities from the Banks as
available on the bid submission date on the Bank’s letter head; limited to 50% of the total
financial resources requirement and (4) assured Revolving line of credit facility from the
banks in Form FIN-6: Sample Form for assured Revolving line of credit facility.
Certificates from the Banks for credit line and the Revolving line of credit facility shall be
unconditional. Certificates from the Banks for Revolving line of credit facility shall generally
be in the format provided in bid document.
1
Remaining contract period to be calculated from 28 days prior to bid submission deadline.
2
Remaining Outstanding Contract Values to be calculated from 28 days prior to the bid submission
deadline (equivalent based on the foreign exchange rate as of the same date).
3
Bidder should calculate this amount based on the sum of 2 Months Financial Resources Requirements
for Each Current Works Contract based on the following calculation:
_________ ...........
(Name of Bidder)
____________ ...........
(Name of Partner)
Each Partner:
_____________ ...........
(Name of Partner 1)
_____________ ...........
(Name of Partner 2)
_____________ ...........
(Name of Partner 3)
- Note -
Form FIN – 5 is made available for use by the bidder as a self-assessment tool, and by the employer as an evaluation
work sheet, to determine compliance with the financial resources requirement as stated in 2.3.3. Failure to submit Form
FIN - 5 by the Bidder shall not lead to bid rejection.
Subject: Letter of Assurance for Revolving line of credit facility for INR ----
Dear Sir,
WHEREAS the Bidder has requested that an assured revolving line of credit be provided
to it for executing the --------------------- ---(name of contract package) ----------------------------
----------------------In the event that the Contract is awarded to it; then
KNOW ALL THESE PEOPLE by these presents that We
____________________________ [name of Bank] of ____________________ [name of
Country] having our registered office at ______________________ [address of registered
office] are willing to provide to _________________________ (the Bidder) a sum of up to
____________________________ [amount of guarantee in figures and words] as an
assured revolving line of credit for executing the Works under --------------------- ---(name of
contract package) --------------should the Bidder be awarded the contract based on its
tendered prices.
We understand that this assurance may be taken into consideration by the Employer
during evaluation of the Bidder’s financial capabilities, and further assure that we intend to
maintain this revolving line of credit until such time as the Works are completed and taken
over by the Employer.
SEALED with the Common Seal of the said Bank on the ____ day of _________, 2019.
The exchange rate to be used to calculate the value of the contract for conversion to a specific
currency shall be the selling rate of the Borrower’s national bank on the date of the contract.
Employer’s name
Address
Telephone number
Fax number
E-mail
Description of the Similarity in Accordance with Criterion 2.4.1 of Section 3 (Evaluation and
Qualification Criteria)
2.4.1.1
Participation as a contractor, JV partner, or
subcontractor, in at least one contract in water
supply where the value of the completed and
commissioned or substantially completed** work
exceeds INR 304 million or two contracts in water
supply where the value of the each completed or
substantially completed** work exceeds INR 217
million or its equivalent
And
one contract in sewerage work including Sewage
treatment Plant and / Effluent Treatment Plant (STP /
ETP) where the value of the completed or
substantially completed** work exceeds INR 736
million OR two contracts in sewerage works
including Sewage treatment Plant/ Effluent
Treatment Plant (STP / ETP) where the value of the
each completed or substantially completed** work
exceeds INR 526 million or its equivalent within
the last 10 years (from 1 Mar, 2009 to bid
submission date)
2.4.1.2
Experience in supply, installation, testing and
commissioning of water supply distribution pipeline
network of all sizes and materials in a minimum
length of 50 KMs (Should be met by the Bidder) in
contracts executed during the period stipulated in
2.4.1.1
2.4.1.3
Experience in supply, installation and
commissioning of sewerage system (of sewer of
minimum 150 mm inner/outer dia) in a minimum
length of 50 KMs (Should be met by the Bidder)in
contracts executed during the period stipulated in
2.4.1.1
If complied by Specialist Subcontractor, each Specialist Subcontractor must fill out this form and
provide the Specialist Subcontractor’s name:
Employer’s name
Address
Telephone number
Fax number
E-mail
Description of the Key Activities in Accordance with Criterion 2.4.2 of Section 3 (Evaluation and
Qualification Criteria)
For the above or other contracts executed during
the period stipulated in 2.4.1 above, a minimum
construction experience in the following key
activities:
Experience in construction, commissioning and
O & M (construction and O&M may be under
same or different contracts) for a period of
minimum one year of STP / CETP (SBR/ MBBR
process) of minimum 3 MLD capacity
(construction or O&M or both requirements could
be met by the specialist subcontractor (s) /
Technology provider.
Schedules
Schedule of Payment Currencies
For ...........................insert name of Section of the Works ...................................
Separate tables may be required if the various sections of the Works (or of the Bill of Quantities)
will have substantially different foreign and local currency requirements. In such a case, the
Employer should prepare separate tables for each Section of the Works.
A B C D
Rate of Percentage of
Local Currency
Name of Payment Amount of Exchange Net Bid Price (NBP)
Equivalent
Currency Currency to Local 100xC
C=AxB
Currency NBP
Local Currency
1.00
Foreign Currency #1
Foreign Currency #2
Foreign Currency #
Provisional Sums
Expressed in Local 4,000,000 1.00
Currency
BID PRICE
- Note -
The rates of exchange shall be the selling rates 28 days prior to the deadline for submission of bids published
by the source specified in BDS 15.
Total 1.00
in Cum/Hr
in Cum/Hr
in Cum/Hr
Per Year
Per Year
Per Year
Capacity
Capacity
Capacity
Per Day
Per Day
Per Day
(8)
(5) = = (11) =
(1) (2) (3) (4) (4) x (6) (7) (7) (9) (10) (12) x
365 x 365
365
Hanumangarh Road
1 702 745 795
H/W
Note:
i. For intermediate flows, guaranteed maximum power consumption will be interpolated.
ii. The above components shall include auxiliary power like EOV/EOT etc.
iii. While submitting Form Tech-1, Bidder shall adhere to the format of Tech-1 and values
mentioned in the table.
iv. Water Pumping Stations shall run continuously for design pumping hours a day.
v. We confirm that the power consumption stated in the above table is the guaranteed maximum
consumption
In case of more than guaranteed power consumption, Employer will recover the cost of excess
monthly power Consumed with two times prevailing power rate.
Guaranteed Gross Power requirement for Sewage Treatment Plants (STPs) and Sewage
Pumping Station (SPS) (excluding power consumption for yard lighting), during O & M period
(after design build completion):
Note:
i. For intermediate raw/ treated sewage flows, guaranteed maximum power consumption will be
interpolated.
ii. We confirm that the power consumption stated in the above table is the guaranteed maximum
consumption. In case of more consumption to the guaranteed power, Employer will recover the
costs of excess monthly power consumed with the two times prevailing power rate.
iii. Power consumption for yard lighting etc shall not be included in above table.
Signed by -------------------
On behalf of -----------------------
In consideration of you, the Employer, awarding the Contract to the Contractor, we ……………….
[name of affiliated company] ………………. irrevocably and unconditionally guarantee to you, as a
primary obligation, that (i) throughout the duration of the Contract, we will make available to the
Contractor our financial, technical capacity, expertise and resources required for the Contractor’s
satisfactory performance of the Contract; and (ii) we are fully committed, along with the Contractor,
to ensuring a satisfactory performance of the Contract.
If the Contractor fails to so perform its obligations and liabilities and comply with the Contract, we
will indemnify the Employer against and from all damages, losses and expenses (including legal
fees and expenses) which arise from any such failure for which the Contractor is liable to the
Employer under the Contract.
This guarantee shall come into full force and effect when the Contract comes into full force and
effect. If the Contract does not come into full force and effect within a year of the date of this
guarantee, or if you demonstrate that you do not intend to enter into the Contract with the
Contractor, this guarantee shall be void and ineffective. This guarantee shall continue in full force
and effect until all the Contractor’s obligations and liabilities under the Contract have been
discharged, when this guarantee shall expire and shall be returned to us, and our liability
hereunder shall be discharged absolutely.
This guarantee shall apply and be supplemental to the Contract as amended or varied by the
Employer and the Contractor from time to time. We hereby authorize them to agree on any such
amendment or variation, the due performance of which and compliance with which by the
Contractor are likewise guaranteed hereunder. Our obligations and liabilities under this guarantee
shall not be discharged by any allowance of time or other indulgence whatsoever by the Employer
to the Contractor, or by any variation or suspension of the works to be executed under the
Contract, or by any amendments to the Contract or to the constitution of the Contractor or the
Employer, or by any other matters, whether with or without our knowledge or consent.
This guarantee shall be governed by the law of the same country (or other jurisdiction) as that
which governs the Contract and any dispute under this guarantee shall be finally settled under the
[Rules or Arbitration provided in the Contract]. We confirm that the benefit of this guarantee may
be assigned subject only to the provisions for assignment of the Contract.
[signature] [signature]
…………………………………… …………………………………….
[Name] [Name]
………………………………… …………………………………
[Position in Parent Company] [Position in Parent Company]
Date:………………. Date:……………….
Note - Bidders are under no obligation to use the proposed sample format for the “ Sub
contracting agreement”, Bidders may submit in their own format acceptable to Employer.
BETWEEN
M/s. ____________________________________________________________, a
company incorporated, and having its registered office at
___________________________________. (Hereinafter referred to as the "First Party"/
"One Partner");
Hereinafter jointly referred to as the "Parties" and individually as "Each Party" or "a
Party” as the case may be.
WHEREAS,
4.2 All rights, interests, liabilities, obligations, risks, costs, expenses and pecuniary
obligations and all net profits or net losses arising out of the Contract shall be
shared or borne by the Parties.
4.3 The members in the proportion as mention in article 4.1, shall contribute sufficient
Initial fixed capital for timely execution of the project including commissioning &
operating period as per the contract.
ARTICLE 6: EXCLUSIVITY:
6.1 The co-operation between the Parties hereto shall be mutually exclusive i.e. none
of them shall without the other Party's consent & prior approval of RUIDP,
approach or cooperate with any other parties in respect of the Project.
6.2 In the course of working as associates, the parties to the JV will be sharing
ARTICLE 8: ARBITRATION:
8.1 Any dispute resulting from this Agreement shall be settled amicably by mutual
Consultation by the Managing Directors/ Chairman of
___________&_____________. In the event that an amicable settlement is not
reached within 60 days in any particular case, the dispute shall be referred to
arbitration and shall be resolved in accordance with and subject to the provisions
of the __________________________ and any statutory modifications and
enactment hereof for the time being in force. The decision of the arbitrators shall
be final and binding upon both parties. The venue of arbitration will be
____________.
Signed by )
For and on behalf of
_________________________ )
_____________________________
Signed by )
For and on behalf of ) ________________________________
__________________________________.
in the presence of: ) Name :
______________________ ) Designation:
Name:
Designation:
Note - Bidders are under no obligation to use the proposed sample format for the “ Sub
contracting agreement”, Bidders may submit in their own format acceptable to Employer.
Section 5
Eligible Countries
Name of Work:-Construction of Works of Water Supply Production and Distribution Network Improvements
with house service connections for nonrevenue water reduction and continuous water supply and Providing
Sewer Network with House connections, and construction of Sewage Treatment Plant & Sewage Pumping
Station and all allied Works and operation services of the entire system for 10 years at Sardarshahar (Churu).
SECTION 6
EMPLOYERS REQUIREMENTS
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Table of Contents
6.1 Scope of Services - General
6.2 Scope of Services –Water Supply
6.3 Scope of Services – Waste Water
6.4Scope of Services – Road Restoration
6.5 Scope of Services – Civil Works
6.6 Scope of Services – Mechanical, Electrical and Instrumentation.
6.7 Specifications of work
6.8 Drawings
6.9 Supplementary Information
6.10 Personnel Requirements
6.11 Equipment Requirements
Annex A: Draft Initial Environmental Examination and Environmental Management Plan
Annex B: Draft Resettlement Plan
RUIDP P a g e | 1of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 2of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 3of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 4of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
6.1.1 DEFINITIONS
The words, terms and expressions beginning with capital letters and defined under this Section 6.1 including
those in Section 7 - General Conditions of Contract and those in Section 8 – Particular Conditions of Contract
shall, unless the context otherwise requires, have the meanings as described thereto / herein:
a) “Battery Limits” shall mean the boundary within which the Contractor has the responsibility of providing
services in accordance to the terms and conditions under this Contract. Boundary Limits OHSR has
the same meaning as Battery Limits;
b) “Consumer Relation Management Centres” means the special centres, planned and established by the
Contractor to provide commercial and public relations services to consumers;
c) “Consumer or Customer” means the registered user to which/ whom PHED / Contractor/ Operator/
ULB provides water servicesthrough the meter at the private tap;
d) “Consumer or Customer” means all entities (including individuals)
e) “Consumer Water Connection Points” means the points in the distribution pipe from which water
connections are given to the consumers ;
f) “Contract Commencement Date” means the Date after the issue of the performance security stated in
the note issued by the Employer’s Representative;
g) “Contract commencement date” means the stipulated date of commencement of contract indicated in
Notice to Proceed (NTP). NTP is issued after signing of the agreement or as decided by the Employer;
h) “Contract Completion” means the Contract Completion Date as mentioned in the Contract Completion
Certificate issued by the Employer’s Representative to the contractor on fulfilment of his obligations in
respect of both the Design-Build and the Operation & Maintenance Services;
i) “Contract Date” means the date on which the contract is signed;
j) “Contractor” means the agency responsible for Design-Build and Operation&Maintenance of the entire
water & waste water system as specified in Scope of work and in Section 6;
k) “Contractor's Personnel” means personnel hired and deployed by the Contractor under provision of
Works and Services but excluding the Municipal Board, Sardarshahar (MBS) or PHED Personnel;
l) “Contract Period or Total Contract Period” means the period of Contract counted from Commencement
Date upto Contract Completion Date;
m) “CPHEEO” means the Central Public Health and Environmental Engineering Organization under the
Ministry of Urban Development, Government of India;
n) “Critical Measurement Points” means the locations agreed for undertaking measurement for facilitating
the monitoring of minimum Service levels stipulated in Clause of Performance Standards;
o) “Design Build Period” means the period commencing from contract commencement date to completion
of design, construction, testing,trial runs and commissioning of all permanent works;
p) “Development Period” has the same meaning as Design Build Period; “DMA" or District Metered Area
(DMA) means a discrete area of water distribution network, created by closing boundary valves so that
it remains flexible to changing demands.
q) “DPR” means the Detailed Project Report of Sardarshahar;
r) “DNI” means Distribution Network Improvement;
s) “DNI Plan” means the detailed techno-economic Distribution Network Improvement plan of the
Contractor to achieve the minimum service levels stipulated in Performance Standards in this Section;
t) “Electricity Department” means the local service provider supplying electricity for facilitating Operation
of the facilities maintained by Contractor;
u) “ESR” means Elevated Service Reservoir; GLSR (Ground Levelservice Reservoir), SR (Service
Reservoirs),OHSR (Over Head Service Reservoir) has the same meaning as ESR;
v) “Existing Assets” means infrastructure components, plant, machinery, equipment and any other units
existing at the site as on the Commencement Date in the Employers Representative-ship of the
Employers Representative of Assets;
w) “Final Take Over Date’ means the date on which the Contractor finally takes over the entire water
supply and sewerage system including bulk water supply system developed by PHED from
Dhaulakhera headworks to the Service reservoirs for operation and maintenance.
x) “Final Take Over Date” is synonymous to “the date stated in the final Commissioning Certificate”
y) “Government Agencies” means all those agencies comprising of local, state and central government
authorities directly or indirectly connected to provision of water and waste water collection services to
the consumers in Town;
z) “Initial Take Over Date’ means the date on which the Contractor/operator takes over the first zone for
operation and maintenance, after completing works of water distribution network or sewerage network
and making house connections.
aa) “Initial Take Over Date” is synonymous to “the date stated in the initial Commissioning Certificate”
RUIDP P a g e | 5of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
bb) “Major Maintenance” means large capital maintenance works requiring replacement of existing
infrastructure / assetsand include, those which are procured and installed by contractor and whose
operational life is exceeded than those specified in CPHEEO manual during the currency of operation
period to be assessed and mentioned in the SIP. Only assets mentioned in the SIP are eligible for
payments;
cc) “Mandatory Works” means, works which are listed in the Bill of Quantities and are required to be
constructed, installed or erected and commissioned and/or rehabilitated including those during Operate
and Maintenance period and in line with the provisions of this Contract unless such works require
change of scope or design as agreed, as part of the works;
dd) “Minimum Service Levels" means the levels of service to be maintained in the operations, maintenance
and management and service delivery to consumers, described in Clause of Performance Standards
as per Section 8 of the Bid Document;
ee) “Minor Maintenance” means routine preventive or corrective maintenance works such as minor repair,
reconditioning, or replacement of spare parts to ensure serviceability of existing and new infrastructure
assets procured and installed by the Contractor including, pipes, electrical equipment, valves, flow
meters, pressure monitoring equipment, and consumer meters, starter panel, electro-mechanical
equipment etc.;
ff) “Mobilization Period” means the period in which activities defined in Section 6 would be completed. It is
the period commencing from the Contract Commencement Date and extends up to limit mentioned
further in this document;
gg) “New Assets” means infrastructure components, plant, machinery, equipment and any other units
procured, supplied, installed, erected and commissioned by the Contractor during the Design-Build
period other than those existing on the site as on the Commencement Date;
hh) “NRW” means Non-Revenue Water, it is that quantity of water, which does not earn any revenue;
ii) “Operating Payments” means the eligible payments towards operation, maintenance, repairs and
service delivery after meeting the stipulated performance indicators;
jj) “Operator” means the agency to operate the system after taking over. Contractor means the agency to
design build the works. Operator is synonymous to the Contractor.
kk) “Performance Standards” mean the Minimum Service Levels to be achieved and maintained by the
Contractor during Contract period set forth in Section 8 of the bid document;
ll) “PHED” means the Public Health Engineering Department, GoR;
mm) “MBS” means Municipal Board, Sardarshahar;
nn) "Physical Losses" is part of the UFW/ NRW and represents the volume of water leaking from the
system;
oo) “Planned Maintenance” means activities required to undertake preventive maintenance of any or all
assets existing or proposed to be installed under the Contract and /or those taken over for operation&
maintenance under this contract;
pp) “PMCB” means the Consultant for Project Management and Capacity Development as appointed by
the Employer;
qq) “CMSC” means the Consultant for Construction Management and Supervision Consultant as appointed
by the Employer;
rr) “Potable / Drinking Water Specification” means the water quality requirements of potable water to be
supplied to the Contractor as stipulated in IS 10500, Guidelines for Physical and Chemical Parameters
and Table 2.3 Bacteriological Quality of Drinking Water, in the Manual on Water Supply and Treatment,
CPHEEO, Government of India, Ministry of Urban Development, New Delhi, edition May 1999or its
amendment or latest edition;
ss) “Preparatory Period” or “Service Improvement Plan Preparation Period” is the period commencing from
the Contract Commencement Date up to the time as specified in this document during which time the
Contractor will prepare the Service Improvement Plan (SIP);
tt) "Project" means “Water Supply and Waste Water Collection System for Town city”;
uu) “Project Report” means the Reports of TownWater Supply System and Waste Water system;
vv) “Release Event” shall mean an event such as non-availability of water at the source, non-availability of
electricity etc., or an event of force majeure;
ww) “RUIDP” means Rajasthan Urban Infrastructure Development Project or its successor agency and is
synonymous with “Employer”
xx) “RSTDIP” means Rajasthan Secondary Town Development Investment Program.
yy) “Scheduled Design Build Completion Date” or “SDBCD” shall mean the date by which the construction
of all the Works as per the agreed Service Improvement Plan are to be completed, commissioned and
certified by the Employer’s Representative;
RUIDP P a g e | 6of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
zz) “Schedules or Schedule” means the schedules forming part of this contract, or any one of them, as the
context requires;
aaa) “Scope of Services” shall mean all those services to be provided by the Contractor in accordance to
the obligations, activities, responsibilities and tasks in implementing the contract;
bbb) “Service Area” means the area where Contractor and/or RUIDP or its successors is responsible for
conveying water Consumers;
ccc) “Service Area” means the area where PHED is responsible for provision of water supply services to
consumers and the Municipality for sewerage services. The Service Area can be either within the
administrative municipal boundary as extended from time to time and also include future growth areas
where RUIDP/MBS decides to provide expansion of water and sewerage services and undertake
operation, maintenance and management services;
ddd) “Services” means all those activities, interventions, actions and tasks required as part of the
implementation of design built works including all planning, design, detailed engineering, procurement,
construction, rehabilitation and operations, maintenance, and management in providing continuous
pressurized water supply with improvement in level of service and sewerage services to the consumers
in town; including all those activities as defined in the Scope of Services;
eee) “SIP” mean Service Improvement Plan proposed by the Contractor and approved by Employer’s
Representative;
fff) “Sub-Project means” either the Water Supply or Wastewater component of the Project;
ggg) “Sewerage Charges" shall mean the charges of sewerage services to the consumers payable to the
Employer as fixed by the Employer from time to time;
hhh) “Water Charge" means the charges per kilo liter of water to be paid by the connected consumers as
fixed by the authority from time to time;
iii) “Water Distribution Network” is the network of pipelines downstream of the water storageutilities/ for
pumping directly to consumers;
jjj) “Water Distribution Station” is the location of a ground reservoir and / or pumping station or an
Overhead Service Reservoir from which when water is released, the same reaches directly to the
consumers’ properties through the water distribution network;
kkk) "UFW" means Unaccounted for Water and is part of the NRW. It means that quantity of water, which
does not reach the desired destination from its upstream point of original measurement. UFW
comprises:
Apparent losses such as illegal water connections and metering inaccuracies; and
Real losses which are leakages in the transmission networks and / or process losses.
6.1.2 PREAMBLE
This Employer’srequirement covers the civil and non-civil works coming under scope of this bid document. All
work shall be carried out in conformity with the same. These specifications/requirments are not intended to
cover the minute details. The works shall be executed in accordance with good engineering practices followed
for achieving highest standards of workmanship, thus ensuring safety and durability of the construction and to
achieve the project goal, process guarantees and performance indicators. All codes and standards referred to
in these specifications shall be the latest thereof, unless otherwise stated.
6.1.3 PROGRAM BACKGROUND AND OBJECTIVES
Government of Rajasthan has approved an Investment Program of US$.700 million (with ADB Loan of
US$500million) for secondary towns of the State named as “Rajasthan Secondary Towns Development
Investment Program (RSTDIP)”. Water management works in 42 towns will be impelemented under the
program.
The Program objective of Rajasthan Urban Sector Development Program is to improve the economic
development by providing the infrastructure and service in the water supply and sewerage sector. The
improvement of quality of life and thereby effective contribution of beneficiary people in the economic activity is
expected. The Program therefore focuses on service delivery along with the creation of quality assets and
service delivery monitoring systems. Objectives of the Program are NRW reduction and continuous pressurised
water supply in the service area of program cities along with sewage collection, treatment and Reuse/ safe
disposal of sewage treatment plant effluent.
6.1.4 PROJECT LOCATION AND CLIMATE
Location: - Sardarshahar lies towards the North East of Bikaner at a distance of 136 Km by Road on the
junction of State Highway No.6 and 7. It is directly connected to Delhi, Jaipur, Ganganagar, and Bikaner by
Road. The Only Rail Link with Ratannagar was provided in 1916 in erstwhile Bikaner State Time. Sardarshahar
town is located at 74o27’. Longitudinal east and 28o26’ latitude North at an Altitude of 224m above mean sea
level. The nearest airports are New Delhi Airport and Jaipur Airport (Both airport are International airport).
RUIDP P a g e | 7of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Climate: -
Sardarshahar has a desert climate. There is virtually no rainfall all year long in Sardarshahar. The average
annual temperature in Sardarshahar is 25.6 °C. Precipitation here averages 296 mm.
6.1.5 NEED OF THE PROJECT
The present service level in Sardarshahar town is only 90-100 lpcd and the water supplied for 1-2hours daily
with low pressure. The service does not cover the entire town. It is assessed that service level can be improved
by (i) augmenting the water supply system (ii) by reducing NRW, and (iii) by extending the service to unserviced
area. In order to reduce the NRW and to ensure continuous pressurized water supply, it is necessary to
improve the distribution system by replacing undersized or leaking pipelines with good quality pipelines having
the leak proof joints, providing metered House Service Connections to all households, and enforcing long time
performance based operation and management arrangement. Since, the project town does not have a regular
sewerage system; therefore construction of appropriate sewerage system along with long time performance
based operation and management system is necessary. The proposed project therefore includes water supply
distribution and sewerage network system as mentioned including performance based O&M arrangement.
6.1.6 PROJECT OBJECTIVE
The objectives of the project are:
A. Water supply
To establish continuous pressurised water supply system to consumers with quality and quantity at
required pressure.
To establish reliably supply the specified quantity and quality of water.
To adopt energy efficient water treatment processes and electromechanical machinery.
To reduce NRW as per performance indicators using district metering areas (DMA) approach.
To ensure 100 % house service connections with metering for water supply.
To ensure sustainability of the project by implementing a comprehensive asset management plan
focussing on an integrated approach to operation & maintenance to minimize lifecycle costs.
B. Sanitation
Construction of sewerage network, including house sewer connection and collection of wastewater
from point of generation.
Construction of energy efficient and mechanized Sewage Treatment Plant and electromechanical
machinery;
Septage management and decentralized wastewater treatment systems in suitable areas;
Provision for reuse of treated effluent etc.
To ensure 100 % house service connections for wastewater collection.
To ensure sustainability of the project by implementing a comprehensive asset management plan
focussing on an integrated approach to operation & maintenance to minimize lifecycle costs.
The project objective also includes the following measures in form of
Environmental andSocial measures - Objective is to minimize the social and environmental impacts of
the project and reduce any adverse impacts to acceptable levels
6.1.7 EMPLOYER’S REQUIREMENT DURING CONTRACT PERIOD
This part describes the extent of works and Employer’s requirements for works in brief. The contractor shall
ensure the technical feasibility of the offer submitted in all respect after visiting the site. It must be clearly
understood that the Contract is “Design-Build-Operate” Contract.
o In respect of Water Supply, the contract includes surveys, investigation, design, construction, supply,
installation, testing, trial run, commissioning, and Operation and Maintenance services for 10 years for
the entire works from completion of Design-Build period. Operation and Maintenance services for
allcommissioned works including DMA’s is to be carried out during Design Build period also.
o In respect of Waste Water, the contract includes survey, investigation, design, construction, supply,
installation, testing, trial run, commissioning, and Operation and Maintenance services for 10 years for
the entire works from completion of Design-Build period Operation and Maintenance services for the
commissioned works is to be carried out during Design Build period also.
6.1.8 BATTERY LIMIT
The battery limit schematic diagram as shown in tender drawing of Volume III shows locations and extent
of the works and limits of the contract for water supply and wastewater works.
o For water supply starts just at Hanumangarh Road PHED Pump House (Apni Yojana)at which lead
to and ends at the downstream end of the tap of the consumer meter at consumer properties.
o For wastewater works starts from outlet of sewage from house/ property connection to property
chamber to manhole to Sewage Treatment Plant to safe dischage of Eflluent up to ultimate
disposal point, and up to outlet from ESR for reuse of treated sewage.
RUIDP P a g e | 8of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 9of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
xiv. All materials used for permanent installation in the works shall be new and shall conform to the
respective clauses of the specifications and if not specified they shall conform to good
standards of construction practice.
Employer reserve the right to construct any work or any part thereof on, over, under, in or through
the site. Employer may use or occupy any part of the permanent work.
Generally the following activities shall be carried out for each component of this contract but shall not
be limited to:
All designs shall conform to latest Indian Standard (I.S.) Specifications and Codes of Practice unless
otherwise specified in the Bid Specifications. The design standards adopted shall follow the best
modern Engineering practice in the field based on any other international standard or specialist literature
subject to such standard reference or extract of such literature in the English language being supplied to
and approved by the Employer’s Representative. In case of any variation or contradiction between the
provisions of the I.S. Standards or Codes and the specifications given in the bid document, the provision
given in this bid document shall be followed.
Preparation and submission of all detailed construction drawings (for all lumpsum and item rate works)
on the basis of conceptual designs and plans approved by the Employer’s Representative.
Design reviews and appraisals at regular interval, prior to construction of works.
Submission of the credential of manufacturer for supply of various materials, machinery,
equipment/instruments for approval of Employers representative.
Submission of the design/specifications, product brochures, technical data sheets, test, Quality
Assurance Plan (QAP) and performance certificates etc., of all mechanical plant and works (pumps,
valves, fittings etc.,), instrumentation/automation SCADA system, appurtenances required for surge
protection, design of the mechanical, electrical components, taking into account the interfaces to the
other project components/packages and future extensions of the project.
Electric design and electric load calculation.
Construction/Installation, testing and commissioning of all civil, mechanical, electrical and
instrumentation, SCADA works strictly as per scope of work, approved drawings, designs, relevant IS
codes and specifications.
Pre- commissioning checks and inspections as per requirement.
Testing of hydraulic, mechanical, electrical and instrumentation system as per relevant IS codes and
specifications and guidelines.
Optimization of the whole system as per design parameters and commissioning of all the components
including but not limited to all components proposed in the bid in all respect.
Responsibility to supply the design water demand to the downstream components of the system is
solely of the Contractor, the Contractor is required to review the design of the Transfer Main pipe line,
pumps, surge analysis etc. and instrumentation SCADA and Automation Control system at his own to
achieve the objectives of the work.
Responsibility to Collect and dispose, discharge/pump the sewage generated from property chambers
to the downstream components of the system from within the sewerage network is solely of the
Contractor, the Contractor is required to review the design of the sewer network, sewage pumping
station, etc.at his own to achieve the objectives of the work.
Getting approval of all designs and drawings, material to be used, machinery and equipment
specifications and the samples, prior to dispatch by manufacturer or
supplier/installation/commissioning of work at site is the sole responsibility of the contractor. If any
specific provision/references have been made in more than one specification, at different places in the
tender document, the provision which is more stringent, shall be applicable.
Designing, providing, erecting, constructing, testing & commissioning of substation, transformer.
The complete work of Road Crossing on National Highway, and railway crossing, shall be done by
trenchless technology, and is in the scope of this contract. All other road crossings are also to be done
by the contractor, by deciding a suitable method as per the instructions of the Employers
Representative.
To co-ordinate with the Operation and Maintenance staff and concerned officers of PHED, PWD,
Forest, BSNL, Gram Panchayat, Mining, Army/Defence, electric supply company and personnel of
local water supply system or any other department / agency (for installation of new equipments etc.,),
with the district administrative offices and other offices for necessary approvals and certificates
wherever required.
Manufacturing, shop testing, pre-dispatch inspection, transportation to site, providing transit insurance,
storage, handling at site, installation, sectional testing, pre-commissioning testing, trial run and
commissioning for all components of the system and the system as a whole, including the hydraulic,
mechanical, electrical, Electro-Mechanical and instrumentation equipment.
RUIDP P a g e | 10of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Civil works, Campus development and Administrative Building, and all such ancillary structures, road
works, storm water drains, RCC chambers, horticulture, electrical works, forming part of the lump sum
work, and Master Control Centre, Consumer Service Centre to be constructed at appropriate locations
as indicated by the Employers Representative.
Analysis, design, supply and installation of Surge Control System for the operating pressure and flow
for pumping mains. The contractor shall obtain surge analysis for all transmission pipe lines (i.e.
pumping main) from IISc Bangalore/IIT Delhi/IIT Chennai/IIT Kanpur/IIT Roorkee/IIT Bombay using
SAP 2 or any other recognised software as per approval of Employers Representative.
For laying of pipe line and construction of any component of project, for Item rated works, the cost of
shifting of electrical poles, transformers, telephone line, trees etc., if required shall be reimbursed to
contractor under provisional sum. The permission fee for crossing of NH/SH and railway crossing shall
also be reimbursed to the contractor under provisional sum on submission of the original bill of
concerning department along with proof of payment done. The contractor shall be responsible for any
damage occurred to telephone lines, electricity cables, OFC cables, cutting of trees, cables,
distribution/pumping water mains and gas pipes, sewer lines, drains, constructed by other
departments/agencies while laying water and sewer pipeline or construction of any component of the
project and shall be liable to pay the amount levied by respective department(s)/agencies for the repair
and/or damages so occurred.
The approval and submission of good for construction drawing is the precondition for starting the
execution on ground and as-built drawings of the works is the pre-condition for the final payment of
execution part. Submission of operation and maintenance manual as per scope of works,
requirements and specifications is the pre-condition for payment of O&M.
Operation, routine and preventive maintenance during defect liability period of 1 year. System shall be
operated and maintained along with rectification of any defects which are observed/ pointed out by the
department as defined in tender document. Payment for only operation of the system shall be
admissible during defect liability period, and no separate payment for spares, material, equipments and
labour required for rectification of defects, routine maintenance of the system shall be made.
Operation, routine and preventive maintenance for 10 years includes defect liability period of 1 year (as
1st year of operation and maintenance period). Payment for all labour, spare parts, consumables,
material/equipments/tools and tackles required for Operation and Maintenance shall be deemed to be
included in accepted O&M charges.
Employer will bear only energy cost and O&M costs including diesel & lubricants cost for operation of
diesel generator set in the event of power failure, during trial run and commissioning, and Operation &
Maintenance period.
Providing mandatory spares tools and tackles at the end of the execution of physical works as per
list required to be submitted along with the bid.
Existing all Civil, Pipelines, Mechanical & Electrical, Instrumentation, etc., equipments, structures,
materials, etc., at the site shall be removed and transported at the location as per the instruction of the
Employers representative. No extra cost will be paid for this work. Contractor shall include the cost for
this work in his bid.
Reference bench marks for Reduced Level shall be adopted as fixed by Survey of India Department,
any delay or error in identification of such bench mark shall be solely on part of contractor for
topographical survey.
Arrangement of adequate security, watch and ward of the system during the execution period to
safeguard the equipment and completed section of the work from any type of mishandling, theft, fire
and other hazards, etc.
Restoration of road surface after completion of backfilling of the earth shall be a part of the work.
Premises of PHED/ULB shall be restored to planned superior premises, including greening and
beautification.
Supply and installation of calibrated flow meters at each DMA entry point.
There shall be provision of daily, weekly and monthly water and power audit, water balance, to check
consumption of energy per MLD for CWPH, SPS, STP wastages of water and power. Separate energy
meters shall be provided for lighting/auxiliary equipment.
The towns under RSTDIP are using inclusive city-wide sanitation solution approach. While the
dense parts of the city will have sewerage network, the less dense parts of the city will be
strengthened on FSSM. The fecal sludge will be co-treated at the STPs, therefore the contractor will
be required to provide design and also implement the FSM also through co-treatment of FSM at the
STP.
6.1.13 WORK PLAN
The Contractor shall prepare the work plan for the execution of works, which includes procurement of pipes
before starting of the works. The Contractor shall submit the planning (Survey, reviewing and redesigning,
Construction, Quality control, and Commissioning) within 14 days after issue of letter of acceptance and take
RUIDP P a g e | 11of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
necessary approvals for the same. The planning’s shall be done on MS project or similar software and indicate,
resources such as material, manpower, cash-flow etc. to complete the works as per agreed time. The planning
shall include all allowances to guard against delays caused due to inclement weather or its effects (such as
floods or draughts), fire or industrial disputes, unless such events could not reasonably have been foreseen by
an experienced Contractor.
6.1.14 SIP- ACTIVITY SCHEDULE
SIP activities are divided into two parts: Cntractor shall be solely responsible for the SIP activities and
schedule.
Part 1:- Includes those activities which are part of Basic Engineering and essentially to be completed within
initial 120 days as per the schedule given in table below. Delays will attract delay damages as per the column
4.
Table 1:Sub-milestones for Preparation of the SIP
Target period for completion Delay
Sl damages per
Activity from contract
No. day
commencement date
1 2 3 4
A. Mobilisation on site 14 days
Preparation of Programme/ Work Plan as per
B. clause 8.3 of General Conditions of Contract 30 Days -
“Part A”
Conformation of topographic survey provided by Rs. 5,000 per
C. 30 Days
the Employer. day
Preparation of Base map, Ground verification of
satellite image, footprint dividing into properties, Rs. 5,000 per
D. 45 days
other physical features available and obtaining day
ground control points at site.
Review, modify (if required) and confirm Waste
water network system (including sewage
Rs. 5,000 per
E. pumping) design provided by the employer to 60 Days
day
achieve the performance indicators and the
objective of the project.
Review, modify (if required) and confirm Clear
Water Pumping main designs provided by the Rs. 5,000 per
F. 60 days
employer to achieve the performance indicators day
and the objective of the project.
Review, modify (if required) and confirm Water
supply distribution system design provided by Rs. 5,000 per
G. 60 Days
the Employer to achieve the performance day
indicators and the objective of the project.
Construction program including Mobilisation
plan for construction manpower, machinery, Rs. 5000 per
H. 75 days
material etc, detailed methodology of day
continuous monitoring etc.
Refurbishment methodology, planning, audit of
Rs. 5000 per
I. existing structures, requirement with justification 75 days
day
and detailing.
General arrangement, unit size calculation and
hydraulic diagram of Clear Water Pumping
Rs. 5,000 per
J. System, Pump Duty Conditions, CWRs, P&I, 85 days
day
SLD (E&M) diagram etc. - Contractor shall
submit his own design and drawings.
Process design, Genaral arrangement
drawings, unit size calculation and hydraulic
diagram, P&I, SLD (E&M) diagram of STP and Rs. 5,000 per
K. 85 days
SPS including sewage pumping main etc.- day
Contractor shall submit his own design and
drawings.
Compilation and submission of Final SIP for
L. 90 days -
necessary items
M. Scrutiny of SIP documents 100 days -
Rs. 10,000 per
N. Shortcoming improvement and submission 110 days
day
O. Approval of final SIP 120 days. -
RUIDP P a g e | 12of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Total amount of the delay damages due to delayed SIP implementation shall be part of the maximum delay
damages as per clause 9.6 “Maximum delay damages” Section-8: Particular condition of contract.Higher of
these shall be levied and recovered from Contractor.
Part 2:- Iinclude those activities which also need to be completed within 110 days of contract commencement
but are not so essential therefore no material damage if these are delayed and may be completed after 120
days, but delays in preparation of Part 2 documents and its approval shall not be considered reason for
contractor’s claim or extension of contract period or will not relieve the contractor from any responsibility of
completing the work in time.
Table 2: Milestones for Preparation of the SIP - Other sub activities
Sl Target period for completion from contract
Activity
No. commencement date
1 2 3
A. Geotechnical Investigations where components Upto 30 days but before commencement of
of water andwaste water systems will be works in that stretch.
constructed and along alignments where
pipelines will be laid.
B. House to house surveys for all properties with Upto 110 days but before commencement of
clear demarcation of properties. works in that stretch.
C. Detailed Design of all water supply and Waste Upto 110 days but before commencement of
water collection system components. work of that component.
I. Preparation of abstract of draft quantities and 110 days but before any contract variation.
cost estimates for the final designs.
J. Detailed O&M plan, Standard Operating Before commencement of O&M service.
Procedures and policies plan, Performance
measurement plan.
The Contractor shall submit the outcome of each sub activity for review of Employer’s Representative
immediately after completion of the activity. Employer’s Representative will review the outcomes on regular
basis and will submit their review comments within 21 days of receipt of the document. Contractor will develop
data bases for hydraulic and quality parameters and the daily flows at each delivery point including hourly flows
and total flow, treated water from Apni Yojana Shahwa lift Project, clear water pumping stations, clear water
distribution stations, raw/ treated wastewater produced at each Sewage treatment plant, and sewage flow at
pumping stations, pump operations, electric parameters, manholes data, overspill of sewers, condition of sewer
pipeline etc.
Contractor shall also submit the activity wise Monthly Reports for reviewing by the employer. Progress of all
activities will be reviewed on weekly basis for design part. Progress will be reviewd based on the progress
Reports on Monthly basis during construction part and daily basis during operations part.
In case of delays in meeting timelines of SIP activities, penalty as per the sums indicated in column 4 will be
imposed and recovered from due payments. If the delays that occurred in activity milestones are covered by
the Contractor within the stipulated or extended period for Compilation and submission of SIP in complete,
which is not attributable to Contractor, penalty imposed on account of such delays will be refunded.
RUIDP P a g e | 13of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
a) The Employer will provide the hydraulic model and the detailed design as mentioned in the SIP only in
single soft copy to the Contactor for verification/modification/review and confirmation.
b) Contractor shall get vetted all designs-drawings for sumpsum works from the reputed Engineering
colleges like MNIT/NITs/IITs/BITS at his cost.
c) The Contractor may recommend any changes, if required, to any or all of these documents to achieve
the performance quarantees and indicators with detail engineering and the Employer shall approve the
same after review.
d) The Contractor’s recommendation changes must only be based on technical grounds and utilizing the
BoQ items and quantities to the maximum extent.
e) The bill of quantities may only be amended to the extent that it reflects any approved changes to the
detailed design.
f) Once the Employer has approved any changes, or if recommended changes have not been submitted
by the due date, the Contractor shall be deemed to have accepted the hydraulic model, the detailed
designs and the bill of quantities in their entirety for the undertaking of the project and it’s guarantees
and performance indicators and shall then proceed to the construction stage of the contract.
6.1.15 MOBILIZATION PERIOD
During the 30 days mobilization period the contractor is required to:
Establish a furnished project office in Town.
Employ/mobilize the staff required for starting the preparatory work
Mobilize the survey teams
Establish Employer Representative office
Mobilize vehicles, office (furnished), equipment, communication equipment etc.
Familiarize himself with the project site condition after required consultation
Collect data and maps etc. and review designs of transmission system to fill all the SRs/ water
distribution stations and pumping systems etc.
Confirm/ conduct topographic survey to ascertain the levels, road width, existing services,
obstacles, etc.
Review the project report and the detailed project report provided by Employers Representative
including all designs and provisions for Town.
Prepare an asset inventory report, baseline water balance and strategy for improving services
with a focus on maintaining reservoir levels and providing and fulfilling the demand at each of
the delivery points in the water system and for monitoring continous supply to cusumers with
minimum pressure as specified in performance indicators.
6.1.16 METHODOLOGY FOR SITE ACQUAINTANCE
As part of this activity, contractor is required to:
i. Establish contact with all relevant stakeholders RUIDP, PHED, PWD, NHAI, Electricity
Distribution Company, Telecommunication companies and the local traffic police and other
government agencies including consultants under the RUIDP, become familiar with the town
system, and the applicable standards and guidelines for design, and with existing assets and
current on-going works in the Service Area. The contractor shall also study the works being
done by PHED/ULB and other departments being undertaken during the same period in the
same area.
ii. Satisfy himself with the nature and scope of work and the prevailing Site conditions.
iii. Be familiar with governing Laws and regulations in order to undertake studies and construction
activities under the Contract such as:
a. Environmental and social impact assessments and prevention, mitigation and
monitoring of impacts during construction;
b. Compensation for damages to property or services;
c. Occupational health and safety including workers compensation;
d. Signage for construction works and;
e. The permissions and co-ordination required from the different agencies
iv. The Contractor shall review and validate the Detailed Project Report of the project which will
enable him to prepare SIP:
a. in line with the Detailed Project Report (DPR) approved for funding,
b. in compliance with the Draft Master Plan – Vision 2031 for the Town,
c. in compliance to the terms and conditions of the Project and Loan Agreements among ADB,
Government of India and Government of Rajasthan and
d. in coordination with the on-going and programmed activities of PHED, MBSand GoR as the
case may be.
e. Any deviations to the document, data provided by RUIDP and consultation shall be
highlighted and got approved as part of the SIP.
RUIDP P a g e | 14of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
v. In case of any interventions proposed in the SIP, which are not part of the DPR or those
interventions which are part of the DPR but require improvement from conventional design
practices, the Contractor shall provide sufficient explanation and justification as to how
implementing such interventions would influence the achievement of the Performance
Standards stipulated in the document.
6.1.17 CONSTRUCTION PROGRAM
Contractor shall prepare Construction Program as part of SIP. Construction Program shall be in the form of a
Critical Path Method (CPM) Diagramshowing sequences, dependencies, durations and dates for execution of
all major items including sectional completion following the sub-divisions in theBills of Quantities for the
execution of the Works within the periods stated inthe Contract. It shall be supported by:
a. Construction Methodology and Data of the construction methods
b. Equipment Utilization Schedule
c. Manpower Utilization Schedule
d. Subcontracting Schedule
e. Mobilization/Demobilization Schedule
The CPM diagram incorporating the above mentioned schedules shall beprepared using Microsoft Project, or
similar approved project managementsoftware, and shall be presented in hard copy and electronic form to
theEmployer’s Representative as part of SIP.
In carrying out the Works due attention shall be paid to all measures whichcan reasonably be taken in order to
diminish the inconvenience which thework may cause to services and access to property.
6.1.18 SURVEY, MAPPING AND INVESTIGATIONS
The Employer shall provide colour satellite image. The contractor will digitize all the footprints, roads,
water bodies, electricity poles, water supply, sewerage, storm water, and other infrastructure components
as visible in the image. This data shall form the basis for an overall development of Geographic Information
System in desire of water supply and sewerage facilities and all consumer connections. A detailed
topographical survey of the area shall be utilized and the spot levels and the contours at 0.5 m interval shall
be and GIS based digitized map in ArcGIS shall be prepared.
6.1.18.1 TOPOGRAPHICAL SURVEY
Topographical Survey will be provided to the Contractor by the Employer. The contractor shall confirm this
topographical survey and modify, if required, at his cost. Contractor shall utilize the same for designing of
whole system including GIS Development and mapping, of the following works but not limited to; Proposed &
Existing Componetns of the town.
Reference bench marks for RL shall be adopted as fixed by Survey of India Department, but the contractor
shall not hold the confirmation of survey if time is required to get the GIS bench mark. Confimation of survey
may be done with the TBM provided and value can be confirmed with the GIS bench mark but not later than
the SIP schedule.
The contractor shall identify the number of crossings required for laying project pipe lines underany
drain/canal/NH/SH/ railway line/oil & gas pipe line etc.
Contour mapping at 0.5m intervals or as instructed by the Employer’s Representative for all the components
included in the Scope of Work, preparation and submission of the layout plan, elevation and cross-sections
for the buildings, structural design and drawings, foundations and associated civil and pipeline works shall
be done by the contractor. The Contractor has to provide large scale coherent drawings for all units to scales
of 1:1000 for plan layouts, 1:100 for plans and sections and 1:20 for details and other scales as appropriate
subject to prior approval of the Employer’s Representative. Soil investigation shall be carried out by the
contractor before starting the works.
6.1.18.2 GEOTECHNICAL SURVEY
a) The contractor shall submit credentials of the agency to be engaged for this work, to Employer’s
Representative for approval. The contractor shall assess type of soil, strata, ground water level
and other required indicators and establish soil properties while doing excavation for foundation of
structures and submit the same to the Employer’s Representative.
b) Conducting required soil / strata investigations as per specifications for proposed pipe networks,
in all type of soil conditions.
c) Detailed Geo-technical investigation required for proper structural design and execution of the
various component of the project shall be done by the contractor at site location and other civil
works, soil characteristics (bearing capacity, chemical analysis, soil resistivity) in order to
decide the dimensions of the foundations of the buildings and other structures. Additionally,
he has to assess the type of soil, the strata, the level of ground water and other indicators, if any,
and establish soil profiles and submit these to the Employer’s Representative for inspection
d) Special attention is required to determine the corrosive nature of soils or contaminated soil where
pipes are required to be laid below ground as well as for foundation of structures.
RUIDP P a g e | 15of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 16of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Shop
1. Grossary shop
2. Medical
7. General store
3. Cloth - Readymade garment
8. Tea - Pan shop
9. Hair saloon - Beauty parlour 0.
4. Vegetable - Fruits shop
10. Electronic shop No
11. Electrical shop shop
5. Book - Magazine -
12. Other
Stationnary shop
6. Sweet - Bakary shop
A18. Property Structure 1. Kutcha 2. Temporary 3. Constructed
A19.1 Type of water
1. Domestic 2. Non-Domestic 3. No connection
connection
A19.2 No Connection ________ no of connection
A20. Govt. Drinking Water
1. Muncipal Water Supply 2. Hand Pump 3. Public Stand Post
Source
A21. Private Water 1. Open Well 2.Bore Well 3.Neighbours 4. None 5. Tanker
Source 6. Handpump 7.Other
1. Under Ground Tank 2. Over Head Tank 3. Both
A22. Storage Facility
4. OGT 5. None
A23. Service Area by
1. Yes 2. No A24. Connection Requirement 1. Yes 2. No
Pipe
A25. Willingness for 24
1. Yes 2. No A26. If yes, ________Rs Per month
hrs. water supply
RUIDP P a g e | 17of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 18of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 19of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 20of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
The Contractor shall submit complete detailed design calculations of each of the components such as
substructure and superstructure together with general arrangement drawings, construction drawings and
explanatory sketches as required by the Employer’s Representative. Separate calculations for
substructures or superstructures submitted independent of each other shall be deemed to be incomplete
and will not be accepted by the Employer’s Representative.
The design considerations described in Employer Requiremen are the minimum basic design requirements
any particular requirement shall be designed for the satisfactory performance fulfilling the functions for
which the same is being constructed. The Contractor shall also check the stability of completed
structures/system to be used for the project.
The Contractor shall submit to the Employer’s representative, all required drawings, designs, equipment
data, as applicable. These shall include. These drawings/data having been corrected or amended as
necessary based on the comments shall become the 'Approved' drawings/data to be used for construction.
The Contractor shall, to the maximum extent practical and feasible, endeavour to standardize on the
manufacturing and supply of Plant and equipment so as to minimize the maintenance requirements.
The Contractor shall ensure that his designs are "maintenance friendly" and that all items of Plant and
equipment are designed and installed in a manner which will facilitate routine and periodic maintenance
operations.
Contractor shall provide an Indemnity Bond for all strcutures constructed under this project (lumpsum
items) that he has designed, build and completedthe project components (lump sum items) in accordance
with the employer’s requirement and specifications to the satisfaction of the employer’s representative
(caused by fire accident, mob violence, attack from the air or strikes of workmen or other major
disturbances only excepted), then, and in such an event the above-written bond shall be void, but
otherwise it shall remain in full force and virtue upto 10 year operation and maintenance period. If any
structural failures occur during above said period, contractor shall be fully responsible, and cost of
correction of defects shall be recovered from the contractor.
6.1.20.4 FUNCTIONAL DESIGN SPECIFICATION (FDS)
The Functional Design Specification (FDS) shall be submitted to the Employer within 3 months of the award of
contract and approved before manufacturing and purchasing commences.The system vendor and/or Contractor
shall include the following as a minimum:
1. Project Overview, design concept, criteria and system architecture
2. Details of associated equipment.
3. Plant Operating Screens (mimics)
4. Instrumentation Design Specifications
5. Quality Plan.
6. Outline of acceptance test procedures (FAT & SAT).
7. Implementation program for manufacture, installation and commissioning.
8. Manufacturer’s literature for each item of equipment supplied.
9. Outline of factory and site acceptance test procedures
6.1.20.5 GENERAL DRAWING REQUIREMNETS
Under this contract broadly following drawings has been classified:-
1. Tender Drawings.
2. Employer Drawings.
3. Design Drawings.
4. Construction Drawings.
5. Working drawings.
6. As-Built Drawings.
7. Record Drawings.
All drawings shall be on A1/A2/A3 sheets, with title blocks approved by the Employer, Signature of the
Contractor’s authorized representative to indicate the drawings have been checked prior to submission. The
text of all drawings and documentation provided by the Contractor shall be in the English Language.
6.1.20.5.1 TENDER DRAWINGS
These Drawings are provided with the bid document for the tender purpose only and canot be used for the
construction purpose. Construction drawings shall be as per SIP.
6.1.20.5.2 EMPLOYER DRAWINGS
The Drawings provided by the Employer’s Representative, are called Employer’s Representative’s Drawings.
They may be modified or added to as per SIP.
The proposals shown on the Employer’s Representative’s Drawings are based on information available prior to
preparation of the Tender Documents. All levels indicated or proposed are based on survey information
previously available but will need to be revised subject to the results of survey and site investigation carried out
by the Contractor during SIP.
6.1.20.5.3 DESIGN DRAWINGS
RUIDP P a g e | 21of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
It shall be the Contractor's own responsibility to prepare such Design Drawings and shall be submitted to
Employers’representative for approval. These drawings shall be prepared by the contractor for both Type-1 &
Type-2.
Any changes or modifications to the Drawings that the Employer’s Representative considers necessary shall be
made by the Contractor promptly and the drawings resubmitted for approval.
Drawings shall include, but not be restricted to, pipeline plans and profiles, reinforcement detail drawings and
bending schedules, equipment drawings, drawings for approval of equipments, equipment installation drawings,
shop drawings for structural steel and miscellaneous metal work, and drawings for other work for which the
Employer’s Representative's approval is required.
All dimensions shall be in SI units and each drawing shall be properly identified by a drawing head and a
numbering code in the form prescribed by the Employer’s Representative after contract commencement.
Any changes or modifications to the Drawings that the Employer’s Representative considers necessary shall be
made by the Contractor promptly and the drawings resubmitted for approval.
Component wise minimum drawing and design requirement are given in document control index provided with
the tender document. Contractor shall rview these requirements and will submit the DCI with modification or
addition within 14 days of date of NTP. If Contractor fails to submit the DCI within specified time then provided
with bid document deemed to be accepted by the contractor. DCI can be modified at any point of time based on
additional requirement assessed by the contractor and approved by the Employer Representative.
6.1.20.5.4 CONSTRUCTION DRAWINGS
It shall be the Contractor's own responsibility to prepare such construction Drawings. Work shall not commence
on an individual structure or facilities until the relevant Drawings have been approved by the Employer’s
Representative.
Approval of final Design Drawings will be given by the Employer’s Representative in the form of a stamp
"Released for Construction" together with the date and signature of the authorized representative. Only those
Drawings carrying the signed and dated stamp shall be used for execution.
Copies of all such approved Drawings together with one unreduced transparency shall be supplied to the
Employer’s Representative by the Contractor immediately after approval. The cost of preparing and providing
all Drawings shall be included in the Contract Rates.
If it would be found at any time after approval has been given by the Employer’s Representative to a Drawing
submitted by the Contractor that the said Drawing does not comply with the terms and conditions of the
Contract or that the details do not agree with the Drawings previously approved, such alterations and additions
as may be deemed necessary by the Employer’s Representative shall be made therein by the Contractor and
the work carried out accordingly without entitling the Contractor to extra payment on account thereof, except
where such alternations and additions are to be made in direct consequence of written order by the Employer’s
Representative to vary the Works. Contractor shall be wholly responsible for correctness of all the drawings and
designs for all the components of the project.
No examination by the Employer’s Representative of neither any document submitted by the Contractor or the
Contractor’s neither Drawing, nor the approval expressed by the Employer’s Representative in regard thereto,
either with or without modificationshall absolves the Contractor from any liability imposed upon him by any
provision of the Contract. Notwithstanding the Employer’s Representative's approval of the Drawings the
Contractor shall be responsible for any dimensional or other errors.
6.1.20.5.5 WORKING DRAWINGS
It shall be the Contractor's own responsibility to prepare Working Drawings as he may require for the proper
setting out and construction of all structures and facilities. These drawings are required for the pipe line works
mainly. For structures the construction drawing may be used as working drawings if no deviation found at site.
These drawings shall be released as per execution planning of the construction activities in each
lane/street/section as per direction of Employers’representative in line with approved construction drawings and
design.
These drawings shall include the following minimum details
S. No. Description Detail
Distribution system - Layout of the water supply line, location
house sewer connections and water meter, step valves,
pressure transmitters, DMA entry point BFM, FCV etc.
1 Water Suupply
Pumpinng/transmission mains - Layout of
pumping/transmission mains, location of Air Valve Scour Valve,
Thrust Blocks etc.
Plan showing Building line with properties, Layout of Sewer
pipe line, sewer property connections, existing road surface
(type and width from centre line), CD works, location of mahole,
2 Sewage
sewer property chambers, vent shalfts, drop manhole, L-section
showing ground level, invert level, manhole top level based on
proposed road restoration etc.
RUIDP P a g e | 22of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 23of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
works in the version of software available with the Employer. Files submitted shall be in
editable format with all supporting/background files.
2. Print copy (3 Copies) of the contents as submitted in the CD/DVD.
6.1.20.7 APPROVAL PROCESS OF DESIGN AND DRAWINGS
Contractor shall get vetted all designs-drawings for lumpsum works from the reputed Engineering colleges like
MNIT/MBM/NITs/IITs/BITS at his cost. Vetted design and drawing shall be submitted to Employer’s
Representative for final approval. During design build period contractor’s designer shall attend the
Employer/Employers representative office as and when required.
6.1.20.8 FINAL SUBMISSION FOR APPROVAL & RELEASE OF CONSTRUCTION DRAWINGS
After making compliance of all the observations of Enigneering colleges and Employers’ Representative the
contractor shall submit the final design calculation and Good for construction drawings of both type-1 and type2
as follows:-
1. Two (2) set of CD/DVD containing electronic files relevant in editable format.
2. Print copy (6 Copies) of the contents as submitted in the CD/DVD. Prints to be submitted on
A1/A2/A3 Size Sheet as a minimum or A0 Size Sheet as required by the Employer’s
Representative. These drawings shall be legible.
3. All modifications or revisions to drawings shall be clearly indicated and the revision reference
changed.
4. Drawings affecting work by other disciplines shall be provided to the Employer, within 6 weeks
from the date of enterprise.
The Employers’ represnetativive shall issue the final approved drawings as the construction drawing/ working
drawing by mentioning “Released for Construction”.
6.1.20.9 WORKING DRAWINGS
After approval of design drawings and release of construction drawings contractor will submit the working
drawings as specified in employer requirement as follows:-
1. One set of CD/DVD containing electronic files relevant in editable format.
2. Print copy (3 Copies) of the contents as submitted in the CD/DVD. A2/A3 Size as required by
the Employer’s Representative and should be handy dunring working at site for day to day
use. These drawings shall be legible.
6.1.21 DELIVERABLE DOCUMENTS FOR SIP
(i) Design should be prepared including sectional completion requirements;
(ii) Detailed design, drawings and cost estimates of works;
(iii) Construction Program, Methodology and timelines for implementation should be in line with the
Employer’s intentions;
(iv) Detailing of integrated Contract Management Information System by using latest software like
Primavera, MS project , data capture, management and reporting structures, protocols including
all related hardware, software, installation;
(v) Contractor Personnel Deployment Plan;
(vi) Construction Plant and equipment deployment plan;
(vii) Cash-flow for the entire contract with sectional completion break up;
(viii) Asset Replacement Schedule with justification;
(ix) Detailed methodology for continuous monitoring of the performance of the Contractor in achieving
and maintaining the Performance Standards for release of the eligible Operating Payments;
(x) Compliance matrix of contract and service requirement, OandM requirement and other
requirement like social, environmental, resettlement etc and;
(xi) A separate Design Basis Report for all project components shall be prepared and submitted for
due diligence;
6.1.22 SIP IMPLEMENTATION
The Scope of Services during the implementation Period shall essentially comprise of implementing the
approved SIP based on the hydraulic model prepared for water distribution based on DMA approach and
sewage system. SIP will be implemented in accordance to international best practice and industry standards
and sufficient care shall be taken by the Contractor in minimizing supply interruptions, traffic disruptions and
ensuring good and timely communications with the Consumers in the Service Area. During work execution,
contractor would be required to inform the residents, say of a particular street, well in advance about the type of
work, inconvenience expected, timelines for various works, etc. Contractor has to have a strong Public
Relations and Social Outreach Team (SOT). Contractor will plan sequencing of activities to synchronize sewer
works and water pipeline works to minimize the road excavation and restoration in the streets which will have
both pipelines.
RUIDP P a g e | 24of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
All the Works and interventions proposed as part of the SIP shall be in conformity with the Specifications set out
in the Employer’s Requirements. Implementation of pipe network and all allied works including house service
connection in a given street / road shall be taken up simultaneously so that the people living in the area are not
affected multiple times.
6.1.23 CONFIDENTIALITY
The Contractor shall keep confidential and shall not, without the written consent of the Employer/Employers
Representative, divulge to any Third Party any documents, data or other information arising directly or indirectly
from the performance of Services under the Contract, whether such information has been furnished prior to,
during or following termination of the Contract. Notwithstanding relevant Clause to the General Conditions of
Contract, the Contractor may furnish to its Sub-Contractors such documents, data and other informationto the
extent required for the Sub-Contractors to perform their work under the Contract, in which event the Contractor
shall obtain from such Sub-Contractors an undertaking of confidentiality similar to that imposed on the
Contractor.
The Contractor shall not use such documents, data and other information received from the
Employer/Employers Representative for any purpose other than the Services as are required for the
performance of the Contract. The Contractor shall not publish, permit to be published, or disclose any
particulars of the Services, Site or The Works in any trade or technical paper or advertising materials without
the prior written consent of the Employer/Employers Representative.
6.1.24 CODES AND STANDARDS
Wherever references are made in the Contract to codes and standards, in accordance with which the Contract
shall be executed, the edition or the revised version of such codes and standards 30 days prior to the
Submission Deadline shall apply unless otherwise specified. During Contract execution, any changes in such
codes and standards shall be applied after approval by the Employer / Employers’ Representative.
6.1.25 PRE-CONSTRUCTION SURVEYS AND SETTING OUT
The Contractor shall verify all measurements and be responsible for their correctness. Any differences which
may be found between actualmeasurements and the dimensions given in the Contract Documents shallbe
submitted to the Employer’s Representative, in writing, for consideration and directivesbefore proceeding with
the execution/Works.
Permanent benchmarks, at least four in every Kilometre shall be fixed, by the contractor, before starting any
work in any section. These benchmarks shall be fixed away from the field of work so as not to be disturbed
during the execution.
The Contractor shall survey the site before excavation and set out all lines and establish levels for various
works such as grading, basement, foundations, plinth filling, roads, drains, cable trenches, pipelines etc. Such
survey shall be carried out by taking accurate cross sections of the area perpendicular to established
reference/grid lines at 5m in case of buildings and 30 m in case of roads and pipe lines works intervals or
nearer, if necessary or instructed by the Employer’s Representative, based on ground profile and thereafter
properly recorded.
Site benchmarks shall be accurately and safely established, maintainedand removed upon completion of the
Works to the satisfaction of the Employer’s Representative. The Employer’s Representative will indicate the
position, co-ordinates and elevationof bench marks near the works, as shown on the Drawings.
The Contractor shall prepare a plan detailing the location of the bench marksand keep this up-to-date
throughout the period of the Contract. Reproduciblecopies of the plan so prepared shall be supplied to the
Employer’s Representative, as andwhen he may require.
The Employer’s Representative reserves the right to order levels, considered necessary forthe full and proper
supervision and measurement of the works, to be takenat any time.
Before the Works, or any part thereof, are commenced, the Contractor and the Employer’s Representative shall
together make a complete survey, and take levels, of theSite and agree on the dimensions and elevations upon
which setting out ofthe Works shall be based.
These levels shall be related to the bench marks and shall be plottedand drawn up by the Contractor. After
agreement of the drawings, whichshall be signed by the Employer’s Representative and the Contractor, these
levels shall formthe basis of setting out of the Works.
The Contractor shall be responsible for the true and proper setting out of theWorks in relation to reference data
given on the Drawings and shallaccurately set out the positions, levels and dimensions of all parts of theWorks.
Any delay or loss resulting from errors in the setting out of the Works shall be the responsibility of the
Contractor.
Setting out shall be reviewed by the Employer’s Representative before commencing theWorks, but any
approval shall, in no way, relieve the Contractor of hisresponsibility for the correct execution of the Work.
6.1.26 SURVEY EQUIPMENT AND FIELD ASSISTANCE TO THE EMPLOYER’S REPRESENTATIVE
The Contractor shall make available to the Employer’s Representative required survey equipment, suitably
educated and trained survey assistants and labourers for use on and about the Site in sufficient numbers and at
all reasonable times. The above mentioned equipment shall be the property of the Contractor upon the
completion of the Contract.
RUIDP P a g e | 25of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Preparation of L-sections based on survey along the proposed pipeline alignment and submission of L-section
of the proposed pipeline to be laid for approval of Employer’s Representative. The L-section shall indicate
ground levels, invert levels, depth of cutting, working pressure, co-ordinates of HGL, along with a route key-
plan. The contractor shall have to submit the plan showing all nearbystructures like buildings, shops, Electric
poles, hand pump, fields, River, Bridge, Nallah, Canal & any important structure along with L-sections while
submitting as built drawings.
6.1.27 GIS DATA CREATION
In parallel with the preparation of as-built drawings, the Contractor shall produce GIS data of the constructed
works. The contractor conducts all necessary survey work, and shall ensure that vertical and horizontal
measurements shall be captured at an accuracy of +/- 0.1m, using the most suitable and cost-effective field
data collection technology and methodology. All horizontal and vertical survey measurements will be referenced
to the present Survey of India benchmarks.
The Contractor will survey the three-dimensional position (x,y,z) of all point and line assets constructed under
this project, e.g., pipelines, bridge crossings, manholes, house connections, chambers, valves, meters,
hydrants, plugs, reducers, and tees. Nodes shall be created to clearly delineate different pipe sections in terms
of material and/or diameter and to allow for future development of a hydraulic model in the GIS platform. Nodes
shall also require a three-dimensional position, and through this, the position of the ends of a pipeline segment
shall be defined. Point and line data (i.e., the pipeline) should be consistent with the attributes of the existing
Survey of India benchmarks. However, the Employer’s Representative and the Employer may require the
Contractor, at no additional cost, to create new attributes to include non-survey data, e.g., valve model, name of
the manufacturer, images or plans, etc. Prior to the field survey, the Contractor shall submit to the Employer’s
Representative, for approval, the GIS design in terms of themes, feature types and attributes.
The Contractor shall develop a checklist of QC checks for each type of deliverable and will be responsible for
ensuring that these QC checks are performed. The Contractor shall assign a GIS expert to manage the quality
review process. This expert shall be independent of the capture and production teams.
The Contractor shall be required to integrate the GIS deliverables with the existing pipe network data, i.e.,
ensure that the GIS data connects with any existing GIS system. This may entail revising GIS data of existing
pipes at connection points. GIS data for the project will be delivered in an ArcGIS compatible file geo-database.
Marking of assets on GIS Platform - The contractor shall submit geo-referenced AUTOCAD/Shape files
drawings compatible with GIS software, for the complete proposed and existing components in all respects
including but not limited to under this contract along with capturing of site plans. Location of all valves and
Tees, bends, junctions/Manholes/Chambers etcshall be determined using differential GPS of 0.5m accuracy or
better. Attributes of pipeline, like diameter, material, class etc., shall be linked with GIS, as directed by
Employers representative.
Table 9: : GIS Layerwise Database structure
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
Water Supply
1 Line WSP ID
2 Type
3 Nominal Size(Diameter)
4 Material
5 Flow (L/Sec)
6 Flow Direction
7 Velocity
8 Depth Of Pipe
9 Upstream Invert
WS PIPE LINE
10 Down Stream Invert
11 Pipe Class
12 Position (With Respective to Road)
13 Commissioned Date(MM/YYYY)
14 Administrative Area
15 DMA No
16 Sub DMA No
18 Status
19 Remarks
RUIDP P a g e | 26of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
1 Point Reservoir ID
2 Type (OHSR/ CWR/ GLSR)
3 Height
4 Capacity
5 Status
6 Construction Year
7 Ward No
RESERVOIRS
8 Status (existing/proposed)
9 X-Coordinate
10 Y-Coordinate
11 Water Supply Zone No.
12 No of DMA Covered
13 DMA Localities
14 Executing Department
1 Point Valve ID
2 Valve Type
3 Nominal Size(Diameter)
4 Valve Type by Function
5 No of Turns to Open
6 Source
7 Daily Operated Valve
VALVES
8 Operating Timings
9 Installation Date
10 Ward No
11 DMA No
12 Elevation
13 X-Coordinate
14 Y-Coordinate
1 Point Hydrant ID
2 Main Valve Type
3 Noninal Size (Barrel Diameter)
4 Nozzle Dia
5 Seat Dia
6 FIRE HYDRANTS Installation Date
7 Ward No
8 DMA No
9 Elevation
10 X-Coordinate
11 Y-Coordinate
1 Point Pump ID
2 Manufacturer
3 Voltage of Motor
4 Pump make
PUMP
5 Capacity
6 Head
7 Discharge
8 Type
RUIDP P a g e | 27of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
9 Pump Type
10 RPM
11 Source
12 Administrative Area
13 Status
14 DMA No
15 X-Coordinate
16 Y-Coordinate
1 Point Flow Meter ID
2 Type
3 Administrative Area
4 Installation Date
5 FLOW METER Size
6 DMA No
7 X-Coordinate
8 Y-Coordinate
9 Elevation
1 Point Meter ID
2 ConsumerNumber
3 Meter Size
4 Meter Type
5 Meter Make
6 Monthly Consumption(Units)
7 Measurement Date
8 Previous Reading
DOMESTIC METER
9 Present Reading
10 Installation Date
11 Ward No
12 DMA No
13 X-Coordinate
14 Y-Coordinate
15 Elevation
17 Remarks
1 Point Pt Id
2 Date Of Survey
3 Ward No
4 DMA No
PUBLIC TAPS
5 Pt Type
6 Pt Status
7 Leakage
8 Remarks
Sewer Line
1 Line SWP ID
2 Type
3 SEWER PIPE LINE Material
4 Nominal Size(Diameter)
5 U/s Connecting Manhole
RUIDP P a g e | 28of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
6 D/s Connecting Manhole
7 Flow Direction
8 GL at U/s MH
9 GL at D/s MH
10 Position (With Respective to Road)
11 Length btw Manholes
12 Installation Date
13 Ward No
14 Status
15 Remarks
1 Point MH ID
2 Access Diameter
3 Invert Elevation
4 Type of MH
5 Installation Date
6 Construction Material
MAN HOLE Manhole Cover
7 Ward No
8 X-Coordinate
9 Y-Coordinate
10 Ele top of MH
12 Status
13 Remarks
1 Point DMH ID
2 Access Diameter
3 Invert Elevation
4 Type of MH
5 Installation Date
6 Wall Material
7 Size of MH
8 No of Connecting Manholes
DROP MANHOLE
9 Size of Connecting Pipe
10 Drop Depth
11 Ward No
12 X-Coordinate
13 Y-Coordinate
14 Elevation
15 Status
16 Remarks
1 Point PC ID
2 Location
3 No of Connections
4 PROPERTY Connecting Manhole No
5 CHAMBERS Installation Date
6 Ward No
7 X-Coordinate
8 Y-Coordinate
RUIDP P a g e | 29of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
9 Remarks
1 Point CP-CM ID
2 Location
3 CONNECTION PIPE No of Connections
4 FROM CHAMBER Connecting Manhole
5 TO MANHOLE Installation Date
6 Zone No
9 Remarks
1 Point STP ID
2 Capacity
3 Administrative Area
4 Construction Year
5 Status
6 STP Location
7 Coverage area
8 X-Coordinate
9 Y-Coordinate
10 Working Status
11 Executing Department
1 Point SPS ID
2 Capacity
3 Administrative Area
4 Coverage area
5 Depth of Sump
6 Invert Levels of Channel
7 Discharge Pipe Dia
8 Screen Type
9 No of Pumps Installed
10 SPS No of Pumps for Lean Flow
11 No of Pumps for average Flow
12 No of Pumps for peak Flow
13 Altenate arrangement to Electricity
14 Construction Year
15 Status
16 X-Coordinate
17 Y-Coordinate
18 Elevation
19 Executing Department
1 Point EDP ID
2 Location of Discharge Point
3 Use of Effluent
EFFLUENT
4 Quality of Effluent
DISCHARGE POINT
5 Ward No
6 X-Coordinate
7 Y-Coordinate
1 PLANTATION IN Point PL_ID
2 STP No of Plants
RUIDP P a g e | 30of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
Road Networks
1 Line Rs ID
2 Rs Length
4 Right Of Way Width
5 Carriage Way Width
6 Road Name
7 Road Type
8 Footpath (Yes/No)
9 ROAD_SEGMENTS Foot Path Width
10 Traffic Volume
11 Road Material
12 Road Condition
13 Accident Info
14 Total No Of Trees
15 Ward No
16 Remarks
1 Line Bd ID
2 Date Of Survey
3 Ward No
4 Road Geo Id
5 Bd Type
6 Bd Length
BRIDGE
7 Bd Width
8 Construction Material
9 Bd Condition
10 Year Of Establishment
11 Maintained By
13 Remarks
1 Line Culvert ID
2 Date Of Survey
3 Ward No
4 Culvert Type
CULVERTS
5 Construction Material
6 Condition
7 Year Of Establishment
9 Remarks
1 Line TS ID
2 Date Of Survey
3 Administrative Area
TRAFFIC SQUARE /
4 JUNCTION TS Type
Number of Connecting roads(3/4/5
5
etc)
7 Remarks
OTHER BASE MAP FEATURES
1 Poly Ward No
2 WARD ,ZONE Area
3 BOUNARY Population 2001
4 Population 2011
RUIDP P a g e | 31of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
FEATURE
S. No. LAYER NAME FIELD NAME
TYPE
5 Projected Population 2030
1 Line Name
STREAMS
2 Type
1 Poly Name
WATER BODIES
2 Area
1 Line Name
CANALS
2 Length
1 Line Name
2 RAILWAY LINES Type
3 No of Lines
1 Lines Elevation (In Meters)
CONTOUR ( 0.5 m)
2
OTHER UTILITY FEATURES
1 Point Tp_Id
2 Date_Of_Survey
3 Ward_No
4 TELEPHONE_POLE Locality
5 Tp_Material
6 Maintainted_By
9 Remarks
1 Point Ep_Id
2 Date_Of_Survey
3 Ward_No
4 Locality
5 ELECTRIC_POLE Ep_Material
6 Ep_No
7 Street_Light
8 Street_Light_Type
10 Remarks
6.1.28 UPDATING DRAFT INITIAL ENVIRONMENTAL EXAMINATION (IEE) AND RESETTLEMENT PLAN
(RP) AND IMPLEMENTATION
Upon completion all detailed design, the Contractor will update the draft IEE and EMP for the Project, contained
in Annexure A, to reflect the changes, submit the updated IEE and EMP to the Employer for review and
submission to respective authorities.
Upon completion of all detailed design, the Contractor will update the draft RP for the Project, contained in
Annexure B, to reflect the changes, submit to the Employer for review and submission to respective authorities.
Contractor will implement the IEE and RP in addition to updating it. The Employer Representative will closely
monitor the contractor for compliance with the updated IEE and RP.
Contractor will ensure that the requirements for (1) updating all safeguards documents following detailed
design, (2) submitting them to respective authorities for endorsement prior to implementation, (3) implementing
them, and (4) no commencement of physical works prior to the implementation of RP in that stretch.
6.1.29 SOCIAL OUTREACH TEAM
Contractor will have community outreach team for community involvement and participation in all components
of the project. This team will work in close coordination and assistance with Employer representative. The main
objectives of social out reach tema are:
1. To assist ensure community involvement during implementation of all components of the project
activities.
2. To create awareness among community regarding, environmental health, understanding of cost
recovery issues and accessibility to the Project, all of which will lead to maximization of Project
benefits and enhanced sustainability through improved community involvement.
RUIDP P a g e | 32of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
3. To initiate dialogue among community members to seek support for implementations of project
activities and to participate in decisions that affect their daily lives, like - resettlement plan for affected
persons, excavation, taking/shifting house service connections, road restoration etc.
4. To provide current and useful information on project, practices and responding to public needs.
5. To give information to Employer representative about the coming marriage or family functions of the
residents in any street so that planning of the construction activity can be done.
6. Ensure the approach to every house during excavation.
7. To give the daily feedback to the Employer representative received from site.
6.1.30 SCOPE OF OPERATION AND MAINTENANCE PHASE
The Operation Services are divided in 2 categories.
Category – I:O&M of Assets commsioned during Design Build period.
Category – II: O&M of all Assets commissioned on completion of Design Build.
The Contractor will be required to operate and maintain the constructed and existing assets in such way to
meet the performance requirements and as agreed upon during the SIP stage.
From the design, build completion date (which shall also mean sectional completion date), the Contractor
shall supply potable water to the legal and authorized Consumers and collect and dispose off the sewage as
part of sewerage services through the laid and commissioned sewerage system.
Contractor shall be responsible for operation, maintenance and management of the entire water supply and
waste water services under this contract in service area as detailed in water supply and waste water sector.
6.1.30.1 OPERATING OBLIGATIONS FOR THE WORKS
The contractor shall operate and maintain the entire works and all other allied works under this contract, for 10
yrs from the date of completion of Design-Build period.It is to be noted that Employer will bear only energy
cost and O&M costs (including diesel & lubricants cost for operation of diesel generator set in the event of
power failure), during trial run, commissioning, and Operation & Maintenance period. Within his quoted cost,
the contractor is to ensure that all guarantees as given in Schedule 7, Section 8 of this bid document are
maintained during the DLP:
The contractor shall provide on the job training to the Employers staff as per specifications.At the end of the
one year of O&M period, an assessment of the condition of the plant will be done by Employers
Representative and based on the assessment, the contractor shall, at no extra cost to the Employer/RUIDP,
repair/ re-condition/replace all the faulty civil works, electrical & mechanical instrumentation, equipments in the
concluding month of the O&M period to a condition so that they are in running condition.
Activities during O&M for water supply components shall include following components but not limited to that,
CWR, CWPH, TWs, OWs, clear water rising main, Direct Pumping stations, Distribution system, consumer
meterand service connections, STP, SPS, Sewer network, sewer and water connection for the new habitation
in the O&M period.
In water supply all the existing facilities including pump houses, CWRs, ESRs, GLSRS, pumping mains,
pumps, tubewells, open wells, electro-mechanical works etc. shall also be operate and maintained by the
contractor used in the water supply scheme of the town from source point to the consumer end for 10 year.
6.1.31 OPERATING AND MANAGEMENT RELATED DELIVERABLE
6.1.31.1 BEFORE START OF OPERATION AND MAINTENANCE PERIOD
(i) Emergency Response Plan (ERP); this shall also separately include response plan for effective
emergency rectifications against any major break downs occurring from the source up to the
service area of this contract;
(ii) Public Relations Plan;
(iii) Standard Operating Procedures (SOPs) for routine operations and emergency responses;
(iv) Water Quality Monitoring Program;
(v) Energy optimization program;
(vi) Detailing of an Integrated Management Information System (MIS) including its architecture, data
capture, management and reporting structures, protocols including all related hardware, software,
installation, and operation and maintenance requirements; and
(vii) The computer hardware and software improvement plan for continued operation of the MIS,
instrumentation and SCADA.
(viii) Annual Mainteneace Schedule (AMS) shall include maintenance activities that should
be implemented in different spaces, structures, equipments, system done every year. This will be
in form of excel spread sheet with cover page report.
6.1.31.2 DURING OPERATION AND MAINTENEANCE PERIOD
(i) Annual Operating Plan (AOP) covering all operations, maintenance and management
requirements in the Service Area; this annual Operating Plan should be updated and
approved before the commencement of each year.
RUIDP P a g e | 33of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
(ii) A system efficiency report on Monthly basis for assessment of NRW in each DMA and half
yearly basis for assessment of Sub district NRW based on step test for each DMA. Every
system efficiency report shall include efficiency of all zones and step test results for the tests
performed during the period of reporting.
(iii) Transmission System extension/ expansion policy;
(iv) Periodic reporting plan including the formats for different performance reports;
6.1.31.3 OPERATION AND MAINTENANCE MANUAL
The contractor will submit an operation and maintenance manual, providing details of all the plant/ mechanical
/electrical / SCADA-Instrumentation facilities he supplies and give details of recommended maintenance
intervals and procedures.
6.1.32 PERFORMANCE INDICATORS
Performance indicators to show the performance of the individual towns and used to have an international
comparison of Water and Sewerage systems are indicated in Schedule 7 of Section 8 of the Bid document.
6.1.33 MAINTAINING PERFORMANCE STANDARDS
The performance standards for the Design Build works during the SIP implementation shall consist of i) quality
of work as per specifications and ii) The time line for completion as per the milestones defined in "Key time
periods and milestones". The liquidated damages will be levied for non-achievement of these milestones in
time, as per the provisions in Section 8: Particular Conditions of Contract.
The measurement of the quality of work will be as per the tests laid down in the specifications of various items
while the measurement of the achievement of milestones is based on the defined works and defined dates
given in “Key time periods and milestones"
Payment of operation services will be in accordance to the procedures in Schedule 5 – Contractor Payments
attached to Section 8: Particular Conditions of Contract. Operation service contract will be governed by
Performance Standards provided in Schedule 7 – Performance Targets and Measurement attached to Section
8: Particular Conditions of Contract.
6.1.34 METHODOLOGY FOR MEASUREMENT OF PERFORMANCE STANDARDS
The Contractor shall develop a robust methodology and framework for measurement and monitoring of
Performance Standards stipulated under the contract and proposed as part of the SIP. The Employer with the
assistance of the Employer’s representative or Auditing Body shall verify the same and upon agreement
between the Parties the agreed methodology shall form the basis for monitoring the performance of the
Contractor and apply the Non Performance Adjustments on the eligible Operating Payments in case of failure to
meet the performance standards.
6.1.35 ELECTRIC POWER CONSUMPTION GUARANTEES
The contractor shall ensure that the net power consumption in the plant should not be more than the figure so
guaranteed by the bidder. Damages payable by Contractor to Employer on excess consumption of net electrical
energy shall be equal to the actual cost of the excess energy used for Operation and Maintenance of the Works
under the Contract, based on the guaranteed consumption provided by the Contractor and the current rates
during operation and mainteneance charged to the Employer for electricity consumed.
6.1.36 EMPLOYER’S AUDIT
(i) Unless otherwise specified, atleast 10 Employer’s Audit per year for each of the Facility
operations shall be carried out, jointly by the Contractor and the Employer’s Representative
and shall include, without limitation, inspection and audit of the following (minimumt 3 listed
item per audit):-
a) Influent/Effluent quantities andcharacteristic;
b) General plant and equipmentconditions;
c) Spare partsconditions;
d) Storage of chemicals, dangerous goods and hazardousmaterials;
e) Storage ofconsumables;
f) Conditions of security and safety installations;
g) Site Cleanliness andHousekeeping;
h) Odour;
i) Noise;
j) Lighting;
k) Surfacewater;
l) Dust;
m) Vermin/insect;
n) Site Diary and Safety and Health Records;
RUIDP P a g e | 34of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
the Contractor fails to complete the remedial works to the satisfaction of the Employer’s
Representative within the specified time, the Employer is empowered to instruct the remedial works to
be carried out by other contractors and deduct the costs for such instruction from any payments due to
the Contractor.
(x) The Contractor shall make and maintain detailed records of all Facility maintenance work, which
shall remain readily available for inspection by the Employer's Representative.
(xi) In accordance with the Specification, the records of Facility maintenance work shall be submitted by
the Contractor to the Employer’s Representative on a monthly basis, and will be made available for
inspection by Contractor for bidding for any follow-on contract.
(xii) The Contractor shall maintain the Facility wholly in accordance with the requirements of the Contract
and the approved maintenance management plans in the Operation Plan. If the Contractor identifies
any possible alternative method of maintenance that may be more efficient he shall notify the
Employer accordingly. If any such change to the method is acceptable to the Employer, it will be
implemented in accordance with the relevant provisions of the Contract.
6.1.38.2 PREVENTIVE AND CORRECTIVE MAINTENANCE
(i) The Contractor shall be responsible throughout the Operation Period for the maintenance of the
Facility and parts thereof including all preventive maintenance, overhaul, repairs, rehabilitation,
renewal and replacement of Plant which at all times shall be maintained in good functional conditions
and to perform in accordance with the Specification.
(ii) The Contractor shall develop and implement specific preventive maintenance programmes for every
system, equipment, building and infrastructure of the Facility with the objective of maximizing their
availabilities as well as minimizing any unscheduled maintenance or emergency shutdown.
(iii) The scope and frequency of preventive maintenance shall meet the manufacturer’s recommendations,
as a minimum, and shall be adjusted with reference to conditions identified in the previous preventive
maintenance and any repair carried out recently.
(iv) The preventive maintenance programmes shall be incorporated into the Operation Plan and updated
whenever necessary in accordance with the Specification. The same shall be entered into the CMMS
in accordance with the Specification for monitoring.
(v) For the avoidance of doubt, the replaced items or parts upon maintenance or repair shall be regarded
as the property of the Contractor and at his disposal and/or removal off-site away of these items shall
be made known to the Employer’s Representative.
(vi) Scheduling of preventive maintenance which requires system or equipment shutdown shall ensure
that the ability of remaining system or equipment can meet the Operational Performance
Requirements and Environmental Performance Requirements.
(vii) The Contractor shall effect all necessary or appropriate maintenance with due diligence and
expedition. Conditions of the Facility shall be proactively managed with defects rectified within a time
frame agreed to by the Employer’s Representative. The Contractor shall rectify any defects identified
by the Employer’s Representative in accordance with the Conditions of Contract.
(viii) Preventive maintenance, corrective maintenance and the subsequent repairs, renewal or replacement
work shall be carried out in a safe manner, including the adoption of the appropriate safe work
procedures stated in the Safety and Health Plan.
(ix) The Contractor shall pay particular attention to the setup and use of temporary equipment / works
such as mobile lifting equipment, mobile access platforms, scaffolding, platforms and ladders, etc. All
relevant guidelines, Code of Practices and statutory requirements shall be strictly followed.
6.1.38.3 MAINTENANCE MANAGEMENT
The CMMS shall include functions for the creation and upkeep of work orders and maintenance records. The
database shall include the following information:
a) Preventive maintenance programmes of systems, equipment, building and infrastructure of the
Facility, which are used to generate work orders for preventive maintenanceautomatically;
b) Logs off system or equipment fault / breakdown and automatic generation of work orders for
corrective maintenance;
c) Date of inspection / maintenance (preventive or corrective) carriedout;
d) Names and positions of Contractor’s staff carried out the inspection / maintenance;
e) Logs off manual alterations of any operations records,etc;
f) Details of inspection / maintenance carried outincluding: -
Causes of maintenance
Maintenance procedures
Special gears / equipment used
RUIDP P a g e | 36of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Spare partsused
Equipment / partsreplaced
Any follow-up actions / recommendations (e.g. change of operational procedures,etc.)
The CMMS shall have functions to organize, sort and filter the maintenance records in the database as
required and perform statistical analysis and generate reports for performance monitoring.
The CMMS database shall be archived on a monthly basis. One electronic copy of the entire database shall be
stored on the Site for retrieval as necessary. Another backup copy shall be passed to the Employer’s
Representative.
6.1.38.4 CALIBRATION OF INSTRUMENTS AND MEASURING EQUIPMENT
(i) The Contractor shall maintain accuracy and reliability of all measurement facilities throughout the
Operation Period to enable correct and effective monitoring and control of the Facility.
(ii) The Contractor shall be responsible for the calibration and re-calibration as necessary of all
measurement facilities. All calibration work shall be carried out so as not to delay or disrupt the
Operation. Calibration frequency shall not be less than that recommended by the manufacturers of
the instruments or measuring equipment and in any case no longer than 12-month intervals. For
the avoidance of doubt, all costs associated with any agreed calibration shall be deemed to be
borne by the Contractor and included in the Operation Fees.
(iii) The calibration shall be carried out by an accredited testing and calibration organization consented
to by the Employer’s Representative. The results of calibration shall be made available to the
Employer’s Representative.
6.1.38.5 SPECIAL TOOLS AND SPARE PARTS
(i) During the Operation Period, the Contractor shall provide and maintain special tools and spare
parts in accordance with the Manufacturere’s Design.
(ii) The storage of special tools and inventory of spare parts shall be recorded and monitored in
accordance with the Specification.
(iii) At the expiry of the Operation Period, the Contractor shall handover to the Employer all special
tools and spare parts in accordance with the agreed list during SIP period.
6.1.39 ASSET MANAGEMENT
6.1.39.1 CONDITIONSURVEYS
(i) The Contractor shall engage with the Employer’s Representative to carry out Condition Surveys of
the Facility in the presence of the Contractor or the Employer’s Representative. The surveys shall be
carried out in the seventh month of the 3rd, 6th and 8th year of the Operation Period, unless
otherwise consented to by the Employer.
(ii) The scope of the Condition Survey shall include:
a) Inspection and auditing of manuals, schedules, reports, SCADA and CMMS records
forcompliance;
b) Visual inspection of all components, including Plant, buildings and structures for state of
maintenance andrepairs;
c) Inspection of performance records and performance evaluation of the plant and equipment in
operatingcondition;
d) Witness testing of the plant and equipment in operating condition, including the Performance
Tests specified in theSpecification;
e) Based on the above information, forming a view as to the general operation and maintenance
condition of the Plant, buildings and structures, with due regard to their service hours and/or
age;and
f) Making recommendation on enhancement of the operation and maintenance of the Facility,
whereapplicable.
(iii) The Contractor shall compile and submit a condition survey plan to the Employer for approval at least
45 days prior to commencement of the Condition Survey. The condition survey plan shall be prepared
in consultation with the Contractor to ensure uninterrupted Operation of the Facility. The condition
survey plan shall include the following information, as a minimum:
a) a programme showing the systems, equipment, structures, etc. which are included in the
Condition Survey;
b) detailed descriptions of precautionary measures, methodologies, procedures, timing for the
inspections, audits, measurements or tests to be carried out on each survey item;
c) effect on normal operation of the Facility including any reduction in redundancy or standby
capacity, with mitigation measures or temporary arrangements clearly stated;
d) any safety, health and environmental related issues;
e) details of any temporary work for the Condition Survey; and
f) contingency plan for emergency situations that may arise during the Condition Survey.
RUIDP P a g e | 37of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
(iv) The Condition Survey shall not commence until the condition survey plan have been approved to by
the Employer. The entire condition survey shall be completed within 1 calendar month.
(v) The Contractor shall prepare and submit to the Employer and the Employer’s Representative, a
detailed condition survey report within 28 days of the completion of the Condition Survey. The report
shall include: -
a) methodologies and findings of the survey;
b) identification of any damage or defects;
c) recommendation of rectification work required to satisfy requirements of the Contract; and
d) recommendation of enhancement to the operation and maintenance of the Facility.
(vi) In the event that the Employer considers, as a result of the Condition Survey and the Residual Life
Assessment specified in the Specification, if appropriate, that any part or parts of the Facility require
repair, maintenance, rectification or replacement to satisfy the requirements of the Contract, the
Employer will serve notice under the Conditions of Contract on the Contractor of the work necessary
to be carried out. The Contractor shall ensure that all such repair, maintenance, rectification or
replacement are completed within reasonable time and in any case not more than 90 days after
receipt of the Employer’s notice, unless otherwise consented to by the Employer.
(vii) Prior to the handing over of the Facility, the Contractor shall conduct an End-of-Contract Condition
Survey as specified in the Specification.
(viii) The Condition Surveys in the 6th and 8th years of the Operation Period shall include the Residual Life
Assessment as specified in the Specification.
(ix) For the avoidance of doubt, all costs associated with the carrying out and reporting of the Condition
Surveys shall be borne by the Contractor deemed to be included in the Operation Fees.
6.1.39.2 RESIDUAL LIFEASSESSMENTS
(i) The Condition Surveys in the 6th and 8th years of the Operation Period and the End-of Contract
Condition Survey shall include a Residual Life Assessment. The Residual Life Assessment shall be
carried out as part of the Condition Surveys by the Independent Surveyor.
(ii) The Residual Life Assessment shall benchmark the Facility against relevant international standards /
guidelines, and performance of similar facilities on a worldwide basis.
(iii) The Contractor shall include a separate section in the survey report specified in the Specification for
the Residual Life Assessment, to record the following: -
a) Residual life assessment methodology;
b) Standards, guidelines and references adopted;
c) Detailed descriptions of assessment carried out;
d) Findings of assessment; and
e) Recommendation of work required for the upkeep of the Facility in satisfactory conditions.
6.1.39.3 END-OF-CONTRACT CONDITIONSURVEY
(i) All requirements for Condition Surveys specified in the Specification and those for Residual Life
Assessments specified in the Specification shall apply to the End-of- Contract Condition Survey
unless otherwise specified.
(ii) The End-of-Contract Condition Survey shall be carried out at least 9 months but not more than 12
months prior to the expiry of the Operation Period to verify conditions of the Facility and ascertain the
residual life of the Facility.
(iii) For the avoidance of doubt, the End-of-Contract Condition Survey shall include a Residual Life
Assessment as specified in the Specification.
(iv) As part of the End-of-Contract Condition Survey, the Contractor shall carry out tests and provide all
necessary assistance to the Employers’ Representative to determine whether the Facility to be
handed over to the Employer is in good and serviceable condition suitable for continual use and
meets the residual life requirements as specified in the Specification.
(v) The Contractor shall compile and submit an End-of-Contract Condition Survey Plan to the Employer
for consent at least 60 days prior to commencement of the End-of-Contract
(vi) Condition Survey. The plan shall include tests and inspections requested by the Employer.
(vii) The Contractor shall prepare and submit to the Employer, and the Employer’s Representative, a
detailed End-of-Contract Condition Survey report within 28 days of the completion of the End-of-
Contract Condition Survey. The report shall include recommendation of work required to meet the
residual life requirements specified in the Specification.
(viii) In the event that the Employer considers, as a result of the End-of-Contract Condition Survey, that
any part or parts of the Facility require repair, maintenance, rectification or replacement to satisfy the
requirements of the Contract, the Employer will serve notice under the Conditions of Contract on the
Contractor for the work necessary and the work that becomes necessary during the remainder of the
Contract to be carried out and completed to the satisfaction of the Employer no later than 60 days
prior to the expiry of the Operation Period. In the interpretation of the End-of-Contract Condition
Survey, the Employer will have due regard for the obligation under this Contract on the Contractor to
RUIDP P a g e | 38of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
fully maintain the Facility that is to be handed over to the Employer in good and serviceable condition
suitable for continual use to the performance requirements of the Facility.
(ix) If in the opinion of the Employer, the Contractor has failed to carry out any work to hand over the
Facility in good and serviceable condition to the Employer for continual use at the expiry of the
Operation Period, the Employer may order such defects to be made good and deduct the Costs from
any payments due to the Contractor from this or any other contract the Contractor may have with the
Employer.
(x) After the remedial works carried out according to the notice served by the Employer after the End-of-
Contract Condition Survey, the Contractor shall carry out joint inspections with the Employer’s
Representative on the plant and equipment that has been maintained or replaced, including all
necessary tests to demonstrate that the requirements of the Contract have been met.
6.1.40 PERIODIC REPORTS
The Contractor shall prepare and submit periodic reports on different plans, progress of Works, performance
standards etc., including exceptional reports on emergencies if any. The reporting requirements are provided in
Table below. The Contractor shall as part of the SIP develop the required formats for the periodic reports and
also identify any critical reporting requirements in order to enable timely decision making by the Employer.
Table 10:Summary of Periodic Document/Reporting Requirements
Deliverable First Report Follow-up Tasks
Design Documents Submit designs not later Not applicable
than days specified in SIP
from the Contract
Commencement Date
Annual Operating Plan (AOP) Submit Annual Operating Submit AOP for subsequent years
Plan (AOP) not later than 60 not later than 90 days prior to end
days from the of previous year plan
Commencement Date
Standard Operating Procedures Submit report not later than Complete implementation and
(SOPs) for operation and 360 days after training 30 days before
management Commencement Date or at commissioning of first DMA, sewer
the time of commissioning network, STP & SPS and
whichever is earlier. subsequently whenever new
employees join for O&M.
Management Information Systems Submit report not later than Generate monthly reports from MIS
(MIS) 90 days after
Commencement Date
Operating Performance Report Submit OPR for any and To be submitted every month
(OPR); the OPR shall include: a every month before the 10th
detailed progress report on the day of subsequent month
implementation of the designs; commencing from the
monthly water account with details of commencement date
Bulk water supplied and received at
service area entry points and the
Bulk Supply effected; waste water
received at STP;revenue collection;
Performance Standards achieved or
maintained during the month; staff
details engaged at various centres;
exceptional reports on emergencies;
financial information on project cash
flows, grievance redressal of
consumers, Environmental and
Social Responsiveness etc.
Quarterly Performance Report Submit Quarterly Repeat for every quarter including
(QPR); the QPR shall include a brief Performance Report for any summary analysis of Bulk Supplies
summary of the relevant issues and every quarter before and lapses in revenue collection, if
detailed in the Monthly Performance 10th day of subsequent any.
Reports including a summary quarter commencing from
analysis of Bulk water supplies, the Commencement Date
Treated water and Sewage
Treatment and lapses in revenue
collection, if any.
Annual Performance Report (APR); Submit Annual Performance Repeat for every year
the APR shall include the annual Report for any and every
accounts, cash flow, and financial year before 20th day of
performance including summary subsequent year
RUIDP P a g e | 39of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 40of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
‐ Date andweather;
‐ Operationhours;
‐ Labour on theSite;
‐ Flow and quality records of influent andeffluent;
‐ Disposal records of treatmentby-products;
‐ Accidents andincidents;
‐ Instructions to theContractor;
‐ Comments by theContractor;
‐ Complaints received and actiontaken;
‐ Authorized visitors to the Site;and
(ii) The exact scope, form and layout of the Site Diary shall be agreed with the Employer from time to
time.
(iii) The Site Diary shall be in a printed proforma completed with one original and three copies:
a) Employer(Original);
b) Employer’sRepresentative;
c) Contractor;and
d) Filecopy.
(iv) The Site Diary shall be checked and signed by authorized personnel of the Contractor in accordance
with the consented Operation Plan. The completed Site Diary shall be made available to Employer’s
Representative for inspection not later than noon time on the following day.
(v) The Contractor shall keep appropriate records of all personnel employed at the Site. These
records shall be available for inspection by the Employer’s Representative at any reasonable time.
These records shall be kept available for inspection throughout the Operation Period.
(vi) The Contractor shall retain at the Facility a Construction Site Safety Manual or approved equivalent.
All accidents occurring to personnel during the Operation Period shall be recorded and reported to
the Employer’s Representative within two hours of the occurrences of the accidents.
6.1.40.7 SAFETY AND HEALTH RECORDS
The Contractor shall keep records on all safety and health matters as specified in the Specification and update
such records daily for inspection by the Employer’s Representative.
6.1.40.8 MONTHLY REPORT
The Contractor shall provide and present details, in the form of Monthly Reports, of operational data and
information in relation to the Operation of the Facility to the Employer in a systematic and concise manner.
Monthly Reports shall be submitted in duplicate to the Employer and the Employer’s Representative by the 14th
day of the month following the month to which the report relates. Typical required information and data shall
include, but not be limited to the following: -
6.1.40.8.1 PROJECT MANAGEMENT
‐ An updated organization chart which includes details such as number of employees in the Facility
by trades;
‐ Change of staffing;
‐ Summary of visits to the Facility;
‐ Performance Tests or Condition Surveys carried out and scheduled in the following month;
‐ Meetings held with the Employer, and other related authorities, etc.;
‐ Scheduled meeting in the following month; and
‐ Quantity and quality of influent and effluent, and a summary of problems encountered during the
month.
6.1.40.8.2 ENERGY CONSUMPTION, ENERGY RECOVERY AND POWER GENERATION DATA
Summary of energy consumption (fuel and electricity) of the Facility,
‐ Quantity of biogas produced and power generated;
6.1.40.8.3 INVENTORY AND CONSUMABLES DATA
‐ Quantities of chemicals, reagents, fuel and spare parts consumed;
‐ Stock level of chemicals, reagents, fuel and spare parts;
‐ A list of current suppliers for chemicals, reagents and additives and their contact details;
‐ Delivery records of all consumables.
6.1.40.8.4 ENVIRONMENTAL MONITORING DATA
RUIDP P a g e | 41of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 42of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 43of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 44of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 45of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
placed on edge, two at a time along the width of the stack. Clear distance between adjacent stacks
shall not be less than 0.8 m. Bricks of each truck load shall be put in one stack.
iv. Bricks of different classifications from strength consideration and size consideration (such as,
conventional and modular) shall be stacked separately. Also bricks of different types, such as, solid,
hollow and perforated shall be stacked separately.
Electrical & Mechanical equipment’s
i. All appliances/equipment’s shall be carefully stored under cover to prevent damage.
ii. Storage shall be done on firm, level and clear ground and wedges shall be provided at the bottom
layer to keep the stack stable.
iii. When accepting and storing appliances, advance planning shall be made regarding the sequence of
removal from the store to the assembly positions.
