Professional Documents
Culture Documents
Itb - Rev - 08 Bhel
Itb - Rev - 08 Bhel
HY:MM:ITB Rev:08
( Attachment to Enquiry No. F7A1T33090 Date:27.06.2020 Due on Date 18.07.2020 for submission by 11.00 hrs to open from 14.00 hrs.)
INSTRUCTIONS TO BIDDER (ITB)
NOTE: Bidder to confirm in affirmative by typing "YES" or "Applicable Data" in the response column. Deviations , if any shall
be recorded in deviations/comments column (Separate sheet can be attached if needed). Non deviatable clauses are indicated
as "NON DEVIATABLE".
VENDOR
Sl. DETAILED TERMS & CONDITIONS DEVIATIONS
RESPONSE
No. / COMMENT
(YES/NO)
1 SCOPE OF SUPPLY:
Signed & Sealed offers are invited for the Scope of Supply of goods and Services or both as detailed in the enquiry. Relevant
enclosures/supporting documents / catalogue, if any shall be enclosed to the technical offer. Bidder can also submit offer through
email at their own risk. The offer is to be submitted in two parts. Technical offer to be submitted to mail ID
[email protected], and price bid to be submitted to mail ID [email protected] as an attachment only. Interchanging the
information in the mails may lead to rejection of the offer. Supplier shall have no claim on e-mail offers sent on any other e-mail ID.
In case of e-mail offers, the mail subject should contain Enquiry No. Due date and Supplier name, Supplier address including
contact details shall be mentioned in the content of the mail. Without these details offer is liable for rejection.
2 GENERAL INSTRUCTIONS:
A The quotation should be neatly typed and free from over writing/ erasures. Any correction or Non Deviatable
addition must be authenticated. The offer including annexures and brochures should be
submitted in English / Hindi. All Pages of Techno Commercial Bids (Main Pages), ITB
should be signed and Stamped. If there is a conflict in case of bilingual submission, the
submission in English will be final.
B In case of Single-Part bid Tender, the complete bid shall be submitted in a single sealed Non Deviatable
cover super subscribing the Tender number and due date. Incomplete offers are liable for
rejection. E mail bids shall be sent to mail ID [email protected] as an attachment
only.
C Bidders to please note that the Terms & conditions contained in this document and Special Non Deviatable
conditions, if any, are to be read fully before submission of quotations.
D BHEL reserves the right to process the tender through Reverse Auction (RA) route. Non Deviatable
Bidders are requested to go through RA guidelines (which are attached) and confirm
acceptance of the same. Otherwise the offer is liable for rejection.
BHEL will decide (after technical bid opening), at its discretion, to process the tender
through Reverse Auction or by opening price bids.
E Vendors are advised to comply with specific conditions of the enquiry, Should there be any Non Deviatable
deviations (where deviations are permitted), it shall be entered in the deviation column.
BHEL reserves the right to reject such offers or load the bid suitably for evaluation.
F Offers shall be submitted directly, only by the vendor or by their authorized representative / Non Deviatable
agent and the offer should be in line with the regulatory guidelines (i.e A valid Agency
agreement between principal vendor and agent / representative shall be attached and the
agreement shall cover the scope of services rendered by Agent, Agency Commission and
any other information called for as per the regulatory guidelines). OEM / Mill details shall be
provided if supplier is not a manufacturer.
Bid envelops shall bear the name of Supplier. In case of submission through authorized
representative/agent, the name of representative/agent should also be mentioned apart
from supplier name.
G Offer received after the specified time and date of submission shall be rejected. No further Non Deviatable
correspondence shall be entertained.
H Unsolicited offers shall not be considered. Non Deviatable
3 OTHER PARTICULARS (Please indicate applicable data)
A Name of the Bid currency (freely tradable foreign currency for imports and Indian Rupees
for indigenous purchase).
B Name of the Port of loading and Port of Discharge (applicable to imports).
4 BID SUBMISSION PROCEDURE:
A. For Single Part Bids: Offers addressed to DGM/CMM, Vendor Complex, BHEL, Non Deviatable
Hyderabad must be sent in a sealed cover on which tender enquiry number and the due
date shall be super subscribed and sent by appropriate mode to above address or dropped
in tender box located at vendor complex on or before the specified time and date of
submission of offers, preferably in the bidder's envelope. For e-mail offers please follow the
procedure mentioned in 2 (B).