Fire Hazards
Causes of fire hazards at construction sites /store yards:
At any construction workplace fire hazards may take place due to the following:
i. Electrical short circuiting / Poorly installed temporary wiring,
ii. Gas cutting and welding,
iii. Defective heating appliances,
iv. Careless storage and handling of flammables,
v. Loose gunny bags, plastic bags, organic debris etc. and
vi. Careless smoking.
Protection against Fire:
i. A site engineer shall be assigned with the specific responsibilities of ensuring compliance with fire
safety provisions by contractors and also of coordinating with fire services and other agencies
concerned with fire safety.
ii. The storage yard shall be clear of any vegetation and debris prior to the storage of material and shall
be cleaned regularly.
iii. A canteen building or any other unit being source of fuel shall be located sufficiently away from stack
yard.
iv. Materials, like timber, coal, paints, plastic pipes etc. shall be stored in such a way that there may not
be any possibility of fire hazards.
v. Inflammable materials like kerosene, diesel and petrol, shall be stored in accordance with the
relevant rules and regulations so as to ensure the desired safety during storage. Stacks shall not be
piled so high as to make them unstable under fire fighting conditions and in general they shall not be
more than 4.5 m in height.
vi. Open flames, welding and cutting operations, wherever necessary, shall be carried out with stringent
precautions and under proper supervision. All combustible materials lying around shall be removed or
covered with wet gunny bags, tin sheets, etc. as welding sparks can fly up to 10 m. After completion
of such work the area shall be inspected.
vii. Electrical wirings shall be either PVC sheathed conductors or vulcanized rubber cables. All joints
shall be made in porcelain insulated conductors and the wiring shall not be permitted to trail on the
floor.
viii. Materials which are likely to be affected by subsidence of soil like precast beams, slabs and timber of
sizes shall be stored by adopting suitable measures to ensure unyielding supports.
ix. Materials liable to be affected by floods shall be suitably stored to prevent their being washed away or
damaged due to floods.
x. Stairways, passageways and corridors shall not become obstructed by storage of building materials,
tools or accumulated rubbish.
xi. Adequate number of appropriate type fire extinguishers shall be placed near vulnerable places which
are easily accessible. The extinguishers shall be available for immediate use at all times.
Extinguishers shall be sited in such a way that the user may not have to travel more than 15 m from
the site of the fire to reach the extinguishers.
xii. Recharging of fire extinguishers and their proper maintenance shall be ensured at prescribed time.
xiii. Watch and ward services shall be provided at storage sites during holidays and nights.
Apart from above following codes may be referred for further detailed specifications and reference:
IS 4082: Stacking and storage of Construction materials and Components at site – Recommendations
IS 7634: Plastics pipes selection, handling, storage and installation for potable water Supplies — code of
practice
IS 2190: Selection, installation and maintenance of first-aid fire extinguishers — code of practice
IS 13416: Preventive measures against Hazards at work places- recommendations (Part 5: Fire Protection)
RUIDP P a g e | 46of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 47of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 48of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
If the Employer’s Representative determines that proper provisions for safe traffic control are not being
provided or maintained, he may restrict construction operations affected by such defective signs or devices until
such provisions are established or maintained, or may altogether order suspension of the Work until a proper
traffic control is achieved. In case of serious or willful disregard by the Contractor of the safety of the public or
his employees, the Employer’s Representative may take necessary steps to rectify the situation and deduct the
cost thereof from monies due or becoming due to the Contractor. The Contractor shall be responsible for all
resulting delays.
The Contractor shall designate or otherwise employ personnel to furnish continuous surveillance of the traffic
control operations. The designated personnel shall be available day and night to respond to calls involving
damage due to traffic accidents.
At sections where traffic is in operation and when ordered by the Employer’s Representative, the movements of
the Contractor's equipment from one place of work to another shall be subject to traffic control. During rush
hours’ movement of larger vehicles, such as trucks, cranes, dumpers, etc. through main thoroughfare are not
permitted by the police. Spillage resulting from hauling operations along or across the road way shall be
removed immediately at the Contractor's expense.
The cost of road construction for detours will be paid separately but costs of traffic control is deemed to be
included in the rates for works.
6.1.52 PROVISION OF TEMPORARY SERVICES
When the execution of the Works requires the temporary disconnection of existing public utilities, the Contractor
shall provide the affected users with temporary services.
For water supply he may install temporary lines or arrange for regular supply by tankers. The amount of water
to be provided for the interruption period for a specific area shall be assessed by the Contractor. The Contractor
shall submit to the Employer’s Representative, for its approval, the recommended volume of water to be
provided.
When forced to disconnect existing sewers/drainage facility, the Contractor shall install temporary pipes/pumps
of adequate size to carry off sewage/drainage. No sewage/driange shall be allowed to flow upon the ground
surface or into the trench excavation.
No valve or other controls in public service facilities shall be operated by the Contractor without approval of the
Employer’s Representative and the relevant authorities. All users affected by such operation shall be notified by
the Contractor at least one hour before the operation and advised of the probable time when service will be
restored.
6.1.53 PROTECTION OF ADJOINING PROPERTY AND REINSTATEMENT UPON COMPLETION
The Contractor shall be responsible and take all measures in order to protect adjoining property including
buildings, electrical and telephone poles, bridges and culverts, retaining walls, compound walls and fences, and
other structures. Prior to the commencement of the activities, the Contractor shall assess the probability and
extent of unavoidable damages, if any, to the building and properties and submit his assessment to the
Employer’s Representative. The Employer’s Representative may make his own opinion and if required may
order arrangements for protection or repair of such likely unavoidable damage in which event the Contractor
shall complete the activities.
Temporary facilities shall be provided by the Contractor, only for as long as required after which he shall
dismantle and remove the same from their place of use as speedily as possible. Re-usable components shall
be safely stored by the Contractor in his yard. The place of use shall be cleared andreinstated immediately to at
least the condition existing before the temporary facilities were provided, andto the satisfaction of the
Employer’s Representative.
6.1.54 COORDINATION WITH OTHER AUTHORITIES
6.1.54.1 STATUTORY SERVICES
As far as possible the Contractor shall acquaint himself with the actual location of all existing public utilities
such as sewers, water mains, drains, cables for electricity, telephone lines, lighting poles, masts, etc., before
commencing any activities likely to affect the existing utilities. The Contractor shall with the assistance of the
Employer obtain such information directly from the responsible authorities as early as possible.
6.1.54.2 NOTICES, PERMITS
Well in advance of the programmed start of any work which may affect traffic or any existing utilities the
Contractor shall give advance information to the Employer/Employer’s Representative indicating the type, the
exact location, the programmed starting time and the expected duration of the activities and shall provide
whatever particulars may be required by the authorities to issue any required permits and make all necessary
arrangements. The Employer will provide necessary permissions.
6.1.55 MAINTENANCE OF THE SITE
The Contractor shall maintain the all the sites, equipment and related services until completion of the work in all
respect or until such time as the aforementioned facilities.
RUIDP P a g e | 49of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
During the course of executing the construction work at the various treatment plant, contractor shall construct a
chain link fencing for the safety of the operators at the existing site and the labour and staff deployed at the
proposed site.
6.1.56 AREAS OUTSIDE THE SITE
In the event of the Contractor making use of any special or temporary way or accommodation acquired by him
or any tip for the disposal of surplus materials, or any borrow pit or quarry, he shall obtain the written consent of
the owner, occupier or authority having charge of the land in which such way, accommodation or tip is situated
and shall make a record agreed by the owner, occupier or authority as aforesaid of the condition of the surface
of that land before entering thereon.
The Contractor shall permit the Employer or his representative and any person authorized by the Town
Municipal Board to access for the purposes of the Contract to any such special or temporary way.
In the event of the Contractor making use of any special or temporary way leave or additional accommodation
mode available to him by the employer or his representative for the purpose of the Contract, the land in which
such way or accommodation is situated shall be deemed to be part of the Site. On completion of the works at
site, the Contractor shall reinstate the area to its original condition to the satisfaction of the Employer or his
representative.
For the purposes of this Clause, ‘accommodation’ shall be deemed to include housing, offices, workshops,
warehouses, and storage areas.
6.1.57 NEW ACCESS ROAD WORKS
The Contractor shall construct a road for access to his office and all the work sites, which shall be separate
from the existing approach road to the plant. The Contractor shall obtain all permits required for carrying out
works such as excavation, if required, on public roads and shall liaise with the appropriate authorities with
regard to the timing and execution of the road works.
The Contractor shall be responsible for establishing and maintain temporary road/ drain diversions required for
execution of the works. The Contractor shall reinstate all the roads to the satisfaction of the Employer or his
Representative after completion of works.
6.1.57.1 MAINTENANCE OF EXISTING ACCESS ROADS
The Contractor shall only use existing access for the execution of the works. In such cases the Contractor shall
obtain the permission of Employer or his representative Representative’s in writing before utilizing existing
access road. Once the approval has been given, the Contractor shall be solely responsible for the maintenance
of the existing site access roads (if any). This responsibility shall continue until the completion of the Defects
Liability Period, or until such earlier date as the Employer or his representative may advise to the Contractor in
writing. Such maintenance work shall include general upkeep and any necessary repairs to damaged road
surfaces, pavement, drainage, associated slopes, etc to a standard at least equal to their original condition.
While carrying out such maintenance work, the Contractor shall make arrangements to maintain through
passage for vehicles and also those of other contractors over these access roads, which may comprise
temporary diversions all to the approval and satisfaction of the Employer or his Representative.
The Contractor shall not run tracked or un-sprung vehicles on surfaced roads without the written approval as it
may require that planking or some other protective material be used to protect the road surface.
6.1.58 CLEARANCE OF THE SITE
The Contractor shall clear all the Sites to the extent required by the Employer or his representative for checking
the setting-out.
Clearance of the Site shall also include demolition and removal of all articles, pumping out the accumulated
water at Pumping Station Sites, excavation/filling by earth, objects and obstructions, which are expressly
required to be cleared.
The Contractor shall ensure that the parts of the Site to be occupied by the proposed Permanent Works are
clear, and shall maintain the remainder of the Site as may be required for access and temporary works areas
required for the project.
The Contractor shall remove the material arising from such clearance and dispose of it in a manner at a
location, to the approval of the Employer or his Representative.
The Contractor shall fill and make good with appropriate materials those cavities and losses of soil, which result
from clearing the parts of the Site not subsequently to be occupied by the Works.
The Contractor shall not clear the Site of any existing structure without the prior written instruction of the
Employer or his Representative.
6.1.59 CLEARANCE AND REINSTATEMENT OF THE SITE ON COMPLETION
On completion of the Works, the Contractor shall clear any temporary works and temporary access roads and
reinstate the areas to their original condition and to the satisfaction of the Employer or his Representative.
6.1.60 ACCESS FOR THE ULB AND ULB REPRESENTATIVE
The Contractor shall permit the ULB and the ULB Representative and/or any person authorized by the ULB or
the ULB Representative including workmen of the ULB Town, other contractors or utility undertaking’s access
RUIDP P a g e | 50of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
for the purposes of the Contract to all areas of the Site and to any additional accommodation or temporary way
leave for the duration of the Contract period.
6.1.61 WATER SUPPLY AND WASTEWATER DISPOSAL AT SITE
The Contractor shall make his own arrangements for water supply during construction at site and he shall
ensure the quality of the water remains usable for the purpose for which it is intended. The Contractor shall also
conduct weekly/bi-weekly test for water quality and comply with the quality requirements, as directed by the
ULB’s representative.
6.1.62 LATRINES AND WASHING FACILITIES
Throughout the period of construction of the Works the Contractor shall provide, maintain and cleanse useable
and sufficient latrines and washing facilities for use by his employees. He shall ensure that his employees do
not foul the Site but make proper use of the latrines. Where practicable, the latrines shall be connected to the
nearest sewer, or if this is not practicable the Contractor shall provide an adequately sized septic tank and
soak-pit.
After completion, the latrines and washing facilities shall be removed, all ground disinfected and the surface
reinstated to the satisfaction of the Employer or his Representative.
6.1.63 ELECTRICITY FOR CONTRACTOR’S USE ON SITE
The Contractor shall be responsible for provision and distribution of an electrical supply for the purpose of
construction.
The installation shall comply with all the relevant regulations, Indian Standards and Codes of Practice, and
Health and Safety requirements, etc. The Contractor must take every possible precaution to ensure that his
installation is safe and injury to personnel or damage to plant and buildings is avoided. The Contractor shall be
fully responsible for all safety. The Contractor shall test the temporary site distribution system every 3 months
for compliance with the relevant standards.
6.1.64 DISPOSAL OF REFUSED/RUBISHED MATERIAL FROM SITE
Refuse and rubbish of every kind shall be removed from the Site and disposed off by the Contractor at his own
expense, frequently and regularly so as to keep the Site in an approved wholesome, hygienic and tidy condition
to the satisfaction of the employer or his Representative.
6.1.65 HANDLING AND DISPOSAL OF STP’S BY-PRODUCTS
The Contractor shall operate and maintain a system for the handling and disposal of byproducts from the Water
/ sewage treatment, including solid waste, screenings, grit and sludge and other residue. When disposals of
these by-products are necessary, the Contractor shall transport the by-products from the Facility to a proper
landfill site, or other sites identified and designated by the Employer’s Representative / ULB within 10 Km.
disntance from STP.
The requirements for handling and disposal of the by-products shall include but not be limited to the following:
a. The Contractor shall carry out pre-treatment of the by-products before disposal, when necessary, to
comply with the requirement to be accepted for landfill;
b. Provision of sufficient vehicles throughout the Operation Period totransport the by-products from the
Facility to the landfill site for disposal;
c. Maintenance and repair of the vehicles in good and clean conditions foroperation;
d. Provision of sufficient containers for the storage and transport of the byproducts from the Facility to the
landfill site. These containers shall be non-combustible, able to withstand accidental impact, provided
withcovers/lids that can be securely locked during transport.
e. The Contractor shall obtain from the landfill site operator records of weight of the byproductsdisposed
of at the landfill site for every trip.
f. All costs related to handling and disposal of the by-products, including but not limited to license
application, transportation, tests and treatment shall be borne by the Contractorand deemed to be
included in the Operation Fees.
6.1.66 RELEASE OF HAZARDOUS SUBSTANCES OR HAZARDOUS WASTES
The Contractor, after first notifying the Engineer, shall be responsible for fulfilling all requirements associated
with any release of any substance or waste into the environment (from the facility to the site) as required by the
Applicable law or by any Legal Entitlement including but not limit to the notification or reporting of release /
Hazardous Waste. The Contractor shall prepare memorandum evidence such notification or reporting and
provide copies thereof to the Engineer along with any documents provided to the relevant regulatory agency
regarding such release.
6.1.67 CHEMICALS, DANGEROUS GOODS AND HAZARDOUS MATERIALS
The Contractor shall provide and maintain storage of chemicals, Dangerous Goods and hazardous
materials required for the Operation. Dangerous Goods means any of the goods or substances to
which the Dangerous Goods Ordinance applies.
The Contractor shall include in his Operation Plan a detailed list all chemicals, Dangerous Goods and
hazardous materials to be used in the Operation with inventorycontrol programme, safety plan and
procedures for handling and storage.
RUIDP P a g e | 51of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
The Contractor shall maintain appropriate stock levels to allow continuous and efficient Operation of
the Facility but the quantity stored in the Facility shall not exceed theregulatory limits.
All chemicals, Dangerous Goods and hazardous materials shall be packed in containers of suitable
design and construction so as to prevent leakage, spillage or escape of the contents under normal
conditions of handling, storage and transportation, and shallcomply with relevant statutory and the
requirements of Delhi Fire Services Department.
Storage areas of chemicals, Dangerous Goods and hazardous materials, including any room,
cupboard, cabinet or bin, should display a hazard warning panel, notice or marking at or near the
entrances or opening of the storage area and such panel, notice ormarking should:
a) be indicated in English and Hindi;
b) be securely attached to or worked in vertical plane of the storage structure;
c) be weather resistant and rigid;
d) be kept clean and free from obstruction; and
e) meet statutory and Delhi Fire Services Departments requirements whereappropriate.
6.1.68 BREAKDOWN AND EMERGENCIES
The Contractor shall notify the Employer’s Representative in advance in writing of all shutdowns and
interruptions to any part of the Operation. Provided that in the event of an emergency shutdown or any
emergency action at the Site, the Contractor shall forthwith give notice by telephone and as soon as
practicable thereafter give notice in writing to the Employer’s Representative and specify the probable
cause, effect and extent of such emergency.
Without limiting the Contractor's obligations and responsibilities under the other provisions of the
Contract, the Contractor shall provide from time to time all temporary arrangements and contingency
provisions necessary or as may be provided in the Contract to maintain the Operation during the
maintenance, overhaul, renewal, breakdown, Performance Tests, Condition Surveys and subsequent
repair of any part of the Facility, without limitation to the generality of the foregoing: -
The Contractor shall not be permitted to suspend the Operation by reason of any such event;
The Contractor shall make available at all times such workers, Plant as provided in the Contract for the
execution of emergency works to the Facility;
If by any reason of any accident or failure of other event occurring which, in the opinion of the
Employer’s Representative requires the emergency works to be executed or services to be performed,
the Employer’s Representative may give to the Contractor an order verbally in the first instance, to be
followed by an instruction within 1 days of the issue by the Employer’s Representative of the verbal
order. The Contractor shall upon receipt of the verbal order immediately execute the works or perform
the services with due diligence as instructed in the verbal order.
6.1.69 EMERGENCY PROCEDURES
The Contractor shall prepare an Operational Contingency Plan as part of the OperationPlan. This shall
state the non-routine operational procedures to be adopted duringemergencies, and shall include at
least the following: -
a) Fire;
b) Vehicle breakdown and accidents;
c) Facility closure;
d) Procedure to handle excessive incoming sewage due to rain storm or infiltration;
e) Floods;
f) Inclement weather conditions;
g) Power outage;
h) Spillage of chemicals;
i) Labour disputes; and
j) Others.
The Operational Contingency Plan shall be submitted to all relevant authorities includingbut not limited
to the Employer’s Representative for comment and submitted to theEmployer for approval. The
Contractor shall review and update the OperationalContingency Plan regularly or when considered
necessary by the Employer.
6.1.70 QUALITY CONTROL
6.1.70.1 QUALITY CONTROL PLAN AND PROCEDURES
The Contractor shall be responsible for establishing and maintaining procedures for quality control that will
ensure that all aspects of the Works comply with the requirements of the ContractAs soon as reasonably
practicable prior to the commencement of Works the Contractor shall submit for approval a Quality Control Plan
giving detailed proposals for control of quality of all aspects of work on the Site and at suppliers' workshops.
The Quality Control Plan shall include the following: a) a list of the Contractor's staff engaged in quality control
b) a list of any outside testing agencies employed by the Contractor for work in connection with quality control
c) where a testing laboratory is to be established on Site under the Contract, a list of major items of equipment
RUIDP P a g e | 52of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
and a layout of the laboratory, together details of the tests which will be carried out there d) a list of
manufactured items and materials, obtained by the Contractor for the Works, which require inspection at the
suppliers' premises, and the proposed procedures for ensuring quality control e) a list of materials and
operations to be inspected by the Contractor at the various stages of construction work on Site, together with
inspection procedures, test types and frequencies f) sample of proposed quality control records, testing and
reporting forms.
Unless the Employer’s Representative permits otherwise, the approved Quality Control Plan shall be followed
throughout the construction of the Works. Any approval by the Employer’s Representative of the Contractor's
plan and procedures shall not relieve the Contractor of his obligation to ensure that the Works comply with the
requirements of the Contract.
The Contractor shall appoint a suitably qualified member of his staff to be responsible for all aspects of quality
control and to maintain effective liaison with the Employer’s Representative.
6.1.70.2 SAMPLING AND TESTING
The Contractor shall provide for the approval of the Employer’s Representative, samples of all construction
materials and manufactured items required for the Permanent Works. All samples rejected by the Employer’s
Representative shall be removed from Site. All approved samples shall be stored by the Contractor in a sample
room, at a location approved by the Employer’s Representative, for the duration of the Contract, and any
materials or manufactured items subsequently delivered to Site for incorporation in the Permanent Works shall
be of a quality at least equal to the approved sample. The approved samples may only be disposed of with the
Employer’s Representatives approval.
Samples shall be submitted and tests carried out sufficiently early to enable further samples to be submitted
and tested if required by the Employer’s Representative. Samples for testing will generally be selected by the
Employer’s Representative from materials to be utilized in the project and all tests will be under the supervision
of, and as directed by, and at such points as may be convenient to the Employer’s Representative.
Material requiring testing shall be furnished in sufficient time before intended use so as to allow for testing. No
materials represented by tests may be used prior to receipt of written approval of said materials.
The Contractor shall give the Employer’s Representative 15 days notice in writing of the date on which any of
the materials will be ready for testing or inspection at the suppliers' premises or at a laboratory approved by the
Employer’s Representative and unless the Employer’s Representative shall attend at the appointed place and
time the test may proceed in his absence. The Contractor shall in any case submit to the Employer’s
Representative within 3 days after every test such number of certified copies of the test readings as the
Employer’s Representative may require.
Approval by the Employer’s Representative as to the placing of orders for materials or as to samples or tests
shall not prejudice any of the Employer’s Representative's powers under the Contract.
The provisions of this clause shall also apply to materials supplied under any nominated subcontract.
After all construction at each Section is completed and before applying for taking-over, the Contractor shall
perform field tests as called for in the Specifications. The Contractor shall demonstrate to the Employer’s
Representative the proper operation of the facilities and the satisfactory performance of the individual
components including all units and equipments, etc.. Any improper operation of the system or any improper or
faulty construction shall be repaired or corrected to the satisfaction of the Employer’s Representative. The
Contractor shall make such changes, adjustments or replacement of equipment as may be required to make
the same comply with the Specifications, or replace any defective parts or materials. In case any of the section
of works or equipment as noted by the Employers representative, does not function and fulfil the requirement
for which it is intended to ev, n after the same is repaired or corrected, that section of any work or equipment
shall be constructed/replaced. Costs towards such construction/replacement will be borne by the contractor and
no payment will be made to the contractor on this behalf. Some of the faulty equipment may require total
replacement without going in to repair; the descision regarding the replacement of faulty unrepairable
equipment will be made by Employers representative.
In addition to any special provision made herein as to sampling and testing materials by particular methods,
samples of materials and workmanship proposed to be employed in the execution of the Works may be called
for at any time by the Employer’s Representative and these shall be furnished without delay by the Contractor
at his own cost. Approved samples will be retained. The Employer’s Representative will be at liberty to reject all
materials and workmanship that are not equal or better in quality and character than such approved samples.
The tests required for quality control shall include but not be limited to:
a) tests conducted at the premises of the Contractor, Subcontractor, manufacturer or supplier which
are normally or customarily carried out at such premises for the items or materials being supplied
for the Works
b) tests which are normally or customarily conducted on the items or materials being supplied for the
Works by the Contractor, Subcontractor, supplier or manufacturer but which have to be conducted
at an approved laboratory because the necessary testing facilities are not available on the
premises of the Contractor, Sub-Contractor, supplier and manufacturer
RUIDP P a g e | 53of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
c) tests on locally obtained materials or items either on the Site or at an approved laboratory for the
purpose of obtaining the approval of the Employer’s Representative to the classification, use and
compliance with the Specifications of such items or materials
d) routine quality control tests conducted by the Contractor to ensure compliance with the
Specifications
e) regular testing of concrete and other materials as specified in the relevant section of the Technical
Specifications
f) Standard shop and Site acceptance tests, including trial assemblies, of Plant.
6.1.70.3 INSPECTION AND ACCEPTANCE
The Employer’s Representative will not inspect any item of fabricated or finished work until such time as the
Contractor shall have forwarded to the Employer’s Representative the approved Construction Drawings
covering the items to be inspected, together with copies of the respective orders.
Manufactured items and materials delivered to the Site shall be inspected by the Contractor on arrival. Any
defects shall be notified to the Employer’s Representative.
Minor defects to surface finishes and the like in manufactured items shall be made good in an approved
manner to the satisfaction of the Employer’s Representative. Items with more serious defects shall be returned
to the suppliers for correction or replacement as appropriate. Detailed requirements pertaining to Inspection,
Testing and Commissioning for Civil, Electrical, Mechanical, Instrumentation works is provided under Section 6
Volume 2 General technical Specifications. All the costs arising due to all the Inspection Testing &
commissioning will be borne by the contractor.
6.1.70.4 INSPECTION REQUIREMENT
All inspection and testing shall be carried out in accordance with the Specification and in absence of
Specification relevant Indian Standard or internationally approved equivalent standard.
The Contractor shall carry out at the place of manufacture tests of the Plant / Equipment at any part of the
Works.
The Employer shall be entitled to attend the aforesaid inspection and/or tests by his own duly authorised and
designated representatives.
The Employer and his duly authorised representative shall have access to the Contractor’s premises at all
suitable times to inspect and examine the material and workmanship of the mechanical and electrical plant and
equipment during its manufacture there. If part of the plant and equipment is being manufactured on other
premises, the Contractor shall obtain permission for the Employer or his duly authorised representative, to
inspect as if the plant and equipment was manufactured on the Contractors own premises. Testing (including
testing for chemical analysis and physical properties) shall be carried out by the Contractor and certificates
submitted to the Engineer’s Representative who will have the right to witness or inspect the above mentioned
inspection / testing at any stage desired by him.
The procedure for the testing and inspection to be carried out during or following the manufacture of the
materials to ensure the quality and workmanship of the materials and to further ensure that they conform to the
Contract in whatever place they are specified shall be as described below.
The Contractor shall give the Employer at least 21 clear days notice in writing of the date and the place at
which any plant or equipment will be ready for inspection / testing as provided in the Contract. The Employer or
his duly authorised representative shall thereupon at his discretion notify the Contractor of his intention either to
release such part of the plant and equipment upon receipt of works tests certificates or of his intention to
inspect. The Employer shall then give notice in writing to the Contractor, and attend at the place so named the
said plant and equipment which will be ready for inspection and/or testing. As and when any plant shall have
passed the tests referred to in this section, the Engineer’s Representative shall issue to the Contractor a
notification to that effect.
The Contractor shall forward to the Employer 3 duly certified copies of the test certificates and characteristics
performance curves for all equipment.
If the Engineer’s Representative fails to attend the inspection and/or test, or if it is agreed between the parties
that the Engineer’s Representative(s) shall not do so, then the Contractor may proceed with the inspection
and/or test in the absence of the Engineer’s Representative and provide the Employer with a certified report of
the results.
If any materials or any part of the works fails to pass any inspection / test, the Contractor shall either rectify or
replace such materials or part of the works and shall repeat the inspection and/or test upon giving a notice. Any
fault or shortcoming found during any inspection or test shall be rectified to the satisfaction of the Engineer
before proceeding with further inspection of wiring of that item. Any circuit previously tested, which may have
been affected by the rectification work, shall be re-tested.
Where the plant and equipment is a composite unit of several individual pieces manufactured in different
places, it shall be assembled and tested as one complete working unit, at the maker’s works.
Neither the execution of a inspection test of materials or any part of the works, nor the attendance by the
Engineer’s Representative(s), nor the issue of any test certificate shall relieve the Contractor from his
responsibilities under the Contract.
RUIDP P a g e | 54of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
The test equipment, meters, instruments etc., used for testing shall be calibrated at recognised test laboratories
at intervals recommended by the manufactures and valid certificates shall be made available to the Engineer’s
representatives at the time of testing. The calibrating instrument used as standards shall be traceable to
National / International standards. Calibration certificates or test instruments shall be produced from a
recognized Laboratory for the Engineer’s consent in advance of testing and if necessary instruments shall be
recalibrated or substituted before the commencement of the test.
The Contractor shall not pack for shipment any part of the Plant until he has obtained from the Employer or his
authorized representative his written approval to the release of such part for shipment after any tests required
by the Contract have been completed to the Employer’s satisfaction.
The Contractor shall maintain proper identification of all materials used, along with reports for all internal / stage
inspection work carried out, based on the specific job requirement and or based on the data sheets / drawings /
specifications
The following inspection and test categories shall be applied prior to delivery of the equipment, of various
categories as indicated in the technical specifications for each type of the equipment.
Category A: The drawing has to be approved by the Employer’s Representative before manufacture and
testing. The material has to be inspected by the Employer’s Representative or a third party inspecting agency
approved by the Employer’s Representative at the manufacture’s premise before packing and dispatching. The
inspection charges of the agency shall be first borne by the Contractor which shall be reimbursed after
production of actual receipt along with the first running bill of material from the item of provisional sums of BOQ.
Category B: The drawings of the equipment have to be submitted and approved by the Employer’s
Representative prior to manufacture. The materials has to be tested by the manufacturer and the
manufacturer’s test certificates are to be submitted and approved by the Employer’s Representative before
dispatching of the equipment. Not withstanding the above, the Employer’s Representative, after examination of
the test certificates, reserves the right to instruct the Contractor for retesting, if required, in the presence of the
Contractor’s representative.
Category C: Samples of the materials and / or equipment shall be submitted to the Employer’s Representative
for pre-construction review and approval in accordance with the provisions of Section , Following approval by
the Employer’s Representative, the material may be manufactured as per the approved standards and
delivered to the Site.
For material / equipment under Category “A” and “B”, the Employer’s Representative will provide an
authorization for packing and shipping after inspection.
The testing and approval for dispatching shall not absolve the Contractor form his obligations for satisfactory
performance of the plant.
Table 12:Category of Inspection
Category of
Sl. No. Items
Inspection
1. Sluice Gates- Manual and Motorized Category A
2. Ultrasonic Type Differential Level Measurement System Category A
3. Mechanically Cleaned coarse & Fine Bar Screens Category A
4. Grit Removal Equipment Category A
5. Submersible Sewage Pumpset Category A
Sluice Valves, Butterfly valves, Knife edge valve, Gate Valve. Air Valves,
6. Category A
Zero Velocity Valve, Air Cushion Valve, Flow Control Valves.
7. Non-Return Valves/Dual Plate Check valves, PRVs. Category A
8. Valve Actuators Category A
Ductile Iron, PVC-U, uPVC, RCC, AC (Mazza Process) HDPE, HDPE
9. (DWC), MDPE, Cast Iron, GI, Double flange Pipes, specials and rubber Category A
rings.
10. High Pressure Pumps Category A
11. Float level switches Category A
12. Instrumentation & Control Cables Category A
Instrument Control Panel comprising of PLC, digital indicator, alarm
13. Category A
annunciator, mimic, pushbuttons etc.
14. Battery & Battery Charger Panel Category A
15. Screen Control Panel Category A
16. SBR equipment Category A
17. Aeration system Category A
18. Transformer Category A
19. 11 KV Go Swithes Category A
20. Diesel Generating set Category A
21. Capacitors and APFC Panel Category A
22. LV switchboards panel and Control Cabinets Category A
23. Induction Motors Category A
RUIDP P a g e | 55of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Category of
Sl. No. Items
Inspection
24. Air Blower Category A
25. Centrifuge Category A
26. Grit Seperator Mechanism - Organic Return Pump, Screw Classifier Category A
27. H.S. Casing centrifugal pumps, VT pumps Category A
28. Induction Motors Category A
29. Decanter Category A
30. Chlorinator, Chlorine Toner Category A
31. Screw Pumps for Sludge Handling Category A
32. Gas Flaming System Category A
33. Domestic Water Meter Category A
34. Electromegnic Flow Meter Category A
35. Bulk Flow Meter Category A
36. Clariflocullator Category A
37. HT Cable Category A
38. 11 KV VCB Category A
39. 11 KV Load break switches Category A
40. VFD Category A
41. Air Circuit Breaker Category A
42. Tubular Poles Category A
43. High mask lighting system Category A
44. 33 kv/ 11 kv Towers Category A
45. DO analyser, Chlorine Analyser, Turbidity Analyser, Conductivity Analyser Category A
46. Solar Lighting system grid connected Category A
47. RCC Precast Manholes Category A
48. Manhole Frame and Cover Category A
49. Footrest CI/SFRC/SS pe capsulated Category B
50. SFRC Drain Covers Category B
51. Ultrasonic flow meter Category B
52. Ultrasonic level measuring system Category B
53. Ultrasonic differential level measuring system Category B
54. All laboratory Equipments. Category B
55. Manually Raked Coarse Screens Category B
56. Manually Raked Fine Bar Screens Category B
57. Electrically Operated Hoists, HOT, Monorails, Chain Pulley Block. Category B
58. Manually Operated Overhead Travelling Crane Category B
59. Fiber Glass Row Boat Category B
60. Surge Protection Devices Category B
61. Lightning arrestors, drop-out fuses and insulators Category B
62. Sub-Distribution Boards Category B
63. Power and Control Cables Category B
64. Lighting system equipment Category B
65. Expansion Bellow, Dismentling Joint Category B
66. Diffusers Category B
67. Open Channel Gate Category B
68. MCCB Category B
69. UPS for PLC and SCADA Category B
70. Portable Screening Containers Category C
71. Exhaust Fans Category C
72. Air-conditioners Category C
73. Portable Fire Extinguisher Category C
74. Pressure Gauges Category C
75. Earthing System Category C
76. Local Push Buttons Category C
77. 33 kv/11 kv Cable end termination Outdoor, Indoor, Category C
78. Contacors Category C
79. Switch fuse units Category C
80. LED Lighting system Category C
81. Pressure Transmitters Category C
Inspite of third party inspection all the materials may be got tested from the reputed institutions/Organization as
approved by the Employers representative and from the NABL acrrediated laboratories after reaching at site.
Decision requarding type of material shall be on sole descrition of Employer’s Representative. The costs for all
such tests shall be paid by the employer through provisional sum of the contractor.
RUIDP P a g e | 56of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 57of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Vertical Separation:
In case of crossings, the water main should be 0.5 m above the sewer top or drain for 3 m on either
sides and should have joints as far as possible.
Any water pipeline shall not in any case be allowed to pass through the sewer manhole/chamber.
6.1.75 CONSUMER RELATION MANAGEMENT CENTRE
The Contractor shall design, develop and set up consumer relation management centres (CRMC), of not less
than 90 m2, and one Central Control Centre (CCC) of about 90 m2 to facilitate receiving and resolving
consumer requests in the areas of new connections, service deficiencies, resolution of billing disputes, payment
of bills etc. The consumers shall file their complaints through e-mail, text message from mobile phones,
telephone, Fax and other electronic media, or by physically visiting the Centre/s. Contractor will maintain two
toll-free numbers, each for water supply and sewerage services, at CCC. The Centres shall function between 8
am and 8 pm during all working days and between 8 am and 1 pm during public holidays, including Sundays.
The CRMC and CCC shall be air conditioned and have reasonable space and furniture for the Consumers to
wait, interact and represent their requirements. During the other off peak times of 8 pm to 8 am, the Contractor
shall have a facility to receive Consumer complaints through telephone, fax, text message, email and any other
electronic means. The complaints once received should be acknowledged automatically and a registration
number shall be given to the complainant immediately. The CRMC and CCC shall be equipped with sufficient
human resources, hardware and software to facilitate continuous record of consumer requests, monitoring the
resolution, and reporting completion of necessary actions and tasks. There shall be an exclusive desk for
servicing the urban poor consumers, preferably serviced by an efficient lady executive who can interact in local
language.
6.1.75.1 BASIC SERVICES
Followign minium services shall be provided at the Consumer Relation Management Centres
Information services;
Enquiry services;
Requests services;
Grievance and resolution services;
New connection services;
Billing services - generate, distribute, payment collection;
Resolution services of consumer requests;
Reponse services to the quality, flow and pressure parameters;
Consumer data backup system; and
Conumer querry and complain followup system.
In addition there should be a capability in the solution to manage the execution of
effective inbound and outbound services, including campaigns and calling back of
customers.
Contractor shall provide a cloud based hosted contact contra that conforms to the following:
1. Has a web based administration consol.
2. Provides Real-time Monitoring - to report on Agents Status and Queues.
3. Has the ability to listen to five calls as they are handled.
4. Is able to handle Inbound &Outbound campaignsand calling back of customers.
5. Can produce reports by single and by user-created queue groups.
6. Can measured agents activities, business targets and conversion rates.
7. Is able to fully configure agent login security queue by queue.
8. Is able to create real time call and agent reporting.
9. Has integrated Quality Assurance.
10. Enables agents to see the calls they are handling and providesome integration with
back-end systems.
11. Enables agents to set call status codes for all inbound and outbound traffic.
12. Enables agents to logon, logoff, go on pause and set pause reason codes.
13. With reference to the live monitoring of all incoming and outgoing calls, call details
have benchmarks that can be easily implemented by the user to let the system flag
any calls that meet the benchmarked criteria
14. Allow all inbound, outbound and transferred calls to be recorded, whether internal or
external in origin.
15. Is able to see the total number of calls received from internal and external callers
per agent as well as a summary of these calls received with their final status as:
- Answered calls
- Lost calls
- Routed to voicemaif
- Overflowed
16. Is able to report the average call duration for all calls per agent and in total
17. Provide an overall report of all incoming calls with the call's final status, even if the
call overflowed This is required to be able to determine what the outcome of the
specific call was.
RUIDP P a g e | 58of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
18. Provides a simple search function for voice recordings. Should be able to search by the following
criteria:
Agent name ( and not agent extension number only)
Incomingcalls
Outgoing calls
Date and time
Telephone number
19. Provides real time redundancy in network access finks to two independent data contras catering for 30
concurrent calls
20. Provides dual hosted infrastructure services in multiple data contras and walk-in contras
21. Provides a solution to log, monitor and track the progress and resolution of the water use, billing and
other water related inquiries provide feedback.
6.1.75.2 IMPLEMENTATION METHEDOLOGY
A comprehensive implementation methodo\ogy, plan and management strategy shall be preared and submitted
to employer as well line agency required for the establishment of the contact centre the same shall be finalized
after incorporating the suggestions of the local administration, Municpal body, PHED and stake holders.
6.1.75.3 SECURITY AND PRIVACY
The solution should be designed in a way that guarantees protection and privacy
of the client and the DWS information;
There should be complete and comprehensive security from unauthorised access
and misuse of information;
The necessary data encryption protocols should be utilised.
6.1.75.4 STAFF AND EQUIPMENTS
The centre should be fully staffed with competent agentsand managed by a
strong management team;
A contact centre team with expertise and knowledge of water supply systems would be
an added advantage. For each CRMC, following shall be the minimum human resource:-
6 Contact Centre Agents;
2 First Line Managers; and
1 Manager.
Minimum hardware requirements
PBX
Management software
Call recording
User PCs
Server
Interactive Voice Response;
Automatic Call Distribution;
Support tickets with logging and tracking;
Campaign management;
Performance monitoring;
Recording;
How the system can integrate back to the back office.
Integrate CRMC with various departmental systems such as Local Administration, Municipal
Body, PHED etc.
6.1.75.5 EXPECTED OUTCOME
It requires that the following outcomes will be realised during operation & maintenance of the water supply
services:-
Improved relationship and communication with all stakeholders and water supply consumers;
Awareness of possible hot spots through feedback by citizens to the line agency;
Fewer billing queries and quick resolution of queries;
An improved image of the water supply system i.e~ positive feedback about the line agency;
An updated and correct register of water users;
Improved debt collection;
Prompt payment of suppliers/service providers accounts;
A team of centre agents who are proficient in their work;
A smooth operating CRM system and centre;
Well trained departmental officials who can operate and run the centres successfully;
Improved communication between the public and line agency on water and sanitation issues;
Build relationships with the various contact centres that belong to different spheres;
Follow-up on service delivery issues in relation to water and sanitation at a
municipal/PHED level
RUIDP P a g e | 59of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 60of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
RUIDP P a g e | 61of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Each above ground Asset shall be given a unique number within the Asset Register. Numbering system shall
be designed in consultation with the Employer. The number shall refer to the site and the type of Asset.
C. Performance and Condition Grades
Performance grades shall define whether the Asset is meeting the required quality standards or levels of
service standards or is suitable for its function. Condition grades shall define the structural condition of the
Asset. This may be from an assessment of the structural condition or from recording of the frequency of failures
of the Asset.
Table below describes the meaning of some of Grades of the Facilities. Detailed definition of these Facilities
shall be formed within six months of commencement of Operations Period, for each Part, in consultation with
the Employer.
D. Definition of Facilities
Table 13: Condition Grades
ID Grade Description
The infrastructure in the system or network is typically new or
a
Very recently rehabilitated.
1
Good A few elements show general signs of deterioration that require
b
attention.
The infrastructure in the system or network has some elements
a
2 Good that show general signs of deterioration that require attention.
b A few elements exhibit significant deficiencies.
The infrastructure in the system or network shows general signs
a
3 Fair of deterioration and requires attention.
b Some elements exhibit significant deficiencies.
The infrastructure in the system or network is mostly below
a standard, with many elements approaching the end of their
4 Poor service life.
b A large portion of the system exhibits significant deterioration.
The infrastructure in the system or network is in unacceptable
a
Very condition with widespread signs of advanced deterioration.
5
Poor Many components in the system exhibit signs of imminent
b
failure, which is affecting service.
E. Timing Definitions and Differentiation Between Asset Types
i. Performance Aspects
The Contractor shall develop a clear understanding of the exact meaning of the phrases 'Immediately'
,'Short Term' and 'Medium' Term' used in association with the Performance Grades with the Employer,
within six months of contract commencement date.
ii. Condition Aspects
Different Facilities shall have different expected lives. Buildings or Civil (usually reinforced concrete
structures) Facilities are expected to have a Asset life of 60 years. Electrical and Mechanical Facilities
are expected to have a Asset life of 15 years. Bulk water mains would be expected to have Asset lives in
excess of 60 years, or may be taken as having an indefinite life.
The terms 'immediate', 'short term', 'medium term' need to describe approximately when major work shall
be required relative to the Asset's normal life.
The Contractor, in consultation with the Employer, shall assign the Performance and Condition Grade.
The Contractor shall give separate Performance and Condition Grades for Facilities with a mix of
Building and Civil elements and Electrical and Mechanical Elements. The Employer shall be entitled to
order an independent inspection at such times. The Contractor shall take into account both the
Performance and the Condition Grade when deciding upon the recommendation to the Employer on
investment on the Asset as part of the capital replacement and refurbishment program.
F. Records to be Produced and Maintained
The scope of the Facilities to be included is summarized in Table below
Table 14: Scope of the Facilities
Type Facilities
Management and Stocks
General Computers and associated equipment
Land
RUIDP P a g e | 62of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
Vehicles
Plant
Above Ground Below Ground
Supply Services Pumping Machinery Pipelines – Transmission and
Reservoirs distribution mains
Pumping stations Valves
SPS Service Connections
Sewer lines (all) and house
connections
G. Operational Work Order Management
The Contractor shall establish and maintain a suitable work order management system, in consultation with the
Employer. This work order management system shall provide detailed information on Assets such as the type
and make of motors, pumps, equipment, valves maintenance schedules etc.
H. Record Drawings
Raw data on Facilities shall be held on Record Drawings.
The Contractor shall establish and maintain up-to-date Record Drawings for both above ground and below
ground Facilities.
The Contractor shall update the Record Drawings and Asset Register to include the facilities taken over them,
together with any works that are subsequently undertaken. The Record Drawings shall be updated by the
Contractor within 3 months of any modifications being carried out in the facilities.
I. Accuracy of Data.
The Contractor shall assign 'Confidence Grades' to the data to validate its accuracy. The Contractor shall
develop the definitions of these grades and how they are to be used in consultation with the Employer.
J. Inventory Management
The Contractor shall operationalise a computer based inventory management system to enable effective control
of spares and consumables. This system shall use standard proprietary software and shall be linked by the
Contractor to MIS. The Contractor shall provide monthly reports from this system to the Employer.A
spreadsheet is all that is need to manage inventory.
K. Customer Service Management System
Customer service encompasses a broad range of activities. The Customer Service Management System shall
have an interface with the Customer’s premises to ensure required performance are met (e.g. water pressure
and flow) and proper response are given to customer enquiries. The following provisions shall be integrated into
the customer service management system:
i. Advance warning of planned supply shut off for repairs and renewals
ii. Advice Customers during emergencies
iii. Billing Customers
iv. Dealing with billing queries
v. Recording and Responding to Customer Complaints
L. Systems and Procedures for Creating and Updating Customer Database
Within one year from the contract commencement date, Contractor shall operationalise the Customer
Database, with all customer contacts with respect to billing and provision of services can be controlled.
Information held shall include the Customer name, reference number, mailing address, telephone number and
account history information.
M. Meter Replacements / Refurbishment / Calibration by the Contractor
RUIDP has not given any schedule for replacement of equipment. However the Contractor shall replace
equipment on the basis of performance of meters and equipment. Contractor will include costs for replacement
of bulk flow meters and its spares including battery, and other equipment in his quoted price.
Useful life of house service connection meters is considered 7 years from the date of commissioning of meter. If
any meter requires replacement before 7 years period, it will be replaced at costs of the Contractor and will not
be paid. Any meter requires replacement after seven years period will be paid with the quoted rate under
Operation Service Costs. However, if the fault has resulted from actin by a third party, such as the meter is
stolen or by-passed, then the Employer will pay for the replacement.
Bulk flow meter and Electromagnetic Meters shall be recalibrated by the Contractor at intervalsof 5 years.
N. Customer Services
A 24 hour customer service desk shall be established at the Central control centre (Old PHED Head Works).
The customer service desk will be integrated with the MIS. All enquiries and customer complaints shall be
recorded into the system along with resolution mechanisms, time of resolution, action taken and feedback
procedures.
RUIDP P a g e | 63of 64
EMPLOYER’S REQUIREMENTS (GENERAL) Package No. RSTDIP /SRD/01
The Contractor shall receive and handle all customer queries and complaints, including, but not limited to,
queries and complaints related to
i. water bills;
ii. malfunctioning or inaccurate meters;
iii. meter readings;
iv. water quality;
v. water pressure;
vi. blockage or flooding of sewers; andleakage and damaged pipes;
vii. change in meter location;changes in customer names;
viii. Cancellation of connection by the customer
RUIDP P a g e | 64of 64
EMPLOYER’S REQUIREMENTS (WATER SUPPLY) RSTDIP/SRD/01
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Name of Work:- Construction of Works of Water Supply Production and Distribution Network Improvements
with house service connections for nonrevenue water reduction and continuous water supply and Providing
Sewer Network with House connections, and construction of Sewage Treatment Plant & Sewage Pumping
Station and all allied Works and operation services of the entire system for 10 years at Sardarshahar (Churu).
TABLE OF CONTENT
6.2.1 OVERVIEW OF EXISTING WATER SUPPLY SYSTEM .............................................................5
6.2.1.1 SOURCE OF WATER................................................................................................ 5
6.2.1.2 WATER TREATMENT PLANTS ................................................................................ 5
6.2.1.3 TRANSMISSION MAINS ........................................................................................... 5
6.2.1.4 DISTRIBUTION SYSTEM IN THE CITY .................................................................... 5
6.2.1.5 PRESENT PER CAPITA WATER SUPPLY .............................................................. 5
6.2.2 SCOPE OF SERVICES: SCOPE OF CONTRACT FOR DESIGN BUILD PERIOD ....................5
6.2.3 THE SUMMARY OBLIGATIONS UNDER THE CONTRACT ......................................................7
6.2.4 SCOPE OF OPERATION & MAINTENANCE PHASE .................................................................8
6.2.5 IMPORTANT MILESTONE AND KEY TIME PERIODS AS PER THE TERMS OF CONTRACT 9
6.2.6 WATER DEMAND & AVAILABILITY ..........................................................................................11
6.2.7 DETAIL OF TRANSMISSION MAINS AND FEEDER MAINS ...................................................12
6.2.8 ZONING PROPOSALS AND HYDRAULIC MODELLING FOR DISTRIBUTION SYSTEM .......12
6.2.9 CLEAR WATER RESERVOIR ...................................................................................................13
6.2.10 PROPOSED WATER DISTRIBUTION SYSTEM & DISTRICT METERED AREA (DMA) .........14
6.2.11 PUMP HOUSE WORKS.............................................................................................................14
6.2.11.1 INDICATIVE CLEAR WATER PUMP AT HEAD WORKS:- ..................................... 14
6.2.11.2 INDICATIVE CLEAR WATER PUMPS AT PROPOSED PUMP HOUSE ................ 14
6.2.12 CHLORINATION ROOM AND SYSTEM....................................................................................15
Table 16 Chlorination System .......................................................................................................................15
6.2.13 REHABILITATION, REFURBISHMENT, AND REPAIR WORKS ..............................................15
6.2.14 CONSUMER CONNECTIONS ...................................................................................................16
6.2.15 SIZING OF SERVICE CONNECTIONS FOR INDIVIDUAL DWELLINGS .................................16
6.2.16 CUSTOMER WATER METERS .................................................................................................16
6.2.17 ILLEGAL CONNECTIONS .........................................................................................................17
6.2.18 REMOVAL OF OLD HSCs .........................................................................................................17
6.2.19 COMPATIBILITY OF TAPPING SHADDLE AND FERRULES ..................................................17
6.2.20 METHODOLOGY OF SERVICES ..............................................................................................17
6.2.20.1 DISTRIBUTION NETWORK IMPROVEMENT (DNI) ON DMA BASIS .................... 17
6.2.20.2 METHODOLOGY FOR DESIGNING OF DNI.......................................................... 17
6.2.20.3 EMERGENCY WATER SUPPLY BETWEEN DMA’S.............................................. 18
6.2.20.4 PRESSURE ZERO TESTS (PZTS) ......................................................................... 19
6.2.20.5 METHODOLOGY FOR MEASUREMENT OF WATER BALANCE AND REAL
LOSSES DURING OPERATION SERVICES ..................................................................................................... 19
6.2.20.6 PERFORMANCE INDICATORS .............................................................................. 19
6.2.20.7 METHODOLOGY FOR COMMISSIONING OF ZONE CUM DMA .......................... 19
6.2.20.8 DISTRIBUTION NETWORK IMPROVEMENTS WORKS ....................................... 20
6.2.20.9 DISTRICT METERS FOR METERED AREAS ........................................................ 20
6.2.20.10 VALVES AT DMA ENTRY POINT ........................................................................... 20
6.2.20.11 VALVES IN DISTRIBUTION SYSTEM .................................................................... 20
6.2.20.12 VALVES AT OHSR .................................................................................................. 20
6.2.21 CLEAR WATER RESERVOIR ...................................................................................................21
6.2.22 OVERHEAD SERVICE RESERVOIR ........................................................................................21
6.2.23 WATER DISTRIBUTION SYSTEM ............................................................................................22
6.2.23.1 HYDRAULIC MODELLING WATER SUPPLY DISTRIBUTION NETWORK ........... 23
6.2.23.2 PROPOSED WATER DISTRIBUTION SYSTEM & DISTRICT METERED AREA
(DMA) 23
6.2.23.3 DESIGNING OF DMA .............................................................................................. 23
6.2.23.4 TRANSMISSION MAIN FOR TW WATER AND CLEAR WATER ........................... 24
Index of Tables
Table 1 Scope of services for water supply .......................................................................................................... 5
Table 2: Summary of Obligations under Water supply .......................................................................................... 7
Table 3: Scope of Works under Operation & maintenance Phase ........................................................................ 8
Table 4: Milestone and Key Time Periods ............................................................................................................ 9
Table 5: Population and Water Demand and Water Availablity (MLD) ............................................................... 11
Table 6: Blending of TWs Water and Surface Water .......................................................................................... 12
Table 7 Transmission main & Feeder main details ............................................................................................. 12
Table 8 Water Supply Zones in Town ................................................................................................................. 13
Table 9 Detail of Water Supply Zones ................................................................................................................ 13
Table 10: Proposed Clear Water Reservoir ........................................................................................................ 13
Table 11: Details of pipes proposed in the distribution system ........................................................................... 14
Table 12: Indicative details of Proposed Clear Water Pumps at Proposed Pump Houses to feed OHSRs ........ 14
Table 13: Indicative details of Proposed Clear Water Pumps at proposed Pump Houses to direct pumping to
Distribution system .............................................................................................................................................. 14
Table 143: Details of Proposed Clear Water Pumps by PHED at Pump Houses to existing OHSRs of Zone-5 &
6 under ongoing PHED Contract ......................................................................................................................... 15
Table 154: Indicative details of Submersible Motor Pump Sets for Ground Water, existing TWs to Clear Water
Reservoir at Hanumangarh road Headworks ...................................................................................................... 15
Table 16 Chlorination System ............................................................................................................................. 15
Table 17: Existing PHED H/Ws Refurbishment .................................................................................................. 15
Table 18: Existing PHED H/Ws Refurbishment ................................................................................................. 15
Table 19: Existing TWs for Refurbishment .......................................................................................................... 16
Table 20: Boundary Wall With gate ..................................................................................................................... 16
Table 21: Penalty for not achieving House Service Connections ....................................................................... 16
Table 22: Sizing of Service Connections ............................................................................................................ 16
Table 23: Design Criteria for Sizing of Transmission Pipeline ............................................................................ 24
Table 24: Pumping Hours ................................................................................................................................... 34
Table 25 PRICE BREAKUP CWR ...................................................................................................................... 44
Table 26 PRICE BREAKUP CWPS .................................................................................................................... 45
Water from Clear Water Reservoirs at Hanumangarh road headworks is being pumping to various OHSRs
through DI transmission of various size. The present condition of laid DI pipeline is OK and satisfactory.
6.2.1.4 DISTRIBUTION SYSTEM IN THE CITY
The Existing Distribution System is of uPVC and AC make, from the OHSR Pipe Line of Size 350mm-300mm
emanates which reduces to 250mm and subsequently branches to 140mm and from thereon to 110mm and
90mm respectively for House Connections. The Existing Distribution system consist of six(6) zones, Zone I to 4
are being fed from the Existing four OHSR’s while it is proposed to supply Zone-5, 6 from the newly
constructed OHSR’s located at Zone-05 & Zone-06, and Zone-7 is to be supplied from newly constructed CWR
at Hanumangar Road. The majority of the uPVC lines are being laid in between 2001 to 2003 and designed on
the basis of 100 lpcd. Existing AC pipes are old and considered as possible source of leakages.
6.2.1.5 PRESENT PER CAPITA WATER SUPPLY
Currently 11-12MLD clear water taken from CWR as the existing system designed based on 100 LPCD
Present service level of Sardarshahar town is 90-100 LPCD. As per the discussion with line agency, present
NRW level may be around 35-40%.
6.2.2 SCOPE OF SERVICES: SCOPE OF CONTRACT FOR DESIGN BUILD PERIOD
Table 1 Scope of services for water supply
Sr. No. Components Scope
1) Preparation of GIS based consumer mapping, survey and Complete Project area.
investigation, plotting assets on GIS map by linking with geo-
spatial data bases. The GIS shall be developed to include entire
project area and shall include the existing and proposed
components of Water Supply and Waste Water systems located
within the project area; and also source, It shall also include
development of website for online payment of Bills and Customer
care services etc. and linking of the same with GIS database
complete in all respect.
2) Preparation of SIP (Service Improvement Plan) as per scope and For all project components.
employer’s Requirement.
3) Design, Supply and Installation of SCADA system required for SCADA works for entire water
effective management of the water supply systems based on the supply system from source to
continuous data, its analysis and management to achieve DMAs.
performance indicators.
4) Design, construction, supplying, installation, testing, trial run and 1. Pump House at
commissioning of new clear water pump house including Hanumangarh Road Head
complete pumping system to feed OHSRs and water water work:-
supply distribution zone by direct pumping using VFD a) Ramnagar OHSR (Z-1)
including but not limited to all Civil, Pipeline, pumps, motors,
b) Bherudan OHSR (Z-3) &
other Electro-Mechanical equipments, Instrumentation SCADA
Holidhora OHSR (Z-2)
system and synchronization of SCADA enabled devices and
equipments installed with geo referencing, along with ancillary c) Suryamandir OHSRs (Z-4)
Civil works (with structures required for suction manifold d) Direct supply to Zone-7
including providing pump floor area; switch-gear or panel area;
S. New /
Maintain
Operate
Design
Rehab
Description
Build/
No. Rehab.
Scope
Execution
S. New /
Maintain
Operate
Design
Rehab
Description
Build/
No. Rehab.
8. Consumer Relation Management Centres (CRMC) New Yes No Yes Yes Yes
Clear Water Pumping system at new pump station
9. New Yes No Yes Yes Yes
building
10. TW Water Transmission Pipeline New Yes No Yes Yes Yes
Water supply Distribution Network & Pipelines in
11. each DMA for whole town within Municipal New. Yes No Yes Yes Yes
Boundary limit.
House service connection from water supply
12. distribution pipe line upto water meter chamber of New Yes No Yes Yes Yes
20/25/32mm
Multi jet magnetic type domestic water meter with
13. New Yes No Yes Yes Yes
Meter Box.
14. Trenchless crossing of roads/Railway Line New Yes No Yes Yes Yes
Electromegnatice flow meter, Bulk flow meters,
15. pressure & level sensors, communication RTUs New Yes No Yes Yes Yes
through GPRS, SCADA.
Rehabilitation and Refurbishment works
16. Clear water Pumping/Transmission mains Rehab. Yes Yes No Yes Yes
17. Tubw wells Rehab. Yes Yes No Yes Yes
18. OHSRs Rehab. Yes Yes No Yes Yes
6.2.5 IMPORTANT MILESTONE AND KEY TIME PERIODS AS PER THE TERMS OF CONTRACT
Completion Time
Sr. from stipulated
Sectional Milestone Activities
No. date of contract
start (days)
1) Mobilization 30
Preparation and approval of Service 120
Improvement Plan (SIP) Preparation of
Plans, Drawings and Designs.
2) SIP Implementation. 1095 Design, construction, testing,
commissioning and completion of
all works as per milestones to
deliver water services
Water supply works:
3) Providing, laying, jointing and testing of Supply, laying, jointing and testing
water supply distribution line in 10% of of distribution networks including
total DMAs including supply, Installation giving house service connections.
and commissioning of Bulk Meters,
220
pressure sensors, level sensors for
DMA’s to enable sectional completion
and commissioning of DMAs Including
house service connections.
4) Construction and commissioning of Design, construction, testing, trial
minimum one clear water Clear Water run and commissioning as per
Pumping House system with CWR milestones to deliver water.
220
including all Electrical & mechanical
items, instrumentation (Including
SCADA).
5) Refurbishment of exsitng clear water Design, construction, testing,
pumping mains by jointing, testing and 220 commissioning and completion of
commissioning of as per scope. all works as per milestones to
Completion Time
Sr. from stipulated
Sectional Milestone Activities
No. date of contract
start (days)
deliver water services.
6) Providing, laying, jointing and testing of Supply, laying, jointing and testing
water supply distribution line in 30% of of distribution networks including
total DMAs including supply, Installation giving house service connections.
and commissioning of Bulk Meters,
410
pressure sensors, level sensors for
DMA’s to enable sectional completion
and commissioning of DMAs Including
house service connections.
7) Construction and commissioning of Design, construction, testing,
minimum one Chlorination room with its commissioning and completion of
system including all electrical, 410 all works as per milestones to
mechanical works, instrumentation deliver water services
including SCADA.
8) Commissioning of complete distribution Commissioning and completion of
system laid up to sr. no. 6. 510 all works as per milestones to
deliver water services
9) Providing, laying, jointing and testing and Supply, laying, jointing, testing and
commissioning of water supply commissioning of distribution
distribution line in 60% of total DMAs networks including giving house
including supply, Installation and service connections.
commissioning of Bulk Meters, pressure 690
sensors, level sensors for DMA’s to
enable sectional completion and
commissioning of DMAs Including house
service connections.
10) Providing, laying, jointing, testing and Design, construction, testing,
commissioning of TWs water commissioning and completion of
690
rising/transmission main as per scope. all works as per milestones to
deliver water services.
11) Refurbishment of existing TWs as per Design, construction, testing,
scope including all electrical, mechanical commissioning and completion of
690
works, instrumentation including SCADA. all works as per milestones to
deliver water services.
12) Providing, laying, jointing and testing and Supply, laying, jointing, testing and
commissioning of water supply commissioning of distribution
distribution line in 90% of total DMAs networks including giving house
including supply, Installation and service connections
commissioning of Bulk Meters, pressure 970
sensors, level sensors for DMA’s to
enable sectional completion and
commissioning of DMAs Including house
service connections.
13) Supply, Installation and commissioning Supply,jointing, testing and
of Bulk Meters, pressure sensors, level commissioning
sensors for DMA’s, Clear water 970
reservoirs, OHSR’s, communication
RTU’s through GPRS, SCADA
14) Refurbishment of existing OHSRs/CWRs Design, construction, testing,
as per scope including all electrical, commissioning and completion of
970
mechanical works, instrumentation all works as per milestones to
including SCADA. deliver water services.
15) Construction and commissioning of Design, construction, testing,
Consumar Relation Management Centre, commissioning and completion of
970
Centre Control Centre and Master Contol all works as per milestones to
Centre. deliver water services.
Completion Time
Sr. from stipulated
Sectional Milestone Activities
No. date of contract
start (days)
16) Providing, laying, jointing, testing and Supply, laying, jointing, testing and
commissioning of water supply commissioning of distribution
distribution line in balance DMAs networks including giving house
including supply, Installation and service connections.
commissioning of Bulk Meters, pressure 1000
sensors, level sensors for DMA’s to
enable sectional completion and
commissioning of DMAs Including house
service connections.
17) Completion of Construction, testing, trial Entire work system components
runs and commissioning of the entire completed and the system tested
system complete including performance 1095 for its performance, taking over of
testing of the water system. PHED works.
Note: To an extent possible, water supply pipeline and distribution system including house connections on a
particular road will be laid simultaneously. Water supply distribution network will be largely synchronized with all
allied activities during execution as per scope of town.
The Contractor shall submit the outcome of each activity for review of Employer’s Representative immediately
after completion of the activity. Employer’s Representative will review the outcomes on regular basis and will
submit their review comments within 21 days of receipt of the document. Contractor will develop data bases for
water hydraulic and quality parameters and the daily flows at each delivery/collection point including hourly
flows and water received from water treatment plant, quality of water produced/received, pump operations,
electric parameters and Non Revenue water (NRW), manholes data, overspill of sewers, condition of water
pipeline etc.
Contractor shall also submit the activity wise Monthly Reports for review by the Employer. Progress of design
activities will be reviewed on weekly basis. For construction activities the progress will be reviewed on monthly
basis, while during the operation phase it will be on daily basis.
Material
Length
Size
Pumping Pumping main details Demand (MLD)
S. Station Existing/
No Existing/ Proposed
Proposed Design Year
mm
From To
m
It is proposed to utilise the above OHSRs to serve specific zones by gravity feed and all other zones by direct
pumping based on the topography and available distribution stations. Accordingly, entire town is divided into
following zones. The details furnished above are indicative only. The Contractor may redesign the DMA subject
to the condtions stipulated above.
Table 9 Detail of Water Supply Zones
Total no of Zones 07
6.2.10 PROPOSED WATER DISTRIBUTION SYSTEM & DISTRICT METERED AREA (DMA)
The existing Distribution system is very old and will be completely phased out except DI pipelines. Entire city
will be provided with new distribution system. The distribution system will be be gravity feed.
Details of pipes proposed in the distribution system are shown below to cover 100% municipal area.
Table 143: Details of Proposed Clear Water Pumps by PHED at Pump Houses to existing OHSRs of
Zone-5 & 6 under ongoing PHED Contract
Note:-
100 % Standby Pumps shall be provided for each section of rising main.
The duty conditions mentioned above are indicative and for bidding purpose only. Contractor shall
verify based on the topographical survey and submit the design calculations, with pump curves w.r.t.
high and low level in sump, maximum and lean demand of distribution network and critical pressure
point in DMA for approval prior to procurement.
No change in cost shall be allowed.
Table 154: Indicative details of Submersible Motor Pump Sets for Ground Water, existing TWs to Clear
Water Reservoir at Hanumangarh road Headworks
Contractor shall provide separate Chlorination room within pump house campus. Thereshall be tonner storage
area with all handling and lifting arrangements. Chlorination room shall be open from all around. There shall be
cross ventilation from all sides of room. An alkaline storage with alkaline water solution tank shall be provided
with auto sprinkling system. Chlorine tonner shall be in auto change over mode.
6.2.13 REHABILITATION, REFURBISHMENT, AND REPAIR WORKS
Rehabilitation, Refurbishment, and Repair of concrete structures is included in the Scope of Works.
Contractor shall submit the reports as per the BOQ.
The operation and maintenace cost associated with the rehabilitated existing structures and those proposed to
be constructed/rehabilitated under this contract is included in the scope of this contract. Contractor shall include
the price of Operation & maintenance of all these components under the relevant item of BOQ.
The following existing structures are to be repaired / rehabilitated
Table 17: Existing PHED H/Ws Refurbishment
S. No. Location Of OHSR Capacity (In KL) Staging
1. Ramnagar (Zone-01) 1500 18
2. Holidora (Zone-02) 500 18
3. Behrudar (Zone-03) 1500 18
4. Suryamandir (Zone-04) 1500 18
accuracy range of the meter at a flow rate of 0,5 Qmin shall be between +5% and –2%. The working pressure
shall not be less than 16 bar and shall conform to the testing in accordance with ISO 4064. The meter shall be
capable to operate in an ambient temperature of up to 500C.
The pressure loss through the water meter shall not be greater than 0.10 bar at Qn and 0.20 bar at Qmax.
Water meter must be safe against tampering. As far as possible, the meter shall be installed inside the, with a
meter box of approved make. The meter box shall be provided as per the approved QAP.
6.2.17 ILLEGAL CONNECTIONS
The Contractor, based on the findings from the Consumer Survey and its GIS based analysis or another
means, shall identify the illegal or unauthorized connections and inform local body for regularization of the
connections. On approval and after payment of prescribed charges by the Consumer, the Contractor shall
rehabilitate the connection with the specification mentioned above. Until approval of regularization by line
agency, the Contractor shall prepare and send temporary bills at the prescribed tariffs for such illegal
connections and undertake disconnection of such Consumers who have not honoured the payment obligations.
The Employer, RUIDP, will take a decision on this within a month's time from bringing to the notice. The
Contractor shall be more particular in bringing to the notice this list well in advance of commissioning new lines,
as the old lines are to be made defunct. Only one connection shall be given to one property. If multiplal
connections are required in a single property, proper application with required documentation shall be
submitted and thereafter the connection will be granted after verifiaction and acceptance of the submitted
documents.
6.2.18 REMOVAL OF OLD HSCs
After the new HSCs have been installed and the customer meter provided, the old (redundant) HSC shall be
plugged withing customer’s property boundary. No extra payment shall me made for the same.
6.2.19 COMPATIBILITY OF TAPPING SHADDLE AND FERRULES
The tapping bands and the ferrules are to be compatible fittings with the same screw threads to relevant Indian
Standards. The supplier/manufacturer of both the saddle tapping band and ferrules are to confirm their
compatibility prior to supply for the specified works.
6.2.20 METHODOLOGY OF SERVICES
6.2.20.1 DISTRIBUTION NETWORK IMPROVEMENT (DNI) ON DMA BASIS
The Distribution Network Improvement (DNI) shall be based on DMAs.The zone boundaries and DMA
boundaries will be provided as per section 6.1 to the contractor. The bidders are required to confirm the
distribution zone and DMA boundaries duly taking into account the design considerations to achieve
performance indicators. DMA boundaries will be changed and suggested by the contractor after field study and
review of the distribution netowkr design provided by the Employer’s Representaive. For designing the
continuously pressurized system, contractor shall make use of all the existing OHSRs, which are in good
condition and plan and design the distribution system accordingly. Each OHSR shall feed one or more DMA.
The Contractor should try to ensure that all DMAs included within the zones are covered with 100% metering of
consumer connections and use this data for analysing Non Revenue Water (NRW). The Contractor shall set up
hydraulically isolated District Metered Areas (DMAs) within the Service Area of each Zone. However,
interconnection with the adjoining DMA (s) should be provided to mitigate the crisis. During normal operations,
these interconnections will be closed. Each DMA, comprising about 750-1500 consumer connections, shall be
considered as basic administrative unit for the purpose of sectional commissioning and O&M purpose. The
Contractor shall review the design water distribution network on DMA basis and shall ensure during the O&M
phase that NRW is well within the limits as per the performance targets and equitable, continuous, pressurized
water supply by using the hydraulic model and simulating both present (2021) and future for Stage I (Year
2036) and Stage II (Year 2051) conditions. Each DMA will have preferably one inflow point and be isolated by
installing valves / end plugs. DMA at entry point will be provided with a bulk flow meter with RTU and an
electrically operated SCADA controlled sluice valve. Each DMA will have two Critical Measurement Points
(CMPs) for continuous logging of pressure, and the same shall be connected to SCADA and linked with GIS.
The CMPs shall be located at the highest and, as far as possible, farthest points from the command reservoir.
During design review contractor shall identify these points with consultantion of Employer’s Representative.
The performance parameters of the contraction as well as including O&M period shall be assessed on DMA
basis. DMA wise monthly reports will be generated to assess the DMA performance. Monthly meter readings
will be taken and will be linked to the NRW assessment system.
Contractor has to ensure availability of adequate water from existing/available source through present/new
system before commencement of laying of distribution network in any of the DMAs up to the satisfaction of
Employer’s Representative.
6.2.20.2 METHODOLOGY FOR DESIGNING OF DNI
The existing distribution system will not be used except DI pipe lines in the proposed Distribution Network
Improvement (DNI) plan, as the entire existing distribution network will not be used with new one under this
contract. Since the entire distribution system will be new; no measurement of current NRW prior to construction
of new system is required. Scope of contractor will involve both technical and consumer orientation with social
awareness. Contractor shall collect data of existing consumers as part of conducting house-to-house survey
and get the information on connections and tally the data by verification from the PHED/Local Body. The
consumers shall be taken in confidence and be informed time to time for the status update. All connections on
new pipelines are very critical. Contractor will start new connections and make old pipelines defunct at the time
of commissioning of new pipelines. It will be verified by Employer’s Representative before making payment for
the DMA. All the connections shifted from old water supply system to new system and new connections given
shall be recorded on GIS database duly attaching each connection with meter serial number to respective
property with social and contact data of each consumer available in database. The Changeover to new
connection shall be preferably done overnight and should not impact customers and this process shall not
extend beyond 24 hours. This database shall be of use to understand demand of water and also for servicing
consumers. The physical work shall not be started in more than 5 DMAs at a time and unless the work is
completed including commissioning of the new system and complete decommissioning of the old system in one
DMA, no sixth DMA shall be taken in hand. Pipe laying may be allowed in more than five DMAs, however, this
shall require the prior approval of the Employer’s Representative and this shall be solely on ER’s discetion only.
All informal settlements and households (slums) of economically weaker sections which are qualified as
authorized settlements, as per the eligibility conditions issued by the State Government, will be included in the
DMAs and network designs for individual household connections. Contractor shall proactively provide individual
house connections to all households including those in slums and informal settlements.
Works shall be planned and executed to provide continuous pressurised water supply in each DMA to all the
connections. The Zones/DMAs shall be equipped with the instrumentation for monitoring the performance of
service delivery in the area. The instrumentation capable of transferring the real time data to the SCADA
system shall include the parameters of performance evaluation of the contractor during the operation,
maintenance and service delivery. It shall include the DMA inlet flow meter, DMA outlet flow meter if any, and
pressure transducers at critical measurement points. The consumer meter reading data for a given month of all
the consumers within DMA shall be entered in the computer database every month and shall be used in
conjunction with the Zone/DMA inlet and outlet meter data for the month to work out the NRW of the
Zone/DMA/complete system. The pressure readings transmitted by the pressure transducers at critical points in
DMA shall not only be used for the performance monitoring and payment mechanism but also for continuously
improving the model, using it for providing connections to the new consumers duly understanding its effect on
the system' interpreting the possible losses from the DMA using the bulk flow meter and consumer meter data
and running the model to understandthe implication of the pressure readings.
The Contractor's approach and methodology towards this work shall be in line with the overall principles and
laid by the the Employer in this bid. The SIP for DNI shall be compatible with these concepts.
6.2.20.3 EMERGENCY WATER SUPPLY BETWEEN DMA’S
While the DMAs are to be designed to be operated as hydraulically discrete areas, the DMAs are also to be
designed so that they can be hydraulically utilized to meet emergency water supply situations where cross
DMA flows may be required. In order to achieve this result, it is necessary that a certain number boundary
valves are located between DMAs to facilitate flow between DMAs. While normal operation will dictate that
these boundary valves remain closed, in an emergency water supply situation, the valves may be opened to
allow flow to the adjacent area (DMA). Once the emergency has been addressed, the boundary valve may be
closed again to restore hydraulic discreteness of the DMAs.
While the DMAs are to be designed to operate under “normal” conditions with design demands, the water
supply network is also to be designed to accommodate the possible emergency water supply requirements.
In order to achieve the desired emergency capability and robust result, the Contractor is to include in the
network of the DMAs and the wider system, the following for each DMA in the water supply system:
Emergency simulated supply condition (each DMA):
Assumption that the DMA has zero inflow through its district meter(s) – water supply failure from its
main source. Assume that gate valve at district meter is closed so zero inflow/outflow to/from the
affected DMA
Assignment of an emergency water demand of 40 l/c/d equally distributed within the affected DMA
Water demands in the DMA are satisfied without flow through the DMAs district Meters, i.e. all flow to
the affected DMA is to be provided by opening boundary valves from adjacent DMAs.
It is envisaged that there will be generally be approximately two critical water mains joining DMAs with a closed
boundary valve ensuring that they remain hydraulically discrete but available for possible emergency supply.
Where the zonal supply is such that it would be impractical to supply a DMA from an adjacent DMA design the
Contractor is to undertake design to ensure the best possible emergency supply arrangement for each DMA
based on the particular water supply system configuration.”
Public awareness programs planned to achieve people's participation in managing the demand by
using continuously available water to their absolute need only and not to waste, and to communicate
importance of metered system and its benefit.
The water to be supplied shall be calculated based on the demand of the population with of 135 lpcd in
any case. Hence, demand management through interventions at consumer connections might be
required. In no case, in order to sustain demand of one zone for continuous water supply, other area
shall suffer. A continuous consumer awareness to spread the demand in different hours of the day to
bring it to the use pattern considered in design shall be implemented by working with the consumer
awareness team of the PIU. The initial teething troubles shall be overcome at earliest but not later than
60 days of commissioning of zone/DMA.
The billing shall be on-time without fail for which a detailed program shall be prepared. The first bill on
time gives early signal for those who have increased demand just because water is available
continuously.
A vigilant surveillance to see that no reverse flow occurs and, no high consumptions go un-noticed
shall be done for firstsixmonths. The pattern of water flowing out of SR shall be critically observed for
the entire day (including night) at 10 minutes interval for initial months. Unusual night flows shall be
checked by surveillance visits in the night at the time when unusual high flow is seen on bulk outlet
meter.
Valves shall be so planned and installed as to work for assesement of losses on a small unit, such as
a sub district (step area).
Checking of As built drawings supplied, verified and loaded into GIS (10% random sample)
Checking of Customer information captured, verified and loaded into billing system (10% random
sample)
Checking of Each building has a property service and registered water meter (10% random sample)
Pressure test after house service connection.
6.2.20.8 DISTRIBUTION NETWORK IMPROVEMENTS WORKS
The contractor will implement the distribution network improvement works in accordance with the technical
specifications and prudent industry practices. The primary objective of the Distribution Network Improvement is
to ensure rationalized, equitable, continuous and pressurized water services to the consumers in the service
area on a DMA based approach.
If distribution pipeline is not laid in any particular area or water meter is not possible to install at individual
connection with the approval of Employer or its Representative, measurement will be made at entry point of the
street and bulk water will be measured. Contractor will be responsible for that work which has been done by
him.
6.2.20.9 DISTRICT METERS FOR METERED AREAS
In the District Metered Areas, the minimum water pressure shall not be less than 1.2 bars (12 m water column)
and should not exceed 3 bars (30 m water column). Pressure is either controlled by the topography or pressure
reducing valves, if necessary.
District Meters shall be Bulk flow meter with RTU either powered by electricity with adequate protection against
power fluctuations or for remote areas with adequate battery power supply. All BFM with RTU have to be
connected to the SCADA System.
If an water supply zone is having more than one DMA then at the outlet of OHSR there will be Electromegnetic
Flow Meter and at DMA entry points BFM with RTU will be used. Electric supply to RTU or EMF will be isolated
from water pipe lines. There should be straigt length of 5D & 3D before and after flow meter. No valve/specials
shall be allowed in between these lengths.
6.2.20.10 VALVES AT DMA ENTRY POINT
DI resilient seated electrically operated SCADA controlled sluice valve shall be installed at the DMA entry point.
If the there is single DMA for one OHSR then no separate valve shall be required for DMA inlet, valve installed
at the outlet of OHSR shall work as DMA entry valve. These valves shall be connected to SCADA system,
However DMA entry valve shall not be operated during normal supply of water supply to the DMA.
6.2.20.11 VALVES IN DISTRIBUTION SYSTEM
Manually operated DI resilient seated In-line valves shall generally be placed at about 750 m distance from
each other. However, the Contractor shall design and install valves in each DMA in such a way that a step test
for leak detection can be performed. The usual way in which the step test is undertaken is to set up the district
for night flow determination by closure of all circulatory valves in order to remove all loops within the district and
produce a tree-line mains layout.
6.2.20.12 VALVES AT OHSR
Electrically Operated SCADA controlled DI resilient seated PN 1.6 shall be provided at inlet of the valve along
with EMF to start and stop the valve as per demand/flow. This valve and flow meter shall be applicable only for
those OHSR which are on the single pump with munltiple OHSR feeding. For single pump single OHSR
manually operated PN 1.6 rating with out EMF shall be provided. At all the outlet of OHSR two valves of PN 1.0
rating in parallel shall be provided with one electrically operated SCADA controlled and one manually operated
with one EMF. While deciding the sizing of the valve BoQ quantities shall be used first up to line size.
6.2.21 CLEAR WATER RESERVOIR
Clear water reservoirs are designed for 2 Hrs capacity of intermediate demand. CWR shall be an RCC
structure with suitable ventilation arrangement, RCC stairs for access to the each CWR compartments with
covered mumty, drain valve and piping arrangement, overflow arrangement etc.
Each CWRs shall be of two compartments. The inlet pipe will split near CWR and shall connect to two
compartments with separate inlet pipes and separate valves. The clear water reservoir shall have total live
storage above the water level required for pump with vortex free suction. The CWR roof shall be kept above
general ground level and suction head should be positive and Ventilators shall be provided in CWR roof at
suitable location and all openings of CWR shall be kept covered. The ventilators shall be provided with SS grill
and wire gauge net to prevent dust entering the clear water reservoirs. The effective storage depth shall not
exceed 5 meters.
The Contractor shall be fully responsible for the soundness of the construction, structural safety & water
tightness of the structure based on the specifications, sound engineering practices, and latest I.S. provisions.
Foundation of the CWRs shall be constructed as per provision of SBC in IS Codes and site conditions from
ground level. The capacity of Clear water reservoir(s) mentioned in scope is effective capacity. The clear water
reservoirs shall have total live storage above the water level required for pumping with vortex free suction of
respective capacity. The live storage depth shall not exceed 5.00 meters height. The CWR shall be of circular
shape with top partially flat slab & Partially dome or fully flat roof for higher capacities and fully dome for smaller
capacities, with suitable hydraulic level and ventilation, so that pump can work with positive suction. The CWR
shall be constructed with internal sump of suitable depth and width to utilize full capacity of CWR.
The scope of work includes:
I. Construction of reservoirs as per the provisions given in the “Specifications for civil works”.
II. Supply and installation of puddle collars and duck foot bends for installation of inlet, outlet, washout
and overflow pipes.
III. Supply and installation of double flanged CI/DI pipes for inlet, outlet, and washout (scour) and overflow
with specials of adequate sizes as per design.
IV. Interconnection of the inlet pipes to the feeder mains with pipe of equal size using CI/DI double flanged
pipes and required specials.
V. Interconnection of outlet pipes to the feeders for zones. The pipe sizes shall be corresponding to the
incoming or outgoing pipes as the case may be.
VI. Providing & installation of one ultrasonic type level sensors and transmitters to transmit levels to
MCC/SMC on each proposed / existing CWR provided with battery backup and, data loggers to have
daily reading and remote reading device which should be able to transfer data through GSM. Since,
electricity supply is not available, solar panel with battery shall be provided by contractor.
VII. An alarm should be provided so as to give a hooting sound when CWR is about to become empty.
VIII. Providing & installation of at least two sluice valves on each outlet, for each reservoirs. The sizes of
the valves shall be equal to that of the main on which they are to be installed.
IX. To provide valve chambers for all valves installed on the inlet, outlet, scour & overflow pipes.
X. Providing float valve with auxiliary float in each CWR. The size of float valve shall be same as that of
inlet pipe. The pressure rating of valve should be in accordance with the maximum designed pressure.
XI. Providing scour/washout pipes up to suitable length to drain the water away from the structure in an
environment friendly manner, using a sluice valve equal to the size of washout pipe as listed above,
CI/DI double flanged pipes and required specials.
XII. The washout pipe will be of 150 mm dia. for all CWRs.
XIII. Testing of tank for water tightness and structural stability by filling it with water and in accordance with
the procedure laid down in tender document.
XIV. Final clearance of site before handing over the work, including leveling of earth and disposal of surplus
earth as per directions of the Employer’s Representative.
Ancillary Works
The works required are as listed below but not limited to:
I. Work of boundary wall of minimum 120 cm in height with wire fencing above wall and one MS gate for
the campus areas as per approved site plan.
II. Site grading and plantation of campus areas.
III. Women friendly toilet facility should be created in Pump Houses, construction site camp office and
SCADA system building for the same adequate design parameter to be included.
6.2.22 OVERHEAD SERVICE RESERVOIR
The capacity of the OHSR shall be reviwed and calculated from the inflow-outflow analysis. The OHSR shall be
provided additional volume for Fire Demand as per CPHEEO norms.
Every OHSR shall have four vertical pipes, viz. Inlet, Outlet, Overflow and Washout. Overflow and Washout
pipes shall be extended to discharge in the nearest nallah or as as recommended by Employer’s
Representative. All the operating valves shall be provided at ground level for the ease of operation.
Details of RCC, plinth protection, lightening arrester, finishing, testing etc. shall be as specified in the Technical
Specifications.
6.2.23 WATER DISTRIBUTION SYSTEM
The scope of work includes, but is not limited to the Design, Construction, Supply, Installation, Testing, Trial
Run, Commissioning, and 10 year O&M of all Civil, Mechanical, Electrical and Instrumentation Works related to
clear water rising main, distribution system with other ancillary structures along with all material, labour, tools &
plants, operating the system and maintaining within limits of the performance indicators and training to the
maintenance personnel. Proposed flow diagram of the ditribution system is shown in the tender for guidance.
Contractor’s scope also covers confirmation of topography survey, soil investigation and review of design of
distribution network within the project area as specified in this section/clause of the bid document. Contractor
shall also design proper distribution network in various areas and link to various Water Distribution
Stations/Others. Command area of each Water Distribution Stations/OHSRs shall form one Zone and a Zone
will comprise of one or more DMAs. Each DMA should generally consist of around 1000-1500 consumer
connections or lesser. If any DMA is having more than about 1500 connections, then the DMA shall be further
divided into more DMAs. As far as possible there shall be only one interconnection between the DMA’s. The
water supply scheme proposed in this project is planned considering continuous pressurized water supply for
the town. Pre-requisites for implementing the continuous pressurized water supply, with adequate residual
head of 12 mwc is the availability of sufficient quantity of water and an efficient pipe network for distribution of
water.
Existing distribution system with AC, CI and PVC.pipes will be completely phased out as most of the pipes are
damaged or outlived therer material/design life and totally new distribution system with HDPE and DI pipelines
envisaged. For design of the water distribution network, design criteria shall be as per CPHEEO Manual, latest
edition. The hydraulic design of distribution network shall be done by modeling software like WaterGems/
EPANET, which will be compatible with GIS. The approximate quantity of pipe lines for each diameter and pipe
material to be laid for rising main and distribution system is given in price bid. These quantities are only for the
bid purpose and shall be verified by the contractor at the time of putting forth designs as part of SIP.
The scope of work shall include but not to be limited to:-
As per the topographic survey provided by the employer, alignment survey and soil investigation
through trial pits along the pipe line route, including bench marking as per specifications, locating and
submission of the drawings in hard and soft forms, all as per section 6.1. The existing water mains &
structure along the right of way of the pipelines to be covered in alignment survey.
Hydraulic model will be provided to the contractor as per section 6.1. Contracotr shall review the
deisgn and calculation along with alignment and L-section with location of different types of valves and
appurtenances such as bulk flow meters with RTU. Existing metallic water mains to be utilized in the
design of distribution system to the extent technically feasible and it shall be decided after assessment
of carrying capacity and condition of the pipes and as directed by the Employer’s Representative.
Surge protection system for rising main shall be provided as per design to be put forth by the
contractor. However, the contractor executing the works, will take into consideration the details of
approved pump head calculations and pump characteristics curves, system curves, data sheets etc, in
order to ensure proper design of surge protection for the pipeline system. Detailed surge analysis shall
be carried out by the Contractor and necessary devices like zero velocity valve, air cushion valve, air
valves and/or surge vessels etc. shall be provided accordingly. No extra claim shall be entertained on
this account. Contractor shall also prepare a hindrance plan, according to which the route shall be
finalised in consultation with Employer’s Representative. No claim, on account of any change in
alignment/level shall be entertained.
Providing suitable support structures for pipe. The saddle supports shall be provided with minimum 10
mm thick MS plate for supporting the pipe line on saddles and roller support where above ground.
Alternatively, PTFE bearings with stainless steel plate, supported with MS saddle shoe, may be
provided in order to reduce the friction. At each bend a designed thrust block shall be provided and at
all in-line valves and scour valves, a properly designed anchorage shall be provided. Permanent guard
rails shall be provided by the side of the pipelines, if the pipelines are above ground.
No consumser connection shall be effected from any water transmission main.
House connections are to be on proposed water distribution mains. The house connections shall be
given from water main up to max 250 mm dia. above 250 mm dia. parallel water distribution main has
to be proposed.
Parallel water supply distribution lines will be laid where road surface BT/CC width is more than 7m.
Providing public stand posts at appropriate locations to be finalised in consultation with Employer’s
Representative.
Based on the site visits, the Contractor shall carry out preliminary surveys/ confirmatory surveys to the
satisfaction of the Employer’s Representative and prepare necessary working drawings and maps.
On the basis of the survey carried out temporary/permanent bench marks shall also be established for
reference during execution.
Contractor shall also arrange for taking trial pits and test for SBC of the strata
Contractor shall also arrange for necessary labour and material for carrying out the works.
The work shall be executed conforming to the approved designs and drawings and detail and levels to
the perfect line and plumb in a highly professional manner. The work shall progress successively as
per the schedule / bar chart to be got approved before the commencement of the works.
Monthly progress of the work shall be reported to the Employer’s Representative along with all other
detail such as material consumption, test reports etc.
As the works gets completed, all the records drawings, as built drawings shall be submitted to the
Employer’s Representative.
Necessary inspection of material/equipment’s, per category shall be carried out well in advance.
No separate payment will be made for confirmatory survey, laboratory test, factory and performance
tests, testing and commissioning etc. unless they are specifically provided and quantified in the Bills of
Quantities, the BoQ. This shall be included in the rates and prices of the physical works itemized and
quantified in the bill of quantities. The payments are to be made for all supplies and physical works
described in the bill of quantities according to the measured and agreed quantities executed.
The works shall be laid out within the confines of the site in order to interface logically with the existing
infrastructure of roadways and inlet and outlet pipework. Underground services (whether physically located on
the site or not) requiring to be relocated in order to accommodate the proposed site layout shall with the
approval of the Employer’s Representative be relocated by the Contractor.
6.2.23.1 HYDRAULIC MODELLING WATER SUPPLY DISTRIBUTION NETWORK
The Contractor shall use the Hydraulic Network Model (HNM) for water supply system provided by the
employer for the review. The HNM shall be built on contour maps of 0.50 m interval GIS. The data pertaining to
water supply infrastructure like reservoirs, pumping stations, rising mains and distribution system, valves and
shall be reviwed as obtained through field study and consumer survey captured and posted on the GIS.
The junction shall be placed at the branching out/ at the crosses at the valves and where there is a
large straight length, at about every 200 m. The model shall be worked out by considering the
domestic demand as 135 lpcd water supply as per CPHEEO guidelines and actual demand for
commercial and industrial requirement.
The water use pattern for the day spread over 24 hours shall be based on the survey data captured
through consumer habits of water use in different hours at present and by following a standard pattern,
after the continuous water supply is successfully implemented.
The storage reservoir capacities shall be modelled to verify the water level in various hours. It shall
neither be empty nor overflow. The incoming flow at constant rate shall be decided accordingly.
The DMAs which are still to develop where the present water requirement is quite less as compared to
the design demand, the present scenario with existing water demand shall be run and the incoming
flow shall be adjusted accordingly. Over the O&M period of ten years, these flows shall be suitably
increased to meet the increased demand.
The minimum pressure in the distribution network when full demand in the zone cum DMA is
developed shall not be less than 12 m of water column at any ferrule point. The excessive pressure in
the typical areas shall be managed using the appropriate pressure management techniques at
distribution system level and others at the individual connection level. Measurment of pressure shall be
done at consumer meter point.
All new connections shall be marked on GIS and captured as additional demand in the model.
The hydraulic model shall be calibrated during commissioning using set of observed data of pressure from
sensors placed in distribution network at critical points of low pressures and flow recorded at the consumer
meters and bulk flow meters. The calibrated model shall be further validated using other set of live data. This
validated model shall be used for the operation and management.
6.2.23.2 PROPOSED WATER DISTRIBUTION SYSTEM & DISTRICT METERED AREA (DMA)
The distribution system will be by gravity.
The design criteria for distribution mains are as follows.
The formulae for friction loss: Hazen Williams by Latest Water GEMs software
‘C’ value for HDPE pipes: 140
‘C’ value for DI-K7 pipe: 130
Minimum residual pressure: 12m
Velocity range: Min 0.60 m/s Max 3.0 m/s
Head loss gradient Max. 5 m /km.
6.2.23.3 DESIGNING OF DMA
Following the criteria mentioned below, the DMA has been designed.
Size of DMA (e.g. number of connections—generally around 750-1500;
Number of valves that must be closed to isolate the DMA – should be kept to a minimum – natural
boundaries should be used wherever possible;
Easily visible topographic features that can serve as boundaries for the DMA, such as rivers,
drainage channels, railroads, highways, ridges etc.
Number of flow meters to measure inflows and outflows (fewer meters required, lower
establishment cost, more accurate flow measurement ); and
Based on the expected number of connections for phase-2 period.
Each zone is divided into sub-zones, called District Metered Areas (DMA). Each DMA will be separated
(isolated) from other DMAs hydraulically so as to measure the actual volume of water supplied and volume of
water billed. The difference will give the non-revenue water (NRW). Sub-zoning into DMA will help to accurately
measure this NRW and to take action to reduce the NRW to an acceptable benchmark, thus increasing the
revenue to the local body. Details of water accounted for and unaccounted for (i.e. NRW) are explained in the
following sections.
6.2.23.4 TRANSMISSION MAIN FOR TW WATER AND CLEAR WATER
6.2.23.4.1 HYDRAULIC MODELING
It is expected that the Contractor will use a system optimization software package for the purpose of review
final sizing of water mains which will be laid as part of this Contract. Pump duties have been firmed up and
indicated in Bid Document and shall form the base data for pipe sizing. Contractor shall obtain final levels of the
components such as suction level at CWRs, pump level, maximum and minimum water levels at reservoirs
from the survey that will be used for the purpose of this contract and finalize the combination of optimum pump
heads and pipe sizes vis-à-vis lengths of pipelines to be taken up for execution of works. This exercise shall be
reported as part of Design Report to be furnished by the contractor and on approval by the Employer’s
Representative; the design shall be submitted for approval within the prescribed time periods listed as part of
the SIP under this section.
The Contractor shall develop a Hydraulic Network Model (HNM) for the clear water transmission system. The
software used shall be fully compatible with the GIS software. The HNM shall be built on contour maps of 0.5 m
interval GIS. The data pertaining to existing and new transmission system infrastructure like reservoirs, pump
stations, water transmission mains and transmission appurtenances viz. in line valves, scour valves, air valves,
pressure points and flow measuring devices and demand allocations shall be suitably located and sized
through field survey. All valves to be used for pressure and flow control and for isolation shall be appropriately
included with their hydraulic characteristics in the hydraulic model to be developed.
Following broad guidelines may be followed during hydraulic modeling for tranmission mains:
The storage capacities shall be modeled to verify the water level in various hours. It shall neither
be empty nor overflow. The incoming flow at constant rate shall be decided accordingly. At all
times from construction completion date when the water supply system will be commissioned up
to contract completion date, all reservoirs being fed shall never get emptied and minimum water
level in the reservoir shall be not less than 0.5 m.
The hydraulic model shall be calibrated using set of observed data of pressure from sensors
placed in transmission network at critical points of high and low pressures and flow from the bulk
flow meters. The calibration of the transmission system modelshall be a continuous and iterative
process. This model shall be used for the operation and management and while making decision
for modification in the Bulk Supply pattern having its effect on the transmission network.
The model will be considered calibrated during O&M phase if the deviation between the output data and the
measured values is less than 15% and improved on routine basis.
Table 23: Design Criteria for Sizing of Transmission Pipeline
Sl. No. Parameter Parameter
1 Design Period 30 Years
2 Design Flows As per water demand.
3 Minimum 3 m head of water
Residual Head
4 Formulae Modified Hazen William
6 Minor Losses As per actual site alignment, 10% for design purpose over and
above friction losses.
7 Velocity Not less than 0.6 m/sec.
9 Diameter for As per economic design of pumping main
selection
10 Appurtenances Air Valve, Scour Valve, Air Cushion Valve, Isolation Valve etc.
Design of rising mains/feeder mains and associated works shall be reviwed for ultimate capacity –year
2051.Economical designs for the proposed transmission mains and feeder mains have been done from the
clear water pumping stations at headworks to Sub-Headworks.The transmission mains and feeder mains are
shown in Bid Document drawing. The details of the transmission mains and feeder mans are shown in this
section 6.2.
Following appurtenances shall be provided on the transmission/pumping mains r:
(i) In-line Sluice Valves I Butterfly valves at suitable locations for flow control and for isolation during
maintenance shall be provided with a minimum distance between two valves on the same pipeline not
exceeding 2 km.
(ii) Scour valves at lowest points for drai ning the pipelines when required. These valves will be provided
at locations where the water taken out of the pipes could be drained away from the pipelines through
natural drains.
(iii) Air valves for removal of air from the pipelines and for air entry into the pipelines. The air release
valves shall be sized not less than 1/12th of the size of the mains on which it will be fitted. The dual
purpose air valves (e.g. double kinetic valve) will be sized not less than 1/8th of the size of the main.
(iv) The entry point battery limit shall be fitted with a sensor having arrangement of permissible fixed flow
rate with a predetermined value that can be set by the system operators time to time when necessary.
The valves should provide indication automatically when the flow rate exceeds the preset value
equivalent to the average daily flow from the entry point.
(v) Pressure reducing val ves shall be provided at suitable locations in case the pressure due to the
pumps and I or boosters is likely to increase beyond the allowable maximum operating pressure for the
pipelines
(vi) Appropriate surge protection devices shall be designed and provided along the alignment of pipelines in
order to ensure safety against bursts due to positive and negative surges.
(vii) Non-return valves shall be installed near the pumping stations to ensure pump safety.
Adequate care needs to be exercised during selection of location for valves, anchor blocks and thrust blocks so
that there are no obstructions created by construction in the regular access for transport and movement of local
populace.
6.2.23.4.2 SECTIONALIZING VALVES
Providing, installation and testing of on-line butterfly/sluice valves, of the same diameter as that of pipe line, at all
junction points, on the main incoming pipe as well on all branch pipes. All valves to be installed at a particular
junction may be housed in one chamber of appropriate size, the drawing of which shall be got approved from the
Employer’s Representative. The pressure rating of valves shall be as per the design pressure at the point of
installation but not less than PN 1.0. The locations of sectionalizing valves shall be proposed as per site
conditions and shall be got approved from Employer’s Representative. No sectionalizing valve shall be required
for a section of pipeline (node to node) of length less than 2 km. The sectionalizing valves shall be installed in
chambers with dismantling joint and other specials. Minimum clear dimensions of the chamber shall be as per
the specifications given in Bid documents. The wall, roof and other structural members of the chambers shall be
constructed as per design, which shall be got approved from the Employer’s Representative.
6.2.23.4.3 KINETIC DOUBLE BALL AIR VALVES
The scope of work under this item includes providing Double Kinetic Air Valves with isolating sluice valves along
with required connecting pipe, specials, clamps, jointing material etc and its installation, testing etc on pumping
mains/distribution mains. Size of the valve shall be not less than 1/12 th of the size of the pumping main. DI
kinetic double air valve shall be used. The work will also include providing, testing & installation of respective
size of kinetic air valves with isolating sluice valves. The air valves shall be placed as per the approved L-
sections on ridge points may be on an interval of 750 – 1000 meter and contractor shall show the location of the
air valves on the L- section as per survey.
6.2.23.4.4 SCOUR VALVES
Providing, installation and testing scour valves in all transfer mains and rising mains of diameters 200 mm and
above at an average spacing of 1 km. The locations of scour valves in transfer mains and rising mains shall be
proposed as per site conditions and shall be got approved from Employer’s Representative. The scour valves
shall be installed in chambers with dismantling joint and other specials. Minimum clear dimensions of the
chamber shall be as as per approved drawings. The wall, roof and other structural members of the chambers
shall be constructed as per design, which shall be got approved from the Employer’s Representative. Scour
valves shall be provided at vealley locations as per the L-section as approved by the Employer’s Representative.
The scope or work under this item includes providing & fixing of Scour Valve, valve rod, Dismantling Joint,
Jointing Material, Tees, Bends etc.
6.2.23.4.5 VALVE CHAMBERS
The work includes construction of RCC Valve Chambers at each location of Sectionalizing/Air valve/Scour valve
along with providing manhole cover with locking arrangement, at least one SS ladder / SFRC foot steps for
access to floor of the chamber and suitable pedestals for supporting the valve and pipe. Location of the valve
chamber and top level shall be decided as per the direction of Employer’s Representative.
6.2.23.4.6 DISMENTLING JOINTS
All Sluice, Butterfly, Scour, Air, valves, meters or any other online valves etc. shall be installed between flanges
with a flexible CI dismantling joint at one side. The joint must allow dismantling of the valve, meters etc. without
causing stress to the joints of the attached pipes. The minimum clearance of the dismantling joint shall be five (5)
cm. The pressure class of the dismantling joint shall be the same as that of the pipe. Drawings of the dismantling
joint shall be submitted to the Employer’s Representative for approval. The nuts and bolts of the joint shall be
galvanised. The joints shall be painted /coated as per the specification given for exposed pipes.
6.2.23.4.7 DUAL PLATE CHECK VALVES
Ductile Iron Dual Plate Check Valves shall be flanged type shall be installed on the delivery side of the pumps,
and shall be suitable for installation in a horizontal pipeline. Valves shall possess high speed closing
characteristics and shall be designed for minimum slam condition when closing to ensure that the valve will
rapidly fully close the moment forward flow of the water ceases i.e. on pump shutdown, external counter weights
will not be acceptable. Material shall be DI as per accordance BS EN 12334. They shall have resilient sealing.
The spring action shall optimise the equal closing rates of each plate especially when the friction coefficients are
uneven due to one plate resting upon one another. The plates shall not drag on the seat while opening. The
plates shall not vibrate under full or partial flow condition. The valve body shall be furnished with a clearly visible
cat, forged, machined-in, or die- tamped arrow to indicate the direction of flow through the valve. At pump
houses DPCV of 1.6 PN rating shall be installed.
6.2.24 LAYING AND TESTING OF WATER PIPELINES
Contractor shall lay the pipe lines with the fittings, specials and valves, valve chambers and thrust blocks. Laying
shall not be allowed without fittings, specials, valves and valve chamber. Paymnent of the laying shall only be
made if fittings, special and valves laid simultaneously. Water supply distribution line shall be laid alongwith
house service connection pipe up to consumer end. Existing water supply connections on old laid water supply
lines shall be removed from the property and shall be plugged. Hydrotesting of the line shall be done with fittings,
specials and valve. Distribution line shall be tested along with house sewervice connection.
6.2.25 MEASUREMENT OF NRW
Sensitive flow measurement and pressure sensor devices are to be permanently installed onto the inlet pipes
to each DMA to establish an intelligent network and flow and pressure profiles are recorded using data loggers.
These profiles may be transmitted via Global Systems for mobile communications (GSM) or any other
communication media, to a personal computer in the control room and the results shall be tabulated in spread
sheet shown below to arrive at the final results.
ZONE NO.
NAME OF WATER DISTRIBUTION STATION
DMA-1 DMA-2 DMA-3 DMA-4 DMA-5
NUMBER OF CONNECTIONS
NUMBER OF TAPS
NUMBER OF LEAKAGES
METER INSTALLATION
INSTALLATI
ON/REPLAC REPLACEMENT
EMENT
IDENTIFIED ILLEGAL CONNECTIONS
INITIAL
SYSTEM
INPUT AFTER ACTIVITIES
ZONE NO.
NAME OF WATER DISTRIBUTION STATION
DMA-1 DMA-2 DMA-3 DMA-4 DMA-5
VOLUME IN
M3/DAY SAVINGS
UNBILLED
QUQNTITY
ILLEGAL
CONNECTION
S
BEFORE ACTIVITIES METER
INACCURACY
NRW (%)
REAL LOSS
(LEAKAGES)
LOSS BY
FIXED RATE
TOTAL
AFTER ACTIVITIES
6.2.26 OPERATION AND MAINTENANCE
The contractor, under the scope of this work shall carry out the following activities, but these shall not limit
requirement of other activities, which otherwise are required as per term and conditions of contract or to fulfil
contractual responsibilities or are essential as per good industrial practices. The contractor shall be
responsible for:
a) Supplying designed per day requirement of water with required quality and at desired pressure
up to consumer end.
b) Providing the minimumspecified staff as approved during operation and maintenance and in
emergencies.
c) Providing all required consumables required for functioning / operation & maintenance of
equipment.
d) For flow measurements of meters at pumping stations/OHSRs, reading shall be recorded every
day& reading of consumer meters shall be taken quarterly and will be signed by Employers
representative and Contractor.
e) Preventive / breakdown maintenance of all pumps, electrical, mechanical & instrument
equipment, installed under the contract. All costs including costs of all material, equipment, etc
required for operation and/or maintenance (preventive and / or breakdown) to be borne by the
contractor.
f) Maintenance of the lighting fixtures and the lighting system of the areas and replacement of all non
functional lighting fixtures within 24 hours.
g) Maintaining;
Repair history of all mechanical, electrical and instrumentation control equipment Logbooks.
Every day power availability, input voltages, KWH meter, power factor readings at pumping
station.
Daily operation of pumps with every hour readings for operating voltage, amperage and
power factor, pressure on the manifold, pressure at outlet of pumps and flow rate in common
manifold.
Last periodic maintenance done for all reservoirs of the system.
Observations made during patrolling of the pipe lines.
Water Audit report of Water Supply for all installations / water supply distribution system to
be submitted half yearly.
In addition to maintenance of above logbooks the contractor is required to maintain one
inspection book at each pumping station. The complaint register must be investigated and
remedial measures must immediately be taken.
h) Providing adequate spares and maintaining adequate inventory of accessories or equipment
itself for repair of system so that the electrical, mechanical, pipe and pipe appurtenances, can
work efficiently as per the guarantees given or minimum required efficiencies asked for in the
contract, without any additional cost. At the end of the contract the contractor shall hand over
the spares, tools, tacklesetc.
i) Maintenance of the inventories for the electrical, mechanical and instrumentation equipment. The
maintenance of inventories will include but shall not be limited to:
Loading / unloading materials received and issued for works.
Proper arrangement of material in stores to ensure its safety and easy availability.
Maintaining store area neat and tidy.
Keeping records and Accounting the incoming materials as per Plants’ Store Manual.
Keeping records and Accounting the consumed materials as per Plants; Store Manual.
The contractor shall be solely responsible for the safety and security of the goods in the store
and its accountability and will be responsible for any loss or damages in stores for any reason.
He shall make arrangement for insurance cover against the value of the goods in the stores
without any additional costs on the Employer.
j) Patrolling of the water mains laid in the contract, to identify and report the damages / defects in pipe
and pipe appurtenances, cross drainage (CD) works, en-route structures frequency of the
patrolling shall be once in a day.
k) Emergency Maintenance/Periodic routine maintenance: providing a fleet consisting of suitable
hauling machine, sufficient inspection/patrolling vehicles and material hauling vehicles and any
other vehicles/machinery/equipment of adequate and timely repairs and/or for routine/periodic
maintenance/patrolling of the system. Contractor shall response immediately and mobilize the
manpower, material and machinery within 1 Hr. and required equipments in 24 hrs and take
early measure to avoid further damage.
l) Periodic routine maintenance of buildings & reservoirs built in the contract such maintenance must
ensure adequate cleanliness, ventilation, illumination and structural safely. In addition to this the
general hygienic standards must be maintained and adequate plantation should be done.
m) Updating and periodic submissions of the operation and maintenance manual as defined in
specifications for O&M works. The contractor shall take up all periodic maintenance works
provided in the approved O&M manual.
n) Submission of monthly report.
o) Co-ordination with other contractors and / or agencies responsible for the Execution, operation
and maintenance for regional schemes and Electric Supply Company.Pipeline Works Contractor
is to provide all labour and material for O&M of all pipe lines which are supplied and laid under
this contract as well as for existing pipe lines for accomplishing aims of this Project. Tools
required for jointing HDPE pipes shall be kept in good conditions always.
p) Repair of leaks, damaged portion of road, embankment, pipe and pipe appurtenances, CD
works and en-route structures identified during patrolling. Contractor shall response immediately
and mobilizes the manpower, machinery and material in 1 Hrs.
q) Emergency Repair(s) or burst(s) for maintaining regular supplies.
r) Operation of all valves quarterly and checks for proper functioning. Maintenance, of all valves in leak-
less conditions. Quarterly inspection of expansion joints and surge protection
equipment/system, and to do repairs, if required. Contractor shall submit quarterly reports of all
such activities done. Contractor shall submit preventive maintenance schedule for approval prior
to the start of the O&M period and this shall be part of Operation and Maintenace Manual.
s) Maintenance of inventory for repair of pipe leak(s) and burst(s), valves (air valve, sluice valves,
isolation valves, expansion joints, surge protection devices or any other pipe appurtenances or
equipment(s) installed.
t) To maintain the valve chambers along the pipeline in clean and dry conditions.
u) To maintain the cover on the pipe damaged due to rains, runoff or any other reason.Cleaning of
CD works along the pipeline alignment and to do required regarding works of area between road
and pipe to ensure that water is not impounded near the pipe during rainy season.
v) To record the pressure readings once daily at all pressure points and submitting the same to the
employer.
A. From sectional Commencement date to Commissioning Date:
Managing the distribution network for distributing water efficiently, equitably and minimizing
non-revenue water (NRW) and maintaining the infrastructure on DMA basis.
Providing continuous pressurized water supply to the connected consumers and maintaining
the infrastructure.
Meter reading, customer services and maintaining the infrastructure.
Detecting and minimizing non-revenue connections and consumption.
Provide consumer service connections on approval or sanction by Employer/Employer’s
Representative
Provide continuous on-the-job training and institutionalise other capacity building programs
and execute the programs.
Sectional commissioning of DAM shall be considered only when all the associated work
related to the DMA shall be completed in all respect right from source to pumping station to
OHSR/GLR to DMA.
B. From Commissioning date to Contract Completion date:
Pumping water from headwork to the CWRs including maintenance of entire system from
TWs/Source to the CWRs and maintaining the infrastructure.
Operating pumping stations at headworks and Maintenance of the same.
Sampling treated water received at CWR at pumping stations and within distribution system
to ensure that it meets the Potable Water Specification and monitor on regular basis;
Managing the distribution network for distributing water efficiently, equitably by providing
continuously pressurized water supply to the consumers and minimizing non-revenue water
(NRW) and maintaining the infrastructure on DMA basis.
Providing continuous pressurized water supply to the connected consumers and maintaining
the infrastructure
Meter reading, bimonthly billing, bill distribution revenue collection and customer services
and maintaining the infrastructure
Detecting and minimizing non-revenue connections and consumption
Provide consumer service connections on approval or sanction by Employer/Employer’s
Representative
During emergency situation ensure water supply system operation so that the supply to the
consumer is maintained to the best possible manner.
Provide continuous on-the-job trainings and other capacity building programs.
Pumping sewage from SPS to Manhole of Sewer line including maintenance of entire sewer
network system from property to STP.
OperatingSewage pumping stations.
Water supply coneection during O&M period and installation of water meter for these new
connections.
If the water at the Consumer location / CWRs is not found to meet Potable Water Specification then the
Contractor shall report to the Employer representative and take necessary remedial steps as per directions
given by Employer representative.
If the Contractor fails to achieve the services defined in performance targets, then the Contractor shall be
levied with Non-Performance Adjustment as specified in Schedule 7 of section 8 of PCC. The Contractor
shall not be liable for Non-Performance Adjustment to the extent such failure is attributable to a Release
Event in which event the Contractor shall take necessary steps to mitigate the effects of the event and
operate the potable water system in accordance with the standards of a reasonable and prudent way.
Contractor shall ensure that a minimum water level at all water retaining structures (CWRs) of not less than
0.30m shall be maintained at all times from reference date to the upto contract completion date.
The Contractor will supply the water through water tankers during emergencies and for special functions as
per direction of Employer representative.
Replacement of equipment, assets or infrastructure which is not part of the contractor’s work or agreed in the
SIP for replacement shall be paid separately. Contractor will include costs for repairs of bulk flow meters,
valves, panels, motor pumps and all other equipment and its spares including battery, and other equipment in
his quoted price.
Useful life of house service connection meters (domestic meter) is considered as 7 years from the
date of commissioning of meter. If any meter requires replacement before 7 years period, it will be
replaced at costs of the Contractor and will not be paid. In case any meter going out of order, only one-time
replacement shall be allowed. Any more replacement shall be on account of the contractor.. Any meter
requires replacement after seven years period will be paid with the quoted rate under Operation Service
Costs. For such replacement, Contractor will submit request to the Employer. Employer, with proper due
diligence and verification that it really requires replacement, will approve for replacement. Any equipment
supplied and installed by the contractor shall not be paid separately for replacement or repairs etc, except
house service connection meters.
6.2.27 TYPICAL NON REVENUE WATER (NRW) SECTION DURING THE O&M PERIOD
The following structure is a guideline for Contractors on how they may wish to structure their NRW section
during the O&M period.
It should be noted that this is only an indicative structure and the size and number of teams will vary
according to the size of the project and the particular site conditions.
18) 1 x set of safety equipment to meet the specified safety requirements including clothing, traffic
management cones and signage, flashlights etc.
The above equipment will be carried in the leak detection team’s vehicle and be available for use during the
leak detection activities.
The Contractor is to identify suitable staff to undertake future leak detection activities and all staff is to be
provided with training by the Contractor’s leak detection equipment supplier/manufacturer. The equipment
supplier/manufacturer is required to provide a certificate of competency for each of the contractor’s nominated
leak detection team members who have been successfully trained.
In addition to the leak detection staff, the Contractor is also to nominate its Lead Detection Team Supervisor
who should have a minimum of ten years leak detection experience and be highly skilled and knowledgeable
in leak detection techniques. The Supervisor should be capable of managing leak detection teams and
ensuring that leak detection activities particularly at night are well managed and effective
6.2.29.1 TRAINING PLAN AND MANUALS
1. As part of the Works and before beginning training, the Contractor shall submit to the Employer, 6
copies of complete operating and maintenance instructions for the system, referring specifically to
the Plant. The documents shall also be presented on a compact disk in Microsoft Office
2003/2007 Word or latest version available for Windows software format and manual should also
be prepared in local regional language i.e.in Hindi.
2. Each copy of the instructions shall be contained in a substantial binder.
3. These manuals shall include but not be limited to the following information:
o Detailed descriptions of the Plant operation and control scheme.
o Manufacturer’s original operation and maintenance procedures.
o Complete parts list for all items of the Plant.
o Recommended spare parts list.
o Detailed maintenance instructions for all items as necessary to maintain the items in good
working order, including all step-by-step procedures for troubleshooting and fault correction.
o Configuration of data base, reports, logs and screen displays.
o Data communication interface standards and protocols.
o All ladder logic and control loop flow diagrams.
o Programme user instruction for all software
o The system shall provide on line, complete user documentation, including examples of how to
operate the various modules within the system. The documentation must be in electronic
format, HTML based with the ability to search for topics by keyword or search for specific text.
6.2.29.2 TESTS TO BE CARRIED OUT DURING O&M PERIOD
The minimum requirement of sampling and testing is to be carried out daily at least at the points given below.
This schedule shall also be maintained during the O&M period:
Flow, turbidity, pH – online measurement for clear water; SS as per CPHEEO manual.
Turbidity, pH and aluminum – online measurement for clarified water; SS as per CPHEEO Manual.
Flow, turbidity, pH, residual chlorine and aluminium – online measurement for final treated water; SS
and Total Coliforms and E.Coli as per CPHEEO Manual.
Flow, online measurement of turbidity, aluminium and SS daily in clarifier underflow and filter
backwash and centrifuge supernatant.
Filtered water quality test as per CPHEEO Manual.
SS and Total Coliforms and E.Coli daily in centrifuge cake from filtrate.
6.2.30 NON-REVENUE WATER MAINTENANCE
Throughout the maintenance period the contractor is required to maintain the water supply network and also to
maintain non-revenue water (NRW) as specified under the contract. Maintaining NRW forms one of the
contractor’s performance outcomes. The periodic calculation of NRW is not included in this section.
Within its overall maintenance responsibility, the Contractor is required to undertake the following NRW
maintenance activities. These are essential if NRW is to be truly maintained as specified under the contract.
1. Ensure that all meters are read monthly and that the data is accurately recorded in a meter
reading database.
1.1 Meters are to be read using any hand-held electronic device and the data is to be uploaded into the
meter reading database within two days of being read. When uploaded the data is to be compared to
previously recorded meter reading data and readings that are outside of a ten percent envelope of what
would be expected are to be flagged for investigation. A work order is to be raised for each
investigation. When executed the results of the investigation and any ensuing actions are to be
recorded in the maintenance management system and the meter reading database.
1.2 If a meter is unable to be read this fact is to be noted and a work order issued to address the problem.
The required action may be to relocate the meter to a place where is can be easily read, or to improve
access to the existing meter. Once the problem is rectified the meter is to be read and the reading
uploaded into the meter reading database. In extreme cases where a meter cannot be read despite
persistent attempts to do so a new property connection may need to be installed.
1.3 Meters are read monthly and where meters are read throughout a month in a cyclical manner there
must be at least 20 calendar days between successive meter reads.
2. Ensure all property connections are metered - The Contractor is to inspect all distribution pipelines
every year in periodic cycle. During these inspections the Contractor is to carry a list of properties being
provided with water in GIS platform. The Contractor is to randomly examine the property connections to
these properties and note any that do not have a meter. Subsequently the Contractor is to raise a work
order to install a meter and then install the meter within two days of identifying the missing meter. The
Contractor is to ensure the new meter is recorded in the meter reading database.
3. Ensure there are no unauthorised connections - The Contractor is to inspect all distribution pipelines
every two years in periodic cycle. During these inspections the Contractor is to carry a list of properties
being provided with water in electronic form. The Contractor is to randomly examine the property
connections to all properties and (1) note any that are not on the list of properties being supplied with
water, (2) note any that have a meter bypass pipe installed, and (3) note any that have installed a
separate unauthorised additional connection. These are to be referred to the Engineer for resolution.
Resolution options may include (1) removal of the connection, (2) authorising the connection and
installing a meter, (3) repairing the existing connection, and (4) reconnecting a bypassed meter. The
Contractor is to raise a work order for any of these actions and ensure the problem is rectified within 24
hrs of receiving an authority from the Engineer to proceed. The Contractor is to ensure each new meter,
new property connection, or meter reconnection is recorded in the meter reading database.
4. Only use electronic means to collect, store and transfer data – Meter reading data is to be entered
using any hand-held electronic device and the collected data transferred by electronic means. Data
transfers between systems are also to be undertaken electronically. The stored electronic data is to be
made secure from external or illegal access and backed up on a daily basis. The recording of data in
paper form is not permitted. Data recording, data storage and data back-up is to be supported by an
uninterrupted power supply.
5. Ensure meters are sampled and tested – Meters are to be sampled and tested in accordance with the
Indian metering standard IS 779 1994 (number and frequency). The results of the testing are to be
provided to the Employer for analysis which will assist in determining the accuracy of NRW calculations
and setting meter replacement programs.
6. Renew all defective customer meters within two days of being detected – As a result of pipeline
inspections, notifications from customers or meter readers, or meter sampling and testing, defective
meters are to be replaced within two days of receiving a work order to do so. The Contractor is to
ensure the meter reading database is immediately updated when a defective meter is replaced.
7. Collect leakage data – The Contractor is to use the maintenance management system (MMS) to
record each leakage. The data recorded is to include the location of the leak, the pipeline (material,
diameter or reference a pipeline identifier in an asset register), a description of the leak and a possible
cause of the leak; all in a standard format. This data is to be provided monthly to the employer in
spreadsheet form for analysis.
8. Collect customer feedback – The Contractor is to record each customer contact (such as walk-in,
phone call, email, SMS or web entry) in its customer management system. The customer contacts will
cover a range of issues such as water quality, low pressure, water off, property connection or pipeline
leak, defective meter, offensive meter readers, disruption due to Contractor’s works and so on. A
number of these contracts will relate to NRW. These contacts are to be collated and provided to the
Employer in spreadsheet form on a monthly basis for analysis. Where necessary (such as a pipeline
leak) a work order is to be raised and actioned within two days.
9. Maintain distribution pressure in range 12m to 30m – The SCADA system is to be programmed to
alarm each time the pressure in a DMA exceeds 30m or as specified by employer. A work order is to be
immediately raised to investigate the cause of the pressure reading above 40m and as a result
recommend steps to be taken to ensure that the pressure will not exceed 40m in the future. These
steps may include the installation of additional flow control devices or the throttling of valves. The
recommendations from the investigation are to be submitted to the Employer and when approved they
must be implemented within 20 days. Where the recommendations are not the result of a design flaw or
poor construction their implementation will be funded by the Employer.
10. Continuously undertake random transient monitoring – A pipeline pressure transient monitor
placed at different locations within the pipeline network continuously or at other frequencies as directed
by the Engineer in charge. Preference is to be given to bulk water offtakes, offtakes feeding customer
pumps, offtakes feeding customer storages and downstream of pump stations. The collected data is to
be examined and where transients are detected these are to be referred to the Employer for review.
Resulting actions are to be undertaken as directed by the Employer. Where these actions require
capital works these will be to the cost of the Employer.
11. Measure flows and pressures – Flow and pressure monitors is installed through the water supply
network. Amongst other uses this data is to be collected for the purpose of calculating NRW. Overtime a
pattern of flow or pressure will emerge at each meter location. The SCADA system is to be used to
monitor flows and pressures against these patterns and alarm when a reading falls outside of ten
percent variation around each pattern. When an alarm occurs, a work order is to be raised to investigate
the abnormal reading and determine any resulting action. When approved by the Employer the resulting
action is to be completed by the Contractor within 24 hrs. When the resulting action is not the result of a
design flaw or poor construction its implementation will be funded by the Employer.
12. Leaks detect each DMA every year – The Contractor is to undertake leak detection of all pipes within
each DMA every years in a periodic cycle. When a leak is detected, a work order is to be raised and the
leak repaired within seven days (Also see ‘Repair Leaks’).
13. Leak detect critical pipes at least half yearly – The Contractor is to undertake leak detection of all
critical pipes half yearly. When a leak is detected, a work order is to be raised and the leak repaired
within 24 hrs. (Also see ‘Repair Leaks’).
14. Leak detect problem areas – The Contractor is to undertake leak detection in areas which have a
history of high leakage each year. These areas are to be determined by the Employer. When a leak is
detected, a work order is to be raised and the leak repaired within seven days (Also see ‘Repair Leaks’).
15. Repair Leaks – The Contractor is to repair all leaks (including pipeline breaks). Leaks are to be
repaired within 24 hrs of notification (in times of high maintenance workload this timeframe will be
relaxed). The identification and repair of each leak is to be recorded in the maintenance management
system. The data recorded is to include the location of the leak, the pipeline (material, diameter or
reference a pipeline identifier in an asset register), a description of the leak and a possible cause of the
leak; all in a standard format. This data is to be provided monthly to the employer in spreadsheet form
for analysis.
16. Inspect service connections every year – The Contractor is to inspect all distribution pipelines every
year in periodic cycle. During these inspections the Contractor is to carry a list of properties being
provided with water in electronic form. The Contractor is to randomly inspect the service connections
(above ground) and the surface of the land within the vicinity of the service connection. If a leak is
detected a work order is to be raised and the leak repaired (see ‘Leak Repair’). Where there is evidence
of an underground leak, such as wet ground or water flowing in a nearby drain, a work order is to be
raised to investigate whether there is a leak. Such an investigation may include leak detection or
opening the ground to inspect the communication pipe. If a leak is found a work order is to be raised
and the leak immediately repaired (see ‘Leak Repair’) before the ground is closed.
17. The Contractor is to inspect all distribution pipelines every year – The Contractor is to inspect all
distribution pipelines every year in periodic cycle. During these inspections the Contractor is to carry a
map of the distribution pipelines in electronic form (GIS download). Amongst other things the pipelines
are to be inspected for leaks and for impending leaks due to excessive corrosion or fractured pipe.
Leaks may be directly evident or inferred from damp ground or water running in nearby drains. If a leak
is detected a work order is to be raised and the leak repaired (see ‘Leak Repair’). Where there is
evidence of an underground leak a work order is to be raised to investigate whether there is a leak.
Such an investigation may include leak detection or opening the ground to inspect the pipe. If a leak is
found a work order is to be raised and the leak immediately repaired (see ‘Leak Repair’) before the
ground is closed.
18. Maintain level sensors and control systems at storages –
18.1 Level sensors are to be maintained in accordance with the manufacturer’s specifications. The
maintenance specifications are to be included in the maintenance management system at part of
the preventative maintenance program. Work orders should be automatically triggered at set
dates.
18.2 The SCADA system controlling the filling of the storage must alert when the storage is
approaching full and alarm if the storage is exceeded. The storage filling control system is to be
programmed to prevent such an occurrence. When a storage alarm is triggered a work order
must be immediately generated and sent to maintenance staff for immediate action.
19. Maintain flow meters, pressure monitors and transient monitors.
20. Flow meters and pressure monitors are to be maintained in accordance with the manufacturer’s
specifications. The maintenance specifications are to be included in the maintenance management
system at part pf the preventative maintenance program. Work orders should be automatically triggered
at set dates.
21. Repair defective service connections – The Contractor is to repair all faulty service connections.
Service connections are to be repaired within 24 hrs of notification (in times of high maintenance
workload this timeframe will be relaxed). The identification and repair of each service connection is to be
recorded in the maintenance management system. The data recorded is to include a description of the
problem with the service connection and a possible cause of the problem; all in a standard format. This
data is to be provided monthly to the employer in spreadsheet form for analysis.
22. Maintain 24/7 pipe repair response capability – The Contractor is to ensure a 24/7 year-round
maintenance capability is available. Maintenance personnel must be available to attend to
23. Collect maintenance data
24. The Contractor is to provide all maintenance data in spreadsheet form to the Employer on a monthly
basis for subsequent analysis.
6.2.30.1 PROVIDING CONTINUOUS PRESSURISED WATER SUPPLY
To start with, the scheme shall be introduced in one zone. After observing the results and rectifying the
problems encountered, the scheme shall be introduced in all other zones.
The DMAs will be converted to continous pressurised supply and operated in a sustainable way.
In case of non availability of water, the contractor shall not be responsible for commissioning the
DMA at the requisite pressure.
Volumetric charging will be introduced.
The changes in customer attitudes and behavior (including coping strategies) will be monitored.
The staff must be trained in modern operational techniques like leak detection and pressure
management
Once these first set of DMAs have successfully supplied water continuously and effectively
reduced the water losses, the next set of DMAs will be established for conversion to continuous
pressurised supply.
Creation of entire DMA shall be completed within design build period and operation from the date of sectional
commissioning to O&M period.
6.2.31 PUMP HOUSE WORKS
The pumping hours for design purposes are as follows:-
Table 24: Pumping Hours
Type Pumping Hours
Clear Water 20 Hrs
TWs 20 Hrs.
VFD 24 Hrs.
Clear water pump house shall be constructed of RCC structure. Size shall be sufficient to accommodate pumps
for supplying clear water and to suit the requirement of ultimate capacity.
The or scope includes Design, Construction, Supply, Installation, Testing, Commissioning, Trial Run, and 10
year O&M of all Civil, Mechanical, Electrical and Instrumentation Works for the TWs and clear water pump
house, including but not limited to pumps, motors, valves, EOT of suitable capacity, necessary electrical
installations and instrumentation works as per specifications pumping machinery, motor, suction and delivery
lines, common / individual headers, valves, pressure guage, bulk flow meter, EMF, etc.
The contractor shall carry out all the necessary works including foundation works for pump/motor/transformer
and other equipment. Additional new structures for additional Electrical switchyard and allied works,
modification to existing structures to cater for additional load, finishing works, lighting works etc. shall be carried
out by the Contractor as detailed below. The Contractor shall suitably plan all the construction activities and
take utmost care as to allow smooth functioning of the existing pump station being operated by the existing
Contractor.
The civil works envisaged at existing TWs/clear water pump station shall be as follows, but not limited to:
a) The Contractor shall check the structural adequacy of the existing pump station in view of installation of
new pumps (work forms part of SIP & design submissions).
b) Required modifications to the existing pump station to cater to the pumps provided up to 2051
requirements
c) The Contractor shall carry out all civil works/modification works for installation, finishing and furnishing of
the building using material as detailed in the specifications.
d) Construction of Retaining walls if any for reclamation of land as necessary.
e) Fencing of the Campus including electrical substation etc. if any
f) Providing a control room totally air-conditioned for PLC in existing PH building.
g) All civil works for new substation (partly indoor) including RCC frame, roofing, trenching and laying of
cables and preparation of ballast ground floor etc.
h) Construction of foundation for new transformers and other structures of substation.
i) Dry distemper on interior and cement based paint on exterior walls of entire pumping station structure.
j) Providing internal roads, overall site grading and landscaping including planting of trees in campus.
6.2.32 PUMP DUTY POINT
Based on the detailed survey and the water demand, the duty points required for the pumps is specified herein
after, however, due to change in alignment, minir changes are expected in the levels of inlet and outlet at the
terminal points etc. which shall only be finalized after detailed layout plan of head works and the L-section of
the mains are finalized. Thus the final selected pumps may require suitable changes for operation in different
combination/speed which the contractor has to make in his final desgin submmitted for approval on the basis of
final L-sections of mains and levels of reservoir.
As it is the responsibility of the contractor to provide the designed flow to all the CWRs, DMAs the contractor on
his own cost has to do the required surveys to verify the Employer‘s data, however to fulfill the contractors
obligations the duty condition asked herein after can be changed to suit the system requirements as per the
prevailing site conditions.
6.2.33 DEWATERING / DRAIN PUMPS
The capacity of the dewatering pumps at clear water pumping station and other head works shall be 50 cum/hr
minimum. The capacity of the drain pump for clear water pumping plant at other head works shall be 5 cum/hr
minimum.
The pumps shall be electric motor driven. The pumps shall be vertical, centrifugal, non-clog type. The impeller
shall be mounted on the extended shaft of the motor.
The pump motor shall be suitable for working with or without submergence in water. The motor rating shall be
more than the maximum power required by the pump from shut off to run out.
Dewatering pumps shall be with flexible delivery piping of minimum 100 mm size. A common delivery pipe of
minimum 50 mm size, as per IS 1239, is to be provided for a set of drain pumps.
Each drain pump shall be provided with a standby.
Design, Drawings and information to be provided by Contractor
Pump data sheets and performance curves
Leaflets / manufacturer’s literature of pumps
6.2.34 DELIVERY AND SUCTION PIPES – DESIGN CONSIDERATIONS
The sizes of the delivery piping at water pump house shall be as per the velocity criterion given in the CPHEEO
manual; diameter of shall not exceed desgin velocities as per CPHEEO Manual.
For suction and delivery piping, the minimum thickness of the MS pipes shall be 8 mm for clear water and 5
mm up to diameter 600 mm and 10 mm for TW water and 6.3 mm above diameter 600 mm (inclusive of 2 mm
corrosion allowance) Buried portions of delivery piping and main header are to be coated externally.
6.2.35 FLOW METERS
Full bore electromagnetic & Bulk flow meter (with RTU) shall consist of flow sensor (i.e. flow tube), flow
transmitter and flow indicator and integrator and any other item required to complete the system. To avoid the
effects of disturbances in the velocity profile, a straight and uninterrupted run, upstream as well as downstream
from the location of the flow meter shall be provided, as required by the flow meter manufacturer and in line
with the applicable standards. Contractor shall finalize the exact location of flow meter in consultation with
Employer’s Representative.
Flow measurement shall not be affected by physical properties of water viz., temperature, pressure etc., within
given limits. Contractor shall provide compensating electronic circuits, if required.
Contractor shall construct a suitable concrete chamber for enclosing flow meter if it is to be mounted on
underground pipe lines. A concrete enclosure shall be constructed above the chamber for housing the flow
transmitter. For surface pipelines, a concrete cabin shall be constructed around the pipeline for housing the
flow meter and the flow transmitter.
A lockable enclosure shall be provided for the flow transmitter cum computing unit.
Flow meters shall be suitable for the water turbidity at site during various seasons. Flow tube shall be rugged in
construction and shall be suitable for continuous operation. Flow tube shall have waterproof construction and
shall be suitable for installation on underground /above ground pipe lines.
The flow computer and transmitter shall be a single unit suitable for field mounting. It shall accept inputs from
flow tube process the signals and shall provide an output proportional to the flow rate. The output shall be
suitable for transmitting over a long distance.
Bulk flow meter and EMF shall be designed for the flow and no extra payment shall be made for the change in
the size as per BoQ.
6.2.36 REHABILITATION, REFURBISHMENT, AND REPAIR WORKS
a) Existing structures are to be repaired/ refurbished to the satisfaction of Employer’s
Representative. Following main activities are to be executed in these works –
1. All concrete and plastering works are to be done using mix in higher proportion than the existing, to ensure
proper adhesion and strength. Contractor has to ensure that the new material sticks to existing by using
cement slurry and or epoxy / adhesive wherever required.
2. Providing and applying free flow, self compacting Microconcrete into the watertight shuttering for
columns, beams jacketing as per manufacturer’s specifications including fixing shear anchors of
sufficient length by drilling in the concrete for all jacketing works.
3. All existing structures are to be inspected after dewatering and desilting. All damages (spalling of
plaster, spalling of concrete, damage to floor, rusting of steel etc). It has to be made good to the
satisfaction of Employer’s Representative.
4. All existing doors and windows in the existing buildings are to be made functional to the satisfaction of
Employer’s Representative. Damaged fittings (handles, tower bolts, locks, etc.) and glass panels etc are
to be replaced by new one. If required the completed door / window panel has to be replaced by
contractor.
5. All existing structures are to be repainted both inside and outside including doors, windows and SS
railing etc.
6. All exterior walls of the existing building to be provided with Washed stone grit plaster with vertical
grooves.
7. All interior walls, ceilings and surfaces of the existing building to be provided with plaster / tile surfacing /
any other surface requirement as per specification.
8. All interior walls, ceilings and surfaces of the existing building to be painted as per specification.
9. All repairable concrete cracks to be made good by contractor to the satisfaction of Employer’s
Representative by pressure grouting.
10. Dismantling of existing damaged floors and reconstruction of flooring with proper slope and as per
specification.
11. Providing / refurbishment of ramps in the existing structure.
12. Providing and laying 100mm thick M-30 grade interlocking paving blocks with kerb stone on both sides
in a width of 3.0m from the entrance of premises to the existing building/ structure.
13. For refurbishment of roof and terrace - Removal of defective concrete in the roof slab, cleaning the
surface thoroughly, applying the concrete mixture mechanically with compressed air under pressure to
repair the roof of the existing building. Contractor has to ensure slope on flat roof for proper drainage of
water from drain pipes to avoid any accumulation of water during rains.
14. For refurbishment of roof - Proposing to raise top level of existing CWR by 300 mm using light weight
filler material. Contractor has to ensure slope on flat roof for proper drainage of water from drain pipes to
avoid any accumulation of water during rains.
15. Installation of sand cast iron SS pipes as the rain water pipe from the roof.
16. Coping of the parapet walls of the existing building.
17. Installing / Painting of mono rail to lift the pumps and the motors.
18. Providing and laying 100mm thick M-30 grade interlocking paving blocks with kerb stone on both sides
in a width of 3.0m from the entrance of premises to the existing building/ structure
19. Replacing all mechanical and electrical equipment with new equipment
20. Replacing water level indicator with specified number of level indications as per specification and
direction of Engineer.
21. R R Stone pitching with hammer dressed from small stones are to done with 30 cm thickness along the
side of wall as a Protection work.
22. Making new service road with a view of easy accessibility and approach to the structure and around.
23. Removal of silt deposited in the bed of the reservoir to be done with initial lead of 50m and lift upto 1.5 m
with proper dressing of the bed.
24. Providing and laying of C C Coping in (1:2:4) of 50mm thickness on top the masonry wall
25. Providing and laying of Random Rubble Stone Masonry in foundation and superstructure wherever the
wall is dismantled and necessary required.
26. Repainting of markings / slogans on existing structure.
27. Food grade two coated epoxy paint have to be applied on all interior walls, top dome and floor surfaces of
the structures (after surface preparation).
28. Fixing of Clamps, Float Valve, specials and water level indicator, wire mesh at ventilator etc.
29. G.I Strips for earthing
30. Exhaust fans of energy efficient type.
31. Outdoor and Indoor lighting with Solar Panel system / isolated pope lighting.
32. Removal of bushes and planting of trees in the vicinity of existing building/ structure with half brick
circular tree guard (distance to be maintained from building/ structures).
Plastering and Repairing (by guniting or any other suitable method) wherever required
All seepage / cracks to be made good by using pressure grouting.
Whole structures are to be repainted both inside and outside including doors, windows and SS
railing etc.
Providing / dismantling / refurbishment of railing by Aluminium Railing in existing structures.
All existing doors and windows are to be made functional and glass panels etc are to be replaced
by new one.
Terrace treatment by applying the shotcrete mixture mechanically with compressed air under
pressure to repair the roof and ensure proper slope for drainage.
Dismantling of existing damaged floors and reconstruction of flooring with proper slope and as per
specification
Providing / refurbishment of plinth protection as per specification.
Providing and laying interlocking paving blocks from the premises entrance with kerb stone in a
width of 3.0m.
Cleaning and removal of debris at site
Any Specific Activity
6.2.36.1 AUDIT OF EXISTING STRUCTURES
Audit of structure shall be a scientific method for assessing the structural integrity with respect to stability,
durability and safety requirements of the structure.
Contractor shall submit his initial assessment about the structures subjected to preliminery audit and then
detailed audit shall be carried out on approval of Employer’s Representative.
The preliminary audit including the detailed audit shall form part of SIP cost.
Following situations may justify conducting audit of all the existing structures:
Structures that have signs of distress due to damage caused by overloading or due to chemical
attacks under aggressive atmospheric conditions.
Existing structures which are required to be modified to suit new loading conditions or expanded
horizontally or vertically to add floor area. In industrial plants, the need may arise due to
upgradation requirements of plants. Thereby requiring higher capacity equipment loads to be
imposed on the existing floors or to create additional floor space for new equipment.
6.2.36.1.1 METHODOLOGY OF AUDIT
Civil / Structural audits are carried out adopting the following steps:
Physical survey of the structure and data collection as per format given
Making drawings of the structures showing architectural details, column /beam sizes and slab
thickness.
Critical review and organising non destruction tests if required (NDTs)
Assessment of reserve strength / weakness in various elements of the structure
Findings and recommendations
Strengthening / repair / rehabilitation measures identified to suit the given requirements
Concrete Strength as per field test: NDT Core locations to be defined. In general Columns are
observed to be sound hardness and the concrete beyond corrosion zone gives sound
appearance.
DOCUMENTS FORMING BASIS OF CONSTRUCTION
Mechanical / Equipment / Architectural drawings
Construction / Erection drawing
Project design parameters / Design calculations
Geotechnical investigation report
As Built drawings
Modification information, if any
Limitations regarding availability of drawings load data, quality rest records
MODIFICATIONS / DEVIATIONS DURING CONSTRUCTION
Change in depth of foundation
Construction joint
Substitution of Reinforcement Steel
Member size
Concrete Grade
Substitution in Structural Steel
Any alternations made to the structure
MODIFICATIONS AFTER CONSTRUCTION FOR UPGRADATION
Details and type of changes
Month/ year of changes
Strengthening measures adopted
Drawings / Details of changes
DETERIORATION and DISTRESS SIGNS DUE TO EARTHQUAKE / OTHER REASONS
Excess defletion
Crack development (type location extent
Flaking of concrete
Exposed corroded reinforcement
Additional Information
If feasible, a brief discussion is held at site with different persons who have been associated with the
construction and for those responsible for maintenance of the structures, It is very useful to know the
construction methods and sequence of construction adopted at the time of construction.
6.2.36.1.4 CRITICAL REVIEW OF EXISITNG STRUCTURES
Based on site visits and collected data, critical review is carried out with the following objectives:
Establish the adequacy of information/data.
Planning for core tests and in-situ investigations, if warranted.
Assess the parameters to be adopted for analysis/design and prepare a design brief.
Identify probable potential areas where the structure is under distress or is likely to be distressed.
6.2.36.1.5 CORE TESTS AND IN-SITU INVESTIGATIONS
Based on physical observations and critical review, the following can be established:
Grade of concrete in the structural elements to be considered in design checks.
Strength/ductility of steel in structural components.
Adequacy of reinforcement covers from durability point of view.
Probable causes for material deterioration and corrective measures for prevention of future
deterioration.
Role of quality of construction materials in causing damage to the structure.
Presence of chloride and sulphate in soil and dust sticking on the structures.
To establish these parameters, core tests and in-situ investigations needs to be organized.
Following tests broadly form the coring and NDT work:
Core. sampling including twin cores for assessing the:
o In-situ compressive strength/grade of concrete.
o In-situ density of concrete.- Depth of carbonation.
o Chloride and sulphate content.
o Ultrasonic Pulse Velocity (USPV) tests for assessment of the in-situ strength of concrete.
Cover meter survey.
Tests on reinforcement steel.
Chemical analysis of concrete, dusts and soil samples.
Deflection measurements of beams.
The core tests and in-situ investigations should. be carried out as per the specifications prepared for the work.
Groundwater samples will be collected from the injection water stream, screened zone (aquifer), and the
extraction water stream prior to rehabilitation. The injection and extraction samples should be collected from
the sampling ports, and the aquifer sample should be collected using a submersible pump.
Biological assay samples do not require refrigeration if they are received by the laboratory within 24 hours of
sampling. In addition, no preservatives are to be used in the sampling bottles.
6.2.37.5 BAILING
During this process, a suction bailer is lowered into the well until it fills with water and sediment. It is then
pulled to the surface and emptied. Water from the aquifer will then flow towards the well and bring in more
drilling fluid. The bailer’s up and down motion causes a surging action which initiates development in the area
around the screen.
Prior to initiating the bailing procedure, the water level, and total depth of well will be measured noting the
amount of sediment in the well (as compared to the total depth in the “as built”). Next, the sediment will be
removed from the bottom of the well using the suction bailer and the contents will be emptied into a drum. The
color, clarity and smell of the water will be noted in the field notebook. After the sediment has been removed
from the bottom of the well, the total well depth will be measured again. Throughout this process, purge water
present in the drum will be decanted to a water storage container and the amount of material (i.e. sand/silt,
etc.) present in the bottom of the drum will be noted (i.e., the amount of sediment removed from the well). The
amount of accumulated sediment in the well should progressively decline following successive rehabilitation
events.
If similar increased sediment volumes are noted in a well during successive rehabilitation events, the OU-1
treatment system will be evaluated for debris discharge and/or more aggressive development methods will be
considered.
6.2.37.6 BRUSHING
Brushing simply involves running a hard bristle brush up and down the length of the well screen to remove
sediment encrusted on the well casing and screen. Similar to bailing, the up and down movement of the brush
produces a surging effect, continuing the development process.
6.2.37.7 BIOFOULING TREATMENT
Following the completion of brushing and bailing, a chemical solution is applied to the well to facilitate the
breakdown of biofilm, and to disperse mineral salts that are present in the well screen and the filter pack. The
chemical treatment will be applied following the manufacturer’s recommendations.
To ensure the proper distribution of the chemical treatment in the screened zone, the treatment mixture will be
tremied into the upper, middle, and bottom third of the well screen. To improve the effectiveness of the
chemical treatment, the well will be swabbed every two hours. The agitation caused by swabbing ensures the
distribution of the chemical treatment through the screened zone and filter-pack. The solution should remain in
the well between 18 to 48 hours depending on the severity of the biofouling and/or encrustation. In addition, it’s
important that the pH of the treatment solution stay below 2.0. If the chemical mixture is left in the well
overnight, a water and acid mixture should be added to the well to ensure that the pH remains below 2.0. The
following morning, the pH should be tested and, if it is greater than 2.0, it should be lowered with the acid and
water mixture. After this has been completed, the well should be swabbed for at least one hour.
Next, an airlift pump system will be lowered into the bottom of the well to remove the chemicals, biofilm and
mineral salts. During the airlift pumping process, the pH of the discharge water will be monitored, and the
airlifting will continue until the pH of the discharge water is >5.
Upon completion of the airlifting, a second chemical treatment will be performed, as described in the section
above.
6.2.37.8 MUD DISPERSANT
In contrast to initial well development, during well rehabilitation only one mud dispersant treatment will be
performed (however, in some cases [e.g., excessive drilling mud present in the well] a second treatment will be
necessary). In theory, the mud dispersant treatment will follow the completion of the initial rehabilitation steps
of brushing, sediment removal, and biofouling treatment. In order for the mud dispersant to penetrate into the
filter pack and beyond, fouling materials (i.e. biological growth, mineral encrustations, etc.) need to be removed
and the available flow paths restored.
• Dual-Swab Airlift
During well rehabilitation, dual-swab airlifting will be utilized after the mud dispersant treatment application to
remove accumulated sediment and groundwater containing the treatment chemicals.
Groundwater containing the treatment chemicals will be removed to the extent practical to minimize potential
impacts to the treatment system (e.g., downgradient extraction).
Initially, the dual-swab tool will be inserted into the well and set at the top 3m of the screened zone. Airlift
pumping will occur at the maximum rate possible for a period of approximately 40 minutes or until the turbidity
of the purge water is less than = 5 NTU. Due to the turbidity of the airlifted water, the initial water will be
pumped into a settlement tank before being transferred to a containment tank. The dual-swab airlift equipment
will be raised and lowered throughout the entire screened zone. During the airlift pumping, the air supply will
be periodically shut off allowing the water column to flow back through the screen. The combination of
swabbing, pumping and surging enhances the removal of trapped material in the screened zone and filter-pack.
Upon completion of dual-swab airlifting, a second mud dispersant treatment/dual-swab airlifting process may
follow.
6.2.37.9 CONVENTIONAL SURGE PUMPING
This stage of rehabilitation involves pumping and surging the wells at a variety of rates until no further sand,
turbidity, and drawdown declines are observed.
6.2.37.10 EQUIPMENT RE-INSTALLATION
Using the development rig, the PVC casing (injection well) and steel casing and pump (extraction well) will be
reset into the well. Once the equipment is lowered into place, the well head flange plates will be bolted, and
associated piping reconnected to the injection or extraction line. The electrical wires connecting the transducer
or pump should be re-connected, and tested. Finally the equipment should be leak tested and injection and
extraction rates tested.
6.2.37.11 WASTE (REHABILITATION WATER AND SEDIMENT)
Purge water that is generated during the rehabilitation process will be highly turbid, and in some cases may
contain acid or mud dispersant chemicals. Without treatment, water that has been treated with acid to remove
biofouling and/or scaling shall be safely handled by approved procedure for dealing with the solid and liquid
waste that is generated during the well development and well rehabilitation process.
6.2.37.12 INJECTION TESTING
At the completion of the well rehabilitation, the well will be yield tested to determine the success of the
rehabilitation procedure. For the case of duty tubewells, this activity will be planned in such a manner that does
not disrupt normal water supply operations of the utility.
6.2.37.13 ELECTROMECHANICAL REHABILITATION
The aim of the inspection work is to find out status of the existing tubewell pumping equipments, how much
water could be supplied from the existing tubewells and how many pumping equipments could be re-used or
replaced.
6.2.38 MANAGEMENT INFORMATION SYSTEM
Contractor shall develop, establish, operate and manage during the entire contract period a comprehensive
Integrated Management Information System (MIS) in respect of all matters including but not limited to:
Design Built activities
All the Operation & maintenance activities
billings and collection systems;
a. Consumer services, including data bases relating to complaints and questions, response
times and resolution;
b. Financial management, including accounting systems;
Performance information systems; and
Others as identified during SIP preparation and implementation.
6.2.39 ESTABLISHING BILLING AND REVENUE COLLECTION SYSTEMS
The Contractor shall:
Prepare and monitor the profile of water service Consumers in the Service Area describing
consumer categories and other attributes collected through consumer survey in a GIS platform
geocoded to the property footprints. The database and software shall be in a position to analyse
the number of Consumers under each category, estimated average volume of water consumed
per month, and estimated average revenue per month;
Develop and implement basic Standard Operating Procedures for
service connections, (ii) preparing, issuing, and collecting a bill for water service, (iii) how water
consumption is estimated for meter under repair Consumers, and (iv) dealing with under-payment
or non-payment;
Develop and implement: (i) meter reading procedures and arrangements, (ii) meter reader
control, and (iii) efficient and accurate meter reading practices;
Set up and implement in detail the revenue collection procedures, and the facilities for achieving
the high level of revenue collection efficiency.
6.2.40 METER READING
The Contractor shall:
Read all consumer water meters in accordance with the general instructions of the Employer on
monthly basis;
the continuous daily program shall be charted out. The observations shall be recorded and those meters which
have gone beyond the accuracy limits specifies in IS779, shall be serviced to reinstate the accuracy.
6.2.43 TRAINING
Contractor will provide on the job training during operation services to the staff of Employer/ PHED and Town
MC. Such trainings will be commenced 30 days prior to commissioning the first DMA. Also that in the last year
of O & M period and before 30 days from the date of handing over the assets back to the Employer, the
Contractor shall organize detailed training to the identified staff in technical, commercial and financial aspects
of water services provision to enable the Employer to build sufficient capacity and skills to manage the water
services after the Contract Completion Date. Commencing from 30 days before the Contract Completion Date,
the staff either from Employer or from a future Contractor will overlap and co-manage the operations to ensure
continuity in service delivery.
6.2.44 ELECTRICITY CONSUMPTION
The Contractor, during the preparation of the Service Improvement Plan or execution of bulk water works shall
assess the capacity of pumps and motors proposed to be provided, the arrangements for maintaining the
power factor before taking over the same etc. During operation & maintenance period, the contractor shall be
responsible to maintain power factor; any equipment required to maintain power factor willbe installed by the
contractor under provisional sum and will be paid separately. Contractor will be responsible for maintaining
power factors at the pumping equipment installed by him. Electricity connections at all existing and proposed
permanent installations will be applied by contractor and will be reimbursed to contractor under provisional
sum. Power charges will be directly paid by the Employer. Penalty if any levied by the electricity company for
not maintaining the power factor will be recovered from the contractor as per actual.
6.2.45 WATER AUDIT REPORT
6.2.45.1 SCOPE
The scope of water audit shall cover all aspects from the water supplied to the distribution system as well as
water losses and/or used with the distribution system and what eventually reaches to the customer’s premises
and is billed/converted into revenue for the utility. This covers the procedures for determination of the various
components of the water audit.
The objectives of preparation of the water audit are to:
a. Ease assessment of the utility’s water loss situation.
b. Improve understanding and identification of problems/issues pertaining to reduction of unaccounted for
water and enhance effectiveness of its improvements through more reliable data.
c. Enhance meaningful benchmarking with other service providers.
d. Deepen understanding of the water for purposes of prioritising attention and investments.
6.2.45.2 KEY VARIABLES IN THE WATER AUDIT REPORT
a. System Input Volume The volume of treated water input to that part of the water supply system to
which the water audit calculation relates.
b. Authorized Consumption The volume of metered and (or) unmetered water taken by registered
customers, the water supplier and others who are implicitly or explicitly authorized to do so for
residential, commercial and industrial purposes. Authorized consumption may include items such as fire
fighting and training, flushing of mains and sewers, these may be billed or unbilled, metered or
unmetered.
c. Water Losses The difference between System Input Volume and Authorized Consumption. Water
losses can be considered as a total volume for the whole system, or for partial systems such as
transmission or distribution schemes, or individual zones. Water Losses consist of Physical Losses and
Commercial.
d. Billed Authorized Consumption Those components of Authorized Consumption which are billed and
produce revenue (also known as Revenue Water)
e. Unbilled Authorized Consumption Those components of Authorized Consumption which are
legitimate but not billed and therefore do not produce revenue.
f. Apparent (Commercial) Losses Includes all types of inaccuracies associated with customer metering
as well as data handling errors (meter reading and billing), plus unauthorized consumption (theft or
illegal use). Commercial losses may also be referred to as Apparent Losses or Non-Technical Losses.
g. Real (Physical) Losses Physical water losses from the pressurized system and the utility’s storage
tanks, up to the point of customer’s meter. Physical losses are also referred to as Real losses or
Technical losses.
h. Billed Metered Consumption All metered consumption which is also billed. This includes all groups of
customers such as domestic, commercial, industrial or institutional.
i. Billed Unmetered Consumption All billed consumption which is calculated based on estimates or
norms but is not metered.
j. Unbilled Metered Consumption Metered Consumption which is for any reason unbilled.
k. Unbilled Unmetered Consumption Any kind of Authorized Consumption which is neither billed nor
metered.
l. Unauthorized Consumption Any unauthorized use of water. This may include illegal water withdrawal
from hydrants (for example for construction purposes), illegal connections, bypasses to consumption
meters or meter tampering.
m. Customer Metering Inaccuracies and Data Handling Errors Commercial water losses caused by
customer meter inaccuracies and data handling errors in the meter reading and billing system.
n. Leaks Water lost through leaks.
o. Bursts Water lost through bursts.
p. Over Flows and Leaks at Storage Tanks: Water lost through overflows and/or leakage of water
storage facilities.
q. Revenue Water Those components of Authorized Consumption which are billed and produce revenue
(also known as Billed Authorized Consumption.
r. Non-Revenue Water Those components of System Input which are not billed and do not produce
revenue.
6.2.46 PAYMENT SCHEDULE FOR CLEAR WATER RESERVOIR:-
The following is the price break-up of work against work done (based on turn-key). Payment equal to 10% for
work shall be released (deducted at each payment) after successful trial run & commissioning as per conditions
of the contract. The break-up of payment is mentioned below.
Table 25 PRICE BREAKUP CWR
S.No BREAK UP %
a E/W Excavation and PCC for underground CWR and foundation in hard rock for CWR 15%
walls column.
b RCC Raft foundation, walls and columns of CWR. 20%
c RCC walls columns inside CWR of CWR and allied structures 20%
d RCC work for slab, stairs ,mumty and valve chamber 13%
Masonry work for mumty finished work including plaster, doors, windows ventilators
e 7%
,railing and finishing etc.
f Piping, fittings,Padels ,700 MM DI from CCT to CWR etc 5%
g Testing of CWR structure. 10%
h Commissioning of the system 10%
Sub breakup of RCC WALLS AND COLUMNS
S.No SUB BREAK UP %
1 14%
Construction of RCC wall for CWR & sump up to 1st lift.
2 17%
Construction of RCC wall for CWR and Sump up to 2nd lift.
3 20%
Construction of RCC wall for CWR and sump up to full height.
4 Construction of columns from raft up to 1st lift. 14%
5 Construction columns from up to 2nd lift. 15%
6 Construction of column up to full height. 16%
7 2%
Allied Structures Intake Structures, overflow chamber etc
8 Allied Structures valve chambers 2%
TOTAL 100%
Sub breakup of RCC WORK FOR SLAB, STAIRS AND MUMTY
S.No SUB BREAK UP %
1 RCC work for slab 85%
2 RCC work for stairs 10%
3 RCC work for mumty 5%
TOTAL 100%
S.No BREAK UP %
Sub breakup of MASONRY WORK FOR MUMTY, FINISHING WORK INCLUDING DOORS WINDOWS
VENTILATORS RAILING
S.No SUB BREAK UP %
1 Masonry work for mumty 40%
2 Finishing Work 20%
3 Doors Windows Ventilators 25%
4 Railing 15%
TOTAL 100%
Table 26 PRICE BREAKUP CWPS
Payment Schedule is in percentage of total amount quoted by contractor for the turnkey job except for O&M
For CWPS in price bid of Vol-II
Particulars %age
Total Amount in Rs. 100.00%
Progressive Payment Related to Design & Construction 80.00%
Payment Related to Wet Testing and Trial Run 10.00%
Payment on Commissioning 10.00%
Total 100.00%
DESIGN, DRAWING AND DOCUMENTATION 4.80%
CIVIL WORKS 33.60%
MECHANICAL WORKS 32.00%
ELECTRICAL AND INSTRUMENTATION WORKS 9.60%
TOTAL 80.00%
Sub Head Payment of Design, Drawing and Documentation – Component Wise
Schedule-1: Design, Drawing & Documentation (4.8%)
Layout & Hydraulics 2.00%
Architectural & Structural Designs and Drawings 0.96%
Mechanical inculding piping, Electrical and Instrumentation & Control Design and Drawings 1.60%
Walls / Columns, 1st lift (including all chambers, launders, plate forms etc up to this lift) 15.0%
Walls / Columns 2nd lift (including all chambers, launders, platforms etc up to this lift) 15.0%
Walls / Roofing, 3rd lift (including all chambers, launders, platforms etc up to this lift) 20.0%
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Name of Work:-Construction of Works of Water Supply Production and Distribution Network Improvements
with house service connections for nonrevenue water reduction and continuous water supply and Providing
Sewer Network with House connections, and construction of Sewage Treatment Plant & Sewage Pumping
Station and all allied Works and operation services of the entire system for 10 years at Sardarshahar (Churu).
TABLE OF CONTENT
6.3.1 OVER VIEW OF EXISTING SEWERAGE SYSTEM .......................................................................6
6.3.1.1 DETAILS OF EXISTING SEWER LINES- ........................................................................................6
6.3.1.2 SEWAGE PUMPING STATIONS (SPS)- .........................................................................................6
6.3.1.3 SEWAGE TREATMENT PLANTS ...................................................................................................6
6.3.2 SCOPE OF WORK UNDER THIS PROJECT FOR DESIGN BUILD PERIOD-SEWERAGE ..........6
6.3.3 SCOPE OF OPERATION AND MAINTENANCE PHASE ...............................................................7
6.3.4 IMPORTANT MILESTONE AND KEY TIME PERIODS AS PER THE TERMS OF CONTRACT ....8
6.3.5 DOCUMENTS COMPRISING THE TECHNICAL STANDARDS ...................................................10
6.3.6 THE SURVEY WORK FOR ALL THE SEWER LINES ..................................................................10
6.3.7 GENERAL SCOPE OF WORK & CONTRACTUAL REQUIREMENTS .........................................11
6.3.8 ALIGNMENT SURVEY AND THE L-SECTIONS ...........................................................................12
6.3.9 DESIGN CRITERIA ADOPTED FOR SEWERAGE NETWORK ...................................................12
6.3.10 PIPE MATERIALS ..........................................................................................................................13
6.3.11 MANHOLES ...................................................................................................................................13
6.3.12 HOUSE SEWER CONNECTION ...................................................................................................14
6.3.13 HOUSE CONNECTION INSIDE PROPERTY BOUNDARY ..........................................................15
6.3.14 STORME/INDULSTRIAL/CHEMICAL WASTE WATER DISCONNECTION .................................16
6.3.15 TRENCHING FOR OPEN EXCAVATION ......................................................................................16
6.3.16 SHORING ......................................................................................................................................16
6.3.17 PIPE BEDDING ..............................................................................................................................16
6.3.18 TRENCHLESS WORK ...................................................................................................................16
6.3.19 DEFLECTION TEST FOR SEWER LINE ......................................................................................19
6.3.20 LAYING AND HYDROTESTING OF SEWER LINE .......................................................................20
6.3.21 ID SYSTEM FOR MANHOLE, ROAD SIDE INSPECTION CHAMBER AND SEWER PIPES ......21
6.3.22 DESIGN CRITERIA ADOPTED FOR SEWAGE PUMPING MAIN ................................................21
6.3.23 SEWAGE TREATMENT PLANT AND SEWAGE PUMPING STATIONS ......................................21
6.3.23.1 SCOPE .......................................................................................................................................21
6.3.23.2 CONSTRUCTION DOCUMENTS ..............................................................................................23
6.3.23.3 PROCESS GUARANTEES FOR STP .......................................................................................24
6.3.23.4 COMPLETENESS OF THE OFFER ..........................................................................................24
6.3.23.5 GENERAL ..................................................................................................................................25
6.3.23.6 RAW AND TREATED SEWAGE CHARACTERISTICS .............................................................26
6.3.23.7 DESIGN PARAMETERS FOR STP BASED ON SBR ...............................................................28
6.3.23.8 MAIN PROCESS UNITS ............................................................................................................28
6.3.23.9 PLANT LAYOUT AND HYDRAULIC PROFILE..........................................................................30
6.3.23.10 ORIENTATION ...........................................................................................................................31
6.3.23.11 GENERAL DESIGN REQUIREMENTS-STP .............................................................................31
6.3.23.12 TREATMENT PROCESS SPECIFICATIONS ............................................................................33
6.3.23.13 DESIGN CRITERIA - SPS .........................................................................................................33
6.3.23.14 GENERAL DESIGN REQUIREMENTS - SPS ...........................................................................33
6.3.24 RECEIVING OF SEWAGE AT STPs .............................................................................................35
6.3.25 Upgradation of Existing STPs (5MLD & 2 MLD) ............................................................................36
6.3.26 CIVIL WORKS FOR STPS & SPS .................................................................................................36
6.3.26.1 PLANT LAYOUT AND HYDRAULIC PROFILE..........................................................................36
6.3.26.2 INLET CHAMBER / STILLING CHAMBER ................................................................................36
6.3.26.3 COARSE BAR SCREEN CHANNEL..........................................................................................37
6.3.26.4 COARSE BAR SCREEN ............................................................................................................37
6.3.26.5 DISTRIBUTION CHAMBER .......................................................................................................38
6.3.26.6 SUMP WELL ..............................................................................................................................39
6.3.26.7 PUMP HOUSE ...........................................................................................................................39
6.3.26.8 INLET CHAMBER AT STP.........................................................................................................39
electrical, mechanical (including Pumps, motors, air blowers, interconnecting piping, valves, mechanical
screens, screen conveyor, dewatering unit,disinfection unit EOT/HOT Crane etc.), instrumentation,
automation and SCADA works and Stores etc. along with ancillary civil works.
Table 2: Proposed Sewage Treatment Plants
S. No. Description Capacity (MLD)
1 STP-South 7.30
2 STP-North 5.40
3 Gandhi Vidya Manir University campus 1.60
Operation and Maintenance- 10 Years operating and Maintenance of Sewerage System (from inspection
chamber to STP) including collection and intermediate Pumping stations and STPs with performance
guarantee of collection system laid under this project.
Reuse of Treated Effluent - Design, construction, execution, testing and commissioning of Treated
Effluent Elevated Reservoir (TEER), Treated Effluent Storage Reservoir (TESR), Effluent Pumping Station
(EPS)including but not limited to all relevant Civil, electrical, mechanical (including Pumps, motor,
interconnecting piping, valves, EOT/HOT Crane etc.), instrumentation, automisation and SCADA works and
Stores etc. along with ancillary civil works.
Disposal of Treated Effluent - Design, construction, execution, testing and commissioning of sewer pipe
from STP effluent chamber to natural drain identified by Employer Representative including but not limited to
all ancillary civil works.
SludgeManagementand Disposal–Safe Disposal of sludge up to designated places provided by the
Employer or line agency within 10 km distance from STP.
The Scope of Services shall include all technical, managerial, administrative, commercial, environmental, and
social interventions as required in accordance with acceptable, prudent waste water utility construction and
management practices. Please provide reference to IEE/Social/CAPP/IDCB interventions. The Scope of
Services mentioned above is indicative only and the contractor is required to undertake his own detailed
investigation of the Project Facilities to determine the complete Scope of Services for achieving the Minimum
specified Service Levels.
Quantities indicated above are indicative and need to be confirmed by Contractor through SIP, and all
components covered under the contract for implementation of SIP are to be planned in detail including
commissioning and operation and maintenance.
6.3.3 SCOPE OF OPERATION AND MAINTENANCE PHASE
Contractor shall be responsible for operation, maintenance and management of the entire waste water services
under this contract in service area as detailed below:
Table 3: Scope of Works under Operation and Maintenance Phase
S. Obligation Period
No.
1 sewage pumping system to pump sewage to STP including From Date of
maintenance of entire system and maintaining the infrastructure commissioning Certificate
(power charges to be paid by the Employer) including STP
2 sewage treatment plant (STP) including maintenance of entire system From Date of
and maintaining the infrastructure (power charges to be paid by the commissioning Certificate
Employer) including STP
3 Managing the sewerage network for collection of sewage including From Date of
maintenance of entire system from property chambers upto disposal commissioning Certificate
outfall of Sewage to STP including STP
4 Sampling treated effluent to ensure that it meets the guaranteed From Date of
treatment parameters; Commissioning
Certificate.
5 Provide house connections for collection of sewage from house From Date of
properties on approval or sanction by Employer Commissioning
Certificate.
6 Contractor will provide continuous on-the-job trainings that will start From Date of
from the day the contractor gets mobilized, and other capacity building Commissioning
programs by the contractor as important regular activities for staff of Certificate.
the Employer, PHED and Municipal Council / Corporation Banswara.
S. Obligation Period
No.
7 Maintaining environmental norms at entire system components. From Date of
Commissioning
Certificate.
6.3.4 IMPORTANT MILESTONE AND KEY TIME PERIODS AS PER THE TERMS OF CONTRACT
Table 4: Milestone and Key Time Periods
1) Mobilisation 30
2) Preparation and approval of 90
Service Improvement Plan (SIP)
Preparation of Plans and Design
3) SIP Implementation 1095 Design, Construction, testing,
commissioning and completion of
all works as per milestones to
deliver water services
Waste water works
4) Construction of Boundary wall Construction of boundary wall at
190
all SPS and STP locations.
5) 10%/ 8 Km Sewage Collection Supply, laying, jointing, testing
Network connecting directly to and flow test of sewage collection
existing sewerage network networks and connecting with
including main, sub main and main sewers to reach to STP and
lateral sewer upto property make functional including property
190
chamber connecting with main chamber and pipes upto property
sewers to make it functional chamber.
including House sewer connection
from Property chamber to sewer
outlet inside property.
6) Additional 30%/22Km Sewage Supply, laying, jointing, testing
Collection Network ( besides and flow test of sewage collection
S.no. 5 above) (Total 40%/ 30 networks and connecting with
Km) including main, sub main and 480 main sewers to reach to STP and
lateral sewer upto property make functional including property
chamber connecting with main chamber and pipes upto property
sewers to make it functional. chamber.
7) Construction of minimum one STP Design, Construction, wet testing
with SBR Technology complete in and completion of all works as per
480
all respect. milestones to deliver sewerage
services.
8) Construction of minimum one Design, Construction, wet testing
SPS with pumping main and all & trial run and completion of all
480
allied works. allied works to deliver sewerage
services.
9) Trial run and Commissioning of 500 Trial run and Commissioning
STP complete in all respect.
d. The data pertaining to House Service Connections (connection to consumers) have to be collected
up to building footprint and submitted.Contratcor shall ensure that the house connections are
connected with the sewerage system by gravity.
e. The Contractor shall communicate regularly, withthe Employers Representative regarding the GIS
mapping survey data and for clarifications.
6.3.7 GENERAL SCOPE OF WORK & CONTRACTUAL REQUIREMENTS
The scope of work under this section shall includebut not limited to the following and as specified in Bill
of Quantities.
i.Review of Employers Representative’s proposals and designs: The Contractorhas to
(i) Confirm the field survey of the entire area proposed for coverage with sewerage and water supply
works,
(ii) Check the actual levels with the levels used in the Employers Representative’s proposal,
(iv)Review,proposemodification/update the sewer network and own the designs provided by Employer
(using approved hydraulic Design Software) and undertake detailed design of sewage pumping
systems wherever necessary and prepare revised drawings,
(v) Submit the revised designs & drawings and obtain approval of the Employers Representative.
ii.For laying of sewers for proposed alignment and levels, at every 10 meters interval and other necessary
locations before execution of the work including house connections, all data required for generating L
section and GIS maps of sewer network. Submission of survey drawings showing L-Sections, ground
levels at every 10 meters interval and other necessary locations, detailed strip plans showing adjacent
structures etc., in AutoCAD for approval of the Employers representative before execution of the work.
iii.Also, total station equipment shall be used to finalize the level for laying of sewers for proposed
alignment and levels, at every 10 meters interval and other necessary locations before execution of the
work including all data required for generating L section and GIS maps of sewer network. Submission of
survey drawings showing L-Sections, ground levels at every 10 meters interval and other necessary
locations, detailed strip plans showing adjacent structures etc., in AutoCAD for approval of the
Employers representative before execution of the work. The Contractor shall take prior approval of the
Employers Representative before surveying in any changes in locations or alignments from his original
proposals.
iv.Earth work excavation for pipeline trenches and manhole chambers including depositing on bank
including, barricading, danger lighting and using sight rails and boning rods at every 100 meters and
wherever necessary, including shoring, strutting, bailing out water for different strata and depth ranges.
v.De-watering for Excavation in all classifications in watery situation or foul conditions towards, including
overnight recuperation for all depth ranges, with all lead and lifts etc., complete.
vi.Providing erecting and removing three tier Barricading firmly including cost and conveyance of all
materials, labour, lead and lift charges complete.
vii.Carting of excavated Earth of all types to a lead distance detailed in bill of quantities & stacking of earth
at identified suitable site and re-carting back the stacked earth to the same site by vehicle, including
loading, unloading charges for to & fro, with all lifts, labour, HOM of machinery etc. complete. Lead
distance indicated is one side distance only. Bidder shall quote the rate for to & fro lead distance.
viii.Disposing off the excess excavated earth of all types to a distance detailed in bill of quantities by vehicle,
including neatly stacking, loading, unloading, with all lifts, labour, HOM of machinery etc. complete
ix.Construction of all appurtenant structures such as Wire cut Brick, RCC Cast in-situ / Pre-cast manhole
structures, using SRC (sulphate resisting cement confirming to IS 12330 with latest revisions) with SFRC
frames & covers, SFRC footsteps, drop manholes, ventilating shafts, pipe supports, drain and road
crossings, etc. as per Bill of Quantities, approved drawings and relevant IS codes including all temporary
works and safety measures.
x.Interlinking the existing sewer lines with proposed lines and vice versa.
xi.The contract covers, Conducting Level Survey of proposed and Existing sewerage system by Collecting
ground levels, invert level of sewers, size and type (material of construction) of Sewers and at every
manhole, including depth of manhole and measuring length in between manholes and safely closing the
manhole cover, preparation and submission of Drawings in AutoCAD & GIS with all particulars in
complete manner as per specification and as directed by the Employers representative for cross verifying
the adaptability of existing sewer network with the proposed, which will be verified by Employers
Representative’s engineers, and decision will be given to retain or reject the part or whole of the existing
sewer network. Levels shall be carried from the nearest Bench mark given by Employer representative
for conducting this survey.
xii.Providing pipes for House Service Connections from Manholes / Sewer lines as per specifications and
approved drawings and as directed by the Employers representative etc. including all materials such as
connecting pipes, earthwork, pipe line laying and jointing, bedding etc.
xiii.Backfilling the trenches in layers of specified thickness, material as per detailed specifications.
xiv.Providing Road or Railway crossing by adopting Trench less Method as per specifications and as
directed by the Employers representative in compliance with the NHAI/PWD/Indian railways authority or
or any suitable method as per guidelines of InDSTT (Indian Society of Trenchless Technology)
xv.Taking all measures complying the Environmental Management Planrequirments and monitoring the
same as per detailed specifications.
xvi.Contractor shall be responsible for providing insurance as provided in Contract data.
xvii.Testing and commissioning the sewers after laying and construction of manholes and its testing as per
specifications/IS codes.
xviii.Submission of as built drawings of sewer lines & its appurtenances, including L-sections and plans as
per specifications including existing laterals for which the Contractor has conducted the existing system
level survey showing the entire sewer network is in the scope of this contract. The scope also covers
associated civil works including protective works, encasing of pipes with concrete and RCC / D.I. and
HDPE, PVC pipes at road crossings, all safety measures etc.
xix.All works shall be done as per the specifications, in Bill of Quantities and in compliance to the Technical
specifications and as approved and directed by the Employers representative. Indicative Drawings
related to the works to be done, are given for guidance of the Contractor. For the execution of Works,
exact details shall be given by the contractor based on the alignment survey drawings. Approved for
construction drawings shall be prepared by the contractor and got approved from the employer before
execution of any works.
xx.The prospective bidder is expected to visit the site of works at his own expense to fully study the local
conditions and to familiarize with the working area and local conditions and include all such factors in his
quoted rates.
xxi.Trial run of the System:-After commissioning of works or a section of the completed works, the
Contractor shall conduct trial run to demonstrate satisfactory performance to the Employer’s
Representative prior to declaring commencement of O and M.
6.3.8 ALIGNMENT SURVEY AND THE L-SECTIONS
The Contractor shall carry out the Survey work for laying of lateral sewers, branch/sub-main/main/trunk sewers
for proposed alignment and levels, at every 10 meters interval and other necessary locations, before execution
of the work, including all data required for generating L section and GIS maps of sewer network. Contractor
shall submit the survey drawings showing L-Sections, ground levels at every 10 meters interval and other
necessary locations, detailed strip plans showing adjacent structures etc., in latest version of AutoCAD as per
the sewer network designs prepared by the contractor for approval of the Employers Representative before
execution of the work.
The Contractor shall be deemed to have considered this aspect and made provision, while quoting the rates for
Sewer pipe, supply, laying and jointing item in the tender. If the alignment and flow directions of the sewers are
to be changed according to the site conditions and the Employers Representative agrees to that, the Contractor
has to redo the alignment and level survey at every 10 m and junction points, and submit all the details in latest
version of Auto Cad & GIS in soft form to Employers Representative, and shall again carry out the design of
that particular stretch and take up the work on receipt of approved designs from Employers Representative.
6.3.9 DESIGN CRITERIA ADOPTED FOR SEWERAGE NETWORK
The Sewerage Network to be Designed, Built, refurbished if applicable, operated and maintained, as detailed in
the ITB/BDS sections, Tested and Commissioned by the Contractor shall comply with the guidelines contained
in “Manuals on Sewerage and Sewage Treatment - Part A - Engineering, Part B - O&M, and Part C -
Management” Latest Edition(s) published by the Central Public Health & Environmental Engineering
Organization (CPHEEO), Ministry of Urban Development, Government of India.
Table 5: DESIGN CRITERION FOR SEWER NETWORK
Parameter Criterion
DESIGN PERIOD The design period for the project is taken as 30 years with Base year as 2021.
Intermediate year as 2036 for design of Electro-mechanical equipment of
pumping Station and for Design of Sewage Treatment Plants
Ultimate design year as 2051 for design of sewerage system and civil
structures of pumping stations.
PER CAPITA SEWAGE As per CPHEEO norms, about 80% of water supply finds its way as
FLOW wastewater into sewers, i.e. 108 lpcd. In addition to that, 5% provisions have
been made for accounting non-domestic flows. Per capita flow of 113.4 lpcd,
including provision for infiltration (500 liter/km/day) shall be considered for the
design.
PEAK FACTOR As per CPHEEO norms.
HYDRAULICS OF
SEWERS
DESIGN FLOW – Manning’s formula will be adopted for the design of sewers.
FRICTION FORMULA
MANNING’S The roughness coefficient ‘n’ value of 0.010 for HDPE / DWC PE and 0.011 for
mechanical devices. On sewers which are to be cleaned manually, which cannot be entered for cleaning or
inspection, the maximum distance between manholes has been adopted as per the CPHEEO manual. The
spacing of manholes as suggested in CPHEEO manual is given below:
(i) Recommended spacing of manholes (CPHEEO) for gravity sewers not receiving house service
sewers.
Table 7: Manhole Spacing
Sewer diameter (mm): Up to 600 600-900 900-1200 1200-1500
Max manhole spacing: 60 m 90 m 120 m 150 m
Maximum manhole spacing for 30 m or it can be less than 30 m depending on the size of the
sewers receiving house service plots and streets.
connections:
(ii) Shape of Manholes: Circular manholes of sewer brick Masonry and RCC precast are provided as
those are stronger than rectangular and arch type manholes. The selection of sizes is as per the
CPHEEO manual on Sewerage and Sewage Treatment.
For depth – up to 1.1 m Invert, 1000 mm diameter (Shallow Manhole).
For depths above 1.1 m and up to 1.65 m, 1000 mm diameter
For depths above 1.65 m and up to 2.50 m, 1200 mm diameter
For depths above 2.50 m and up to 9.00 m, 1500 mm diameter
For depths above 9.00 m and up to 14.00 m, 1800 mm diameter
(iii) Foot-rests: Foot-rest shall be provided in manholes at every 0.30 m c/c height and 0.30 m c/c
width (staggered). SFRC foot rest shall be provided.
(iv) Drop Manholes: Drop manholes are required when the maximum difference in inverts between the
shallow incoming and outgoing sewer of a manhole is more than 60 cm. PVC-U pipe of dia as per
hydraulic design shall be used for the drop pipes embedded in the concrete as per approved
drawing.
(v) Ventilation Shafts: For the escape of the suphide gases from the sewer network It is necessary to
make provision for ventilation shafts. Theseshafts shall be preferably installed on the main sewers
where sewage flow is more than half flow condition. Location of the vent shafts shall be such that
do not affect the nearby habitation for sulphide gases smell it should be on the extreme of the
ROW so that traffic do not get disturbed and not near to multi-storey building. Flue chamber shall
be constructed and connected to vent shaft as well as the manhole. PVC-U pipe of 200 mm dia
will be used for the connection between flue chamber and the Manhole. Vent shaft shall be
embedded in the concrete as per structural design for the stability of the same.
(vi) Manhole Covers and Frames: The size of the manhole covers should be such that there should be
clear opening of not less than 560 mm diameter for manholes exceeding 0.90 m depth. Provision
of SFRC manhole covers has been made in accordance with IS 12592 (latest revision).
6.3.12 HOUSE SEWER CONNECTION
Provision of Sewer Property Connection shall be made through Road side Inspection Chambers. These
chambers shall be on either side of the road to facilitate connection to the sewer system by existing and
prospective consumers. Pre-cast Road side inspection chamber of 450mm dia (internal), 600mm depth and
base 100 mm thick PCC of 750mm dia& 450mm dia (internal), 900mm depth and base 100 mm thick PCC of
750mm dia foundation shall be used.
PVC-U pipes (SN 8) as per IS 15328 (amended up to date) and as per specifications with rubber rings with
socket and spigot joint , (EPDM/SBR) for all depths for pipe length as per drawing and specification including
bedding, hydraulic field testing and commissioning etc. complete as directed by Engineer. Contractor shall also
do sewer connection of the future development after completion of work during O&M period.
Making Connection of existing house sanitary system to road side inpection / property chamber by construction
of chambers and Providing, laying, jointing, testing & commissioning of house sewer line / chambers with in the
premises and upto road side inspection chamber, it includes dismentling of floor, excavation of trenches, laying,
jointing of 110 mm dia PVC-U pipe, trapes, construction of intermediate house chambers (with in the premises)
for connecting existing sewage / sullage pipe line upto property chamber for joining of existing pipes coming
from WC's, toilets, bathrooms, kitchen, wash basins etc.
Type of Road side inspection chamber shall be as per following table:-
Table 8: Type of Road Side Chamber
More than 3.5 450 mm dia (ID) & 900 mm depth 160 mm
However provision of 900 mm deep road side chamber has been kept for the connection of more than one
property to reduce the road cutting.
6.3.13 HOUSE CONNECTION INSIDE PROPERTY BOUNDARY
The Scope of work includes connection of existing sanitary system from inside property boundary up to road
side inspection / property chamber. This includes laying of 110 mm diaPVC-U pipe from inside property
boundary up to road side inspection / property chamber. The items related to this work i.e. outside property
boundary has been included in BOQ and will be paid accordingly.
This section mainly deals with provision of house service connection inside the property boundary which
includes construction of Inspection Chamber; connection from Bathroom/Kitchen waste pipe and WC pipe;
laying the pipe inside the property boundary by-passing septic tank, if any. Connect it to the Property connection
pipe/Road side chamber constructed outside the property boundary. In this conjunction, the Contractor shall
undertake a door-to-door survey of all properties and obtain the details in regard to name, address, number of
resident members, categories of general residential households (independent housing, group housing
connections and apartments), urban poor households, government housing, non-domestic, commercial,
institutional, religious places, industrial and fire services and any other category of resident, existing sewerage
system, method of disposal of wastewater etc. The data collected from household survey shall be geo recoded
to the footprints from the digitized satellite image.
The Contractor will survey the three-dimensional position (x,y,z) of all waste water collection point including the
details of existing disposal system within property boundary e.g., pipelines, inspection chamber, location of
septic tank, details of water supply connection, material of disposal line, outlet points etc.
The Contractor shall develop a checklist of QC checks for each type of deliverable and will be responsible for
ensuring that these QC checks are performed.
As per site condition and in consultation with property owner, contractor shall prepare the plan showing property
connection work details, alignment, etc. and submit to the employer and got it approved before commencement
of this activity.
Approx. 7,600 numbers of properties covered for carrying out the property connection work inside property
premise. These house hold sizes are based on average house hold size of 5 persons per house. Final no. of
properties shall be as per the consumer survey.
Table 9: Penalty for not achieving house sewer connections
S.No. Period Considered Properties to be connected.
1. During Build phase 5,600
2. During Operation and Maintenance period 2,000
Note: If contractor fails to achieve 100 % sewer property connections as per approved house hold
survey, then penalty of Rs 1500/- per connection will be imposed.Damages due to less sewer property
connection it shall be in addition to the maximum amount of delay damages i.e. 10% of accepted contract
amount as per clause 9.6 “Maximum delay damages” Section-8: Particular condition of contract.
This work will be paid on per house connection and pipe length basis on complete work in all respect etc.
required for completion of this Job. Payment of property connections proposed under this project will be made
by RUIDP. The payment beyond proposed number of connection shall be made by concerned ULB.
The quantities given in the BOQ is summarized based of combination of particular length of pipe line with all
allied works. The scope of in house property connection, work includes the following works
1. Dismantling of existing surfaces of any type and Boundary wall, if any.
2. Excavation in all types of soils, ordinary rock and hard rock
3. refilling and consolidation of trenches
4. Providing at site, lowering & laying in trenches, aligning & jointing of 110 mm diaPVC-U pipes (SN
8) as per IS 15328 (amended up to date) ISI marked with rubber rings (EPDM/SBR) with socket
and spigot joint for all depths
5. including specials, fittings/ accessories of class III (6 Kg/sqcm) uPVC as per IS 4985 with sealed
joints in uPVC pipe
6. Gulley trap / Master Trap - 1No.
7. Reinstatement of excavated surface and Boundary wall as per original condition.
8. Cover of the house hold terminal chamber / property chamber inside the property shall be either
SFRC or composite FRP (confirming to BSEN-124:1994). Color/shade may be given in these
covers matching to the floor of the proprety.
9. Any other activity required to complete the connectivity to outside property chamber.
In carrying out the Works due attention shall be paid to all measures which can reasonably be taken in order to
diminish the inconvenience which the work may cause to services and access to property. Cost of Household
Inspection chamber is excluding for within property premise and shall be paid extra separately if required as per
the BOQ rate.
6.3.14 STORME/INDULSTRIAL/CHEMICAL WASTE WATER DISCONNECTION
Contractor shall identify and remove the storm/Industrial/Chemical waste water connections in reducing the
amount / to maintain sewage influent quality parameter.Inflow into the sewer system such as flow from roof
leaders, driveway drains, industrial, chemicalwasteand other unauthorised connections shall not be allowed to
flow into the sewer system.
The contractor shall inspect the each property/premise/location and submit the report to Employer’s
Representative. Employer’s Representative during design build /ULBduring O&M shall review and approve the
disconnection.Employer’s Representative/ULB shall assist in the permanent removal of these connections as
per municipal laws and these disconnections shall be permanent.
After compliance with the removal of the connection, the Contractor shall inform to Employer’s
Representative/ULB in writing.
6.3.15 TRENCHING FOR OPEN EXCAVATION
The trench width for laying of sewer should be as per trench section attached with bid document and as
approved by Employer’s Representative.
6.3.16 SHORING
Adequate shoring shall be provided toprevent collapse of trench walls. In narrow trenches deeper than 1.5 m
where strata is stable. If strata is sandy and soil can not be held in vertical position than timbering and shoring
may be provided for less than 1.50 m depth as per site condition and, shoring shall be done in accordance to
the relevant IS code.
6.3.17 PIPE BEDDING
Bedding of sewers is essential whether the sewer rests on rocksurface or soil surface to prevent sagging and
cracking of pipe and also to obtain safe supporting strength to the pipe. The bedding shall be provided as per
CPHEEO manual.
6.3.18 TRENCHLESS WORK
To ease the execution and to avoid public inconvenience during execution and safety aspects for laying deeper
sewers, it is proposed to lay sewer lines with trenchless method. The technology has been preferred on the
roads having dense traffic with narrow widths having sewer. The trenchless sewer has also been proposed at
important circles in the city where traffic density is more, in the streets where traffic diversion is not feasible,
highway crossing, railway crossing etc. In general sewer network at depth more than 3.5 m will be laid through
trenchless technology. Even if the depth of sewer is more than 3.5 m but RoW is more/open area & site
condition is favourable sewer may be laid with open excavation to reduce trenchless laying.
The complete work of Road Crossing on National Highway, and railway crossing, shall be done by trenchless
technology, and is in the scope of this contract. All other road crossings are also to be done by the contractor,
by deciding a suitable method as per the instructions of the Employers Representative.
Trenchless technology covers any techniques, processes or procedures, including the equipment,
machines and materials involved, which minimizes or eliminates the need for surface excavation
or reduces environmental damage or reduces the associated costs for underground work.
Based on the technique selection, a specific technique will be approved and finalized. Technical
requirement of the techniques, the work scope, terminology, material specifications, subsurface
investigation stipulations, and construction related requirements will be submitted by the
contractor and approved by the Employer’s Representative.
The alignment of the pipes shall be marked on the plan by the contractor after survey to
determine the existing utilities both underground and above ground along the route of pipe / cable
length. All the existing utilities, hazards & natural features shall be recorded on the plan. Mapping
of entire proposed route shall be done and shall be got approved from Employer’s Representative
before starting any execution activity.
Existing utilities will be located with the help of line departments and also NOC from concerned
authorities shall be obtained from line department.
Overhead electric lines, undergrounds existing utilities, Cables, obstructions, will be inspected by
Employer’s Representative and verified as marked on the plan and submitted by the contractor.
Entire work area shall be staked out as per the specific technique requirement. The general
arrangement of entire work area on every sides shall be got approved from Employer’s
Representative before commencement of execution.
Geotechnical Site investigation both surface as well as subsurface shall be conducted by the
contractor to get topographical information for horizontal and vertical control, classification of
soils, SPT values, gradation curve of granular soils, water table etc.
Underground survey: Ground Radar Penetration survey shall be done by the contractor to identify
and prevent the the damage to the underground utilities. The contractor shall be responsible for
all damages to the underground utilities. No extra payment shall be made for such type of survey.
The contractor shall collect all available information regarding underground services and take
necessary care to protect them. He should also have sufficient arrangements and resources to
identify and protect such underground services.
Trenchless Equipments:- Capacity and quality of the deployed equipment and its selection is
important and shall be approved by the Employer’s Representative. Under capacity equipment
must not be permitted to deploy. Employer’s Representative should ensure the submission of
following details before permitting the deployment of any equipment at the worksite:
I. Design calculations to evaluate the various forces/stresses that can be expected in the
project;
II. Copies of Documents detailing equipment capabilities matching the project requirement;
III. Proof of ownership / leasing for such equipment.
Technical Manpower:- It is imperative that the engaged workmen are adequately trained and
experienced to execute the project to avoid accidents and failures at project site. Unskilled or
uncertified workmen must not be allowed to operate the equipment. Employer’s Representative
should ensure the submission of following details before permitting the deployment of manpower
at the worksite:
I. A list of manpower proposed to be deployed for the trenchless work.
II. CVs of the main operators, their alternate operators;
III. Technical Educational Qualification Testimonials like degree/ diploma/certificates.
The Scope of works: generally envisaged under Trenchless tender include but not limited to the
following:
I. Carrying out hydro-geological, geotechnical and topographic surveys.
II. Design and Engineering of crossing to meet the technical parameters of the trenchless laying
and specifications.
III. Performing all engineering and design calculations to verify suitability of pipe
material/thickness proposed for installation in accordance with requirements of application
codes/ standard for owner’s review and approval.
IV. Preparation of all detailed construction/Installation drawing and methodology for trenchless
work.
V. Submission of QA/QC Procedure.
VI. Procurement and inspection of all materials and consumables required for or in connection
with execution of the trenchless laying.
VII. Mobilizing equipment, manpower and other resources etc, site preparation including arranging
of additional land required for pipeline/fabrication, stringing, placement of equipment and
preparation of pipeline connecting area and access to work site.
VIII. Setting out works including establishing the location of extremity points (i.e. entry and exit
locations of drilled portion of the pipeline to be laid by trenchless techniques, etc) on ground
including carrying out of pre construction survey and collection of all necessary data.
IX. Preparation of pipe string, installation of the carrier pipe string below the river / water course
bed or at the designated crossing location prepared by single trenchless operation to the
correct profile as per the drawing approved by the Employer’s Representative.
X. Disposal of drilling fluid returns and cutting produced from drilling operation from worksite
including arranging disposal site at contractors cost and initiative.
XI. Submission of daily log activities with all relevant details connected with trenchless operations
for installing pipeline as required by Employer’s Representative.
XII. Final clean up& restoration of ROW including de-mobilization.
XIII. Submission of as built drawings, reconciling the owner issue material and returning the
balance items to the owner’s stores.
XIV. All other works, which are not specifically indicated above, but required for successful
completion of the trenchless work, associated mainline work and allied works as per the
tender documents, drawings, construction methodology & details engineering calculation etc.
XV. The contractor shall familiarize himself with the site conditions and technical requirement.
CPM chart of the entire Trenchless work shall be prepared in sufficient details and shall be got
approved from Employer’s Representative before start of Work. Permission shall be obtained
by Employer’s Representative from government authorities/line agencies holding right of way
like local municipal body, PHED, PWD, NHAI, VVNL, BSNL etc.
XVI. The contractor shall work out following requirements before start of Trenchless work:-
a) Technology as per site condition.
b) Methodology.
c) Equipment Requirement.
d) Consumables including handling and operational details.
e) Pipe layouts including sizes, location and depth of entry and exit pits.
f) Crossing length and depth requirements including bending radius etc.
g) Horizontal and Vertical Clearance.
h) Horizontal and Vertical angles.
XVII. The contractor shall carry out Trenchless work by ensuring public safety, protecting existing
underground utilities and structures at site.
XVIII. The entire Trenchless equipment shall be operated by contractor strictly as per manufacturer’s
operation manual and a copy of same shall be provided to Employer’s Representative by
contractor.
XIX. All underground utilities shall be indentified and mapped and shall be submitted before start of
work. The mapping shall include both horizontal as well as vertical position of underground
utility and structures/ obstructions.
XX. The Trenchless Contractor shall mark the entry and exit locations, proposed alignment and L-
Section at 10 meter interval and shall got it approved from Employer’s Representative before
start of work.
XXI. Distance between trenchless pit shall be got approved from Employer’s Representative.
Maximum distance may be up to 60 m if no sewer connection is required as per site condition.
For the out fall sewer distance may be up to 100m.
XXII. If Invert of the sewer as per approved hydraulic design not matched because of improper
maintaining of horizontal and vertical angles during laying, contractor shall rectify at his own
and no payment shall be made for faulty laying.
XXIII. Necessary Traffic control plan shall be made by planning engineer of the contractor with the
help of Employer’s Representative and local administration and necessary approval from
Traffic police as applicable shall be taken and contractor shall be directed to deploy necessary
manpower for traffic control as required by competent authorities.
XXIV. The contractor shall handle and dispose of all construction waste as per directions of
Employer’s Representative and designated location and it will be ensured that drilling fluid /
excavated solids do not enter roadways, drains and sewer lines. Drilling fluid shall be disposed
of in environmentally safe manner as per govt. regulations. No extra payment shall be made to
contractor for such safe disposal.
XXV. Back filling operations shall not begin until written unless the entire work has been inspected
and passed by Employer’s Representative.
XXVI. The contractor shall submit the As-Built drawings supported by tracking data and record
drawings in duplicate hard copy as well as soft copy (giving horizontal and vertical alignment
and details of existing utility locations) of Trenchless installations within 30 days of completion
of Trenchless work.
XXVII. All trenchless work shall be included in the GIS work with 3 D coordinates.
XXVIII. The contractor shall clean the site on completion of Trenchless work and shall ensure that no
heaving or humping of ground has occurred.
XXIX. Defect rectification period of Trenchless installation shall be two years from the date of
sectional completion issued by Employer’s Representative and shall be liable for rectification
of all defects notified to him during the operation and maintenance period.
XXX. Specification of trenchless techniques shall be as per the Codes of Practice Suiting Indian
Conditions.
General approach for selection of trenchless technique shall be as under-
A. Application-
a. Sewer line
B. Function
a. Gravity
b. Pressure
C. Dimensional details
a. Diameter/ Size (if non circular)
b. Depth of installation
c. Obligatory length of single drive
D. Geotechnical aspects
a. Soft ground (Clayey)
b. Sandy/ silty
c. Murum
d. Soft/ Weathered rock
e. Hard rock
E. Physical conditions
a. Along a narrow road
b. Along a wider road with heavy traffic
c. Railway crossing
d. Highway crossing
e. River/ Nala/ Water course crossing
F. Pipe Material
a. RCC
b. HDPE
c. MS/ DI (Metallic)
G. Carrier Pipe
a. With
b. Without
H. Carrrier Pipe Mterail
a. RCC
b. MS/ DI (Metallic)
I. Arrangement desired
a. Carrier and Sleeve
b. Direct installation
The Engineer shall in general consider the above aspects for recommending and ordering a particular
trenchless technology at a particular stretch of the work.
Trenchless techniques considered suitable are-
A. Box pushing
B. Pipe pushing/ Jacking
C. Auger boring
D. Microtunneling
E. Horizontal directional drilling (HDD)
The Contractor shall request for approval of the Engineer to any other technique but the Engineer’s decision
shall be final and binding on the contractor.
XXXI. For detailed specifications of execution of works, bidders are advised to refer to the relevant
spcifications presented in Volume 2
6.3.19 DEFLECTION TEST FOR SEWER LINE
In order to ensure the proper flow of sewage & to avoid silting due to deflection of PE pipe, “deflection test” are
mandatorily required in addition to other tests being conducted during execution of sewer network. Contractor
shall ensure following during the test:
The test shall be conducted after the sewer trench has been backfilled to the desired finished grade for
a minimum of 30 days.
The deflection test shall be performed by pulling a rigid ball or pointed mandrel through the pipe
without the aid of mechanical pulling device. The mandrel shall be cylindrical in shape, and constructed
with an odd number of evenly spaced arms or prongs, minimum 9 in number and ball or mandrel shall
have a minimum diameter equal to 92.5% of the actual inside diameter of the pipe.
The maximum allowable deflection shall not exceed 5% of the pipe internal diameter. The line will be
considered acceptable if the mandrel can progress through the line without binding.
The time of the test, method of testing and the equipment to be used for the test shall be gor approved
from Employers Representative.
Test shall be performed by the contractor at its expense without any direct compensation being made
and he shall furnish all necessary equipment and material required.
In the event of test failure on any test section, that section of sewer line shall be replaced, with all
repair work subject to approval of the Employers Representative. The replaced section shall be re-
tested for leakage and deflection in conformance with the specifications. All repair replacement, re-
testing shall be at the contractor’s expense.
A monthly status of Deflection Test along with test results shall be submitted to Employer’s
Representative on regular basis.
6.3.21 ID SYSTEM FOR MANHOLE, ROAD SIDE INSPECTION CHAMBER AND SEWER PIPES
Before the designing of the sewer network contractor shall get the approval of the ID system manhole and Pipe
numbering. The Contractor shall prepare and submit a sewer, manhole and road side inspection chamber ID
system to the Employer’s Representative for its approval. These IDs must be included in the GIS.Each manhole
and road side inspection chamber cover shall be marked with the ID to identify in the field. JPEG photographs
and MPEG/ AVI videos with street shall be submitted by the contractor to the Employer’s Represetative with the
running bill showing manhole and road side inspection chamber IDs.
6.3.22 DESIGN CRITERIA ADOPTED FOR SEWAGE PUMPING MAIN
Following design criterion will be adopted for the design of sewage pumping main
Table 10: Design Criteria for Sizing of Transmission Pipeline
Sl. No. Parameter Parameter
1 Design Period 30 Years
2 Design Flows As per sewage produced in the catchment area after applying peak
factor.
3 Minimum 3 m head of water
Residual Head
4 Formulae Modified Hazen William
5 Modified Hazen 1
Williams
C-value for pipes
6 Minor Losses As per Actual Site Alignment, 10% for design purpose over and above
friction losses with pipe wall due to flowing water.
7 Velocity Not less than 0.6 m/sec. and not more than 3.0 m/sec.
and effect diagrams, detailed structural steel fabrication drawings; data sheets of equipment and cable
schedules; preparation of design report manufacture and testing at places of manufacture, painting, packing,
transport, delivery, supply, storage, erection, building-in, setting work, commissioning, testing, lining and
finishing after erection of all plant required for the sewage treatment work, including pipelines, pumps, pumping
installations, machinery apparatus, flow meters at various installations, on line monitoring equipment for
monitoring process parameters (BOD, COD, TSS etc.), whole plant computer based atomization system, pipe
work, lifting, handling and ventilation equipment, electrical equipment, instrumentation & control, lighting
systems, earthing and lightening protection system, materials, articles, fittings and accessories, electrical
switchyard, ancillary works, enabling works of all kind and nature required for installations of the highest
possible operative standards and for compliance with the standards prescribed and with the particulars and
guarantees entered by the contractor, followed by operation and maintenance of the Plant and facilities
(hereinafter referred to as “Operation and Maintenance”) following successful completion of the commissioning
and issuance of the Taking-Over Certificate for the Works. It broadly comprises the following works:
(a) All preparatory work, including required topographical survey, clearing out trees, shrubs,
debris, leveling and dressing of the site, excavation in wet saturated soil and disposal of
surplus excavated earth within the site to the extent possible and proper disposal of the extra
surplus excavated earth to a suitable location as decided by the Employer’s Representative.
Pumping of sub soil water may be required during execution along with special treatment of
foundation and avoid STP from flooding in rainy season.
(b) Carrying out necessary site surveys and soil investigations (Standard Penetration Test, Plate
Load Test etc. as directed by Engineer in charge) as deemed necessary by the Contractor for
the purpose of designs / drawings check, and if the soil bearing capacity is less, then
contractor has to do soil treatment work at his own cost.
(c) The worst-case criteria for bearing pressures and other design criteria shall be used from the
site surveys and soil investigation.
(d) Process and hydraulic design calculations, analytical sewage characterization, detailed
engineering, process layout, hydraulic flow diagram, construction drawings, civil works
construction, supply, installation/erection, testing and commissioning of Mechanical, Electrical,
Instrumentation and automation system, allied road work etc. complete on turkey basis;
commissioning and operation & maintenance of treatment plant based on the Sequential
Batch Reactor (SBR) process followed by disinfection process for complete sewage treatment
plant & Intermediate Sewage Pumping Station and facilities, including future up-gradation,
making provision for second module to meet the ultimate design capacity and tertiary level
treatment etc. For STP, process and equipment performance shall be controlled by well
proven instrumentation and automation software. An instrumental control system that
regulates timed sequences for filling, reaction, settling and effluent decanting (All the Cyclic
Processes). It should be possible to vary cycle timings as per the requirement.
(e) Reactor shall consist of a multiple tank/minimum 2 tanks as per technology provider, equipped
with an inlet for raw sewage, air diffusers, with associated compressors and piping for
aeration.
(f) The detailed Architectural & Structural designs and drawings for all civil works, including those
for plant components, buildings, building services, water supply, building, plant & yard lighting,
storm water drainage etc. as per the requirement of the system.
(g) All the designs, drawings and specifications are required to be approved by the Employer or
his authorized representative. All units of STPs / SPS shall be designed to cater the peak flow.
(h) Construction of compound wall all around the plot boundary and fixing of compound gates as
the requirement and as per the approval of Employer or Employer’s Representative.
(i) Construction of Approach Road with 4.5m wide bituminous top with necessary base layers to
STPs / SPS sites including RCC Culvert on existing Nallah (if any).( bidders are advised to
visit the the site and assess the requirements, if any).
(j) Detailed design and drawings of all mechanical, electrical and instrumentation systems and all
other equipment based on the approved design process, layout etc.
(k) Construction of all civil structures including plant components, buildings, water supply, storm
water drainage as per latest prevailing specification and as per QA-QC manual of RUIDP.
(l) Designs, manufacture, shop-testing, inspection, transportation to site, installation, testing and
commissioning of all piping work & valves, mechanical, electrical, instrumentation & control
equipment and systems as per specifications.
(m) Construction and equipping of analytical laboratory for routine testing of raw and treated
sewage quality on a day to day basis.
(n) Installation of online measurement facility for BOD, COD and TSS etc.
(o) Instituting Quality Assurance and Quality Control procedures during construction and O& M
period.
(p) Preparation and submission of “as-built drawings” and “Operation and Maintenance Manual”
for the plant as well as for sewer network.
(q) Power supply for STP & SPS shall be provided by the Employer through
respectiveVidutVitaran Nigam Limited (VVNL) nearest point to the Campus area. The
expenditure incurred on this shall be reimbursed through Provisional Sum to the Contractor.
From this point onward to the Campus, the responsibility will be of the Contractor.Metering
room shall be provided by the Contractor and the Contractor shalll be required to make the
remaining supply arrangement for the STP/SPS. There shall be 2 transformers at each STP/SPS
(1W+1S). Contractor has to inform at least 3 months before requirement of Power for trial run.
Power charges during trial run & commissioning shall be borne by the Employer. Level of
power factor shall be maintained as per concerning VVNL norms by the Contractor. Any
penalty due to this shall be borne by the Contractor.
(r) Trial runs, testing, commissioning and conducting of performance guarantee tests of complete
STP & SPS.
(s) Operation and Maintenance of the STP and SPS with all required consumables,
polyelectrolyte,liquid chlorine, tools and tackles and spares (including electrical power and
water) for a period of 10 years. The line agency for O & M shall be Town Municipal Council.
(t) Constructing, equipping and maintaining a utility workshop dedicated for routine minor repairs
such as welding, drilling, machining etc.
(u) Training Employer’s designated personnel in operation and maintenance of STPs & SPS and
its facilities.
(v) Campus development including construction of campus road network from main road outside
campus to all new units of plant in order to have access for operation and maintenance of
plant & equipment as per the directions of Engineer-in-charge, site development, landscaping,
arboriculture and horticulture at the side of new units of the treatment plant, by providing earth
filling and storm water drainage network ultimately discharging into STP outside drainage.
(w) Model of plant: A model for each STP shall be provided in the form of a three dimensional
Auto Cad (or equivalent) software model viewable on the computer equipment. The model
shall be rendered to allow viewing of the model from various viewpoints to show all structures,
interconnecting pipe work and equipment with different Colour lighting. Three-dimensional
physical model with seating table, covered by transparent sheet, showing treated and
untreated sewage with different colours lightings and necessary internal lighting in different
colours for made the self-explanatory of plant model in suitable scale shall also be provided.
(x) Site office at all the STPs shall be provided during execution period till completion of work.