B. For two-Part Bids:
Page 1 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
ii Techno-commercial Bid will be opened on the assigned date .Only the price bids of vendors whose Non
techno commercial bids are accepted will be opened later on a specified date. In case BHEL opts for Deviatable
Reverse Auction, the date of conducting RA will be intimated separately to all the qualified bidders.
iii The bidders whose bids are techno commercially not accepted will be informed & EMD (Earnest
Money Deposit) shall be returned wherever submitted.
iv Bidders will be allowed to submit the impact on their quoted prices due to changes in technical scope, Non
specifications, and commercial terms/conditions as specified in NIT which in the opinion of BHEL Deviatable
warrant changes in prices.
v Bids shall be opened on due time and date in the presence of bidders who may like to be present. Non
Only one representative of each bidder shall be permitted to attend the bid opening. Deviatable
5 Delivery Instructions
A Indigenous Purchase
Goods shall be delivered on FOR Destination basis to the named destination(s) or as specified in
the enquiry, Insurance in the scope of supplier.
B. Imports
The goods shall be delivered on CIP-basis to port of discharge as mentioned in the purchase
order.
6 Documentation:
A Indigenous Purchase
Seller shall arrange to send to BHEL, Hyderabad along with all the required documents as detailed in Non
Purchase Order, such as, Tax Invoice (Original for Recipient, Duplicate for Transporter), consignee copy Deviatable
of LR, Packing list , Pre-dispatch Inspection report, Test/ Guarantee/ Warranty certificate/ O&M
manuals (as applicable) etc. immediately on dispatch of the goods. Any addition/ exclusion to such
documents shall be as specified in the Purchase Order.
In case of dispatches from vendor works to site, material receipt certified by site office / Customer shall
be provided.
Softcopies of the above documents shall be uploaded in Pradan portal https://web.bhelhyd.co.in/mm/
immediately after dispatch of the material
B Imports
i) Seller shall inform the purchaser the readiness of material along with packing details well in 30
days advance from the date of delivery.
Seller shall also upload soft copy of the dispatch documents consisting of BL / AWB, Invoice,
Shipping list & Test certificates and other documents as specifically indicated in the Purchase
Order
in PRADAN Portal (https://web.bhelhyd.co.in/mm/) within 3 days from the B/L date for sea
shipment
and 1 day from AWB date for Air shipment.
ii) In case of CIP shipments, seller shall also inform purchaser the information about discharge port
agent details and ship arrival information within 7 working days from the date of Shipment.
iii) In case the material shipped in Full Containers(FCL), Seller shall ensure that the Bill of Lading
should clearly spell out the following
1. Port of discharge -- "Nhavaseva"/chennai
2. Place of Delivery / Final Destination - "ICD Sanath Nagar".
3. For air consignment the port of discharge will be Hyderabad, India and consignee shall be
BHEL.
Page 2 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
iv) In case of Air shipment, the following dimensions of single package may be noted.
If any package dimension or weight crosses the above set limits, it will be treated as Over Dimension
Cargo (ODC) or Over Weight Cargo and seller shall inform BHEL well in advance of 20 days prior to the
delivery date to enable BHEL to finalize the freight forwarder
(vi) Description of items in invoice, packing list, BL / AWB or LR shall be same as PO item description.
Vendors shall ensure that invoice shall contain PAN nos. of both seller and buyer along with other tax
related numbers. BHEL PAN AAACB4146P and BHEL TAN HYDB00086C
Any other additional documents sought by the statutory authorities, the same shall be produced by the
seller on priority basis.
(vii) Seller shall provide package details including number of packages, gross weight, net weight etc.
(viii) The seller shall provide the following documents at the time of submission of offer :-
a) No Business Connection in India declaration issued by the seller as per the format specified. (or)
b) (i) No Permanent Establishment in India declaration issued by the seller as per the format
specified.
(ii) Tax Residence Certificate issued by the seller’s tax authorities.
(iii) Form 10F issued by the supplier.
c) In case the seller has a Business Connection in India as per Section 9 of Income Tax Act or
Permanent Establishment in India as per Article 5 of Double Taxation Avoidance Agreement between
India and the seller’s country, the seller shall provide a withholding tax order issued by the Indian
Income Tax authority for recovery of applicable tax.