(y) Installation of required capacity DG set at SPSs& STP in that campus. DG set shall be
operated whenever power supply fails (DG set will be designed for critical loads as decided
during approval of process). In case it is not required to be operated during any week, it
should be compulsorily operated in one shiftat least in a week to maintain it in good health
under intimation to the line agency. Regular stock of diesel and consumption shall be
maintained. The cost of operating DG Set will be paid under O&M as a BOQ item for non-
power supply hours only. Log book of power failure and DG Set operation, including
consumption of diesel shall be maintained by the contractor.
(z) Tertiary treatment plant to meet discharge standards where necessary.
(aa) Effluent storage tank at ground level attached to Chlorination tank, construction of pump
house to pump the effluent to Elevated reservoir along with pumping system, a bypass
arrangement from ground level effluent storage tank and connecting the system to effluent
outlet pipe.
(bb) One tube well (8 inches dia) at each STP site (for at least double the requirement of water
during O&M shall be provided along with pumps & panels to get water for drinking & laboratory
purpose etc. Its operation responsibility will be of the Contractor. The power supply to tube
well shall be from the power control system of the STP.
(cc) The instrumentation requirement shall be as per process requirement for the STPs & SPS as
per Engineer approval.
(dd) Plantation at STP and SPS site
(ee) CCTV camra at 8 places in STP campus
(ff) Solar panel lighting for STP area & all buildings
6.3.23.2 CONSTRUCTION DOCUMENTS
These documents shall include:
Unit sizing of the process and sizing of all components of the plant including mechanical&
electrical equipment supported by P & I diagram, Piping diagram, GA drawing of various units
and buildings etc.;
6.3.23.5 GENERAL
This description is intended to provide a general indication of the types of facilities that the Contractor shall be
required to design, construct, and operate, and applies to SPS, Pumping Main, included in this bid unless
specifically indicated otherwise.
The Contractor shall use this description together with other specific information for SPS, Pumping Main
provided in these bid documents, including but not limited to all of which are integral to this facilities description
and are incorporated herein by reference.
The Contractor shall propose its own structural design and configuration for SPS and the design will be subject
to approval of the Employer’s Representative.
The proposed sewage pumping stations shall be circular in shape and shall consist of an incoming discharge
chamber, screen channels and a wet well. Suitably sized submersible pumps shall be installed in the wet-well.
Design of pumping station shall be designed for lean, average and peak flows.
The designs and drawings as formulated by the Contractor shall be subject to approval by the Employer’s
Representative or its authorized representative as part of SIP.
Superstructure shall be provided for Transformer, electrical switchgears, Contractor and DG room. The design,
manufacture and performance of all the equipment used in the pumping station shall confirm to the latest
applicable Indian and International standards.
Sewage Pumping Station shall have the following units:
o - Wet well/ Receiving tank
o - Inlet and Screen Chamber
o - Raw Sewage Pump House
o - Raw Sewage Pumps
o - Rising Main
o - EOT
o - Flow Measuring Unit
o - Knife Gate Valves
o - Non Return Valves
o - Electrical Works
o - DG Room
o - Any other item not specified above
All the civil components shall be designed and constructed for ultimate stage flow and pumping machinery shall
be provided for immediate flow of capacity.
Coarse-screened sewage from the Coarse Screens shall be collected via appropriately sized channel or gravity
pipe into a common channel or gravity pipe which shall connect to each of the two wet well compartments
described below via a separate isolation gate or valve for each wet well compartment.
Arrangement of wet well and EOT shall be suitable for installation of future pumps also. Minimum clear volume
of wet well: 15 minutes at peak flow.
The arrangement and levels shown in the Tender drawing of SPS are indicative. Actual levels may change
marginally to suit the site conditions during executions. All other accessories, whether specified or not, but
required for completeness shall form part of contractors scope. While designing pumping station due
consideration shall be given to safety and ease of O & M.
Both compartments shall be identical and symmetrical, and shall be designed to be fully self-cleaning and
prevent any accumulation of solids or debris under any and all flow conditions. Each compartment shall be
provided with an adequate number of vents of adequate size to allow unrestricted changes in wet well liquid
level. The vents shall be located in open areas exposed to the atmosphere, and shall be terminated in
“goosenecks” (inverted U fittings) with screens to prevent entry of foreign objects into the vent piping.
Inlet chambers shall be provided at inlet, and connected to screen channels through sluice
gate openings. Over-flow having capacity to discharging average inflow to be arranged from
inlet chamber.
Mechanically raked screens with conveyor shall be provided at the inlet screen channels for
the pumping stations.
Screen channel shall be in two parallel streams, with provision of sluice gates of cast iron as
per IS 13349 at the starting of channels.
Inlet chamber shall be 300mm below the invert levelof sewer with gradual slope towards wet
well.
The capacity of the wet well is to be so kept that with any combination of inflow and pumping
the cycle of operation for each pump shall not be less than 5 minutes and the maximum
detention time in the wet well shall not exceed 30 minutes of the average flow.
The capacity required between ‘start’ and ‘stop’ levels in the sump depends on the extent of
inflow rate variations and the need to prevent pumps from starting with greater frequency than
the rating of the electrical equipment shall tolerate.
The lowest ‘start’ level should be such that the pump body is below the water level so that
there is no air pocket within the pump volute. This is to prevent cavitation on starting.
The lowest ‘stop’ level should be such that it doesnot allow air to be entrained by vortex into
the pump suction.
The pumping station design shall meet the pump’s NPSH requirement to operate without risk
of cavitation.
The total head shall be calculated at low level in wet well for satisfactory operation.
Starting level of last pump shall be minimum 150 mm below the expected maximum
Sewage level in sewer, to avoid surcharging of sewer. This shall ensure free flow of sewage to
wet well at all flow conditions.
Flanged Ductile iron pipe fittings as per standard BS 4504 or ISO 2531 shall be provided for
pump suction and delivery piping. Restrained dismantling joints of ductile iron shall be
provided for ease of installation and dismantling. The delivery pipe shall be connected to
header from side. Gaskets material of construction to be EPDM, BS681-1. Natural rubber,
NBR or SBR material for gasket shall not beaccepted
Pump delivery sluice valves shall be with electric actuators as these are to be opened and
closed when pump is started and stopped.
Quick closing spring controlled non-slam type swing check valve shall be provided at pump
delivery to prevent back flow of wastewater
Rising mains shall be ductile iron class K-9 with cement mortar lining.
Ultrasonic level measuring system shall be providedfor proper operation of the plant
A pressure gauge/transmitter complete with isolation valve shall be mounted on the delivery
pipe of each pump set upstream of the non-return valve. The tapping shall be on the centre
line of the pipe and the instrument shall be calibrated to measure a pressure range of 0 to 100
meters of water.
The ladders, platform, covers and handrails to be supplied and fixed under this Contract shall
be supplied in accordance with the standard specification. Provide suitable corrosion lining in
wet well. Access hatches shall be provided through the cover as necessary to facilitate
personnel access, inspection and removal of submersible pumping units and instrumentation.
Lifting equipment shall be provided for pumps and screens. Capacity of lifting equipment shall
be 1.5 times of the heaviest piece to be handled.
In addition to these, norms laid down by the Regional Pollution Control Board regarding handling of treated
effluent and sludge/screenings shall also be adhered to as mentioned in the Environment (Protection) Act 1986.
Fine Screen
No. of Mechanical (Working) Fine Screens = 1 Nos.
No. of Mechanical (Standby) Screens = 1 Nos.
Clearing opening of fine screen = 06 mm
Total No. of Screens = 2
No. of Mechanical Screens = 2 Nos.
Design Flow = Peak Flow
Mechanical Degritter
No. of Mechanical Degritter = 2 No
Design Flow in each Degritter = Peak Flow
Hydraulic Retention Time (HRT) in Grit
= 60 Sec
Chamber at Peak Flow
Freeboard = 0.50 M
Sequential Bio Reactor (SBR)
Min No of Units = 2 Nos
Min Freeboard = 0.5 M
Min Aeration Tank HRT = 12 Hrs
Min Aeration Tank SRT = 10 Days
MLSS in Aeration Tank < 4000 Mg/l
Kg Oxygen/Kg
Oxygen requirement (AOTR) = 1.2
BOD removed
Kg VSS/Kg BOD
Min sludge production = 0.7
removed
Design no. of cycles per day- Maximum = 6 Nos
Normal decanting range = 1/3 Of total depth
per SBR basin with
synchronised
SBR Decanter > 1
operation through
PLC
Electro-
mechanically
positioned with
subsurface
Type of Decanter
withdrawal and
scum exclusion
mechanism in SS
316
One working + One
SBR Waste Activated Sludge (WAS) Pumps = 2
standby
Air Blowers
Type of Air Blowers = Twin lobe/ Tri lobe
1 Working + 1
No of Air blowers = 2
Standby
Air Diffusors
Fine bubble tubular
Diffuser type = As required membrane
retrievable EPDM
Max air flow per effective area <= 101 Nm3/hr/m2
All aspects of Contractor’s technical design shall be subject to review and approval by Employer and Engineer.
The design, execution of buildings, pathways, drainage, campus lighting, security system, Boundary wall &
plantation shall be as per Employer’s Requirement/Standard Specifications. These works are included in the
scope of work.
Effluent discharge point level:-
Level at discharge point of STP: 193.865
Note- (i) during confirmation of levels & design checking if any modification is required shall be done by the
contractor.
6.3.23.10 ORIENTATION
The plant’s overall arrangements of units shall be finalised on approval of employer’s representative. Contractor
shall take all care in making sure that the site orientation is proper and aesthetically appealing.
All the components shall be laid out and fully contained within the site boundary subject to specific conditions
and constraints as mentioned in the Bid Drawings and Documents. Appropriate clearance from the Site
Boundary Wall/ Fence shall be provided on all sides. Approach Road and main entrance gate to Site shall be
provided by the Contractor.
Contractor’s proposed site layout shall clearly show the space allocated for all plant components, including
those components and/or unit processes that may be designated for future construction or installation(if any).
Setbacks and clearances from the site boundary shall be provided as appropriate and as required by
law/standards. All existing utilities (including water, sewer, power, or others, whether overhead or underground
and whether physically located on the site or not) requiring to be relocated to accommodate the Contractor’s
proposed and approved site layout shall be relocated by the Contractor at no additional cost and without
interrupting provision of such utility services to users and customers. Such relocations shall be fully coordinated
with Employer’s Requirements.
Minimum clear distance between foundation of two adjacent treatment plany units provided to permit safe and
convenient access for operation and maintenance shall be 4 mete, and in case of equipment it should governed
by manufacturers that that recommendations/convenience of working.
An area adjacent to all mechanical equipment shall be provided as a maintenance lay down area.
All electrical equipment shall be located above the high flood level elevation for the site or for the effluent
receiving water body, whichever is higher.
6.3.23.11 GENERAL DESIGN REQUIREMENTS-STP
The following general design requirements shall be met for STP. These requirements shall be fully met
regardless of whether or not such requirements or any related components are shown in any drawings included
in the contract documents:-
The Contractor shall perform a complete Hazardous Area Classification analysis per IS 5572 for
STP in this contract and shall submit a complete report of such analysis as well as Hazardous
Area Classification Drawings that delineate boundaries of all classified areas and indicate the
classification of each area. All electrical or other powered equipment, instrumentation, or
components shall fully comply with all requirements of IS 5571.
All components (including but not limited to equipment such as pumps, blowers, screens,
diffusers, inline devices; instruments such as flow meters; and distribution and collection channels
or pipes) shall be provided with appropriate isolation devices such as valves, gates, or other
devices in order to allow isolation, drainage, cleaning, calibration, servicing, and maintenance of
such components.
Where necessary, equipment shall be provided with acoustic, sound-dampening enclosures to
limit ambient noise during normal operation to the limits detailed in the General Requirements.
All equipment shall be arranged and buildings and structures designed to permit safe and easy
access to and removal of all equipment.
Fixed runways, lifting eyes, cranes, hoists, or other appropriate devices and means shall be
provided to permit safe and easy removal of all equipment for maintenance or any other purpose
All gas flow distribution shall be using automatic feedback flow control using inline flow
measurement and modulated flow control valves with electric actuators. Any other means of flow
distribution shall not be acceptable.
All structures, whether liquid-holding or not, shall be designed such that they can be fully and
completely drained and will not float or move when empty, because of groundwater buoyancy or
any other reason. The structures shall be designed to counteract any possible floatation without
the use of any type of groundwater pressure relief valves.
The floors of all liquid-holding structures shall be appropriately sloped and trenches and drain
sumps shall be provided at the bottoms of such slopes to facilitate complete drainage of liquid.
Appropriate drain pipes and valves connected to the drain sump(s) shall be provided for all
structures. Where the drain pipe connects to the structure, the top-of-pipe elevation shall be at
least 150 mm lower than the lowest floor elevation for the structure. The drain piping shall be
routed from the structure being drained to the Plant Drain and shall be continuously sloped
downward in the direction of flow with a minimum slope of 1 percent. For liquid-holding structures,
the drain piping and fittings shall be sized such that the entire structure can be drained by gravity
in no more than six (6) hours. The Plant Drain Pump Station, Plant Drain Pumps, and other
related equipment and controls shall be designed and sized to allow draining of the structure with
the largest volume from full to empty within six (6) hours. The highest design water level (High
High Alarm) in the Plant Drain Pump Station wet well shall be at least 300 mm lower than the
lowest pipe invert elevation amongst all drain pipes connecting to the wet well.
Non-liquid-holding areas, structures, or buildings where leakage or other wet activities can occur,
whether in normal use or during maintenance, shall be provided with covered drainage channels
which shall direct the spillage either to a suitable gravity drain or to a sump equipped with
standard dual submersible sump pumps discharging to the Plant Drain.
All concrete structures in contact with sewage and/or sludge upstream of the Aeration Basins shall
be provided with full interior corrosion protection linings and/or coatings of appropriate material
and thickness – to be approved by Employer and Engineer. This also applies to all concrete
structures in contact with any type of sewage sludge anywhere in the plant. For Aeration Basins,
interior lining shall extend from the top of wall down to 1 meter below the lowest operating water
level.
Inlets into tanks, reactors, or other structures via pipes, channels, valves, or gates shall be
designed such that the incoming flow does not cause any damage or excessive wear whatsoever
to the structure or any equipment in the vicinity under any hydraulic condition, including but not
limited to the condition when the structure is empty.
All piping shall be fully and adequately supported and braced to comply with all applicable code
and standard. All supporting hardware shall also be of corrosion resistance material. The design
of pipe supports and anchors shall fully account for static and dynamic vertical, lateral,
longitudinal, and seismic loads, fluid flow, and thermal expansion. Seismic bracing, thrust
restraints and/or thrust blocks, and appropriate expansion joints or loops shall be provided as
needed. Pipe lengths and joints shall be assembled and arranged for ease of removal in such a
way that individual runs can be changed without dismantling adjacent pipes, by providing
dismantling joints at regular intervals.
For liquids and sludge, the minimum pipe flow velocity shall be no less than 0.6 m/s and the
maximum pipe flow velocity shall be no more than 1.2 m/s for pumped suction and no more than
1.5 m/s for pumped discharge. All mixed liquor and sludge lines shall be minimum 150 mm
diameter and shall be provided with appropriate cleanouts and flushing arrangements for safe and
easy flushing using high-pressure water. The normal pipeline peak flow velocity for gases shall be
no more than 15.0 m/s.
All liquid service pipes shall be provided with appropriate means for safe and easy drainage of the
pipes when not in service.
All pipes shall be colour banded and suitably labelled with the stream designation and direction of
flow to enable individual lines to be identified throughout their run.
Particular attention shall be paid to the layout of the chemical piping, which shall be arranged
without clutter and shall be functional and neat in appearance. Generally, where piping is installed
in ducts, it shall be supported not less than 150 mm clear of the floor.
All piping routed under any type of structure or equipment shall be fully and completely encased in
reinforced cement concrete, with the encasement thickness beyond the outer diameter of the pipe
being at least 200 mm on all sides. The encasement shall extend along the pipe length for a
minimum horizontal distance of 1500 mm in each direction beyond the footprint of the overlying
structure or equipment.
All piping connecting to, entering, or exiting any and all structures shall be provided with
appropriate restrained flexible connections and/or joints at all such interfaces with structures to
allow for differential movement between pipe and structure in all directions without stressing or
breaking the pipes.
Appropriate restrained flexible connections and/or joints shall be provided for all pipes where they
connect to any and all of the following:
Equipment such as pumps, blowers, or inline devices
Valves
Wall, floor, or roof penetrations
Platforms, handrails/guardrails, ladders, and stairs shall be provided where necessary for proper,
safe, and easy access to and/or operation of valves, gates, instruments, control panels, and other
devices, equipment, or structures.
Appropriate sampling ports and/or sampling valves shall be provided to allow easy, safe sampling
of all process streams without spillage or contamination and without the need to interrupt normal
operation.
The influent flow meter and influent sampling location shall be selected such that the true influent
flow and characteristics will be measured without inclusion of in-plant recycles or other extraneous
streams. Separate flow measurement and sampling shall be provided for the recycle streams.
Foam, scum, fats, oil, grease, or any other floating material removed from any location in the STP
shall be completely removed from the process flow path along with waste, digested, and/or
dewatered solids leaving the STP and shall under no circumstances be recycled or returned to
any location in the plant.
Piping shall have appropriate corrosion resistant Material of Construction as mentioned in the Bid
Drawings and Documents. All supporting hardware shall also be of corrosion – resistant material.
The piping design and erection shall follow applicable standards and the tenets of good
engineering practice
All piping shall be fully and adequately supported and braced to comply with all applicable codes
and standards. All units shall be provided with drain out pipe with isolation valve
6.3.23.12 TREATMENT PROCESS SPECIFICATIONS
This Process and Facilities description is intended to provide a general indication of the processes and a type
of facilities that the Contractor shall be required to design, construct, and operate, and applies to STP in this
contract unless specifically indicated otherwise. The Contractor shall use this description together with other
specific information for STP provided elsewhere in these bid documents, all of which are integral to this Process
and Facilities Description and are incorporated herein by reference. The Contractor may propose alternate
implementation details such as detailed site layouts and elevations of specific components. However, the
Contractor shall strictly comply with the specified treatment concept, treatment unit processes, flow
configuration (connectivity between unit processes and facilities), performance requirements (such as effluent
and sludge quality and equipment efficiencies), and design criteria (such as design operating conditions,
various process loading rates and/ or detention times, volumes, and dimensions where specified) such as
the minimum requirements
6.3.23.13 DESIGN CRITERIA - SPS
The sewage flow reaching to SPS will be through gravity mains. To pump further, provisions of inlet chamber,
trash rack, coarse screen (mechanically cleaned , sump with pumps are included. The sewage shall be
received at inlet then to coarse screen & will be collected in to the sump well. The units up to sump shall be
designed for design flow and pumps shall be for intermediate flow. The sewage from sump shall be pumped
STP through a pumping main.
6.3.23.14 GENERAL DESIGN REQUIREMENTS - SPS
The following general design requirements shall be met for SPS and Pumping Main. These requirements shall
be fully met regardless of whether or not such requirements or any related components are shown in any
drawings included in the bid documents.
The Contractor shall perform a complete Hazardous Area Classification analysis per IS 5572 for
all SPS, Pumping Main in this bid and shall submit a complete report of such analysis as well as
Hazardous Area Classification Drawings that delineate boundaries of all classified areas and
indicate the classification of each area. All electrical or other powered equipment, instrumentation,
or components shall fully comply with all requirements of IS 5571.
All components (including but not limited to equipment such as pumps, screens, inline devices;
instruments such as flow meters; and distribution and collection channels or pipes) shall be
provided with appropriate isolation devices such as valves, gates, or other devices in order to
allow isolation, drainage, cleaning, calibration, servicing, and maintenance of such components.
Bypasses shall be provided around all flow meters and other in-line instrumentation such that the
instrument can be isolated and removed for calibration and maintenance without interrupting the
flow, regardless of whether or not such bypasses are shown in any drawings included in the bid
documents.
Where necessary, equipment shall be provided with acoustic, sound-dampening enclosures to
limit ambient noise during normal operation to be less than 85 db at 1.86 m distance from
equipment
All equipment shall be arranged and buildings and structures designed to permit safe and easy
access to and removal of all equipment.
Fixed runways, lifting eyes, cranes, hoists, or other appropriate devices and means shall be
provided to permit safe and easy removal of all equipment for maintenance or any other purpose
All structures, whether liquid-holding or not, shall be designed such that they can be fully and
completely drained and will not float or move when empty, because of groundwater buoyancy or
any other reason. The structures shall be designed to counteract any possible floatation without
the use of any type of groundwater pressure relief valves.
All concrete structures in contact with sewage shall be provided with full interior corrosion
protection linings and/or coatings of appropriate material and thickness – to be approved by
Employer and Engineer.
Appropriate restrained flexible connections and/or joints shall be provided for all pipes where they
connect to any and all of the following:
o Equipment such as pumps, blowers, or inline devices
o Valves
o Wall, floor, or roof penetrations
Where piping or other materials susceptible to damage from ultraviolet radiation are employed,
they shall be protected from such radiation through the use of appropriate additives and/or
coatings and shall be physically shielded from direct sunlight at all times in their normal service
location using enclosures, covers, canopies, roofs, and/or other similar means.
Platforms, handrails/guardrails, ladders, and stairs shall be provided where necessary for proper,
safe, and easy access to and/or operation of valves, gates, instruments, control panels, and other
devices, equipment, or structures.
Appropriate sampling ports and/or sampling valves shall be provided to allow easy, safe sampling
without spillage or contamination and without the need to interrupt normal operation.
SPS shall provide sewage collection and distribution, coarse screening, and pumping functions and capacities
as follows:
Receive into a common collection chamber a combined total design average/peak sewage flow.
Provide downward opening overflow weir gate, distribution chamber, and piping for passive
overflow of flows exceeding total design peak flow or emergency overflow to nearest receiving
water body.
Provide downward opening overflow weir gates, distribution chambers, and piping for distribution
design average/peak coarse-screened sewage flow as follows (all numbers are design
average/peak capacities required)
Main Electical Panel building shall have proper doors, windows and rolling shutter at main entrance as per
tender specifications. Plastering and painting from inside and outside shall be carried out as per specifications.
Flooring shall be done as per civil specifications. The minimum clear height of the pump house shall be 4.0 m.
EOT of minimum 2 T capacity shall be provided in the pump house to lift the pump assembly, valves and
specials. There shall be clear water tank of capacity 2000 litres on the roof of the pump house. The tank can be
of RCC / PVC / HDPE. Necessary GI piping (class C, min dia 15mm) along with stop cock shall be provided.
There shall be MCC room and Contractor room near pump house. These rooms shall be in RCC framed and
brick masonry structure. It shall have proper doors, windows and rolling shutter at main entrance as per tender
specifications. Plastering and painting from inside and outside shall be carried out as per specifications. An
electronically controlled automatic jam removal system shall be provided in addition to the safety devices
specified elsewhere in the document. The screen chamber shall have coarse screens. Two mechanical coarse
screens shall be provided in each channel in series. It shall be fabricated with SS316 flats as per specifications
given in the tender documents. Clear opening between the bars for coarse screen shall be 20 mm. EOT of min
2 tonnes capacity shall be provided to lift J type screens (Trash rake) for cleaning.
The screenings shall be collected mechanicallyat least 2 m above plinth level. Raking arrangement, Conveyor
belt, chute arrangement, EOT (2 ways) shall be provided to take the screenings for safe
disposalthroughtruck/tractor-trolley positioned at ground level.
Before inlet chamber there shall be manhole at a distance of about 15 m. The contractor shall construct this
manhole (having nearly same invert level as that of inlet chamber) and lay the gravity sewer from manhole to
inlet chamber. This gravity sewer line shall be RCC NP 4. The pipe and inlet chamber shall be designed for
peak flow. There shall be two screen channels (manual) in this chamber. The entire construction is in M 30
grade concrete and as per IS: 3370.
Electrically operated CI sluice gates shall be provided at the upstream and downstream of each channel to
isolate the flow. Entire super structure from inside and from outside shall be painted with approved colour and
make as directed by Employers Representative. All other accessories, whether specified or not, but required for
completeness shall form part of contractors scope.
Table 17 Design Ultimate Average flow for SPS (MLD)
S. Initial Intermediate Ultimate
SPS
No. 2021 2036 2051
1 Main SPS at STP-1 (Near Gulpura Road) 3.35 3.75 4.00
2 Main SPS at STP-2 (Near Pilani Road) 2.85 3.35 3.70
3 Main SPS at STP-3 (Near 1.80
1.50 1.70
TaranagarRoard)
4 SPS-1 (Purana Baas) 2.75 3.25 3.60
Pumps Configurations
Pumps shall be designed for average flow. Minimum following pumps shall be adopted min 50% as
per CPHEEO Manual
*Contractor may propose the vertical lifting screen for small size pumping station as per hydraulic requirements
approved by Employer’s Representative.
6.3.24 RECEIVING OF SEWAGE AT STPs
Common receiving chamber for existing & proposed STPs shall be in this scope. Raw sewage for proposed
MLD STP shall be taken from this receiving chamber which shall be designed for ultimate sewage flow (sewage
generation 2051)
The Contractor will carry-out the works in a co-ordinated and planned manner in consultation with the
Employer’s Representative to meet the requirements of the works.
Contractor is also advised to coordinate with the contractor (M/s Anand Kumar) who is on field and executing
the phase-I sewerage project. The Contractor must particularly take note that an existing 5 Mld & 2 MLD STP
based on SBR has been constructed by the Municipal Body. This STP is under operation-maintenance and
maintained under a separate contract (O&M is already considered in the scope of the present contractor for the
existing STP and sewer line that is laid). Moreover, the proposed sewerage system under this contract shall be
connected to the sewerage system designed and executed by this contractor. It is this responsibility of the
contractor to connect the sewerage system to existing sewerage system by gravity/pumping.
The Contractor as such shall carryout the works of his construction of the new STP and added amenities as per
the contract provision by providing space, requisite access and facilities to the personnel / workmen engaged in
the O&M services of the other contract with due instruction of the Engineer.
The proposed STP will also be constructed within the existing STP Campus and shall utilise the available land
for construction of new STP.
For treatment of the waste-water flowing into the STP campus following measures is to be followed:
1 The Contractor will construct a common inlet chamber before inlet of existing STP for total flow of
existing & proposed STP average flow of ultimate year design capacity (2051) capacity. 1000 mm
(5MLD) & 500 mm (2 MLD) dia RCC pipe shall be laid from the manhole just before the existing inlet
chamber to the proposed common inlet point. This inlet chamber will have a weir arrangement to divide
the incoming flow in proportionate to the STP plant capacities. Thimble mounted gate shall be provided
on the two outlets of this chamber.
2 Operation and maintenance of common Inlet Chamber will be in the scope of the present contract.
3 The instruction of the Engineer regarding flow diversion to the existing and proposed STP will be
binding on the Contractor.
4 The Contractor on his part shall provide all information regarding waste-water flow reaching the
common inlet chamber in the STP, as per the direction of the Engineer.
5 Common inlet chamber will be equipped with the flow measuring system on both the outlets connecting
to SCADA system.
6 Proposed STP will cater the sewage flow up to year 2036 for sewage generation from proposed sewer
network under this contract including sewage generation from FSSM area considering future
expansion of sewerage network.
7 Issues related to the waste-water reaching the STP will be mutually discussed and sorted out in
consultation with the Engineer, Employer.
Effluent discharge pipe will be for the combined capacity of both existing as well proposed STPs.
chamber will be fitted with Thimble mounted sluice CI gates as per IS:13349 of suitable size to each bar screen
channel downstream of it. The pumping main/gravity sewer or the rising main will enter to this chamber from
below ground to discharge sewage.
Table 19 Design Parameter for SPS Inlet Chamber
Design Flow Ultimate peak flow
Quantity 1 No (1 Working) designed for peak flow
Type Rectangular or square Type
Material of Construction RCC M30
Hydraulic Retention Time 20 seconds (Minimum) at ultimate year design peak flow
Free Board 0.5 m (minimum)
Allied Works The inlet channel shall be provided with 1.2 m wide RCC
Maintenance platform all along the length of the channel and also
for operating gates. Peripheral railing of 1.2m height in Aluminium
pipe of 40 mm dia and 5.08 mm thickness (schedule-80) with
anodizingthickness as per specification shall be provided, with SS
verticals and mid-pipe.
6.3.26.3 COARSE BAR SCREEN CHANNEL
There will be channels (2 nos.) with a screen, each connected to inlet chamber & up to sump well (wet well).
One channel will act as a standby when the other is closed for cleaning. The channels will be in R.C.C. M-30 in
Sulphate Resistance Cement (SRC). The purpose of this channel is to remove large size particles and debris
which otherwise will enter the sump well and clog the pumps. The screens will be cleared regularly with
operation. The sewage after screen shall enter to sump well through a RCC channel.
6.3.26.4 COARSE BAR SCREEN
The mechanical screen shall be inclined bar screen, rake type or other suitable type, and of sturdy design to
take care of all sorts of materials envisaged in the gravity sewer. The effective opening for the sewage to pass
through shall not exceed 20 mm in one direction and width & thickness shall be 30 mm &4 mm of SS-316
respectively. The maximum velocity through the bars/openings shall not exceed 1 m/s. The freestanding height
of dead-plate above the freeboard of the screen chamber shall not be less than 0.5 m for easy maintenance.
Mechanical Bar Screen: To handle design flow.
The mechanical screen shall include the following:
Frame work
Bar rake
Dead plate
Cleaning rake
Guide blocks
Lower channel guides
Upper channel guides
Screening conveyor
Discharge chute
Hoist drum and shaft assembly
Drive unit with motor
Machinery platform
Screen canopy
Local control panel
Shed of FRP material to protect against rain/dust etc. (CPHEEO manual part B, Appendix B.1.3)
The frame work of the screen shall be of robust construction and shall consist of SS 316 angles/channels. The
framework shall support the drive mechanism platform and the inspection and maintenance platform.
The bar rack shall consist of stainless steel bars, formed straight and true and accurately spaced to provide
required openings between adjacent bars. Bars shall extend from the bottom of the channel to a height of at
least 225 mm above the maximum water depth in the channel and be fastened at that level to a dead plate.
Bars shall be supported only at both ends.
The dead plate of stainless steel construction shall extend from the top of bar rack to the screening discharge
point in the head section.
The wetted parts of cleaning rakes shall be fabricated in Stainless Steel. The rake tines shall be replaceable
and bolted to the rake carriage and shall mesh with the bar screen openings.
The rake assembly shall be supported by cast iron sliding blocks and shall slide in stainless steel rolled section
channel guides recessed in the side walls / anchored to the side walls.
The discharge chute shall be attached to the top of the dead plate and consist of a pivoted section and fixed
section. The section of discharge chute, which will be pivoted, shall be designed to prevent screenings from
returning to the upstream side of channel when the rake discharges screenings from the cleaning rake. The
fixed section of the discharge chute shall direct the screenings to the belt conveyor. The discharge chute shall
be fabricated from stainless steel.
The drum shaft shall be solid cold rolled steel of sufficient size to transmit the power required. The drum shaft
shall be grease lubricated pillow block rolled bearings and shall support two sets of two grooved rope / hoist
drums with one drum of each set keyed to the shaft while the other is free from limited rotation controlled by the
fixed drum. The two inside drum shall be provided with friction bank brakes to assist in opening of rake
carriage. Cables shall be provided for raising and lowering the screen rake.
The drive unit for the screen shall be of the motorized type securely mounted on the machinery platform. The
drive unit shall consist of an electric motor with in-built AC/ DC brakes and of crane (S-4) duty coupled to a gear
reducer. The gear reducer shall be further coupled to the hoist shaft by means of pinion and spur gear. The
service factor of gear box shall be minimum 2.0. A suitable motor shall drive the mechanism. A machinery
platform to support the drum shaft assembly and drive unit shall be provided. The machinery platform-
supporting frame shall be fabricated from mild steel plate/rolled sections.
Screen canopy/cover shall be provided on top of the hoist assembly for weather protection.
The mechanism shall incorporate an overload protection device incorporated in the drive assembly. The
mechanism shall consist of an overload protection device with a shear pin and trip lever and a limit switch. In
the event of overload, the shear pin shall break thereby changing the position of trip lever which shall then
strike the limit switch to cutoff the supply to the motor.
Rotary Limit Switch for limiting Upper & Lower Travel
Slack Cable Limit Switch
Upper Over-travel Cut-off Limit Switch which shuts off the motor and sounds an alarm if the rotary
limit switch fails to operate.
Overload protection limit switch.
Power to open motor brakes to prevent the rake carriage from free falling into the screen channel
when power is cut-off to the motor.
Screen shall be fully assembled at manufacturer’s works and dispatched in one piece. Dry run test shall be
given by the manufacturer before dispatch. During inspection, the Positive Material Identification (test) shall be
carried out (during inspection). Screen fabrication shall be done in Ferrous free area to avoid ferrous
contamination. Cuttings of stainless steel material shall be done using heatless water jet cutting procedure such
as Plasma method.
Screen provided by the contractor shall be maintained by the screen manufacturer during O&M period also.
The conveyor shall be common to the mechanical and manual screens. The conveyor system shall be a
combination of a horizontal conveyor and upward inclined conveyor (if required) and shall have a capacity to
transfer the maximum screenings anticipated at the peak flow. The discharge elevation of the dropping
conveyor system shall be provided. The conveyor provided for discharge of screenings shall be inter-locked
with all the screenings discharging on to the conveyor so that it operates when the screenings are discharged
on to it and stops automatically after a time lag when the screen stops discharging the screenings on top the
conveyor.
Numbers One
Conveyor type Horizontal
Capacity To handle screenings of peak flow
Speed 15 m / minute (maximum)
Type Troughed
Belt 3 ply Z duck, 3 mm top, 1.5 mm
bottom, rubber cover CR M –24
Minimum two numbers trolleys are to be provided for screening collection. The trolley’s shall be of approved
material and shall have a sloping perforated floor. The location for trolley collecting the screenings shall be
provided with a draining arrangement at the ground level.
Note: However, bidder can suggest other type coarse screen subject to that the power requirement of system
shall not exceed the power required for above coarse screen system & shall fulfill the requirement of the client.
6.3.26.5 DISTRIBUTION CHAMBER
A distribution chamber shall be designed to enable to collect screened sewage and discharge into single or
both the wet wells as per operation requirement.
Controlsystem TheFinebarscreensshallhavecontrolsformanualstart&stop,automati
cstartandstop, highlevelswitch, high level alarm, Overload
protection switchandOverloadalarmetc
InletandOutletgates The Inlet & Outlet Sluice gates (Electrically
operatedwithmanualoverride)withextendedspindle
shallbeprovidedattheinletandoutletofthe Inlet Channel. The design
flow velocity throughSluiceGatesshallnot exceed1.0m/s.
BeltConveyor TheBeltconveyorshallbeprovidetoconveytheandcollectthescreening
materialintotruck/tractor trolleyorbinthrough an SSChuteasper
specifications.
6.3.26.11 DISTRIBUTION CHAMBER
The Distribution chamber shall be receiving sewage from screen and further distribute to grit removal system.
Table 22: Distribution Chamber
Description Requirements
DesignFlow Ultimate peak flow + recycle flow
Quantity 1No
MaterialofConstruction RCCM30 (sulphate resistant Cement)
HydraulicRetentionTime 10seconds(Minimum)at DesignFlow/peakflow
DepthofLiquid 3.0m(maximum)
FreeBoard 0.5m(minimum)
AlliedWorks Thedistributionchannelshallbeprovidedwith1.2mwide
RCCmaintenanceplatformallalongthelengthofthechannelandalsoforoperating
gates.Peripheralrailingof 1.2mheightinAluminium pipe of 40 mm dia and 5.08
mm thickness (schedule-80) with anodizingasperspecification shall be
provided. Thedistributionchamber shallalsobeprovidedwithaccessStaircase/
Ladder.
6.3.26.12 BELT CONVEYOR
Belt conveyor, suitable for removal of the screenings with belt length of min 5.5 m, shall be provided. Belt width
shall be less than 600 mm and belt height shall not be less than 1 m. Belt material shall be 2-ply nylon, driven
by suitable HP, RPM electric motor drive unit with a service factor of 2. Screening collection arrangement from
the conveyor belt, for final disposal in form of trolleys, shall be provided. Speed of the conveyor shall be approx.
25 m/min.
6.3.26.13 GRIT SEPARATOR UNITS
These shall be of RCC. These are provided to arrest all the inorganic grit of size 0.15 mm and above with a
specific gravity of 2.4 to 2.65. Minimum detention time provided is 1 min and surface overflow rate shall be as
per CPHEEO. The grit will be dumped in the portable bins located on ground near the grit classifiers after
washing.
6.3.26.14 DETRITOR WITH CLASSIFIER & ORGANIC RETURN MIXER (PUMP)
Two nos. of Grit Chambers shall be provided with detritor and classifier mechanism. Detritor (Detritor with
Classifier) shall be suitable for a Degritting tank provided. The Detritor mechanism shall be of moving rake type
and shall comprise the following:
Detritor mechanism shall comprise central drive located on full bridge. Bridge shall be provided in SS
304construction and minimum6 mm thick GI chequered plate for walkway. Bridge shall also be provided with
1.2 m height handrails.
Central drive shaft shall be in SS 304 construction. Scraper arms with scraper blades and scoop shall be in SS
304 construction. This shall be fixed at the lower end of the shaft and shall be designed to effectively push the
grit towards circumference and subsequently to push through the opening to the bottom end of the classifier.
Detritor drive shall be provided with suitable rating and RPM electrical motor. Overload alarm shall be provided
for indication of overload conditions. Turning vanes for flow control at inlet side in detritor shall be provided in
SS 304 construction. Weir plate in SS 304 construction shall be provided at the outlet channel with necessary
clamps in CI and anchor fasteners in SS 304 construction. Scraper frame, rag screen, stay rods and shaft shall
be in SS 304 construction.
Classifier shall have a reciprocating rake mechanism driven through link mechanism for rendering reciprocating
action. Link mechanism shall be provided with electrical motor and reducer. Classifier shall have raking stroke
adjustment features. The reciprocating rake mechanism shall be installed at about 150 degrees inclinations. All
components of classifier mechanism shall be in SS 304 construction.
Each mechanism shall be provided with organic return pump (mixer). This shall be suitably located to return
organics batch to Grit Chamber. The organic mixer shall have specially designed impeller to create washing
action. Shaft and impeller of the mechanism shall be in SS 304 material. Suitable size electric motor shall be
provided with each mechanism. Hardware/anchor fasteners shall be in SS 304 construction. All MS parts shall
be sand blasted and Epoxy painted to a total DFT of 150 microns.
6.3.26.15 PARSHALL FLUME FLOW MEASURING CHANNEL AND METER AT STP
There will be one Parshall Flume flow measuring channel in RCC, which will be capable of measuring
maximum designed peak at STP. There will be an approach channel, a throat, and a downstream channel.
Depth in the flume shall be measured by ultrasonic flow meter to be mounted above the channel. While field
mounted flow indicator shall be placed near the unit, instant flow and integrated flow values shall be displayed
as well as recorded in the control room.
6.3.26.16 DISTRIBUTION CHAMBER
The chamber will be of RCC and will have detention time of ½ min. at peak flow. This will essentially serve the
purpose of collecting the sewage coming from Parshall Flume and feeding the same to SBR units.
Note: Proper placing of CI gates of suitable size and in suitable nos. are to be ascertained by contractor as he
feels necessary to complete his works for best performance.
6.3.26.17 SEQUENCING BATCH REACTOR
Effluent from Parshall Flume to the distribution chamber shall enter in two SBR reactors. The SBR basins (Fill
and draw type) will be constructed as per technology provider. RCC staircase 900 mm wide shall be provided to
each basin for access from the ground level to the operating platforms. All platforms and walkways shall be
provided hand railings made of Aluminium pipe of 40 mm dia and 5.08 mm thickness (schedule-80) with
anodizing. 1.2 m plinth protection along periphery shall be provided as per IS specifications.
Sludge settled and collected in SBR sump will be pumped by RAS pumps to mix with influent at the inlet of SBR
and excess sludge will be pumped by SAS pumps to the sludge sump/thickener
(i) Secondary Treatment Units shall be design based on Cyclic Activated Sludge Technology
(Sequential Batch Reactor).
(ii) Process and equipment performance shall be controlled by well proven software. An
instrumental and automation control system through PLC that regulates timed sequences for
filling, reaction, settling and effluent decanting (All Cyclic Processes) shall be provided.
There may be possibility to vary cycle timings as per the requirement and the same shall be
taken care of in process design.
(iii) Each reactor shall consist of a multiple tank/minimum two tank equipped with an inlet for raw
sewage, air diffusers with associated air blowers and piping for aeration by diffused aeration
system; a sludge draw-off mechanism for waste sludge; a decant mechanism (mechanized
swing controlled decanter equipped with scum baffles) to remove the supernatant after
settling; and a control mechanism to time and sequence the processes.
(iv) Design and operational guidance given in the latest edition of CPHEEO manual should be
adhered to.
(v) If necessary, tertiary treatment to achieve discharge standards for TSS shall also be included
(vi) Units for post treatment by chlorination as well as for mechanical sludge dewatering/drying
etc shall also be included in scope of work and as per CPHEEO manual. Chlorine tonners of
minimum storage capacity to satisfy needs of minimum 15 days shall be provided on
standby.
Contractor shall also provide all ancillaries that are required for proper working of the STPs. Minimum
requirement of treatment plant units, ancillaries, equipment, instrumentation etc shall be strictly as per the latest
CPHEEO Manual. SBR tanks shall have minimum side water depth as 5.5 m. Freeboard in all the units shall be
minimum 0.5 m. Minimum requirements of processing units and equipment are given in subsequent sections.
Plant and ancillaries shall be designed to achieve desired treated water quality with easy, cost effective and
normal operation of plant and least utilization of consumable chemicals. The Decanter shall be moving weir
type and made of SS 316.
Table 23: SEQUENCE BATCH REACTOR
Sr.No. Description Requirements
A SBR Basins
B Aeration Requirements
C Decanting Device
of chlorine drum store and chlorinator room. Two nos of eye washing and Shower arrangements shall be
provided at strategic locations.
Solution piping shall be in HDPE/ PP. Solution piping shall be suitable for dosing at pre and post chlorination
locations.
6.3.26.20 AIR BLOWERS
The air blower arrangement shall be capable of handling Total Water Level and Bottom. Water Level operation
conditions, controlled by process sensors such as DO, temperature and level.
Suitable no. of blowers with individual acoustic enclosure shall be provided with duty conditions suiting to
technology/ process. Blower room with noise control system, PMCC/MCC room and buildings shall be of proper
size for operation & maintenance. Devices and sensors shall be provided such that STPs and SPS are
operated automatically and controlled by devices, units and components at optimum level. Devices such as
variable frequency drive (the system of VFD shall be suitable to filter harmonic to optimum desired level) as
approved by Employer or his representative etc for efficient working of pumps/blower/other
electrical/mechanical units etc. shall be provided. Operation of the Air Blowers shall be controlled through
PLC/SCADA system
Quantity : 3 nos. (2W+1S).
Duty : Providing clean dry and oil free air.
Equipment shall be designed to provide clean, dry and Oil free air at optimum
power consumption and least noise level. Twin Lobe type Rotary Air Blower,
operating below 1000 RPM is recommended. There should be provision in
the design to increase air output from the blower to the extent of 20% and
decrease the air out put from the blower upto 40% of design value.
Type : Twin Lobe Type Rotary Air Blower.
Capacity : Capacity of the blower shall be suitable for meeting process
Oxygen requirement of the plant.
Pressure : Shall be suitable for injecting air in reaction vessel without causing break
pressure.
Accessories: Inlet and outlet silencers, pressure gauge, safety valve, vibration
isolation pads, air filter etc.
Testing : Blower to be tested for capacity, pressure, power consumption,
Noise level and vibration etc. at vendors shop as per BS 1571. Dynamic
Balancing of rotor and shaft shall be as per ISO 1940.
The blowers for air diffuser system shall be positive displacement (roots) type or centrifugal type, and head for
blowers shall be decided on the basis of efficiency of diffusers and maximum liquid depth in tank duly
considering the losses governing point of delivery (diffusers) and the blowers. Blowers shall be complete with
motor and accessories like base frame, anti-vibratory pad, silencer, non-return valve, air filter etc. as per
requirements. Vibration due to operation of blowers shall be controlled to avoid damage to structures. The
blower room shall have sufficient ventilation, lighting and working space. The room will be equipped with
sufficient capacity EOT (Min 2 T or 1.5 times the weight of blower, whichever is more) to facilitate removal of
blower/ motor etc. for repairs. The room will also have rolling shutter.
Blower room with noise control system and PMCC/MCC room and buildings shall be of proper size for
operation & maintenance. Devices and sensors shall be provided such that STPs and SPS are operated
automatically and controls by devices units and components at optimum level. Devices such as variable
frequency drive (the system of VFD shall be suitable to filter harmonic to optimum desired level) as approved by
Employer or his representative etc for efficient working of pumps/Blower/other electrical/mechanical units etc.
shall be provided.
6.3.26.21 SOLIDS AND SLUDGE HANDLING
Sludge Dewatering Units comprising of Mechanical Sludge Dewatering Device (Centrifuges) with Centrifuge
Platform, Centrifuge House and Dewatering Polymer Dosing System shall be designed for Average Flow 2 Nos.
(1W + 1S) with all other accessories, whether specified or not, but required for completion of Contract shall form
the part of Bidder’s Scope.
Mechanical Sludge Dewatering Device (Centrifuges) and Centrifuge Platform
The Mechanical Sludge Dewatering Device shall be Multi –Diskplate Screw Press (VOLUTE) type Centrifuges
designed for 100% trouble free operation at all times and provided as per the following guidelines/
specifications:
6.3.26.22 SLUDGE SUMP
A Sludge Sump shall be provided to collect thickened sludge from SBR basins. Sludge Sump shall be
constructed in M 30 grade concrete and as per IS3370, The sump shall be equipped with coarse bubble air grid
made from HDPE/ PVC pipes and Air Blower Assembly to facilitate mixing of contents of sludge sump on
continuous basis. The sump shall be equipped with coarse bubble air grid made from HDPE/ PVC pipes and Air
Blower Assembly to facilitate mixing of contents of sludge sump on continuous basis. Above sludge sump there
shall be pump house. This shall be RCC frame brick masonry structure. Minimum height of the pump house
shall be 4.5 m from the plinth level. It shall be provided with rolling shutter and doors and windows as per
technical specifications EOT of minimum 1.5 T capacity shall be provided in the pump house to lift the pump
assembly. Flooring of the pump house shall be IPS flooring. Pump house shall be plastered from inside and
from outside as per tender specifications. Entire pump from inside and from outside shall be painted with
approved colour and make as directed be Employer’s Representative. Sludge sump shall be painted inside with
bituminous paint.
Number of units 1 (One) No
Free Board 0.5 m
Minimum SWD 3.0 m
Detention time 4 hrs
All other accessories, whether specified or not but required for complete shall form part of contractors
scope.
6.3.26.23 SLUDGE THICKENER
Table 25: Sludge Thickner
Sr. No. Description Requirements
Gravity Sludge Thickeners
1. Design Flow Secondary sludge (SAS) from SBR basins
2. Quantity 1 Nos
3. Material of Construction RCC M30 in SR cement
4. Design Sludge Loading 30 -50 Kg /m2-d
Rate
5. Hydraulic loading 20 to 30 m3/m2/day
6. Side Water Depth 4.5 m
7. Tip speed of rake 2.5 m/ minute
8. K- Factor for selection of 10kg/m : based on the formulae T = KD2 where T is torque in kg-m,
drive (minimum) D is tank diameter in meter. K is constant (kg/m).
9. AlliedWorks - Fixed Bridge with passage 1 m wide
- Centre assembly with drive unit shall consist of a drive motor, helical
gear box, steel roller chain drive, intermediate worm gear assembly,
turntable type internal spur gear visual torque indictor, overload alarm
and cut off actuating system.
- The power transmission between the first- reducer and the
intermediate worm gear assembly shall be through a chain and
sprocket drive. which shall be enclosed in a fiberglass chain guard.
- Centre Drive Platform
- Centre Cage shall be of a steel box truss and shall be provided with
connections for the sludge rake arms and feed well supports.
- Picket Fence, Walk way with hand rails
10. FreeBoard 0.6m(Minimum)
11. Solid 4.0%(Minimum)
concentrationinthickened
sludge
12. OtherComponents ThickenerMechanismshallbeCirculartype,centralcolumnsupportedwith
centraldriveandHalfBridge&FullScraper.
TheMOCoftheThickenerMechanismshallbeasperTenderSpecification.
Contractor may also propose proven mechanical sludge thickening system in place of gravity thickener.
6.3.26.24 THICKENED SLUDGE PUMPING STATION
The Thickened Sludge Pumping Station is provided to transfer the thickened sludge from the thickener to
the sludge dewatering machines. The Contractor shall make provision for the supply of high pressure water
(at 4.0 Kg/cm2 pressure) through permanent pipeline up to the flushing connection valve to enable flushing
of the sludge withdrawal line from Thickeners as necessary. The sludge Pumping Station consists of
sludge pump room with ground floor (Pump and electrical control panel level). The areas of windows,
ventilators shall be minimum 20% of the ceiling area / floor area. Fire protection equipment shall be
provided inside the pump room.
Table 26: Thicken Sludge Pumping Station
Thickened Sludge Pumping Station
1. Quantity 1 No (Ground Floor structure)
Ground Floor – Pump Room
First Floor - Panel Room
2. Type Preferably Rectangular in Shape
3. Material of Construction RCC M30 (SRC) with beam, column, and roof framing structure
including Brick work walls at the periphery.
4. Size of the Pumps House The size of the Pump House shall be designed to accommodate
minimum 4 Nos. (2W+2S) thickened sludge pumps and 1no. de-
watering pump set with starter panels, control panel and other
accessories.
5. Floor Height 4.5 M (Minimum)
6. Allied Works The Sludge Pumping Station shall include all accessories and
associated works including all interconnecting piping works for
the sludge pumps, specials, appurtenances, supporting structures,
lifting arrangement shall be provided for maintenance of pumps and
motors. Mechanical Ventilation system, Fire fighting system shall
also be provided
7. Type of pump Progressive Cavity Pump with drive motors and control panel
complete with all standards accessories.
8. Actual Pumping hours for 20 Hrs/day for design flow (Maximum)
sludge Pumping
9. Pump-Motor units : Minimum 4 Nos (2 W+ 2S)
a. Quantity As per Contractor’s Design +10% overloading
b. Pump Capacity (m3/hr)
10. c. Head As per Contractors Design + 10% overloading As per
d. Motor Capacity manufacturer’s recommendation
subject to minimum requirement at each storied except for stairs. The dewatering machines of the building
shall be such that wet cake discharge through a central chute to the parked trucks/trailer/bins etc. below.
Building shall have adequate space for storage tanks for polymer dosing, dosing pumps for polyelectrolyte,
necessary pipes, fittings, valves and other electrical, mechanical and instrumentation works stair case etc.
The height of dewatering room from finish ground level shall permit passage of truck underneath it plus a
clearance of 1 m. The room shall be so designed to permit dewatered sludge being directly loaded on the
waiting truck/trailer beneath the platform. Room shall have a RCC roof at a height suitable (minimum 4.5m)
for installing an electrically operated two way travelling crane. The capacity of the electrically operated
travelling crane shall be minimum 1.5 times the sum of weight of the dewatering machine, including motor,
all accessories of centrifuge. Contractor shall supply a total of 4 nos. FRP coated trolleys suitable for
tractors for collection of dewatered sludge. The dewatered sludge shall be guided to trolleys providing GI
(2mm) chute of adequate opening. Chute shall be extended upto 2m above ground level or as directed by
Employer’s Representative during execution.
flow into this sump directly from the outlet effluent channel of CCT. On the opposite side of the inlet to the sump
a weir of suitable width and depth shall be constructed to allow excess treated water to flow into the effluent
channel. On the inlet side a 1.20 m wide RCC slab shall be constructed over the sump with 1.0 m high pipe
railing in Aluminium pipe of 40 mm dia and 5.08 mm thickness (schedule-80) with anodizing. The sump shall be
designed and constructed as water retaining structure. A clear space of 1 m shall be provided between pumps
for easy access to the pump. A clear space of 1.5 m shall be provided from the end walls.
Necessary internal electric wiring, light and fan fixtures and fitting with light/power points shall be included in the
Contract price.
Table 29: Plant Water Pump Station
Sr.No. Description Requirements
A PlantWaterSump
i DesignFlow Aspercontractorsdesign+ 10%overload
ii Quantity 1No.
iii Type PreferablyRectangularinShape
iv MaterialofConstruction RCCM30structure
v CapacityofSump Minimum10MinuteHydraulicRetentiontimeatDesign
Flow
vi AlliedWorks The Plant Water sump shall include all
accessoriesandassociatedworksincludingallinterconnectingpipin
gworksfor the plant water pump, specials, appurtenances,
supporting structures.Thetop of the Sump shall be
providedwithminimum1.2mwideclearwalkwaywith
handrailing.Peripheralrailingof 1.2mheightinAluminium pipe of
40 mm dia and 5.08 mm thickness (schedule-80) with
anodizingasperspecification shall be provided.
B PlantWaterPumps Submersiblepumpswithdrivemotorsandcontrolpanelcompletewith
allstandards
i Pump-Motorunits: 1Working+1 Standby
Quantity Aspercontractorsdesign+ 10%overload
PumpCapacity(m3/hr) Aspercontractorsdesign
Head Aspermanufacturer’srecommendation
MotorCapacity
ii MaterialofConstructionof AsperTenderSpecifications
Pumpsanditsassociated
Accessories.
iii OtherAlliedWorks All internal piping, valves and
specialityitemsasapplicable.Pipesupportsandappurtenancesupt
otheterminalpoint.Dischargepressuregauges,foreachofthepump
ofsuitablerangealongwithnecessaryaccessorieslikeisolatingsluic
evalvesetc.Submersiblepumpshallbewithmotorssuitableforoper
ationof415Vforpumpswith control
panelscompletewithallstandard accessories
includingmotorterminalboxandcableglands.
6.3.26.29 TREATED EFFLUENT WORKS
It is proposed to sell the treated effluent for use of agriculture, horticulture, development of urban forestry etc.
and remaining treated effluent is proposed to be discharged in to an open drain along with the treated effluent
from the existing STP. All pipes and conduits downstream of CCT shall be selected considering corroding
potential of residual chlorine.
Table 30: Treated Effluent Works
Sr.No. Description Requirements
i. DesignFlow Average flow with ability to handle decant flows
1 7.30 MLD It is proposed to construct Construction of one treated
effluent storage reservoir (TESR) of 370 KL, Treated
Effluent Elevated Reservoir (TEER) 730 KL (22 m
7. Alarm & annunciation system to annunciate the plant equipment malfunction and tripping on fault
as well as any other abnormality sensing.
8. Manual override facilities shall be provided at all places where PLC controls the operations
The lines, levels and setting out points for works are indicated in the Drawings enclosed. The drawings are
indicative only. The Contractor shall submit all drawings based on his process design, layout and hydraulics.
6.3.26.37 SUBMISSIONS FROM THE CONTRACTOR
The contractor is to do the complete design and detailing (Civil/ Mechanical/ Electrical & Instrumentation) of the
SPSs and STP. Contractor will be required to submit the necessary designs and drawings and the data
schedules for the equipment and their drawings for approval to the Employer.
6.3.27 DETAILED DESIGN AND DRAWINGS OF THE SPSs AND STP
Sizing and design of different units of SPS & STPs described above are minimum requirement and indicative.
Contractor has to work out his own design based on the raw sewage characteristics and expected treated
effluent quality as mentioned in the bid document by the Employer. All the detailed parameters laid down in the
document, in Manual on Sewerage and Sewage Treatment or the relevant IS and other section of the chapter
however shall be applicable based on the process design, approved by Engineer’s Representative, The
contractor has to prepare the final detailed design according to the latest Indian Standards, the Manual on
Sewerage and Sewage Treatment, the bid document and the instructions of the Engineer’s Representative.
The detailed design of these units, architectural and structural design has to be prepared in close co-ordination
with the Engineer or his representative. The bidder shall submit his own layout and submit the same with his
bid. This layout shall be got approved from the Engineer or his representative before preparing the detailed
design.
The outline dimensional drawings submitted by the Contractor shall include the following in addition to overall
dimensions:
Parameters of equipment
Load details
Support details
Foundation pocket details
6.3.27.1 SUBMISSION OF EQUIPMENT DESIGN DRAWINGS
The equipment and systems, which are to be bought out from the sub-vendors, are also to be approved by the
Employer/ Employer’s Representative’s representative prior to manufacture. The relevant technical literature
and drawings pertaining to such equipment and systems shall contain information detailed above and shall be
submitted for approval. In addition, drawings submitted by sub-vendor/sub-contractor shall carry Contractor's
approval stamp and the Contractor shall be responsible for their contents, accuracy and completeness.
After tests on completion, the Contractor shall submit the conclusion of the tests, within 15 days and “As Built
Drawings” within four months of actual completion to the Employer/ Employer's representative. These Drawings
shall be accurate and correct in all respects and shall be shown to and by the Employer’s representative.
Completion Drawings shall be supplied by the Contractor two prints and one polyester film, along with a soft
copy in CD to the Employer’s representative. These drawings shall be developed in Auto CAD – 2004 or more
recent version.
6.3.28 INSPECTION AND TESTING REQUIREMENTS
6.3.28.1 GENERAL
The Contractor shall submit the following for approval:
a) Certificate/undertaking for having achieved Physical completion of Plant and facilities;
b) As-Built Drawings; and
c) Operation and Maintenance Manuals.
All the tests shall be conducted in the presence of Employer’s representative and shall not be commenced until
the aforementioned documents are approved by the Employer’s representative.
6.3.28.2 TESTS ON PHYSICAL COMPLETION OF PLANT AND FACILITIES
6.3.28.3 DRY TEST
A. GENERAL
As a minimum requirement, the following dry tests shall be carried out:
a) A general inspection to check for correct assembly, installation of all equipment etc., and quality of
workmanship;
b) A check on the presence of lubricant, cooling medium, etc;
c) A general check to ensure that all covers, access ladders, water proofing, guard Aluminium railings, etc
are in place; and
d) A check on damp-proofing, rust – proofing, vermin-proofing and particularly the sealing of apertures
between building structures, chambers etc.
If the observed flows are more than Q/2 MLD and Q/4 MLD at Q MLD STP, then both the
streams of the STPs shall be operated for PG test.
If the observed flows are below Q/4 MLD and Q/8 MLD at Q MLD, then “Conditional Take
Over Certificate” shall be issued by the Employer and PG test shall be conducted within six
months thereafter or as mutually agreed by both the parties.
However, the Employer’s decision shall be final in this.
4. In the event of any interruption in the PG Test for the reasons not attributable to the Employer,
the Contractor shall redo the PG test for 120 hours again. The time gap between the interruption
and restart shall not exceed 5 days. If the Contractor does not restart the test after interruption
within the period stipulated above the Employer shall initiate action in accordance to contract
conditions.
5. During the tests the Contractor shall take samples to demonstrate that each part of the works
and the works as a whole is performing in accordance with functional guarantees. In case,
functional guarantees are not met during the Performance Guarantee Test, Performance
Guarantee Test shall be considered as failed.
6. In case of failure of first Performance Guarantee Test, action shall be initiated in accordance
with condition of contract. In any case, the extension for clearing the PG Tests shall not be
extended beyond 90 days after the Works has failed first Performance Guarantee Tests.
7. In case of failure of Performance Guarantee Test, in-respect of Effluent parameters (BOD, COD)
the works shall be rejected and contractor has to rectify process to achieve parameters at his
own cost.
8. All consumables needed for operation of the works such as laboratory chemicals, lubricants etc.
and transportation of screening and wet grit, off site, shall be provided by the Contractor. The
wet sludge shall be disposed inside the plant premises as directed by the Employer’s
Representative. The Contractor shall provide all facilities and equipment not supplied under the
contract and which are deemed necessary to carry out and monitor the Tests on Completion.
9. Samples during PG tests shall be drawn for testing as below:
Table 32: Performance Guarantee Tests
Location of Sampling /
S. No. Sample/ Reading To be tested for
Check point
1 Stilling well Liquid BOD, COD, SS and pH
2 Grit Discharge Chute Wet Grit Organic content in grit (on Dry basis)
3. SBR tanks (Decanted Liquid BOD, COD, SS and pH, P, N
water)
4 Chlorinationated effluent Liquid BOD, COD, SS and pH, Residual
Chlorine, Fecal Coliforms
5 Sludge centrifuge sludge Dried Sludge % Solids Concentration and VSS
discharge chute fraction (on dry basis)
6 Energy meter Reading Guaranteed process power
consumption from VVNL grid.
All samples shall be collected at defined periodicity in an iced container and stored in a bottle cooler to the
quantity as indicated by process code towards domestic sewage or as per “Standard Methods” and as per
direction of Employer and these samples shall be used for testing. These composited samples shall be divided
equally into three parts and one part shall be used for testing at the Plant laboratory, one part given to the
Employer for testing at any place selected by him and one part given to the referral laboratory as nominated by
Rajasthan State Pollution Control Board. The results of the third named laboratory shall overrule the results of
the first and second laboratories in the event of a discrepancy between the results of two.
Wet grit samples shall be collected at the rate of about 250 gm at every four hours and sealed in an air tight
poly bag from each grit separator in an iced container and stored in a bottle cooler such that a total of about
1500 gm per day per grit separator becomes available on final collection and this sample shall be used for
testing. This composited sample shall be divided equally into three parts and one part shall be used for testing
at the Plant laboratory, one part given to the Employer for testing at any place selected by him and one part
given to the referral laboratory as nominated by Rajasthan State Pollution Control Board. The results of the
third named laboratory shall overrule the results of the first and second laboratories in the event of a
discrepancy between the results of two.
All the readings for gases (if any) and energy shall be recorded at every four hours in a separate register and
every reading shall be signed as accepted then and there by the Employer’s Representative, Contractor and
PHED / referee and shall be used for compliance evaluation with respect to the corresponding guaranteed
values in the contract.
6.3.28.8 TREATED SEWAGE QUALITY CRITERIA FOR PASSING THE TESTS ON COMPLETION OF
STPS
The works shall be considered to have achieved the required treated sewage quality standards for passing
Tests on Completion if all samples taken during a five (5) day continuous operational period comply with the
guaranteed quality In respect of BOD, COD, pH and Suspended solids in all 5 out of 5 cases. For other
parameters if compliance is achieved in 4 out of 5 results, in accordance with criteria defined for the same, the
P G Tests (Tests on Completion) shall be deemed to have been cleared. If the two or higher number of such
samples fail the tests, a suitable compensation may be levied by the Employer ((as per RPCB/CPCB).
6.3.28.9 TESTS AFTER COMPLETION
During O & M period, tests for BOD, SS, COD and pH shall be done daily on 24 Hrs. composite samples with
flow proportional auto sampler. The values observed on composite sample shall comply with the guaranteed
values in 100% samples for BOD, SS, COD and pH. Test for other parameters shall be carried out on
fortnightly basis or as need arises. The results of these parameters shall have 90% compliance of the
guaranteed values recorded over a month.
For monitoring the compliance of power guaranteed and actual power consumed, the following procedure shall
be adopted.
a. The process energy meter reading of concerning VVNL shall be recorded in the presence of
Contractor on every first of the month. Contractor and Employer’s representative shall sign this
monthly record.
b. The flow integrator reading will be recorded every day at 11 AM. Contractor and Employer’s
representative shall sign this daily record.
c. The composite value of BOD measured shall also be recorded and signed.
d. Employer reserves the right to send part of the sample collected by the Contractor to outside
laboratory of Employer’s choice, periodically without any notice.
e. At the end of the every calendar month, the computation shall be done as follows:
The guaranteed energy corresponding to the actual flow recorded and actual BOD observed
shall be summed up for the entire calendar month. If such summed up values for the calendar
month exceed the concerning VVNL energy meter reading, then excess energy charges as
said in Appendix to the Technical proposal shall be levied and recovered from the subsequent
O & M bills due for payment.
6.3.28.10 TESTS TO BE CARRIED OUT DURING O&M PERIOD
The minimum requirement of sampling and testing is to be carried out daily at least at the points given below.
This schedule shall also be maintained during the O&M period:
Flow measurement
pH, BOD, COD, Suspended Solids / MLSS, Dissolved Oxygen, Alkalinity, Total Nitrogen,
Sulphate, Total Phosphate, Residual Chlorine, Fecal Coliform etc shall be carried out at
laboratory.
Instrument/equipment for on line monitoring system for effluent (BOD, COD & TSS) measuring
shall be installed & shall be connected thought PLC to control room as per guide lines issued by
Central Pollution Control Board vide dated 07.11.2014. However for all purposes the laboratory
analyzed report shall be the based for performance purpose.
6.3.29 OPERATION AND MAINTENANCE-SEWERLINE
6.3.29.1 GENERAL
Contractor shall maintainfullfunctioning of sewerage network as intended. All assets like sewers and
appurtenances constructed under a contract must be properly operated and maintained in proper functional
conditions which will help in ensuring required level of service from the system and also help in ensuring the
planned service life.
These specifications pertain to the equipment to be supplied and operated under this contract for maintenance
of the system through a systematic Operations Maintenance Plan. The specifications provide for key equipment
while the contractor shall ensure that he possesses all other ancillary equipment and tools necessary for
provision of desired level of service.
The contractor shall also provide required trained and skilled manpower to provide the O&M services as
intended herein under.
These specifications shall be used for formulation of a comprehensive “Operations & Maintenance
Management Plan” for the sewerage system.
6.3.29.2 SCOPE OF O&M UNDER THE CONTRACT
The scope of contract interalia includes the following
The procurement of equipment for Operations and Maintenance of sewerage network system.
Establishment of O&M Management Plan.
Operation and maintenance of the equipment including provision of required skilled and experienced
manpower.
Provision of supervisory staff including Sewerage System O&M Engineer and a Safety Officer.
Inspection of existing sewerage system using CCTV sewer inspection system and providing annual
reports on the condition assessment of inspected sewers (minimum 10% per annum as per the age of
sewers)
The O&M management plan shall be compliant with the requirements of the CPHEEO Manual on Sewerage of
MoUD, Government of India.
6.3.29.3 PHYSICAL INSPECTION OF SEWER LINE
Contractor shall physical inspect the sewerage network laid by him and quantify the maintenance
characteristics of the sewer system one in a year. As part of a preventative maintenance routine, the contractor
should employ both visual and equipment based techniques. Physical inspection of the system will provide the
following:
A system inventory.
A means of identifying and quantifying the rehabilitation and maintenance requirements.
A preventative maintenance plan.
An assessment of the current conditions in the system during operation and maintenance
period.
A means of preparing an inventory of spare parts for emergency situations.
Submit the report to Employer’s Representative/ULB
6.3.29.4 EQUIPMENT PROCUREMENT
The following minimum equipment shall be procured and provided to the Employer in his name as the owner
under this Contract-
1 no Jetting and Suction (Combination) Vehicle (Capacity 4 Cum Capacity) for every individual
town under the package;
1 no Jetting Vehicle (Capacity 0.50 Cum Capacity) for every individual town under the package;
Pipe Investigation CCTV Camera equipment Van and sewer condition assessment software;
Sewerage O&M equipment and tools including power rodding equipment, pneumatic plugs, air
blowers, High pressure sewer jetting hose, Foot operated valve, Hose reel, Hydraulic hose reel,
Camera, Torch, Inflattable pneumatic pipe plugs for pipe blocking/bypass, Portable non clog
sludge pumps, Manhole Guard.
Hand gloves and safety shoes
Safety gear for the staff involved in sewer cleaning and maintenance (gas masks, gas detectors,
consumables like lead acetate paper, safety lamp), safety harnesses, rescue tools, tripods, first
aid kits;
Setting up sewer control rooms.
Contractor shall use these equipment throughout the operation and maintenance period including necessary
manpower and consumables such as fuel and oil and shall hand over the same to ULB at the end of O&M
period in fuctional condition. The equipment shall always be maintained in proper working condition. In case
equipment malfunctions or under repairs, suitable alternative shall be provided by the contractor from his costs
so that the required level of equipment and tools is always maintained.
6.3.29.5 O&M MANAGEMENT PLAN
Contractor shall develop a systematic comprehensive O&M plan and get it approved from the Employer’s
Representative at least 3 months prior to commencement of the O&M period. Works contract completion
certificate notifying beginning of the O&M period shall not be issued unless such O&M Management Plan is
approved by the Employer’s Representative.
6.3.29.6 CLEANING METHODS
Before using the cleaning methods contractor shall findout the reson for the blockages in sewer pipes such as
collapsed pipe, accumulation of materials in the pipe because of sags, root intrusion in pipe or, manhole,
accumualation of grit material, such as sand and stones. Contractor shall use the systematic cleaning methods
such as various hydraulic/mechanical/chemical methods after getting approval from Employer’s
Representaitve/ULB:
Hydraulic Cleaning – Contractor shall use the Sewer Jetting / Sewer jetting-cum-suction machine with
minimum two man crew with all accessories to remove manhole covers, route traffic and all other
necessary equipments.
Rodders – Contractor shall use the rodder to remove build-up or cut intruding roots in a pipe in
conjunction with a hydraulic cleaning devise as they are not designed to pull the material to a removal
location. After using rodder contractor shall monitor the pipe for any damages to the line.
Bucket Machines – Contractor shall use the bucket machines for removing large amounts of debris
from a sewer pipe. They are effective at removing grease build-up, and sediments. The equipment
shall have a specialized set of winches and a specially designed bucket that is pulled through the pipe.
The contractor shall keep all size of bucketsas per size of the pipes in sewer network system.Bucket
should be so designed the brushes and cutters can be added to the bucket to completely scrape the
inside of the pipe, leaving very little residual material.
Chemical Cleaning–If Contractor after site visit found that chemicals are required with mechanical
equipment then chemical agents such as enzymes, caustics, hydroxides and biocides can be applied
for specific purposes, such as grease build-ups etc.
6.3.29.7 SEWER OVERFLOW RESPONSE PLAN (SORP)
Contractor shall prepare and submit the Sewer Overflow Response Plan before 60 days from start of Operation
and Maintenance period. Contractor shall get and include the views of the local administration and ULB’s
sanitary inspectors during preparation of plan looking to the town’s local facts. Employer’s Representative shall
approve the plan and provide the same to the ULB. Contractor shall follow this plan during entire operation and
maintenance period.
6.3.29.8 OBJECTIVES OF SORP
Contractor shall plan the SORP in such a way that following objectives shall meetout:
appropriate customer service,
Maintain the wastewater collection systems including all related appurtenances, and
protect public health and the environment, and
Satisfy the requirements of regulatory agencies and waste discharge permits which address
procedures for managing sanitary sewer overflows.
6.3.29.9 OVERFLOW RESPONSE PROCEDURE
For the Sanitary Sewer Overflow Response Procedure contractor shall present a strategy for the cleaning of
sewer system of townand quantify the required labor, materials, tools and equipment to clean, correct or repair
any condition, which may cause or contribute to an un-permitted discharge from sewerage system. Contractor
shall mobilize following inimum required staff for sewer cleaning:
1. Sewer inspector – 1
2. Sewer Supervisor – 2 nos.
3. Computer operator – 2 nos.
4. Sewer cleaning staff – 10nos. (5 teams)
5. Sewer cleaning equipment operator – one for each equipment +1 extra
Receipt of Information Regarding an Sewer Over Flow –
Contractor shall provide the toll free number for the over flow complain to the public through
Employer’s Represntative/Local Administration/ULB. Sewer Supervisor shall be responsible
for receiving phone calls from the public/sewer cleaning staff notifying the of possible
overflows from the wastewater conveyance and system. The Sewer inspector then
responsible for forwarding mobilizing the sewer cleaning staff in the field.
The emergency response shall be available 24 hours per day, 365 days of the year.
After receving the call from the public,sewer supervisor shall will obtain all relevant information
available regarding the possible overflow and insert into hand held electronic device including:
a. Time and date call wasreceived;
b. Specific location and/or address of possibleoverflow;
c. Description of problem;and
d. Caller’s name and call back phonenumber.
Data of the hand held electronic devise shall be transferred to centralized computer system.
Sanitary sewer overflows detected by Sewer Supervisor in the course of their normal duties shall be
reported to the Sewer Inspector. Dispatched team of cleaning staff personnel shall record all relevant
overflow information and report back information to the Sewer Inspector for the mobilization of required
sewer cleaning equipments from site after analyzing the site condition within one hour of receving of
overflow complain on toll free number. The Sewer inspector shall dispatch additional cleaning staff or,
equipment or contracted services as necessary.
Sewer Supervisor shall submit the sewer overflow report within 24 hrs. after confirmation from site visit.
The Sewer Inspector shall be responsible for reviewing, updating, signing, and submitting the final
sewer inspection or overflow report form to the Employer’s Representative/ULB. Report shall contain
the following requirements:-
Determine if the sewer over flow have impacted the surface waters.
Characterize the sewer overflow by evaluating the following:
a. Date and time of overflow report.
b. Arrival time of Sewer cleaning staff on site.
c. Arrival time of Sewer cleningequipments.
d. When the blockage cleared or controlled.
e. Estimated rate of overflow in Cum/Hr.
f. Visual Obervations,
g. Sewage overflows to stormwater system,
h. Preplanned or emergency maintenance jobs involving bypass pumping,
i. Overflows where observation or on-site view clearly indicates all sewage was
retained on land and did not reach surface water.
j. Photograph of the event initial, during blockage removal and after blockage
removed.
8. Loading, Unloading and Transportation of screenings and wet grit out of treatment Plant site at his
cost as from the Plant at the place as directed by the Employer’s representative from time to time.
The contractor shall be responsible for disposal of dried cake from sludge drying beds within the
Sewage Treatment Plant campus as directed by Employer’s Representative and modalities of final
disposal will be worked out by the Employer at a later date.
9. Maintenance of log books of all the machinery not connected to the PLC / SCADA shall be done
separately & collectively, at the STP fortnightly and monthly reports of all such machinery and
parameters monitored by the PLC shall be generated and hardcopy along with soft copy shall be got
approved by the Employer’s representative. These reports shall contain sufficient appropriate and
adequate data to make the records meaningful and amenable to analysis for evaluating the
performance of the Plant as well as to help in O & M decisions.
10. Security of the campus and contents therein shall be Contractor’s responsibility.
11. The records maintained by the Contractor shall be produced periodically to the Employer’s
representative for proper monitoring. The Employer’s representative’s remarks shall be attended to
on next submission. Consolidated summary reports shall be furnished to the Employer monthly,
quarterly and yearly containing salient features.
12. All the stuctures shall be painted with preapproved material every alternate year and the roads be
repaired and maintained without any potholes.
The Contractor shall also maintain history sheets of overhauling, maintenance, replacement of all the important
electrical and mechanical equipment
The O & M shall include the appropriate preventive maintenance of equipment as per the manufacturer’s
recommendation.
The operation, maintenance and repairs services shall be performed according to the following:
Down time: The Plant shall never be operated at less than 50% of its design capacity due
to maintenance and repair reasons. The period of such exceptional operation
shall not exceed two consecutive days and shall not be more than three days a
month. The maximum downtime of the whole Plant shall not exceed 8 hours.
The periods for repairs and maintenance have to be communicated to the
Employer’s representative at least one month in advance. For machinery and
equipment which requires maintenance to be carried out by manufacturer/
manufacturer’s authorized representative, the down time shall not exceed 10
days in a year. Employer reserves the right to impose penalty, should there be
any default by Contractor on this account. The penalty amount will be
deducted in the next O & M bill if adequate reasons are not furnished by the
Contractor for delay.
Operation of the The Plant shall be operated according to the rules and procedures laid down in
Plant as per O & M the O & M manual. The Plant must be in position to work at the design capacity
Manual: at any time. Where necessary contractor shall modify/improve the operation
and maintenance manual and got approved from Employer.
Awareness & The Contractor and his staff shall maintain a high degree of awareness in
Cleanliness operation and maintenance of the Plant and all relevant safety codes and
procedures. At all times the Plant, its equipment and surrounds shall be kept
clean and in order’ including the buildings, floors, walls, roofs, windows, and
garden etc.
Frequency of The preventive maintenance shall be carried out according to the preventive
Preventive maintenance schedule of the Plant. The regular staff may be reinforced with
Maintenance short-term specialists by the Contractor for special maintenance tasks, after
duly informing the Employer’s representative of the need and the schedule.
Repairs Repairs shall be made as and when needed very promptly on the spot or at the
Contractor’s / Manufacturer’s workshop. The need of repair on the spot or at
the Contractor’s workshop has to be defined in co-ordination with the
Employer’s representative and according to the status of spare parts
availability.
Spare Parts The Contractor shall keep a reasonable stock of spare parts so that the down
time of equipment can be kept within the limits specified. The contents of the
stock and the reorder level of the inventory have to be approved by the
Employer’s representative.
Transportation All necessary transportation shall be arranged and made by the Contractor at
equipment including planned maintenance schedules or charts giving daily, weekly, monthly, quarterly, half
yearly, annual and overhaul instructions, together with recommended lubricants and spares. These shall also
include details of routine maintenance work that will be within the competence of the normal maintenance staff
and notification of maintenance work that will have to be done by the manufacturer, his agent or other specialist
operator.
Fault locations and remedy charts to facilitate tracing the cause of malfunctions or breakdown and correcting
faults.
Complete list of recommended lubricants and lubrications charts, insulating oil and insulation checking /
replacement chart.
A ‘spares schedule', which shall consist of a complete list of item wise spares for all Plant, items with ordering
references and part numbers.
A complete list of manufacturer’s instructions for operation and maintenance of all bought out equipment. The
list shall be tabulated in alphabetical order giving the name of supplier / manufacture, identification of the Plant
item giving the model number and the literature provided including instruction leaflets and drawing numbers.
Step by step procedure for the dismantling, repair and re-assembly of all items of equipment.
Part-list and drawings or exploded diagrams for each item of Plant with construction particulars, materials of
construction, mating components, clearances and tolerances, maximum wear permitted before replacements
are to be done, etc
Record drawings of all systems installed, including general arrangements, conduit and wiring systems, wiring
diagrams, control schematics and valve charts, etc., to a reduced scale.
The Operation and Maintenance Manual shall include details of all equipment (i.e. new, refurbished and
existing).
The Contractor shall furnish 8 copies of the Operation and Maintenance Manual for the pumping station. Each
volume shall be durable and permanently bound within a stiff binder of a design to be approved by the
Employer. They shall permit the subsequent incorporation of revisions to be necessary during the Defect
Liability Period.
6.3.30.7 REPORTING
The Contractor shall prepare consolidated daily reports, weekly and monthly reports on Plant operation and
maintenance and submit to the Employer’s representative. The daily reports are to be submitted within first
working hour of the next day. The monthly reports shall be submitted on the first day of the next month and
within two working hours.
Overall reporting formats shall be approved by Employer’s representative and may have to be modified from
time to time as required and approved by Employer’s representative. Contractor may have to prepare and
submit additional reports on particular matters and incidents as and when required by the Employer’s
representative for each significant occurrence.
6.3.30.8 TESTS TO BE CARRIED OUT DURING O&M PERIOD
The minimum requirement of sampling and testing is to be carried out daily at least at the points given below.
This schedule shall also be maintained during the O&M period.
Flow measurement
pH, BOD, COD, Suspended Solids / MLSS, Dissolved Oxygen, Alkalinity, Total Nitrogen, Sulphate,
Total Phosphate, Residual Chlorine, Fecal Coliform etc shall be carried out at laboratory.
Instrument/equipment for on line monitoring system for effluent(BOD,COD & TSS) measuring shall be
installed & shall be connected thought PLC to control room as per CPCB order No. A-19014/43/06-
MON dated 21.04.2015. However for all purposes the laboratory analyzed report shall be used for
performance evaluation purpose.
6.3.31 MAINTENANCE
6.3.31.1 MAINTENANCE OF INSTALLATION AT PLANT
The Contractor shall ensure the continuity of the Plant operations. The breakdown or the deterioration in
performance of any items of the Plant and equipment and component parts thereof shall be minimized. The
classes of maintenance provided shall comprise full operational maintenance and standby maintenance.
Full operational maintenance comprises the planned and regular maintenance carried out by the Contractor on
a day-to-day basis, including cleaning, lubricating, minor adjustment, together with the preventive and
corrective maintenance plan for those items of the Plant and equipment within the treatment works which have
been commissioned and made operational.
Standby maintenance comprises the planned and regular maintenance carried out by the Contractor including
cleaning, lubricating, periodic, and minor adjustment of all items of Plant and equipment within the treatment
works which have been installed but have not yet been made operational.
The Contractor shall carry out the maintenance of the Plant installations in accordance with the requirements of
the O&M Manual and as per approved maintenance plan. The Contractor shall strictly adhere to the
manufacturers’ recommendations with respect to equipment maintenance, and only use types and grades of
a- BOD; b- COD; c- Suspended solids/ MLSS; d- pH; e- Dissolved oxygen; f- VSS content
6.3.33.4 RECORD OF SLUDGE DISCHARGED
The record of sludge discharge from the Sludge centrifuge shall contain the duration sludge flow and the quality
of sludge discharges for sludge dewatering. This record shall be maintained by the Employer’s representative
and contains basic data on Plant functioning.
Month:
Year:
Date Flow Total sludge Total Solids % VSS (g/l) Total dried officer Operator
Duration fed to (g/l) sludge on duty
per day Centrifuge (M3 disposed
per day) (Kg)
1. Pump Operation
Pump 1
Pump 2
Pump 3
………
Contractor shall maintain log book for operation & maintenance of each equipment based on
the operation instruction and maintenance instruction provided by manufacturer of equipment.
The maintenance schedule shall include the following:
DG set operation at least once in a week.
Each Screen at SPS shall be cleaned at least two time in one shift.
All sluice gates shall be operated at least once in a month.
All sluice valves shall be operated at least once in a month.
The crane shall be operated at least once in a month.
Daily reports as per the format indicated in Table-2 below for the SPS shall be presented to
RUIDP every week.
TABLE - 2
Operation of Sewage Pumps
Date :
Pump No. 1 Pump No. 2 Pump No. 3 Pump No. 4 Pump No. 5
Detail
Reading
Reading
Reading
Reading
Reading
Power
Power
Power
Power
Power
Time
Time
Time
Time
Time
Start
Stop
Start
Stop
Start
Stop
Note: If any pump is out of service due to maintenance or any other reason, then the same is to be indicated in
the table as “Not Available”
Electrical power bills will be paid by client / line agency during operation & maintenance period.
The Contractor shall submit every month details of the following which will also include the man power
requirement and cost:
Report on preventive maintenance carried out
Report on maintenance carried out due to equipment / system failure
Report on delay in maintenance due to non-availability of man power, spare parts, tools,
chemicals, consumables, etc.
Report on instrumentation failure
Report on calibration of instruments
Spare parts used and/or to be procured
Tools used and/or to be procured
Chemical & consumables used
DG set operation
Quantity of screened material removed
Quantity of grit removed
The contractor shall make arrangements for training the operation staff of the PHED during O&M period.
Monthly report on training of operation staff shall be submitted to client.
The contractor shall provide necessary sets of minimal safety equipment required for regular operation &
maintenance such as safety gloves, helmets, oxygen mask, safety harness, life jackets, gum boots, overalls
etc. The contractor shall give a list of all the safety kits which will be provided. There should be at least 3 nos.
safety kit sets.
6.3.34 OPERATIONS AND MAINTENANCE – OTHER REQUIREMETNS
The scope of work under this contract broadly but not limited to:
All the cost for operation and maintenance of the new STP and new SPS and treated water pumping stations
(PS) - such as manpower, chemicals, fuel, spares, tools, transportation, disposal of treated effluent, disposal of
sludge, disposal of screenings and grit, maintenance of civil structures, electrical and mechanical equipment,
entire plant automation etc shall be ensured by the contractor. Power bill charges are in the scope of the bidder.
The contractor’s scope of work includes preventive maintenance, repairs and replacements of machineries and
equipment, if necessary. No extra payment other than whatever has been quoted by the contractor in the
financial bid will be entertained.
The Contractor shall provide, upkeep and maintain the following facilities for the Employer and Employer’s
Representative during the time for completion of the works at all campuses of proposed STPs/SPS. The cost
for these facilities shall be included in the Contract Price.
The Contractor shall furnish the site office rooms (200 sq feet area) as per the direction of the Engineer in
charge.
6.3.36 OPERATION & MAINTENANCE MANUAL AND AS-BUILT DRAWINGS
The submission of the As-built drawings and the operation and maintenance manual for the system is the
precondition for the final payment.
The Contractor has to submit as operation and maintenance manual after the physical completion of the work.
This manual will be submitted as draft at the date of physical completion and as final version one month after
commissioning. It shall include all the experience made during the tests and the training given to the operators
during the commissioning period. The Contractor will prepare this manual in cooperation with his suppliers and
subcontractors and after consultation with the Employer’s representative for detailed contents. It will at least
contain the following items.
General description of the STPs/IPS and their functioning
Step- by step procures for all the each plant functioning.
Architectural, mechanical electrical, instrumentation, piping drawings, sections, details, charts.
Nomenclature of all the equipment (mechanical, electrical, instrumentation, power and signal cables,
electrical and sanitary fixtures)
For each item of the equipment
o Drawing charts (if required)
o Operational Instructions
o Calibration charts (if required)
o Fault identification and location guides and charts
o Repair instructions (if repair by operations if possible)
o Maintenance instructions including type and quantity of lubricants
o Spare parts list with addresses of suppliers and procedures for ordering.
o Preventive maintenance schedules for all the equipment, showing the type and frequency of
maintenance of different items
o Type and quantity of the recommended consumables (lubricants, fuels etc.,)
o Emergency management for specimen emergency situation which might occur due to external
or internal factors
o Logs for the operator of the system
o Operating hours
o Salient indicators of the operation
o Maintenance operations
o Fault and actions taken
o Other events
o Address and telephone number to contact in case of operation problems shall be provided. It
is emphasized that a collection of standard literature of a general nature, unaccompanied by
specific drawings and descriptive matter relating to the work as commissioned, shall not be
acceptable. The operation and maintenance manual shall be bound in one or several loose-
leaf binders designed to prevent loss and damage of the contents. The binders shall be tilled,
numbered, and have a table of contents of all information contained.
SPS Pumps-
The sewage pumps shall operate based on variations of the sewage level in the wet well. An ultrasonic level
transmitter shall be installed in wet well to measure the water depth of sewage in the wet well. The transmitter
shall send a signal to the pump control panel and to the pump control system (PCS) for level indication. The
pumpcontrol panel shall use this level signal to control the pumps.
Gaskets shall be Flat-ring type for PN10 raised-face flanges. Gasket pressure rating shall be to equal or exceed
the system hydrostatic test pressure. Gasket material shall be 3 mm thick nylon-reinforced cloth inserted
rubber, corrosive acid and alkali freeSewage Pump Operation.
The control system shall be designed to control the sewage as follows:
Each pump station pump shall have control modes “On,” “Off,” and “Auto.”
The “On” mode shall energize the pumps until the switch is turned to the “Off” or “Auto” modes. The
“On” mode shall override any level interlocks calculated from the analog level signal.
In the “Auto” mode, the pumps shall be controlled from the local wet well level control panel.
The ultrasonic level transmitter signal shall be utilized for the control. The pumps shall start one at a
time in sequence as the water in the wetwell rises due to increasing inflow and stop in the reverseorder
as the water level drops due to decreasing inflow. The start and stop levels of all pumps differ by a
constant value ∆H that is determined by the characteristics of the control system.
The control panel shall automatically alternate thestarting sequence of each duty pump after each
cycle of pump operation. The controller shall energize the next duty pump if a duty pump fails to start.
The controller shall energize the standby pump if either the last duty pump fails to start ora pre-set
level is reached on the controller.
In the “Auto” mode, high temperature detected in the pump bearing/motor shall de-energize the
respective pump and activate an alarm.
In the “Auto” mode, moisture detected in the pump shall de-energize the respective pump and activate
an alarm.
In the “Auto” mode, all pumps shall stop when the wetwell is reaches the low level.
In the “Auto’ mode, high wet well level shall activate an alarm.
In all modes, required head not detected in the discharge pipe by a pressure transmitter installed at the
swing check valve shall de-energize the respective pump.
The pump control system shall record and display the running status and moisture detected and shall
have an alarm, a seal failure alarm, and a pump bearing/motor high temperature alarm.
6.3.40 FAECAL SLUDGE MANAGEMENT
6.3.40.1 BACKGROUND
Rajasthan Urban Infrastructure Development Project (RUIDP) has proposed to implement non-sewer solution
to some selected pockets of the towns through Fecal Sludge and Septage Management as suggested by the
Asian Development Bank. These pockets /areas are having the population density less than the density
required to generate the sewage in sufficient quantity for piped sewer network. However, sewer network has
been designed including these areas so that in future whenever required sewer network can be laid.
6.3.40.2 OBJECTIVE
The Objective of Faecal Sludge Management (FSM) is to provide low costs sanitation where sewer network is
not an immediate requirement and make its collection, treatment and effluent management environment-
friendly.
6.3.40.3 MUNICIPAL AREA PROPOSED UNDER SEPTAGE MANAGEMENT
Town is having 40 municipal wards. Out of 40, 23 ward 100 % covered and 12 wards partially covered under
UIDSSMT. There are total 9 wards having the low density, unfavourable topography and safe disposal of waste
water generation from these wards is also a major problem. Therefore town partially covered under FSM.The
following diagram shows proposed coverage withFSM area in cyan color hatching.
Population
Projected Density Per %
Area Proposed
WARD Population Hectar Coverage
under FSM
NO.
Total Habitated
Total Habitat(Ha.) 2021 2021
2021 2021
2 111.02 11.00 3465 22 38 339 10%
10 39.24 3.00 2560 42 42 189 7%
12 45.62 8.00 2592 38 38 443 17%
14 48.14 33.00 3896 39 39 2650 68%
18 111.87 58.00 3773 25 25 1963 52%
19 56.19 39.00 3035 49 49 2823 70%
24 49.37 19.00 3793 47 47 3182 84%
35 38.46 9.00 2938 51 56 665 23%
37 23.51 7.00 1730 74 74 486 28%
Total 27782 12740 46%
Note:- Above table give an general idea of FSM area of the town considered, population shown under FSM above is
an estimated population however, desludging of soakpits/wells is a BoQ item based on no. of trips and as per
requirement and call by the customer/ULB in above wards and shall not be related with area and population of ward.
6.3.40.4 GENERAL SCOPE
Desludging of septage from household pits/ septic tank, transportation to STP, Disposal to designated unit in
STP including operate and maintenance of the equipment with all accessories complete in all respect over the
entire O&M period. Generally the following activities shall be carried out by the Contractor. The scope of work is
broadly listed below and shall include, but not limited to the followings.
6.3.40.5 DESLUDGING EQUIPMENT
Supply, Trial run and commissioning of Truck mounted Desludging Equipment with all accessories, as
per technical specification.
Maintenance of equipments- Routine, Preventive and Break down maintenance
Desluding from household pits/septic tanks at any location domestic/institutional/public within respective
premises, transportation to STP and disposal to stipulated unit of STP.
The equipment shall be a Truck Mounted Mobile Unit suitable for desludging, dislodging and removing
obstructions and blockages from containments (pits/septic tanks/etc.) by a High Vacuum suctioning the
Sludge/ slurry by Vacuum Suction System and discharging the collected sludge by Hydraulic Tipping of
the Tank, alternatively through Blow-back Arrangement.
6.3.40.5.1 DRIVING SYSTEM
The Engine of the Truck Chassis will be utilized to drive the vacuum pump through a split- shaft power take-off
unit installed between the vehicle gearbox and the differential unit. The Hydraulic pump shall be driven through
the side Power Take Off (PTO) of the truck gear box.
The changeover of the PTO unit for individual drive will be from driver’s cabin.
6.3.40.5.2 TANKER
The cylindrical tank and Dish ends shall be fabricated out of 5 mm thick MS Plates conforming to IS: 2062
grade. The tank shall have a capacity of 3500 Ltrs. The tank will be mounted on an appropriate sub-frame,
which in turn will be bolted to the truck chassis.
The tank has Blow – Back arrangement for discharge of material from the sludge tank using the Exhauster /
Compressor in compressor mode. The Blow-back Arrangement will be more hygienic and cleaner way of
evacuating the sludge from the tank by pressurizing the tank when the exhauster compressor will run in
compressor mode.
The tank also has arrangement for hydraulic tipping for discharge of material from the sludge tank. The rear
door of the sludge tank will be fitted with hydraulic cylinders for opening and closing of the door. Adequate
sealing and locking arrangement has been provided to render the door leak proof. Further, necessary
arrangement for filling and draining the fresh water compartment will be provided. A filter shall be provided in
the inlet of the fresh water tank.
The Level Indicator made of thick transparent acrylic tubing to be provided on sludge compartments in positions
convenient for the operator to view.
The tank exterior will be spray painted with a coat of superior quality anticorrosive primer and two coats of
enamel paint of reputed make. The tank interior will be coated with two coats of anti-corrosive epoxy paint.
The maintenance activity shall include checking of fuel, training of driver, tyre puncture checking, cleaning of
equipments, lubricating the accessories and equipments and any other, etc.
If machine is not repaired for want of repairs, then deduction shall be made on pro-rata basis from running O&M
bill.
The successful bidder would be responsible for training the municipality official/staff for “operation and general
maintenance of the equipment supplied by them”. The supplier / Contractor can even hire trained staff from the
equipment dealer to cater for the training needs. The training should commence immediately once the
equipment has been received by officials/ staff and after the training the operator/supervisor would be able to
run the equipment independently without support. 3 No. workers/drivers of the ULB will have to give thorough
training by the contractor for 03 months covering all technical aspects of maintenance of the vehicle viz.,
weekly, daily and monthly maintenance and preventive maintenance.
TheContractorshallprovidethefollowings
One copiesofworkshopand service manual
One copies of spare partscatalogue
Warranty card for one year.
Battery warranty card for one year.
The technology integration in terms of GPS device to be integrated with the truck, there should be designated
call center where citizens of the town can call to avail the desludging services and also maintain the records of
all the desludging activities done in the town.
If collection, transportation and disposal at designated place (inlet to STP) is non-complied, then penalty shall
be charged as per regulations of Urban Local Body of concerned city.
6.3.40.6 TREATMENT PLANT
No separate treatment plant will be required contractor has to design the Sewage Treatment plan (SBR) under
this contract for sewerage system considering the faecal sludge disposal in STP designated (Co-treatment)
unit. Timing of the disposal of the faecal sludge into STP may be during peak hours.
6.3.40.7 OPERATION AND MAINTENANCE
Operation and maintenance of entire septage chain from collection-disposal-treatment for 10 years.
6.3.40.8 PROVISIONS OF DAMAGES – FSM
If contractor fails to collect and safe disposal of faecal sludge at designated place, he shall be penalized as per
following provisions:-
a. Improper/unsafe Dispoal of Faecal Sludge – If contractor do not dipose the sludge collected from the
pits to the Inlet of STp/as per approved process design, a damages of Rs. 5000/- per unsafe disposal will
be imposed and recovered from next Running Payment to contractor.
b. Non-collection of Faecal Sludge on demand of Owner/MC – If contractor do not mobilize the collection
team and vehicle on the demand of the owner/MC to empty the pits a damages equal to double the rate
quoted by the contractor for per trip limit will be imposed and same shall be recovered from the next
Running Payment to contractor.
c. Damages due to unsafe and non collection of faecal sludge as per (a) & (b) shall be in addition to the
maximum amount of delay damages i.e. 10% of accepted contract amount as per clause 9.6 “Maximum
delay damages” Section-8: Particular condition of contract.
6.3.41 PAYMENT SCHEDULE FOR STP & SPS WORKS
The following is the price break-up of the STP & SPS work against work done (based on turn-key). Payment
equal to 10% for STP/SPS work shall be released (deducted at each payment for STP/SPS) after successful
trial run & commissioning of the STP/SPS as per conditions of the contract. The break-up of payment is
mentioned below.
Table 35: Payment Breakup for STP and SPS
Payment Schedule for Turn Key Job (Excluding O&M)
Payment Schedule is in percentage of total amount quoted by contractor for the turnkey job except
for O&M for STP in price bid of Vol-II
S.No. Particulars %age
Total Amount in Rs. 100%
1) Progressive Payment Related to Design & Construction 80%
2) Payment Related to Wet Testing and Trial Run 10%
3) Payment on Commissioning 10%
Total 100%
1 DESIGN, DRAWING AND DOCUMENTATION 4.80%
2 CIVIL WORKS 33.60%
Sub-head payments
1.1 PROCESS DESIGN & DRAWINGS 2.00%
1.2 ARCHITECTURAL & STRUCTURAL DESIGNS AND DRAWINGS 0.96%
MECHANICAL INCLUDING PIPING ELECTRICAL AND INSTRUMENTATION &
1.3 1.60%
CONTROL DESIGNS AND DRAWINGS
1.4 AS BUILT DRAWINGS FOR THE PLANT 0.08%
1.5 OPERATION AND MAINTENANCE MANUAL 0.08%
1.6 TRAINING PROGRAMME AND MANUAL 0.08%
TOTAL AFTER FINAL APPROVAL OF DRAWINGS 4.80%
2 Schedule 2 - CIVIL WORKS (33.60)
2.1 INLET WORKS( Pretreatment units)
a Receiving chamber , coarse screen, sump etc. 1.80%
b Inlet chamber cum Distribution chamber 0.20%
c Fine screen chamber 0.40%
d Grit separator units 0.40%
e Flow measurement system 0.20%
2.2 SECONDARY TREATMENT UNITS
a SBR Tank 16.00%
b Blower Room 0.20%
c Return sludge system 1.40%
d Chlorination system 4.00%
2.3 SOLIDS and SLUDGE HANDLING UNITS
c Sludge thickener & Centrifuge and System 0.68%
2.4 ANCILLARY FACILITIES
a Office and laboratory Building 1.00%
b Parking Shed 0.08%
c All Pump House and other Buildings 0.16%
d PMCC and Control Room 1.00%
e Work Shop and Store 0.40%
f MCC Room 0.20%
g Security Room 0.08%
2.5 Horticulture and landscaping 0.40%
2.6 Treated Waste water reuse system 4.80%
2.7 Roads 0.12%
2.8 Compound Wall 0.08%
Total (Civil works) 33.60%
Payment Schedule is in percentage of total amount quoted by contractor for the turnkey job except
for O&M for SPS in price bid of Vol-II
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Name of Work:- “Construction of Works of Water Supply Production and Distribution Network
Improvements with house service connections for nonrevenue water reduction and continuous water
supply and Providing Sewer Network with House connections, and construction of Sewage Treatment
Plant & Sewage Pumping Station and all allied Works and operation services of the entire system for 10
years at Sardarshahar (Churu)”
TABLE OF CONTENT
6.4.1 ROAD RESTORATION ....................................................................................................................3
Road restoration is a critical activity which requires special attention of the contractor. Project city wise
limits and penalties are as follows: -
a) The contractor shall have to restore the road up to WMM/PCC stage including refilling/hydrotesting
which ever is earlier trench in layers, watering, rolling and compacting to within 14 days after
trenching is completed in a particular street/reach.
b) The contractor shall have to restore the BT/CC surface (wearing course) within 45 days after
refilling/hydrotesting whichever is earlier of trench in a particular street/reach. The contractor shall
ensure that total uncovered length by BT / CC surface (wearing course) does not exceed 3.0 KM at
any stage of work.
c) Contractor shall erect informatory board at his own cost showing type of work, inconvenience
expected and timeline for various construction activities going to take place in a particular street or
a particular reach of road as per direction of Employer’s Representative in charge.
d) Contractor shall deploy a Social Outreach Team (SOT) of social activity work with government
recognized NGO or other government institutes to make strong relation with public prior to start of
work in a particular ward/ area.
e) The contractor shall have to do the sequencing of activities as per direction of Employer’s
Representative in charge to synchronize sewer work and water pipe line work to minimize the road
excavation and restoration in the street which will have both pipe lines.
f) The cutting of existing C.C. pavement shall be done by using mechanical cutter to ensure cutting in
regular line and the laying of C.C pavement shall be done below ambient temperature as per
relevant IS code.
g) In the town where only water supply works are porposed road restoration in BT and CC will be in
trech width only, however if condition of existing road is poor and considered as main road of town
for traffic movement, then can be restored to full width as per sub clause of road restoration but
total length of such restoration up to 10 % of total network length. Approval of such type of roads
shall be taken by the employer representative before planning of road restoration in full width.
a. For laying sewer on BT Surface for road width up to 3.5 m, restoration up to WMM stage in trench
width and bituminous work (wearing surface) in full width of the Existing Road.
b. For road width upto and including 7.0 m, restoration up to WMM stage in trench width and
bituminous work (wearing surface) in entire road width up to and including 7.0 m. For road width
more than 7.0 m, restoration limited to 7 m (2 lanes) to cover the trenches (may be one lane over
each trench).
c. For interior roads (where paver finisher is not feasible):- WMM-150-200 mm, 25 mm PMC laid and
finished manually with primer coat, tack coat, and sand seal coat.
d. For other roads as per existing road traffic requirement:
1. GSB – 150 mm, WMM – 200 mm.
2. For road width more than 3.0 m and up to 5.5 m PMC with paver – 25 mm with sand seal
coat.
3. For road width 5.5 m and up to 7 m (intermediate lane): BM – 50 mm, SDBC 25 mm
4. For road width 7.0 m (two lane): BM – 75 mm, SDBC 35 mm
e. If the condition of the existing road is good Employer Representative shall review the requirement
of full with raod restoration.
f. Provision of the profile correction has been considered in the BoQ. If any correction of the profile
is required to be made, it shall be executed only after approval of the Employer’s representative.
However, length and width of road shall be under the sole discretionary of the ER. Profile
correction shall be three dimensional - alignment, profile, and cross-section to be done on the
existing BT surface. This work shall be limited to the BoQ quantity only. This profile correction
shall not be applicable for the full width road constructed by the contractor under this package, if
any profile correction is required in the executed road due to quality issue of the road this shall be
done by the contractor at his own cost.
g. In Bituminous road restoration, Use of Paver is mandatory for carriage way width equivalent and
above 3.0 m of road restoration.
a. For road width less than & equal to 4.0m, restoration up to PCC stage (lean concrete) will be in
trench width and CC pavement of M-30 grade in full width.
b. For road width more than 4.0m, restoration by lean concrete and pavement in M-30 grade in
trench width only.
c. For interior roads:- PCC (base course) – 125mm, wearing course 150 mm but not less than
existing layer.
d. For Main roads:- PCC (base course) – 150 mm & wearing course 200 mm but not less than
existing layer.
Notwithstanding all which has been laid down on road restoration, Employer’s representative with reasons
recorded and prior permission of PIU incharge will be authorized to come up with the site specific solution
based on prevailing ground situation.
If contractor fails to adhere the provisions of time cap for road restoration mentioned in a) above, he shall
be penalized as below:-
a. For a stretch uncovered by CC/BT after refilling/hydrotesting whichever is earlier of trench beyond
45 days, a damages of Rs.: 6000/- per day per km of incomplete length will be imposed and
recovered from next Running Payment to contractor.
b. If the length of uncovered by CC/BT exceed, 3 Km, a damages of Rs. 3000/- per day per km of
uncovered length over 3 Km will be imposed and same shall be recovered from the next Running
Payment to contractor.
c. Damages due to delayed road restoration as per (a) & (b) shall be in addition to the maximum
amount of delay damages i.e. 10% of accepted contract amount as per clause 9.6 “Maximum
delay damages” Section-8: Particular condition of contract.
Any road work done by the contractor, if get damaged within defect liability period under this project shall
be repared by the contractor without any cost implication on the Employer.
For emergency and unforeseen condition in prominent/ congested area of town, where road resoration is
required to be restored immediately, contractor may be allowed to use any rapid hardening componund
equivalent to cement concrete or BT surface as per relevant IS/ASTM subjected to approval of Employer’s
representative.
For construction of Bitumen road and CC road contractor shall establish his own WMM, BT & CC plant
and no subletting shall be allowed.
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Name of Work:- Lot-1 ““Construction of Works of Water Supply Production and Distribution Network
Improvements with house service connections for nonrevenue water reduction and continuous water
supply and Providing Sewer Network with House connections, and construction of Sewage Treatment Plant
and Allied Works and operation services of the entire system for 10 years at Sardarshahar (Churu) ”
Table of Content
6.5.1 CIVIL STRUCTURES DESIGN REQUIREMENTS ..........................................................................3
6.5.2 DESIGN SUBMISSIONS .................................................................................................................3
6.5.3 DESIGN STANDARDS ....................................................................................................................3
6.5.3.1 DESIGN LIFE.................................................................................................................3
6.5.3.2 DESIGN LOADS ............................................................................................................3
6.5.3.3 DEAD LOAD ..................................................................................................................3
6.5.3.4 LIVE LOAD ....................................................................................................................4
6.5.3.5 WIND LOAD...................................................................................................................4
6.5.3.6 EARTHQUAKE LOAD ...................................................................................................4
6.5.3.7 DYNAMIC LOAD............................................................................................................4
6.5.3.8 EQUIPMENT LOADS ....................................................................................................4
6.5.3.9 CRANE LOADS .............................................................................................................4
6.5.3.10 TEMPERATURE LOAD .................................................................................................4
6.5.3.11 INDIVIDUAL MEMBERS LOAD .....................................................................................4
6.5.4 PARTLY/FULLY UNDERGROUND LIQUID RETAINING STRUCTURES- BASIS FOR DESIGN ....
.........................................................................................................................................................4
6.5.5 FOUNDATIONS ...............................................................................................................................5
6.5.6 REQUIREMENTS FOR REINFORCED AND PLAIN CONCRETE WORKS (STRUCTURES) .........
.........................................................................................................................................................5
6.5.7 REQUIREMENTS FOR BUILDING WORKS ...................................................................................6
6.5.8 CONCRETE REINFORCEMENT.....................................................................................................8
6.5.9 JOINTS ............................................................................................................................................8
6.5.5 FOUNDATIONS
i. The minimum depth of foundations for all structures, equipments, buildings and frame
foundations and load bearing walls shall be minimum 2 m and as per IS: 1904.
ii. Care shall be taken to avoid the interference of the foundations or any other component of the
new building with the foundations of adjacent buildings or structure. Suitable adjustments in
depth, location and sizes may have to be made depending on site conditions. The Employer’s
Representative shall accept no extra claims for such adjustments.
iii. Special attention is drawn to danger of uplift being caused by the ground water table. Base raft
for underground structure shall be designed for uplift forces that are likely to be developed.
iv. Where there is level difference between the natural/ existing ground level and the foundations
of structure or floor slabs, this difference shall be filled up in the following ways:
In case of non-liquid retaining structures the natural top soil shall be removed till a firm
stratum is reached (minimum depth of soil removed shall be 500 mm.) and the level
difference shall be made up by compacted backfill as per specifications. However, the
thickness of each layer of the backfill shall not exceed 150 mm. The area of backfilling for
floor slabs shall be confined to prevent soil from slipping out during compaction. The safe
bearing pressure of this well compacted backfilled soil for design calculations shall not
exceed 100 KN/m2.
In case of liquid retaining structures, the natural top soil shall be removed as described
above and the level difference shall be made up with Plain Cement Concrete (1:5:10)
Submission of structural designs and working drawings for approval of Employer’s
Representative. The structural design and reinforcement drawings shall be prepared
assuming SBC of soil or the base rock as 10 T/Sqm, if the SBC on testing is found to be
10 T/Sqm or more at foundation depth. If the SBC testing is found to be less than 10
T/Sqm at foundation depth the structure shall be designed on the basis of actual SBC
found on testing for which no extra payment will be made to contractor. SBC tests shall be
got done through an approved agency wherever the strata on which foundation is to be
laid is not rocky. The foundation shall only be laid on firm rock or hard soil bed after
removing decomposed rock and all loose material.
6.5.6 REQUIREMENTS FOR REINFORCED AND PLAIN CONCRETE WORKS (STRUCTURES)
The following are the design requirements for all reinforced or plain concrete structures:
a. All blinding and levelling concrete shall be a minimum 100 mm thick with minimum concrete
M10 grade and M15 grade for liquid retaining structures.
b. All structural reinforced concrete other than for water retaining structures shall at least be of M-
25 grade with a maximum 40 mm aggregate size for footings and base slabs and with a
maximum 20 mm aggregate size for all other structural member.
c. The RCC work shall be carried out with SRC cement where the structure will remain in touch with
sewage / sludge in design mix of min M-35 having minimum cement content of 370Kg/m3.
d. The minimum grade of concrete for water retaining structures shall be M-35 having minimum
cement content of 350 kg/m3 with a maximum 40 mm aggregate size for footings and base
slabs and with a maximum 20 mm aggregate size for all other structural member.
e. All liquid retaining structures shall be designed based on NO CRACK BASIS.
f. The minimum clear cover to all reinforcement including stirrups and links shall be 45 mm for all
water retaining structures and 50mm for sewage retaining structures including the bottom of
roof. For other structures the minimum clear cover shall be as specified in IS: 456.
g. Any structure or pipeline crossing below roads shall be designed for a minimum of Class A of
IRC loading.
h. The bridges and supporting structure (for clarifiers, pipeline crossing river, etc.) shall be
designed to safely withstand the loadings such as loads and torque transmitted through
scrapper blades, motor, water force in the river, etc. depending on the arrangement offered
besides other loads.
i. All pipes and conduits laid below the structural plinth, road works, river bed, nallah crossing, etc.
except those crossing National Highway/Railway line, shall be embedded in plain concrete of
minimum grade M15 having minimum 300 mm thick concrete cover all around.
j. Approved quality water proofing compound (chloride free) shall be added during concreting of all
liquid containing structure, in the proportion specified by manufacturer.
k. For walls of liquid retaining structures, the following shall be considered.
Minimum reinforcement shall be as per IS: 3370 part -2.
Maximum length of panel to be concreted considering partial construction joints shall
be 7.5 m. The adjacent panels shall be poured with a minimum time gap of
4 days. Height of pour shall not exceed 2 m.
l. The following minimum thickness shall be used for different reinforced concrete members,
irrespective of design thickness:
(i) Walls for liquid retaining structures : 200 mm
(ii) Roof slabs for liquid retaining structures : 150 mm
(iii) Bottom slabs for liquid retaining structures : 200 mm
(iv) Floor slabs including roof slabs, walkways, canopy : 150 mm
slabs
(v) Walls of cables / pipe trenches, underground pits etc : 125 mm
(vi) Column / Wall footings : 300 mm
(vii) Parapets, Chajja : 100 mm
(viii) Precast trench cover : 75 mm
6.5.7 REQUIREMENTS FOR BUILDING WORKS
Unless otherwise specified, all the building works shall generally comply with the following
a. All buildings shall have Reinforced Concrete framework.
b. 75 mm thick RCC Damp Proofing Course in M15 shall be provided to all building walls.
c. Anti-termite treatment as per IS: 6313 part-III – 1971 with injection of chloropyrious emulsifiable
concrete (1%) timber care ground treatment chemically emulsion 1:3 and creating a chemical
barrier under and around the column pits, wall trenches, basement excavation, top surface of
plinth filling, junction of wall and floor along the external perimeter of building, expansion joints,
surrounding of pipes and conduits etc.
d. All external walls shall be in 230 mm thick brick masonry built in cement mortar in (1:4). Transoms
and mullions shall be of 115 mm x 230 mm size of cement concrete in M15 with four numbers 6
mm bars and 6 mm links at 150 mm c/c shall be provided to form panels not exceeding 3500 mm x
3500 mm in size.
e. All internal partition walls except for toilets shall be in 230 mm thick brick masonry built in cement
mortar 1:4 with transoms and mullions as stated above. Toilet partition walls shall be in 115 mm
thick brick masonry built in cement mortar 1:4 and shall have transoms and mullions as stated
above to form panels not exceeding 1200 mm x 1200 mm size.
f. All internal masonry surfaces shall be finished with 12 mm thick smooth faced cement plaster in
cement mortar (1:4).
g. All external masonry surfaces shall be plastered in two coats with sand faced cement plaster in
cement mortar (1:4) and shall have total thickness of 20 mm. Waterproofing compound of
approved make and quality shall be added to the cement mortar in proportions as specified by the
manufacturer.
h. Bathroom/ W.C. floor slab shall be sunk and filled with brickbat coba (broken bricks set in lime)
and provided with waterproofing as per the specifications of an approved specialist waterproofing
company. The finished floor level in Bathroom / W.C. areas shall be normally 12 mm below the
finished floor level on the outer side.
i. Toilet facilities shall be provided at all New STP, SPS, Master Control Centre, for
men and women usage separately and shall include at least:
i. 1 No. Water closet with white porcelain EWC/Orissa pan minimum 580 mm long
with PVC flushing cistern of 10 liters capacity.
ii. 1 No. Urinal of sizes 600 mm x 400 mm x 300 mm flat back type in white porcelain
separated by a kota stone partition of size 680 mm x 300 mm shall be provided
outside toilet.
iii. 1 No. Washbasin of size 510 mm x 400 mm in white Porcelain with inlet, outlet with
bottle trap.
iv. 1 No. Mirror of size 400 mm x 600 mm PVC moulding wall mounted type fitted over
washbasins.
v. 1 No. Plastic liquid soap bottles
vi. 1 No. Chromium plated brass towel rails minimum 750 mm long.
vii. All stopcocks, valves and pillar cocks shall be of chromium-plated brass, heavy
duty.
viii. All fittings such as `P’ or `S’ traps, floor traps, pipes, down-take pipes etc.
ix. The sewage from toilet blocks shall be led to the sewerage system is as directed by
the Employer.
i. Wherever specified, staircases shall be finished with 25 mm thick Kota Stone treads and 20 mm
thick Kota Stone skirting. The rise of stairs shall not exceed 170 mm and minimum width of the
tread shall not be less than 275 mm. All steps shall have 20 mm nosing. R.C.C. stairways shall be
provided to permit access between different levels within buildings. All roof tops and tops of
overhead tanks shall be made accessible with ladder provision. Vertical ladders fitted with landing
point extensions will be permitted where considered appropriate by the Employer’s Representative
to access areas not frequently visited.
j. All floor cut outs and cable ducts, etc. shall be covered with pre-cast concrete covers in outdoor
areas and G.I. chequered plates with epoxy paint of adequate thickness in indoor areas. All
uncovered openings around the platforms, balcony, stairs, and landing shall be protected with SS
(Building works)/ Aluminium hand railing (treatment plants and pumping stations) of 40 mm dia
pipe and 5.08 mm thickness (schedule-80) with anodizing as per specification.
k. All staircases shall be provided with SS PVC cover or wooden handrail (Building works)/
Aluminium hand railing (treatment plants and pumping stations40 mm dia pipe and 5.08 mm
thickness (schedule-80) with anodizing as per specification.
l. The reinforced concrete roofs shall be made waterproof by application of approved cement/ lime
based waterproofing treatment. The finished roof surface shall have adequate slope to drain
quickly the rainwater to R.W down-take points.
m. For roofing drainage, PVC rainwater down-takes with khurra and door bend with grating at top
shall be provided. For roof areas up to 40 m2. minimum two nos. 100 mm diameter down-take
pipes shall be provided. For every additional area of 40 m2 or part thereof, at least one no. 100
mm dia. down take pipe shall be provided. The RW pipes shall be concealed.
n. Top surfaces of chajjas and canopies shall be made waterproof by providing a screed layer of
adequate slope or application of an approved roof membrane and sloped to drain the rainwater.
o. Building plinth shall be minimum 450 mm above average finished ground level around building and
shall not be less than plinth level of existing buildings.
p. All buildings shall have a minimum 1.0 m wide, 100 mm thick plinth protection paving in M15 grade
concrete finished with stone slabs/ tiles. All plinth protection shall be supported on well-compacted
stratum.
q. All concrete channels and ducts used for conveying liquid shall have smooth finish from inside.
The width of concrete channels shall not be less than 500 mm. All open channels shall be provided
with SS (building works)/ Aluminium hand railing (treatment plants and pumping stations) 40 mm
dia pipe and 5.08 mm thickness (schedule-80) with anodizing as per specification.
r. Kerbs to be provided below the hand railing on the catwalks/pathways should be as per relevant
sections of the Factory Act.
s. All rooms in the treatment plant buildings and SPS shall be provided with appropriate signboards
indicating the function of the rooms involved.
t. Wherever equipment and machinery is required to be moved for inspection, servicing, replacement
etc., suitable movable gantry of required capacity shall be provided.
u. The design of buildings shall reflect the climatic conditions existing on site and it shall as far as
possible permit the entry of natural light.
v. Emergency exit doorways shall be provided from all buildings in order to comply with local and
international regulations. Stairways and paved areas shall be provided at the exit points.
w. Toilet blocks in process building shall be provided with two drinking water taps of 12mm size and
sink with appropriate drainage.
x. All chequered Plates shall be hot dip galvanized.
y. All types of opening such as doors, windows and ventilators shall be minimum 25% of the floor
area.
z. Glass shall be minimum 5 mm thick, pin headed or opaque.
aa. All roof tops and overhead tanks shall be made accessible with ladder provision. Vertical step
ladders fitted with landing point extensions will be permitted where considered appropriate by the
Engineer to access areas not frequently visited.
bb. Steel staircases shall be constructed of standard channel stringers with M.S. grating treads 25mm
thick with non skid nosing. Steel Ladders shall be minimum 600mm wide and shall not exceed 6m
of straight run. The ladders shall be painted with epoxy paint.
cc. All doors, windows and ventilators shall be made of aluminium confirming to latest version of IS:
1948. All fixtures for doors, windows and ventilators shall also be of aluminium. Aluminium grills
shall be provided in all the windows. Doors shall be in two panel and both panels shall be
glazed/unglazed. Minimum weight of aluminium doors and windows shall be as follows
Single Glazed Window : (Weights Outer Frame :Weight 0.70 kg/Rmt
indicated shall be aluminium) Shutter Frame:Weight 0.97 kg/Rmt
Openable
Intermediate Mullion:Weight 0.97 kg/RMt
Beading:Weight 0.31 kg/Rmt
This Section contains the Scope of Services, Specifications, Drawings, supplementary information that
describes the existing system, Personnel Requirements and Equipment Requirements.
Name of Work: “Construction of Works of Water Supply Production and Distribution Network
Improvements with house service connections for nonrevenue water reduction and continuous water
supply and Providing Sewer Network with House connections, and construction of Sewage Treatment Plant
and Allied Works and operation services of the entire system for 10 years at Sardarshahar (Churu) ”
Table of Content
6.6.1 MECHANICAL DESIGN REQUIREMENTS ........................................................................ 4
6.6.1.1 THE BASIC DESIGN REQUIREMENTS FOR SATISFACTORY HYDRAULIC
PERFORMANCE OF PUMP HOUSE SHALL BE AS UNDER: ............................................... 4
6.6.1.2 SUBMERSIBLE, HORIZONTAL SPLIT CASING (HSC) CENTRIFUGAL PUMP,
END SUCTION PUMPS – DESIGN REQUIREMENTS ........................................................... 4
6.6.2 ELECTRICAL SYSTEM ...................................................................................................... 8
6.6.2.1 GENERAL ............................................................................................................... 8
6.6.2.2 MAJOR UNITS OF THE CONTRACT..................................................................... 9
6.6.2.3 AVALIABILITY OF POWER SUPPLY ..................................................................... 9
6.6.2.4 CLEAR WATER PUMPING STATION .................................................................... 9
6.6.2.5 ELECTRICAL SYSTEM FOR PROPOSED SEWAGE PUMPING STATION....... 10
6.6.2.6 ELECTRICAL SYSTEM FOR PROPOSED SEWAGE TREATMENT PLANT ..... 10
6.6.2.7 PROPOSED AND EXISTING TUBE WELL .......................................................... 11
6.6.2.8 ELEVATED SERVICE RESERVOIRS .................................................................. 11
6.6.2.9 TRANSFORMER SIZE SELECTION CRITERIA .................................................. 11
6.6.2.10 DG SIZE SELECTION CRITERIA......................................................................... 12
6.6.2.11 SOLAR PANEL TECHNICAL SPECIFICATION ................................................... 12
6.6.3 INSTRUMENTATION, AUTOMATION AND CONTROL SYSTEM DESIGN
REQUIREMENTS .......................................................................................................................... 14
6.6.3.1 DESIGN REQUIREMENTS FOR INSTRUMENTATION, CONTROL,
AUTOMATION AND SCADA SYSTEMS ............................................................................... 14
6.6.3.2 FURNITURE.......................................................................................................... 14
6.6.3.3 SITE CONDITIONS ............................................................................................... 15
6.6.3.4 GENERAL DESIGN REQUIREMENTS ................................................................ 15
6.6.4 INSTRUMENTATION, AUTOMATION AND CONTROL SYSTEM TECHNICAL
REQUIREMENTS .......................................................................................................................... 15
6.6.4.1 GENERAL ............................................................................................................. 15
6.6.4.2 THE SCOPE AND BATTERY LIMITS................................................................... 16
6.6.4.3 WATER SUPPLY NETWORK............................................................................... 16
6.6.4.4 SEWAGE TREATMENT PLANT AND PUMPING STATIONS ............................. 16
6.6.5 DESIGN CRITERIA FOR INSTRUMENTATION, CONTROL, AUTOMATION AND
SCADA SYSTEMS ........................................................................................................................ 20
6.6.5.1 INSTRUMENTATION SYSTEM ............................................................................ 20
6.6.5.2 PLC SYSTEM........................................................................................................ 21
6.6.5.3 RTU SYSTEM ....................................................................................................... 21
6.6.5.4 SCADA SYSTEM .................................................................................................. 22
6.6.5.5 FUNCTIONAL DESIGN SPECIFICATION (FDS, SEQUENCE OF OPERATION) ..
............................................................................................................................... 22
6.6.5.6 POWER SUPPLY.................................................................................................. 23
6.6.5.7 VOLTAGES ........................................................................................................... 23
6.6.6 CONTROL SYSTEM PROTECTION ................................................................................ 23
6.6.6.1 SHORT CIRCUIT ....................................................................................................... 23
6.6.6.2 SURGE PROTECTION .............................................................................................. 23
6.6.7 INSTRUMENTATION POWER SUPPLY CABLES AND INSTRUMENTATION SIGNAL
CABLES ......................................................................................................................................... 23
6.6.8 SURVEILLANCE CCTV SYSTEM .................................................................................... 23
6.6.9 REFERENCE STANDARDS ............................................................................................. 24
Reference Tables
Table 1 Vertical turbine pump ................................................................................................................. 4
Table 2 Centrifugal and Submersible Pumps ......................................................................................... 4
Table 3: Design Stages of Electrical Components ................................................................................. 9
Table 4: Details of Transformer ............................................................................................................ 11
Table 5: Details of DG .......................................................................................................................... 12
Table 6: Location of solar panel ............................................................................................................ 12
Table 7: SCADA Furniture and other Items .......................................................................................... 14
Table 8: Instrumentation Schedule ....................................................................................................... 17
Table 9: Instrumentation Voltage Required .......................................................................................... 23
Table 10: SCHEDULE OF MECHANICAL AND INSTRUMENTS ITEMS ............................................ 25
Pump
Corbel top Pump floor
floor for
S. No. HP of Pump to roof slab to bottom Lifting equipment
corbel
bottom of roof total
top
ii. Double floor pump house: Generally double floor arrangement shall be provided for
Delivery pipe (diameter 350mm and above), The height of pump shall be as bellow:
Monorail with
1 up to 50 HP - - 4.0
Electric Hoist
6.6.1.2 SUBMERSIBLE, HORIZONTAL SPLIT CASING (HSC) CENTRIFUGAL PUMP, END SUCTION
PUMPS – DESIGN REQUIREMENTS
The Contractor shall select suitable submersible pump for tube well water and HSC, end suction pump for
clear water in the specified operating range. All the pumps for the particular pressure main shall be of
similar characteristics.
The type of pumps for TWs water and Sewage Water shall be submersible. The type of pumps for clear
water shall be of HSC centrifugal. For smaller capacities where HSC pumps are not available, end suction
centrifugal pump sets may be used. All the pumps shall be provided with suitable motors and accessories.
The pumps shall be capable of developing the required total head at rated capacity for continuous
operation. The pumps shall be suitable to operate satisfactorily, in parallel, within the operating range. The
pumps shall have a stable head curve, i.e. the total head-capacity curve shall be continuously rising
towards the shut off. The shut off head shall be at least 10% more than pump head at intersecting point of
the pump curve with the upper range system head curve. The design point shall be as close as possible to
maximum efficiency point of pump.
The Contractor may operate the combination of pumps and operation of pump for the varying pumping
hours, installation of pumps in series to achieve the required flow within the flow range.
The pump shall operate satisfactorily at any point between the maximum and minimum system
resistance, or at the end of performance curve with respect to the NPSH available at the lowest
permissible suction level. The pump characteristics should be selected on the basis of existing/
proposed layout of the pumping station. Space should be available for new pumping station, suction
manifold and clear water reservoir to ensure that the requirements are met.
The required NPSH at any operating point shall be at least 1.0 meter less than the available NPSH.
Minimum submergence of bell mouth shall be as per Hydraulic Institute Standards (HIS) which has
to be calculated. The horizontal split casing pumps shall be used with positive suction head. In case
the site condition warrants suction lift, suitable vacuum pumps shall be provided for priming the
pumps.
All the pumps shall be capable of developing the required total head at rated capacity of design
discharge for continuous operation. The Contractor shall match the performance curves of pumps to
the operating range.
The Contractor shall guarantee a minimum overall efficiency for pumps as per the reference given in
CPHEEO manual or as offered by the manufacturer, whichever is higher, corresponding to delivery
of design discharge at duty point. The Contractor shall specify the pump performance.
The static head for the design of clear water pumps at pump Station will be the difference in centre
line of inlet at CWR and highest water level in the ESR/ RL of delivery point of inlet pipe whichever
applicable.
Horizontal split casing pumps or mono block pumps shall be installed with positive suction head with
individual suction.
The pumps shall be capable of reverse rotation up to 125% rated full speed of the drive motor, due
to backflow of water, without damage or loosening of threaded components.
Pumps shall run smooth without undue noise or vibration. Noise levels and velocity of vibrations shall
be within acceptable limits. Noise level shall be limited to 85 dBA at a distance of 1.86 m. Velocity of
vibrations shall be as per relevant Hydraulic Institute Standards (HIS).
Pump must be suitable for operating in parallel over the entire operating range. The pump shall
operate satisfactorily at any point between the maximum and minimum system resistance.
The drive motor power rating shall be the maximum of the following requirements:
a) 115% of pump input power including losses in transmission shafting and thrust bearing for duty
parameters i.e. head and capacity.
b) 105% of the maximum pump input power including losses in transmission shafting and thrust
bearing within the operating range between maximum and minimum system resistance curves,
considering multiple pumps operation.
Spare parts supplied for O&M period with the pump shall be identical to respective pump
components and shall be from original pump manufacturer.
Contractor shall offer only pumps of proven design, and such pumps of at least the same capacity
and type should be in operation for more than 5000 hours satisfactorily in at least two locations.
The Contractor shall confirm that the pumps of the same approved design and size shall be supplied
and tested satisfactorily.
One set of standard and special tools, centring tools, lifting lugs, pipe and shaft clamps, etc.,
required for erection and maintenance shall be supplied
If the overall arrangement requires any modifications, other than that provided for satisfactory
operation of the pumps, the same are to be carried out by the Contractor without any extra cost.
Unless otherwise specified the drive unit power rating shall be the maximum of the following
requirements:
A. Required margin/factor as given below over the pump shaft input power required at duty
point.
Pump shaft input power 15-75 KW - 1.20
Pump shaft input power>75 KW - 1.10
B. Pump shaft input power at maximum of below two conditions.
i. 115% of pump input power including losses in transmission shafting and thrust
bearing for duty parameters i.e. head and capacity.
ii. 105% of the maximum pump input power including losses in transmission shafting
and thrust bearing within the operating range between maximum and minimum
system resistance curves, considering multiple pumps operation.
C. Pump shaft input in the operating range corresponding to minimum and maximum water
level in the CWRs
The specifications for flanges shall be as per the relevant IS code.
Drawings and Information to be Provided by Contractor:-
General arrangement, cross-sectional drawing with materials of construction and dimensional
drawings with pump parameters
Performance curves with initial, intermediate and final impellers
(a) H - Q curves
(b) Shaft Power - Q curves
(c) Efficiency -Q curve
(d) NPSHR - Q curve
Hydraulics study report
General arrangement drawing of pumping plant
Pumps each with motors including all accessories.
Lubricating and cooling water system with all accessories.
The suction piping should be as short and straight as possible, any bend or elbows should be of long
radius. The diameter of suction pipe shall be designed considering the velocity of 1.5 m/s.
When a reducer is used at suction side, it should be of the eccentric type. When on suction-lift, the
taper side of the reducer should be below the centre line of the pump.
The suction strainer should have net open area, minimum equal to three times the area of the
suction pipe.
Discharge piping connection to a common manifold or header should be connected by a radial Tee
or by 30° and 45° bend.
A dismantling joint/ expansion bellow must be provided between the pump and the valves. The
design of the dismantling joint/ expansion bellow should be such that no pull or moment is
transmitted to the pump.
Each discharge pipe shall have electrically operated sluice valve / butterfly valve, dual plate check
valve, kinetic air valve and dismantling joints / expansion bellows.
Sufficient space should be available in the pump house to locate the pump, motor, valves, piping’s,
control panels and cable trays in a rational manner with easy access and with sufficient space
around each equipment for the maintained and repairs.
Space for control panel should be planned as per the Indian Electricity (I.E.) Rules.
A service bay should be provided in the station with such space that the largest equipment can be
accommodated there for overhauling and repair.
Foundation of pump set shall be as per guidelines of pump and motor manufacturers, operation &
maintenance requirement of pumping machinery.
Height of pump house shall be adequate to house the pump motor set, valves, pipe work and lifting
equipment with necessary operation clearance. Sufficient head room shall be provided above the
corbel up to bottom of slab of pump house considering the operation & maintenance of crane.
Required concrete support, anchor block & thrust block shall be constructed below the valves, bends
& tapers.
Suitable size concrete chamber shall be constructed to house the valves & flow meter.
Ventilation system for pump house and electrical room.
Fire extinguishers
The Pumping Station at hanumangarh road with 11kV sub-station is already constructed. The existing
substation is not adequate to cater entire load of proposed system (i.e. additional pumps). Hence, tapping
is taken from existing feeder and a tripping less substation shall be constructed for proposed scheme.
The new substation shall be capable for feeding the entire load of clear water pumping station with
adequate voltage and power quality.
Outdoor substation located in place of existing substation shall be provided for above loads contains RCC
framed structure shall be required for constructing new 11 kV switchyard and transformers. 11 kV overhead
lines to be terminated on a Ring main unit through suitable HV disconnections with earthing switch and all
metering and protection arrangements and Lightning arresters shall be provided on the incoming lines.
Incoming 11 KV supplies shall be step down by two nos. of transformers, which in turn shall feed the main
LV indoor switchboard shall be located in place of existing switch yard. 100% redundant transformers are
proposed to feed the entire load of the proposed pump system. The transformer neutral is to be earthed to
limit the earth fault current. The transformers (and the cables to the LV switchboard) shall be suitable for
outdoor application. The transformers, and the cables emanating from the secondary, shall be rated to
cater to the entire load including the future loads installed by the Employer, under a separate Contract.
Suitable provision shall however be made in the LV switchboards, under the present Contract, to cater to
this future connection. Also, spaces for the future LV switchboard extension etc. shall be provided in the
present scope of works.
Both transformers also have capability of supply power to the LV auxiliary loads, which includes loads such
as electrical valve actuators, control and instrumentation panels, EOT crane, LV auxiliary motors, Air
conditioning Load and indoor & outdoor lighting load.
Main LV switchboard located in place of existing LV switch board in PS shall receive power from the
transformers to feed the individual loads. Suitable space in the Pumping station shall be provided for future
expansion of main LV switchboards. Outgoing Feeders for VFD and motor starters, existing pumping
station, proposed pumping station shall be taken in main LV Switchboard. The LV switchboard contains two
main incomers, one DG incomer, and bus coupler with outgoing feeder for both VFD and motor starters of
motors.
LV capacitor banks with control panel consisting of automatic power factor correction (APFC) relay are to
be proposed across each LV bus section of each LV switchboard.
Necessary metering, protection and indication/ annunciation are to be provided on all the switchboards.
6.6.2.5 ELECTRICAL SYSTEM FOR PROPOSED SEWAGE PUMPING STATION
A new tripping-less reliable 11kV connection shall be taken for Proposed Sewerage Pumping Station. The
new substation shall be capable for feeding the entire load of proposed load of SPS (up to Stage-II
requirement) with adequate voltage and power quality.
Outdoor substation shall be located adjacent to Proposed Sewerage Pumping Station shall contains RCC
framed structure shall be required for constructing new 11 kV switchyard and transformers. 11 kV overhead
lines to be terminated on a Ring main unit through suitable HV disconnections with earthing switch and all
metering and protection arrangements and Lightning arresters shall be provided on the incoming lines.
Incoming 11 KV supplies shall be step down by two nos. of transformers, which in turn shall feed the main
LV indoor switchboard shall be located in place of existing switch yard. 100% redundant transformers are
proposed to feed the entire load of the proposed pump system. The transformer neutral is to be earthed to
limit the earth fault current. The transformers (and the cables to the LV switchboard) shall be suitable for
outdoor application. The transformers, and the cables emanating from the secondary, shall be rated to
cater to the entire load including the future loads installed by the Employer, under a separate Contract.
Suitable provision shall however be made in the LV switchboards, under the present Contract, to cater to
this future connection. Also, spaces for the future LV switchboard extension etc. shall be provided in the
present scope of works.
The transformers also have capability of supply power to the LV auxiliary loads of Proposed Sewage
Pumping Station, which includes loads such as electrical valve actuators, control and instrumentation
panels, EOT crane, LV auxiliary motors and indoor and outdoor lighting load.
Main LV switchboard shall be located in electrical room of Proposed Sewerage Pumping Station receive
power from the transformers to feed the individual loads. Suitable space in the Pumping station shall be
taken for future expansion of main LV switchboards. The proposed STP & SPS also have their individual
LV switchboard which contains two incomers and one DG incomer and outgoing feeders for STP & SPS
plant and all other remaining electrical equipments shall be as per CPHEEO manual.
LV capacitor banks with control panel consisting of automatic power factor correction (APFC) relay are to
be proposed across each LV bus section of each LV switchboard.
Necessary metering, protection and indication/ annunciation are to be provided on all the switchboards.
6.6.2.6 ELECTRICAL SYSTEM FOR PROPOSED SEWAGE TREATMENT PLANT
A new tripping-less reliable 11KV connection shall be taken for Proposed Sewerage Treatment Plant. The
new substation shall be capable for feeding the entire load of proposed STP (up to Stage-II requirement)
with adequate voltage and power quality.
Outdoor substation shall be located adjacent to Proposed Sewerage Treatment Plant shall contains RCC
framed structure shall be required for constructing new 11 kV switchyard and transformers. 11 kV overhead
lines to be terminated on a Ring main unit through suitable HV disconnections with earthing switch and all
metering and protection arrangements and Lightning arresters shall be provided on the incoming lines.
Incoming 11 KV supplies shall be step down by two nos. of transformers, which in turn shall feed the main
LV indoor switchboard shall be located in place of existing switch yard. 100% redundant transformers are
proposed to feed the entire load of the proposed pump system. The transformer neutral is to be earthed to
limit the earth fault current. The transformers (and the cables to the LV switchboard) shall be suitable for
outdoor application. The transformers, and the cables emanating from the secondary, shall be rated to
cater to the entire load including the future loads installed by the Employer, under a separate Contract.
Suitable provision shall however be made in the LV switchboards, under the present Contract, to cater to
this future connection. Also, spaces for the future LV switchboard extension etc. shall be provided in the
present scope of works.
The transformers also have capability of supply power to the LV auxiliary loads of Proposed Sewerage
Treatment Plant, which includes loads such as electrical valve actuators, control and instrumentation
panels, EOT crane, LV auxiliary motors and indoor and outdoor lighting load.
Main LV switchboard shall be located in electrical room of Proposed Sewerage Treatment Plant receive
power from the transformers to feed the individual loads. Suitable space in the STP shall be taken for future
expansion of main LV switchboards. The proposed STP & SPS also have their individual LV switchboard
which contains two incomers and one DG incomer and outgoing feeders for STP & SPS plant and all other
remaining electrical equipments shall be as per CPHEEO manual.
LV capacitor banks with control panel consisting of automatic power factor correction (APFC) relay are to
be proposed across each LV bus section of each LV switchboard.
Necessary metering, protection and indication/ annunciation are to be provided on all the switchboards.
6.6.2.7 PROPOSED AND EXISTING TUBE WELL
The works described under this contract are to be executed as per items listed in schedule of prices read in
conjunction with this scope of work and technical specifications. The works under this contract are broadly
divided under the following components:
Removal / unlowering of existing pump sets, their electrical panel and other appurtenances from ground
water sources including deposition of old material to Employer’s stores (Divisional stores) located in
Sardarshahar town.
Providing and installation/ lowering of new energy efficient pump set in each of sources, bulk flow meters
and pressure sensors for flow and pressure monitoring and SCADA operated Electrical and instrumentation
Control Panels. The existing useful lowering pipes, wire ropes and electrical cables shall be used.
Refurbishment of tube wells with provision of SCADA operated hydrostatic level sensors for monitoring of
ground water table.
Any deficiency shall be made good, and these shall be connected to SCADA Control Station.
Providing complete system metering, automation and SCADA for fail safe operation of system.
6.6.2.8 ELEVATED SERVICE RESERVOIRS
Suitable power supply shall be made available at each ESR and contractor shall develop necessary
infrastructure as per the requirement such as
1. Distribution Board/ Lighting Panel
2. LV cables
3. Lighting system
4. Cabling system
5. Earthing and lightning protection system
6.6.2.9 TRANSFORMER SIZE SELECTION CRITERIA
The transformer size shall be determined from the estimation of the simultaneous maximum demand based
on the power rating of motors and other loads and their operating / running periods.
The design shall be based on maximum nos. of main motors working for Stage -II and the corresponding
auxiliary loads shall be considered for sizing of transformer.
Table 4: Details of Transformer
Transformer
Location Remarks
Rating (KVA)
Clear water pumping station 630*
(*) The ratings given are tentative and bidding purpose only and values to be ascertained by the Contractor
after Submitting design calculations subject to approval
Appropriate values of load factor, diversity factor, power factor and efficiency shall be considered for each
type of load. Improvement in power factor due to capacitors shall not be considered. Ten percentage (10%)
contingency shall be added to the simultaneous maximum demand thus calculated and the next standard
size of transformer as per IEC shall be selected.
Two such transformers shall be provided for 100 % redundancy at each site. The design calculations for
transformer sizing shall be subject to the approval of the Employer’s Representative. The transformer size
shall be selected in such a way that it should work at maximum efficiency.
6.6.2.10 DG SIZE SELECTION CRITERIA
The DG size shall be determined from the estimation of the simultaneous maximum demand based on the
power rating of motors and other loads and their operating / running periods.
The design shall be based on main motors working for Stage -II and the corresponding auxiliary loads shall
be considered for sizing of DG.
Table 5: Details of DG
DG Rating
Location Remarks
(KVA)
Clear water pumping station 630*
(*) The ratings given are tentative and bidding purpose only and values to be ascertained by the Contractor
after Submitting design calculations subject to approval
One DG set shall be provided for 100 % Load at each location. The design calculations for DG sizing shall
be subject to the approval of the Employer’s Representative.
6.6.2.11 SOLAR PANEL TECHNICAL SPECIFICATION
A Grid Tied Solar Rooftop Photo Voltaic (SPV) power plant consists of SPV array, Module Mounting
Structure, Power Conditioning Unit (PCU) consisting of Maximum Power Point Tracker (MPPT), Net Meter,
Inverter, and Controls & Protections, interconnect cables and switches. PV Array is mounted on a suitable
structure. Grid tied SPV system is without battery and should be designed with necessary features to
supplement the grid power during day time. Components and parts used in the SPV power plants including
the PV modules, metallic structures, cables, junction box, switches, PCUs etc., should confirm to the BIS or
IEC or international specifications, wherever such specifications are available and applicable.
Solar PV system shall be installed on following location in given approximate area.
Table 6: Location of solar panel
APPROX. AREA CAPACITY
S.No. LOCATION
(Sqm.) (KW)
(*)The area given above for various location is tentative and bidding purpose only. These values shall be as
per approved GA drawings considering the 80% of rooftop available area.
(**)Values to be ascertained by the Contractor after Submitting design calculations subject to approval.
This section outlines the particular requirements for the instrumentation, automation and control systems.
Unless specified in this section to the contrary instrumentation Plant provided by the Contractor and
workmanship shall comply with the General Instrumentation, Automation and Control Requirement
Chapters of these Requirements.
6.6.4.2 THE SCOPE AND BATTERY LIMITS
The scope of instrumentation, control and automation (ICA) works for Town shall comprise the design,
manufacture, programming and configuration, off site testing, delivery to site, installation and erection,
testing, commissioning, setting to work and provision of documentation for a complete supervisory,
instrumentation, control and automation system including the interfaces required to provide monitoring and
control for a safe and efficient operation of plant, equipment and system.
The Contractor shall submit and obtain approval of the instruments and the system from the employer
before beginning the detailed control system design.
At the time of bid submission, the contractor shall submit the completed technical schedule of the proposed
instruments as per the technical schedule. All relevant manuals should be attached. Failure to adhere to
the above would be treated as a non-responsive bid. The contractor should take note of the importance of
this obligation
6.6.4.3 WATER SUPPLY NETWORK
MASTER CONTROL CENTRE (MCC) at AEN Campus
Design, supply, install, test and commission a dual redundant control system. PLC, RTU & SCADA shall
include but not limited to process controller including its central process units (CPUs), communication
modules, input-output (I/O) modules, control networks, operator workstations, engineering workstation &
server with 32” LED display. 60” LED display for monitoring of entire water supply system and A4 & A3
colour printers for printing reports and trends. The MCC shall be designed to monitor & control entire water
supply network and waste water network of the town. Proposed and Existing Tube well have SCADA
compatibility and interfaced to the secondary control centre as well master control centre.
SECONDARY CONTROL CENTRE (SCC) at Pumping Stations
Design, supply, install, test and commission of Instrumentation, dual redundant control system. PLC, RTU
& SCADA shall include but not limited to process controller including its central process units (CPUs),
communication modules, input-output (I/O) modules, control networks, sever, operator workstation,
engineering workstation with 32” LED display and A4 & A3 printers for printing reports and trends. The
SCC shall be provided for the each of the below mentioned components of the project and shall be
designed to efficiently control, operate & monitor the following
- Treated Water reservoirs and Pumping stations
INSTRUMENTATION SYSTEM FOR THE OHSRs AND DMA’s
Supply, installation, testing commissioning of flow meters, level transmitters, pressure transmitters, RTU’s
along with GPRS modems at ESR’s, OHSR’s GSR’s and DMAs to transmit flow, level, pressure and
actuated valve position data to Master Control Centre for monitoring and control. The item also includes
Supply, laying, termination of instrumentation cables complete with all accessories like lugs, glands, etc.
Supply, installation of perforated GI cables trays complete with all accessories like bends, joints and T-
sections, etc. and any other Item required to complete the above Instrumentation system.
The monitoring and control of all the DMAs in the Water Supply system shall be at the Master Control
Centre, for this purpose Bulk flow meters and pressure transmitters at strategic locations in the DMAs shall
be provided along with RTU’s, GPRS modem and shall be interfaced with the Master Control Centre. The
pressure transmitters at strategic locations in the DMAs shall be self-powered with built-in battery and
GPRS modem. The selection of self-powered RTUs for pressure transmitters shall be capable of
transmitting instantaneous pressure data to the master control centre for monitoring and control.
The flow meters at the outlet of ESRs, direct pumping mains and at the DMA entry point shall be selected
to measure the entire regime of flow viz. peak flow to lean flow to satisfy the NRW requirements and
transmitted to the Master Control Centre.
The instrumentation provided at the DMAs shall be capable to measure and record reverse flow and un-
common flow shall be alarmed at the Master Control Centre.
6.6.4.4 SEWAGE TREATMENT PLANT AND PUMPING STATIONS
MAIN CONTROL CENTRE (MCC) at Sewage Treatment Plant
Design, supply, install, test and commission a dual redundant control system. PLC Panel with 15’’ HMI,
RTU & SCADA shall include but not limited to process controller including its central process units (CPUs),
communication modules, input-output (I/O) modules, control networks, operator workstation and
engineering workstation with 32” LED display and A4 & A3 printers for printing reports and trends. Main
Control Centre shall be interfaced with Master Control Centre of water supply network through GPRS
modules. A common PLC & SCADA system shall be provided for the entire STP. The monitoring of levels
in the manholes at strategic location shall be done at secondary control centre as well as master control
centre at STP. For this purpose level transmitter along with RTU, GPRS, GSM based modem, UPS, Power
supply system shall be provided and interfaced to the master control panel and hand held device.
SECONDARY CONTROL CENTRE (SCC)
Design, supply, install, test and commission of Instrumentation, dual redundant PLC based control system.
PLC, shall include but not limited to process controller including its central process units (CPUs),
communication modules, input-output (I/O) modules, PLC – cum Instrumentation control panel shall be
provided with 15” HMI for operation of pumping station and display flow and level.
FIELD INSTRUMENTATION
Design, supply, install, test and commission field instrumentation for the Entire Water supply system
including Clear Water Pumping Stations and sewage treatment plant.
INSTRUMENTATION SCHEDULE
A listing of the basic instrumentation and control system to be supplied, installed, tested and commissioned
under this package shall include, but not be limited to, the list given in Table below.
Table 8: Instrumentation Schedule
Service Type of Instrument Instrument Function
I. Flow Measurement
i Flow measurement of Electromagnetic flow meter – full Transmission, Indication and
waste water bore recording of flow rates and
totalisation of flow.
ii Clear water from CWPS Electromagnetic flow meter – full Transmission, Indication and
bore recording of flow rates and
totalisation of flow.
iii Bulk water Flow Bulk flow meter with Pulsed Transmission, Indication and
measurement at all retransmission output/GPRS recording of flow rates and
DMA’s. totalisation of flow.
II. Level Measurement
i Water level in clear water Ultrasonic level measurement Monitoring of water level,
sump continuous measurement
trending of data and initiation of
alarms
Conductivity type level switches Tripping of pumps at low water
for high and low level detection level and generating an alarm
ii Level in OHSR, CWR’s, Ultrasonic level measurement Monitoring of water level
and CWR continuous measurement
trending of data and intimation
of alarm
Conductivity type of level Tripping of pump at high water
switches for high and low level level and starting at low level,
detection and generating alarms
III Pressure Measurement
i Pressure in all the Pressure measurement system Pressure transmission,
pumping mains of TWs consisting of a pressure monitoring and generating an
transmitter and panel mounted alarm
indicator system
ii Pressure in all the Pressure measurement system Pressure transmission,
pumping mains of consisting of a pressure monitoring and generating an
CWPSs transmitter and panel mounted alarm
indicator system
iii Pressure in all the Pressure measurement system Pressure transmission,
delivery piping of OHSRs consisting of a pressure monitoring and generating an
and GLSRs transmitter and panel mounted alarm
COMMUNICATION NETWORK
Interface equipment to enable communication between water supply system field instruments, PLC’s,
RTU’s, SCC at CWPS, RTU’s at DMA’s and Master Control Centre at Office Campus.
Supply, installation, testing commissioning of RTU’s along with GPRS at ESR’s, OHSR’s GSR’s and DMAs
to transmit flow, level, pressure and actuated valve position data to Master Control Centre for monitoring
and control.
A minimum 60” LED screen with necessary CPU shall provide an elementary full colour pictorial flow
diagram display of the water supply scheme including pumping stations DMAs. The mimic shall also
include displays of process values e.g. reservoir levels, process flows, water quality etc. Mounting of LED
mimic panel shall be as approved by employer’s representative.
The communication equipment required to achieve this interfacing complete with all required accessories
shall be supplied, installed, tested and commissioned under this contract.
DATA ACQUISITION AND PROCESSING
The data acquisition, processing and interfacing with the Master Control Centre of entire water supply
scheme of Town is covered under this package. The domestic water meters data shall be collected
manually and this data shall be fed into the Master Control SCADA system for records and further
analytical purposes.
SYSTEM CONSOLE
Control room furniture(system console) include but not limited to control console for placing dual redundant
workstations and two printer compartments, desk for one engineering workstation, ODMS workstation and
printer compartment and chairs .The system console design shall be submitted to the Employer for prior
approval.
The Contractor shall be responsible for the design of each instrumentation and plant monitoring system,
including the selection and design of appropriate transducers (on approval by the Employer’s
representative), transmitters, signal conditioning devices, indicators, alarm system programmable devices,
communications, cable system etc. The Contractor shall take account in his design of all installation and
environmental conditions prevailing at the site.
6.6.5 DESIGN CRITERIA FOR INSTRUMENTATION, CONTROL, AUTOMATION AND SCADA
SYSTEMS
6.6.5.1 INSTRUMENTATION SYSTEM
a) Electronic instruments shall utilize solid state electronic components, integrated circuits,
microprocessors, etc., and shall be of proven design.
b) all instruments shall be suitable for continuous operation;
c) all digital outputs shall be volt free;
d) all instrumentation systems for use out of doors shall be protected to IP 65 for sensors and
transmitters, while enclosures under submersible conditions shall be protected to IP68;
e) all analogue displays shall be of the digital type with no moving parts utilizing back lit liquid
crystal diode technology;
f) For transmitting instruments, output signal shall be 4-20 mA DC linear having two wire system
g) Unless otherwise stated, overall accuracy of all measurement systems shall be ±0.5% of
measured value, and repeatability shall be ±0.5%.
h) After a power failure, when power supply resumes, the instruments and associated equipment
shall start working automatically.
i) The instruments shall be designed to permit maximum inter changeability of parts and ease of
access during inspection and maintenance.
j) The instruments shall be designed to work at extremes of the ambient conditions of
temperature, humidity, and chlorine contamination that may prevail. The instruments shall be
given enough protection against corrosion.
k) Lockable enclosure shall be provided for the field mounted instruments wherever required.
l) All field instruments, and cabinets / panel-mounted instruments shall have tag plates / name
plates permanently attached to them.
m) The performance of all instruments shall be unaffected for the ±10% variation in power supply
voltage and ±5% variation in frequency simultaneously.
n) All wetted parts of sensors shall be made out of non-corrosive material capable of working
with chlorine content of 5 ppm.
o) For all instruments (transmitting analogue signals) installed in the field, surge protection
devices (SPDs) shall be provided at both ends of the connecting cable for the protection
against static discharges / lightning and electromagnetic interference.
p) Pressure transmitters shall be provided with two valve manifold and a test port, so that in situ
calibration can be carried out.
q) Two wire transmitters shall be provided with on-line test terminals.
r) The ranges of all instruments shall be suitable for the application in the process.
s) Instruments of similar type shall be of same make for appropriate inventory of spares, ease of
maintenance and training.
t) The Indian agents of imported equipment shall have establishment to provide after sales
maintenance facilities.
6.6.5.2 PLC SYSTEM
PLC shall be provided as a Hot-Standby configuration to perform combinational and sequential logic
functions, status monitoring and reporting functions with counter and timer facilities.
PLC Panel interrogation power supply should be fully redundant.
PLC shall comprise of necessary processors, input/output (I/O) modules, communication interface modules
and human-machine interface (HMI) required performing the desired functions. Each PLC shall have
memory protected built in historical archiving/data logging of system alarms & events and process
variables. Data logger shall be able to log data based on time or an event PLC shall have enough memory
allocated to allow 200,000 time and data stamped discrete and /or analog values to be archived. The
historical archive shall allow the oldest data to roll off the system as memory is used keeping the 200,000
most current data points available. Process point time stamping frequency shall be selectable within the
configuration software. It shall be possible for the archived data to be exported in CSV format allowing use
with standard spreadsheet and data software applications
PLC shall have the following attributes as a Hot-Standby configuration.
- carry out sequential logic implementation for operations of plant;
- carry out computation and interfacing for data acquisition, data storage and retrieval;
- it shall accept downloaded program from a programmer;
- it shall have different functional modules to perform the desired functions;
- it shall scan the inputs in time cycles and update the status of its outputs.
6.6.5.3 RTU SYSTEM
RTU shall be designed in accordance with this specification. The RTU shall be of proven design and suited
for water supply and distribution SCADA applications.
RTU design should aim to minimize power consumption and heat generation. It should be designed to work
in remote installation by being of robust physical construction with immunity to electrical noise.
The RTU shall be assembled from modular units, for example, power supply module, CPU and
communications module, communication interface modules and modules for input/output purposes. I/O and
serial cards shall be able to be arranged in the RTU rack in any order.
Modules shall be interconnected via a suitably robust plug and socket method. It shall not be necessary to
unscrew individual wires/cables, both internal RTU wiring and I/O wiring, to replace faulty modules. The
failure of one module will not affect the performance of any other module.
A marshalling terminal area shall be incorporated with each RTU to provide terminations for field cables.
This area can be located in the RTU cubicle itself for an RTU replacement but for new locations
there should be a separate marshalling cubicle. The RTU and marshalling cubicles shall normally be bolted
together to form a 2-bay cubicle suite. A separation plate may be located between the cubicles.
The RTU and the cubicles shall be designed to accommodate the actual number of input/outputs, plus
spare capacity.
Power connection required for RTU’s at remote location other than pumping station and treatment plant will
be provided by the employer. However the required application and Liaison with the concerned authorities
shall be under the scope of the contract.
6.6.5.4 SCADA SYSTEM
The SCADA shall be a fully dual redundant server integrated microprocessor based control and data
acquisition system which shall monitor, control, display, record and trend all assigned plant and water
supply network inputs and outputs. The main process monitoring and control shall be by means of Visual
Display Unit (min. 60 inch. LED monitor) based process operator workstations that shall be located in the
central control room.
SCADA/HMI system shall be Dual Redundant server system. SCADA/HMI system shall be designed and
implemented such that the failure of a central processor or HMI console does not inhibit continuous
automatic control of the plant. In the event of such a failure, historical data shall be recoverable to a
condition where a worst-case maximum of 15 minutes of historical data is lost. The SCADA shall be
integrated with the geographical information system (GIS) for the distribution network.
Failure of a single outstation or communications to that outstation shall not affect control or operation of any
other outstation, unless the failed outstation provides essential data to another outstation, in which case the
non-failed outstations shall revert to a fail-safe mode.
6.6.5.5 FUNCTIONAL DESIGN SPECIFICATION (FDS, SEQUENCE OF OPERATION)
The Contractor shall propose the details the sequence of operation for the water supply system and
pumping stations through careful study of the water supply scheme proposed. Further, the contractor shall
be solely responsible to comply with any change/additional processes during the contractors design stages.
The Contractor shall submit a complete functional design specification (FDS) for approval by the Employer
within 3 months of the award of the contract.
Functional design specification (FDS) for the SCADA system shall be combined with the FDS for
instrumentation, control and automation to form a complete document and shall comply with the
specification of the FDS for instrumentation, control and automation. This document shall serve as the
primary mechanism by which the Employer may confirm that the Contractor possesses an accurate
understanding of the system and its control requirements. The Contractor is encouraged to obtain any
necessary clarifications and to suggest refinements to the control descriptions contained in this
Specification.
The FDS shall include a detailed block diagram of the PLC, RTU& SCADA system with a description of the
communications scheme to be provided. The FDS shall include operational details of the SCADA system
which have an effect on plant operations, such as power failure response, communication failure response,
and automatic shut-down and start-up of the system.
The FDS shall include a description of the interface of the SCADA system with any existing or planned
future DAC (Digital Access Carrier) equipment.
The Contractor shall submit a preliminary FDS and obtain approval before the system architecture design
is finalized or detailed design takes place. The Contractor shall formally notify the Employer for approval of
any amendments or additions to the approved FDS. The final FDS shall be submitted for approval before
submission of the factory acceptance test definition documents. The Contractor should take note of the
importance of this obligation.
The FDS shall comprise an overall description of the system, its functioning and control, and a detailed
description of each section of the control system covering modes of operation, manual overrides, set-point
and parameter selection and adjustment. The detailed description shall include a step-by-step control
description which defines the function of each piece of equipment and each control action and interlock,
including details of the program in each programmable item.
The FDS shall describe the ‘fail-safe’ features incorporated into the design for the event of failure of a plant
item or system, or loss of an input signal affecting a control loop or process sequence.
The FDS shall describe control actions taken and monitoring functions which remain available during a
power failure, and any automatic controls or sequencing which take place during system start-up and shut-
down.
The FDS shall be presented in a clear and precise manner and shall include figures or drawings where
appropriate.
6.6.5.6 POWER SUPPLY
The control system shall be powered from a number of uninterruptible power supplies (UPSs). These shall
be sized to provide sufficient power to maintain the control system functioning for a period of not less than
two hours.
The UPS for use with each Control Panel may be free standing or integral with the Control Panel and shall
derive their primary power from the Control Panel.
The status of each UPS shall be monitored and alarmed via the control system for any fault condition
including the UPS battery supply is about to expire.
6.6.5.7 VOLTAGES
The following control voltages shall be used:
Table 9: Instrumentation Voltage Required
Item Voltage
1. within starter enclosures 240 V AC
2. instrumentation power supplies 240 V AC / 24 V DC
3. PLC inputs cards 24 V DC
4. PLC outputs 24 V DC
System should provide inter-operability of hardware, OS, software, networking, printing, database
connectivity, reporting, and communication protocols. System expansion shall be possible through off-the-
shelf available hardware.
6.6.9 REFERENCE STANDARDS
Unless otherwise approved, instrumentation shall comply with relevant quality standards test procedures
and codes of practice collectively referred to as Reference Standards including those listed in General
Instrumentation, Automation and Control System in accordance with the requirements detailed elsewhere
in this specification.
Transmission/
Rising Mains
TW/OWs
Rising Mains
SV- Sluice Valve, BFV- Butterfly Valve, DPCV- Dual Plate Check Valve, EB- SS Expansion Bellows, DJ- Dismantling Joint,
EMF-Electro-magnetic Flow meter & BFM-Bulk Flow Meter, PT- Pressure Transmitter, RTU - Remote Terminal Unit
*where there are more than one OHSR/GLSR on single pumping main with branches. Above table is for the understanding of the Mechanical and instrumentation
schedule.
52 SRD/01/WS/47 Piping & Instrumentation Diagram for Clear Water Pump House
Typical Drawings-WS
Typical Drawings-WW
1. The following list is not exhaustive but shows some of the main reports that are available as part of
the electronic data room (EDR) set up in RUIDP. Bidders can obtain the information by seeking the
necessary permission from the Addl. Project Director ([email protected]).
a) Detailed Project Report for Sardarshahar Water Supply Works
b) Detailed Project Report for Sardarshahar Sewerage system
2. The following studies/surveys are also available as separate reports:
a) Topographical Survey Report;
b) Geotechnical Investigation Report;
Package No.- RSTDIP/SRD/01
6.10 Personnel Requirements
Using Form PER-1 and PER-2 in Section 4 (Bidding Forms), the Bidder must demonstrate it has personnel that meet the
following requirements:
Experience
Total Work Deductable
In Similar
S. No. Position Requirement Experience per month if
Work
[years] not provided
[years]
Experience
Total Work Deductable
In Similar
S. No. Position Requirement Experience per month if
Work
[years] not provided
[years]
In field office on
regular basis since
12 Water and waste water quality analyst 5 years 2 years 20,000
Commencement of
operation services
Note:
1. Personnel will be mobilized as per agreed key personnel mobilization schedule. Above proposed
recovery/deductions will be applicable if personnel are not mobilized as per agreed personnel schedule.
2. Design and field team shall be always available for any discussion or meeting at the Employer /Project
Management Consultant office whenever called.
3. For the position of Construction Supervision and Operation-Maintenance 30 % the staff should be preferably be
the Female candidates,
4. The position of Customer manager, Water and Waste Water Analyst, GIS Analyst and Utility Finance should
be reserved for the women,
5. In addition to this, in Social Outreach team to be deployed at the time of construction, preference should be
given to female candidates and 50% reservation for the female candidates should be ensured. Preference
should be given to the person having permanent residence in the same project town.
6. Similarly, during operation and maintenance phase for the reading of the consumer meters, distribution of the
bills, collection of the revenues and in GRC, CRMC/CCC, there should be preference for the female
candidates.
Package No.- RSTDIP/SRD/01
Using Form EQU in Section 4 (Bidding Forms), the Bidder must demonstrate it has the key equipment listed
below:
Deductable per
Min.
month if not
No. Equipment Type and Characteristics Number
mobilized/ not
Required
found in working
1 Excavator 4 1,00,000
2 Concrete batch mix plant 1 10,00,000
3 Transit mixers 4 1,00,000
19 Crane 2 1,00,000
20 Trenchless Equipment 2 1,00,000
21 Road Roller(Vibratory) 2 30,000
22 Sheep foot roller(mechanized) 3 30,000
23 Water Meter Test Bench 2 15,000
Note: Equipment will be mobilized as per agreed equipment mobilization schedule. Above proposed
recovery/deductions will be applicable if equipment are not mobilized as per agreed mobilization schedule.
Amount of Damages due to non-mobilization of Personnel & Equipment shall be in addition to the
maximum amount of delay damages i.e. 10% of accepted contract amount as per clause 9.6 “Maximum
delay damages” Section-8: Particular condition of contract.
Annx. A (Draft IEE)
Contract Package: RSTDIP/SRD/01
Draft Initial Environmental Examination
February 2019
C Degree Celsius
km kilometre
lpcd litres per capita per day
mm milli meter
m metre
MLD million litres per day
mm millimetre
Nos Numbers
Sq.km Square Kilometer
This initial environmental examination is a document of the borrower. The views expressed
herein do not necessarily represent those of ADB's Board of Directors, Management, or staff,
and may be preliminary in nature.
In preparing any country program or strategy, financing any project, or by making any
designation of or reference to a particular territory or geographic area in this document, the
Asian Development Bank does not intend to make any judgments as to the legal or other status
of any territory or area.
Contents
Executive Summary ....................................................................................................................................... 7
I INTRODUCTION ......................................................................................................................................... 11
Background ................................................................................................ Error! Bookmark not defined.
Background of IEE ................................................................................................................................... 11
Scope of IEE ............................................................................................................................................. 12
Report Structure ..................................................................................................................................... 13
II DESCRIPTION OF PROJECT ....................................................................................................................... 14
Existing Conditions .................................................................................................................................. 26
Need of the Project ................................................................................................................................. 28
Infrastructure Improvements Proposed ................................................................................................. 29
Water Supply ........................................................................................................................................... 29
Sewerage .................................................................................................... Error! Bookmark not defined.
Energy Efficiency Measures included in the subproject ......................................................................... 35
Investment Program Implementation Schedule ..................................................................................... 36
III POLICY, LEGAL AND ADMINISTRATIVE FRAMEWORKS ........................................................................... 14
Environmental Regulatory Compliance .................................................................................................. 14
ADB Safeguard Policy ......................................................................................................................... 14
IV DESCRIPTION OF ENVIRONMENT ........................................................................................................... 48
A Physical Resources .......................................................................................................................... 48
Location, Area & Connectivity ........................................................................................................ 48
Topography, Soils and Geology ..................................................................................................... 49
Seismology ........................................................................................................................................ 50
Climatic Conditions .......................................................................................................................... 50
Surface Water ................................................................................................................................... 50
Groundwater ..................................................................................................................................... 51
Air Quality .......................................................................................................................................... 52
B Ecological Resources ....................................................................................................................... 52
C Economic Development .................................................................................................................. 53
Land use ............................................................................................................................................ 53
Industry & Agriculture ...................................................................................................................... 53
Infrastructure ..................................................................................................................................... 54
D Socio Cultural Resources ................................................................................................................. 56
Demography ...................................................................................................................................... 56
History, Culture and Tourism .......................................................................................................... 56
E Environmental Settings of Investment Program Component Sites ................................................ 57
V ANTICIPATED ENVIRONMENTAL IMPACTS AND MITIGATION MEASURES .............................................. 58
Introduction ............................................................................................................................................ 58
Location Impacts ..................................................................................................................................... 59
Design Impacts ........................................................................................................................................ 60
Pre‐construction Impacts ........................................................................................................................ 63
Construction Impacts .............................................................................................................................. 64
Operation and Maintenance Impacts ..................................................................................................... 76
VI PUBLIC CONSULTATION AND INFORMATION DISCLOSURE .................................................................... 79
Overview ................................................................................................................................................. 79
Public Consultation ................................................................................................................................. 79
1. Consultation during Project Preparation ....................................................................................... 80
2. Consultation During Construction ................................................................................................. 80
A. Information Disclosure ..................................................................................................................... 81
VII GRIEVANCE REDRESS MECHANISM ....................................................................................................... 82
B. Project Specific Grievance Redress Mechanism ........................................................................ 82
C. Grievance Redress Process ....................................................................................................... 82
VIII ENVIRONMENTAL MANAGEMENT PLAN .............................................................................................. 85
A. Environmental Management Plan .................................................................................................. 85
B. Institutional Requirements ............................................................................................................ 113
C. Training Needs ........................................................................................................................... 119
D. Monitoring and Reporting .......................................................................................................... 121
E. EMP Implementation Cost ............................................................................................................ 121
IX CONCLUSION AND RECOMMENDATION .............................................................................................. 125
Appendix 1: REA Check list .............................................................................................................. 128
Appendix 2: National Ambient Air Quality Standards (2009) ....................................................... 137
Appendix 2A: Emission limits for New DG sets up to 800 KW .................................................... 138
Appendix 2B: Stake Height Requirement of DG sets ................................................................... 138
Appendix 3: National Ambient Air Quality Standards in Respect of Noise................................ 139
Appendix 3A: Noise Limits for DG Set ............................................................................................ 140
Appendix 4 A: Effluent Discharge Standards for Sewage Treatment Plant by MOEF & CC . 142
Appendix-4B ........................................................................................................................................ 144
Pages from Rajasthan State Sewerage and Waste Water Policy for reuse of treated effluent
and sludge ........................................................................................................................................... 144
Appendix 5: Vehicle Exhaust Emission Norms .............................................................................. 148
Appendix 6: Drinking Water Standards (as per CPHEEO) .......................................................... 149
Appendix 7:Compliance with Environmental Criteria for Subproject Selection ........................ 151
Appendix 8: Salient Features of Major Labor Laws Applicable to Establishments Engaged in
Construction of Civil Works ............................................................................................................... 154
Appendix 9 : Sample Outline Spoil Management Plan................................................................. 158
Appendix 10: Sample Outline Traffic Management Plan ............................................................. 159
Appendix 11: Stakeholders Consultations Conducted During Project Preparation ............................. 169
Appendix 12:Sample Six Monthly Reporting Format ............................................................................ 187
Appendix12: Sample Environmental Site Inspection Report ................................................................ 192
Appendix 13: Sample Grievance Registration Form ............................................................................. 195
Appendix 14: Management Plan for Night works at Project Sites .............................................. 197
Appendix 15: Photographs of Proposed Component Locations and Existing components ... 199
Appendix 16: Environmental Monitoring Plan - Ambient Air, Noise, Water and Soil ............... 200
Appendix 17 ........................................................................................................................................ 203
Guidelines for Reuse of Treated Effluent and Sludge from STP for Beneficial Purposes ...... 203
Appendix 18 ........................................................................................................................................ 208
Guidelines for Safety during Monsoon/Heavy rainfall................................................................... 208
Appendix 19: Letter of Water Allocation for proposed Water Supply Works ............................ 210
Appendix 20: Environmental Audit Report of Existing STPs in Sardarshahar .......................... 211
Appendix 21: AUDIT REPORT OF EXISTING WATER SUPPLY SYSTEM ............................ 216
5.1. Existing System of intermediate Pumping station at Sadasar & Pallu: ..................................... 216
5.2. Existing pump house for distribution system in Sardarsahar ................................................... 218
5.3. Existing storage reservoirs‐STRUCTURAL (OHSR & GLSR) ........................................................ 222
5.4. Status of existing Transmission main : ...................................................................................... 230
5.5 Status of Existing Distribution main : .............................................................................................. 231
Appendix 22: Details of land availability, ownership and NOCs for sites .................................. 236
Executive Summary
2. Sardarshahar town water supply and sewerage subproject is one of the subprojects
proposed under the investment component of Phase IV of RUIDP. Recently, under UIDSSMT
project; two STPs and 4 SPSs based on WSP technology has been constructed in the town
and core area of town is covered by sewerage networks and house connection is under
progress by Municipal Council, but entire sewerage system is not operational. Therefore, most
of the residential, commercial buildings and educational institutions are still dependent on septic
tanks and soak pits. The effluent from the septic tanks directly drain into the open drains. This
drainage is pumped to discharge in the outskirt low lying areas of the town. Therefore sewerage
system proposed in the town along with existing sewerage system, will enhance environmental
and sanitation conditions of the town and increase liveability conditions of residents.
3. Present source of water for Sardarshahar town is both Groundwater as well as surface
water. There are 45 tube wells/open wells within the town. Total water produced from these
TW’s is directly boosted to distribution system. Existing source of surface water for
Sardarshahar Town is Sawarsat minor Canal of IGNP (Indira Gandhi Nahar Pariyojana).
Presently water is supplied to consumers on daily basis for 2-4 hours. Gross water supply rate
is around 100 litres per capita per day (LPCD) but water received at consumer end is about 80-
85 LPCD only, which is less than standard of 135 LPCD. This is due to heavy losses reported in
the existing distribution network (about 40-45%). As the distribution mains consists of about
92% of uPVC pipes laid almost 15 years ago, frequent bursting, leaking occurs, which leads to
high percentage of NRW. The water distribution network is old, profusely leaking and is badly in
need of rehabilitation and replacement. Proposed water supply in the town will increase the
supply rate to consumer up to CPHEEO standard rate and will reduce NRW in the town.
1
Abu Road, Badi, Balotra, Barmer, Banswara, Chomu, Dausa, Didwana ,Fatehpur, Jaisalmer, Jalore,
Jhalawar, Karauli, Kuchaman, Ladnu, Laxmangarh, Makrana, Nimbeheda, Nokha, Pratapgarh, Rajgarh, Rajsamand,
Ratangarh, SardarShahar, Sri Dungargarh, Suratgarh, Shahpura (Bhilwara), Shahpura (Jaipur), Sirohi, Tijara and
Heritage towns - Bandikui, Deeg, Dungarpur, Jobner, Khetri, Kama, Mandawa, Nawalgarh, Pillibanga, Sambhar-
Phulera and Tijara
4. ADB requires consideration of environmental issues in all aspects of the Bank’s
operations, and the requirements for Environmental Assessment are described in ADB’s SPS
(2009). This Initial Environmental Examination (IEE) addresses the infrastructure components
proposed under Sardarshahar water supply and sewerage subproject.
6. Project Scope. The subproject is formulated to address gaps in water supply and
sewerage infrastructure in a holistic and integrated manner. The main objective of the RUIDP
Phase-IV is to (i) provide improved water supply in the town so that adequate drinking water in
terms of quality and quantity may be available to residents. (ii) safe sewage collection, treatment
and disposal. With the on-going investments in water supply and sewage treatment, this will
have an important effect on public health and environment. Investments under this subproject
includes
a) Sewerage- (i) Construction of 3 STPs of 7.30 MLD, 5.40 MLD and 1.60 MLD
capacities with Treated Effluent Elevated Reservoir (TEER), Treated Effluent Storage Reservoir
(TESR), Effluent Pumping Station (EPS) for reuse of treated effluent (ii) 2 nos. of SPSs (0.65
MLD and 2.30 MLD capacity) (iii) Rising main- 2.1 Km (800 mt. For SPS-8 of 250 mm DI K9
pipes and 1300 mt. For SPS 6 of 350 mm DI K9 pipes) (iv) Sewer network of 68.02 km
including 12.00 Km trenchless laying (v) Electrical and Mechanical works (vi) house sewer
connections- during design build period- 5600 and during O&M period- 2000, total 7800 nos.
b) Water Supply-(i) Construction of new CWR of 2400 KL and Clear Water Pump House
at Hanumangarh Road H/w, (ii) Rehabilitation of OHSRs at Bairudan, Holidhora, Suryamandir,
& Ramnagar, (iii) Rehabilitation of CWR of 4100 KL and Clear Water Pump House at
Hanumangarh Road Headworks (iv) laying of Rising Main- 30 km of DI K9 pipes of 100-300
mm dia, (v) water supply pipe for distribution networks- 430 Kms of different diameters and pipe
materials (vi) Construction of Consumer Relation and Management Centre- 1 no., Central
Control Centre- 1 no. and Master Control Centre- 1 no (vii) Consumer Connections- during
design build period- 22000 and during O&M period- 3000i.e. total 25000 nos.
10. Locations and siting of the proposed infrastructures were considered to further reduce
impacts. These include (i) locating facilities on government-owned land to avoid the need for
land acquisition and relocation of people; and (ii) laying of pipes in RoW alongside main/access
roads, to reduce acquisition of land and impacts on livelihoods specifically in densely populated
areas of the town.
11. Potential impacts were identified in relation to location, design, construction and
operation of the improved infrastructure. During the construction phase, impacts mainly arise
from the need to dispose of moderate quantities of waste soil and disturbance of residents and
traffic. These are common temporary impacts of construction in urban areas, and there are well
developed methods for their mitigation. Mitigation measures have been developed to reduce all
negative impacts to acceptable levels. Resettlement Plan (RP) is prepared separately for the
Sardarshahar water supply and sewerage subproject which addresses issues of temporary
impacts on livelihood resulting mainly from laying of water and sewer pipelines in the proposed
areas of town.
12. Measures such as appropriate scheduling of works (non-monsoon season, low traffic
hours, etc.) and minimizing inconvenience by best construction methods will be employed like
trenchless pipe laying for sewer for the depth of more than 3.5 mtr and in areas where traffic is
more. Traffic management plan will be prepared by contractor before start of construction works
for pipe/sewer-laying works on busy roads. In the operational phase, all facilities and
infrastructure will operate with routine maintenance, which should not affect the environment.
Facilities will need to be repaired from time to time, but environmental impacts will be much less
than those of the construction period as the work will be infrequent, affecting small areas only.
13. Mitigation measures have been developed to reduce all negative impacts to acceptable
levels. Mitigation will be assured by a program of environmental monitoring to be conducted
during construction. The environmental monitoring program will ensure that all measures are
implemented, and will determine whether the environment is protected as intended. It will
include observations on- and off-site, document checks, and interviews with workers and
beneficiaries. Any requirements for corrective action will be reported to the ADB.
14. The details of cost estimate (budgetary provision) for mitigating the anticipated impacts
by proposed subproject component is approximately INR 486,18,839/- (Four Crore Eighty Six
Lakhs Eighteen Thousand Eight Hundred Thirty Nine Only) for effective implementation of
the EMP Plan.
15. The citizens of the Sardarshahar will be the major beneficiaries of this subproject. With
the improved sewerage system will remove the human waste from their homes safely and
quickly. Improved water supply will help in reducing the time and cost of citizens in collection of
drinking water and better quality water will be available to them improving their health due to
poor quality drinking water. This subproject, in addition to improved environmental conditions,
will improve the over-all health condition of the town. People would spend less on healthcare
and lose fewer working days due to illness, so their economic status should also improve, as
well as their overall health.
16. Consultation, Disclosure and Grievance Redress. Public consultations were done in
the preparation of the project and IEE. Consultations will continue throughout the design and
project implementation period with the assistance of the CAPP.
17. The stakeholders were involved in developing the IEE through discussions on-site and
public consultation, after which views expressed were incorporated into the IEE and in the
planning and development of the project. Apart from on-site public consultations, a stakeholder
meeting of City Level Committee (CLC) was held and CLC has appreciated and approved the
DPR. The IEE will be made available at public locations in the city and will be disclosed to a
wider audience via the ADB and RUIDP websites. The consultation process will be continued
and expanded during project implementation to ensure that stakeholders are fully engaged in
the project and have the opportunity to participate in its development and implementation.
18. A grievance redress mechanism is already prevailing in RUIDP projects, which will
continue in Phase-IV also. Grievance Redress Mechanism is described within the IEE to ensure
any public grievances are addressed quickly.
19. Monitoring and Reporting. The PMU, PIU and Supervision consultants will be
responsible for monitoring. The Supervision Consultants will submit monthly/quarterly/semi-
annual monitoring reports to PMU, and the PMU will review and send the semi-annual
monitoring reports to ADB. ADB will post the environmental monitoring reports on its website.
20. Updating of IEE. This draft IEE shall be part of tender documents and this will be
updated by contractor (in coordination with Environment Safeguard Specialist(ESS) of
consultant), during Service Improvement Plan (SIP) preparation (within three months of contract
award) as per updated /changed scope of works (if any) and revised IEE shall be submitted to
ADB for approval and after approval from ADB shall be applicable to contractor throughout the
project. Contractor will also conduct Environmental monitoring of baseline conditions of air,
noise, water and soil and the same will be reflected in the revised IEE to be prepared during SIP
Period. This IEE is revisable document and can be revised anytime during project
implementation if there is any considerable change in scope of works, change in location of
component, change in cost due to addition or subtraction of components etc.which can change
the environmental impacts, and revised IEE shall supersede the earlier version of IEE and shall
be contractually applicable to the contractor after approval from RUIDP and ADB.
I INTRODUCTION
A. Background
22. Project background and context. The proposed Rajasthan Secondary Towns
Development Investment Program (RSTDIP), which is fourth phase under Rajasthan Urban
Infrastructure Development Project(RUIDP), will support the ongoing efforts of the Government
of Rajasthan (the government) towards improving the water and wastewater services in40
towns2 , each with population between 50,000 and 100,000, or which are district headquarters
(irrespective of population) or having heritage, cultural or other importance (irrespective of
population)in the state. The project will support investing in the rehabilitation and expansion of
water supply network for reduction of nonrevenue water (NRW), 24x7 water supply, the
rehabilitation and expansion of sewerage network, modernization and new construction of water
supply and waste water treatment plants, as required, fecal sludge management, and
decentralized waste water management systems in the project towns. The project is expected to
increase operational efficiency, improve service delivery, and result in positive impact on health
and quality of life for the residents of project towns in the state.
23. The focus of the proposed investment will be on water supply and sewerage
infrastructure. A series of subprojects will be implemented under the Project, with each
subproject providing improvements to water supply or sewerage or both in a project town.
B. Background of IEE
24. Presently sewerage system is developed for the core area of city, which is not
commissioned yet. Most of the residential, commercial buildings and educational institutions
have on-site septic tanks and soak pits. The effluent from the septic tanks directly drains into the
open drains. Water supply in the towns is also not adequate in terms of quality and quantity and
2
Abu Road, Badi, Balotra, Barmer, Banswara, Chomu, Dausa, Didwana ,Fatehpur, Jaisalmer, Jalore, Jhalawar,
Karauli, Kuchaman, Ladnu, Laxmangarh, Makrana, Nimbeheda, Nokha, Pratapgarh, Rajgarh, Rajsamand,
Ratangarh, SardarShahar, Sri Dungargarh, Suratgarh, Shahpura (Bhilwara), Shahpura (Jaipur), Sirohi and
Heritage towns - Bandikui, Deeg, Dungarpur, Jobner, Khetri, Kama, Mandawa, Nawalgarh, Pillibanga, Sambhar-
Phulera and Tijara
huge water losses persist in existing water supply system in the town. Therefore water supply
and sewerage system is proposed in this town under ADB financial assistance.
25. Project Description: Under Water Supply components proposed works are – (i)
Construction of new CWR of 2400 KL and Clear Water Pump House at Hanumangarh Road
headworks, (ii) Rehabilitation of OHSRs at Bairudan, Holidhora, Suryamandir, & Ramnagar, (iii)
Rehabilitation of CWR of 4100 KL and Clear Water Pump House at Hanumangarh Road
Headworks (iv) laying of Rising Main- 8.588 km of DI K9 pipes of 100-300 mm dia, (v) water
supply pipe for distribution networks- 236.561 Kms of different diameters and pipe materials (vi)
Construction of Consumer Relation and Management Centre- 1 no., Central Control Centre- 1
no. and Master Control Centre- 1 no (vii) Consumer Connections- during design build period-
15834 and during O&M period- 2474 total 18308 nos.
26. Under Sewerage components proposed works are (i) Construction of 3 STPs of 7.30
MLD, 5.40 MLD and 1.60 MLD capacities with Treated Effluent Elevated Reservoir (TEER),
Treated Effluent Storage Reservoir (TESR), Effluent Pumping Station (EPS) for reuse of treated
effluent (ii) 2 nos. of SPSs (0.65 MLD and 2.30 MLD capacity) (iii) Rising main- 2.1 Km (800 mt.
For SPS-8 of 250 mm DI K9 pipes and 1300 mt. For SPS 6 of 350 mm DI K9 pipes) (iv) Sewer
network of 68.02 km including 12.00 Km trenchless laying (v) Electrical and Mechanical works
(vi) house sewer connections- during design build period- 5600 and during O&M period- 2000,
total 7800 nos.
27. ADB requires the consideration of environmental issues in all aspects of the Bank’s
operations, and the requirements for environmental assessment are described in ADB’s
Safeguards Policy Statement (2009). Accordingly, this Initial Environmental Examination (IEE)
has been conducted to assess the environmental impacts and provide mitigation and monitoring
measures to ensure that there are no significant impacts as a result of the subproject.
28. The environmental impacts of Sardarshahar water supply and sewerage subproject have
been identified and assessed as part of the planning and design process. An environmental
assessment using ADB’s Rapid Environmental Assessment Checklist for Sewerage (Appendix
1) was conducted, and results of the assessment show that the subproject is unlikely to cause
significant adverse impacts. Thus, this IEE has been prepared in accordance with ADB SPS’s
requirements for environment category B projects.
C. Scope of IEE
29. The IEE is prepared for water supply and sewerage works proposed in Sardarshahar
town of Churu district of Rajasthan as per Detail Project Report. IEE report is prepared based
mainly on secondary sources of information and field reconnaissance surveys; no field
monitoring (ambient environmental conditions) survey was conducted. Stakeholder consultation
was an integral part of the IEE.
30. This IEE needs to be updated by contractor (in coordination with ESS of consultant),
during SIP preparation (within three months of contract award) as per changed scope of works
(if any) and revised IEE shall be submitted to ADB for approval and after approval shall be
applicable to contractor throughout the project. Contractor will conduct baseline environmental
monitoring for ambient air, noise, water and soil during pre-construction stage (to be
incorporated in revised IEE) and periodical environmental monitoring in construction phase.
31. This IEE is revisable document and can be revised anytime during project
implementation if there is any considerable change in scope of works, change in location of
component, change in cost due to addition or subtraction of components etc. which can change
the environmental impacts, and revised IEE shall supersede the earlier version of IEE and shall
be contractually applicable to the contractor after approval from ADB.
D. Report Structure
32. This Report contains nine (9) sections excluding Executive summary; (i) Introduction (ii)
Description of the project (iii) Policy, Legal and Administrative Framework (iv) description of the
environment; (v)Anticipated environmental impacts and mitigation measures; (vi) public
consultation and information disclosure; (vii) Grievance redress mechanism; (viii) Environmental
management plan, and (ix) Conclusion and recommendation.
II POLICY, LEGAL AND ADMINISTRATIVE FRAMEWORKS
A. ADB Policy
33. ADB SPS Requires that during the design, construction, and operation of the project
necessary compliance to all applicable laws and international conventions / treaties along with
pollution prevention and control technologies and practices consistent with international good
practice, are ensured.
34. Screening and Categorization with that of ADB SPS 2009. ADB uses a classification
system to reflect the significance of a project’s potential environmental impacts. A project’s
category is determined by the category of its most environmentally sensitive component,
including direct, indirect, cumulative, and induced impacts in the project’s area of influence.
Each proposed project is scrutinized as to its type, location, scale, and sensitivity and the
magnitude of its potential environmental impacts. Projects are assigned to one of the following
four categories:
35. Environmental Management Plan. An EMP which addresses the potential impacts and
risks identified by the environmental assessment shall be prepared. The level of detail and
complexity of the EMP and the priority of the identified measures and actions will be
commensurate with the Project’s impact and risks.
(i). For environmental category A projects, a draft EIA report at least 120 days
before Board consideration;
(ii). Final or updated EIA and/or IEE upon receipt; and
(iii). Environmental monitoring reports submitted by the Project Management Unit
(PMU) during project implementation upon receipt.
38. ADB SPS International Best Practice Requirements. ADB SPS requires that, during
the design, construction, and operation of the project, the executing agency shall apply
pollution prevention and control technologies and practices that are consistent with
international good practice, as reflected in internationally recognized standards .These
standards contain performance levels and measures that are normally acceptable and
applicable to projects. When Government of India regulations differ from these levels and
measures, the PMU and PIUs will achieve whichever is more stringent. If less stringent
levels or measures are appropriate in view of specific project circumstances, the PMU and
PIUs will provide full and detailed justification for any proposed alternatives that are
consistent with the requirements presented in ADB SPS.
39. The IEEs shall also reflect meaningful consultation and disclosure process with a
provision for grievance redress mechanism.
40. The environmental impacts of Sardarshahar water supply and sewerage subproject
have been identified and assessed as part of the planning and design process. An
environmental assessment using ADB’s Rapid Environmental Assessment Checklist for Water
Supply and Sewerage (Appendix 1) was conducted, and results of the assessment show that
the subproject is unlikely to cause significant adverse impacts. Thus, this IEE has been
prepared in accordance with ADB SPS’s requirements for environment category B projects.
B. National and State Laws
41. The implementation of the subprojects will be governed by Government of India and
State of Rajasthan and other applicable environmental acts, rules, regulations, and standards.
These regulations impose restrictions on the activities to minimize or mitigate likely impacts on
the environment. It is the responsibility of the project executing and implementing agencies to
ensure subprojects are consistent with the legal framework, whether applicable international,
national, state or municipal or local. Key standards include those related to drinking water
quality, air quality, effluent discharge, and protected areas. Compliance is required in all stages
of the subprojects including design, construction, and operation and maintenance.
42. Environmental assessment. The GoI EIA Notification of 2006 (replacing the EIA
Notification of 1994), sets out the requirement for Environmental Assessment in India. This
states that Environmental Clearance (EC) is required for specified activities/projects, and this
must be obtained before any construction work or land preparation (except land acquisition)
may commence. Projects are categorized as A or B depending on the scale of the project and
the nature of its impacts.
43. None of the components of this sewerage system subproject falls under the ambit of the
EIA Notification 2006, and, therefore EIA Study or EC is not required for the subproject.
45. Clearances / permissions to be obtained prior to start of construction. Table 3 shows the
list of clearances/permissions required for project construction. This list is indicative and the
contractor should ascertain the requirements prior to start of the construction, and obtain all
necessary clearances/permission prior to start of construction.
46. PMU will be overall responsible for supervision in getting all clearances and provide
details to ADB through semi-annual report.
III DESCRIPTION OF PROJECT
48. Sardarshahar city has the administrative headquarters in Churu district. There are 7
tehsils in the district
Churu, Ratangarh, Taranagar, Rajgarh, Sardarshahar, Sujangarh and Bidasar. Bidasar is the
newest Tehsil. The total area of Sardarshahar is 2473 acre.The municipal area of
Sardarshahar town has been divided in to 40 wards. Sardarshahar lies towards the North East
of Bikaner at a distance of 136 Km by Road on the junction of State Highway No.6 and 7. It is
directly connected to Delhi, Jaipur, Ganganagar, and Bikaner by Road. The Only Rail Link with
Ratannagar was provided in 1916 in erstwhile Bikaner State Time. Sardarshahar town is
located at 74o27’. Longitudinal east and 28o26’ latitude North at an Altitude of 224m above
mean sea level.
A. Present Status of Water Supply and Sewerage
49. Water Supply: Potable water for the Sardarshahar city is available from two
main sources i.e. Groundwater source (Tube wells) and Surface water of IGNP through
sawarsat minor canal.
50. Groundwater source: Currently, tube wells also play a role in Sardarshahar water
supply system which is situated in the city limits. There are 45 tube wells/open wells harnessed
with individual production of 225-300 LPM (10.00 MLD approx.). Average depth of these tube
wells is 200 M and the general water table in the area is 41 M. Total water produced from these
TW’s is directly boosted to distribution system for non-drinking purposes.
51. Surface water of IGNP through Sawars at minor: Main Source of Sardarshahar town
water supply is Indira Gandhi water canal under Indira Ganghi Nahar Project (IGNP) from
thereon Sawashat Canal emanate which is used to feed water to the existing WTP of 70 MLD
capacity at Dhannasar (Dhannasar Water Treatment Plant).
3 Abu Road, Badi, Balotra, Barmer, Banswara, Chomu, Dausa, Didwana ,Fatehpur, Jaisalmer, Jalore, Jhalawar, Karauli,
Kuchaman, Sardarsahar, Laxmangarh, Makrana, Nimbeheda, Nokha, Pratapgarh, Rajgarh, Rajsamand, Ratangarh, Sardar
Shahar, Sri Dungargarh, Suratgarh, Shahpura (Bhilwara), Shahpura (Jaipur), Sirohi, Tijara and Heritage towns - Bandikui,
Deeg, Dungarpur, Jobner, Khetri, Kama, Mandawa, Nawalgarh, Pillibanga & Sambhar-Phulera
52. Treatment, Storage and Distribution: Dhannasar WTP is part of AAPNI Yojna which is
Asia’s largest rural drinking water supply project. Also under the Phase II Aapni Yojna, there is a
provision for the construction of new 160 MLD WTP at the same premises. Currently from
Dhannasar WTP, water is being fed to Sardarshahar CWR with intermediate Pumping Station at
Palloo and Sadasar by 1100dia PSC pipe line, from CWR at Sardarshahar, water is being fed to
4 OHSR’s of varying capacity which supplies water to the Distribution system of Sardarshahar.
At present there are 6 OHSR and 1 GLSR in Sardarshahar town. The capacity of the reservoirs
varies from 350 KL to 1500 KL. Existing OHSRs and GLSR are situated in different locations of
town and OHSRs are having staging height of 18 mtrs. At present there are total 6 water supply
zones in Town. Distribution system is already laid inside the town except in outskirts. Presently
Distribution system in town is receiving water from their respective OHSR/GLSR by gravity. The
Existing Distribution System is of uPVC and AC make, from the OHSR Pipe Line of Size
350mm-300mm emanates which reduces to 250mm and subsequently branches to 140mm and
from thereon to 110mm and 90mm respectively for House Connections. The Existing
Distribution system consist of six(6) zones, Zone I to IV are being fed from the Existing four
OHSR’s while it is proposed to supply Zone-V, VI from the newly constructed OHSR’s located at
Zone-05 & Zone-06, and Zone-VII is to be supplied from newly constructed CWR at
Hanumangar Road.
53. The majority of the uPVC lines have been laid in between 2001 to 2003 and designed on
the basis of 100 lpcd. The total length of existing distribution system is reported to be about 156.
Km which consists of AC and uPVC pipes of sizes varying from 80 to 350 mm diameter. The
supply interval is also varying from 2-3 hours 2 times a day. But most of the wards also have
Bore wells directly connected to their distribution system which presents a challenge and makes
the distribution system much more complicated. Total number of water connections in town are
20600 out of which 19600 are metered and 1000 are non-metered connections.
54. Currently 11-12MLD clear water is taken from CWR as the existing system was
designed on the basis of 100 LPCD. Present service level of Sardarshahar town is 90-100
LPCD. As per the discussion with line agency, present NRW level may be around 35-40%.
55. Sewerage: At present the Town does not have functional Underground Sewerage
system. The municipal Drains are mostly open causing problem in Rainy season. Presently
sewerage from the city flows into several small drains. Present drainage system is based on
eleven ginanis/ sumpwells. Each ginani has its own contributory area where house drainage
and storm water is collected through combined Drains. The disposal from ginani located in the
North of the Town numbered as 1 to 4 in the town map is done by pumping the waste water
towards outer low lying area of Northern side. Likewise remaining ginani are interconnected to
ginani no.10 from where waste water is finally pumped to low lying area in south-west of the
town. Normally pumping is done almost 4 to 6 hrs a day from each ginani. For this, separate
stand by pumps and D.G sets are provided.
56. Sewer is laid under UIDSSMT project currently in Sardarsahar. Presently 4 sewerage
pumping stations and 2 STP’s based on WSP (Waste Stabilisation Ponds) technology are
constructed but not functional, which when connected to the sewer system will cater to the
demand up to the intermediate year 2025 as per the proposed Detailed report prepared under
UIDSSMT. According to which, 155. 96kms sewer Lines are supposed to be laid under Phase-I
and II of the scheme. Out of 155.96 Km of sewer Line, only 109 Km has been laid, the
remaining line along with the other areas not covered under the existing scheme is to be
connected under the present RUIDP Phase-IV scheme. 10 No’s of SPSs have been proposed
out of which only four have been constructed. Currently two STP’s of 2MLD and 5 MLD based
on WSP process are constructed for Sardarshahar Town, STP was designed to confirm to
effluent quality standard as per applicable standards at that time as : BOD < 100mg/l, COD <
250mg/l and SS < 100mg/l. Sewer lines are completed in most of the core area of town and
some area of core zone and other outer areas are still not covered.
57. Water Supply: As all the pumps of intermediate pumping stations have served their
useful lives, they work at very low efficiency. Refurbishing them under the present condition will
be uneconomical. Hence these pumps are recommended to be phased out. The piping system
and all the valves need to be changed as the proposed system will be SCADA based. All the
existing valves are manually operated having operational problem which need to be replaced to
make compatible with SCADA system. Existing AC pipes are old and are considered to be
possible source of leakages. There are estimated 30-40 % water losses due to various reasons
and therefore NRW reduction is required for efficient and sustainable water supply system in
town. Also present water supply rate is 90-100 LPCD which is lower than the recommended rate
of 135 LPCD and water supply is for 2-4 hours per day which needs to be increased as 24
hours, therefore improvement in the existing water supply system is required and recommended
in the proposed sub project.
59. Under Phase-I & II of UIDSSMT scheme, 156 km (approx.) sewer network was
proposed, outfall sewer up to STP along with the construction of Sewage Pumping Stations
(SPS). In Phase-I nearly 86 Km of Sewer Line are supposed to be connected, while the rest are
to be laid and connected in Phase-II, as proposed in the DPR. Under the existing scheme of
UIDSSMT, out of 10 Nos. SPS only 4 have been constructed, and construction of STP of
capacity 2MLD and 5 MLD to cater the North and South Zone have been done as against
proposed 4 MLD & 9.6 MLD in DPR. The total length of sewer laid under the scheme is 109Km.
There are still several uncovered areas in the present system, these areas are- Bikaner Road
(South Side), Mandi Zone (Industry Area), Surya Mandir Area at Bikaner Road, Colonies near
Rama Hotel area at Bikaner Circle, Bahadur Singh Colony, Masjid Colony at Hanumangar h
road, Kaka Colony, Purana Bus Stand Area, Lohar Colony & Madina Colony in the North Zone.
However as Kaka Colony &Lohar Colony is outside the municipal boundary hence sewer
network is not proposed in the current DPR. These areas are adjoining to the municipal
boundary hence sewer network design for these areas are also done in the DPR and
accordingly STP is also designed.
60. To make existing sewerage system functional it is at most need to fill up the uncovered
areas and to provide sewerage facilities in new developing areas. As per the population
projections for coming 15 years the capacity of the existing STP is also required to be
enhanced. However in consideration of meeting the CPCB criteria ,up gradation of the current
Treatment technology is recommended and SBR process needs to be adopted.
C. Infrastructure Improvements Proposed in Sardarsahar Town under RSTDIP
61. In the absence of safe disposal system of sewage and intermittent supply of water as
mentioned above, the people of Fatehpur are facing unhealthy and unhygienic environmental
conditions therefore public representatives are also demanding facilities of sewerage system on
priority basis. The town requires sound drainage and sewerage system.
62. Potable water for the Sardarshahar city is available from two main sources i.e.
Groundwater source (Tube wells) and Surface water of IGNP through sawarsat minor canal.
Existing source of surface water for Sardarshahar Town is Sawarsat minor Canal of IGNP
(Indira Gandhi Nahar Pariyojana). Raw Water from canal treated at WTP of 70 MLD capacity at
Dhannasar (Dhannasar Water Treatment Plant) will be available for this project (Letter of Water
Allocation for proposed Water Supply Work is given in Appendix 19). Overall drinking water
supply requirements are as follows:
65. This subproject complies with the environmental subproject selection criteria agreed
between the government and the ADB (Compliance checklist is at Appendix 6). Following
Table 3 shows the nature and size of the various components of the subproject along with land
availability.
66. Location maps of proposed components in google earth are shown in Figures 1-6 and
in. Layout plans of proposed STP and sewerage networks and CWR and schematic diagrams of
water supply are shown in Figures 7-11. Details of proposed works under subproject are given
in Table-3 below-
Sewerage Works
Construction of STPs – 3 STP-1 (5.40 MLD)- All the lands STP-1 (5.40 MLD)-
nos. Existing STP North available with STP-2 (7.30 MLD)
campus of Municipal Council STP-3 (1.60 MLD)- All STPs
Sardarshahar STP-1 and 2 near are on SBR technology
existing STP
STP-2 (7.30 MLD)- campuses
Existing STP South
campus of STP-3 (1.60 MLD
Sardarshahar near Ashoke circle)
Confirmation on
STP-3 (1.60 MLD)- STP 3 land is yet
near Ashoke circle to be obtained
from the owner
Gandhi
Vidyamandir Trust.
NagarPalika will
provide land for
STP for this project.
Consent letter/NOC
should be
appended in the
IEE report before
award of contract.
Construction of SPSs - 2 SPS-1 (0.65 MLD) at Both lands are SPS-1 (0.65 MLD)
nos. Kamdhenu Gaushala under possession SPS-2 (2.30 MLD)
Land near Shyamdev of Gaushala Samiti,
Hotel.
NagarPalika had
SPS-2 (2.30 MLD) for applied to obtain
near BSNL office consent /NOC from
Gaushala Samiti.
Consent letter/NOC
should be
appended in the
IEE report before
award of contract.
Sub-project Components Location Land availability Capacity/ Work Proposed
and ownership
Rising Mains for SPSs For SPS 1 and SPS 2 Existing ROW of For SPS 1- 800 mt. of 250
roads under mm dia of DI K9 pipes and
Municipal Council For SPS 2- 1300 mt. of 350
mm DI K9 pipes
Sewer Networks Different locations of Existing ROW of HDPE DWC SN8 pipe- 62.5
town roads under mk.
Municipal Council RCC NP4 pipe- 1.0 Km
HDPE PE-100/PN-6 pipe-
13.5 Km Trenchless method)
SCADA for entire system - - -
68. Excavation for the pipe/sewer laying works will be undertaken through open trenching,
which will be maximum width of 1 m only on one side of the road ROW with maximum length,
an average 140 m per day for water supply lines and 70 m for sewers. Excavation, laying of
pipes and backfilling will be completed within the day. Subsequent to completion of works, road
reinstatement will be undertaken by the contractor as part of the civil works. The same shall be
mentioned in the bid document to make it binding on the contractor.
69. Proposal for SBR type of sewage treatment plant. Sewage shall be fed into the
Cyclic Activated Sludge Process/SBR Process Basins for biological treatment to remove BOD,
COD and Suspended Solids. SBR is a Cyclic Activated Sludge Treatment process. It provides
highest treatment efficiency possible in a single step biological process. The SBR System is
operated in a batch reactor mode. This eliminates all the inefficiencies of the continuous
processes. A batch reactor is a perfect reactor, which ensures 100% treatment. Two modules
are provided to ensure continuous treatment. The complete process takes place in a single
reactor, within which all biological treatment steps take place sequentially. No additional settling
unit, Secondary Clarifier is required.
70. In line with the notification issued by the CPCB, MoEFCC on 21.04.2015, it is proposed
to apply technology / process to achieve the following discharge standards:
Table 6: Discharge Standards to be achieved as per 21.04.2015 Notification
71. Disposal of Treated Effluent. The proposed SBR process shall achieve very low BOD
(BOD 10) and suspended solids in the treated effluent. It is proposed to reuse the treated
effluent for use of agriculture, horticulture, development of urban forestry etc. and remaining
treated effluent is proposed to be discharged in to nearby natural nallah. In order to safeguard
the interest of users of treated effluent, it is proposed to apply technology/process to achieve
very low BOD (BOD10) and suspended solids in the treated effluent. The treated effluent reuse
plan shall be developed and implemented by the Contractor in consultation with the Municipality
authorities who shall be guided by the RUIDP and the PMDSC experts, as well.
72. The structures for reuse of treated effluent proposed under the project is as below: -
73. The sewer system will be designed as a separate sewer system that carries only the
domestic wastewater, the open drain system that exists in the town will cater to storm runoff
only after implementation of proposed works. No industrial wastewater will be allowed into the
sewers.
74. Disposal of Sludge: Sewage sludge generated from the SBR process has undergone
sufficient treatment for stabilization and pathogen reduction. Additionally, the industrial effluents
do not get into the wastewater collection system thereby avoiding any toxic constituents being
part of the sludge generated from the wastewater treatment process. Hence, the sludge
generated is of high quality that can be applied on land. Considering that the sludge from the
SBR process is composed of both inorganic and organic materials, large concentration of some
plant nutrients and much smaller concentrations of numerous trace elements and organic
chemicals, the sludge can be put to good use when applied on land. Under the project, the
sludge reuse plan shall be developed and implemented by the Contractor in consultation with
the Municipality authorities who shall be guided by the RUIDP and the PMDSC experts, as well.
75. Scope of work Operation and Maintenance Phase .Contractor shall be responsible for
operation, maintenance and management of the entire waste water services and water supply
under this contract in service area for 10 years as detailed below:
2 Drawing water from TWs/Open Wells to CWRs including water From the date of
pumping main and Maintenance of entire underground water Commissioning Certificate
system.
3 Operating & Maintaining all the Clear Water pumping stations to From the date of
fill all the CWRs/OHSRs/GLSRs through transmission pipe lines Commissioning Certificate
and also direct pumping to distribution system and operation of
chlorination system, maintenance of complete system including
maintaining the infrastructure and specified Water levels at each
of the reservoirs throughout the O&M period
4 Managing the distribution network for distributing water efficiently, From Sectional Completion
equitably and minimizing non-revenue water (NRW) and Certificate
maintaining the infrastructure on DMA basis in the distribution
network.
5 Providing continuous pressurized water supply with improvement From the date of
in level of service on continuous basis to the connected Commissioning Certificate
Sl. No. Obligation Period
consumers and maintaining the infrastructure while meeting the
performance indicators. A minimum of 12 m water column
pressure shall be maintained at all ferrule points, but it shall not
exceed the maximum allowable pressure.
6 Meter reading, customer services and maintaining the From Sectional Completion
infrastructure in water supply sector Certificate
7 Meter reading, bimonthly billing, bill distribution, revenue collection From Date of Construction
and customer services and maintaining the infrastructure in water Completion Certificate
supply sector
8 Sampling treated water received at all the CWRs/ESRs/GLSRs From Sectional Completion
and from random points within the Zones/DMA to ensure that it Date
meets the Potable Water Specification and monitor on monthly
basis;
9 Assessing and minimizing non-revenue water and locating the From Sectional Completion
causes for high NRW and bringing down the NRW level within the Certificate
7% for DMA, 12 % from clear water source and 15% from raw
water sources.
10 Provide consumer service connections on approval or sanction by From Commencement Date
Employer Representative or line agency through Employer
Representative
11 Contractor will provide continuous on-the-job trainings that will From Commencement Date
start from the day the contractor gets mobilized, and other
capacity building programs by the contractor as important regular
activities for staff of the Employer, PHED and Local Body.
12 Maintaining environmental and safety norms at entire system From Commencement Date
components
76. The subproject is primarily designed to improve environmental quality and living
conditions of Sardarshahar town through provision of water supply and sewerage. The benefits
arising from this subproject include: (i) increased availability of good quality potable water at
appropriate pressure to all households including urban poor; (ii) reduced time and costs in
accessing alternative sources of water. (iii) better public health particularly reduction in
waterborne and infectious diseases; (iv) reduced risk of groundwater contamination; (v) reduced
risk of contamination of treated water supplies; and, (vi) improvement in quality of water bodies
due to disposal of treated effluent meeting disposal standards.
77. Both the water supply and sewer network in Sardarshahar town are designed with
utmost consideration to energy efficiency. Gravity flow systems adopted. In existing water
supply system, water losses (UFW) are very high, reducing the losses and improving the
efficiency of the system is identified as the most important component under RUIDP. This is
considered as an alternative for source development/augmentation.
78. To make the project energy efficient, as part of this project, energy efficiency measures
are being considered and incorporated into the subproject designs where appropriate.
79. Energy efficient, high performance motors and transformers shall be provided for
optimum utilization of energy during construction and operation of the project.
80. Component of luminaries shall be ‘energy efficient low loss’ type. CFL/LED type of
luminaries shall be used for office/ all indoor areas except pump house area. HPSV or HPMV
luminaries shall be used for pump house area and other outdoor areas. Street/ area lighting
shall be of LED type and controlled by time switch/ photocell for automatic switching of
luminaries. Specification of solar lighting shall be as per Ministry of New and Renewable
Energy. Fixtures shall be energy efficient and ballast shall be electronic low loss type.
81. Supervisory Control and Data Acquisition (SCADA) has been proposed for entire system
of sewerage and water supply. SCADA shall support and include a multi-level real-time auditing
and advising of energy optimization process and Real-time process performance software. The
key benefits of a performance auditing system would be a more energy efficient plant, improved
reliability & safety, and increased profitability.
82. The detailed design of this subproject will be completed by December 2018. After the
approval, bid will be prepared and tenders will be invited by RUIDP, and the contract will be
awarded after technical and financial evaluations of bids. Construction will take (about 36
months) after the award of works. Dates for bids and works award will be finalized by RUIDP in
due course of time.
Figure 1: Location of project components in Google Map
Figure 2: Location of proposed site of STP-1 (South campus) in Google Map
Figure 3: Location of proposed site of STP-2 (North Campus) in Google Map
Figure 4: Location of proposed site of SPS-3 in Google Map
Figure 5: Location of proposed site of SPS-1 (Near BSNL Office) in Google Map
Figure 6 : Location of proposed site of SPS-2 (Near Kamdhenu Gaushala) in Google Map
Figure 7: Layout of proposed pump house and CWR in PHED campus
Figure 8: Layout of Proposed STP 1.60 MLD
Figure 9 : Layout of existing and proposed sewer networks
Figure 10 : Layout of Proposed SPS
Figure 11: Schematic diagram of proposed Water Supply Networks
48
IV DESCRIPTION OF ENVIRONMENT
A
[
Physical Resources
83. Recognized as an entry gate to the great Thar Desert, Churu is located in the desert
areaof Rajasthan. The district is located in the eastern Rajasthan between 27024’ to 29000’
North latitude and 73º 40’ to 75º 41’ East longitudes. It is bounded by Sri Ganganagar district in
the North, by Sikar and Jhunjhunu and Hissar district of Haryana in the East, by Nagaur in the
South and in the West by Bikaner. Churu, like an oasis, situated in the middle of the shifting
golden sand dunes, opens the gate to the great desert of Thar. The north border is neighbor of
Hanumangarh District, east by Haryana state, Jhunjhunu and Sikar districts to the southeast,
Nagaur District to the south, and Bikaner District to the west. The total area of the district is 13,
85,898 hectares. It is occupied nearly 4.92 percent of the area of the state andstands eight in
respect of area amongst the district of Rajasthan. The district covers 6 Tehsils Churu,
Ratangarh, Taranagar, Rajgarh, Sardarshahar, and Sujangarh.
84. Sardarshahar lies towards the North East of Bikaner at a distance of 136 Km by Road on
the junction of State Highway No.6 and 7. It is directly connected to Delhi, Jaipur, Ganganagar,
and Bikaner by Road. The Only Rail Link with Ratannagar was provided in 1916 in erstwhile
Bikaner State Time. Sardarshahar town is located at 74027’. Longitudinal east and 28026’
latitude North at an Altitude of 224m above mean sea level. Location map of Sardarshahar is
shown in Figure 12.
85. Topography: District Churu is a part of the great Thar Desert. It is covered with a thick
mantle of sand, is characterized by 6 to 30 meter longitudinal dunes treading north east to south
west. The ground level in the district is about 400 meters above mean sea level the terrain in
general is sloping from south to north. There are no big hill in the district expect some hillocks.
There are no perennial rivers or streams in the district. Wells and ponds are the principal
sources of water supply. The climate of the district is dry desert with large variation in
temperature. The minimum and maximum temperature recorded in the district varies from –2`c
to 50`c. Relative humidity is generally below 30% except during the brief south east monsoon
period when the same rises up to 60% in the district the rainy season usually lasts from July to
mid-September and the normal usual rainfall is only 328 mm.
86. Soils: The project area is generally covered sand to loamy sand, Aeolian in nature,
belonging to mainly Entisols and Aridisols. Major soil types in District Churu are - Deep
Yellowish brown Sandy, Deep Light yellowish brown Loamy, Deep Pale brown Sandy, Medium
Light yellowish brown Loamy, Medium Light yellowish brown Sandy, Deep Pale brown
Loamy.The soil in Sardarshaharis sandy underlain by hard clay and brick red sand stone.
87. Geology: The geology of the Churu district is largely concealed by windblown sand and
has been worked out on the basis of scanty exposures, from dug well and borehole data. The
area, a part of the Thar Desert is basically a fluvio–aeolian depositional basin containing 255 m
thick pile of Quaternary sediments. It is characterized by an undulating topography consisting of
sand dunes interspersed with interdunal valley and linear depressions. The various rock types
of the area belong to the Delhi Supergroup, Erinpura Granite, Malani Igneous Suite, the
MarwarSupergroup and the tertiary sediments including the Palana Formation of Palaeocene
age. The oldest rock sequence in the area belongs to the Punagarh Group comprising of slate,
phyllites, quartz-mica schist, ferruginous quartzite etc. of the Delhi Super Group. These rocks
are well exposed in south of Bidasar and east of Pandurai Geologically, the area belongs to
rocks of Delhi super group.
88. The site on which the town stands is of great significance in its natural setting. The old
town was established on the eastern side of a hillock, which provided natural protection against
the westerly sand storms. It has a gradual slope towards south and the old town was located in
a river valley namely ‘khagal’. This location advantage made this town to grow and prosper
throughout its history. There is no developed storm drainage and sewerage within the city.
Geological set up of the town is mostly brick red sand stone with evaporates belonging to
Barmer Group of sand stones. Some older alluvium consisting of sand with gravel and Kankar,
coarse to medium sand stone, silt and clay belonging to different geological ages are also
encountered.
89. Mineral Resources: A major part of the area of the district, being thickly covered with
sand, remains hidden from geological observations. But at some places rock exposures have
been found both in eastern and western portions. The Delhi super Group of rock is represented
by Ajabgarh group covering phylites. Slate and quartzite. The malani igneous suite is mainly
represented by an effusive phase which comprises phylites and volcanic tuffs. The Marwar
super group is represented by rocks of Jodhpur, Bilara and Nagaur group which include
sandstone, shale, limestone, dolomite, anhydrite, gypsum and halite.
90. Churu is not rich in minerals but they are found at few places. The various mineral
50
deposits are copper salt petrel, sand stone, limestone, gypsum etc. But these deposits are very
small in size and not of much economic importance.Only masonry and marble stones are
available as stones in the district. Masonry stones are available in Randhisar Hill, Lodasar,
Biramsar and Gopalpura where stone grit units are establishing. Marble stones are extracted in
village Dunkar, tehsil Sujangarh that are colored linear but not superior to other marbles.
Seismology
91. Churu district is located in the Zone II of Seismic Zoning Map of India (BIS 2001, New
Delhi), which is a low activity zone. As per the hazard map of Rajasthan the Churuis located in
the Zone-II (MSK VI) which is a low damage zone. Churu district lies in low damage risk zone
(Zone II). The area is less prone to earthquakes as it is located on relatively stable geological
plains. Based on available earthquake zone information Zone II is the least seismically active
region. This region is liable to MSK VI or less and is classified as the Low Damage Risk Zone.
The earthquakes in this region had magnitudes of m 5.0 or more in the past.
Climatic Conditions
92. Temperature: The period from March to May is one of continuous increase in
temperatures. May is generally the hottest month with a mean daily maximum temperature of
about 41.7°C and mean daily minimum of about 25.1°C. The weather is intensely hot in summer
and on some days the day temperature may reach up to 46°C. From November, both day and
night temperatures begin to decrease rapidly. January is generally the coldest month with the
mean daily maximum temperature at about 22.9°C and mean daily minimum at about 4.6°C.
Minimum temperature sometimes drops down to sub zero temperatures.
93. Rainfall: The annual rainfall in this desert area varies from 200 mm in the west to
around 400 mm in the east, with high annual coefficient of variation. Most of the rainfall over this
area is contributed by a few high intensity rainfall events. The meteorological records for 100
years at the Sardarshahar Station indicate a nominal declining trend in the total amount of
rainfall. The critical analysis of rainy days in monsoon years points out that the number of rainy
days with total daily rainfall between 20 and 50 mm and above constitutes nearly 4 to 5 events,
indicating maximum contribution in the annual amount of rainfall by these events.
94. Average rainfall in the region is 408.3 mm. About 90 percent of the annual rainfall in the
region is received during the southwest monsoon months i.e. June to September. July is the
rainiest month on an average 153.4 mm rainfall occurs in the month of July. July is having
maximum number of rainy days i.e. 7.1. Sardarshahar is having average rainfall of 296 mm.
95. Relative Humidity: Most humid conditions are found in the monsoons, followed by post-
monsoons, winter and summer in that order.
Surface Water
96. There is no river in Sardarshahar town. There are some small ponds and reservoirs in
Sardarshahar, which are mostly filled after mansoon and used for irrigation by nearby
agricultural fields. No any river flows through Sardarshahar town.
51
Groundwater
97. Water bearing formations in Churu district range from unconsolidated alluvium to semi
consolidated sandstones and consolidated schistose rocks. The older and younger alluvium
constituted of primarily sand of windblown and fluvial origin forms aquifers covering 71% of the
district area. Next most prominent aquifers in the district are sandstones (17.5%) followed by
schist (6.8%) and limestone (4.7%) aquifers. The hardrock aquifers are prominent in southern
and partly in western part of the district.Apart from Taranagar block which is completely saline,
the rest of the five blocks fall into different categories of stage of ground water development.
While SardarShahar is within ‘Safe’ category the Sujangarh and Rajgarh blocks are in ‘Over
Exploited’ category warranting need for conservation measures.The shallow groundwater
bearing aquifer formations in the desert area are mainly composed of aeolian sands of
unconsolidated nature. Aeolian sediments are remarkably uniform in grainsize distribution,
textural characteristics and mineral composition over contiguous areas and generally lack
stratification. Due to greater degree of sorting, the porosity and permeability of these deposits
are respectively greater than the corresponding quantities for aqueous deposits of similar
particle size.Fluoride in groundwater of this region is high mainly due to dissolution from
fluoride-bearing minerals like hornblende and illite. X-ray diffraction study of the soil samples
from this region states that apart from the causative minerals mentioned above, presence of
calcite and dolomite may also have accelerated the leaching of fluoride to the groundwater. The
arid climate with high evaporation and insignificant natural recharge might have accelerated the
strengthening of fluoride concentration in the groundwater of this area.
98. Depth of Groundwater table in Sardarshahar is Min. 10 and maximum 87mtr in pre-
monsoon and minimum 2mtrs and maximum 20mtrs in post-monsoon.
99. Ground Water Quality monitoring is being conducted by PHED in existing tube wells
situated in Sardarshahar town used for water supply in town. Results of 2 samples of this test
report are discussed in below Table 4-
Air Quality
100. In Sardarshahar town there are no industries and therefore level of air pollution is not
high. Source of air pollution in the town is only agricultural activities and means of transport.
101. Ambient air quality in Rajasthan is monitored by Rajasthan Pollution Control Board.
However, at present there is no monitoring station in Churu and therefore no data on ambient
air quality available. Air quality monitoring shall be conducted in the pre-construction phase (SIP
period) by the contractor and shall be updated in IEE.
102. Climate Change Projections: Average temperature projections from global climate
models (PRECIS) suggest a strong increase in temperature for state of Rajasthan. Baseline
data of temperature from 1975 to 2005 has been considered. Projections of maximum
temperature predicted that temperature varies from 0.6°C in 2020s to 3.2°C in 2080s.
Projection trends of minimum temperature increases clearly stated that minimum temperature of
atmosphere in the state is slightly increases from 0.9°C in 2020s to 3.9°C in 2080s.In context of
precipitation, available rainfall projection from global climate models (PRECIS) suggest an
increase in average rainfall for state of Rajasthan depicts that based on the baseline data of
precipitation from 1975 to 2005, projection of average annual rainfall varied from 6.6% in 2020s
to 9.1% in 2080s. The models also suggest an increase in the duration of dry spells as well as a
tendency towards more intense rainfall events. Any likely increase in precipitation would occur
in the northern part of the state and any decrease in the southern part of the state. Climate of
Rajasthan is varied in nature. Temperature and rainfall are the main climatic factors that
determine eco-climate of the area. Diurnal variations in temperature could be seen in the state
of Rajasthan. Temperature reaches above 50°C in summer and 0° in winter in some of district in
the state. Pattern of rainfall is uneven and erratic in nature.
103. By the proposed sewerage project, all the treated water will be used in beneficial
purposes such as Agriculture etc. that is the major component of the economic sector which is
largely dependent on rainfall for agricultural activities. Adequate treated water from treatment
plant will ensure the sustainability of more crops per drops in the area/regions and to make less
dependent on precious groundwater resources in the area/region.
B Ecological Resources
104. Forest: Churu district is a part of the Indian Great Thar desert. The district has only
6663 hectare area under the forest which is only 0.46% of the total area of the district. The
vegetation cover in the district is almost negligible due to extremes of temperature during winter
and summer and scanty rainfall established sand dunes inside Grass Reserves of inside areas,
free from biotic interference, contain very poor and open forest. Important trees found in the
district are Khejari, Kikar, Neem, Hingotaker, Shisham, Rohira, Bhhui, Phog, Ask, Senia, Thor,
Morali, Bura, Lampre, Kucha, Mural etc. Fox, Blue, Bull, common hare, Jackal porcupine, Bats
and Bush rats etc. are found here. The common birds found here are Bulbul, kite, Owl, Pigeon,
Sand Grouse, Grey pasctridge, Godavan of Guraha.
105. Common Flora in Sardarshahar: Common trees found in Sardarshahar are- Neem
(Azadirachtaindica), Dhak (Butea monosperma), Gulmohar (Delonixregia), Imli
(Tamarindusindica), Pipal (Ficusreligiosa), Ker (Capparis decidua Forsk.), Bargad
(Ficusbengalensis Linn.), Babool (Acacia nilotica), Avla (EmblicaofficianalisGaerth.), Siris
(Albizialebbeck), Vilayatibabool (Prosopisjuliflora) etc.
53
107. Proposed subproject components are located in Sardarshahar town of Churu District, an
urban area located in semi-arid dry region. Town area is mostly characterized by dense to
medium habitation, there is no natural habitat left in these places.
C Economic Development
Land use
108. Rajgarh Master Plan provides land use details of 1000.8 hectare area which was then
the municipal area. Out of total 1000.8hectare area, 453.06 hectare i.e. 47.05 % is developed
urban area. Rest of the land is under school, agriculture use and vacant land. Details of the land
use is provided in table below-
Table 4: Existing Land Use of Sardarshahar
Area (in Percentage
Percentage
Sl. Area (in Ha.) of
Land Use of Urban
No. Acres) Developed
area (%)
area (%)
1 Residential 952 385.3 81.80 38.50
2 Business 10.37 4.2 0.89 0.41
3 Industrial 17.87 7.23 1.53 0.72
4 Govt. / Central Govt. 1.25 0.51 0.10 0.05
5 Recreation 40.87 16.54 3.51 1.65
6 Public and Semi Public 59.11 23.92 5.07 2.39
Transport, roads and 33.40
7 82.53 7.10 3.33
Recirculation
453.06
Developed Area 1119.50 100 47.05
8 Agricultural 24 9.71 - 0.97
9 Other vacant & unused land 92.38 37.38 - 3.73
10 Tanks and Nallahs 2.62 1.06 - 0.10
11 Gandhi VidyaMandir 1190 481.57 - 48.15
1000.8
Total Urban area 2473 - 100
Source: Master Plan Sardarshahar 1986-2016
109. Industries: Churu district offers all the important infrastructure facilities essential for
economic and industrial growth like water, power, transport, industrial training, industrial area
etc. Total numbers of registered units in district are 1800 out of which Forest Based 489,
54
Miscellaneous & Service 337 (Hotel & Restaurants, laundry, tent house, Auto mobile workshop,
Mobile repairing and maintenance, offset printing, printing press, transportation), Cotton &
Textile 251, Engineering & Metal 233, Non-Metallic Minerals Prducts 165, Agro& Food
Processing 115. Micro & Small Enterprises products which have export potential and also being
presently exported from the district are handicrafts items like wooden decorative pieces &
article, leather jutis, sandal, guar gum, wood items etc.
110. There is only one industrial area in Sardarshahar having 277 registered units. There is
no large and medium industry in Sardarshahar, only small scale industries such as gum factory,
pulses and oil mills exist. Iron goods and iron craft is also an important small scale industry in
Sardarshahar. Small industrial units of mines and mineral based industries also present in this
town. (Source: Brief Industrial Profile of Churu District, MSME, Govt. of India and public
consultations)
111. Agriculture: The climatic conditions (arid desert) of a region affect the agricultural
cropping pattern of different areas. Thus, it produces different crops. Amongst a host of climatic
factors i.e. rainfall, temperature, humidity, wind velocity and duration of sunshine etc. affect the
cropping pattern in a significant way. Annual rainfall and its distribution over the entire year and
the regimes of diurnal and annual temperatures are by far, the prominent factors affecting
agriculture and the life style of the people in the region. Agricultural land is very less in
Sardarshahar as most of the vacant land is not suitable for agriculture. There is no means of
surface water irrigation system such as canal and therefore agriculture is mainly based on
ground water and rain water. Two crops are grown in Churu namely (i) Rabi in which crops like
Gram, Mustard, Moong, Garlic, Barley are grown during months of September-April. (ii) Kharif in
which crops like Maize, Jowar, Moong, Soya bean, Chilly, Ground Nut, Cottonseed, Rapeseed
etc. are grown during months of April-October.
112. Millet, Kidney-bean, Moth, gram, mustard, Tara Mira and Ground Nuts are other crops
abundantly in this area. The agriculture is based on the monsoon out rightly, In some tehsils,
irrigation is made by extracting water from wells but it is not success satisfactorily due to salty
and deep water.
Infrastructure
113. Water Supply. At present Sardarshahar meets its Water supply from Sawarsat Canal,
Water Treatment Plant of capacity 70 MLD located at Dhannasar which is used to supply Clear
Water to Sardarshahar Town along with 3 other Towns and nearly 500 Villages. In between
supply to Sardarshahar Town there are Two(2) Intermediate Pumping Station located at Palloo
and Sadasar with CWR of capacity 4100 KL each. At present Total incoming Water to
Sardarshahar Town from WTP is 12MLD, the remaining requirement is met up from Bore-Wells
located inside Sardarshahar Town. There is an Existing Reservoir of 4100KL capacity inside
Sardarshahar Town which is used to supply Water to Sardarshahar Town as well as
Sardarshahar Industrial Areas, and also to Ratangarh CWR. Inside Sardarshahar Town, there
are four OHSR from where water is being supplied to from the Sardarshahar CWR. Four OHSR
of capacity from 500KL to 1500KL is used to distribute Water to the entire Municipal area of the
Town.
114. Sewerage. At present the Town does not have existing Underground Sewerage system.
Though sewer is laid under UIDSSMT project currently in Sardarsahar, yet it has not been
functional till now. Presently 4 sewerage pumping stations and 2 STP’s based on WSP (Waste
55
Stabilisation Ponds) technology are being constructed which when connected to the sewer
system will cater to the demand up to the intermediate year 2025 as per the proposed Detailed
report prepared under UIDSSMT. In absence of functional sewage system in town most of
houses and establishments depend on septic tanks and soak pits. Open defecation is also not
uncommon especially in outskirt of town.
115. Solid Waste Management: Sardarshahar Nagar Palika collects solid waste via door-to-
door collection systems through an NGO under supervision of Nagar Palikastaff from all
municipal wards. Waste from door to door collection, community dust bins/open collection points
is manually lifted into vehicles for transportation to the disposal site. Currently there is no solid
waste processing facility and solid waste is dumped without any segregation in the vacant
government lands and low lying area for surface leveling. The un-segregated waste collected
from the city is disposed-off by crude open dumping method at the site. There is no landfill
facility in the city.
116. Storm Water Drainage: The municipal Drains are mostly open causing problem in
Rainy season. Presently Sewerage from the City flows into several small Drains. Presently the
drainage system is based on eleven ginanis/sumpwells. Each ginani has its own contributory
area where house drainage and storm water is collected through combined Drains. The disposal
from ginani located in the North of the Town numbered as 1 to 4 in the town map is done by
pumping the wastewater towards outer low lying area of Northern side. Likewise, remaining
ginani are interconnected to ginani no.10 from where waste water is finally pumped to low lying
area in South west of the town. Normally pumping is done almost 4 to 6 hrs a day from each
ginani. For this, separate stand by pumps and D.G sets are provided.
117. Power Supply: Thermal power is the main source of energy from conventional sources
in Rajasthan, contributing nearly 90% of the electricity, compared to hydropower, which
produces the remainder. State-level companies (RajyaVidyutUtpadan Nigam Ltd, RVUN; and
RajyaVidyutPrasaranNigamLtd, RVPN) are responsible for power generation and transmission
respectively, and distributionis provided by three regional companies, the Ajmer Vidyut Vitaran
Nigam Limited (AVVNL), Jaipur Vidyut Vitaran Nigam Limited (JVVNL) and Jodhpur Vidyut
Vitaran Nigam Limited (JDVVNL). Presently, total power availability / installed capacity of
RVUN in the State is 17281 MW as on Dec. 2016, including 5957.35 MW installed capacity of
RVUN power stations as on 31.12.2016. In addition, RVUN is also managing and operating two
Inter State Hydel Power Stations with installed capacity of 271 MW. Over 26% of total power
generation (conventional and non-conventional) comes from non-conventional sources like
wind, solar and biomass power is supplied from the central grid by overhead cables carried on
metal and concrete poles, mainly located in public areas alongside roads. The power supply in
the state is continuous and reliable, except in warmer months with periodic outages in warmer
months, and large fluctuations in voltage. In Sardarshahar town power supply is reliable and
sufficient power is supplied to the town by the authorities.
118. Transport: Sardarshahar is a comparatively new town, still its development is not very
much planned, and especially the roads are narrow and kutcha. The main traffic of the town
moves along the road from Bus Stand to Railway Station which is quite narrow. The existing
Bus Stand is located in congested area. The major transportation mode is autorikshaw. The
Only Rail Link is with Ratangarh and it was provided in 1916 in erstwhile Bikaner State. By
Road it is well connected to Churu District Headquaters, located at a distance of 52 Km from
Sardarshahar and also to Jaipur at a distance of 250 Km. nearest Railway Station is Churu,
nearest Airport is Jaipur.
56
119. The old city area is characterized by very narrow roads that are frequently congested
with traffic and pedestrians. In contrast the remainder of the town has a relatively good road
system, particularly in the outer areas, where streets are wide and not heavily used by traffic.
Roads in the town are consisting of bitumen/tar roads, cement concrete roads and gravel roads.
Most of the roads are maintained by Nagar Palika, Sardarshahar, while major intercity roads
and highways are maintained by the Public Works Department (PWD). Road condition is
generally good, but some roads are in need of repairs and resurfacing. This plus the absence of
parking spaces and pedestrian walkways leads to slow traffic and congestion in old town
specially walled city areas. Transport in the city is mainly by personal vehicles (cars and
motorcycles) and motor-rickshaws. The Rajasthan State Road Transport Corporation (RSRTC)
runs public buses to neighboring villages and towns such as Ajmer, Kota, Udaipur and Jaipur.
Demography
120. Sardarshahar is a Municipality city situated in Sardarshahar tehsil of Churu district. The
Sardarshahar city is divided into 40 wards for which elections are held every 5 years. As per the
Population Census 2011, there are total 15,433 families residing in the Sardarshahar city. The
total population of Sardarshahar is 95,911 out of which 49,669 are males and 46,242 are
females thus the Average Sex Ratio of Sardarshahar is 931.
121. The population of Children of age 0-6 years in Sardarshahar city is 14042 which is 15%
of the total population. There are 7398 male children and 6644 female children between the age
0-6 years. Thus as per the Census 2011 the Child Sex Ratio of Sardarshahar is 898 which is
less than Average Sex Ratio (931).
122. As per the Census 2011, the literacy rate of Sardarshahar is 74.1%. Thus Sardarshahar
has higher literacy rate compared to 66.8% of Churu district. The male literacy rate is 83.98%
and the female literacy rate is 63.54% in Sardarshahar.
123. Largest proportion of population comprises Hindus followed by Muslims and Jains. Main
languages spoken are Rajasthani, and Hindi.
124. In Sardarshahar Municipality out of total population, 27,695 were engaged in work
activities. 88.6% of workers describe their work as Main Work (Employment or Earning more
than 6 Months) while 11.4% were involved in Marginal activity providing livelihood for less than
6 months. Of 27,695 workers engaged in Main Work, 1,033 were cultivators (owner or co-
owner) while 612 were Agricultural labourer. (Source: Census of India 2011)
125. History: Churu district was founded in 1620 AD by the Nirban clan of Rajputs. Churu
was a part of Bikaner district before the Independence of India. In 1948, it was separated from
Bikaner when it was reconstituted.
126. The town was named after Maharaj Sardar Singh (1851 to 1872) who built a fort even
before his accession, in 1839.. He also built four bazaars known as Utradha, Aguna, Dakhinade
and Athuna along with the Fort. The digging and construction fo wells in various part of this
57
desert town as sources of drinking water, has played an important role in the growth of the town.
Wells names after Kalu Khan, Meena and Siyani were constructed in the year 1843in the
northern part of the town, for the use of the roaming tribes. Subsequently people settled around
these wells. Other important wells were also constructed from time to time. Jama Masjid was
constructed in the year 1863 in the north of the Utradha Bazar. The Railway line which came in
1916 in Sardarshahar and Ramnagar made important additions in the development of the town.
Subsequent developments were the old ginani in the west and Arjun club in the east of the
town. In the year 1930, when Ganga Golden Jubilees was celebrated, the area under Talai was
donated to MahantPrasram, with the condition that it would be kept as an open space. Rapid
development took place after Independence when Gandhi VidyaMandir was established in 1950
on the eastern fringe of the town. Electricity came in 1960. Bikaner bye-pass was constructed in
the year 1965 and some industrial units were established between 1971-1981. Large areas
under residential use were also added during this period.
127. Salasar Balaji Temple - Located in the town of Salasar near Sujangarh, SalasarBalaji is
the temple of Lord Hanuman. Fairs are organized every year on Chaitra Poornima and Ashwin
Poornima at SalasarBalaji temple. The place also houses Rani Sati temple and KhatuShyamji
temple as well. Salasar Balaji is also known by the name of Salasar Dham. SalasarBalaji is
about 80kms from Sardarshahar.
128. Tal Chhappar Sanctuary- Tal Chhappar sanctuary is located in the Shekhawati region of
the state of Rajasthan. The sanctuary is known for its rare blackbuck. The Tal Chhappar
sanctuary is located at the edge of the Thar desert on the Ratangarh-Sujangarh highway.
Geographically, the sanctuary falls in Sujangarh Tehsil of Churu and is an amusement place for
the visitors. The sanctuary is at a distance of 85 km from Churu city and at 75 km from
Sardarshahar.
129. Sewers and water supply pipes will be laid along the roads/streets in the town within the
road right of way (ROW). In wider roads pipes/sewers will be laid in the road shoulder beside
the tarmac, and in narrow roads, where there is no space, sewers will be laid in the road
carriage way by break opening the tarmac. Roads in some part of the town are narrow. Roads
are lined both sides with open drains. In narrow roads sewers will be laid in the middle of the
road, which may affect the traffic. Bigger diameter trunk sewers will be laid along the main
roads, which are wide and have adequate space. No tree cutting is anticipated as there is
adequate space to lay the water &sewer pipeline in those roads.
130. Proposed site of STP-1 (7.30 MLD) is near to existing STP at South Campus in vacant
Government land , which will be made available by municipal council for construction of
proposed STP. There is existing 5 MLD STP constructed under UIDSSMT, but is not
operational yet. There are few trees of ber, babool and khejri, which may be required to cut for
construction of proposed STP. There are no habitations near the proposed site. No wildlife is
reported in this area.
131. Proposed site of STP-2 (5.40MLD) is proposed near existing STP at North Campus is
vacant government land under Municipal Council. There is existing 2 MLD STP constructed
under UIDSSMT, which is not operational yet. There are no habitations near the proposed site.
No wildlife is reported in this area.
58
132. Proposed site of STP 3 (1.60 MLD) is proposed near Ashoke circle. The land belongs to
Gandhi Vidyamandir Trust Presently solid waste collected from city is being dumped here.
Some new settlements are established about 500 mtrs distance near the site. Some small
shrubs and bushes are present at site. Site is having undulating area and vacant. Approach
road is available on two sides of the site.
133. Proposed site of SPS 1 (2.30 MLD) is located in on land of Gaushala committee and
shall be made available by municipal council for construction of proposed SPS. There is BSNL
office near the proposed site. Kabristan is also present on the other side of the road. Few
scattered habitations also exist within 500 meters from this site. Some trees of babool are
present at site. Solid waste is being dumped here to level the land.
134. Proposed site of SPS 2 (0.65 MLD) is located in Zone 2 near Shyamdev Hotel on
Gaushala land and shall be made available by municipal council for construction of proposed
SPS. There are vacant lands and some agricultural fields near this land. Few scattered
habitations also exist within 100 meters from this site.
135. The CWR of (2400 Kl capacity) will be constructed within the existing CWR at
Hanumangarh Road. where enough space is available. No trees are present at the proposed
site .
A. Introduction
137. Screening of potential environmental impacts are categorized into four categories
considering subproject phases: location impacts and design impacts (pre-construction phase),
construction phase impacts and operations and maintenance phase impacts.
i. Location impacts include impacts associated with site selection and include loss of on-
site biophysical array and encroachment either directly or indirectly on adjacent
environments. It also includes impacts on people who will lose their livelihood or any
other structures by the development of that site.
ii. Design impacts include impacts arising from Investment Program design, including
technology used, scale of operation/throughput, waste production, discharge
specifications, pollution sources and ancillary services.
iii. Pre-construction impacts include impacts which are anticipated during construction
works but planning are required for proposed mitigation measures before start of
construction works i.e. during SIP period such as taking consents from various
departments, planning for construction and workers camps, deployment of safety officer,
arrangement of required barricades and caution boards etc.
iv. Construction impacts include impacts caused by site clearing, earthworks, machinery,
59
vehicles and workers. Construction site impacts include erosion, dust, noise, traffic
congestion and waste production.
v. O&M impacts include impacts arising from the operation and maintenance activities of
the infrastructure facility. These include routine management of operational waste
streams, and occupational health and safety issues.
138. Screening of environmental impacts has been based on the impact magnitude
(negligible/moderate/severe - in the order of increasing degree) and impact duration
(temporary/permanent).
139. This section of the IEE reviews possible project-related impacts, in order to identify
issues requiring further attention and screen out issues of no relevance. ADB SPS (2009)
require that impacts and risks will be analyzed during pre-construction, construction, and
operational stages in the context of the project's area of influence. The ADB Rapid
Environmental Assessment Checklist has been used to screen the project for environmental
impacts and to determine the scope of the IEE.
140. In the case of this project (i) most of the individual elements are relatively small and
involve straight forward construction and operation, so impacts will be mainly localized and not
greatly significant; (ii) most of the predicted impacts are associated with the construction
process, and are produced because that process is invasive, involving excavation and earth
movements; and (iii) being located in an urban area, will not cause direct impact on biodiversity
values. The project will be in properties held by the local government body and access to the
project location is through public rights-of-way and existing roads hence, land acquisition and
encroachment on private property will not occur.
B. Location Impacts
Location Impacts of Sewage Treatment Plants. Proposed site of STP-1 (7.30 MLD) is near
to existing STP at South Campus in vacant land which will be made available by municipal
council for construction of proposed STP. There is existing 5 MLD STP constructed under
UIDSSMT, which is not operational yet. There are no habitations near the proposed site more
than 500 mtrs. There are trees of ber, babool and khejri in abundance, which may be required to
be cut for construction of proposed STP. Mitigation measures as per RUIDP policy on
compensatory afforestation should be adopted
141. . Proposed site of STP-2 (5.40 MLD) is near existing STP at North Campus is vacant t
land under Municipal Council. There is existing 2 MLD STP constructed under UIDSSMT, which
is not operational yet. There are trees of ber, babool and khejri in abudance, which may be
required to cut for construction of proposed STP. Mitigation measures will be required as per
EMP, i.e. tree native trees for each cut tree shall be required to be planted by the contractor.
There are no habitations near the proposed site. No wildlife is reported in this area.
142. There are no habitations near the proposed site. No wildlife is reported in this area.
Proposed site of STP 3 (1.60 MLD) is located near Ashoke circle . The land is vacant. land and
belongs to Gandhi Vidyamandir Trust. Some new settlements and a temple/university are motre
tah 500 mtrs distance from r the site. Some small shrubs and bushes are present at site. Tree
60
cutting is not anticipated at this site. Mitigation measures will be required to avoid/reduce
impacts on the nearby residents and devotees/visitors of temple. Confirmation on availability of
STP 3 land near Ashoke circle is yet to be obtained from the owner Gandhi Vidyamandir Trust.
NagarPalika will provide land for STP for this project. Consent letter/NOC should be appended
in the IEE report once available.
143. The Contractor should ensure that the relevant consents from RPCB are obtained for
construction and operation of the STP and treated effluent should meet the parameters as set
by CPCB/RPCB. Contractor will also ensure compliances to all the conditions as mentioned in
the CTE.
144. Location Impacts of SPSs. Proposed site of SPS 1 (2.30 MLD) is located on
land which is under Gaushala Samiti and shall be made available by municipal council
for construction of proposed SPS. There is BSNL office and gochar land near the
proposed site. Kabristan is also present on the other side of the land. Few scattered
habitations also exist within 500 meters from this site. Mitigation measures will be
required to avoid/reduce impacts on the nearby residents. Some trees of babool are
present at site, which may be required to cut mitigation measures as per RUIDP policy
on compensatory afforestation should be adopted.
145. Proposed site of SPS 2 (0.65 MLD) is located in Zone 2 near Shyamdev Hotel on
Kamdhenu Gaushala land and shall be made available by municipal council for construction of
proposed SPS. There are vacant lands and some agricultural fields near this land. Few
scattered habitations also exist within 100 meters from this site.
146. The CWR and pump house are proposed in the Govt. land available with PHED. As for
preliminary survey some shrubs and bushes are present at site therefore tree cutting will not
be required during construction of CWR. There is no wildlife reported at this site.
147. Locations impacts of Water Supply Networks: The Water Supply transmission and
distribution networks will traverse through different city roads within ROW. Therefore no impacts
shall be envisaged regarding location. These works will require advance permission from
concerned authority for road cutting and traffic diversion etc. No wildlife reported in project
impact areas and no tree cutting will be required as per preliminary design and if any tree
cutting will be required during execution mitigation measures shall be adopted.
148. Locations impacts of Sewerage Networks: The sewerage collection networks will
traverse through different city roads within ROW. Therefore no impacts shall be envisaged
regarding location. These works will require advance permission from concerned authority for
road cutting and traffic diversion etc. No tree cutting will be required as per preliminary design
and if any tree cutting will be required during execution mitigation measures shall be adopted.
C. Design Impacts
149. Design of the Proposed Components. The Central Public Health and Environmental
Engineering Organization (CPHEEO) manual suggests a design period of 15/30 years 4 in
general while designing the systems for water supply and sewerage components. It is proposed
4
As per CPHEEO, pumps, motors, STP, storage reservoirs are to be designed for a life of 15 years.
61
to consider 2051 as the design year for all the components in order to maintain unanimity in the
design period and design population. Accordingly, 2017 shall be the base year and 2036 the
intermediate year to cross check the designs pertaining to intermediate demand. The rate of
water supply has been taken as 135 lpcd for 100% population. Sewage generation is 85% of
water supply (including 5% to account for infiltration).
150. One of the critical aspects in sewerage system operation is, change in raw sewage
characteristics at inlet of sewage treatment plant may affect the process and output quality.
STPs are designed for municipal wastewater, which does not include industrial effluent.
Characteristics of industrial effluent widely vary depending on the type of industry, and therefore
disposal of effluent into sewers may greatly vary the inlet quality at STP, and will upset process
and affect the efficiency. Although legally the disposal of effluent meeting certain standards is
allowed into municipal sewers (refer Appendix 4A), the monitoring of the same is not-practical.
151. To prohibit the industrial discharge in to municipal sewers following measures should be
considered:
No industrial wastewater shall be allowed to dispose into municipal sewers
No domestic wastewater from industrial units shall be allowed into municipal
sewers
Ensure that there is no illegal discharge through manholes or inspection chambers
Conduct public awareness programs; in coordination with RPCB, issue notice to all
industries for compliance
Conduct regular wastewater quality monitoring (at inlet and at outlet of STP) to
ensure that the treated wastewater quality complies with the national effluent
standards
152. Appropriate design of STP and pumping station are being adopted in the project which
includes energy efficient pumps and technology suitable for treatment and disposal of sewage.
Sequential Batch Reactor (SBR) is being adopted for sewage treatment which is the best
suitable technologies proven for such treatments and locations. Therefore, no design impacts
will arise from the proposed works.
153. Selection of pipe materials for Water Supply system: The pipe material proposed
for the Clear water transmission network is duly considering the durability of the material and
its strength to withstand the expected normal internal and external stresses. The selection of
pipe material has been done considering the parameters like: Ability to withstand internal /
external pressure, Ease in handling and lowering of pipes, Corrosion resistance, Pipe jointing
materials should be effective and reliable, Trouble-free maintenance operation should be
ensured, Availability of specials and fittings, Pipe roughness coefficient. Various available
alternates were compared during detail design like AC pipes, CC, DI and HDPE. AC pipes
were not adopted because those are banned by government due to carcinogenic risks and CC
pipes were not considered due to profuse leakages and heavy in handling. Therefore DI pipes
were considered for transmission and HDPE pipes were considered for distribution networks.
154. Treatment Process proposed for STP: Sewage Treatment Plants are basically
designed to treat the sewage to stipulated standards. Till the issue of stricter norms in April
2015, the most common treatment process adopted has been Conventional Activated Sludge
Process (ASP). Considering the presently applicable disposal norms, Sequencing Batch
Reactor (SBR) Process, which is similar to Conventional ASP but being a batch process it
62
permits sedimentation under quiescent condition resulting in final effluent containing lesser
amount of suspended solids and BOD. Further, as the process includes PLC controlled
operation, process is more power efficient.
155. The STP is based on SBR technology and is designed to meet the latest standards
defined in the CPCB Notification dated 21 April 2015 (refer Appendix 4A) as follows:
156. In this regard, it should be noted that National Green Tribunal in its order dated 21
December 2018 (Appendix 4A), stayed the implementation of “Effluent discharge standards for
Sewage Treatment Plant” by MOEF&CC Notification Dated 13th October 2017 that proposed
lower standards than those defined in the above table and hence is no longer applicable.
157. It is, therefore recommend that the proposed STP based on SBR process and the
treated effluent be disinfected using chlorination. As the treated effluent is planned to be reused
in agriculture and other gain purposes, therefore it is necessary that treatment should be done
as per standards mentioned above. Disinfection is also required and proposed before
discharge/reuse of treated effluent.
158. Design of Sewer system - collection & conveyance. The sewerage system is
designed as a separate system of sewage collection (i.e. caters only to domestic wastewater).
There is considerable length of existing surface drains in the project area that can be used for
disposal of storm runoff. The underground gravity sewers will carry sewage from households to
trunk sewers and further to STPs. To maximize the benefits as intended, Sardarshahar Nagar
Palika should ensure that all existing septic tanks are phased out by bypassing the inlet and
connecting the toilet discharge from each house directly to sewerage system.
159. Accumulation of silt in sewers in areas of low over time, overflows, blockages, power
outages, harmful working conditions for the workers cleaning sewers etc. are some of the issues
that needs to be critically looked into during the sewer system design. A properly designed
system is a must for system sustainability.
160. Measures such as the following shall be included in sewer system design to ensure that
the system provides the benefits as intended:
Limit the sewer depth where possible
Sewers shall be laid away from water supply lines and drains (at least 1 m,
wherever possible);
In all cases, the sewer line should be laid deeper than the water pipeline (the
difference between top of the sewer and bottom of water pipeline should be at
least 300 mm)
If unavoidable, where sewers are to be laid close to storm water drains,
appropriate pipe material shall be selected (stoneware pipes shall be avoided)
63
For shallower sewers and especially in narrow roads, use small inspection
chambers in lieu of manholes;
Design manhole covers to withstand anticipated loads & ensure that the covers
can be readily replace if broken to minimize silt/garbage entry
Ensure sufficient hydraulic capacity to accommodate peak flows & adequate slope
in gravity mains to prevent buildup of solids and hydrogen sulfide generation
Equip pumping stations with a backup power supply, such as a diesel generator, to
ensure uninterrupted operation during power outages, and conduct regular
maintenance to minimize service interruptions. Consider redundant pump capacity
in critical areas;
Highest Flood Level (HFL) should be used as a basis while deciding on the SPS
dimensions. Also, all the prevention methods including buffer capacity secondary
tank and alternative power arrangements should be implemented so that sewage
does not either leak during power outages or percolate into ground and pollute
ground water or any surface water bodies nearby.
D. Pre‐construction Impacts
161. Utilities. Telephone lines, electric poles and wires, water lines within the proposed
project locations may require to be shifted in few cases. To mitigate the adverse impacts due to
relocation of the utilities, the contractor, in collaboration with ULB will (i) identify the locations
and operators of these utilities to prevent unnecessary disruption of services during construction
phase; and (ii) instruct construction contractors to prepare a contingency plan to include actions
to be done in case of unintentional interruption of services.
162. Social and Cultural Resources. Any work involving ground disturbance can uncover
and damage archaeological and historical remains. For this project, excavation will occur in
project sites, so it could make no risk of such impacts on any archeological and historical
remains. Nevertheless, PIU will:
consult Department of Archaeology and Museums to obtain an expert assessment
of the archaeological potential of the site;
consider alternatives if the site is found to be of high risk;
include state and local archaeological, cultural and historical authorities, and
interest groups in consultation forums as project stakeholders so that their
expertise can be made available; and
develop a protocol for use by the construction contractors in conducting any
excavation work, to ensure that any chance finds are recognized and measures
are taken to ensure they are protected and conserved.
163. Site selection of construction work camps, stockpile areas, storage areas, and
disposal areas. Priority is to locate these near the project location. However, if it is deemed
necessary to locate elsewhere, sites to be considered will not promote instability and result in
destruction of property, vegetation, irrigation, and drinking water supply systems. Residential
areas will not be considered for setting up construction camps to protect the human
environment (i.e. to curb accident risks, health risks due to air and water pollution and dust, and
noise, and to prevent social conflicts, shortages of amenities, and crime). Extreme care will be
taken to avoid disposals near forest areas, water bodies, swamps, or in areas which will
inconvenience the community.
64
164. Site selection of sources of materials. Extraction of materials can disrupt natural land
contours and vegetation resulting in accelerated erosion, disturbance in natural drainage
patterns, ponding/water logging, and water pollution. To mitigate the potential environmental
impacts, locations of quarry site/s and borrow pit/s (for loose material other than stones) would
be assessed by PIU. Priority would be sites already permitted by Department of Mines and
Geology. If new sites are necessary, these would be located away from population centers,
drinking water intakes and streams, cultivable lands, and natural drainage systems; and in
structurally stable areas. It will be the construction contractor's responsibility to verify the
suitability of all material sources and to obtain the approval of Department of Mines & Geology
and local revenue administration. If additional quarries will be required after construction is
started, then the construction contractor shall use the mentioned criteria to select new quarry
sites, with written approval of PIU.
165. Debris disposal. Prior to the commencement of works, contractor shall identify a debris
disposal site in consultation with the PIU and Consultant. Contractor will follow all the prescribed
rules5during construction and adhering to following criteria (including but not limited to)
The site shall be selected preferably from barren, infertile lands. In case
agricultural land needs to be selected, top-soil stripping, stacking and preservation
should be undertaken prior to initiation of any activities.
The local governing body and community shall be consulted while selecting the
site.
Contractor shall prepare a construction and demolition waste management plan in
pre-construction phase for safe disposal of construction and demolition wastes as
per applicable rules and submit to Municipality through PIU for approval
Debris disposal site shall be at least 200 m away from surface water bodies6.
No residential areas shall be located within 100 m downwind side of the site.
The site is minimum 250 m. away from sensitive locations like hospitals, religious
places, ponds/lakes or other water bodies.
E. Construction Impacts
166. The civil works for the subproject include earth work excavation for sewer trenches,
sewer laying, construction manholes, shifting of public utilities and providing house service
connections. Earth work excavation will be undertaken by machine (backhoe excavator) and
include danger lighting and using sight rails and barricades at every 100 m., while sewer laying
works will include laying sewer at required gradient, fixing collars, elbows, tees, bends and other
fittings including conveying the material to work spot and testing for water tightness.
167. Laying of Sewer Networks. The maximum depth for sewers depends on the design,
and in Sardarshahar most of the sewers will be laid 1.2 to 3.5 m below the ground, and some
sewers will be laid deeper (> 2m)and maximum depth will be 11m (trenchless work). Sufficient
care will be taken while laying so that existing utilities and cables are not damaged and pipes
are not thrown into the trenches or dragged, but carefully laid in the trenches. Trenches deeper
than 2 m will be protected by bracings to avoid collapse of trenches, and also to avoid any risk
to surrounding buildings. Once they are laid, pipes will be joined as per specification and then
tested for any cracks of leakages. The minimum working hours will be 8 hours daily, the total
5Construction and Demolition Waste Management Rules 2016 (refer appendix 8)
6
In the absence of site meeting the stipulated criteria, an alternate site can be selected specifying the reasons. In
such a case, the construction camp management plan should incorporate additional measures specific to the site
as suggested by the Construction Manager.
65
duration of each stage depends on the soil condition and other local features. The excess
excavated soil shall be used for filling low lying area or stored/ dumped in approved debris
disposal sites.
168. Although construction of these project components involves quite simple techniques of
civil work, the invasive nature of excavation and the project locations in the built-up areas of the
town where there are a variety of human activities, will result in impacts to the environment and
sensitive receptors such as residents, businesses, and the community in general. The
anticipated impacts are temporary and for short duration.
169. Physical impacts will be reduced by the method of working and scheduling of work,
whereby the project components will be (i) constructed by small teams working at a time; (ii) any
excavation done near sensitive area like school, religious places and house will be protected as
per standard norms etc.
170. Construction of STPs and SPSs. STPs and SPSs are proposed in the land which are
under possession/identified by Nagar Palika. Construction impacts of these structures are the
common impacts of any construction works like site clearance, excavation, erection of
building/structures, health and safety of workers and nearby residents etc. which can be
mitigated as per the best practices prevailing in the country which includes but not limited to
health and safety arrangements for workers and nearby habitants, periodical maintenance of
construction equipment, protection of air, water and noise pollution due to construction works
etc. Contractor is required to adopt all the measures as per best international practice and
standards. Mitigation measures are given in EMP, which contractor is required to follow and
prepare EHS plan before start of construction works.
171. Proposed pipe line. A detail survey is needed after finalization of alignment to access
the feasibility of the alignment for need of any tree cutting, demolition of any structure, road and
railway crossings, pipe laying in any private land, presence of any sensitive receptor along
alignment, disturbance to public or business etc. Mitigation measures have been prepared for
potential adverse impacts. Prior consent from land owners (if pipe laying is required in private
land) and NOC from concerned departments (for pipe laying in roads, road/railway crossings
etc) prior to start of construction works, is required. To mitigate the impacts of disturbance to
road users during pipe laying works on road, it is strongly recommended that contractor dig only
those length of road, up to which extent he can lay pipe on the same day and can back fill the
trench and restore the road up to motorable conditions. All the safety measures for work on road
such as barricades, road signage, traffic assistance etc. is required to be adopted by contractor
during construction works. Further if night works are required (however unlikely, applicable only
in extreme conditions) all the mitigation measures to reduce impacts of disturbance to minimum
level to nearby habitants and road users should be ensured by contractor.
172. Demolition works. In the initial stage of project planning it is accessed that there is no
requirement of demolition of structures. If any demolition works are required, proper work plan
and Mitigation measures will be required for demolition works. Structures to be demolished
should be wetted through water sprinkling to reduce dust emission. Appropriate site for storage
and disposal of demolished materials should be selected prior to start of demolition activities
with prior permission/approval of PIU/ULB. All the safety measures should be adopted during
demolition activities.
173. Storage and Disposal of excavated earth. A large quantity of soil will be excavated for
pipe laying, construction of STPs and SPSs. Some part of this excavated soil will be reused for
66
backfilling and/or surface leveling; rest of the soil will need to be disposed in other locations.
Proper storage and disposal plan from contractor is required before start of the work. Prior
permission from land owner/concerned authority for storage and disposal of excess earth is
required. Prior to the commencement of works, Contractor will follow all the prescribed rules7
and shall identify a debris disposal site in consultation with the PIU/ULB and adhering to
following criteria:
The site shall be selected preferably from barren, infertile lands. In case
agricultural land needs to be selected, top-soil stripping, stacking and preservation
should be undertaken prior to initiation of any activities.
Debris disposal site shall be at least 200 m away from any surface water body.
No residential areas shall be located within 200 m downwind side of the site.
The site is minimum 250 m. away from sensitive locations like hospitals, religious
places, ponds/lakes or other water bodies.
The local governing body and community shall be consulted while selecting the
site.
Contractor is required to prepare plan for disposal of construction and demolition
waste including excavated earth in the designated site/sites and submit the plan in
PIU to be approved by Municipal Council as per Construction and Demolition
Waste Rules 2016
Soil storage site should be properly demarcated by fencing and information board
should be placed at entrance
At soil storage site soil should be covered by tarpaulin or regular water sprinkling
should be done to reduce dust emission
At soil disposal site the disposed soil should be leveled on daily basis and no heap
or mound should be left at end of the day
174. Sources of Materials. Significant amount of gravel, sand, coarse aggregate, and
cement will be required for this project. The construction contractor will be required to:
Use material sources permitted by government8;
Verify suitability of all material sources and obtain approval of PIU;
Ensure that the loading and unloading of the materials and the transportation of the
materials from source to construction site does not cause impact on health and
safety of the workers and the community; and
Submit to PIU on a monthly basis documentation of sources of materials. . If
contractor is purchasing ready mix concrete, asphalt/macadam and aggregates
from third party, contractor will assure that all the parties/ suppliers are having
CTE/CTO from RPCB and will collect the copy of these certificates and submit to
PIU/consultants
175. Air Quality. Emissions from construction vehicles, equipment, and machinery used for
excavation and construction will induce impacts on the air quality in the construction sites.
Anticipated impacts include dusts and increase in concentration of vehicle-related pollutants
such as carbon monoxide, sulfur oxides, particulate matter, nitrous oxides, and hydrocarbons.
These however will be temporary limiting to construction activities only. To mitigate the impacts,
7
Construction and Demolition Waste Management Rules 2016 and Solid Waste Management Rules (refer appendix
8)/ Table 1
8 CTE and CTO will be required for batching plant, hot mix plant, crushers etc. if specifically established for this
project. If contractor is purchasing raw material or ready mix concrete, asphalt/macadam and aggregates from third
party, he has to be assured that third party is having CTE/CTO from RPCB and should collect the copy of these and
submit to PIU/consultants. Quarry sites should also have the desired permissions.
67
176. Surface Water Quality. There are no surface water sources in the town, however, run-
off from stockpiled materials and chemical contamination from fuels and lubricants during
construction works can contaminate the drainage system of town. These potential impacts are
temporary and short-term duration only. However, to ensure that these are mitigated,
construction contractor will be required to:
Prepare and implement a spoils management plan;
Avoid to construct any construction camps and labour camps away from any water
body and do not allow to dispose any waste or sullage in to any water body
Avoid stockpiling of earth fill especially during the monsoon season unless covered
by tarpaulins or plastic sheets;
Prioritize re-use of excess spoils and materials in the construction works. If spoils
will be disposed, consult with PIU on designated disposal areas;
Install temporary silt traps or sedimentation basins along the drainage leading to
the water bodies;
Place storage areas for fuels and lubricants away from any drainage leading to
water bodies and provide impermeable lining under the storage yard of fuels and
lubricants
Dispose any wastes generated by construction activities in designated sites;
Keep oil tray or pans under the DG set or during maintenance of mechanical
equipment to avoid oil spillage resulting soil and water pollution, and
Conduct surface water quality Monitoring according to the Environmental
Management Plan (EMP)
177. Noise and Vibration Levels. Construction works will be conducted along the roads in
Sardarshahar urban area, where there are majorly houses, commercial activities, few religious
places and small-scale businesses. The sensitive receptors are the schools, religious places,
hospitals in these areas. Increase in noise level may be caused by excavation, particularly
breaking of cement concrete or bitumen roads, operation of construction equipment like
concrete mixers, and the transportation of equipment, materials, and people. Vibration
generated from construction activity, for instance from the use of pneumatic drills, will have
68
impact on nearly buildings. This impact is negative but short-term, and reversible by mitigation
measures. The construction contractor will be required to:
Plan activities in consultation with PIU so that activities with the greatest potential
to generate noise are conducted during periods of the day which will result in least
disturbance;
Use road cutters instead of breaker/hammer for cutting the road before excavation
for pipe laying on roads
Horns should not be used unless it is necessary to warn other road users or
animals of the vehicle’s approach;
Minimize noise from construction equipment by using vehicle silencers, fitting
jackhammers with noise-reducing mufflers, and use portable street barriers to
minimize sound impact to surrounding sensitive receptor;
DGs being used at site should have sound reducing (acoustic) enclosures,
preferably silent DGs should be used at site;
Maintain maximum sound levels not exceeding 80 decibels (dBA) when measured
at a distance of 10 m or more from the vehicle/s and equipments;
Identify any buildings at risk from vibration damage and avoiding any use of
pneumatic drills or heavy vehicles in the vicinity;
Consult the custodians of important buildings, cultural and tourism authorities and
local communities in advance of the work to identify and address key issues, and
avoid working at sensitive times, such as religious and cultural festivals;
Provide all workers appropriate PPEs like ear plug/muff, working in high noise
conditions;
Keep all vehicles and equipment in good conditions to avoid excessive noise
generation;
Provide noise barriers near sensitive receptors like schools, hospitals, temples,
courts etc and consult in advance with sensitive receptors about the working hours
(specially schools, hospitals, offices, courts etc) and avoid noisy works in those
hours;
Avoid noisy works in nights in inhabited areas to avoid any disturbance to
habitants; and
Consult in advance with habitants and inform them about the nature and duration
of works
Conduct noise monitoring according to the Environmental Management Plan
(EMP)
178. Management Plan for Night works (if required). Following requirements should be
fulfilled for construction works at night hours-
(i) Night works should be avoided at construction sites specially in residential areas
and should be performed only when day works are not possible due to excessive
traffic/public/pedestrian movement, site of cultural or religious importance, where
there is huge crowd during day hours or any other unavoidable circumstances.
(ii) Contractor should plan for night works only after directions from PMU/PIU/DSC
(iii) Contractor should submit plan for night works for approval from PIU.
(iv) PIU should ensure that prior written information should be given to local authorities
such as district administration, Police/traffic police, line agencies concerned,
residents welfare association/business association/vyaparmandal of the affected
areas and their consents/permissions should be taken prior to start of night works.
69
(v) PIU/DSC engineers should check and ensure that all the preparation as per
management plan is done by contractor and contractor is having all the necessary
equipment and materials for night works.
(vi) Contractor is required to have following equipment/arrangements for night works-
Contractors should have hand held noise level meter for measurement of noise
during night hours
Contractors should have hand held lux meter for the measurement of
illumination during night hours
Preferably electrical connections is available for running equipment otherwise
sound proof/super silent Diesel Generator set should be available
Sound level should not increase as per following-
Type of area of work Maximum noise level dB(A)
Industrial 70
Commercial 55
Residential 45
Silence zone 40
Old persons and pregnant women and women having small kids should not
work in night time
All the vehicles and equipment being used at night works should have adequate
type of silencers/enclosures/mufflers to reduce noise
All the vehicles should be checked for working head lamps, tail lamps, inner
lights etc. before start of night works
(vii) PIU/DSC site engineers and contractors safety personnel should closely
monitor the safety of works continuously and noise and illumination levels on
hourly basis and maintain photographic and videographic records as well as
register the observations
(viii) Night works should be stopped early in the morning at least one hour before
start of pedestrian/traffic movement
(ix) After completion of night works all the site should be cleaned and maintained
obstruction free for day time movement of vehicles and pedestrians
(x) Drivers and workers should be alert and responsive during night works
(xi) All the wages to workers working in night hours should be as per the applicable
labour acts
(xii) Avoid any nuisance which may create problems to nearby habitants and work
peacefully during night hours
(xiii) Night works should not be conducted near hospitals and during peak seasons
such as peak tourist season, students’ exam times etc.
179. Landscape and Aesthetics. The construction works may require cutting of trees and
also will produce excess excavated earth, excess construction materials, and solid waste such
as removed concrete, wood, packaging materials, empty containers, spoils, oils, lubricants, and
other similar items. Haphazard disposal of these will have negative impacts on landscape and
overall aesthetics. These impacts are negative but are of short-term and reversible by mitigation
measures. The construction contractor will be required to:
Prepare and implement spoils management plan;
Avoid stockpiling of excess excavated soils;
Coordinate with ULB for beneficial uses of excess excavated soils or immediately
dispose to designated areas;
Recover used oil and lubricants and reuse or remove from the sites;
Manage solid waste according to the following preference hierarchy: reuse,
recycling and disposal to designated areas;
Minimize removal of vegetation and disallow cutting of trees;
If tree-removal will be required, obtain tree-cutting permit from the Revenue
Department; and
Plant three native trees for every one that is removed.
Remove all wreckage, rubbish, or temporary structures which are no longer
required; and
Request PIU to report in writing that the necessary environmental restoration work
has been adequately performed before acceptance of work.
180. Groundwater Quality. Another physical impact that is often associated with excavation
is the effect on drainage and the local water table if groundwater and surface water collect in the
voids. Although, groundwater is much deeper than the proposed trenching depth, and rains are
scarce and limited to very short duration during monsoon, to ensure that water will not pond in
pits and voids near project location, the construction contractor will be required to conduct
71
excavation works in non-monsoon season to the maximum extent possible. These potential
impacts are temporary and short-term duration only. However, to ensure that these are
mitigated, construction contractor will be required to:
Prepare and implement a spoils management plan (Appendix 8);
Avoid stockpiling of earth fill especially during the monsoon season unless covered
by tarpaulins or plastic sheets;
Prioritize re-use of excess spoils and materials in the construction works. If spoils
will be disposed, consult with PIU on designated disposal areas;
Install temporary silt traps or sedimentation basins along the drainage leading to
the water bodies;
Place storage areas for fuels and lubricants away from any drainage leading to
water bodies;
Dispose any wastes generated by construction activities in designated sites; and
Conduct periodical ground water quality monitoring according to the Environmental
Management Plan (EMP).
181. Accessibility. Excavation along the roads, hauling of construction materials and
operation of equipment on-site can cause traffic problems. Potential impact is negative but short
term and reversible by mitigation measures. The construction contractor will be required to:
Prepare and implement a Traffic Management Plan (Appendix 9)
Plan transportation routes so that heavy vehicles do not use narrow local roads,
except in the immediate vicinity of delivery sites;
Schedule transport and hauling activities during non-peak hours;
Locate entry and exit points in areas where there is low potential for traffic
congestion;
Keep the site free from all unnecessary obstructions;
Drive vehicles in a considerate manner;
Coordinate with Traffic Police for temporary road diversions and for provision of
traffic aids if transportation activities cannot be avoided during peak hours; and
Notify affected sensitive receptors by providing sign boards informing nature and
duration of construction works and contact numbers for concerns/complaints.
182. Wherever road width is minimal, there will be temporary loss of access to restrains and
vehicular traffic (including 2-wheelers) during the laying of pipes. Under those circumstances,
contractor shall adopt following measures:
Inform the affected local population 1-week in advance about the work schedule
Plan and execute the work in such a way that the period of disturbance/ loss of
access is minimum.
Provide pedestrian access in all the locations until normalcy is restored. Provide
wooden/metal planks over the open trenches at each house to maintain the
access.
183. Socio-Economic - Income. The project components will be located in government land
and there is no requirement for land acquisition or any resettlement. Construction works will
impede the access of residents to specific site in limited cases. The potential impacts are
negative and moderate but short-term and temporary. The construction contractor will be
required to:
Prepare and implement spoils management plan (Appendix 8);
Leave spaces for access between mounds of soil;
72
Provide walkways and metal sheets where required to maintain access across for
people and vehicles;
Increase workforce in the areas with predominantly institutions, place of worship,
business establishment, hospitals, and schools;
Consult businesses and institutions regarding operating hours and factoring this in
work schedules; and
Provide sign boards for pedestrians to inform nature and duration of construction
works and contact numbers for concerns/complaints.
Notify community/ water users in advance about likely interruptions in water
supply.
Provide alternate sources of clean water until water supply is restored.
Provide all mitigation measures as given in resettlement plan (RP) prepared for the
project to mitigate impacts on vendors and shopkeepers
185. Occupational Health and Safety. Workers need to be mindful of the occupational
hazards which can arise from working on roads, in height and excavation
(trenches and trenchless) works. Potential impacts are negative and long-term but reversible by
mitigation measures. Construction contractor will depute experienced EHS personnel and will
be required to:
Comply with all national, state and local labor laws (see Appendix 7);
Develop and implement site-specific occupational health and safety (OH&S) Plan
which will include measures such as: (a) excluding public from the site; (b)ensuring
all workers are provided with and use personal protective equipment;(c) OH&S
Training9 for all site personnel; (d) documented procedures to be followed for all
site activities; and (e) documentation of work-related accidents;
Ensure that qualified first-aid is provided at all times. Equipped first-aid stations
shall be easily accessible throughout the site;
Provide medical insurance coverage for workers;
Secure all installations from unauthorized intrusion and accident risks;
The project area experiences extreme temperature during summer months of April
and May, which may affect the health of workers engaged in construction work.
Contractor should take necessary measures during summers including the
following:
a. Work schedule should be adjusted to avoid peak temperature hours (12 -3
9
Some of the key areas that may be covered during training as they relate to the primary causes of accidents include (i) slips, trips
and falls; (ii) personal protective equipment; (iii) ergonomics, repetitive motion, and manual handling; (iv) workplace transport;
and (v) legislation and responsibilities. Training can provide the foundations of competence but it does not necessarily result in a
competent worker. Therefore, it is essential to assess staff competence to ensure that the training provided is relevant and
effective. Supervision and monitoring arrangements shall be in place to ensure that training has been effective and the worker is
competent at their job. The level of supervision and monitoring required is a management decision that shall be based on the
risks associated with the job, the level of competence required, the experience of the individual and whether the worker works as
part of a team or is a lone worker.
73
PM)
b. Provide appropriate shade near the work place; allow periodic resting and
provide adequate water
c. Provide necessary medicine and facilities to take care of dehydration related
health issues
Provide supplies of potable drinking water;
Provide clean eating areas where workers are not exposed to hazardous or
noxious substances;
Provide H&S orientation training to all new workers to ensure that they are
apprised of the basic site rules of work at the site, personal protective protection,
and preventing injuring to fellow workers;
Provide visitor orientation if visitors to the site can gain access to areas where
hazardous conditions or substances may be present. Ensure also that visitor/s do
not enter hazard areas unescorted;
Ensure the visibility of workers through their use of high visibility vests when
working in or walking through heavy equipment operating areas;
Ensure moving equipment is outfitted with audible back-up alarms;
Mark and provide sign boards for hazardous areas such as energized electrical
devices and lines, service rooms housing high voltage equipment, and areas for
storage and disposal. Signage shall be in accordance with international standards
and be well known to, and easily understood by workers, visitors, and the general
public as appropriate; and
Disallow worker exposure to noise level greater than 85 dBA for duration of more
than 8 hours per day without hearing protection. The use of hearing protection
shall be enforced actively.
10 In the USA, standards and approaches for handling asbestos are prescribed by the Occupational Health and
Safety Administration (OHSA) and the Environmental Protection Agency (EPA) and can be found at
http://www.osha.gov/SLTC/asbestos
74
188. Central part of the town is characterized by narrow roads. Particularly, the areas located
in old town have very narrow roads with dense habitation and heavy traffic and are accessible
only to pedestrians. Besides impeding the access, the trench excavation and pipe laying will
pose safety risks to pedestrians, and the people living in these areas. Though the width (<500
mm) and depth (<750mm) of trench is minimal, it will pose safety risk, especially for children and
elders The construction contractor will be required to:
Provide prior information to the local people about the nature and duration of work
Conduct awareness program on safety during the construction work
Undertake the construction work stretch-wise; excavation, pipe laying and trench
refilling should be completed on the same day
Provide barricades, and deploy security personnel/traffic marshal to ensure safe
movement of people and also to prevent unnecessary entry and to avoid
accidental fall into open trenches
189. Work Camps. Operation of work camps can cause temporary air and noise pollution
from machine operation, water pollution from storage and use of fuels, oils, solvents, and
lubricants. Potential impacts are negative but short-term and reversible by mitigation measures.
The construction contractor will be required to:
Consult PIU before locating project offices, sheds, and construction plants;
Minimize removal of vegetation and disallow cutting of trees;
Provide safe drinking water, water for other uses, and sanitation facilities for
employees;
Periodically test the drinking water supplied to workers from external agency and
submit test report to PIU
Ensure conditions of liveability at work camps are maintained at the highest
standards possible at all times;
Prohibit employees from poaching wildlife and cutting of trees for firewood;
Train employees in the storage and handling of materials which can potentially
cause soil contamination;
Recover used oil and lubricants and reuse or remove from the site;
Manage solid waste according to the following preference hierarchy: reuse,
recycling and disposal to designated areas;
Conduct periodical soil quality and ground water quality monitoring at construction
camps/storage yard as per EMP and submit report to PIU
75
190. Social and Cultural Resources. For this project, excavation will occur at locations not
known to have archaeological values, so there is no risk of such impacts. Nevertheless, the
construction contractor will be required to:
Strictly follow the protocol for chance finds in any excavation work;
Request PIU or any authorized person with archaeological/historical field training
to observe excavation;
Stop work immediately to allow further investigation if any finds are suspected;
Inform PIU/ACM if a find is suspected, and take any action they require ensuring
its removal or protection in situ.
Adjacent to religious/historic sites, undertake excavation and construction work in
such a way that no structural damage is caused to the building.
191. Traffic diversion and/or road closure-If traffic diversion and/or road closure is required
for the proposed works, prior consent from traffic department will be required and prior
information to affected areas and public should be disseminated through consultations by
CAPC. Proper road signage and traffic aids should be provided at site. Excavation along the
roads, hauling of construction materials and operation of equipment on-site can cause traffic
problems. Potential impact is negative but short term and reversible by mitigation measures.
The construction contractor will be required to:
Prepare and implement a Traffic Management Plan
Plan transportation routes so that heavy vehicles do not use narrow local roads,
except in the immediate vicinity of delivery sites;
Schedule transport and hauling activities during non-peak hours Locate entry and
exit points in areas where there is low potential for traffic congestion;
Keep the site free from all unnecessary obstructions;
Drive vehicles in a considerate manner;
Coordinate with Traffic Police for temporary road diversions and for provision of
traffic aids if transportation activities cannot be avoided during peak hours; and
Notify affected sensitive receptors by providing sign boards informing nature and
duration of construction works and contact numbers for concerns/complaints.
Maintain sufficient access to houses and shopkeepers (commercial
establishments) during pipe laying work through metal sheets and temporary
bridges
Locate entry and exit points in areas where there is low potential for traffic
congestion;
192. Wherever road width is minimal, there will be temporary loss of access to pedestrians
and vehicular traffic including two wheelers during the laying of pipes. Under those
circumstances, contractor shall adopt following measures:
Inform the affected local population 1-week in advance about the work schedule
Plan and execute the work in such a way that the period of disturbance/ loss of
access are minimum.
Provide pedestrian access in all the locations until normalcy is restored. Provide
wooden/metal planks over the open trenches at each house to maintain the access
76
Excavate only that stretch in a day that could be finished in the same day by laying
of pipes and backfilling
193. Operation and Maintenance of the water supply and sewerage system will be carried out
by DBO contractor for 10 years and then directly by Sardarshahar Nagar Palika. The system
have a design life of 30 years, during which shall not require major repairs or refurbishments
and should operate with little maintenance beyond routine actions required to keep the
equipment in working order. The stability and integrity of the system will be monitored
periodically to detect any problems and allow remedial action if required. Any repairs will be
small-scale involving manual, temporary, and short-term works involving regular checking and
recording of performance for signs of deterioration, servicing and replacement of parts.
194. The Contractor should obtain the relevant consents from RPCB for operation of STP and
the treated effluent should meet the parameters as set by CPCB/RPCB. Contractor will also
ensure compliances to all the conditions as mentioned in the CTO.
195. Safe disposal of treated effluent and sludge from STP: In conventional treatment
process, risks from STP operation are mainly hazards of disposal of treated effluent and
sludge in unscientific manner and risk of infection due to these. Under proposed project,
treated effluent from STP will be reused in beneficial purposes and a plan shall be
developed by Municipal council for beneficial uses of treated effluent. Treated effluent shall
meet the minimum criteria set by RPCB/CPCB/MOEF&CC and disinfected treated effluent
shall be stored in elevated service reservoir for further reuse under this project. Towards
aiding the Municipality finalize an appropriate approach for treated effluent reuse, the
project shall carryout a capacity building activity to enable the Municipal Engineers develop
an appropriate knowledge and skills on the matter. Digested and disinfected sludge can be
used as manure (as quality of sludge from SBR process can be used in agriculture
practices after testing of sludge for toxicity and heavy metals), keeping in mind that there
are vast agricultural practices nearby the STP site. While sludge reuse can be promoted
under the project so far no designs or plan of action has been proposed. Hence, along with
the capacity building activity for the Municipality Engineers on the treated wastewater reuse,
appropriate knowledge and skills on sludge management and reuse shall be provided.
Such training shall enable the Municipality Engineers to participate in the decision making
process. Guidelines for reuse of treated effluent and sludge and its safe handling and
disposal are given in Appendix-17.
196. Contractor will propose the plan with best methods for reuse of treated effluent and
sludge as per guidelines of CPHEEO (guidelines are attached as Appendix 17) and best
practices in consultation with RUIDP and Municipality and submit it to RUIDP for approval.
197. Repair works could cause some temporary disruption of activities at the point of
sensitive receptors i.e. locations of social and cultural importance such as schools, hospitals,
churches, tourist sites etc., so the same precautions as employed during the construction period
should be adopted. ULB needs to:
Identify any buildings at risk from vibration damage and avoiding any use of
pneumatic drills or heavy vehicles in the vicinity;
77
198. There are also certain environmental risks from the operation of the sewer system, most
notably from leaking sewer pipes as untreated faecal material can damage human health and
contaminate both soil and groundwater. It will be imperative therefore that the operating agency
establishes a procedure to routinely check the operation and integrity of the sewers, and to
implement rapid and effective repairs where necessary. There is an occupation health risk to
workers engaged in sewer maintenance activities. Following measures should be followed:
Establish regular maintenance program, including:
• Regular cleaning of grit chambers and sewer lines to remove grease, grit, and
other debris that may lead to sewer backups. Cleaning should be conducted
more frequently for problem areas.
• Inspection of the condition of sanitary sewer structures and identifying areas that
need repair or maintenance. Items to note may include cracked/deteriorating
pipes; leaking joints or seals at manhole; frequent line blockages; lines that
generally flow at or near capacity; and suspected infiltration or exfiltration; and
• Monitoring of sewer flow to identify potential inflows and outflows
• Conduct repairs on priority based on the nature and severity of the problem.
Immediate clearing of blockage or repair is warranted where an overflow is
currently occurring or for urgent problems that may cause an imminent overflow
(e.g. pump station failures, sewer line ruptures, or sewer line blockages);
Review previous sewer maintenance records to help identify "hot spots" or areas
with frequent maintenance problems and locations of potential system failure, and
conduct preventative maintenance, rehabilitation, or replacement of lines as
needed;
When a spill, leak, and/or overflow occurs, keep sewage from entering the storm
drain system by covering or blocking storm drain inlets or by containing and
diverting the sewage away from open channels and other storm drain
facilities(using sandbags, inflatable dams, etc.). Remove the sewage using
vacuum equipment or use other measures to divert it back to the sanitary sewer
system.
Prohibit/prevent disposal of wastewater/effluent from industrial units in the sewers;
ensure regular checking to ensure no illegal entry of industrial wastewater into
sewers
Develop an Emergency Response System for the sewerage system leaks, burst
and overflows, etc.
Provide necessary health & safety training to the staff in sewer cleaning
&maintenance
Provide all necessary personnel protection equipment
For personnel cleaning underground sewers there is a risk due to oxygen
deficiency and harmful gaseous emissions (hydrogen sulphide, carbon monoxide,
methane, etc.); provide for adequate equipment (including oxygen masks) for
emergency use
199. The Contractor should ensure that the relevant consents from RPCB are obtained for
operation of STP and treated effluent should meet the parameters as set by CPCB/RPCB.
Contractor will also ensure compliances to all the conditions as mentioned in the CTO Latest
78
standards for discharge of effluent are given in Appendix 4A. Municipality should have
responsible supervision of the effluent discharge standards
200. There is an occupation health risk to workers engaged in sewer maintenance activities.
During cleaning/clearing of manholes and sewer lines great precautions should be taken for the
safety of workers conducting such works. Therefore O&M contractor will be required to-
As for as possible use CCTV mechanism to detect the problems in pipe lines and
do not engage persons for this purpose
As far as possible use mechanized cleaning of manholes and pipe lines by using
modern techniques and machines and do not engage persons for this purpose and
engage persons only if mechanized cleaning is not possible in any way
Ensure that employees and line management understand the risks through proper
instruction, training and supervision.
Use gas detector before entering any person inside manhole to detect any
hazardous or inflammable gas present inside the manhole.
Provide suitable personal protective equipment that may include waterproof /
abrasion-resistant gloves, footwear, eye and respiratory protection. Face visors are
particularly effective against splashes. Equipment selection and a proper system
for inspection and maintenance are important.
Provide adequate welfare facilities, including clean water, soap, nail brushes,
disposable paper towels, and where heavy contamination is foreseeable, showers.
For remote locations portable welfare facilities should be provided.
Areas for storage of clean and contaminated equipment should be segregated and
separate from eating facilities.
Provide adequate first-aid equipment, including clean water or sterile wipes for
cleansing wounds, and a supply of sterile, waterproof, adhesive dressings.
Make effective arrangements for monitoring the health of staff.
Keep emergency preparedness plan ready before start the work of sewage system
cleaning
201. Recurrence of pipe bursting and leakage problems in water supply can be managed by
the leak detection and water auditing surveys. The ULB will be required to ensure that the leak
detection and rectification time is minimized.
202. Improper disposal of silt and debris removed from trenches could cause inconvenience
to public. Silt and debris shall be collected in trucks and transported to the approved disposal
site or can be used as covering material for wastes being landfilled.
203. Septic Tank Closure Plan: The project shall enable a majority of the households
connect to the sewerage network. However, the existing septic tank system that is being used
by the residents should be closed appropriately. This is to prevent the contamination of
groundwater or surface water or land resulting from improperly closed septic tank system or
septic tank failure. Effective and proper closure of septic tanks can be achieved when the
sullage present in the system is emptied into a larger mobile tank which is later sent to the
treatment plant for effective treatment. Later, the walls of the septic walls should be removed
and disposed as construction debris appropriately. Subsequently, the empty septic tank pit
should be filled with stone, coarse and fine sand material to complete the septic tank closure.
Towards this, the ULB should establish a mechanism by which the household owners can hire
recognized service providers to perform effective septic tank closures and the ULB can issue a
closure permit after inspection.
79
204. Potable water for the Sardarshahar city will available from two main sources i.e.
Groundwater source (Tube wells) and Surface water of IGNP through sawarsat minor canal.
Sardarshahar is within ‘Safe’ category in terms of Groundwater withdrawal. Fluoride in
groundwater of this region is high mainly due to dissolution from fluoride-bearing
minerals like hornblende and illite. The arid climate with high evaporation and
insignificant natural recharge might have accelerated the strengthening of fluoride
concentration in the groundwater of this area. Fluoride is above the permissible limit of
1.5mg/l in both the samples. However Blending of TWs Water and Surface Water shows that
fluoride content is below the permissible limit after blending,
205. The citizens of the Sardarshahar will be the major beneficiaries of the improved water
supply and sewerage system, as the human waste from the homes will be removed rapidly,
which otherwise would flow in open drains. In addition to improved environmental conditions,
the project will improve the over-all health condition of the town as diseases due to poor
sanitation such as diarrhea and dysentery will be reduced. This should improve the
environment, should deliver major improvements in individual and community health and well-
being. Therefore people should spend less on healthcare and lose fewer working days due to
illness, so their economic status should also improve, as well as their overall health.
206. The active participation of stakeholders including local community, NGOs/CBOs, and the
media in all stages of project preparation and implementation is essential for successful
implementation as well as operation of the project. It will ensure that the subprojects are
designed, constructed, and operated with utmost consideration to local needs, ensures
community acceptance, and will bring maximum benefits to the people. Public consultation and
information disclosure is a must as per the ADB policy.
207. A three tier consultation process has been adopted for Phase-IV project: focus group
discussions, primary household sample surveys and a town-level public consultation workshop.
Most of the main stakeholders have already been identified and consulted during preparation of
preliminary design and IEE, and any others that are identified during project implementation will
be brought into the process in the future. Primary stakeholders of the subproject are: residents,
shopkeepers and businesspeople who live and work alongside the roads in which network
improvements will be provided, and government and utility agencies responsible for provision of
services, Sardarshahar Nagar Palika, Public Health Engineering Department, and Rajasthan
Pollution Control Board. Secondary stakeholder are: NGOs and CBOs working in the area,
community representatives, beneficiary community in general, government agencies, the
executing and implementing agencies (LSGD and RUIDP), Government of India and the ADB.
B. Public Consultation
208. The public consultation and disclosure program is a continuous process throughout the
project implementation, including project planning, design and construction. Social impact
assessment (SIA) was conducted in August, 2018. Informal and formal consultations at sites
80
were also conducted during SIA in Sardarshahar on 28 August 2018. (Appendix 10).
209. Institutional consultations were conducted with the Governmental Departments such as
Local Self Government Department, Public Works Department, Pollution Control Board, Public
Health Engineering Department, Sardarshahar Nagar Palika, etc. The project proposals are
formulated in consultation with Sardarshahar Nagar Palika and the proposals have been
finalized only after certification of Nagar Palika that the proposals suit the requirements of the
ULB.
210. Focus-group discussions with residents and other stakeholders were conducted to learn
their views and concerns. A SIA has been conducted in the town, covering sample households
and nearby vendors to understand the basic characteristics of town, health status, and the
infrastructure service levels, and also the demand for infrastructure services. General public and
the vendors along the project activity areas (roads) were also consulted during visits to the
project sites.
211. It was observed that people are willing to extend their cooperation as the proposed
activities are supposed to enhance the infrastructure service levels and the living standard of
the public. The public expressed their concern regarding the nuisance and disturbance (dust,
road closure and traffic management activities) during the construction stage which can have
impact on their day to day activities. Public demanded for advance notice before construction
and proper warning signs along the construction area to avoid accidents and inconvenience.
Public opined that an appropriate operation and maintenance system should be in place,
especially for sewerage system, for its best functioning and to have the maximum health and
aesthetic benefits.
212. A town-level City Level Committee (CLC)has been formed in Churu district by
Government orders. City Level Committee meeting was organized during the detailed design
stage to which representatives of primary and secondary stakeholders were invited. City
stakeholder committee meeting was organized in district headquarter Churu on dtd. 13.07.2018
to discuss the matter of proposed water supply and sewerage works in Sardarshahar under the
chairmanship of District Collector, Churu in presence of public representatives, consultants,
RUIDP officials, PHED/ Municipal officials, NGOs and other invitee members. Proposed scope
of works and technology was discussed in the meeting. Land availability for the proposed
components was also confirmed by local authority. The feedback and concerns of the
stakeholders were taken into consideration for finalization of design and scope of works. The
project was agreed by the committee for further course of action of RUIDP. Details of CLC
meeting, minutes and photographs are attached in Annexure 10.
213. Prior to start of construction, Sardarshahar Nagar Palika and PIU with the assistance of
Consultants will conduct information dissemination sessions at major intersections and solicit
the help of the local community leaders/prominent citizens to encourage the participation of the
people to discuss various social and environmental issues. At each ward/neighborhood level,
focus group meetings will be conducted to discuss and plan construction work with local
communities to reduce disturbance and other impacts, and provide a mechanism through which
81
214. A constant communication will be established with the affected communities to redress
the environmental issues likely to surface during construction and operational phases and also
regarding the grievance redress mechanism. Nagar Palika/PIU with the help of Community
Awareness and Participation Consultant (CAPC) will organize public meetings and will appraise
the communities about the progress on the implementation of EMP. Meeting will also be
organized at the potential hotspots/sensitive locations before and during the construction.
C. Information Disclosure
215. Executive summary of the IEE will be translated in the local language and made
available at the offices of Nagar Palika, RUIDP PMU and PIU. Copies of summary will be
provided to participants of city level workshop to be organized in Sardarshahar. Hard copies of
the IEE will be accessible to citizens as a means to disclose the document and at the same time
creating wider public awareness. Electronic version of the IEE in English and Executive
Summary in Hindi will be placed in the official website of the Nagar Palika/RUIDP after approval
of the IEE by Government and ADB. Stakeholders will also be made aware of grievance register
and redress mechanism.
216. Public information campaigns via newspaper/radio/TV, to explain the project details to a
wider population will be conducted. Public disclosure meetings will be conducted at key project
stages to inform the public about the progress and future plans. Prior to start of construction, the
PIU will issue Notification on the start date of implementation in local newspapers A board
showing the details of the project will be displayed at the construction site for the information of
general public.
219. Common GRM. A common GRM will be in place for social, environmental, or any other
grievances related to the project; the resettlement plans (RPs) and IEEs will follow the GRM
described below. The GRM will provide an accessible and trusted platform for receiving and
facilitating resolution of affected persons' grievances related to the project. The multi-tier GRM
for the project is outlined below, each tier having time-bound schedules and with responsible
persons identified to address grievances and seek appropriate persons' advice at each stage,
as required. ULB-wide public awareness campaigns will ensure that awareness on grievance
redress procedures is generated through the campaign. PIU Assistant Safeguards Officer
(ASO) through Community Awareness and Participation Consultant (CAPC) will conduct ULB-
wide awareness campaigns to ensure that poor and vulnerable households are made aware of
grievance redress procedures and entitlements.
220. APs will have the flexibility of conveying grievances/suggestions by dropping grievance
redress/suggestion forms in complaints/suggestion boxes will be installed by project ULBs or
bye-mail, by post, or by writing in a complaints register in ULB/PIU offices. Appendix 13 has the
sample grievance registration form. Careful documentation of the name of the complainant, date
of receipt of the complaint, address/contact details of the person, location of the problem area,
and how the problem was resolved will be undertaken. The PMU Project Officers
(Environment& Social) will have the overall responsibility for timely grievance redress
respectively on environmental and social safeguards issues and for registration of grievances,
related disclosure, and communication with the aggrieved party through the PIU ASO.
221. In case of grievances that are immediate and urgent in the perception of the
complainant, the contractor, and supervision personnel from PIU and Consultants on-site will
provide the most easily accessible or first level of contact for quick resolution of grievances.
Contact phone numbers and names of the concerned PIU Assistant Safeguards Officer,
contractors, will be posted at all construction sites at visible locations.
(i) 1st level grievance. The contractors, PIU supervision personnel, PIU Assistant
Safeguards Officer and implementing NGO/CAPC 11 can immediately resolve issues
on-site in consultation with each other, and will be required to do so within3 days of
receipt of a complaint/grievance.
(ii) 2nd level grievance. All grievances that cannot be redressed within 3 days at field/ward
level will be brought to the notice of respective Project Officers (Environment/Social) of
PMU. PMU POs will resolve the grievance within 7 days of receipt of
Community Awareness and Public Participation (CAPC) will oversee the matters if there is no Resettlement Plan (RP) Implementing
NGO
83
compliance/grievance in discussion with the PIU, CAPC and the Contractor. Project
Management and Capacity Building Consultants (PMCBC) will assist POs in resolving
the issue.
(iii) 3rd level grievance. All the grievances that are not addressed by PMU within in7 days
of receipt will be brought to the notice of notice of the Grievance Redress Committee
(GRC). The City Level Committee (CLC) that will be established in every project town
will act as GRC 12 . GRC will meet twice a month and determine the merit of each
grievance brought to the committee. The PIU ASO will be responsible to see through
the process of redressing of each grievance. The GRC will resolve the grievance within
15 days of receiving the complaint.
(iv) 4th level grievance. Very major issues that are beyond the jurisdictional authority of the
CLC or those that have the potential to cause social conflicts or environmental damage
or those that remain unresolved at PMU/CLC level, will be referred to the Empowered
Committee (EC).13 All decisions taken by the GRC will be communicated to the APs by
the PIU ASO.
222. The project GRM notwithstanding, an aggrieved person shall have access to the
country's legal system at any stage, and accessing the country's legal system can run parallel to
accessing the GRM and is not dependent on the negative outcome of the GRM. Alternatively, if
the grievance is related to land acquisition, resettlement & rehabilitation, the APs can approach
the Land Acquisition, Rehabilitation and Resettlement Authority (LARRA). As per the latest
Right to Fair Compensation and Transparency in Land Acquisition, Rehabilitation, and
Resettlement Act, 2013, the state government will have to establish the LARRA to address
grievances in implementation of LARRA.
185. In the event that the established GRM is not in a position to resolve the issue, the
affected person also can use the ADB Accountability Mechanism through directly contacting (in
writing) the Complaint Receiving Officer (CRO) at ADB headquarters or the ADB India Resident
Mission (INRM). The complaint can be submitted in any of the official languages of ADB's
DMCs. The ADB Accountability Mechanism information will be included in the PID to be
distributed to the affected communities, as part of the project GRM. Schematic diagram of
Grievance Redress Mechanism is given in Figure-13 .
City Level Committees (CLC) will be formed at town-level with members composed of: District Collector (DC) as Chairperson, and
following as members: ULB Commissioner; Assistant Safeguards Officer PIU; representative from RPCB regional office; and one
representative each from relevant government departments as appropriate (PWD / PHED / DAM etc). All town-level GRCs will have
at least one woman member/chairperson. In addition, for project-related grievances, representatives of APs, community-based
organizations (CBOs), and eminent citizens will be invited as observers in GRC meetings.
13
The Empowered Committee (EC) will be chaired by the Minister of Urban Development and Housing, and members will include
Ministers, Directors and/or representatives of other relevant Government Ministries and Departments
84
186. Record-keeping. The PIU of each town and PMU will both keep records of grievances
received, including contact details of complainant, date the complaint was received, nature of
grievance, agreed corrective actions and the date these were affected and final outcome. The
number of grievances recorded and resolved, and the outcomes will be displayed/disclosed in
the PMU office, PIU offices, and on the web, as well as reported in monitoring reports submitted
to ADB on a semi-annual basis.
187. Periodic review and documentation of lessons learned. The PMU Project Officer
(Environment) will periodically review the functioning of the GRM in each town and record
information on the effectiveness of the mechanism, especially on the project’s ability to prevent
and address grievances.
188. Costs. All costs involved in resolving the complaints (meetings, consultations,
communication and reporting/information dissemination) will be borne by the concerned PIU at
town level while costs related to escalated grievances will be met by the PMU. Cost estimates
for grievance redress are included in resettlement cost estimates.
85
223. The purpose of the environmental management plan (EMP) is to ensure that the
activities are undertaken in a responsible, non-detrimental manner with the objectives of:
(i)providing a proactive, feasible, and practical working tool to enable the measurement and
monitoring of environmental performance on-site; (ii) guiding and controlling the implementation
of findings and recommendations of the environmental assessment conducted for the
project;(iii) detailing specific actions deemed necessary to assist in mitigating the environmental
impact of the project; and (iv) ensuring that safety recommendations are complied with.
224. A copy of the EMP must be kept at work sites at all times. This EMP will be included in
the bid documents and will be further reviewed and updated during implementation. The EMP
will be made binding on all contractors operating on the site and will be included in the
contractual clauses. Non-compliance with, or any deviation from, the conditions set out in this
document constitutes a failure in compliance.
225. For civil works, the contractor will be required to (i) establish an operational system for
managing environmental impacts (ii) carry out all of the monitoring and mitigation measures set
forth in the EMP; and (iii) implement any corrective or preventative actions set out in safeguards
monitoring reports that the employer will prepare from time to time to monitor implementation of
this IEE and EMP. The contractor shall allocate budget for compliance with these EMP
measures, requirements and actions.
86
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
be obtained by
contractor are in
place before start of
construction
Refer table 1&2 for
consent
requirements
Incorporating Implementation of The EMP should be Bid Document PIU PMU Contractor /
EMP and Health the EMP included in the Bid Cost estimates
and Safety Document so that provided in the
requirements the selected IEE
into Contractor Contractor
Bid Document understands the
issues and makes
necessary plans to
prepare and
implement the EMP
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
noise, water and
soil
Utilities Telephone lines, (i) Identify and -List and maps Contractor in (i) List of affected No cost
electric poles and include locations showing collaboration with utilities and operators; required.
wires, water lines and operators of utilities to be PIU and with (ii) Bid document to
within proposed these utilities in the approval of PMU include requirement Mitigation
shifted
project area detailed design for a contingency plan measures are
documents to for service part of TOR of
-Contingency
prevent unnecessary interruptions (example PMU, PIU and
plan for
disruption of provision of water if Consultants
services
services during disruption is more
disruption
construction phase; than 24 hours), spoil
and management plan
(ii) Require (Appendix 8), and
construction traffic management
contractors to plan (Appendix 9)
prepare a
contingency plan to
include actions to be
taken in case of
unintentional
interruption of
services.
(iii) Require
contractors to
prepare spoils
management plan
(Appendix 8) and
traffic management
plan (Appendix 9)
Social and Ground disturbance (i) Consult Dept. of Chance find PIU Chance Finds No cost
Cultural can uncover and Archaeology and protocol Protocol required.
Resources damage museums,
archaeological and Government of Mitigation
historical remains Rajasthan to obtain measures are
an expert part of TOR of
assessment of the PIU and
91
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
archaeological Consultants
potential of the site;
(ii) Consider
alternatives if the
site is found to be of
medium or high risk;
(iii) Develop a
protocol for use by
the construction
contractors in
conducting any
excavation work, to
ensure that any
chance finds are
recognized and
measures are taken
to ensure they are
protected and
conserved.
Construction Disruption to traffic (i) Prioritize areas ‐List of pre- Contractor to (i) List of selected No cost
work camps, hot flow and sensitive within or nearest approved sites finalize locations in sites for construction required.
mix plants, receptors possible vacant for construction consultation and work camps, hot mix
stockpile areas, space in the project approval of PIU plants, stockpile Mitigation
work camps,
storage areas, location; areas, storage areas, measures are
and disposal (ii) If it is deemed areas for and disposal areas. part of TOR of
areas. necessary to locate stockpile, (ii) Written consent of PIU and
elsewhere, consider storage and landowner/s (not Consultants
sites that will not disposal lessee/s) for reuse of and also part of
promote instability excess spoils to contractual
and result in -Waste agricultural land terms
destruction of management
property, vegetation, plan
irrigation, and
drinking water
supply systems;
(iii) Do not consider
residential areas;
92
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
(iv) Take extreme
care in selecting
sites to avoid direct
disposal to water
body which will
inconvenience the
community.
(v) For excess spoil
disposal, ensure (a)
site shall be selected
preferably from
barren, infertile
lands. In case
agricultural land
needs to be
selected, written
consent from
landowners (not
lessees) will be
obtained; (b) debris
disposal site shall be
at least 200 m away
from surface water
bodies; (c) no
residential areas
shall be located
within 50 m
downwind side of
the site; and (d) site
is minimum 250 m
away from sensitive
locations like
settlements,
ponds/lakes or other
water bodies.
Sources of Extraction of (i) Prioritize sites Permits issued Contractor to (i) List of approved No cost
Materials materials can already permitted by to quarries/ prepare list of quarry sites and required.
93
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
disrupt natural land the Department of sources of approved quarry sources of materials;
contours and Mines and Geology materials sites and sources (ii) Bid document to Mitigation
vegetation resulting (ii) If other sites are of materials with include requirement measures are
in accelerated necessary, inform the approval of for verification of part of TOR of
erosion, disturbance construction PIU suitability of sources PIU and
in natural drainage contractor that it is and permit for Consultants
patterns, ponding their responsibility to additional quarry sites and also part of
and water logging, verify the suitability if necessary. contractual
and water pollution. of all material terms
sources and to
obtain the approval
of PMU and
(iii) If additional
quarries will be
required after
construction is
started, inform
construction
contractor to obtain
a written approval
from PIU.
Consents, Failure to obtain (i) Obtain all Consents, PIU and Incorporated in final No cost
permits, necessary necessary consents permits, Consultants design and required. Cost
clearances, consents, permits, (including CTE for clearance, communicated to of obtaining all
NOCs, etc. NOCs, etc. can STP from RPCB), NOCs, etc. contractors. consents,
result to design permits, clearance, permits,
revisions and/or NOCs, etc. prior to clearance,
stoppage of works award of civil works. NOCs, etc. prior
(as per Table-1& 2).. to start of civil
(ii)Following works
consents are responsibility of
required- PIU.
Tree cutting- local
authority Mitigation
Storage, handling measures are
and transport of part of TOR of
hazardous PIU and
94
Field Anticipated Impact Mitigation Indicator of Responsible for Monitoring of Cost and
Measures Compliance Implementation Mitigation Source of
Funds
materials- RPCB Consultants
Sand mining,
quarries, borrow
areas- Department
of mines and
Geology
Traffic
diversion/road
cutting- local
authority, traffic
police
(ii) Ensure that all
necessary approvals
for construction to
be obtained by
contractor are in
place before start of
construction
(iii) Acknowledge in
writing and provide
report on
compliance all
obtained consents,
permits, clearance,
NOCs, etc.
(iv) Include in
detailed design
drawings and
documents all
conditions and
provisions if
necessary
95
Socio-Economic Generation of (i) Employ at least 50% of the labour -Employment Construction (i) Employment Cost for
- Employment temporary force, or to the maximum extent, local records Contractor records; implementation
employment persons within the 2-km immediate area (ii) Records of of mitigation
and increase in if manpower is available; sources of materials measures
local revenue (ii) Secure construction materials from (iii) Compliance to responsibility of
local market. labor laws (see contractor.
(iii) Comply with labor laws Appendix 7 of this
100
Field Anticipated Impact Mitigation Measures Indicator of Responsible Monitoring of Cost and
Compliance for Mitigation Mitigation Source of
Funds
Construction All work sites Implementation of dust All the dust Weekly during Supervising No costs
disturbances, control, noise control, traffic control will be construction staff and required
nuisances, public management, & safety done by water safeguards
& worker safety measures. sprinkling specialists
Site inspection checklist to measures at
review implementation is site, noise will
appended at Appendix 12 be kept well
within
prescribed
limits of
standards,
Follow Traffic
management
Plan as given
in Appendix-10
and all the
safety
measures
such as PPE’s
etc.
Site inspection
will be done as
per checklist is
given in
Appendix-13.
Check the It may affect the sewer system, Effective operation to avoid Follows Sardarshahar Sardarshahar DBO
leakages contaminate land, water and and/or immediate clearance regular O & M Nagar Nagar Palika contractor cost
blockages, create public health issues of such leaks, blockages schedule Palika/O&M O&M Cost
108
Field Anticipated Impact Mitigation Measures Indicator of Responsible Monitoring of Cost and
Compliance for Mitigation Mitigation Source of
Funds
overflow problem Implementation of regular contractor
in sewers O&M schedules
Check the Occupational health & safety: for (i)Provide necessary health -Training and Sardarshahar Sardarshahar O&M Cost
leakages personnel cleaning underground & safety training to the staff Awareness Nagar Nagar Palika
blockages, sewers there is a risk due to engaged sewer cleaning & campaign for Palika/O&M
overflow problem oxygen deficiency and harmful maintenance Occupational, Contractor
in sewers gaseous emissions (hydrogen (ii) provide appropriate Health& Safety
sulphide, carbon monoxide, personal protection to ensure the
methane, etc.); equipment (including oxygen use of PPE’s.
masks)
Consent to Periodical renewal of consent to Renew the consent to RSPCB Sardarshahar Sardarshahar Sardarshahar
Operate operate, if not done, may attract operate (CTO) before expiry Nagar Nagar Nagar
penal action from State Pollution date and follow all the Palika/O&M Palika/O&M Palika/O&M
Control Board conditions set forth in CTO Contractor Contractor Contractor
Treated effluent Water pollution of the receiving Regular monitoring Test results Sardarshahar Sardarshahar Sardarshahar
quality body if treated effluent does not (parameters tests) of treated records Nagar Nagar Nagar
meet the standards set by effluent quality Palika/O&M Palika/O&M Palika/O&M
CPCB/RPCB Follow all the parameters Contractor Contractor Contractor
given in CTE/CTO
Reuse of Adverse impact on water Prepare a plan of reuse of Records on Sardarshahar Sardarshahar Sardarshahar
Treated hydrology and crops treated effluent in agriculture treated water Nagar Nagar Nagar
effluent/safe or other gainful purposes reuse Palika/O&M Palika/O&M Palika/O&M
disposal Contractor Contractor Contractor
Achieving Violation of ULB commitment Records Sardarshahar Sardarshahar Sardarshahar
Ensure that the targeted
targeted sludge under the project. Moreover, o Nagar Nagar Nagar
sludge reuse is achieved
reuse land has been identified for safe Palika/O&M Palika/O&M Palika/O&M
throughout the project period
sludge disposal. Hence, it is Contractor Contractor Contractor
imperative to achieve the targeted
sludge reuse under the project.
Achieving Septic Groundwater and surface water Household ULB Household
Effective implementation of a Septic Tank
Tank Closure pollution resulting from failure of Owner Owner
Septic Tank Closure Plan Closure Plan;
unused septic tanks.
involving emptying the
sullage, transporting the Records in the
sullage to a treatment plant ULB showing
and filling up the septic tank the septic tank
pit with stones, coarse and
109
Field Anticipated Impact Mitigation Measures Indicator of Responsible Monitoring of Cost and
Compliance for Mitigation Mitigation Source of
Funds
fine sand to remove any closure details.
contamination arising out of
the failed septic tanks.
Safety Health and safety risk to workers Ensure all the safety -Training and O&M Nagar Palika Nagar Palika
precautions engaged in sewage manhole equipment are available Awareness contractor for Mandal, Mandal,
during sewage cleaning during manual cleaning campaign for 10 years and Sardarshahar Sardarshahar
manhole As for as possible, use Occupational, then Nagar
cleaning CCTV and mechanical Health& Safety Palika
cleaning (sewage jetting to ensure the Mandal,
machine) for cleaning of use of PPE’s. Sardarshahar
manhole
Routine Health impact due to supply of Ensure periodical Maintenance O&M Nagar Palika O&M cost of
maintenance of unsafe drinking water in the maintenance and cleaning of Records contractor for Mandal, contractor
CWR and other system OHSRs, CWRs to ensure 10 years and Sardarshahar
facilities to delivery of safe drinking then Nagar
ensure delivery water Palika
of safe drinking Periodical testing of treated Mandal,
water water to ensure treated Sardarshahar
water quality meets the
required standards
Leakages in Entry of waste water into water Ensure to identify and repair Maintenance O&M Nagar Palika O&M cost of
water supply supply pipes and health risk to leakage immediately Records; contractor for Mandal, contractor
pipe lines public due to poor quality water Strengthen grievance Periodic 10 years and Sardarshahar
mechanism and attend the Leakage then Nagar
grievance of any leakage Report; Palika
Mandal,
Sardarshahar
Asset Reduction in NRW Preparation and O&M Manual; O&M Nagar Palika O&M cost of
management Increased efficiency of the system implementation of O&M Implementatio contractor for Mandal, contractor
Manual n Records; 10 years and Sardarshahar
then Nagar
Palika
Mandal,
Sardarshahar
110
Table 12: Environmental Monitoring Plan of ambient air, noise, water and soil quality and
other during Construction
Monitoring Monitoring Monitoring Frequency Responsibility Cost &
field location parameters Source of
Funds
Construction All work sites Implementation of Weekly Supervising No costs
disturbances, dust control, noise during staff, EHS required
nuisances, control, traffic construction officer and
public & worker management, & safeguards
safety safety measures. specialists
Site inspection
checklist to review
implementation is
appended at
Appendix 12
Tree cutting SPS, STP, Pipe Tree cutting permit Continuous Supervising No costs
laying, camps taken, Tree cutting staff, EHS required,
and PHED done officer and cost for
campus safeguards plantation
specialists from
contractor
Construction, Construction, As per EMP Weekly EHS officer, contractor
Labour Camp, Labour Camp, Environment
storage yard storage yard Specialist of
Management Management consultant
Solid waste Construction, As per EMP Weekly EHS officer, contractor
management Labour Camp, Environment
storage yard Specialist of
Management consultant
Construction All construction As per EMP and Weekly EHS officer, contractor
and demolition site applicable rules Environment
waste and regulations Specialist of
management consultant
Consent to STPs, batching Consents are Periodically EHS officer, No cost
establish of plants, crusher, taken as per table Environment required for
STPs, batching hot mix plants 1&2 Specialist of monitoring
plants, crusher, etc consultant cost for
hot mix plant. obtaining
DG sets etc. CTE/CTO
from PMU
and for
others from
Contractor
Ambient air 8 locations PM10, PM2.5, NO2, Quarterly Contractor Contractor
quality (3 STP sites, 2 SO2, CO except (ref table 16
SPS sites, 1 Monsoon and
PHED site, 1 period Appendix 16)
pipe laying site
and 1 at
construction/
workers
camp/storage
yard during
construction)
Ambient noise 8 locations Day time and night Quarterly Contractor Contractor
111
B. Institutional Requirements
189. The proposed implementation arrangements include LSGD, GOR to be the Executing
Agency of the Project, who will be responsible for overall strategic guidance and for ensuring
compliance with ADB’s loan covenants. RUIDP (a unit of RUDSICO) will be the Implementing
Agency for the RSTDIP responsible for technical supervision and project implementation. The
RUDSICO Board A State-Level Empowered Committee (SLEC) under the chairmanship of the
Minister for Urban Development, and Town Level Monitoring Committees (TLMCs) under the
Chairmanship of the respective Mayor/President/ Chairman (Elected head of House of ULB) is
proposed to be constituted to provide required guidance and monitor the project
implementation. A state-level project management unit (PMU), headed by project director, and
housed in RUIDP and Project Implementation Units (PIUs) in cluster of project towns and
housed (wherever space is available) in the largest ULB within the cluster, will be responsible
for implementation of the Project. PMU and PIUs will be supported by three institutional
consultants namely as PMCBC, CMSC-2 in number and CAPC.
190. The RUDSICO Board (superseding the earlier SLEC), under the Chairmanship of the
Minister for Urban Development , comprises of the Chief Secretary, Secretaries of LSGD,
Finance, Planning, Public Works Department (PWD), PHED and the Project Director, RUIDP as
Member Secretary. It shall have full powers to decide on matters related to RUIDP Phase IV
Project. The Board will take needful policy decisions, provide administrative and financial
approvals, expedite clearances of project matters, ensure inter-departmental coordination and
provide guidance to the PMU. As per GO dated 21 Feb 2018, all powers and responsibilities of
earlier SLEC (under RUIDP Phase III) have now been transferred to RUDSICO Board.
191. The TLMCs will be headed by the Chairperson of respective ULBs and shall have
Commissioner/Executive Officer of ULB, Local PHED and PWD Officers and officers of PIU of
respective town/cluster. The PIU officers shall include EE, PIU (Contract Manager), AE and/or
JE, PIU (RUIDP officer) and AE/JE of ULB. The AE of PIU (RUIDP Officer) shall be Member-
Secretary. The TLMC shall meet at least once in two months to monitor the project progress
and sort out any local issues. The implementation arrangements shall further include a central
PMU at Headquarter level and a number of PIUs at field level.
192. The PMU shall be headed by a dedicated Project Director (PD). Considering the breadth
and width of Rajasthan, it is proposed to have two regional offices as part of PMU - each
headed by an Assistant Chief Engineer. ACE–I is proposed to be located at Jaipur and ACE II at
Udaipur. Both shall facilitate management of projects worth INR 2500-3000 crores each during
next 5 years. This ACE (Jaipur) shall take care of 4 administrative Divisions of Rajasthan,
namely Bharatpur (4 districts), Bikaner (4 districts), Kota (4 districts) and Jaipur (5 districts),
114
whereas, ACE (Udaipur) shall take care of Divisions of Ajmer (4 districts), Udaipur (6 districts)
and Jodhpur (6 districts). Office of ACE shall be provided one EE, two Assistant Engineers one
computer operator and a support staff.
193. At HQ level, the Project Director shall be supported by Additional Project Director (CE
level), who shall be supported by SE (Procurement, Contract Management, Consultancies), SE
(Administration, Training, Institutional), SE (Monitoring, Reporting, Social and Environment) and
a Financial Advisor. All SEs shall have one Executive Engineer level Project officer. In addition,
there shall be one Project Officer for Social and another PO for Environmental aspects of the
project. The EEs (POs) shall have one AE under them except for Social component, wherein it
is suggested to have a Social/Public Participation professional. Besides these - there shall be
offices of Finance and Accounts, Legal, IT (including GIS, Project Management, Asset
Management) etc. To monitor and support field works, both offices of ACE shall have three SEs
(water and wastewater) each - located at divisional headquarter levels
194. The PIUs will be established by clustering of towns (39 project towns excluding Sambar
and Phulera). It is proposed that 15 such cluster level PIUs will be established based on
geographical location, administrative logistics, sub project costs and other such considerations.
Each PIU shall be headed by an Executive Engineer, who shall work as Project Manager. At
each PIU, an assistant engineer rank officer will be designated as safeguards officer (ASO) who
will assist PMU Project Officer (Environment) in implementation of the environmental
safeguards at the PIU level. PMU Project Officer will receive support from Environmental
Specialist of the PMCBC Team in implementation of environmental related tasks at PIU level.
The PIUs will be responsible for implementation of the Environmental management plan.
195. The PMU will be supported by three institutional consultants under the supervision and
control of PD, PMU. These consultants shall be:
Project Management and Capacity Building Consultants (PMCBC);
Construction Management and Supervision Consultants (CMSC), 2 Nos. and
Community Awareness and Participation Consultants (CAPC)
196. Project Management and Capacity Building Consultants (PMCBC) shall manage
preparation/vetting design documents, tendering of contracts, implementation of resettlement,
environmental management and gender action plans; setting and managing project
performance monitoring systems, planning and managing implementation of training and
capacity building as well as institutional strengthening activities besides preparing reports as per
ADB requirements.
197. Construction Management and Supervision Consultants (CMSC) shall support PIUs
in day to day contract management, construction supervision including quality management of
ongoing works etc. This shall include work measurement, quantities, verification of bills of
contractors etc.
198. Community Awareness and Participation Consultants (CAPC) will closely work in
field (with PIUs) to facilitate creation of project awareness and ensuring public participation for
all project works at the community level. This shall mainly involve house connections for water
supply, sewerage and metering. Besides, they shall also undertake various IEC activities to
promote and pursue health and hygiene amongst communities.
199. Contractor. Project being DBO contract, contractor will be required to review the IEE
and provide information to consultant’s ESS for update the IEE as per changed design and
115
latest scope of works. The contractor shall appoint an Environment, Health and Safety (EHS)
engineer who will be responsible on a day-to-day basis for (i) ensuring implementation of EMP,
(ii) coordinating with the ACM and environment safeguards specialists (all levels PO, SO &
ESS); (iii) community liaison 14 , consultations with interested/affected parties, and grievance
redress ; and (iv) reporting. Requirement of EHS Supervisor will be included in the bid
documents.
200. The following Figure 13 and Table 14 summarizes the institutional responsibility of
environmental safeguards at all stages of the project. PMU and PIUs will be supported by four
consultants namely as PMCBC, CMSC-1 & 2, and CAPP. PMCBC shall engage an
Environmental Safeguard Specialist (ESS) at the PMU level for managing all environmental
safeguard related support services as envisaged in its scope of work. S/he shall be assisted by
a team of field level safeguard support staff. It is proposed that each PIU should have at least 1
such environmental safeguard support personnel. Construction Management and Supervision
Consultants (CMSC) shall support PIUs in day to day activities. Community Awareness and
Public Participation Consultants (CAPP) will closely work in field (with PIUs) to facilitate creation
of project awareness and ensuring public participation for all project works at the community
level. This shall mainly involve house connections for water supply, sewerage and metering.
Besides, they shall also undertake various IEC activities to promote and pursue health and
hygiene amongst communities.
14 Reasonable size social outreach team (SOT) to be appointed by contractor to facilitate community liaison,
consultations and R&R implementation (including resolution of grievances). Requirement of SOT will be included in
bid document.
116
Responsible Responsibility
Agency Pre-Construction Stage Construction Stage Post-Construction
Project Officer (i) Review REA checklists (i) Over-all environmental Compliance monitoring to
(Environment), and assign categorization safeguards compliance of review the environmental
PMU based on ADB SPS 2009 the project performance of project
(ii) Review and approve (iii) Monitor and ensure component, if required
EIA/IEE compliance of EMPs as and as specified in EMP
(iii) Submit EIA/IEE to ADB well as any other
for approval and disclosure in environmental provisions
ADB website and conditions.
(iv) Ensure approved IEEs (i) Review monthly
are disclosed in monitoring report
RUIFDCO/PMU websites (ii) Prepare and submit to
and summary posted in ADB semi-annual
public areas accessible and monitoring reports
understandable by local (iv) If necessary prepare
people. Corrective Action Plan
(v) Ensure environmental and ensure
management plans (EMPs) implementation of
117
Responsible Responsibility
Agency Pre-Construction Stage Construction Stage Post-Construction
are included in the bid corrective actions to
documents and contracts ensure no environmental
(vi) Organize an orientation impacts;
workshop for PMU, PIU, ULB (iii) Review and submit
and all staff involved in the Corrective Action Plans
project implementation on (a) to ADB
ADB SPS, (b) Government of (iv) Organize capacity
India national, state, and building programs on
local environmental laws and environmental
regulations, (c) core labor safeguards
standards, (d) OH&S, (e) (iv) Coordinate with
EMP implementation national and state level
especially spoil government agencies
management, working in (vi) Assist in addressing
congested areas, public any grievances brought
relations and ongoing about through the
consultations, grievance Grievance Redress
redress, etc. Mechanism in a timely
(vii) Assist in addressing any manner as per the IEEs
grievances brought about (ix) Coordinate PIUs,
through the Grievance NGOs, consultants and
Redress Mechanism in a contractors on mitigation
timely manner as per the measures involving the
IEEs community and affected
(viii) Organize an induction persons and ensure that
course for the training of environmental concerns
contractors preparing them and suggestions are
on EMP implementation, incorporated and
environmental monitoring implemented
requirements related to
mitigation measures; and
taking immediate actions to
remedy unexpected adverse
impacts or ineffective
mitigation measures found
during the course of
implementation.
(ix) Ensure compliance with
all government rules and
regulations regarding site
and environmental
clearances as well as any
other environmental
requirements
(x) Assist PMU, PIUs, and
project NGOs to document
and develop good practice
construction guidelines to
assist the contractors in
implementing the provisions
of IEE.
(xi) Assist in the review of the
contractors’ implementation
plans to ensure compliance
118
Responsible Responsibility
Agency Pre-Construction Stage Construction Stage Post-Construction
with the IEE.
Assistant (i) Ensure IEE is included in (i) oversee day-to-day (i) Conducting
Safeguard bid documents and contract implementation of EMPs environmental
Officer, PIU agreements. Ensure cost of by contractors, including monitoring, as specified
EMP implementation is compliance with all in the EMP.
provided. government rules and (ii) Issuance of clearance
(iv) Disclose of approved regulations; for contractor’s post-
EIAs/IEEs. (ii) take necessary action construction activities as
(v) Obtain all necessary for obtaining rights of specified in the EMP.
clearances, permits, way;
consents, NOCs, etc. Ensure (iii) oversee
compliance to the provisions implementation of EMPs,
and conditions. including environmental
(vi) EMP implementation monitoring by
regarding sites for disposal of contractors;
wastes, camps, storage (iv) take corrective
areas, quarry sites, etc. actions when necessary
(vii) Organize an induction to ensure no
course for the training of environmental impacts;
contractors, preparing them (v) submit monthly
on EMP implementation, environmental monitoring
environmental monitoring reports to PMU,
requirements related to (vi) conduct continuous
mitigation measures, and on public consultation and
taking immediate action to awareness;
remedy unexpected adverse (vii) address any
impacts or ineffective grievances brought about
mitigation measures found through the grievance
during the course of redress mechanism in a
implementation. timely manner as per the
IEEs; and
Consultant - (i) Conduct initial (i)Monitor EMP (i) Assist in the inspection
1. Environmental environmental assessment implementation and verification of
Safeguard for proposed project using (ii) Recommend contractor’s post-
Specialist REA checklists and submit to corrective action construction activities.
PIU/PMU measures for non-
2. Assistant (ii) Prepare EIA/IEE based compliance by
Construction on categorization and submit contractors
Manager at PIU to PIU/PMU for approval (iii) Assist in the review of
(ii) Assist PIU in obtaining all monitoring reports
necessary clearances, submitted by contractors
permits, consents, NOCs, (iv) Assist in the
etc. Ensure provisions and preparation of monthly
conditions are incorporated monitoring reports
in the IEE and detailed (v) conduct continuous
design documents. public consultation and
(iii) Assist in ensuring IEE is awareness;
included in bid documents (vi) Assist in addressing
and contract agreements. any grievances brought
Assist in determining about through the
adequacy of cost for EMP Grievance Redress
119
Responsible Responsibility
Agency Pre-Construction Stage Construction Stage Post-Construction
implementation. Mechanism in a timely
(iv) Assist in addressing any manner as per the IEEs
concern related to IEE and
EMP.
(v) Assist in summarizing IEE
and translating to language
understood by local people.
Contractors(EHS (i)Depute a qualified and (i) Implement EMP. (i) Ensure EMP post-
supervisor) experienced EHS personnel (ii) Implement corrective construction
before start of construction actions if necessary. requirements are
works (iii) Prepare and submit satisfactorily complied
(ii) Prepare EHS plan and monitoring reports (ii) Request certification
take approval from including pictures to PIU from PIU
PMDSC/PIU and Ensure (iv) Comply with all
EMP implementation cost is applicable legislation, is
included in the methodology. conversant with the
(iii) Undergo EMP requirements of the EMP;
implementation orientation by (v) Brief his staff,
ESS of PMDSC prior to start employees, and laborer
of works about the requirements of
(iv) Provide EMP the EMP and provide
implementation orientation to environmental awareness
all workers prior to training to staff,
deployment to worksites employees, and laborers;
(v) Seek approval for camp (vi) Ensure any sub-
sites and sources of contractors/ suppliers
materials. who are utilized within
(vi) Ensure copy of IEE is the context of the
available at worksites. contract comply with all
Summary of IEE is translated requirements of the EMP.
to language understood by The Contractor will be
workers and posted at visible held responsible for non-
places at all times. compliance on their
behalf;
(vii) Bear the costs of any
damages/compensation
resulting from non-
adherence to the EMP or
written site instructions;
(viii) Ensure that PIU and
ACM/ASO are timely
informed of any
foreseeable activities
related to EMP
implementation.
C. Training Needs
226. The following Table 15 presents the outline of capacity building program to ensure EMP
implementation. The estimated cost is Rs.475,000 (excluding trainings of contractors which will
be part of EMP implementation cost during construction) to be covered by the project's capacity
building program. The detailed cost and specific modules will be customized for the available
skill set after assessing the capabilities of the target participants and the requirements of the
120
227. Prior to commencement of the work, the contractor will either submit a compliance report
to PIU ensuring that all identified potential environmental impacts and their mitigation measures
as detailed in the EMP are meeting project requirements and scope of works and will be
undertaken or will provide EMP for the proposed works with his Service Improvement Plan (SIP)
covering all the requirements proposed in this IEE. PIU with the assistance of the ASO and ESS
of Consultants will review the report and thereafter PMU will allow commencement of works.
228. During construction, compliance of EMP and results from internal monitoring by the
contractor will be submitted in their quarterly EMP implementation reports to the PIU and
Consultants. ASO and ACM will review and advise contractors for corrective actions if
necessary. Quarterly report summarizing compliance and corrective measures taken will be
prepared by ASO with the assistance of ESS and submitted to PMU.
229. Based on quarterly reports and measurements, PMU with assistance of ESS will draft,
and submit to ADB, 6-monthly (twice a year) EMP implementation progress report (Appendix
11). Once concurrence from the ADB is received the report will be disclosed in the Project
website.
230. ADB will review project performance against the Phase-IV project commitments as
agreed in the legal documents. The extent of ADB's monitoring and supervision activities will be
commensurate with the project's risks and impacts. Monitoring and supervising of social and
environmental safeguards will be integrated into the project performance management system.
231. Most of the mitigation measures require the contractors to adopt good site practice,
which should be part of their normal procedures already, so there are unlikely to be major costs
associated with compliance. Regardless of this, any costs of mitigation by the construction
contractors or consultants are included in the budgets for the civil works and do not need to be
122
estimated separately here. Mitigation that is the responsibility of PIU/ULB will be provided as
part of their management of the project, so this also does not need to be duplicated here. Cost
for the capacity building program is included as part of the project.
2 Barricading with Construction Sq. Mtr. 4425 101 446925 Civil works
GI Corrugated contract
Sheet
3 Close Timbering Construction Sq. Mtr. 50726 125 6340750 Civil works
depth up to 3 mtr. contract
4 Close Timbering Construction Sq. Mtr. 155 126 19530 Civil works
3 mtr. to 6 mtr. contract
5 Planking and Construction Sq. Mtr. 5088 1020 5189760 Civil works
strutting extra contract
8 Planking and Construction Sq. Mtr. 20294 430 8726420 Civil works
strutting extra contract
10 Mobile Toilet Construction 2160 Units day 800 1728000 Civil works
contract
(In Words: Four Crore Eighty Six Lakhs Eighteen Thousand Eight Hundred Thirty Nine
Only)
125
IX CONCLUSION AND RECOMMENDATION
232. The process described in this document has assessed the environmental impacts of all
elements of the Sardarshahar water supply and sewerage subproject. All potential impacts were
identified in relation to pre-construction, construction, and operation phases. Planning principles
and design considerations have been reviewed and incorporated into the site planning and
design process wherever possible; thus, environmental impacts as being due to the project
design or location were not significant. During the construction phase, impacts mainly arise from
the construction dust and noise, the need to dispose of large quantities of waste soil and import
a similar amount of sand to support the sewer in the trenches; and from the disturbance of
residents, businesses, traffic and important buildings by the construction work. The social
impacts (access disruptions) due to construction activities are unavoidable, as the residential
and commercial establishments exist along the roads where sewers will be laid. A resettlement
plan has been developed in accordance with ADB SPS 2009 and Government of India laws and
regulations.
233. Sardarshahr Town is located in the semi-arid region of the state where the average
temperature during winter season ranges between 10°C and 17°C and the summer season
temperature range 32°C to 36°C. Also, Churu District where Sardarshahr Town is located, has
seen an average rainfall of 337.9mm in the period 1901 – 1970 which has increased at an
average of 37% during the period 2012-2016.
234. In general, it should be noted that the air quality as reported under the National Air
Monitoring Program covering 21 monitoring stations located across Rajasthan revealed that the
air quality in the urban areas in between “moderate” to “poor” category and suggests a link
between air quality and vehicular emissions, uncontrolled burning of wastes and construction
activities carried out without any mitigation measures. Groundwater levels in Churu District
where Sardarshahr Town is located has seen a fall in 68% of the wells analyzed during the
decadal period May 2006 – May 2015. In terms of Groundwater Quality, Churu District has
seen a high nitrate and fluoride concentration in its wells. Noise levels are at permissible levels
in the town.
236. Presently, the sewerage system in the core area of Sardarshahr has been developed;
however not yet commissioned. As such, majority of the residential, commercial buildings and
educational institutions have on-site septic tanks and soak pits. The effluent from the septic
tanks directly drains into the open drains. Though septic tanks is an accepted onsite treatment,
as the septic tanks are not designed and maintained properly, the effluent does not confirm to
the standards. The effluent from the septic tanks is directly let into the open drains. In the
absence of safe disposal system of sewage as mentioned above, the people of Sardarshahr are
facing unhealthy and unhygienic environment. Water supply in the towns is also not adequate
in terms of quality and quantity and huge water losses persist in existing water supply system in
the town.
237. The subproject is formulated to address gaps in water and sewerage infrastructure in a
holistic and integrated manner. The Project Components include improvements in water supply
126
infrastructure.
238. The STPs and SPS are located away from habitation areas. However, there are a few
shrubs and trees at these locations which may need to be cut during construction. Adequate
compensatory afforestation measures are being proposed under the project to counter the tree-
cutting activity under RUIDP policy. Also, it is proposed to reuse the treated effluent for use of
agriculture, horticulture, development of urban forestry etc. and remaining treated effluent is
proposed to be discharged in to a nearby low lands/drains. In order to safeguard the interest of
downstream users it is proposed to apply technology/process to achieve very low BOD (BOD
10) and suspended solids in the treated effluent. Sequential batch reactor (SBR) technology has
been adopted in RUIDP, Phase-IV Treated effluent shall be mostly reused for beneficial
purposes for which proposal of construction of Treated Effluent Elevated Reservoir (TEER),
Treated Effluent Storage Reservoir (TESR) and Effluent Pumping Station (EPS) has been
taken.
239. Confirmation on STP 3 (1.60 MLD)land near Ashoke circle is yet to obtained from the
owner Gandhi Vidyamandir Trust. NagarPalika will provide land for STP for this project.
Consent letter/NOC should be appended in the IEE report before award of contract.
240. At the STP, sewage sludge will be removed continuously from reactors, and solidified
using decanter, and stored in sludge drying beds for a period of seven days. The treatment and
drying processes kill enteric bacteria and pathogens. Because of its high content of nitrates,
phosphates and other plant nutrients the sludge can be used as organic fertilizer.
241. Contractor will propose the plan with best methods for reuse of treated effluent and
sludge as per guidelines of CPHEEO and best international practices in consultation with
RUIDP and Municipal Council and submit it in RUIDP for approval. In order to aid preparation
of a viable treated wastewater reuse and sludge reuse plan, an institutional and capacity
building component shall be incorporated in the Project to enable the ULB staff to develop an
understanding of the relevant issues.
242. In the project, in a large portion of the project town areas, the septic tank system in
individual households is replaced with direct connections to the new sewerage network. The
non-use of the existing septic tanks may result in its failure thereby contaminating the surface
and groundwater in the region. Hence, an action plan comprising of pumping the sullage,
treating it at the STP and closing the septic tank pit with stones, coarse and fine aggregates
shall be developed and implemented during the Operation Phase.
243. Certain new initiatives have been taken in the project viz., promoting wastewater reuse,
sludge reuse and contractor to work on private properties to provide sewerage connections.
Hence, appropriate guidelines for these measures should be provided for these new initiatives.
These could include viz., Guidelines for the ULBs for promoting wastewater reuse; Guidelines
for the ULBs for sludge reuse; and Guidelines for the Contractors to work within the private
properties.
244. Anticipated impacts of sewerage system during operation and maintenance will be
related to repair of blocks, overflows and leakages in sewers. Sewers are not 100% watertight
and leaks can occur at joints. Faulty section will be exposed and repaired following the same
basic procedure as when the sewer was built. Also, sewer pipes require regular maintenance as
silt inevitably collects in areas of low flow over time. Necessary equipment for cleaning and
127
247. The public participation processes undertaken during project design ensured
stakeholders are engaged during the preparation of the IEE. The planned information disclosure
measures and process for carrying out consultation with affected people will facilitate their
participation during implementation. The project's grievance redress mechanism will provide the
citizens with a platform for redressing grievances, and describes the channels, timeframe, and
mechanisms for resolving complaints about environmental performance.
248. The Environmental Management Plan proposed in the project includes mitigation
measures for identified impacts, training and capacity building activities, a monitoring plan to
ensure that the environmental standards are maintained throughout the project construction
period and a reporting plan to ensure that the project is implemented as per environmentally
sound engineering and construction practices. The details of cost estimate (budgetary provision)
for mitigating the anticipated impacts by proposed subproject component is approximately INR
486,18,839/- (Four Crore Eighty Six Lakhs Eighteen Thousand Eight Hundred Thirty Nine
Only) for effective implementation of the EMP Plan.
249. The EMP will assist the PMU, PIU, Consultants and contractors in mitigating the
environmental impacts, and guide them in the environmentally sound execution of the proposed
project. The EMP will also ensure efficient lines of communication between PIU/ULB, PMU,
consultants and contractor. A copy of the EMP shall be kept on-site during the construction
period at all times. The EMP shall be made binding on all contractors operating on the site, and
will be included in the contractual clauses. Non-compliance with, or any deviation from, the
conditions set out in this document shall constitute a failure in compliance.
250. The project will benefit the general public by contributing to the long-term improvement
of sewerage system and community livability in Sardarshahar. The potential adverse
environmental impacts are mainly related to the construction period, which can be minimized by
the mitigation measures and environmentally sound engineering and construction practices.
251. Therefore, as per ADB SPS, the project is classified as environmental category B and
does not require further environmental impact assessment.
128
Instructions:
The project team completes this checklist to support the environmental classification of a project. It is to
be attached to the environmental categorization form and submitted to the Environment and Safeguards
Division (RSES) for endorsement by the Director, RSES and for approval by the Chief Compliance
Officer.
This checklist focuses on environmental issues and concerns. To ensure that social dimensions are
adequately considered, refer also to ADB checklists and handbooks on (i) involuntary resettlement, (ii)
indigenous peoples planning, (iii) poverty reduction, (iv) participation, and (v) gender and development.
Answer the questions assuming the “without mitigation” case. The purpose is to identify potential
impacts. Use the “remarks” section to discuss any anticipated mitigation measures.
Noise and dust from construction All the construction machineries employed should
activities? comply with noise emission standards of Central
Pollution Control Board.
Dust suppression measures such as water
sprinkling will be employed
Increased road traffic due to Excavation and laying pipelines along public
interference of construction activities? roads will interfere with the traffic. Construction
material transport will increase traffic within city.
Proper traffic management and construction
planning will be ensured to minimize the
interference
Continuing soil erosion/silt runoff from Construction work during monsoon shall be
construction operations? carried out with due care so that silt run off due to
construction operation is prevented. No
construction will be allowed during rains.
Delivery of unsafe water due to poor There is possibility of delivery of unsafe water due
O&M treatment processes (especially to poor O&M of storage and distribution facilities.
mud accumulations in filters) and O&M contractor has to ensure the quality of water
inadequate chlorination due to lack of to be supplied. Penalty provisions should be made
adequate monitoring of chlorine in O&M contract for delivery of unsafe drinking
residuals in distribution systems? water
Delivery of water to distribution Not envisaged, pipes of corrosion free materials
system, which is corrosive due to should be used in the project and provision should
inadequate attention to feeding of be made in designs
corrective chemicals?
Accidental leakage of chlorine gas? Accidental leakage of chlorine gas may take place
during chlorination. Utmost care should be taken
Excessive abstraction of water Only water allocated for the water supply from
affecting downstream water users? Indira Gandhi Canal shall be used for proposed
project.
Competing uses of water? Only water allocated for the water supply from
Indira Gandhi Canal shall be used for proposed
project.
Increased sewage flow due to Sewerage system is already under progress and
increased water supply also proposed in the town to cater sewage
generated due to increased water supply
large population influx during project Most of the unskilled workers will be hired locally,
construction and operation that some of skilled workers will be brought from
causes increased burden on social outside but numbers will not so large to have
infrastructure and services (such as impacts on social infrastructure and services
water supply and sanitation systems)?
Social conflicts if workers from other The contractor will be utilizing the local labour
regions or countries are hired? force as far as possible; in case if it is
unavoidable, labour camps and facilities will be
provided appropriately. No conflicts envisaged
risks to community health and safety No explosives shall be used in project. Fuel and
due to the transport, storage, and use other chemicals will be used in very less
and/or disposal of materials such as quantities which will not have significant impact on
explosives, fuel and other chemicals community health and safety. Safe handling of
during operation and construction? fuels and chemicals will be ensured by contractor.
135
community safety risks due to both Community safety risk may be there during
accidental and natural hazards, construction during excavation for pipe laying,
especially where the structural equipment and vehicle operation, construction of
elements or components of the WTP etc. for which mitigation measures will be
project are accessible to members of required by contractor
the affected community or where their
failure could result in injury to the
community throughout project
construction, operation and
decommissioning?
136
Location and Is siting and/or routing of the project (or its components) 0 No such issue
Design of likely to be affected by climate conditions including may affect the
project extreme weather related events such as floods, droughts, project
storms, landslides?
Would the project design (e.g. the clearance for bridges) 0 No such issue
need to consider any hydro-meteorological parameters may affect the
(e.g., sea-level, peak river flow, reliable water level, peak project
wind speed etc)?
Materials and Would weather, current and likely future climate conditions 0 No such issues
Maintenance (e.g. prevailing humidity level, temperature contrast may affect the
between hot summer days and cold winter days, exposure project
to wind and humidityhydro-meteorological
parameterslikely affect the selection of project inputs over
the life of project outputs (e.g. construction material)?
Would weather, current and likely future climate 0 No such issue
conditions, and related extreme events likely affect the may affect the
maintenance (scheduling and cost) of project output(s) ? project
Performance Would weather/climate conditions, and related extreme 0 No problem will
of project events likely affect the performance (e.g. annual power envisaged in
outputs production) of project output(s) (e.g. hydro-power future which
generation facilities) throughout their design life time? likely affect the
performance of
project output
Options for answers and corresponding score are provided below:
Response Score
Not Likely 0
Likely 1
Very Likely 2
Responses when added that provide a score of 0 will be considered low risk project. If adding all
responses will result to a score of 1-4 and that no score of 2 was given to any single response, the project
will be assigned a medium risk category. A total score of 5 or more (which include providing a score of 1
in all responses) or a 2 in any single response will be categorized as high risk project.
Other Comments: The proposed subproject activity involves construction of three new STPs, 2 SPSs and
one CWR along with water supply and sewerage networks and the anticipated environmental impacts are
very marginal and the construction activity does not impose any threat to the existing climatic conditions.
15 If possible, provide details on the sensitivity of project components to climate conditions, such as how climate parameters
are considered in design standards for infrastructure components, how changes in key climate parameters and sea level
might affect the siting/routing of project, the selection of construction material and/or scheduling, performances and/or the
maintenance cost/scheduling of project outputs.
137
138
Appendix 4 A:
Effluent Discharge Standards for Sewage Treatment Plant by Central Pollution Control
Board, Ministry of Environment, Forests and Climate Change, Government of India,
Dated 15th April 2015
NOW THEREFORE, in view of the above stated facts and realizing that rivers and water
bodies have been polluted and to prevent further deterioration of surface, sub-surface
and coastal waters, it is essential to issue following directions under section 18(1)(b) of
the Water(Prevention and Control of Pollution) Act, 1974. The following directions are
hereby issued for compliance;
1. State Pollution Control Board shall make mandatory for local/urban bodies to set up a
sewerage system for sewage collection, underground conveyance, treatment and its
disposals to cover the entire local/urban area to bridge the widening treatment gap along
with enforcement of consent management in line with standards for sewage treatment as
below:
2. SPCB/PCC shall issue directions to all municipalities and other concerned authorities in
the State/UT responsible for treatment and disposal of sewage to the following effect;
a) The existing STPs which are being operated before issuance of these directions shall
meet the standards within two years from the date of issuance of these directions.
b) All the local bodies shall seek consent under Water (Prevention and Control of Pollution)
Act, 1974 from the SPCB/Committee within a period of 60 Days.
c) Secondary treated sewage should be mandatorily sold for use for non-potable purposes
such as industrial process, railways & bus cleaning, flushing of toilets through dual
piping, horticulture and irrigation. No potable water to be allowed for such activities.
143
They will also digest methane for captive power generation to further improve viability of
STPs.
d) Dual piping system should be enforced in new housing constructions for use of treated
sewage for flushing propose.
e) Each municipal authority and the concerned authority shall submit a time bound action
plan for setting up sewerage system covering proper collection, treatment and disposal
of sewage generated in the local/urban area and such plan shall be submitted by the
municipal authority to the State Board within a period of 90-120 Days.
f) In case of disposal of effluents on land or river or any water body including coastal
water/creek or a drain, the treated effluents shall meet the suggested standards annexed
to these direction.
g) The new sewage treatment plants which will come in existence after the issuance of
these directions shall be designed to treat and achieve standards as per the suggested
standards.
144
Appendix-4B
Pages from Rajasthan State Sewerage and Waste Water Policy for reuse of
treated effluent and sludge
145
146
147
148
149
(i) Workmen Compensation Act, 1923 - The Act provides for compensation in case of injury
by accident arising out of and during the course of employment.
(ii) Payment of Gratuity Act, 1972 - Gratuity is payable to an employee under the Act on
satisfaction of certain conditions on separation if an employee has completed 5 years’ service or
more or on death at the rate of 15 days wages for every completed year of service. The Act is
applicable to all establishments employing 10 or more employees.
(iii) Employees’ PF and Miscellaneous Provisions Act, 1952 - The Act provides for monthly
contributions by the employer plus workers @10 % or 8.33 %.The benefits payable under the
Act are: (a) Pension or family pension on retirement or death as the case may be; (b) deposit
linked insurance on the death in harness of the worker; (c) payment of PF accumulation on
retirement/death etc.
(iv) Maternity Benefit Act, 1951 - The Act provides for leave and some other benefits to
women employees in case of confinement or miscarriage etc.
(v) Contract Labour (Regulation and Abolition) Act, 1970 - The Act provides for certain
welfare measures to be provided by the Contractor to contract labor and in case the Contractor
fails to provide, the same are required to be provided by the Principal Employer by Law.The
principal employer is required to take Certificate of Registration and the Contractor is required to
take a License from the designated Officer. The Act is applicable to the establishments or
Contractor of principal employer if they employ 20 or more contract labor.
(vi) Minimum Wages Act, 1948 - The employer is supposed to pay not less than the
Minimum Wages fixed by appropriate Government as per provisions of the Act if the
employment is a scheduled employment. Construction of Buildings, Roads, Runways are
scheduled employment.
(vii) Payment of Wages Act, 1936 - It lays down as to by what date the wages are to be paid,
when it will be paid and what deductions can be made from the wages of the workers.
(viii) Equal Remuneration Act, 1979 - The Act provides for payment of equal wages for work
of equal nature to Male and Female workers and not for making discrimination against Female
employees in the matters of transfers, training and promotions etc.
(ix) Payment of Bonus Act, 1965 - The Act is applicable to all establishments employing 20
or more workmen. The Act provides for payments of annual bonus subject to a minimum of 8.33
% of wages and maximum of 20 % of wages to employees drawing Rs. 3,500/- per month or
less. The bonus to be paid to employees getting Rs. 2,500/- per month or above up to
Rs.3,500/- per month shall be worked out by taking wages as Rs.2,500/- per month only. The
Act does not apply to certain establishments. The newly set up establishments are exempted for
155
five years in certain circumstances. Some of the State Governments have reduced the
employment size from 20 to 10 for the purpose of applicability of the Act.
(x) Industrial Disputes Act, 1947 - The Act lays down the machinery and procedure for
resolution of industrial disputes, in what situations a strike or lock-out becomes illegal and what
are the requirements for laying off or retrenching the employees or closing down the
establishment.
(xi) Industrial Employment (Standing Orders) Act, 1946 - It is applicable to all establishments
employing 100 or more workmen (employment size reduced by some of the States and Central
Government to 50). The Act provides for laying down rules governing the conditions of
employment by the employer on matters provided in the Act and get the same certified by the
designated Authority.
(xii) Trade Unions Act, 1926 - The Act lays down the procedure for registration of trade
unions of workmen and employees. The trade unions registered under the Act have been given
certain immunities from civil and criminal liabilities.
(xiii) Child Labor (Prohibition and Regulation) Act, 1986 - The Act prohibits employment of
children below 14 years of age in certain occupations and processes and provides for regulation
of employment of children in all other occupations and processes. Employment of child labor is
prohibited in Building and Construction Industry.
(xv) Construction and Demolition Waste Management Rules 2016- This Rule stipulate
that-
Every waste generator shall segregate construction and demolition waste and deposit at
collection centre or handover it to the authorized processing facilities
Shall ensure that there is no littering or deposition so as to prevent obstruction to the
traffic or the public or drains.
Large generators (who generate more than 20 tons or more in one day or 300 tons per
project in a month) shall submit waste management plan and get appropriate approvals
from the local authority before starting construction or demolition or remodelling work,
Large generators shall have environment management plan to address the likely
environmental issues from construction, demolition, storage, transportation process and
disposal / reuse of C & D Waste.
Large generators shall segregate the waste into four streams such as concrete, soil, steel,
wood and plastics, bricks and mortar,
Large generators shall pay relevant charges for collection, transportation, processing and
disposal as notified by the concerned authorities;
156
(xvi) Solid Waste Management Rules 2016- As per this Rule, responsibility of Solid Waste
Generator is as below-
segregate and store the waste generated in three separate streams namely bio-
degradable, non biodegradable and domestic hazardous wastes in suitable bins and
handover segregated wastes to authorized waste pickers or waste collectors as per the
direction or notification by the local authorities from time to time;
store separately construction and demolition waste, as and when generated, in his own
premises and shall dispose off as per the Construction and Demolition Waste
Management Rules, 2016; and
No waste generator shall throw, burn or burry the solid waste generated by him, on
streets, open public spaces outside his premises or in the drain or water bodies.
(xv) The Building and Other Construction Workers (Regulation of Employment and
Conditions of Service) Act, 1996 and the Cess Act of 1996 - All the establishments who
carry on any building or other construction work and employ 10 or more workers are covered
under this Act. All such establishments are required to pay Cess at rate not exceeding 2% of the
cost of construction as may be notified by the Government. The employer of the establishment
is required to provide safety measures at the building or construction work and other welfare
measures, such as canteens, first-aid facilities, ambulance, housing accommodation for workers
near the workplace etc. The employer to whom the Act applies has to obtain a registration
certificate from the Registering Officer appointed by the Government. Following are the major
requirements under this Act, applicable to this project-
Employer shall-
Provide and maintain, at suitable point, sufficient quantity of wholesome drinking
water, such point shall be at least 6 meters away from any washing areas, urinals or
toilets
Provide sufficient urinals and latrines at convenient place, easily accessible by
workers
Provide free of charge, temporary living accommodations near to work sites with
separate cooking place, bathing and lavatory facilities and restore the site as pre
conditions after completing the construction works
Provide crèche with proper accommodation, ventilation, lighting, cleanliness and
sanitation if more than fifty female workers are engaged
Provide first aid facilities in all construction sites
I. Spoils information
The spoil information contains the details like a) The type / material, b) Potential contamination
by that type, c) Expected volume (site / component specific), d) Spoil Classification etc.
III. Documentation
The volume of spoil generated (site specific, date wise), site disposed, reuse / disposal details
should be documented properly.
159
1. One of the prime objectives of this TMP is to ensure the safety of all the road users
along the work zone, and to address the following issues:
(i) the safety of pedestrians, bicyclists, and motorists travelling through the
construction zone;
(ii) protection of work crews from hazards associated with moving traffic;
(iii) mitigation of the adverse impact on road capacity and delays to the road users;
(iv) maintenance of access to adjoining properties; and
(v) addressing issues that may delay the project.
2. The following principles will help promote safe and efficient movement for all road users
(motorists, bicyclists, and pedestrians, including persons with disabilities) through and around
work zones while reasonably protecting workers and equipment.
(i) Make traffic safety and temporary traffic control an integral and high-priority
element of project from planning through design, construction, and maintenance.
(ii) Inhibit traffic movement as little as possible.
(iii) Provide clear and positive guidance to drivers, bicyclists, and pedestrians as they
approach and travel through the temporary traffic control zone.
(iv) Inspect traffic control elements routinely, both day and night, and make
modifications when necessary.
(v) Pay increased attention to roadside safety in the vicinity of temporary traffic
control zones.
(vi) Train all persons that select, place, and maintain temporary traffic control
devices.
(vii) Keep the public well informed.
(viii) Make appropriate accommodation for abutting property owners, residents,
businesses, emergency services, railroads, commercial vehicles, and transit
operations.
3. Figure A2 to Figure A12 illustrates the operating policy for TMP for the construction of
water pipes and the sewers along various types of roads.
C. Analyze the impact due to street closure
4. Apart from the capacity analysis, a final decision to close a particular street and divert
the traffic should involve the following steps:
(i) approval from the ULB/Public Works Department (PWD) to use the local streets
as detours;
(ii) consultation with businesses, community members, traffic police, PWD, etc,
regarding the mitigation measures necessary at the detours where the road is
diverted during the construction;
(iii) determining of the maximum number of days allowed for road closure, and
incorporation of such provisions into the contract documents;
(iv) determining if additional traffic control or temporary improvements are needed
along the detour route;
(v) considering how access will be provided to the worksite;
160
5. If full road-closure of certain streets within the area is not feasible due to inadequate
capacity of the detour street or public opposition, the full closure can be restricted to weekends
with the construction commencing on Saturday night and ending on Monday morning prior to
the morning peak period.
Figure A1: Policy Steps for the TMP
• Develop a mechanism to address public grievances regarding disruptons (traffic, utilities, and
Public diversions)
Redress
6. As per discussions in the previous sections, there will be travel delays during the
constructions, as is the case with most construction projects, albeit on a reduced scale if utilities
and traffic management are properly coordinated. There are additional grounds for travel delays
in the area, as most of the streets lack sufficient capacity to accommodate additional traffic from
diverted traffic as a result of street closures to accommodate the works.
6. The awareness campaign and the prior notification for the public will be a continuous
activity which the project will carry out to compensate for the above delays and minimize public
claims as result of these problems. These activities will take place sufficiently in advance of the
time when the roadblocks or traffic diversions take place at the particular streets. The reason for
this is to allow sufficient time for the public and residents to understand the changes to their
travel plans. The project will notify the public about the roadblocks and traffic diversion through
public notices, ward level meetings and city level meeting with the elected representatives.
161
7. The PIU will also conduct an awareness campaign to educate the public about the
following issues:
(i) traffic control devices in place at the work zones (signs, traffic cones, barriers,
etc.);
(ii) defensive driving behaviour along the work zones; and
(iii) reduced speeds enforced at the work zones and traffic diversions.
9. The campaign will cater to all types of target groups i.e. children, adults, and drivers.
Therefore, these campaigns will be conducted in schools and community centres. In addition,
the project will publish a brochure for public information. These brochures will be widely
circulated around the area and will also be available at the PIU, and the contractor's site office.
The text of the brochure should be concise to be effective, with a lot of graphics. It will serve the
following purpose:
(i) explain why the brochure was prepared, along with a brief description of the
project;
(ii) advise the public to expect the unexpected;
(iii) educate the public about the various traffic control devices and safety measures
adopted at the work zones;
(iv) educate the public about the safe road user behaviour to emulate at the work
zones;
(v) tell the public how to stay informed or where to inquire about road safety issues
at the work zones (name, telephone, mobile number of the contact person; and
(vi) indicate the office hours of relevant offices.
E. Install traffic control devices at the work zones and traffic diversion routes
10. The purpose of installing traffic control devices at the work zones is to delineate these
areas to warn, inform, and direct the road users about a hazard ahead, and to protect them as
well as the workers. As proper delineation is a key to achieve the above objective, it is important
to install good traffic signs at the work zones. The following traffic control devices are used in
work zones:
Signs
Pavement Markings
Channelizing Devices
Arrow Panels
Warning Lights
11. Procedures for installing traffic control devices at any work zone vary, depending on
road configuration, location of the work, construction activity, duration, traffic speed and volume,
and pedestrian traffic. Work will take place along major roads, and the minor internal roads. As
such, the traffic volume and road geometry vary. The main roads carry considerable traffic;
internal roads in the new city areas are wide but in old city roads very narrow and carry
considerable traffic. However, regardless of where the construction takes place, all the work
162
zones should be cordoned off, and traffic shifted away at least with traffic cones, barricades,
and temporary signs (temporary “STOP” and “GO”).
12. Figure A2 to Figure A12 illustrates a typical set-up for installing traffic control devices at
the work zone of the area, depending on the location of work on the road way, and road
geometrics:
14. Traffic police should regulate traffic away from the work zone and enforce the traffic
diversion result from full street closure in certain areas during construction. Flagggers/
personnel should be equipped with reflective jackets at all times and have traffic control batons
(preferably the LED type) for regulating the traffic during night time.
16. In addition to the delineation devices, all the construction workers should wear
fluorescent safety vests and helmets in order to be visible to the motorists at all times. There
should be provision for lighting beacons and illumination for night constructions.
163
Figure A2 & A3: Work on shoulder or parking lane & Shoulder or parking lane closed on
divided road
164
Figure A4 & A5: Work in Travel lane & Lane closure on road with low volume
165
Figure A6 & A7: Lane closure on a two-line road with low volume (with yield sign) & Lane
closure on a two-line road with low volume (one flagger operation)
166
Figure A8 & A9: Lane Closure on a Two-Lane Road (Two Flagger Operation) & Lane
Closure on a Four-Lane Undivided Road
167
Figure A10 & A11: Lane Closure On Divided Roadway & Half Road Closure On Multi-Lane
Roadway
168
Near Hospital
172
Consultations were done by design engineers with various departments to discuss the project
design and availability of lands required for psoposed components. Details of these
consultations are given below-
S. No. Name of person consulted Date & Place Point Discussions Outcomes
& Designation
1 Mr. Ramesh Saini, Executive 26.10.2017 Existing Sewerage Received Existing
Engineer, RUIDP, System and also met Sewerage As-Built
Sardarshahar PHED Officials with Drawings
Mr.Saini
2 Mr. Meena, Executive 16.11.2017 Existing Water Received Existing
Engineer, PHED, Supply System Water Supply
Sardarshahar System Detail
4 Mr. Sunil Jain, JEn, Nagar 16.11.2018 Ward Map and Collected Ward
Palika, Sardarshahar Nagar Palika Municipal Boundary Map
3 Mr. Pramod Jangir, Executive 01.08.2018 Land for Proposed Suggested site
Officer, Nagar Palika, Nagar Palika SPS & STP visit and land
Sardarshahar finalized
4 Mr. Sunil Jain, JEn, Nagar 01.08.2018 Site visit for Land for STP & SPS land
Palika, Sardarshahar Nagar Palika Proposed SPS & finalized
STP
5 Mr. Sukaran, LDC, Nagar 01.08.2018 Site visit for Land for STP & SPS land
Palika, Sardarshahar Nagar Palika Proposed SPS & finalized
STP
173
Various consultations were done during preparation of IEEt with residents of the town at various
locations to understand their level of satisfaction about the present water supply and sewerage
conditions in town and also to understand their awareness about the proposed works and their
willingness/acceptance of the proposed works under RUSTDIP. Details of these consultations
are given below-
2 28.08.2018 Ward no-3 Present Status of Water Supply People are concerned about
and sewerage system in the the poor supply (intermittent
Local town supply on alternate days) and
Habitants Work Proposed by RUIDP quality of water. No sewerage
Environment & Health impacts in the town
of proposed projects People are supportive of the
Quality of present Water Supply. project.
By the proposed projects of
water supply, chance of water
borne disease will be mitigated
as proper disinfection will be
ensure before supply the water
and there relevant health
implication will be mitigated
due to mitigated in the
area/town.
People are willing to pay for
improved services.
There are no any forest,
wildlife or any sensitive
/unique environmental,
component nearby the project.
Solid waste collection facility is
poor in this area. Town has
lack of solid waste collection
and their proper disposal
facilities.
People demanded for the
measures of dust suppression
such as water sprinkler to
control dust and noise during
construction phase.
Proper care of the safety
arrangement during
construction phase and should
provide traffic diversion routes
to avoid the vehicle congestion
by the contractor.
People are agree with the
proposed water supply works
175
City level Stakeholder Committee (CLC) Meeting (dtd. 13.07.2018)- City stakeholder committee
meeting was organized for Sardarshahar in District Head Quarter, Churu on dtd. 13.07.2018 to
discuss the matter of proposed Water Supply and Sewerage works in Sardarshahar under the
chairmanship of District Collector, Churu in presence of consultants, RUIDP officials, PHED
officials, Municipal Council officials and other invitee members. Proposed scope of works and
technology was discussed in the meeting and it was decided that treated effluent shall be
reused by Municipality in beneficial uses. Minutes of CLC meeting, attendance sheet and
photographs are given below-
report send to ADB. Visual assessment and review of relevant site documentation during
routine site inspection needs to note and record the following:
• What are the dust suppression techniques followed for site and if any dust was
noted to escape the site boundaries;
• If muddy water was escaping site boundaries or muddy tracks were seen on
adjacent roads;
• adequacy of type of erosion and sediment control measures installed on site,
condition of erosion and sediment control measures including if these were intact
following heavy rain;
• Are their designated areas for concrete works, and refuelling;
• Are their spill kits on site and if there are site procedure for handling emergencies;
• Is there any chemical stored on site and what is the storage condition?
• Is there any dewatering activities if yes, where is the water being discharged;
• How are the stockpiles being managed;
• How is solid and liquid waste being handled on site;
• Review of the complaint management system;
• Checking if there are any activities being under taken out of working hours and how
that is being managed.
189
Pre-Construction Phase
Construction Phase
Operational Phase
Brief description on the approach and methodology used for environmental monitoring of
each sub-project
Photos
Summary of consultations
Copies of environmental clearances and permits
Sample of environmental site inspection report
Other
192
Implementation
Pre-Commissioning
Guarantee Period
Tarpaulins used to cover sand & other loose material when transported by vehicles
193
After unloading , wheels & undercarriage of vehicles cleaned prior to leaving the
site
Work at a stretch is completed within a day (excavation, pipe laying & backfilling)
Road is not completely closed; work is conducted on edge; at least one line is kept
open
Road is closed; alternative route provided & public informed, information board
provided
Prior public information provided about the work, schedule and disturbances
Workers using appropriate PPE (boots, gloves, helmets, ear muffs etc)
Workers conducting or near heavy noise work is provided with ear muffs
Pneumatic drills or other equipment creating vibration is not used near old/risky
buildings
Signature
Name Name
Position Position
195
Should you choose to include your personal details but want that information to remain
confidential, please inform us by writing/typing *(CONFIDENTIAL)* above your name. Thank
you.
Project:
* Female
Home address
Place
Phone no.
How do you want us to reach you for feedback or update on your comment/grievance?
196
Mode of communication:
Note/letter
Verbal/telephonic
Action taken:
No
Means of disclosure:
197
1. Night works should be avoided at construction sites specially in residential areas and
should be performed only when day works are not possible due to excessive
traffic/public/pedestrian movement, site of cultural or religious importance, where there is
huge crowd during day hours or any other unavoidable circumstances.
2. Contractor should plan for night works only after directions from PMU/PIU/DSC
3. Contractor should submit plan for night works for approval from PIU.
4. PIU should ensure that prior written information should be given to local authorities such
as district administration, Police/traffic police, line agencies concerned, residents welfare
association/business association/vyaparmandal of the affected areas and their
consents/permissions should be taken prior to start of night works.
5. PIU/DSC engineers should check and ensure that all the preparation as per
management plan is done by contractor and contractor is having all the necessary
equipments and materials for night works.
6. Contractor is required to have following equipments/arrangements for night works-
Contractors should have hand held noise level meter for measurement of noise
during night hours
Contractors should have hand held lux meter for the measurement of illumination
during night hours
Preferably electrical connections is available for running equipments otherwise
sound proof/super silent Diesel Generator set should be available
Sound level should not increase as per following-
Type of area of work Maximum noise level dB(A)
Industrial 70
Commercial 55
Residential 45
Silence zone 40
Illumination should be as follows-
Minimum Areas to be Type of work activity
illumination illuminated
(lx)
54 Illumination General work area lighting, and
throughout the performance of visual tasks of large
work area size, or medium contrast, or low
require accuracy
108 Illumination of Performance of visual tasks of
work area and medium size, or low to medium
areas adjacent contrast, or medium required
to equipment accuracy
216 Illumination of Performance of visual tasks of
task small size, or low contrast or high
required accuracy or fine finish
As far as possible ready mix concrete from batching plant to be used, otherwise
the concrete should be prepared away from residential areas and brought to the
site
198
All the noise activity like hammering, cutting, crushing, running of heavy
equipments should be done in day time and avoided in night time
Workers engaged in night works should have adequate rest/sleep in day time
before start of night works
Worker engaged for night works should have previous experience of night works
and should be physically fit for such works including clear vision in night
All the necessary provisions of traffic aids such as traffic signals, road signage,
barricades, cautions boards, traffic diversion boards etc. should be available with
fluorescent/retro-reflectivearrangements
Workers should be trained before start of night works about risks and hazards of
night works and their mitigation measures and should be provided all the
protective aids (PPEs) including fluorescent/retro-reflective vests
Horns should not be permitted by equipments and vehicles
Workers should not shout and create noise
First aid and emergency vehicles should be available at site
Emergency preparedness plan should be operative during night works
Old persons and pregnant women and women having small kids should not work
in night time
All the vehicles and equipments being used at night works should have adequate
type of silencers/enclosures/mufflers to reduce noise
All the vehicles should be checked for working head lamps, tail lamps, inner lights
etc. before start of night works
7. PIU/DSC site engineers and contractors safety personnel should closely monitor the
safety of works continuously and noise and illumination levels on hourly basis and
maintain photographic and videographic records as well as register the observations
8. Night works should be stopped early in the morning at least one hour before start of
pedestrian/traffic movement
9. After completion of night works all the site should be cleaned and maintained obstruction
free for day time movement of vehicles and pedestrians
10. Drivers and workers should be alert and responsive during night works
11. All the wages to workers working in night hours should be as per the applicable labour
acts
12. Avoid any nuisance which may create problems to nearby habitants and work peacefully
during night hours
13. Night works should not be conducted near hospitals and during peak seasons such as
peak tourist season, students’ exam times etc.
199
Existing WSP at STP 2 MLD, North Campus Site of proposed STP 5.42 MLD at North
Campus
Site of proposed SPS-6 near BSNL office Discharge of untreated sewage in open land at
Bikaner road
200
Existing STP 5 MLD at South Campus Location of proposed STP 7.7 MLD at South
Campus
Location of proposed SPS-8 near Shyamdev Location of proposed STP 2.3 MLD at
Hotel Ghantaghar Road
Existing PHED headworks at PHED campus Location of proposed CWR and pump house at
PHED campus
Appendix 16: Environmental Monitoring Plan - Ambient Air, Noise, Water and Soil
1. Under RUIDP works Environmental Monitoring will done for ambient air, noise, surface
water, ground water and soils with following parameters-
A. Ambient Air Quality- Particulate Matters PM10, Particulate Matter PM2.5, SOx,
NOx, Carbon Monoxide (CO) as per methods and norms approved by CPCB
B. Ambient Noise Quality- Lday and Lnight (in LeqdBA) 24 hrs basis as per methods
and norms approved by CPCB
C. Surface Water Quality- pH, Turbidity, Total Hardness, DO, BOD, COD, Chloride,
Hg, Iron, TDS, TSS, Calcium, Zn, Cr+6, Magnesium, Copper, Manganese,
201
3. During construction stage below monitoring should be done on minimum quarterly basis at
the following sites-
Note -
i. All the tests should be done by labs approved by CPCB and/or RPCB and should be
accredited by NABL
ii. All the tests should be done as per the norms and methods approved by CPCB/RPCB
iii. All the meteorological data like weather, wind, location, nearby features etc. should be
recorded during sampling and indicated in the report for ambient air quality
iv. If surface water is not available within 500 meters of the site, ground water quality
monitoring should be done from the vicinity within 500 meters and if both surface and
ground water is available at any site both should be taken
v. For air quality monitoring, if any two sites are within the distance of 2 kms from each
other, only one sampling can be done at any site
* Sensitive receptors are hospitals, schools, any major religious place etc
203
Appendix 17
Guidelines for Reuse of Treated Effluent and Sludge from STP for Beneficial
Purposes
(Source: Manual on Sewerage and Sewage Treatment Systems, CPHEEO, Ministry of
Urban Development, Govt. of India)
Labourers working on the sewage treatment and operations may suffer from a number of
aliments directly attributed to handling of sewage. In view of this it is desirable to disinfect
sewage and where feasible mechanize sewage operations.
The staff of sewage operations must be well educated in the sanitary rules on the utilization of
sewage for irrigation as well as with personal hygiene. All persons working in sewage farms
must undergo preventive vaccination against enteric infections and annual medical examination
for helminthiases and be provided treatment if necessary.
Sewage treatment plants should be provided with adequate space for canteens with proper
sanitation, wash-stands and lockers for irrigation implements and protective clothing. Safe
drinking water must be provided for the workers and for population residing within the effective
range of the sewage treatment plants.
All workers should be provided with gum boots and rubber gloves, which must compulsorily be
worn while at work. They should be forced to observe personal hygiene such as washing after
work as well as washing before taking food. The use of antiseptics in the water used for
washing should be emphasized. The farm worker should be examined medically at regular
intervals and necessary curative measures enforced.
The worker should take precautions because a large number of coliform groups, various kinds
of micro-organisms, and egg parasites exist in sewage. The workers should strive to maintain
good health by taking care of the following points:
• After work and before having a meal, always wash hands and disinfect them.
Maintaining Cleanliness The worker should maintain each facility in a clean and neat
condition.
• The flors of workrooms, stairs and corridors should be cleaned at the appropriate frequency to
maintain them in a clean condition
Health Check Workers should receive health check once a year to maintain their health, and
prevent illnesses or detect them at an early stage. The results of the health check should be
maintained as records. Recommended items to be inspected during the health check are as
given below.
• Urine analysis.
• Electrocardiogram analysis
• Make provision and improvement of welfare measures and facilities as may be prescribed
Corrective Measures When a worker has symptoms of an illness listed above, the plant
engineer should ensure that the worker is checked-up by a specialist doctor and receives proper
treatment and care and should take the following actions considering the content of work done
by the worker:
Cultivation of crops that are eaten raw should be banned. Cultivation of paddy in bunded fields
is likely to give rise to sanitation problems and hence is undesirable. Growing of non-edible
commercial crops like cotton, jute, fodder, milling varieties of sugarcane and tobacco would be
suitable. Cultivation of grasses and fodder legumes, medicinal and essential oil yielding plants
like menthol and citronella may be allowed. Cultivation of cereals, pulses, potatoes and other
crops that are cooked before consumption may be permitted, if sewage is treated and care is
taken in handling the harvests to ensure that they are not contaminated. Cultivation of crop
exclusively under seed multiplication programmes would be advantageous as these are not
consumed. As an additional safeguard, sewage irrigation should be discontinued at least two
months in advance of harvesting of fruits and berries, one month for all kinds of vegetables and
a fortnight for all other crops. Direct grazing on sewage irrigated farms should be prohibited.
Crops receiving excessive dosage of nitrogen show superflous vegetative growth and decrease
in grain or fruit yield. The phosphate deficit of sewage, therefore, should be made good by
supplementing with phosphate fertilizers, the extent of phosphate fortification depending upon
the nature of crop and its phosphate requirements. As the availability of phosphate is low in the
irrigation water it would be desirable to apply the required quantity of phosphatic fertilizer at the
time or even (about a fortnight) before the sowing or planting of the crop. Even when sewage
nutrients are balanced by fortification, irrigation with such sewage may supply excessive amount
of nutrients resulting in waste or unbalanced growth of plants with adverse effects on yields. It
may therefore be necessary to dilute the sewage. Dilution also helps in reducing the
concentration of dissolved salts and decomposable organic matter in the sewage thus,
decreasing hazards to the fertility of the soil. It is desirable to limit the BOD and total suspended
solids of sewage to be disposed on land for irrigation, as per relevant standards. There is a
need to take caution on describing nutrient supply capacity of sewage particularly in the case of
availability of phosphorus because there is a possible conversion of available phosphorus in
206
unavailable mode in the presence of heavy metals present in the sewerage. This happens
commonly in high as well as low pH soils.
During rainy and non-irrigating seasons, agricultural practices may not need any water for
irrigation. Even during irrigating season, the water requirement fluctuates significantly. Hence,
satisfactory alternative arrangements have to be made for the disposal of sewage on such
occasions either by storing the excess sewage or discharging it elsewhere without creating
environmental hazards. The following alternatives are generally considered: a) Provision of
holding lagoons for off-season storage. They enable irrigation of a fied area of land to varying
rates of crop demand. They may also serve as treatment units such as aerated or stabilization
lagoons, provided the minimum volume required for treatment is provided beyond the flow-
balancing requirement. b) Provision of additional land where treated sewage is not required on
the main plot of land c) Discharge of surplus treated sewage to river or into sea with or without
additional treatment. Combining surface discharge facilities with irrigation system is quite
common and often quite compatible. d) Resorting to artificial recharge in combination with an
irrigation system where feasible.
When sewage is treated and discharged into perennial flowing rivers and the blended river
water is drawn downstream of the point of such blending as raw water for treatment in public
water supply schemes. This is indirect potable use after blending. This is historical and ongoing
all around. However, of late, the organic load due to the discharged treated, partially treated and
non-point sewage becomes in excess of the self-purifying capacity of the river. Thus, the river
water is not actually fresh water. The water quality of Yamuna river for Agra water supply
scheme requires to be fist treated in MBBR to purify the river water to a level as raw water for
the downstream WTP. When it passes through flowing surface water it has the potential
disadvantages of contamination by human and animal activities adding organic matter and
waterborne pathogens unless the river stretch is protected from such activities. The guiding
principle in such cases for the ULBs will be to at least intercept the sewage outfalls and provide
adequate STPs and follow the recommended quality criteria for the treated sewage.
There are locations where the rivers are not perennial or almost dry throughout the year except
some monsoon runoff. In this case the discharged treated sewage sinks into the aquifer zone
and is extracted by infiltration wells or galleries. The advantage of direct dilution from surface
water is lost, but the additional purification in the soil and dilution from the aquifer water are
happening. An example is the case of the Palar river course in Tamilnadu. The surface water
flow in this occurs only for about a week if the monsoon is normal and if the water spills beyond
the upstream impoundments. The aquifer however supports the public water supply of over 30
habitations along its dry tract of nearly 80 km before the sea. The partly treated sewage of the
en-route habitations does reach this river course as intervals. So far, no epidemics have been
met with. This may be due to the above said additional purification in the soil and dilution by
207
aquifer water. However, if these are exceeded by the contamination load, there can be
immediate health problems. The guiding principle in such cases for the ULBs will be (a) to keep
a check on the raw water quality from the infiltration wells to detect sudden increase in
contaminants and (b) at least intercept the sewage outfalls and provide adequate STPs.
208
Appendix 18
Normal and heavy rainfall event affect our ongoing works, It should be our conscientious effort
to ensure that such events do not prove to be problematic to people and structures in town.
During monsoon PIU/PMDSC should ensure that any further excavation work is taken up only
after ensuring that the earlier work is in safe stage. It is desired that DCM/ACM & Ex En PIU
should inspect all sites during rains and take proactive actions.
Some of the precautions and mitigation measures to be taken are discussed below-
1. The execution of works having deep excavation in smaller lanes and congested areas
should be completed well before monsoon. The works of deep excavation during monsoon
should not be preferably taken up or extensive care should be taken for execution of such
works.
2. The settlement in refilled trenches of sewerage and water supply lines may occur during
monsoon. PMDSC and PIU team should inspect all sites after a storm to identify such
reaches and take immediate corrective action by proper refilling and compacting.It is
responsibility of all engineers to look after this activity during monsoon and ensure
corrective actions from Contractor’s side.
3. The contractor’s crew should be equipped with vehicle, gum boots, raincoats, torch etc. to
tackle such situation during and after rains. Adequate quantities of earth, debris and gravel
should be stacked at strategic places so that no time is lost in procuring such material.
4. In trenches where pipe laying has been done and duly tested and approved, refilling should
be done and all surplus material relocated to safe disposal sites such that it does not
obstruct traffic or waterways.
5. All open ends of WS and WW pipelines should be firmly plugged to prevent debris from
entering the pipeline. Manhole covers of sewer lines should be fixed in place to avoid any
harm to road users.
6. Drains are primary or secondary carriers of storm water. Any unutilized construction
material should be relocated to allow free passage of storm water. Surplus earth should be
suitably and immediately be relocated to avoid earth from falling into the drain so that
choking does not occur.
7. Overhead works should not be carried on in-weather conditions that threaten the safety of
workers. More frequent checks on scaffold and bracings should be done during monsoon
season.
8. Additional precautions should be taken of the power lines, ignorance and carelessness can
cause major accidents and casualty.
9. Take preventive measures for water logging in working areas by providing dewatering
pumps. Place bright and reflective warning signs.
10. Inspection should also be carried out before resumption of work after a shower/rain.
11. Storage of Construction Material: Steel & Cement are vital ingredients for quality
construction work but in absence of proper storage, especially during monsoon, cement
and steel may rapidly decline in quality and strength. Care should be taken to protect these
materials and use of any exposed material should be allowed only after conducting fresh
tests. Improper storage of such material should be reported to SE PIU/ACM PMDSC and
209
Additional Precautions
1. Adequate set up and resources such as dewatering pumps, electrical routings etc should
be planned ahead. Water logging on main roads to be avoided, where construction works
are going on.
2. Ensuring the monsoon specific PPE’s issued in adequate and are used during monsoon.
3. Use of electric extension box should be avoided; extension cables (if used) should not be
wet and damaged.Cables connections should be only weatherproof/waterproof.Electrical
and HSE personnel of contractor should visit permanent and running sites regularly.
Transparent protective sheets/rain sheds should be placed for the power distribution
boards.
4. Welding machines, bar cutting machines etc. should be kept in dry conditions; should not
stand in water logged area. Brakers and Drill machines should not be used when raining;
dirt/mud should be scrubbed with cloth.
5. Special Trainings to all drivers and operators on safe practices and all vehicles/
equipment’s maintenance checks to be more frequent.
6. High boom equipment to be stopped during blowing of high speed wind and rain storm.
Arresting of parked vehicles, equipment during mansoon should be done.
7. All chemicals should be stored as per MSDS, chemicals to be protected from water ingress.
Chemical waste should be disposed for preventing overflow of chemicals.
8. At labor camps following precautions should be taken:-
Maintaining hygiene & proper housekeeping.
Additional health checkup camp to identify seasonal diseases
Preventive measures on mosquito/parasite breeding mainly in work locations and
camps
Frequent cleaning of toilets
To avoid water borne diseases, high level of cleanliness to be maintained, drinking
water containers need to be cleaned and kept covered. Walk areas and pathways to
be covered with Murom and soft rock particles (to avoid soft soil conditions).
Obstacle free approach to rest sheds, camp and toilets.
Proper illumination, provision of battery operated emergency lights
No bonfires inside resting sheds. No use of wood.
SE–PIU and DCM/ACM-PMDSC should oversee the arrangements to effectively deal with the
eventuality.
EHS officer of contractor should visit each site and camps more frequently. Contractor/EHS
officer will also impart training on safe working methods during Monsoon and will keep a daily
watch on weather conditions to share with site team to act accordingly.
Contractor should organize Monsoon Health Camps and Monitor Workmen Habitat and
Hygiene.
210
Appendix 19: Letter of Water Allocation for proposed Water Supply Works
211
10. Sewerage networks laid under the project (type, dia and length):
1 150 137995.00
2 200 5086.50
3 250 2989.50
4 300 2112.50
5 350 1614.00
6 400 632.50
7 450 2558.00
8 500 49.00
9 600 1239.50
10 700 266.00
11 800 422.50
12 900 212.00
13 1000 783.50
Total 155960.5
89.58
4. Near Railway Crossing SPS 10 STP 1 (5 MLD) 313.31
13. Areas of different units of plant (sq. mtrs): 60940 Sqm Considering Two STP’s
18. Tree plantations done under this project (nos. and types of trees): 25 nos at 2 MLD Plant
& 25 nos at 5 MLD
19. Date of completion of construction works of STP: 31.05.2018 ( Hand over to Nagar
Palika on dated 23.06.2018)
21. Status of Consent to Establish (CTE) from Pollution Control Board: obtained
23. Status of Consent to Operate (CTO) from Pollution Control Board: obtained/not
obtained- in process
27. Details of total covered area with this STP: (ward nos.) Ward No 4 to 8, 11, 16, 17, 20 to
27, 31, 33 to 35.
29. Whether trail run completed, if yes give date, if no give tentative date: Yes (
31. What are the parameters of discharge of treated effluent: BOD <100mg/l, COD<250mg/l,
SS<100mg/l
213
32. What are the proposals/methods for reuse/disposal of treated effluent from STP: Under
the current scheme there is a proposal for the construction of a Underground Tank,
Pump House, Overhead Tank, along with 100m DI (K-7) pipe for recycling of treated
effluent of STP. The treated effluent will be used by Gaushala Samriti.
33. What are the proposals/methods for reuse/disposal of treated sludge from STP: same as
above
34. Is this plant anywhere related/dependent on proposed STP under RUIDP Phase-4
project: Yes
35. Status and type of electricity connection: (connection number and approved load, KW)-
02 nos connection at STP and 04 nos. connections at SPS
36. Whether DG set installed, if yes give capacity and type of DG set: Yes - 02 nos. 40KVA
at STP and 02 nos 125 KVA at SPS & 60 KVA at another 02 SPS
37. Whether consent from Pollution Control Board taken for DG set:Yes
38. Fresh water requirements/day (for domestic use) and type of water supply: 25.2MLD for
Sardarshahar Town
39. If tube well installed, provide number and capacity of tube well and status of clearance
from Ground Water Board for tube well: 48 Nos, Total Capacity of Tube Well 5.5MLD
40. Numbers of employees proposed for operation of plant (designation wise numbers of
employees): 10 Nos
41. Is rain water harvesting system established, if yes, provide details, drawing and cost of
rain water harvesting : No
45. Whether provisions for odour control taken in design, if yes give details:
LT Panel at Paloo
217
Transformer at Paloo
AIS at SADASAR
218
Transformer at SADASAR
LT Panel at SADASAR
Existing Transformer
Table 5.2 : Existing Pumping system at Clear Water Pumping staion ,Hanumangarh Road
Flow Year of
Name of Head Motor No. of
Supplying to (m3/hr) installat
HW/CWR (M) (KW/HP) Pumps
ion
Bhairudera 44 55/75 262 2(1W+1S) 2006
Apart from above pumps, there are 16 more pumps installed in this pumping station which are
supplying water in the nearby villages which is beyond municipal boundary of Sardarsahar
hence there pumps are not included in scope of this project.
221
BhairuderaOHS Required
2. 1500 18 2006
R strengthening
Required
3. HolideraOHSR 500 18 2006 strengthening
RamnagarOHS Required
4. 1500 18 2012 strengthening
R
SuryamandirOH Required
5. 1500 18 2007-08 strengthening
SR
Hydro test is
6. Zone 5 OHSR 350 18 2012 required
Hydro test is
7. Zone 6 OHSR 350 18 2012 required
5.3.1 Holi DhoraOHSR: This OHSR was constructed in 2006. This OHSR is continuously
supplying water hence condition of reservoir could not assessed from inside.
OHSR photo
224
5.3.2 Zone 5 OHSR: This OHSR is constructed in 2012 but is not in use currently. Hence it is
proposed to do hydro testing before using this OHSR.
5.3.3 RamnagarOHSR: This OHSR was constructed in 2012. This OHSR is continuously
supplying water hence condition of reservoir could not assessed from inside. But there are
spots of leakage observed at bottom dome hence it is required to do rehabilitation of this
OHSR.
Spots of leakage on conical
dome.
5.3.4 Zone 6 OHSR: This OHSR is constructed in 2012 but is not in use currently. Hence it is
proposed to do hydro testing before using this OHSR.
5.3.5 Zone 6 GLSR: This GLSR was constructed in 2000. This GLSR is continuously supplying
water hence condition of reservoir could not assessed from inside. But there are spots of
leakage observed in GLSR wall hence it is required to do rehabilitation of this GLSR.
228
5.3.6 BhairuderaOHSR : This OHSR was constructed in 2006. This OHSR is continuously
supplying water hence condition of reservoir could not be assessed from inside. But there are
spots of leakage observed at bottom dome and conical dome hence it is required to do
rehabilitation of this OHSR.
This OHSR consist of boundary wall all around. There is no plaster on the boundary wall & MS
Jali provided over boundary wall is also damaged.
229
5.3.7 SuryamandirOHSR : This OHSR was constructed in 2007. This OHSR is continuously
supplying water hence condition of reservoir could not be assessed from inside. But there are
spots of leakage observed at bottom dome and conical dome hence it is required to do
rehabilitation of this OHSR.
230
A route survey has been carried along the alignment of the Existing Rising Main from
Hanumangar Road CWR to different OHSR location at Sardarsahar Town. The existing line is of
DI make and the condition of the line has been found to be satisfactory and barring its hydraulic
suitability for the Ultimate Demand of Sardarsahar Town it can be used further. Presnetly there
is no transmission main from CWR to Zone-5 & Zone -6 OHSR.
Existing Transmission main
Pipe Line in workable
condition.
The Existing Distribution Network was commissioned in the year 2003 as per AapniYojna
Scheme Phase-I, laying work started from 2001. At some of the places the condition of the
existing line is detoriating frequent leakage problems are being encountered at random. In most
places accessibility for the maintenance work poses a big problem as the existing line is more
than 10 ft deep, these problems is mainly encountered in Ward No :- 05 to 08. In other places
depth of more than 7 ft is common. At some places the Existing Distribution Line alignment
passes through houses and permanent structure making the system more vulnerable for
maintenance works.
236
Appendix 22: Details of land availability, ownership and NOCs for sites
Project Location Ownershi Area Khasra Remarks
Component p required No.
(sq mtr)
Construction Near Ashoke Gandhi Letter moved to Trust committee
of STP (1.60 Circle Vidyaman
MLD dor Trust
Construction Existing STP Nagar 5500 303 Existing STP Sardarshahar North
of 5.40 MLD Sardarshahar Palika Campus)
North
Campus)
2.30 MLD near BSNL Gausala 500 Letter moved to Gausala committee
capacity - Office Committe
SPS e
Appendix 1: Letter of E.O Nagar Palika to Gausala Samiti for allotment of land for
proposed works
Transcript
To The President,
Gausala Committee,Sardarsahar
Sub- Provide land for the constrction of 2 nos of SPS and 1 nos of STP
Ref-RUIDP letter no-4583-85 dated 05.07.2018
The land required for the above works are as below:
During site visit of RUIDP officials it was noticed that Nagar palika land are not available nearby
areas for the above works.Sufficient encumbrance/unproductive land of Gausala committee are
available.Thus it is requested to allot/provide the land for the construction of 2 nos of SPS and
one nos of STP under RUIDP-Phase 4.
Executive officer,Nagar Palika,Sardarsahar
238
Appendix 1(A) Letter of E.O Nagar Palika for confirmation of availability of land for 1
nos of STP9Ghanta Ghar Road) and 2 nos of SPS
239
Appendix 2: Confirmation letter of E.O Nagar Palika that Land for STP near Existing STP
at both south and North campus are avaialble
See -Appendix2(a)
240
Appendix 2(A) Letter of E.O Nagar Palika to ED,RUIFDCO regarding avialability of land
in which in south and north campus for Construction of 2 Nos of STP
Annx. B (Draft RP)
Contract Package: RSTDIP/SRD/01
Draft Resettlement Plan
_________________________________________________________________________
This resettlement plan is a document of the borrower. The views expressed herein do not
necessarily represent those of ADB's Board of Directors, management, or staff, and may be
preliminary in nature.
In preparing any country program or strategy, financing any project, or by making any
designation of or reference to a particular territory or geographic area in this document, the
Asian Development Bank does not intend to make any judgments as to the legal or other status
of any territory or area.
CURRENCY EQUIVALENTS
(as of March 2018)
ABBREVIATIONS
APPENDIX
Appendix 1: Letter of E.O Nagar Palika to Gausala Samiti for allotment of land for proposed
works ................................................................................................................................... 28
Appendix 2: Confirmation letter of E.O Nagar Palika that Land for STP near Existing STP at
both south and North campus are avaialble ................................................................... 29
See -Appendix2(a) .................................................................................................................................... 30
Appendix 2(A) Letter of E.O Nagar Palika to ED,RUIFDCO regarding avialability of land in which
in south and north campus for Construction of 2 Nos of STP .................................... 31
Appendix 2(B) Letter of E.O Nagar Palika for confirmation of availability of land for 1 nos of
STP9Ghanta Ghar Road) and 2 nos of SPS .................................................................... 29
Appendix 3: Details of land availability, ownership and status of No Objection Certificate (NOC)
for sites ............................................................................................................................... 32
Appendix 4: Location of proposed site of STP-1 (North Campus) ..................................................... 35
Appendix 5: Location of proposed site of STP-2 (South Campus) ..................................................... 36
Appendix 6 : Location of proposed site of STP-3 Near Ghanta Ghar ................................................. 37
Appendix 7 : Location of proposed site of SPS- near Doordarshan Relay Kendra .......................... 38
Appendix:8 Location of proposed site of SPS- near Shyam Deb Hotel ............................................. 39
Appendix 9: Total proposed length of sewer (Designed Length) ............ Error! Bookmark not defined.
Appendix 9 (a) Diameter wise proposed pipe line detail (DMA Wise........ Error! Bookmark not defined.
Appendix 10: Profile of Affected Person ............................................................................................... 40
Appendix 11: Photographs of sample Survey ...................................................................................... 43
Appendix 12: Detail of Sample survey ................................................................................................... 45
Appendix 13: Photographs of Transect Walk ....................................................................................... 46
Appendix 14: Summary of Public Consultations .................................................................................. 48
Appendix 15: – Sample Sub-Project Leaflet .......................................................................................... 53
Appendix 16: Grievance Format ............................................................................................................. 54
Appendix 17: Minimum Wage Rate in Rajasthan (Jan 2018) ............................................................... 55
Appendix 18: Minutes of CLC meeting .................................................................................................. 57
Appendix 19– Draft for RP implementation Officer .............................................................................. 62
Appendix 20 : Sample Monitoring Template ......................................................................................... 65
Appendix 21 : site photographs ............................................................................................................. 67
i
EXECUTIVE SUMMARY
1. Background: The proposed Rajasthan Secondary Town Development Investment Program
(RSTDIP) will support the ongoing efforts of the Government of Rajasthan (the government)
towards improving the water and wastewater services in 40 towns1, each with population
between 50,000 and 100,000, in the state. The project will investing the rehabilitation and
expansion of water supply network for reduction of nonrevenue water (NRW), 24x7 water
supply, the rehabilitation and expansion of sewerage network, modernization and new
construction of water supply and waste water treatment plants, as required, fecal sludge
management, and decentralized waste water management systems in the project towns. The
project is expected to increase operational efficiency, improve service delivery, and result in
positive impact on health and quality of life for the residents of project towns in the state.
2. Sardarshahar city has the administrative headquarters in Churu district. There are 7 tehsils in
the district Churu, Ratangarh, Taranagar, Rajgarh, Sardarshahar, Sujangarh and Bidasar.
Bidasar is the newest Tehsil. The total area of Sardarshahar is 2473 acre.The municipal area
of Sardarshahar town has been divided in to 40 wards. Sardarshahar lies towards the North
East of Bikaner at a distance of 136 Km by Road on the junction of State Highway No.6 and 7.
It is directly connected to Delhi, Jaipur, Ganganagar, and Bikaner by Road. The Only Rail Link
with Ratannagar was provided in 1916 in erstwhile Bikaner State Time. Sardarshahar town is
located at 74o27’. Longitudinal east and 28o26’ latitude North at an Altitude of 224m above
mean sea level.
3. Recently, under UIDSSMT project; two STPs and 4 SPSs are constructed in the town and core
area of town is covered by sewerage networks and house connection is under progress by
Municipal Council, but entire sewerage system is not operational. Therefore, most of the
residential, commercial buildings and educational institutions are still dependent on septic
tanks and soak pits. The effluent from the septic tanks directly drain into the open drains. This
drainage is pumped to discharge in the outskirt low lying areas of the town. Therefore
sewerage system proposed in the town along with existing sewerage system, will enhance
environmental and sanitation conditions of the town and increase liveability conditions of
residents.
4. Presently water is supplied to consumers on daily basis for 2-4 hours. Gross water supply rate
is around 100 litres per capita per day (LPCD) but water received at consumer end is about 80-
85 LPCD only, which is less than standard of 135 LPCD. This is due to heavy losses reported
in the existing distribution network (about 40-45%). As the distribution mains consists of about
92% of uPVC pipes laid almost 15 years ago, frequent bursting, leaking occurs, which leads to
high percentage of NRW. The water distribution network is old, profusely leaking and is badly
in need of rehabilitation and replacement. Proposed water supply in the town will increase the
supply rate to consumer up to CPHEEO standard rate and will reduce NRW in the town.
5. Subproject Description: Sardarsahar is one of the town selected under RSTDIP and subproject
components: Sewerage- (i) Construction of 3 STPs of 5.40 MLD, 7.30 MLD and 1.60 MLD
capacity with CWR and OHSR for reuse of treated effluent (ii) 2 nos. of SPSs (0.65 MLD and
1
Abu Road, Badi, Balotra, Barmer, Banswara, Chomu, Dausa, Didwana ,Fatehpur, Jaisalmer, Jalore, Jhalawar,
Karauli, Kuchaman, Sardarsahar, Laxmangarh, Makrana, Nimbeheda, Nokha, Pratapgarh, Rajgarh, Rajsamand,
Ratangarh, Sardar Shahar, Sri Dungargarh, Suratgarh, Shahpura (Bhilwara), Shahpura (Jaipur), Sirohi, Tijara and
Heritage towns i.e. Bandikui, Deeg, Dungarpur, Jobner, Khetri, Kama, Mandawa, Nawalgarh, Pillibanga & Sambhar-
Phulera
ii
2.30 MLD capacity) (iii) sewer network of 68 km including 12 Km trenchless laying(iv) House
service connection-5600 (v) Electrical and Mechanical works. Water Supply-(i) Construction of
new CWR of 2400 KL at HanumangarhRooad CWR headworks, (ii) Rehabilitation of OHSRs at
Bairudan, Holidhora, Suryamandir, & Ramnagar (iii) Construction of boundary wall at Zone-05,
Ramnagar, at Behrudar, (iv) Construction of pumping station of 35 x 10 m at Hanumangarh
Road CWR headworks, (v) laying of Rising Main- 8860 mtr, (vi) water supply pipe for
distribution networks- 194 Kms. (vi) House service connection-22000
6. Resettlement Plan: This Resettlement Plan (RP) document is prepared for proposed Water
supply and Sewerage Subprojects in Sardarsahar town and is in line with the Resettlement
Framework (RF)2 prepared for the implementation of social safeguards under (RSTDIP).
7. Scope of Land Acquisition and Resettlement: No involuntary land acquisition of private land is
anticipated for this project. Summary of Resettlement Impact Consistent with the subproject
selection criteria, rehabilitation is prioritized over new construction to avoid / minimize
involuntary resettlement impacts. STP (1.60 MLD proposed at Ward No 19, Ghantagar Road)
will be constructed in the vacant/unproductive land. The land required for the STP are 1500 sq
mtr and sufficient land is available which are under the jurisdiction of Gausala committee and
will be transferred to Nagar Palika. (Nagar Palika have moved the letter to Gausala Committee
for allotment of lands for the above works.(See annexure 1 & 1(A)). 7.30 MLD STP
proposed at Existing STP Sardarshahar South Campus,and 5.40 MLD STP at Existing STP
Sardarshahar North Campus . Land required for the STPs are 7300 sq mtr and 5400 sq mtr.
The vacant land 26500 sq mtr and 13725 sq mtr are available within the existing campus for
the new STPs.. This lands were also initially under the jurisdiction of Gausala Committee and
have allotted to Nagar Palika during construction of STPs under UIDSSMT project. Agreement
has been made between Nagar Palika and Gausala committee during UIDSSMT worksfor the
allotment of such land..(See appendix 2&2(a)). (Summary Table on the Land Revenue
Records of Proposed Works are attached in Appendix 3 and Google Maps of Proposed STPS
are attached in Appendix 4 to 6). 2 nos of Sewerage Pumping Station of 0.65 MLD near
Shyam Deb Hotel &2.30 MLD capacity near Doordarshan Relay Kendra will also be
constructed in the unproductive/vacant Land. The lands required for the SPS are 500 sq mtr
and 1000 sq mtr which are presently under the jurisdiction of Gausala Committee and will be
allotted to Nagar Palika for the above works. Nagar Palika have moved the letter to Gausala
Committee for allotment of lands for the above works.( See annexure 1& 1(A))., (Summary
Table on the Land Revenue Records of Proposed SPS are attached in Appendix 3 and Google
Maps are attached in Appendix 7&8 ). Clear Water Reservoirs- – 2400 KL will be constructed
in the existing campus of PHED.Unused vacant land available in the campus for the said
works.
8. Pipeline Works: Water pipeline and Sewer network pipeline are proposed within the
boundaries of RoW3, of government roads. No impacts on structures (neither Temporary nor
Permanent) and CPRs4 is envisaged. However, during laying of pipeline, due to loss of access,
temporary livelihood loss to roadside vendors, Kiosks, is envisaged. The diameter of pipeline
ranges from 75 to 500 mm depending on the road width which are 2 mtr to 20 mtr. Ref
appendix 9 & 9(a) for further details.
2 RF of Phase-4
3 PWD/ULB has ownership of all the roads.
4
Common property resources include public resources, community-owned facilities or cultural property such as
temples, shrines, public utility posts, etc, that the landless poor and vulnerable depend on for survival
iii
9. To identify temporary impacts and to collect socio economic profile of DPs, a transect walk
followed by visual screening on the proposed alignment was conducted ( Profile of affected
person along transect walk and methodology along with photographs is appended at Appendix
10 to Appendix 13 has the photographs of transect walk) on the proposed alignment. After
visual screening it is confirmed that laying of pipeline may result into temporary loss of income
to road side vendors. To ascertain the socio economic profile of potential DPs, the proposed
network length was classified in two categories i.e Busy Market Area and less busy areas
(semi commercial market/ areas). Since, the impact in semi commercial areas could be easily
avoided through a town specific mitigation plan (road width being sufficient) , socio economic
survey was carried out in main commercial/ market areas. Before survey, the visual screening
of all these areas was conducted and tentative head count was done followed by 20% (59 nos)
survey of potential DPs of all the areas. The rationale behind selection of busy market area as
representative sample to conduct socio-economic survey is to track worst case scenario. It may
be expected that during implementation, with proper mitigation measures, the intensity of
impacts may be lessened or altogether avoided. The RP would be updated accordingly. Survey
was conducted in all Busy areas, the result of Survey conducted was extrapolated and
accordingly it is estimated that, a total of 295 APs (close to the visual screening) along
roadside with movable/transitory businesses5 might be affected due to pipe laying in the right
of way. These potential DPs are non-titled movable /transitory structure (push carts etc.)6
owners. Out of 295,10 nos of DPs comes under vulnerable category.(See appendix 10)
10. As per information from design engineers, maximum number of days the vendors/kiosks will
experience loss of access/disruption of livelihood is 14 days which can be further minimized by
scheduling civil works at night time or non-market day and laying of pipeline in phases.
Temporarily affected persons (APs) will be assisted in moving to the other side of the road and
returning to their structures after construction is completed. Where moving is not required,
access will be ensured by the contractor through measures prescribed in bidding documents.
11. The construction period will be minimized and is estimated to be less than 14 days per section
of work for sewerage pipeline. Though, the construction period is specified, livelihood losses
will be estimated for 14 days considering delays in works and road restoration (which force
movable vendors to operate from different place)., It will be suggested that sewerage works
should be carried out at parallel to minimize impacts on stretches where both the works are
proposed.
12. However, initial impact assessment will be re-assessed and reconfirmed after finalization of
detailed design and finalization of alignment through detailed measurement surveys on sites/
sections of pipeline alignment and accordingly to be updated in the RP prior to implementation.
Transect walk data/analysis will be updated road wise where pipelines will be laid before start
of civil works and finalization of SIP7 by the contractor and revised RP will be submitted to the
5 Sample survey was conducted in key representative areas and data generated for entire town (taking Phase II& III
RF and RP as base). Refer appendix 6 for further details.
6
Resettlement impacts based on the preliminary design.
7 Taking, RUIDP Phase III, RF and methodology of initial impact assessment, as a base, transect walk was
conducted in municipal areas and visual screening of town in light of DPR (preliminary DPR as the final designing
and alignment will be done by Contractor due to DBO methodology of operation) was done. Since the town municipal
area was limited, visual screening has been conducted for entire town. It is important to mention that, similar to
Phase III, sample survey has been conducted in key representative area ( required for initial impact assessment and
for basic socio economic profiling of DP) and it is expected that contractor will conduct detailed socio economic
survey of the entire town (similar to Phase III) before start of civil work (after SIP) and updating and implementation of
RP is kept under scope of Contractor.
iv
ADB for approval. A 100 percent census and socio-economic surveys will be undertaken to
register and document the status of affected people (APs) within subproject impact areas.
13. The pipelines are proposed to be laid underground within the existing available road ROW.
Diameters of proposed pipeline to be laid ranges between 75mm to 500 mm depending on the
width of the roads that vary between 2 to 20 m to minimize economic and traffic impact to the
extent possible. Wherever, the road widthis lesser, contractor will have to operate within
restricted available ROW but have to ensure to provide access to all the households as well as
permanent shops. If the impact on ramp is unavoidable, contractor will restore the same as per
contract.
14. Categorization: This Resettlement Plan (RP) document is prepared for proposed Water supply
and Sewerage Subprojects in Sardarsahar and is in line with the Resettlement Framework
(RF)8 prepared for the implementation of social safeguards under (RSTDIP). The subproject is
classified as Category B in accordance with ADB's Safeguard Policy Statement (SPS). ADB’s
SPS covers both temporary and permanent impacts to both titled and non-titled persons, and
includes both physical and economic displacement. The RP is prepared on the basis of
technical details made available by the DPR consultants for the subproject. It will be updated
and reconfirmed for final IR impacts after completion of detailed measurement surveys in
sections which get ready for implementation.
15. Consultation and Disclosure: Goals and objectives of the project have been disclosed to
stakeholders (including, beneficiaries, affected persons, elected representatives and
institutional stakeholders) through consultation meetings and briefed them about the technical
details of project and project implementation cycle; project benefits as well as adverse impacts
envisaged during construction; environmental and social safeguards, gender inclusion,
community participation aspects built into the project etc . Consultations with APs during
transect walks mainly included concerns such as traffic disruptions and impacts on livelihood
and compensation provision in accordance with the entitlement matrix. A program of
continuous consultation and disclosure is proposed. (Consultation records are attached in
Appendix 14)
16. A summary of RF and RP in local language will be disclosed to representatives of all key
stakeholders through a city level stakeholder workshop. A hard copy of summaries will also be
made available at government offices and full documents will be uploaded at their/ADB
websites. (Refer Appendix 15 for Project Summary Leaflet sample)
17. Grievance Redress Mechanism: The RP will follow the three-tier project-specific grievance
redress mechanism (GRM) furnished in the RF. The GRM established will receive, evaluate,
and facilitate the resolution of AP’s concerns, complaints, and grievances about the social and
environmental performance at the level of the Project. The GRM will aim to provide a time-
bound and transparent mechanism to voice and resolve social and environmental concerns
linked to the Project (Grievance registration format is attached in Appendix 13).
18. Grievances of APs will first be brought to the attention of the Contractor, Supervision
Consultant and PIU. They can immediately resolve issues on-site in consultation with each
other, and will be required to do so within 3 days of receipt of a complaint/grievance. All
grievances that cannot be redressed within 3 days at field/ ward level will be brought to the
notice of Social Project Officer (SPO) of PMU. PMU SPO will resolve the grievance within 7
8
RF of Phase IV
v
days of receipt of compliance / grievance in discussion with the PIU, and the Contractor. All the
grievances that are not addressed by PMU within in 7 days of receipt will be brought to the
notice of the Grievance Redressal Committee (GRC). The Town Level Committee (TLC), which
will be established in every project town, will act as GRC. The GRC will resolve the grievance
within 15 days of receiving the complaint. An aggrieved person shall have access to the
country's legal system at any stage, and accessing the country's legal system can run parallel
to accessing the GRM and is not dependent on the negative outcome of the GRM. The PIU will
keep records of all grievances received including: contact details of complainant, date of the
complaint received, nature of grievance, agreed corrective actions and the date these were
effected, and final outcome. All costs involved in resolving the complaints will be borne by the
PMU. The GRCs will continue to function throughout the project duration.
19. Policy Framework and Entitlements. The policy framework and entitlements for the program
are based on national laws: the Right to Fair Compensation and Transparency in Land
Acquisition, Rehabilitation and Resettlement Act, 20139, (ii) ADB SPS, 2009; and agreed RF.
20. Compensation and Income Restoration: The implementing agency (PIU) will provide
compensation in accordance with the entitlement matrix of the agreed/ updated RF. As a
policy, all affected persons will be provided 30 days advance notice to ensure minimal
disruption of livelihood. Compensation will be completed prior to start of civil works. If required,
they will also be assisted to temporarily shift for continued economic activity. For example they
will be assisted to shift to the other side of the road where there is no construction.
21. Resettlement Budget and Financing Plan: The Tentative resettlement budget for Sardarsahar
Water supply and Sewerage subproject components includes resettlement assistance, as
outlined in the entitlement matrix and contingency provision amounting to be 10% of the total
cost is given in table 9. It is suggested that a separate account is opened towards RP
compensation and the entire compensation amount should be deposited upfront. CAPC will be
involved in facilitating the disbursement process, and will facilitate opening bank accounts for
the affected persons who do not have bank accounts. The costs are conservative estimates,
and will be confirmed during detailed project preparation and planning. The total resettlement
cost for the subproject is INR 2713579. PIU will be issuing sanction order forpayment to DPs /
APs and making ECS/NEFT transaction from bank through concerned Treasury. The costs are
conservative estimates with provisions kept for unanticipated impacts and cushion for special
provisions ( like ST population is this town especially), and will be confirmed during detailed
project preparation.
22. Institutional Setup: The Local Self Government Department (LSGD), Government of Rajasthan
(GoR) will be the Executing Agency (EA) of the Project and will be responsible for overall
strategic approvals, guidance, monitoring the execution of the project. The current Project
Management Unit of RUIDP, under the LSGD, will be the Implementing Agency (IA) for the
project. IA will execute and monitor the RSTDIP implementation. Project Implementation Units
(PIUs), will be setup for implementation. PMU is providing support to PIUs in implementation,
management and monitoring of the project. PIUs are be assisting by construction management
and supervision consultants (CMSC). At state-level an inter-ministerial Empowered Committee
(EC) will be established to provide overall policy direction and City Level Committees (CLCs)
will be established in each town to oversee the implementation at town level. (Refer CLC
Meeting Minutes in Appendix 4)
9
The Act has received the assent of the President on the 26 September 2013.
vi
23. Resettlement issues are coordinated by a Social Development Specialist (PMU SDS) within the
PMU, who ensures that all sub-projects comply with involuntary resettlement safeguards. A
Social safeguards specialist cum Resettlement Specialist (RS) who will be part of the project
management and capacity building consultants (PMCBCs) will assist the SDS. Resettlement
Specialist (RS) will have the responsibility to update the RP in the detailed design stage, and to
prepare RPs for new subprojects, where required to comply with Government and ADB
policies. (Refer Appendix 14 for TOR of RP implementation officer). DBO Contractor will
have a dedicated Social Supervisor and sufficient number of Social Outreach Team for
implementation of RP and will report to Town incharge of CAPC Expert.
24. RP Implementation and Monitoring: All compensation is to be paid prior to start of civil works.
RP implementation will be closely monitored by PIU with an effective basis for assessing
resettlement progress and identifying potential difficulties and problems. The PIU, will prepare
monthly and quarterly progress report in terms of physical and financial indicators. In addition,
the monitoring process will also look into: the communication and reactions of affected
persons; use of grievance procedures; information dissemination to affected persons on
benefits; and options and implementation time table, livelihood and living standard of affected
persons in pre and post-project situations. Report prepared by PIU will be compiled by PMU on
a semi-annual basis for its due submissions to ADB. (Refer Sample Monitoring Template in
Appendix 20.)
i
1
I. INTRODUCTION
A. PROJECT DESCRIPTION
1. The proposed Rajasthan Secondary Town Development Investment Program (RSTDIP) will
support the ongoing efforts of the Government of Rajasthan (the government) towards
improving the water and wastewater services in 40 towns10, each with population between
50,000 and 100,000, in the state. The project will invest in the rehabilitation and expansion of
water supply network for reduction of nonrevenue water (NRW), 24x7 water supply, the
rehabilitation and expansion of sewerage network, modernization and new construction of
water supply and wastewater treatment plants, as required, fecal sludge management, and
decentralized waste water management systems in the project towns. The project is expected
to increase operational efficiency, improve service delivery, and result in positive impact on
health and quality of life for the residents of project towns in the state.
2. Sardarshahar city has the administrative headquarters in Churu district. There are 7 tehsils in
the district Churu, Ratangarh, Taranagar, Rajgarh, Sardarshahar, Sujangarh and Bidasar.
Bidasar is the newest Tehsil. The total area of Sardarshahar is 2473 acre.The municipal area
of Sardarshahar town has been divided in to 40 wards. Sardarshahar lies towards the North
East of Bikaner at a distance of 136 Km by Road on the junction of State Highway No.6 and 7.
It is directly connected to Delhi, Jaipur, Ganganagar, and Bikaner by Road. The Only Rail Link
with Ratannagar was provided in 1916 in erstwhile Bikaner State Time. Sardarshahar town is
located at 74o27’. Longitudinal east and 28o26’ latitude North at an Altitude of 224m above
mean sea level.
4. As per the Site Visit conducted by STUP Consultant Pvt Ltd along with RUIDP officials it was
seen that some of the areas(1.Bikaner Road (South Side). 2.Mandi Zone (Industry Area).
3.SuryaMandir Area at Bikaner Road. 4.Colonies near Rama Hotel area at Bikaner
10
Abu Road, Badi, Balotra, Barmer, Banswara, Chomu, Dausa, Didwana ,Fatehpur, Jaisalmer, Jalore, Jhalawar,
Karauli, Kuchaman, Sardarsahar, Laxmangarh, Makrana, Nimbeheda, Nokha, Pratapgarh, Rajgarh, Rajsamand,
Ratangarh, Sardar Shahar, Sri Dungargarh, Suratgarh, Shahpura (Bhilwara), Shahpura (Jaipur), Sirohi, Tijara
and Heritage towns - Bandikui, Deeg, Dungarpur, Jobner, Khetri, Kama, Mandawa, Nawalgarh, Pillibanga &
Sambhar-Phulera
2
5. Present Water supply system in Sardarsahar Town:Main Source of Sardarshahar town water
supply is Indira Gandhi water canal from thereon Sawashat Canal emanate which is used to
feed water to the existing WTP of 70 MLD capacity at Dhannasar (Dhannasar Water Treatment
Plant). DhannasarWTP is part of AAPNI Yojna Asia's largest rural drinking water supply
project. Also under the Phase II AapniYojna, there is a provision for the construction of new
160 MLDWTP at the same premises. Currently from DhannasarWTP water is being fed to
Sardarshahar CWR with intermediate Pumping Station at Palloo and Sadasar by 1100dia PSC
pipe line, from CWR at Sardarshahar, water is being fed to 4 OHSR’s of varying capacity which
supplies water to the Distribution system of Sardarshahar. Currently, tube wells also play a role
in Sardarshahar water supply system which is situated in the city limits. There are 48 tube
wells/open wells harnessed with individual production of 225-300 LPM (10.00 MLD approx.).
Average depth of these tube wells is 200 M and the general water table in the area is 41 M.
Total water produced from these TW’s is directly boosted to distribution system for non drinking
purposes. While existing gross water supply rate is around 100 litres per capita per day
(LPCD), the water received at consumer end is about 80-85 LPCD only, which is less than
standard of 135 LPCD. This is due to heavy losses reported in the existing distribution network
(about 40-45%). As the distribution mains consists of about 92% of uPVC pipes laid almost 15
years ago, frequent bursting, leaking occurs, which leads to high percentage of NRW. The
water distribution network is old, profusely leaking and is badly in need of rehabilitation and
replacement. At present, there is an intermittent water supply system with low pressure in
Sardarshahar town.
6. Subproject Description: Sardarsahar is one of the town selected under RSTDIP and subproject
components: Sewerage- (i) Construction of 3 STPs of 5.40 MLD, 7.30 MLD and 1.60 MLD
capacity with CWR and OHSR for reuse of treated effluent (ii) 2 nos. of SPSs (0.65 MLD and
2.30 MLD capacity) (iii) sewer network of 68 km including 12 Km trenchless laying(iv) House
service connection-5600 (v) Electrical and Mechanical works. Water Supply-(i) Construction of
new CWR of 2400 KL at HanumangarhRooad CWR headworks, (ii) Rehabilitation of OHSRs at
Bairudan, Holidhora, Suryamandir, & Ramnagar (iii) Construction of boundary wall at Zone-05,
Ramnagar, at Behrudar, (iv) Construction of pumping station of 35 x 10 m at Hanumangarh
Road CWR headworks, (v) laying of Rising Main- 8860 mtr, (vi) water supply pipe for
distribution networks- 194 Kms. (vi) House service connection-22000
7. Detail of works are given in the Table 1 below:
1
8. The Resettlement Plan is prepared based on the available preliminary design for the
subproject. The Resettlement Plan will be updated and reconfirmed for final involuntary
resettlement impacts after completion of detailed measurement surveys in sections ready for
implementation.11The final Resettlement Plan will be reviewed and disclosed on IA and ADB
websites. No civil works contracts package should be awarded and started before the
completion of final Resettlement Plan implementation for the said package. The IA is
responsible to hand over the project land/site to the contractor free of encumbrance.
9. Measures to Avoid and Minimize Involuntary Resettlement: To avoid and minimize involuntary
resettlement impacts, the subproject will consider the use of government land where available
and right-of-way of government road for laying of all proposed pipelines under this package.
The pipelines are proposed to be laid underground within the existing available road ROW.
Diameters of proposed pipeline to be laid ranges between 75mm to 500 mm depending on the
width of the roads that vary between 2 to 20 m to minimize economic and traffic impact to the
extent possible. Excavation for the pipe/sewer laying works will be undertaken through open
trenching, which will be maximum width of 1 m only on one side of the road ROW with
maximum length, an average 140 m per day for water supply lines and 70 m for sewers.
Excavation, laying of pipes and backfilling will be completed within the day. Subsequent to
completion of works, road reinstatement will be undertaken by the contractor as part of the civil
works. The same shall be mentioned in the bid document to make it binding on the contractor.
10. To further minimize construction impacts, work will be executed during the early hours of
the day in order to avoid inconveniences to the public as well as traders and vendors. All safety
11 Detailed measurement survey will be jointly conducted by Safeguard Expert (Social) of the PMC of consultants
and contractors prior to implementation at each site/stretch of alignment. Supervision Consultants (SC) and
contractor will be responsible for conduct of DMS and SPISC Social Safeguard Specialist will update Resettlement
Plans prior to implementation.
2
norms would strictly be adhered to depending on the magnitude of work and the sensitivity of
the location. The Project Implementation Unit (PIU) will also ensure that all the necessary rules
related to safety and security of the public and residents are followed by the contractor. The
actual dates of construction schedule with respect to rush hour, festival time, and special
business days will be discussed with vendors, squatters, market committee members, and
residents, and accordingly construction activities will be planned. After laying pipes the
lane/road will be restored to its original condition (including bitumen, cement concrete (CC) and
CC interlocking tiles as applicable).
11. Traffic management during pipe laying work, advance notice to residents and
businesses prior to start of work, ensuring access to shops and businesses by providing
pedestrian access through planks, assistance to mobile hawkers and vendors and those with
moveable, temporary structures to shift to (and back from) nearby locations where they can
continue with their economic activities, is will be adopted. Where excavation close to
residences or commercial properties cannot be avoided, simple mitigation measures such as
provision of planks will be implemented as per available guidelines in EMP and best practice.
Timely information will be provided to the public about potential negative impacts and mitigation
measures, including grievance redress procedures and time taken for the same, prior to start of
project implementation.
12. This Resettlement Plan is prepared for proposed Water supply and Sewerage
components of the subproject of Sardarsahar Town under RSTDIP. It addresses the potential
involuntary resettlement impacts of the proposed subproject components and is consistent with
the agreed RF for the Project, and as per ADB SPS (2009).
13. This Resettlement Plans prepared in accordance with ADB SPS 2009 requirements for
involuntary resettlement Category B projects and to meet the following objectives:
(i) to describe the identified scope and extent of land acquisition and involuntary
resettlement impacts because of identified project components, and address
them through appropriate recommendations and mitigation measures in the
Resettlement Plan;
(ii) to present the socio-economic profile of the population in the project area,
identify social impacts, including impacts on the poor and vulnerable, and the
needs and priorities of different sections of the population, including women, poor
and vulnerable;
(iii) to describe the likely economic impacts and identified livelihood risks of the
proposed project components;
(iv) to describe the process undertaken during project design to engage stakeholders
and the planned information disclosure measures and the process for carrying
out consultation with affected people and facilitating their participation during
project implementation;
(v) to establish a framework for grievance redressal for affected persons that is
appropriate to the local context, in consultation with stakeholders;
(vi) to describe the applicable national and local legal framework for the project, and
define the involuntary resettlement policy principles applicable to the project;
(vii) to define entitlements of affected persons, and assistance and benefits available
under the project;
3
14. Scope of Land Acquisition and Resettlement: No involuntary land acquisition of private
land is anticipated for this project. Summary of Resettlement Impact Consistent with the
subproject selection criteria, rehabilitation is prioritized over new construction to avoid /
minimize involuntary resettlement impacts. STP (1.60 MLD proposed at Ward No 19,
Ghantagar Road) will be constructed in the vacant/unproductive land. The land required for the
STP are 1500 sq mtr and sufficient land is available which are under the jurisdiction of
Gausala committee and will be transferred to Nagar Palika. (Nagar Palika have moved the
letter to Gausala Committee for allotment of lands for the above works.(See annexure 1 &
1(A)). 7.30 MLD STP proposed at Existing STP Sardarshahar South Campus,and 5.40 MLD
STP at Existing STP Sardarshahar North Campus . Land required for the STPs are 7300 sq
mtr and 5400 sq mtr. The vacant land 26500 sq mtr and 13725 sq mtr are available within the
existing campus for the new STPs.. This lands were also initially under the jurisdiction of
Gausala Committee and have allotted to Nagar Palika during construction of STPs under
UIDSSMT project. Agreement has been made between Nagar Palika and Gausala committee
during UIDSSMT worksfor the allotment of such land..(See appendix 2&2(a)). (Summary Table
on the Land Revenue Records of Proposed Works are attached in Appendix 3 and Google
Maps of Proposed STPS are attached in Appendix 4 to 6). 2 nos of Sewerage Pumping
Station of 0.65 MLD near Shyam Deb Hotel &2.30 MLD capacity near Doordarshan Relay
Kendra will also be constructed in the unproductive/vacant Land. The lands required for the
SPS are 500 sq mtr and 1000 sq mtr which are presently under the jurisdiction of Gausala
Committee and will be allotted to Nagar Palika for the above works. Nagar Palika have moved
the letter to Gausala Committee for allotment of lands for the above works.( See annexure 1&
1(A))., (Summary Table on the Land Revenue Records of Proposed SPS are attached in
Appendix 3 and Google Maps are attached in Appendix 7&8 ). Clear Water Reservoirs- – 2400
KL will be constructed in the existing campus of PHED.Unused vacant land available in the
campus for the said works.
Table 4: Subproject Components and its Impact on Land Acquisition and Resettlement
15. Pipeline Works Sewer network and Water supply pipeline are proposed within the
boundaries of RoW of government roads. No impacts on structures (neither Temporary nor
Permanent) and CPRs12 is envisaged. However, during laying of pipeline, due to loss of
access, temporary livelihood loss to roadside vendors, Kiosks, is envisaged. The diameter of
pipeline ranges from 75 to 500 mm depending on the road width.(See Appendix 9&9(a)).
16. To estimate the temporary impacts, transect walks were undertaken in busy areas
where the pipelines are proposed to estimate worst case scenario. Transect walk was therefore
undertaken in areas such as busy market areas, commercial and office areas, core city/old city
areas, extension areas, areas near Bus stand, major junctions, main roads, residential areas
etc. In addition to these, a visual screening in the entire area was done and it has been
confirmed that there will be no impacts on permanent/semi-permanent structures, common
property resources etc. Both, visual screening and transect walk, confirm that the proposed
12
Common property resources include public resources, community-owned facilities or cultural property such as
temples, shrines, public utility posts, etc, that the landless poor and vulnerable depend on for survival
5
subproject impacts are temporary in nature i,e loss of livelihood to vendors with movable
/transitory structures (push carts etc.), operating within Right of Way (RoW).
17. Based on city visits, discussion with technical team and latest data available on
land use classification, the total proposed network length was classified into two categories i.e.
i) residential, industrial and other areas with minimal temporary business/activities and ii)
commercial, mixed-use, public, recreational areas where such activities are more in numbers.
18. It was observed that around 5-6 areas namely Roadways to Ghanta ghar,Private Bus
stand,Nagar Palika,Sabji Mandi,Hospital,Station , are having large number of commercial
establishments followed by presence of large number of road side vendors. In short all these
areas are very busy areas falling under category 1. Similarly it was also observed that areas
Bikaner road,Bobel Circle,Arjun club,Tulsi Chowk,Teenmurti Marg and surrounding areas also
have scattered commercial establishments with presence of road side vendors and petty
businesses; however the impact in these areas would be possible to avoid through a town
specific mitigation plan by the contractor. All these category 1 areas were surveyed (20%
sampling survey of APs was done) and visual screening was done for the remaining areas
19. As per sample survey, 24 percent are engaged in Tea and Snack, 39 percent are
engaged in vegetable/fruit selling 12 percent are engaged in Cloth and Cosmetic and 25
percent are engaged in flower,blacksmith etc. Average daily income estimated at Rs. 403 per
day, 3 percent of APs belong to vulnerable category. None of the surveyed APs however were
scheduled tribes (STs).
20. Thus after distribution of total proposed length and after extrapolation n based on
transect walk results/ survey results, it is anticipated that around 295 roadside
movable/transitory businesses13 will be affected in the subproject. Summary of transect walk
surveys, methodology of transect walk and temporarily affected APs are attached in Appendix
10to 13.
21. This, Transect walk data/analysis will be updated road wise where pipelines will be
laid before start of civil works and finalization of SIP14 and detailed measurement surveys on
sites/ sections of pipeline alignment by the contractor and revised RP will be submitted to the
ADB for approval. A 100 percent census and socio-economic surveys will be undertaken to
register and document the status of affected people (APs) within subproject impact areas.
13
Sample survey was conducted in key representative areas and data generated for entire town (taking Phase II& III
RF and RP as base). Refer annexure 14 for further details .
14 Taking, RUIDP Phase III, RF and methodology of initial impact assessment, as a base, transect walk was
conducted in municipal areas and visual screening of town in light of DPR (preliminary DPR as the final designing
and alignment will be done by Contractor due to DBO methodology of operation) was done. Since the town municipal
area was limited, visual screening has been conducted for entire town. It is important to mention that, similar to
Phase III, sample survey has been conducted in key representative area ( required for initial impact assessment and
for basic socio economic profiling of DP) and it is expected that contractor will conduct detailed socio economic
survey of the entire town (similar to Phase III) before start of civil work (after SIP) and updating and implementation of
RP is kept under scope of Contractor.
6
22. Care will be taken by contractor to avoid/mitigate economic impacts through the
following measures: (a) announcement of proposed civil works in advance (to enable shop
owners to stock up and remain unaffected if goods vehicles are unable to reach them during
construction, (b) provision of planks to ensure pedestrian access; (c) careful timing of
implementation to avoid peak sale hours/days or school timings; (d) night work in commercial
areas, where possible; (e) minimizing construction period to the extent possible; (f) assistance
to mobile vendors if any present during construction, to shift nearby; (g) signage with project
details and contact details for grievance redress; and (h) proper traffic management. These
measures will be part of the contract and will be implemented with careful monitoring by the
concerned PIU.
23. The contractor appointed will be also required to maintain access to shops and
residences or other buildings along pipe alignments and to institutions located close to
proposed sites, and safety through hard barricading of excavated alignments/sites. specific
provisions related to impact avoidance, for pipe laying activities as well as construction work
near schools, health centers, Anganwadi centers (ICDS), etc.
7
B. INDIGENOUS PEOPLE
24. Based on social analysis from the project site it is found/ confirmed that there will be no
impact on Indigenous peoples (IPs). This is categorized as “C” for Indigenous Peoples. No
Indigenous Peoples Plan will be needed for this sub-project.
25. The following sections present socio-economic profile of the households likely to be
affected by the proposed works. To estimate the temporary impacts transect walks were
conducted. The baseline information collected through survey provides the socio-economic
conditions of affected households. A wide range of data including, social category, Type of
losses, Type of Occupation, sources of income, choice of resettlement etc have been collected.
15 Total income per day of Surveyed APs (51 nos) comes to Rs 19800 and accordingly an average of 388 Rs per day
has been arrived. The average income arrived (Rs 388 approx), is much above the current minimum wage rate
prevalent at Rajasthan.(Appendix 20).
9
A. PUBLIC CONSULTATION
30. The Draft RP was prepared in consultation with stakeholders. The key stakeholders
consulted during RP preparation include (i) APs, including vulnerable households;(ii) program
beneficiaries (iii) elected representatives, community leaders, and representatives of
community- based organizations; (iv) local NGOs; (v) local government and relevant
government agency representatives; and (vi) Program staff, PMU, PIU, and consultants.
Meetings and individual interviews were held involving stakeholders particularly, potentially
temporarily affected persons; and transect walks, survey and interviews were conducted to
determine the potential impacts of subproject. During meeting they were briefed about the
technical details of project and project implementation cycle; project benefits as well as
adverse impacts envisaged during construction; environmental and social safeguards, gender
inclusion, community participation aspects built into the project etc. The issues like, awareness
and extent of the project and development components, benefits of project, traffic disruptions
and impacts on livelihood. It was informed to APs surveyed that appropriate measures will be
undertaken during construction to minimize impacts. (Including scheduling of activities and
reducing construction activities during the rush hour). It was also informed that, if despite
mitigation measures, there would be any temporary impacts on livelihood; these would be
compensated in accordance with the resettlement plan’s entitlement matrix. Further
consultations will also include focus group discussions (FGDs) and structured census surveys
before the project implementation. Details of Consultation are attached in appendix 14.
B. INFORMATION DISCLOSURE
31. The approved RP (with 100% Socio Economic Survey) will be disclosed on ADB and
local government’s websites and will be available in key local/state government offices. During
the subproject implementation, construction schedules will be informed to all residents
(including APs) prior to the commencement of pipe laying through signboards. The signboards
will be in local language and will include at minimum: (i) section to be affected, (ii) start and end
dates, (iii) information on traffic rerouting if any, and (iv) contact information for
questions/grievances.
32. During revised RP preparation, PIU/PMU will be responsible for issuing various required
public notices. For the temporary impacts the date/period of socio-economic surveys will be
considered as cut-off date. Cut-off-date for temporary impacts will be communicated to APs
through implementing CAPC, 2-3 days before the start of survey (and not in much advance)
and also by putting up printed information in project affected area at some common
advertisement place. Similarly, list of APs will be published at common places with contact
details of implementing CAPC/PIU officials. The list will be put up area wise and at a time for
the entire city. This will avoid APs moving into other areas and to identify any duplication of
APs. Implementing CAPC will facilitate APs to approach lists in their area and get confirmation
on any duplication, missing/absent APs. (Refer Appendix 15 for Project Summary Leaflet
sample)
33. The PMU will extend and expand the consultation and disclosure process during the
construction period. The project management consultants will conduct training of contractors
(engineers as well as safeguards personnel). The PMU, and with the support of CAPC, will
design and conduct a public awareness campaign during project implementation. A
consultation and participation Consultant will be mobilized for preparation and implementation
10
35. Common GRM. A common GRM will be in place for social, environmental, or any other
grievances related to the project; the resettlement plans will follow the GRM described below.
The GRM will provide an accessible and trusted platform for receiving and facilitating resolution
of affected persons’ grievances related to the project. The multitier GRM for the project is
outlined below, each tier having time-bound schedules and with responsible persons identified
to address grievances and seek appropriate persons’ advice at each stage, as required.
36. ULB-wide public awareness campaigns will ensure that awareness on grievance redress
procedures is generated through the campaign. Project implementation unit’s (PIU) assistant
safeguards officer (ASO) through community awareness and public consultant (CAPC) will
conduct ULB-wide awareness campaigns to ensure that poor and vulnerable households are
made aware of grievance redress procedures and entitlements.
38. Grievance redress process. In case of grievances that are immediate and urgent in the
perception of the complainant, the contractor, and supervision personnel from PIU the PMCBC
on-site will provide the most easily accessible or first level of contact for quick resolution of
grievances. Contact phone numbers and names of the concerned PIU Assistant Safeguards
Officer, contractors, will be posted at all construction sites at visible locations.
(i) 1st level grievance. The contractors, PIU supervision personnel, PIU assistant
safeguards officer, CMBC(PIU level safeguard support staff) and CAPC16 can
16
CAPC will oversee the matters if there is no resettlement plan Implementing NGO.
11
immediately resolve issues on-site, in consultation with each other, and will be
required to do so within 3 days of receipt of a complaint/grievance.
(ii) 2nd level grievance. All grievances that cannot be redressed within 3 days at
field/ward level will be brought to the notice of socialproject officer (SPO) of PMU.
PMU SPO will resolve the grievance within 7 days of receipt of
compliance/grievance in discussion with the PIU, PMCBC, CAPC and the
Contractor.
(iii) 3rd level grievance. All the grievances that are not addressed by PMU within in
7 days of receipt will be brought to the notice of the grievance redress committee
(GRC). The townlevel committee (TLC), which will be established in every project
town will act as GRC.17 GRC will meet twice a month and determine the merit of
each grievance brought to the committee. The PIU ASO will be responsible to
see through the process of redressal of each grievance. The GRC will resolve
the grievance within 15 days of receiving the complaint.
39. The project GRM notwithstanding, an aggrieved person shall have access to the
country's legal system at any stage, and accessing the country's legal system can run parallel
to accessing the GRM and is not dependent on the negative outcome of the GRM. In case of
grievance related to land acquisition, resettlement and rehabilitation,18 the affected persons
will have to approach a legal body/court specially proposed under RFCTLARRA, 2013; Land
Acquisition, Rehabilitation and Resettlement Authority (LARRA)19 affected persons cannot
approach any other court other than this
40. In the event that the established GRM is not in a position to resolve the issue, the
affected person also can use the ADB Accountability Mechanism through directly contacting (in
writing) the Complaint Receiving Officer (CRO) at ADB headquarters or the ADB India
Resident Mission (INRM). The complaint can be submitted in any of the official languages of
17
City Level Committees(CLC)/grievance redress committees (GRCs) will be formed at town-level with members
composed of: District Collectoras Chairperson,and following as members: ULB Commissioner; Assistant
Safeguards Officer PIU; representative from RPCB regional office; and one representative each from relevant
government departments as appropriate (PWD/PHED/DAM etc.). All town-level GRCs will have at least one-
woman member/chairperson. In addition, for project-related grievances, representatives of affected persons,
community-based organizations (CBOs), and eminent citizens will be invited as observers in GRC meetings.
18
The Authority admits grievance only with reference to the Land Acquisition and R&R issues under the
RFCTLARRA, 2013.
19
The authority shall consist of one person called Presiding Officer. Presiding Officer shall be either District Judge or
qualified legal practitioner with minimum seven years of service and shall be appointed in consultation with the
Chief Justice of the High Court within the Project jurisdiction. S/He shall hold the officer for three years and shall be
supported by Registrar and other officers. The Authority shall, for the purposes of its functions under this Act, shall
have the same powers as are vested in a civil court under the Code of Civil Procedure, 1908. Authority (GRS) shall
dispose any matter received within six months. All proceedings before Authority shall be judicial proceedings and
shall take place in public. No civil court (other than High Court or the Supreme Court) shall have jurisdiction to
entertain any dispute relating to land acquisition in respect of which the Collector or the Authority is empowered by
or under this Act, and no injunction shall be granted by any court in respect of any such matter. Applications first go
to Collector and within 30 days he can refer (if required) to the Authority. Such application can be made within six
weeks by the applicant (if he or representative is personally present) after the date of award, and in other cases
within six months. Collector may also accept any application within one year if feels appropriate. Interests are
payable for delayed and excess payments. Payment of award into their bank accounts. Any disputed payments
etc. shall be deposited with the Authority.
12
ADB’s DMCs. The ADB Accountability Mechanism information will be included in the PMU to
be distributed to the affected communities, as part of the project GRM.
41. Record-keeping.The PIU of each town and PMU will both keep records of grievances
received, including contact details of complainant, date the complaint was received, nature of
grievance, agreed corrective actions and the date these were affected and final outcome. The
number of grievances recorded and resolved, and the outcomes will be displayed/disclosed in
the PMU office, PIU offices, and on the web, as well as reported in monitoring reports
submitted to ADB on a semi-annual basis. (Grievance registration format is attached in
Appendix 13).
42. Periodic review and documentation of lessons learned. The PMU Project Officer (Social)
will periodically review the functioning of the GRM in each town and record information on the
effectiveness of the mechanism, especially on the project’s ability to prevent and address
grievances.
43. Costs. All costs involved in resolving the complaints (meetings, consultations,
communication and reporting/information dissemination) will be borne by the concerned PIU at
town level while costs related to escalated grievances will be met by the PMU. Cost estimates
for grievance redress are included in resettlement cost estimates.
44. Capacity Building. PMU safeguards and gender officer and PIUs’ safeguards focal
persons will be trained by PMC’s social resettlement experts on safeguards issues of the
projects and the project GRM. The targeted participants of the briefings would be PMU and
PIUs’ staff, design engineers, and contractors. Typical modules would be as follows: (i)
introduction and sensitization to ADB SPS on involuntary resettlement and indigenous people
policies and requirements resettlement framework and IPPF; (ii) review, updating and
preparation of the resettlement plans and IPPs (as required) upon the completion of project
detailed design; (iii) improved coordination within nodal departments; (iv) monitoring and
reporting system; and (v) project GRM. Briefings on safeguards principles and GRM will also
be conducted to the contractors upon their mobilization by PIU safeguards focal persons
supported by Safeguard Consultant.
45. Civil works contracts and contractors. The RPs/IPPs are to be included in bidding and
contract documents and verified by the PIUs and PMU. All contractors will be required to
designate an Environment, Health and Safety (EHS) supervisor to ensure implementation of
EMP/resettlement plan social safeguard provisions in the agreed resettlement framework for
the Project during civil works and O&M, who will also have the responsibility for communication
with the public under the guidance of PMU/PIUs and grievance registration. Contractors are to
carry out all mitigation and monitoring measures outlined in their contract.
46. The PMU and PIUs will ensure that bidding and contract documents include specific
provisions requiring contractors to comply with: (i) all applicable labor laws and core labor
standards on (a) prohibition of child labor as defined in national legislation for construction and
maintenance activities; (b) equal pay for equal work of equal value regardless of gender,
ethnicity, or caste; and (c) elimination of forced labor; and with (ii) the requirement to
disseminate information on sexually transmitted diseases, including HIV/AIDS, to employees
and local communities surrounding the project sites.
13
14
47. The policy framework and entitlements for the RSTDIP are based on:
(i) the recently passed-The Right to Fair Compensation and Transparency in Land
Acquisition, Rehabilitation and Resettlement Act (RFCT in LARR), 201320;
(ii) ADB’s Safeguard Policy Statement (SPS), 2009. The salient features of
Government and ADB polices are summarized below. The resettlement
principles and procedures to be followed for social safeguards under RSTDIP are
detailed out in the RF document.
48. The key involuntary resettlement principles of the ADB Safeguards Policy Statement
(2009)are:
Screen the project early on to identify past, present, and future involuntary
resettlement impacts and risks. Determine the scope of resettlement planning
through a survey and/or census of displaced persons, including a gender
analysis, specifically related to resettlement impacts and risks.
Carry out meaningful consultations with affected persons, host communities, and
concerned nongovernment organizations. Inform all displaced persons of their
entitlements and resettlement options. Ensure their participation in planning,
implementation, and monitoring and evaluation of resettlement programs. Pay
particular attention to the needs of vulnerable groups, especially those below the
poverty line, the landless, the elderly, women and children, and Indigenous
Peoples, and those without legal title to land, and ensure their participation in
consultations. Establish a grievance redress mechanism to receive and facilitate
resolution of the affected persons’ concerns. Support the social and cultural
institutions of displaced persons and their host population. Where involuntary
resettlement impacts and risks are highly complex and sensitive, compensation
and resettlement decisions should be preceded by a social preparation phase.
Improve, or at least restore, the livelihoods of all displaced persons through (i)
land-based resettlement strategies when affected livelihoods are land based
where possible or cash compensation at replacement value for land when the
loss of land does not undermine livelihoods, (ii) prompt replacement of assets
with access to assets of equal or higher value, (iii) prompt compensation at full
replacement cost for assets that cannot be restored, and (iv) additional revenues
and services through benefit sharing schemes where possible.
Provide physically and economically displaced persons with needed assistance,
including the following: (i) if there is relocation, secured tenure to relocation land,
better housing at resettlement sites with comparable access to employment and
production opportunities, integration of resettled persons economically and
socially into their host communities, and extension of project benefits to host
communities; (ii) transitional support and development assistance, such as land
development, credit facilities, training, or employment opportunities; and (iii) civic
infrastructure and community services, as required.
Improve the standards of living of the displaced poor and other vulnerable
groups, including women, to at least national minimum standards. In rural areas
provide them with legal and affordable access to land and resources, and in
urban areas provide them with appropriate income sources and legal and
affordable access to adequate housing.
20
Ministry of Law and Justice. The Act has received the assent of the President on the 26 September 2013.
15
49. Core involuntary resettlement principles for the RSTDIP to be followed for each sub-
project, including sample sub-projects are:
(i) land acquisition, and other involuntary resettlement impacts will be avoided or
minimized exploring all viable alternative sub-project designs;
(ii) where unavoidable, time-bound resettlement plans (RPs) will be prepared and
APs will be assisted in improving or at least regaining their pre-program standard
of living;
(iii) full information and close consultations with APs including consultation with APs
on compensation, disclosure of resettlement information to APs, and participation
of APs in planning and implementing sub-projects will be ensured;
(iv) vulnerable groups will be provided special assistance;21
(v) payment of compensation to APs including non-titled persons (e.g., informal
dwellers/squatters, and encroachers) for acquired assets at replacement rates;
(vi) payment of compensation and resettlement assistance prior to the contractor
taking physical acquisition of the land and prior to the commencement of any
construction activities;
(vii) provision of income restoration and rehabilitation; and
(viii) Establishment of appropriate grievance redress mechanisms.
21
Including poor households, households headed by women, the elderly, the physically handicapped and scheduled
tribes considered vulnerable based on the Indigenous Peoples Planning Framework (IPPF).
16
50. The anticipated types of losses due to the proposed sub-project components under
RSTDIP Project comprise (i) potential temporary income loss to shop owners/vendors with
permanent or movable structures (ii) potential temporary income loss to employees of shop
owners/vendors, and (iii) impacts to vulnerable persons (among the above categories of APs).
The income loss to APs will be partial loss of daily income for the period of disruption, if access
to shops/businesses can be maintained, failing.
51. According to ADB SPS 2009 in the context of involuntary resettlement vis-à-vis
economic impacts, affected persons (APs) are those who are economically displaced (loss of
productive land, structures, assets, access to assets, income sources, or means of livelihood).
The absence of formal and legal title to the land does not bar the affected person from receipt
of compensation and resettlement assistance from the project. Vulnerable APs are eligible for
additional compensation and assistance and are to be accorded priority in employment in
project related construction activities.
B. ENTITLEMENTS
52. As per agreed RF and similar to phase-3, all the DPs will be eligible for Livelihood losses
compensation i.e. 14 days and will also be compensated for the time lags (7% inflation in
survey income is provided per year) between implementation/ construction and survey, Shifting
assistance (LS 1500 Rs) should be paid to all the DPs irrespective of their structure and
Vulnerable persons/businesses will receive Rs. 9,000 as one time assistance under temporary
impacts.
53. All DPs who are identified in the subproject areas on the cut-off date22 will be entitled to
compensation for their affected assets, and rehabilitation measures (as outlined in the
entitlement matrix23 below) sufficient to assist them to improve or at least maintain their pre
project living standards, income-earning capacity and production levels. APs who settle in the
affected areas after the cut-off date will not be eligible for compensation and assistance. APs
will be provided 30 days advance notice to ensure no or minimal disruption in livelihood. If
required, they will also be assisted to temporarily shift for continued economic activity. For
example they will be assisted to shift to the other side of the road where there is no
construction. Ensuring there is no income or access loss during sub-project construction is the
responsibility of contractors.
54. Work will be undertaken on one side of the road and temporarily affected person (APs)
will be assisted in moving to the other side of the road and returning their structures after
construction is completed. Where moving is not required, access will be ensured by the
contractor through measures prescribed in bidding documents/environmental management
plan (EMP). An alternate place in the vicinity will also be identified where more number of APs
are affected at one place (e.g. vegetable market) so that they can continue with their Livelihood
activities.
22
Cut off date will be disclosed during census and socio-economic survey.
23
Based on RF of RUIDP Phase III
17
18
3 Loss and Common Communitie Replacement or restoration of the - PMU and Contractor.
temporary resources s affected community facilities –
impacts on including public water stand posts,
common public utility posts, temples,
resources shrines, etc.
4 Any other - - Unanticipated involuntary impacts - Supervision Consultant
loss not will be documented and mitigated SSS and implementing
identified based on ADB’s Safeguard Policy CAPC will ascertain the
(SPS), 2009/RSTDIP RF/EM. nature and extent of
such loss.
19
55. If construction activities results unavoidable livelihood disruption, compensation for lost
income or a transitional allowance for the period of disruption whichever is greater will be
provided. Vulnerable APs will be given priority in project construction employment and provided
with additional special assistance for income restoration support. Compensation and
assistance to APs must be made prior to possession of land/assets and prior to the award of
civil works contracts. Since most affected households have moveable stalls, ID cards should be
distributed 30 days before compensation. In summary, temporarily APs will be provided with:
(i) 30 days advance notice regarding construction activities, including duration and
type of disruption.
(ii) Contractor’s actions to ensure there is no income/access loss consistent with the
initial environmental examination. This includes: leaving spaces for access
between mounds of soil, providing walkways and metal sheets to maintain
access across trenches for people and vehicles where required, increased
workforces to finish work in areas with impacts on access, timing of works to
reduce disruption during business hours, phased construction schedule and
working one segment at a time and one side of the road at a time.
(iii) Assistance to mobile vendors/hawkers to temporarily shift for continued
economic activity. For example assistance to shift to the other side of the road
where there is no construction.
(iv) For construction activities involving unavoidable livelihood disruption,
compensation for lost income or a transitional allowance for the period of
disruption whichever is greater.
56. The resettlement budget for Sardarsahar Sewerage subproject components includes
resettlement assistance, as outlined in the entitlement matrix and contingency provision
amounting to be 10% of the total cost is given in Table 9 . It is suggested that a separate
account is opened towards RP compensation and the entire compensation amount should be
deposited upfront. CAPC will be involved in facilitating the disbursement process, and will
facilitate opening bank accounts for the affected persons who do not have bank accounts. The
costs are conservative estimates, and will be confirmed during detailed project preparation and
planning. The total resettlement cost for the subproject is INR. 2713579. PIU will be issuing
sanction order to payment of DPs /APs and making ECS/NEFT transaction from bank through
concerned Treasury.
20
59. The SLEC, established under the chairmanship of the Minister for Urban
Development(being Chairman of Board of RUDSICO), shall comprise of the Chief Secretary,
Secretariesof LSGD, Finance, Planning, PWD, PHED and the ProjectDirector, RUIDP as
Member Secretary. It shall have full powers to decide on matters relatedto RUIDP Phase IV
Project. The SLEC will take needful policy decisions, provideadministrative and financial
approvals, expedite clearances of project matters, ensure interdepartmentalcoordination and
provide guidance to the PMU.
60. The TLMCs will be headed by the Chairperson of respective ULBs and shall
haveCommissioner/Executive Officer of ULB, Local PHED and PWD Officers and officers of
PIUof respective town/cluster. The PIU officers shall include EE, PIU (Contract Manager),
28 Total income per day of Surveyed APs (59 nos) comes to Rs 23800 and accordingly an average of 388 Rs per day
has been arrived. The average income arrived (Rs 403 appr), is much above the current minimum wage rate
prevalent at Rajasthan. Refer Appendix 17.
21
AEand/or JE, PIU (RUIDP officer) and AE/JE of ULB. The AE of PIU (RUIDP Officer) shall
beMember-Secretary. The TLMC shall meet at least once in two months to monitor the
projectprogress and sort out any local issues.The implementation arrangements shall further
include a central PMU at Headquarter level and a number of PIUs at fieldlevel.
61. Project Management Unit.The PMU shall be headed by a dedicated Project Director.
Considering the breadth and width of Rajasthan, it is proposed to have two regional offices as
part of PMU - each headed by an Assistant Chief Engineer. ACE–I is proposed to be located at
Jaipur and ACE II at Udaipur. Both shall facilitate management of projects worth ₹2,500-3,000
crores each during next 5 years. This ACE (Jaipur) shall take care of four administrative
Divisions of Rajasthan, namely Bharatpur (four districts), Bikaner (four districts), Kota (four
districts) and Jaipur (five districts), whereas, ACE (Udaipur) shall take care of Divisions of
Ajmer (four districts), Udaipur (six districts) and Jodhpur (six districts). Office of ACE shall be
provided one executive engineer, one computer operator and a support staff.
62. Atheadquarter level, the project director shall be supported by assistant project director
(CE level), who shall be supported by team of Superintending Engineers including
Superintending Engineers (Procurement, Contract Management, Consultancies),
Superintending Engineers (Administration, Training, Institutional), Superintending Engineers
(Monitoring, Reporting, Social and Environment) and a Financial Advisor. All SEs shall have
one Executive Engineer level Project officer. In addition, there shall be one Project Officer for
Social (SPO) and another PO for Environmental aspects of the project. The EEs (POs) shall
have one AE under them except for Social component, wherein it is suggested to have a
Social/Public Participation professional. Besides these, there shall be offices of Finance and
Accounts, Legal, IT (including GIS, ProjectManagement, Asset Management) etc. To monitor
and support field works, both offices of ACE shall have three SEs (water and wastewater) each
- located at divisional headquarter levels
63. PMU will (i) monitor the Project and have overall responsibility for its implementation; (ii)
assist PIUs in identifying and preparing subprojects and appraise them in consultation with
towns; (iii) appoint consultants; (iv) ensure land acquisition and other safeguards; (v) approve
surveys, investigations, engineering designs and bid documents prepared by PIUs; (vi) review
procurement of works and goods undertaken by PIUs; (vii) oversee contract administration;
(viii) guide in awareness campaigns and participation programs; (ix) organize and operate the
program performance monitoring system; (x) prepare disbursement requests and forward them
ADB through Government of India; (xi) prepare and submit timely reports to ADB; (xii) review
and facilitate the progress of the urban reform agenda and compliance with loan covenants;
and (xiii) design and organize capacity building programs. The PMU will be assisted by
PMCBC in managing and guiding the overall implementation of the Program. The social project
officer (SPO) of PMU will responsible for all land acquisition and resettlement matters from
PMU side.
64. PMU SPO will perform responsibilities like: (i) addressing social safeguards issues; (ii)
implementing the resettlement framework/IPPF; (iii) liaising with district administration for land
acquisition and resettlement plan implementation; (iv) addressing any problems and/or delays
in the land acquisition process; (v) monitoring physical and financial progress on land
acquisition activities and updating the PMU on the same; (vi) monitoring implementation of
22
safeguards plans (resettlement plan/IPPs); (vii) guiding the PIUs as and when necessary; and
(viii) endorsing and submitting periodic monitoring reports29.The PMU will be assisted by a
PMCBC social safeguards specialist (PMCBC SSS). The SSS will (i) update the existing
resettlement plans based on the detailed design; (ii) assist in the monitoring and supervision of
ongoing subprojects and resettlement plan and IPP implementation; (iii) prepare resettlement
plan and/or IPPs for new subprojects, where required, to comply with national law and/or ADB
procedures; (iv) ensure all subprojects meet safeguard requirements as agreed in the loan
covenant and in line with this resettlement framework; (v) review and finalize all reports in
consultation with the PMU SPO; (vi) provide project management support; (vii) provide advice
on policy reforms. In addition, SSS will assist the PMU in procurement needs and other project
implementation aspects, and shall play a central role in ensuring capacity building on
resettlement management of the PMU, CAPC/implementing NGO, and line departments
through capacity development support and training.
65. Project Implementation Unit.30The PIUs will be established by clustering of towns (40
project towns excluding Sambar and Phulera). It is proposed that 15 such cluster level PIUs will
be established based on geographical location, administrative logistics, sub project costs and
other such considerations.Each PIU shall be headed by an Executive Engineer, who shall work
as Project Manager. At each PIU, an assistant engineer rank officer will be designated as
assistant safeguards officer (ASO) who will assist PMU social project officer (SPO) in
implementation of the social safeguards at the PIU level. PMU SPO will receive support from
Social Safeguard Specialist of the PMCBC Team in implementation of social/land
acquisition/resettlement related tasks at PIU level. (Refer Appendix 14 for TOR of RP
implementation officer)The PIUs will be responsible for implementation of the resettlement
plan/IPP. PIUs will undertake internal monitoring and supervision and record observations
throughout the project period to ensure that the safeguards and mitigation measures are
provided as intended. ASO will be responsible for (i) conduct briefing to contractors on
safeguards requirements including GRM (ii) implementing and monitoring safeguards
compliance activities, public relations activities, gender mainstreaming activities, and
community participation activities; (iii) coordinating with district administration and
PMCBC/CAPC for land acquisition and R&R aspects and addressing any problems and/or
delays; (iv) monitoring physical and financial progress on land acquisition and R&R activities;
and (v) organizing monthly meetings with the CAPC and PMCBC Safeguard Support Staff to
review the progress on R&R. (
66. Project Management and Capacity Building Consultants shall manage
preparation/vetting design documents, tendering of contracts, implementation of resettlement,
environmental management and gender action plans; setting and managingproject
29
The monitoring report will focus on the progress of implementation of the IEE/EIA and environmental assessment
and review framework (EARF), resettlement plan/resettlement framework and IPP/IPF, issues encountered and
measures adopted, follow-up actions required, if any, as well as the status of compliance with subproject selection
criteria and relevant loan covenants
30
If the subproject triggers new LARR, PIU will facilitate land acquisition (LA) through district collector and will provide
all details of land acquisition to PMCBC SSS/PMU. PMCBC SSS will incorporate the same in resettlement plan
and check its compliance with resettlement framework/ADB SPS-2009 to make necessary additions (if any). PIU
will bear the cost of any deviations in the compensation etc. to comply with resettlement framework/ADB SPS-
2009. So far, not a single project has been executed so far under LARR, 2013 in Rajasthan and suggested
institutional structure under LARR, 2013 (commissioner, committees, authorities etc.) is not in place. Government
procedures under land acquisition act can run parallel even though under ADB project required
surveys/preparation of resettlement plan will be undertaken. ADB project need to wait for the outcomes of
government procedures to finalize the compensation and disbursement of payments.
23
67. Construction Management and Supervision Consultants (CMSC) shall support PIUs
inday to day contract management, construction supervision including quality management
ofongoing works etc. This shall include work measurement, quantities, verification of bills
ofcontractors etc.
68. Community Awareness and Participation Consultants (CAPC) will closely work in field
(with PIUs) to facilitate creation of project awareness and ensuring public participation for all
project works at the community level. This shall mainly involve house connections for water
supply, sewerage and metering. Besides, they shall also undertake various IEC activities to
promote and pursue health and hygiene amongst communities.
69. DBO Contractor.31 The DBO Contractor will have a dedicated Social Outreach Team
and Social Supervisor, who will hold a Master’s degree in social science and would have at
least 5 years of experience in resettlement planning and implementation, as well as gender
action plan implementation, preferably in multi-lateral aided projects. The tasks of the
Contractor’s Social Supervisor will be to:
(i) Work in close coordination with the PIU, design engineers and PMC social
safeguards personnel to finalise detailed design keeping the safeguard principles
adopted for the project in view;
(ii) Ensure that all design-related measures (e.g. special considerations for the
vulnerable related to facility locations or design, mitigation measures for affected
persons etc.) are integrated into project designs before approval
(iii) Conduct joint walk-throughs with PIU, design engineers and social safeguards
personnel in sites/sections ready for implementation; identify the need for detailed
measurement surveys, and conduct detailed measurement surveys to arrive at
the final inventory of loss;
(iv) Update the draft RP and Due Diligence Report and submit to PIU/PMU and ADB
for review and approval.
(v) Ensure strict adherence to ADB and government policy on social safeguards and
the agreed entitlement matrix during implementation,
(vi) Assist with grievance redressal and ensure recording, reporting and follow-up for
resolution of all grievances received;
(vii) Assist PIU in disclosing relevant information on safeguards (eligibility,
entitlements, compensation, cut-off date, processes, timelines, GRM etc.) to
beneficiaries and affected persons including the vulnerable.
(viii) Submit monthly social safeguard and gender action plan monitoring reports to
PIU, with gender-disaggregated data as required for monitoring.
31
The DBO contractor will be responsible for RP updating and implementation, in close coordination with the PIU and
PMC.
24
70. Further details on agencies responsible for resettlement plan activities are in Table 7
below
Table 8 : Institutional Roles and Responsibilities
Activity Responsible Agency
Subproject Initiation Stage
Finalization of sites for subprojects PMU
Disclosure of proposed land acquisition and subproject details by PMU
issuing Public Notice
Meetings at community/household level with affected persons PIU/NGO
Formation of Valuation Committees PMU/PIU
25
Activity Months
1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18
iv. GRC Formation
v. Briefing of the CLC
on GRC functions
vi. Census and socio-
economic surveys
(issuance of ID.
cards)
vii. Consultations and
disclosure
viii. Confirmation of
government land to
be used and transfer
from other
departments
ix. RP preparation
x. RP review and
approval (PMU and
ADB)
xi. Issue notice to APs
xii. Compensation and
resettlement
assistance
xiii. Relocation as
required
xiv.Skills training as
required
xv. Takeover possession
of acquired property
xvi.Internal monitoring
xvii. Handover land to
contractors
xviii. Start of civil
works
xix.Rehabilitation of Immediately
temporarily occupied after
lands construction
* The census will be the cut-off date for non-titled APs. For titled APs, the cut-off date is the date
Declaration.
** The RP will be updated based on final detailed design and AP census and surveys.
*** Endorsement and disclosure of finalized RPs consistent with the RF to be undertaken.
ADB-Asian Development Bank, AP-affected person, SC- supervision consultants, GRC-
grievance redressal committee, PIU-Project Implementation Unit, PMU- Project Management
Unit, CSSS- Supervision Consultant’s social safeguard specialist, CLC-City Level Committee
26
71. RP implementation will be closely monitored to provide the PMU with an effective basis
for assessing resettlement progress and identifying potential difficulties and problems. Internal
monitoring will be undertaken by the PIU (through the SSS) with assistance from the PMU
SPO. Monthly progress reports will be prepared and submitted to the PMU. PMU will
consolidate the same and will submit semi annual monitoring reports to the ADB for approval.
(Refer Sample Monitoring Template in Appendix 20)
72. Following will be the steps for RP updating and implementation (including but not limited
to):
i. Transect walk data/analysis will be updated road wise where pipelines will be laid
before start of civil works and finalization of SIP by the DBO contractor and
revised RP will be submitted to the ADB for approval. A 100 percent census and
socio-economic surveys will be undertaken to register and document the status
of affected people (APs) within subproject impact areas. Detailed measurement
survey will be jointly conducted by Safeguard Expert (Social) of the PMC of
consultants and contractors prior to implementation at each site/stretch of
alignment.
ii. During RP revision, census/socio-economic surveys for temporary impacts
should include specific questions on place of business, its seasonal variation and
27
AP’s migrant nature. A separate list of such APs should be made available in the
Updated RP.
iii. Cut-off-date for temporary impacts will be communicated to APs before the start
of survey (and not in much advance) and also by putting up printed information in
project affected area at some common advertisement place and that to be added
to the updated RP.
iv. ADB approval of the updated RP based on the final assessment at detailed
measurement survey stage needs to be obtained by the PMU.
v. Formal and informal consultative methods will be carried out including, but not
limited to: focus group discussions (FGDs), public meetings, community
discussions, and in-depth and key informant interviews; An intensive information
dissemination campaign for APs will be conducted and details will be appended
in the Updated RP.
vi. All the required NoC(Land transfer from Gausalla committee to Nagar Palika for
the construction of STP will be taken prior to start of civil works.
28
Transcript
To The President,
Gausala Committee,Sardarsahar
Sub- Provide land for the constrction of 2 nos of SPS and 1 nos of STP
Ref-RUIDP letter no-4583-85 dated 05.07.2018
The land required for the above works are as below:
During site visit of RUIDP officials it was noticed that Nagar palika land are not available nearby
areas for the above works.Sufficient encumbrance/unproductive land of Gausala committee are
available.Thus it is requested to allot/provide the land for the construction of 2 nos of SPS and
one nos of STP under RUIDP-Phase 4.
Executive officer,Nagar Palika,Sardarsahar
29
30
Sewage Treatment Plant(STP) North‐
Total land acquired : 32725 Sqm
Area Utilized : 19000 Sqm.
Land available at present : 13725 Sqm.
(For proposed STP under RUIDP Ph‐IV)
Sewage Treatment Plant(STP) South‐
Total land acquired : 73500 Sqm
Area Utilized : 47000 Sqm.
Land available at present : 26500 Sqm.
(For proposed STP under RUIDP Ph‐IV)
See -Appendix2(a)
31
32
Appendix 3: Details of land availability, ownership and status of No Objection Certificate (NOC)
for sites
Project Location Ownership Area of Area Khasra Khata Remarks NOC Photo of Land
Componen government required No. No. Status
t land available (sq mtr)
at the location
(sq mtr)
Constructio Ward No Gausala Sufficient land 1500 Letter
n of STP (- 19, Committee Available moved to
1.60 MLD Ghantagar Gausala
committee
- Ref- See
annexure
1 1(A)
33
Project Location Ownership Area of Area Khasra Khata Remarks NOC Photo of Land
Componen government required No. No. Status
t land available (sq mtr)
at the location
(sq mtr)
Constructio Existing Nagar 13725 5400 303 Existing
n of 5.40 STP Palika STP
MLD Sardarshah Sardarsha
ar North har North
Campus) Campus)
Ref-
Appendix
2)
34
Project Location Ownership Area of Area Khasra Khata Remarks NOC Photo of Land
Componen government required No. No. Status
t land available (sq mtr)
at the location
(sq mtr)
Clear (Near PHED Sufficient land 1000 Sufficient
Water Existing is available in land is
Reservoirs- CWR at the PHED available in
– 2000 KL Hanumang campus the PHED
campus
arh Road)
35
36
37
38
39
40
Years in
Business
Fathers/Husband Type of Daily Caste
S.no Location Name of Persons Age at Vulnerability
Name Business Income Category
Surveyed
Place
1 Roadways Rakesh Kumar Hansraj 35 Flower 8 400 Gen
2 stand to Manti Narayan 20 Ice Cream 2 500 OBC
Ghanrta
3 Ghar/Nagar Parasmal Dhanraj 22 Ice Cream 4 400 OBC
4 Palika Nandu Ramchandra 40 Ice Cream 4 450 OBC
5 Narayan Deviram 55 Ice Cream 25 500 OBC
6 Ratanmal Surat Singh 27 Puchka 8 300 Gen
7 Bhagwan Ranjeet 40 Cloth 18 500 OBC
8 Mayaram Buchram 70 Blacksmith 30 250 OBC
9 Omprakash Kumbharam 60 Blacksmith 30 250 OBC
10 Indira Devi Rajuram 30 Cloth 15 500 OBC WHH
11 Ajay Kumar Ranjeet 32 Cloth 10 450 OBC
12 Dullaram Mayaram 30 Blacksmith 11 500 OBC
Private Bus
13 stand to Akbar Khan Mohmad 25 Fruit 7 500 Gen
14 Roadways Kamlesh Jaichandra 23 Vegetable 6 350 OBC
stand
15 Mukesh Bhagwanram 27 Tea+ snack 9 500 OBC
16 Madanlal Sohanlal 36 Barbor 12 400 OBC
17 Mahendra Ramratan 21 Pottery 5 350 OBC
18 Deendayal Mohanram 30 Spices 7 400 SC
19 Vikram Kumbharam 35 Flower 10 400 OBC
20 Ravi Prithiviraj 27 Flower 8 400 OBC
21 Prakash Sewaram 25 Flower 9 350 OBC
22 Sushil Kamalram 25 Cycle Repairing 8 300 OBC
41
Years in
Business
Fathers/Husband Type of Daily Caste
S.no Location Name of Persons Age at Vulnerability
Name Business Income Category
Surveyed
Place
23 Chaganlal Sohanlal 45 Garlic 15 400 OBC
24 Jaichandra Deepchandra 22 Fruit 7 350 OBC
25 Gaurav Rammohan 18 Puchka 2 300 Gen
26 Sakil Khan Pappu khan 18 Sticker 2 350 Gen
27 Narendra Kumbharam 30 Flower 8 300 OBC
28 Bhanwarlal Amar Singh 24 Snack 5 500 Gen
29 Manak Chandra Kaxminarayan 48 Vegetable 18 400 OBC
30 Nandu Ramchandra 40 Vegetable 15 400 OBC
31 Ramlal Ramchandra 35 Vegetable 12 400 OBC
32 Mohanlal Munnalal 40 Vegetable 20 400 OBC
33 Chothmal Rameshwar 31 Vegetable 8 400 OBC
34 Remant Shankar 35 Fruit 6 400 OBC
35 Rajkumar Mohanlal 38 Vegetable 14 400 OBC
36 Mustak Amin Khan 32 Fruit 6 400 Gen
37 Sabji Arif Munshi Khan 35 Vegetable 14 400 Gen
38 Mandi Kanhaiyalal Goplaram 33 Vegetable 8 400 OBC
39 Rajkumar Mohanlal 38 Vegetable 12 400 OBC
40 Mustak Shermohmad 35 Fruit 10 400 Gen
41 Gani Mohmad Faijal Khan 40 Vegetable 15 400 Gen
42 Salim Khan Akbar Khan 38 Vegetable 13 400 Gen
43 Munnalal Sohanlal 55 Vegetable 22 400 OBC
44 Shankarlal Heeralal 45 Vegetable 25 400 OBC
45 Ramlal Gopi 35 Vegetable 10 400 OBC
46 Hariram Ganpat ram 38 Vegetable 14 400 OBC
47 Hospital Radheshyam Brijmohan 40 Ice Cream 10 400 Gen
42
Years in
Business
Fathers/Husband Type of Daily Caste
S.no Location Name of Persons Age at Vulnerability
Name Business Income Category
Surveyed
Place
48 Gopal Nanuram 30 Cold Drinks 7 400 OBC
49 Ramlakhan Harinarayan 21 Cold Drinks 4 400 OBC
50 Shiv Prasad Laxmanram 40 Pichka 15 350 OBC
51 Manoj Nagarmal 33 Snack 10 400 OBC
52 Pursottam Raghunath 56 Snack 24 500 OBC
53 Sakin Khan Nizamuddin 43 Vegetable 20 400 Gen
54 Talim Sakin Khan 25 Fruit 6 400 Gen
55 Sri Kishan Shankarlal 49 Garlic 23 400 OBC
Near
56 Railway Nandlal Sawadlal 35 Cosmetic 12 400 OBC
57 Station Indrachandra Mohanlal 35 Garlic 11 400 OBC
58 Manoj Ghanshyam 40 Footwear 16 500 Gen
Readymade
59 Shyamlal Bhagwan 45 20 500 Gen
Garment
Source: Transect Walk surveys at Roadways,Private Bus stand ,Ghanta Ghar,Sabji Mandi,Hospital,Railway station,
43
44
Near Hospital
45
Results/ Extrapolations:
The busy commercial areas (5 in number) have been identified during transect walk in the town
wherein from each area total likely affected vendors have been enumerated of which 20% have
been selected zone/area wise to a total of 59 whose socio-economic survey has been
conducted. Treating this as the worst case scenario, the result of the survey has been
extrapolated for the entire town wherein pipeline laying would be implemented. In such
circumstances, 295 likely affected vendors would be temporarily impacted.
46
Road towards STP‐2MLD Road towards Proposed SPS near BSNL
office
RICCO Industrial Area Near Proposed SPS‐Shyam Hotel
Near Roadways Stand Near Ghanta Ghar
47
Sabji Mandi Near railway Station
Near Private Bus stand Market Area
Road of Ward no‐4 Bobel Chowk
48
1 70 40 30 Present Water supply and sewerage Public in general were satisfied with
system of the town, Project the components identified and
components, sewerage system, assured for required support.,
property connection, Willingness to People are willing to pay for the
pay improved quality of water.
49
3 29 .08.2018 Local Habitant Ward n0-3 Work Proposed by People are supportive of the
RUIDP, Quality of project and indicated their
present Water willingness to participate
Supply. Status of in the project to make it
Sewerage , successful. (especially
Willingness to pay women), People
for improved understand direct benefits
services along with latent benefits
of the project
50
29.08.2018 Local Farmers Ward n0-7 Work Proposed by People are supportive of the
RUIDP, Quality of project and indicated their
present Water willingness to participate
Supply. Status of in the project to make it
Sewerage , successful. (especially
Willingness to pay women), People
for improved understand direct benefits
services along with latent benefits
of the project
51
Consultation sheet
52
53
RP implementation schedule
54
55
56
57
58
59
60
61
62
63
6. Assist APs identify suitable land for relocation, wherever necessary. Where
suitable government land is not available, assist the AP to locate a landowner
willing to sell his land and will assist in the negotiation of the purchase price.
7. Assist project authorities in making arrangements for the smooth relocation of the
APs and their business. This will involve close consultation with the APs to
ensure that the arrangements are acceptable to them.
8. Ensure proper utilization of the compensation money by the APs, particularly the
vulnerable APs to purchase equipment and tools received under the economic
rehabilitation programme.
9. Assist APs in getting benefits from various government development programs
particularly for income restoration/ generation, if desirable by the APs. The officer
will co-ordinate the training programs for sustainable livelihood and assist in
identifying the required skills for livelihood rehabilitation and the training institutes
to impart skills. The officer shall coordinate with other government departments
and other NGOs working in the area to ensure that all the skill development
trainings are known to the APs to select from the list the appropriate training.
10. Develop micro level plans for resettlement and rehabilitation in consultation with
the APs and the PIU where relevant. A plan shall be prepared and agreed for
each AP and will include:
• List of options for loss of land, assets, and livelihood are known by the
APs. The officer will explain to the APs the options available and assist
them in selection.
• Arrangements for shifting, if required
• Awareness about existing Government Development Programs by the
APs;
• Provide data on inputs, outputs and impact indicators for the ULB to
monitor RP implementation and prepare internal monitoring report
• Any other responsibility as may be assigned for the welfare of the
affected Households.
11. Assist in the identification of sites for the relocation of cultural properties and
community assets, especially for the affected Indigenous Peoples’ community, if
affected due to project. This is to be done in consultation with the affected IP
community and the ULB.
B. Methodology
In order to carry out the above tasks, employees of CAPC are to be stationed in the sub-project
area. Besides interaction with the APs on an individual basis to regularly update the baseline
information, group meetings will be conducted by the CAPC on a regular basis. The frequency
of such meetings will depend on the requirements of the APs but should occur at least once a
month, to allow the APs to remain up to date on project developments. CAPC will encourage
participation of individual APs in such meetings by discussing their problems regarding LA, R&R
and other aspects relating to their socio-economic lives. Such participation will make it easier to
find a solution acceptable to all involved.
C. Reporting
The CAPC shall submit an inception report with detailed action plan, manpower deployment,
time schedule, and detailed methodology within 30 days of the commencement of the
assignment. The CAPC should also submit quarterly progress reports on the activities carried
out and proposed activities for the coming month. The quarterly progress reports will include
data on indicators as required by the PIU/PMU.
• Updated data on APs and data on additional APs coming due to changes will be
submitted within two months of the commencement of the assignment;
64
• Micro level plans for each AP on the project will be submitted to the PIU for
information within 3 months of the commencement of the services. Where
changes occur during the project implementation necessary changes in the micro
level plans will be reflected, and the CAPC will update the relevant plans and
resubmit them to the PIU;
• On completion of the assignment the CAPC shall submit a final report
summarizing the actions taken during the sub-project implementation, the
methodology and manpower used to carry out the work, and a summary of
assistance given to each AP under the sub-project.
D. Time Schedule
It is estimated that the CAPC services will be required for three years for undertaking various
Community Awareness and Public Participation- activities including RP implementation.
However, this may be rescheduled based on the exact nature of the activity and change if any in
project plan and other project related activities.
E. Key Personnel
A Team Leader, a Gender Specialist and a Social Development Specialist apart from the
support staff (at town level) will be required to carry-out the activities. The key professionals
should have combined professional experience in the areas of socio-economic surveys,
resettlement and rehabilitation, participation, community development and training for economic
rehabilitation activities. The staffing requirements may be reviewed based on field requirement.
65
S. Completed
Resettlement Plan Activities Remarks
N. Y/N
A. Pre-Construction Activities and Resettlement Plan Activities
1 Approval of final Resettlement Plan by ADB prior to contract
award
2 Disclosure of final Resettlement Plan on ADB and EA websites
3 Circulation of summary Resettlement Plan in local languages
to all stakeholders
A. Resettlement Plan Implementation
1 Grievance Redress Mechanism established at different levels
2 Entitlements and grievance redress procedure disclosed
3 Finalization of list of affected persons, vulnerable affected
persons and compensation due
4 Finalization of list of roads for full or partial closure; mitigation
measures proposed and implemented (with photographic
documentation)
5 Affected persons received entitlements as per EM in RP
6 Payment of compensation, allowances and assistance (No. of
affected persons)
7 Additional assistance (project-related construction jobs, if
willing and able) for vulnerable households given (No. of
vulnerable affected persons assisted)
8 Grievances
No. of grievances registered
No. of grievances redressed
Outstanding complaints
Disclosure of grievance redress statistics
9 Consultation, participation and disclosure as per Plan
66
S. Completed
Resettlement Plan Activities Remarks
N. Y/N
C. Monitoring
10 Survey on satisfaction levels of affected persons with
Resettlement Plan implementation completed
D. Labor
11 Implementation of all statutory provisions on labor like health,
safety, welfare, sanitation, and working conditions by
Contractors. Ensuring no child labour used
12 Equal pay for equal work for men and women
NOTE: Where applicable, the information provided in the table should be supported by detailed
explanatory report, receipts and other details.
67
68
Section-7 - 1 General Conditions of Contract RSTDIP/ SRD/01
Section 7:
General Conditions of Contract
RUIDP RSTDIP
Section-7 - 2 General Conditions of Contract RSTDIP/ SRD/01
Section7
General Conditions of Contract
The General Conditions that follow are the Conditions of Contract for Design, Built and Operate
contracts pepared by the Fédération Internationale des Ingénieurs‐Conseil, or FIDIC (FIDIC 2008).
Any amendments and additions to the GCC, specific to the contract in hand, are introduced in
Section 8 (Particular Conditions of Contract), Part A (Contract Data) and Part B (Special
Provisions). Clause numbers in the PCC correspond to those in the GCC. As per GCC 1.5 (Priority
of Documents), the PCC take precedence over the GCC.
Part A (Contract Data) of the PCC includes data to complement the GCC.
Part B (Specific Provisions), includes the amendments and additions to the GCC.
RUIDP RSTDIP
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/ SRD /01
Section 8
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
The following Particular Conditions of Contract (PCC) shall supplement the General
Conditions of Contract (GCC). Whenever there is a conflict, the provisions herein shall
prevail over those in the GCC.
Sub-
Data to be given Data
Clause
1.1.23 Cost Cost means all expenditure reasonably
incurred ( or to be incurred) by contractor,
whether on or off the site, including
overhead and similar charges equal to 10 %,
but does not include profit.
1.1.24 Cost Plus Profit Cost + 10% profit.
1.1.26 Time for completion of design built Cut-off Date - 30 days after the stipulated
after which the Employer can period of completion of design-build
terminate the contract
1.1.32 Employer’s Name and Address (i) During Design Build: Rajasthan Urban
Infrastructure Development Project
(RUIDP) or its successor agency, AVS
Building, JLN Marg, Malviya Nagar,
JAIPUR, State of Rajasthan, India;
(ii) During Operation Services: Municipal
Board, Sardarshahar (MBS), State of
Rajasthan, India for sewerage works and
Public Health Engineering Department,
Government of Rajasthan for water
supply works or water supply and
sewerage by Municipal Board,
Sardarshahar (MBS) or as decided by
GoR.
1.1.35 Employer’s Representative The Employer’s Representative shall be Mr.
----------------, EE, PIU, Municipal Board,
Sardarshahar.
1.1.70 Section Section means the part of Works scheduled
to be completed in accordance to the
Milestones provided at Section 6.1.14, 6.2.5
& 6.3.3 – Employer’s Requirements.
1.1.78 Time for Completion 1095 days for Design Built
3650 days for Operation Services
Total 4745 days from commencement date.
Time for completion of each section is
provided in Employer’s requirement.
1.3 (c) Agreed Systems of Electronic By facsimile or electronic mail only
Transmission
1.3 (d) Address of Employer’s EE, PIU, Municipal Board, Sardarshahar
Representative for communication
1.3 (d) Address of Contractor for Contractor to provide prior to the signing of
Communication Contract Agreement
1.4 Contract shall be governed by the Union of India and State of Rajasthan. In
law of case of conflict, the Laws of Union of India
will prevail.
1.4 Ruling Language English
1.4 Language for Communication English
Section- 8 - 1
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 2
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 3
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 5
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
The Particular Conditions of Contract (PCC) Part B - Specific Provisions, is to amend or for
additions to the General Conditions of Contract (GCC - Section 7). Whenever there is a
conflict, the provisions herein shall prevail over those in the GCC.
Section- 8 - 6
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
1.5 Priority of “Delete sub paragraphs (a) to (i) in Sub-Clause 1.5 and
Documents substitute with the following:
(a) Contract Agreement,
(b) Letter of Acceptance,
(c) Tender (Technical and Price Bid including priced Bill of
Quantities),
(d) Addendums
(e) Particular Conditions – Part A,
(f) Particular Conditions – Part B
(g) General Conditions of Contract
(h) Employer’s Requirements;
(i) Schedules
(i) Contractor’s Proposal
(j) EMP, IEE and Social Management Plan
Add the following at the end of paragraph:
Contract agreement will be made among three parties,
Contract
1.6 RUIDP as Employer to the Design Built works, Municipal
Agreement
Board, Sardarshahar during Operation & maintenance and
the Contractor.
1.14 Compliance with Add sub clause (d), (e) and (f) as follows:
Laws (d) Preparing applications in accordance to standard
procedures for obtaining all statutory clearances and
approvals required from Government of Rajasthan and/or
Government of India, including all environmental clearances,
permission from Highway and Railway authorities, inland
waterway authorities, forest authorities and any other such
authorities as may be required.
Section- 8 - 9
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Water
a) The Water required for construction purpose during
the Design Build Period shall be arranged by Contractor at
his cost. The Employer will not be responsible for any water
supply and no time extension will be granted on account of
non-availability of water. Water required for testing of
pipelines and liquid retaining structures/tanks shall also be
arranged by the Contractor at his cost.
b) If the quality of ground water is as per standards and
contractor makes his own arrangement for construction and
drinking purposes. The quality of water shall be got tested
as per BIS by the Contractor at his own cost at the
Employer's own laboratory. Permission for extracting ground
water shall be obtained from concerned authority by the
Contractor.
5.6 Operation and Insert 28 days in the first line of Sub -Clause
Maintenance
Manuals
Add the following at the end of this Sub-Clause:
Section- 8 - 12
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 14
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Period.”
Add the following after the last sentence of this Sub-Clause:
Section- 8 - 17
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 18
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 19
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 20
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 21
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 22
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
14.10 Payment of Replace this Subclause in its entirety with the following:
Retention Money
“The Contractor shall be entitled to include the first half of
the Retention Money in the Final Statement Design–Build.
Section- 8 - 23
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
1
Whether as a Contractor, Subcontractor, Consultant, Manufacturer or Supplier, or Service Provider; or in any other capacity
(different names are used depending on the particular Bidding Document).
Section- 8 - 24
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Section- 8 - 25
SECTION‐8: PARTICULAR CONDITION OF CONTRACT RSTDIP/SRD/01
Requirements
“The Contractor shall take out any insurance under or in
connection with the Contract with insurers from any eligible
source country listed in Section 5 of Bid Documents.. In
case of failure by the Contractor to comply with this
requirement, and irrespective of any former approval from
the Employer, he shall forthwith take replacement
insurance(s) from insurers having their origin in an eligible
source country and in terms both subject to approval by the
Employer, all at the Contractor’s risk and cost. For the
avoidance of doubt, the Employer’s Representative shall be
entitled to withhold corresponding payment certification in
accordance with Sub-Clause 14.7 [Issue of Advance and
Interim Payment Certificates] until such time replacement
insurance(s) are provided in accordance with the Contract.”
Replace the fifth paragraph in its entirety by the following:
“The agreement between the Parties and either the sole
member ("adjudicator") or each of the three members shall
Appointment of the
be based on the sample form included in the tender
20.3 Dispute
documents, and incorporate by reference the General
Adjudication Board
Conditions of Dispute Adjudication Agreement in these
General Conditions, with such amendments as are agreed
between them.”
Insert the text below after the first paragraph and before the
second paragraph of this Sub-Clause:
Representative.”
20.8 Arbitration Replace paragraph (a),(b) and (c) with following:
a) The Dispute shall be finally settled under following
rules of arbitration:
For National (Indian) Contractor: As per Rules of
Arbitration of the Indian Arbitration Act.
For Foreign Contractor: As per rules of international
arbitration conducted in accordance with the Arbitration
Rules of the Singapore International Arbitration Centre.
The arbitration procedure shall be administered by the
Singapore International Arbitration Center.
b) For National Contractors only: Dispute shall be settled
by sole or three arbitrators. Dispute to be arbitrated upon
shall be referred to a sole Arbitrator where the total value
of claims does not exceed to Rs. 10 millions. Beyond the
claim limit of Rs. 10 Million, there shall be three
arbitrators. For this purpose the Employer will make out a
panel of Engineers with the requisite qualifications and
professional experience relevant to the field to which the
Contract relates. This Panel, will be for serving or retired
Engineers of Government Departments or of Public
Sector. The Arbitrator/Arbitrators shall be appointed
within a period of 30 days from the date of receipt of
written notice/demand of appointment of Arbitrator by
either party. In case of a single arbitrator, the panel will
be of three Engineers, out of which the contractor will
choose one. In case three arbitrators are to be appointed,
the Employer will make out a panel of five. The contractor
and the employer will choose one arbitrator each and the
two so chosen will chose the third arbitrator from the
panel. Neither party shall be limited in the proceeding
before such arbitrator/s to the evidence or arguments put
before the Engineer for the purpose of obtaining his
decision. No decision given by the Engineer in
accordance with the foregoing provisions shall disqualify
him from being called as a witness and giving evidence
before the arbitrator/s on any matter whatsoever, relevant
to dispute or difference referred to arbitrator/s. The
arbitration proceeding shall be held at Jaipur. The
arbitrators shall always give item-wise and reasoned
awards in all cases where the value of total claim
exceeds to Rs. 5.00 million. Where three arbitrators have
been appointed, the award by the majority will prevail.
c) The language used arbitration for proceedings –
Language for communication defined under Subclause
1.4 [Law and Language].
apply.”
Section- 8 - 29
Schedule to Section-8: Particular Conditions of Contract
During the term of this Contract, the Employer shall have the following obligations:
2. On receipt of a request from the Contractor, deemed reasonable to RUIDP, to: (i)
release sufficient funds to undertaking major maintenance like replacement of
existing or new infrastructure but not including those assets procured and installed
by the Contractor as part of the approved Service Improvement Plan; and (ii)
expressly permit the Contractor to implement such works (a) on appropriate
Variation orders, or (b) by organizing implementation of such works by third party
contractors under separate contracts in such a manner that it will not affect the
smooth conduct of the Contractor Obligations under this Contract.
3. Manage the project roles and responsibilities, interfaces and resolution of problems
arising out of them using appropriate level(s) of interface.
4. Employer will be responsible for getting the utility shifting and provide hindrance free
right of way to the Contractor. Contractor will provide full support and assistance in
identifying utilities and hindrances and for liasoning with concerned department.
1. PHED/MBS shall by or before the Commencement Date, grant, or procure for the
benefit of the works the rights and powers to repair or replace the facilities, to lay
pipes, construct civil structures, install equipment and machinery on its behalf and to
carry out necessary excavations to do the works, to undertake necessary remedial
works at the Water Works sites and pumping stations and new works, where
appropriate, and to install connections and any other rights and powers reasonably
required by the Contractor.
2. MBS shall provide free of charge sufficient space to construct Consumer Service
Centers and other utility buildings to enable the Contractor to perform its obligations
under this Contract.
3. MBS/PHED shall be responsible for and pay the land rent and the property taxes if
any and the Contractor shall not be responsible for these charges. MBS/PHED will
also bear the cost of any increase in such charges from time to time.
1. Contractor Obligations
1.1.1. The Contractor shall have the right and obligation to provide the Design –
Build and Operation Services in the works site on an exclusive basis during
the Contract period. Should the Employer desire to expand the Service Area,
the Employer and the Contractor shall meet and negotiate in good faith with a
view to agreeing on the provision of Operation Service by the Contractor to
such expanded Service Area and the payment to the Contractor there for.
1.1.2. The Contractor shall perform the Design – Build and s in accordance with
governing Laws (including all environmental legislations), Asian Development
Bank policies and procedures, guidelines and agreements with Government
of India and Government of Rajasthan on RUIDP, approved SIP, prudent
industry practice, the Performance Standards, the urban poor services
policies, and the locally applicable regulatory social policies if any.
1.1.3. The Contractor shall have care and custody of Works and Site during the
term of this Contract.
1.1.4. Subject to Section 1.1.2 above, the Contractor shall have discretion in
determining the means and methods to be used to perform the Design – Build
and Operation Services.
1.2.1. The Contractor shall maintain accurate and systematic accounts and records
in respect of the Operation Service in such form and detail enabling clear
identification of all relevant charges and cost incurred by the Contractor and
the basis thereof as well as proper and timely technical and financial audits.
Such accounts may be audited by external auditors as appointed by RUIDP
or ADB.
1.2.3. The Contractor shall permit the Employer or its designated representative to
semi-annually inspect such accounts and records and shall permit Auditing
Body (AB) to carry out technical and financial audits on an annual basis.
1.2.4. Contractor shall open a dedicated Bank account in the project city or at Jaipur
and all payments including mobilization advance payment received from
RUIDP shall be deposited in the dedicated account. Employer will have full
right to monitor the flow of funds from this account and will ensure that the
funds are used at project activities and has no problem of mobilization of
financial resources.
1.3.1. Neither the Contractor nor its sub-contractors nor the Contractor personnel
shall engage during the term of this Contract, either directly or indirectly in
1.3.2. Notwithstanding Sections 1.3.1, the Contractor will be eligible to bid for
subsequent contracts related to the Operation Services, but shall not have
any right of first refusal except in case of reuse and recycle of treated sewage
which is part of the total city Integrated water management.
2.1. The Contractor shall perform all the Design – Build and Operation Service from the
Commencement Date until the Contract Completion Date in accordance with
Section 6 Employer Requirements, Schedule 5 to the Particular Conditions of
Contract - Contractor Payments and Schedule 7 to the Particular Conditions of
Contract – Performance Targets and Measurements; as well as:
2.2. The Contractor shall collect the revenue generated from Operation Service and
deposit in the Designated Revenue Account (Escrow Account) maintained by the
Employer as described under Section 6, Employer’s Requirement.
1. PHED/ MBS personnel will assist and provide full support to the Contractor in making
assessment of existing infrastructure during preparation of Service Improvement Plan
and during execution of Design Build and Operation Service.
2. PHED/ MBS shall not depute any personnel for Operation Service of the works.
3. Contractor will arrange all required personnel for Operation Serviceduring the
Operation Service period.
4. However if PHED/ MBS is able to provide some of the existing staff and Contractor
wishes to use their services in Operation Service, he/they can be provided to the
Contractor on deputation basis. In such case, Contractor will make all payment
related to his salary and allowances and an additional 20% of salary and allowances
to the Employer to take care of his/their pension and retirement benefits.
b. For water supply Rising mains, common feeder mains and other pipelines including
all pipeline accessories
i. 50% of the cost of respective BoQ item of pipeline on supply and stacking of
material at site
ii. 30% of the cost of respective BoQ item of pipeline on laying, jointing, sectional
hydro testing of pipes and road restoration
iii. 20% on commissioning respective BoQ item of pipelines works
c. For Sewerage collection system (upto 300 mm dia, precast manholes and other
sewer appurtances )
i. 50% of the cost of respective BoQ item of sewer line works on supply and stacking
of material at site
ii. 30% of the cost of respective BoQ item of sewer line works on laying, jointing, hydro
testing of pipes and road restoration
iii. 20% on commissioning of lateral system with property connection up to and
including property chamber
d. For sewerage collection system more than 300mm dia and pumping main
i. 50% of the cost of respective BoQ item of sewer line on supply and stacking of
material at site
ii. 30% of the cost of respective BoQ item of sewer line on laying, jointing, hydro
testing of pipes and road restoration
iii. 20% on commissioning of respective BoQ item of sewer line works
g. For civil works, road restoration, trenchless and other items: Progressive payment as
per progress of work
h. For WTP, Sewage and Water Pumping Stations, STP and other lump-sum items
etc:80% of progressive payment as per progress of work and approved break up of
payment + 10% on testing & trial run + 10% on commissioning
i. During Design-Build period there shall not be (i) un-laid length of 50 km for the
payment for supplying the material at site and untested length of 3.5 km for payment
on laying, jointing, hydro testing of pipes in water supply and (ii) un-laid length of 17
km for the payment for supplying the material at site of pipes in sewerage.
j. The Contractor shall be required to provide satisfactory proofs of the cost of supply
and delivery of such materials, and to provide an Indemnity Bond for ensuring safe
storage and protection of such materials against all risks of damage, theft, fire, loss,
wastage, etc.
3.1 Payment for the Operation Services would comprise two components, namely Fixed
payment and Performance payment, as follows:
(i) Fixed Payment equal to 70% of the eligible Total Payment for Operation
Services with service delivery in water supply or sewerage system;
(ii) Performance Payment equal to 30% of the eligible Total Payment for
Operation Services with service delivery in water supply and sewerage
system as per Schedule 7: Performance Target and Measurement
Employer shall pay the fixed Payment to the Contractor within 7 days of raising the
monthly bills. The monthly payment bills will be reviewed and certified by the Employer’s
representative/ Auditing Body/ Technical Auditor within 7 days of submission by the
Contractor. Eligible performance Payment and other charges if any will be paid on
certification within 21 days of recommendation by the Employer’s representative/
Technical Auditor along with a certificate regarding fulfilment of the performance
conditions and the Technical Auditor’s report.
Power consumption for each unit, as guaranteed by the bidder during bidding
stage, will be verified during operation services. In case of more consumption to
the guaranteed power, Employer will recover the costs of excess monthly power
consumed with two times the prevailing power rate.
All electricity costs and initial connection charges etc associated with operations shall be
paid by Employer directly to the electricity service provider. The power connections shall
be obtained in the name of Employer, the charges of which will be paid by Employer
directly to electricity department or reimbursed under provisional sum if paid by the
Contractor.
3.1.1.1. The Fixed Payment shall be paid to the Contractor on monthly basis
subject to fulfilment of the following conditions:
(iii) Providing daily water supply to the respective bulk water transfer
points specified in the project area (except the extraordinary situation
where water is not supplied by PHED).
Contractor is eligible to get full 70% of the agreed Operation Services Payment as
fixed Payment only if he achieves performance indicators sufficient enough to get
50% of the maximum Performance Payment. In case the Contractor gets less than
50% of the maximum Performance Payment of 30%, deductions shall be made from
the fixed Payment for below satisfactory or inferior performance.
For the purpose of reckoning the work done during any period, bills prepared during the
period shall be considered. Dates of recording measurements in the Measurement Book
by the Engineer’s Representative shall be the guiding factor to decide the bills relevant to
any period. The date of completion, as finally recorded by the Engineer’s Representative
in the Measurement Book, shall be the criterion.
The index relevant to any quarter, for which such compensation is paid, shall be the
arithmetical average of the indices relevant of the calendar month.
The amount to be added to or be deducted from the Payment Certificates for changes in
cost shall be determined from formulae as stated below:
(a) LABOUR
VL =0.75 x L/ 100 x R x (IL1 - IL0) / IL0
VL = Increase or decrease in the cost of work during the quarter under consideration.
IL0= Base Price which is Consumer Price Index for Industrial labour for jaipur issued by
Labour Bureau, Shimlaon the base date.
IL1= Final price (average for the quarter under consideration)which is Consumer Price
Index for Industrial labour for jaipur issued by Labour Bureau, Shimla.
(c) Bitumen:
Vb = 0.75 x B/100 x R (Bi – B0) / B0
Vb= Increase or decrease in the cost of the work during the quarter under consideration.
R= Value of the work done during the quarter under consideration excluding the cost of
materials supplied by the department.
Bo= Base price which is the Wholesale Price Index for Bitumen issued by Economic
Advisor, GoI on the base date.
Bi= Final price (average for the quarter under consideration) which is the Wholesale
Price Index for Bitumen issued by Economic Advisor, GoI.
Pb= Percentage of bitumen component excluding bitumen supplied by the Department.
R= The value of the work done during the quarter under consideration excluding the cost
of materials supplied by the department.
Fo= Base price which is the Wholesale Price Index for Rubber and Plastic Product
issued by Reserve Bank of India on the base date.
Fi= Final price (average for the quarter under consideration) which is the Wholesale
Price Index for Rubber and Plastic Product issued by Reserve Bank of India.
H= Percentage of HDPE/PVC resin.
VM= Increase or decrease in the cost during the quarter under consideration.
R= Value of the work done during the quarter under consideration excluding the cost of
materials supplied by the department.
IM0=Base price which isWholesale price index (all commodities) published in Reserve
Bank of India Journal on the base date.
IM1= Final price (average for the quarter under consideration) which is the wholesale
price index (all commodities) published in Reserve Bank of India Journal.
The cost indices or reference prices stated in the table of adjustment data in section 4
shall be used.
Foreign currency payments, if any, will be converted into the local currency (INR) at the
selling exchange rate, published by Reserve Bank of India, on the last date of quarter for
which the index is required to be applicable.
All Operation Services under this Contract shall be governed in accordance to the
adjustments for change in costs as provided in above clauses and based on following
formula:
(A) LABOUR
VL =0.75 x PL/ 100 x R x (IL1 - IL0) / IL0
VL = Increase or decrease in the cost of work during the quarter under consideration.
R = Value of the work done during the quarter under consideration excluding the cost of
materials supplied by the department.
IL0= Base Price which is Consumer Price Index for Industrial labour for jaipur issued by
Labour Bureau, Shimla on the base date.
IL1= Final price (average for the quarter under consideration) which is Consumer Price
Index for Industrial labour for jaipur issued by Labour Bureau, Shimla.
VM= Increase or decrease in the cost during the quarter under consideration due to
change in rates of material.
R= The value of the work done during the quarter under consideration excluding the cost
of materials supplied by the department.
IM0= Base price which is Wholesale price index (all commodities) published in Reserve
Bank of India Journal on the base date.
IM1= Final price (average for the quarter under consideration) which is the wholesale
price index (all commodities) published in Reserve Bank of India Journal.
Adjustment for changes in Cost will be applicable for amount of work carried out by the
Contractor within stipulated completion period or extended contract period for which
delay is not attributable to the Contractor. The indices shall be considered of the quarter
in which the work is actually executed.
Adjustment for the work items valued on the basis of Cost or current prices or new rate
items shall be applicable from the next quarter in which new rate has been given.
Adjusted Amount: The adjusted amount of each Payment Certificate may be subject to
any deductions therefrom for liquidated damages, and any other monies due to the
Employer from the Contractor including the recovery of advance amounts, if any.
Price adjustment shall be applicable on the amount of entire work done during the
stipulated /extended period not attributable to the contractor, excluding provisional sum.
1. Appointment: RUIDP and Contractor jointly will appoint an Auditing Body (AB) for the
purpose of monitoring and evaluation of the performance of the Contract during the
Operation ServicePeriod. AB may be the Employer’s representative or any other
personnel appointed by the Employer. AB shall play a positive and independent role in
discharging its functions, thereby facilitating smooth implementation of the Operation
Service.
a) Review the Service Improvement Plan (SIP) furnished by the Contractor and suggest
modifications if any required especially with reference to the baseline service levels
and investments proposed by the Contractor to achieve the Performance Standards
stipulated in, Section 6.1 - Scope of Services;and in clause 2&3 of Schedule8
b) Monitor the performance of the Contractor and verify the periodical reports furnished
by the Contractor in terms of achievement or maintenance of Performance Standards
set forth in Section 6.1 – Scope of Services;
c) Review the procedures and policies and suggest any modifications or changes
required to protect the interest of Consumers, Employers RUIDP and `PHED/MBS;
d) Review matters related to safety and environmental management measures adopted
by Contractor;
e) Provide independent advise to both Parties under this Contract in times of
requirement of revision or rebasing of the Performance Standards required due to the
following events:
i. Substantial change in baseline parameters;
ii. Discovery of unknown assets and additional infrastructure which can be put to
use resulting in revision of Mandatory Works;
iii. Failure of the performance of any of the existing assets other than the new or
replaced assets implemented by the Contractor necessitating Major
Maintenance by way of replacement;
iv. Substantial change in Raw Water Quality and the tube wells requiring
additional processing and treatment requirements; and
v. Default of the Employer,RUIDP, PHED or MBS on the Contractor’s Notice to
Correct.
f) Attend project review meetings and provide recommendations on mid-course
corrections if any, required for successful implementation of the Project;
g) Check, verify and advise the Parties on any Variations proposed by the Contractor
from time to time;
h) Undertake periodical, at least once in a month, on-site verification of the Services
and provide recommendations on any issues which require immediate attention and
action from any of the Parties;
i) Set out a mechanism and monitor smooth handover of Project Facilities by
PHED/MBS to the Contractor and hand back of the Project Facilities by the
Contractor to PHED/MBS `or other authorised agency
3. Reports: The AB shall prepare and submit to RUIDP, monthly reports including the
following:
d) Issues, if any, with regard to operation, maintenance and management along with the
details of the action taken for the resolution of the same;
e) Photographic records of on-site periodical verification;
f) Report on AB’s compliance with this Terms of Reference; and
g) Any other report as may be reasonably required by RUIDP or as may be necessary
to give effect to the provisions of this Contract.
4. Duration: The appointment of AB shall be initially for 60 months commencing from the
contract commencement date or the dates as decided by Employer but not later than the
day as the Operation Service commences. RUIDP reserves the right to extend the
services of the AB for a further period or up to the Contract Completion Date on mutual
consent basis.
A. Definitions
i. Water Supply and Sewerage Services shall include but not limited to, the
operation, maintenance and repairs of all existing and new assets created for the
water supply and Sewerage system to be kept in operation to deliver the services,
including supply of metered drinking water at consumer end and sewerage collection
system from consumers’ sewage collection chambers and its treatment etcincluding
pumping station/s, operation & maintenance and recycling & reuse of treated sewage
etc. This involves operation & maintenance of distribution/collection network within
the supply/drainage zone, treatment of the sewage effluent, House connections,
computerized billing & distribution of bills, collection of user charges, operating 24
hours consumer care centre, consumer complaint redressal within specified time
period etc.
ii. Continuous Pressurized Water Supply means a continuous supply of water for 24
hours a day, at a minimum pressure 12 meters of water at consumer meter point.
Continuous supply and pressure to be measured at Critical Points in the zone from
mid night to mid night.
iii. Critical Points in the zone means the points on the distribution network at which the
flow or pressure measuring devices would be installed which shall be mutually
agreed by the Employer and the Contractor during the works contract.
iv. Potable Water means water meeting the Water Quality as per the standards
specified in IS 10500-1991.The following important parameters are to be checked,
documented and ensured properly.
a. The physical and bacteriological examination shall be carried out for one sample
daily per 10,000 population as given in CPHEEO manual.
b. The turbidity less than 1 NTU andminimum residual chlorine of 0.2 ppm shall be
maintained continuously at the consumer end.
Where
a. SI shall be the average of the (i) quantity of bulk water supplied by PHED
between date stated in initial Commissioning Certificate and the final
Commissioning Certificate or (ii) quantity of raw bulk water received at WTP
after final Commissioning Certificate, including any water imported from other
sources in a particular month and as recorded by the bulk meters
b. BC is the sum of water billed to the consumers in the supplied zone in same
month as of SI as per billing records for the month.
vi. Blockage & Spillage: Blockage in sewer is any incident thataffect free flow of
sewage through the sewer. Spillage is any incident by which sewage comes out of a
sewer line or manhole or inception chamber or the property that results in a public
health concern; damage to public or private property.
B. Performance Targets
I Water Supply:
vi. Water Quality at Consumer Connection Points: 100% of water samples taken are
free of any kind of turbidity and contamination and shows minimum 0.2 ppm residual
chlorine.
The Contractor shall develop a robust methodology and framework for measurement
and monitoring of Performance Standards stipulated under this clause and proposed
as part of the Service Improvement Plan (SIP). The Employer shall review the same
and upon agreement between the Parties, the agreed methodology shall form the
basis for monitoring the performance of the Contractor and apply the Performance
Payment.
Water supply
consumer meter.
Electronic register of bills generated against each of the
consumer
Electronic register of bills received by consumers entered after
verification of receipt
Allowable Nil
Exclusions
4 Parameter Adhering to HSC connection and disconnection request in
time
Minimum 100%
Service Level
Measured By No. of connections/disconnections given in 3 days of clearance
received from line agency X 100 / Total no. of connections
cleared
Monitored By The electronic register of dated requests for connections
received, cleared by authority and actually connected as per the
signed report of consumer.
Sewerage
under review
Section – 9
Contract Forms
Section-9 : Contract Forms RSTDIP/ SRD/01
Table of Forms
9-1
Section-9: Contract Forms RSTDIP/ SRD/01
. . . . . . . date of notification . . . . . . .
This is to notify you of our intention to award the contract [. . . . . . . . . insert name of the contract
and identification number, as given in the Bid Data Sheet .
. . . . . . . . ]. You have [. . . insert number of
days as specified in ITB 41.1 of the BDS . . .] days , from
the date of this notification to (i) request for
a debriefing in relation to the evaluation of your Bid, and/or (ii) submit a bidding-related
complaint, if any, in relation to the intention for award of contract, in accordance with the
procedures specified in ITB 46.1.
1. List of Bidders
Bid Price as read out at
Name of Bidder Evaluated Bid Price
opening
…………………………………………………………………………………………………………
…………………………………………………………………………………………………………
…………………………………………………………………………………………………………
………………………
9-2
Section-9: Contract Forms RSTDIP/ SRD/01
Notification of Award
[on letterhead paper of the employer]
Letter of Acceptance
. . . . . . . date. . . . . . .
This is to notify you that your Bid dated . . . . date . . . . for execution of the . . . . . . . . . .name of
the contract and identification number, as given in the Bid Data Sheet . . . . . . . . . . for the Accepted
Contract Amount of the equivalent of . . . . . . . . .amount in words and figures and name of currency . . .
. . . . . ., as corrected and modified in accordance with the Instructions to Bidders is hereby
accepted by our Agency.
You are requested to furnish the Performance Security within 28 days in accordance with the
Conditions of Contract and any additional security required as a result of the evaluation of your
bid, using for that purpose the Performance Security Form included in Section 9 (Contract
Forms) of the Bidding Document.
9-3
Section-9: Contract Forms RSTDIP/ SRD/01
Contract Agreement
THIS AGREEMENT made the . . . . . .day of . . . . . . . . . . . . . . . . ., . . . . . . ., between . . . . .
name of the employer. . . . .. . . . . (hereinafter “the Employer”), of the one part, and . . . . . name of
the contractor. . . . (hereinafter “the Contractor”), of the other part:
WHEREAS the Employer desires that the Works known as . . . . . name of the contract. . . .
.should be executed by the Contractor, and has accepted a Bid by the Contractor for the
execution and completion of these Works and the remedying of any defects therein.
The Employer and the Contractor agree as follows:
1. In this Agreement, words and expressions shall have the same meanings as are
respectively assigned to them in the Contract documents referred to.
2. The following documents shall be deemed to form and be read and construed as part of
this Agreement. This Agreement shall prevail over all other Contract documents.
(a) the Contract Agreement,
(b) the Letter of Acceptance,
(c) the Letter of Technical Bid and bid,
(d) the Letter of Price Bid and its bid,
(e) the addendums . . . .
(f) the Particular Conditions of Contract – Part A,
(g) the Particular Conditions of Contract – Part B,
(h) the List of Eligible Countries that was specified in Section 5 of the Bidding Document
(i) the General Conditions of Contract,
(j) the Specifications,
(k) the Drawings,
(l) the completed Schedules including Bill of Quantities, and
(m) any other documents shall be added here.1
4. The Employer hereby covenants to pay the Contractor in consideration of the execution
and completion of the Works and the remedying of defects therein, the Contract Price or
such other sum as may become payable under the provisions of the Contract at the
times and in the manner prescribed by the Contract.
IN WITNESS whereof the parties hereto have caused this Agreement to be executed in
accordance with the laws of . . . . . name of the borrowing country. . . . .on the day, month and year
indicated above.
for and on behalf of the Employer for and on behalf the Contractor
in the presence of in the presence of
1
Tables of Adjustment Data may be added if the contract provides for price adjustment (see GCC 13.8).
9-4
Section-9: Contract Forms RSTDIP/ SRD/01
Performance Security
.................................... Bank’s name, and address of issuing branch or office ...............................................................
Date: .........................................................................................................................
We have been informed that . . . . . name of the contractor. . . . . (hereinafter called "the
Contractor") has entered into Contract No. . . . . . reference number of the contract. . . . . dated . .
. . . . . .with you, for the execution of . . . . . . name of contract and brief description of works. . . . .
(hereinafter called "the Contract").
Furthermore, we understand that, according to the conditions of the Contract, a performance
guarantee is required.
At the request of the Contractor, we . . . . . name of the bank. . . . . hereby irrevocably undertake
to pay you any sum or sums not exceeding in total an amount of . . . . . name of the currency and
amount in words2 . . . . . (. . . . . amount in figures. . . . . ) such sum being payable in the types and
proportions of currencies in which the Contract Price is payable, upon receipt by us of your
first demand in writing accompanied by a written statement stating that the Contractor is in
breach of its obligation(s) under the Contract, without your needing to prove or to show
grounds for your demand or the sum specified therein.
This guarantee shall expire, no later than the . . . . . Day of . . . . . . . . . . , . . . . . . 3, and any
demand for payment under it must be received by us at this office on or before that date.
This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication No.
458 (or ICC Publication No. 758 as applicable), except that subparagraph (ii) of Sub-article 20(a) is
hereby excluded.4
.....................................
Signature(s) and seal of bank (where appropriate)
Note to Bidder
If the institution issuing the performance security is located outside the country of the employer, it shall have
a correspondent financial institution located in the country of the employer to make it enforceable.
2
The guarantor shall insert an amount representing the percentage of the contract price specified in the contract and
denominated either in the currency(ies) of the contract or a freely convertible currency acceptable to the employer.
3
Insert the date 28 days after the expected completion date. The employer should note that in the event of an extension of
the time for completion of the contract, the employer would need to request an extension of this guarantee from the
guarantor. Such request must be in writing and must be made prior to the expiration date established in the guarantee. In
preparing this guarantee, the employer might consider adding the following text to the form, at the end of the penultimate
paragraph: “The Guarantor agrees to a one-time extension of this guarantee for a period not to exceed [6 months][1 year],
in response to the Employer’s written request for such extension, such request to be presented to the Guarantor before
the expiry of the guarantee.”
4
Or the same or similar to this clause specified in the Uniform Rules for Demand Guarantees, ICC Publication No. 758
where applicable.
9-5
Section-9: Contract Forms RSTDIP/ SRD/01
Date: .........................................................................................................................
We have been informed that . . . . . name of the contractor. . . . . (hereinafter called "the
Contractor") has entered into Contract No. . . . . . reference number of the contract. . . . . dated . .
. . . . . .with you, for the execution of . . . . . . name of contract and brief description of works. . . . .
(hereinafter called "the Contract").
Furthermore, we understand that, according to the Conditions of the Contract, an advance
payment in the sum . . . . . name of the currency and amount in words5. . . . . . (. . . . . amount in figures.
. . . . ) is to be made against an advance payment guarantee.
At the request of the Contractor, we . . . . . name of the bank. . . . . hereby irrevocably undertake
to pay you any sum or sums not exceeding in total an amount of . . . . . name of the currency and
amount in words6. . . . . . (. . . . . amount in figures. . . . . ) upon receipt by us of your first demand in
writing accompanied by a written statement stating that the Contractor is in breach of its
obligation under the Contract because the Contractor:
(a) used the advance payment for purposes other than the costs of mobilization and cash
flow support in respect of the Works; or
(b) has failed to repay the advance payment when it has become due and payable in
accordance with the conditions of the Contract, specifying the amount payable by the
Contractor.
It is a condition for any claim and payment under this guarantee to be made that the advance
payment referred to above must have been received by the Contractor on its account number .
. . . . Contractor’s account number. . . . . at . . . . . name and address of the bank. . . . . .
The maximum amount of this guarantee shall be progressively reduced by the amount of the
advance payment repaid by the Contractor as indicated in copies of interim statements or
payment certificates which shall be presented to us. This guarantee shall expire, at the latest,
upon our receipt of a copy of the interim payment certificate indicating that ninety percent
(90%) of the Contract Price has been certified for payment, or on the . . . day of . . . . . . . , . . . .
. 7, whichever is earlier. Consequently, any demand for payment under this guarantee must be
received by us at this office on or before that date.
This guarantee is subject to the Uniform Rules for Demand Guarantees, ICC Publication No.
458 (or ICC Publication No. 758 as applicable).
............................
Signature(s) and seal of bank (where appropriate)
Note to Bidder
If the institution issuing the advance payment security is located outside the country of the employer, it shall
have a correspondent financial institution located in the country of the employer to make it enforceable.
1
The guarantor shall insert an amount representing the amount of the advance payment denominated either in the
currency(ies) of the advance payment as specified in the Contract, or in a freely convertible currency acceptable to the
employer.
2
Footnote 1.
3
Insert the expected expiration date of the time for completion. The employer should note that in the event of an extension
of the time for completion of the contract, the employer would need to request an extension of this guarantee from the
guarantor. Such request must be in writing and must be made prior to the expiration date established in the guarantee. In
preparing this guarantee, the employer might consider adding the following text to the form, at the end of the penultimate
paragraph: “The Guarantor agrees to a one-time extension of this guarantee for a period not to exceed [6 months][1 year],
in response to the Employer’s written request for such extension, such request to be presented to the Guarantor before
the expiry of the guarantee."
9-6
Section-9: Contract Forms RSTDIP/ SRD/01
We hereby certify that the above plant, material and equipment are required for use of the
under Rajasthan Urban Sector Development Program (RUSDP) being implemented under
the Local Self Government Department of the Government of Rajasthan. We further certify
that the Rajasthan Urban Sector Development Program (RUSDP) is being financed by the
Asian Development Bank (ADB) through loan No. ADB Loan: 3183-IND, duly approved by
the Government of India. We also certify that the condition of giving an essentiality certificate
for claiming custom duty exemption exists in the Contract Agreement with this organization.
This Certificate is being issued in pursuance to the requirement under Government of India
(Ministry of Finance, Department of Revenue) Notification No. 84/97 dated 1.11.1997 as
amended up to date. Custom Duty exemption may be allowed against the above referred
plant, materials and equipment.
________________________ ________________________
Project Director, RUIDP
Countersigned by:
[Name]
Secretary Finance (Expenditure)
Government of Rajasthan
9-7