Page 3 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
7 Delivery Schedule
A The tendered goods shall be delivered within the period stipulated in PO . Delivery at BHEL can be Non
accepted at the earliest, 30 days prior to delivery date as mentioned in the Purchase order. Delivery Deviata
earlier than 30 days of contractual delivery date may be accepted with the written permission of BHEL ble
-Purchase department.
Goods arriving after the delivery date will be accepted only with the prior written permission of BHEL
otherwise they will not be allowed inside the factory. BHEL reserves the right to reject the material, if not
delivered by scheduled Purchase Order Delivery Date.
(In case of imports , the final entry date of Import General Manifest (IGM) will be reckoned as delivery
completion date )
B Documents such as TC,GCs Inspection reports are to be submitted within 10 days of dispatch of these
materials. C note date or Date of submission of documents whichever is later shall be considered as
delivery date incase documents are not submitted within 10 days from the dispatch of the material.
Supply of plant/ equipment/ stores shall not be considered complete until they have been inspected and
accepted at the place and destination specified for delivery by the time stipulated under the terms &
conditions of the Order/ Contract. Mere payment by itself shall not constitute acceptance of the goods
or materials in any manner, whatsoever.
8 Pricing Terms
Prices once quoted shall remain firm and valid during the execution of PO. Offers with PVC will be Non
rejected outright except in cases where specifically called for in the NIT. Deviata
ble
9 PRICE VALIDITY :
Unless otherwise specified, offer shall be valid for a period of 90 days from the date of bid opening
(Technical bid /part-I in case of two part bid).
However the prices quoted for spare parts of the Main equipment shall be kept valid for a period of 1
year from the date of Placement of PO for the main equipment.
10 Taxes & Duties (RATE TO BE INDICATED by the bidder against the space provided )
A Indigenous Purchase
The Taxes as applicable shall be quoted in the following manner.
i Vendor to indicate HSN of Goods or SAC of Services.
ii IGST/CGST/SGST/UTGST: Rate of Tax to be quoted as extra in %
111 Payment Terms: Unless otherwise specified in Special Conditions, following shall be the terms of Payment.
Page 4 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
A Indigenous:
100% payment along with taxes, freight & insurance will be made within 75 days from the date of receipt of
complete documentation as per PO. However payment would be done only after receipt of original
documents, including site/ Customer acknowledgement on LR (MRC - Material Receipt Certificate at site) /
GR clearance at BHEL Stores.
For MSEs (covered under MSME Act) which are registered and periodically renewed with BHEL, this
period will be 45 days* as prescribed in the relevant act.
Adherence to the above time schedule of payment is contingent upon Vendor complying with GST
provisions and availment of Input Tax Credit by BHEL before the date of payment.
*The taxes and duties that are reimbursed would be the ones applicable as on the contractual
Purchase Order delivery date or the amount actually paid whichever is less.
In case GST credit is delayed/ denied to BHEL, due to non/delayed receipt of goods and/or tax invoice
or expiry of timeline prescribed in GST Law for availing such ITC, or any other reason not attributable to
BHEL, GST amount shall be recoverable from Vendor along with interest levied/ leviable on BHEL.
B Imports:-
i) 100% payment (less Indian Agency Commission, if any) shall be paid through “Usance Letter of
Credit / Cash Against Documents (CAD) / Wire Transfer” with a credit period of 60 days
ii) LC will be opened after successful completion of pre dispatch inspection prior to the scheduled /
agreed delivery date LC will be opened within 7 working days from the date of request.
C Note: Non
1) No advance payment is acceptable. However, in exceptional/rare cases, BHEL at its discretion, may Deviatable
consider advance payment against Bank Guarantee valid up to receipt of material at BHEL for 110% of
advance amount issued / confirmed by any of the BHEL consortium banks.
2) Wherever EMD (Earnest Money Deposit) is applicable, it may be noted that no interest will be paid on
EMD and the EMD will be paid back to unsuccessful bidders within fifteen days after award of the
contract. Successful bidder's EMD will be converted to SD (Security Deposit).
Tender Cost wherever applicable is not refundable.
12 Penalty clause:
In the event of delay in supply of goods, penalty of 0.5% per week or part there of shall be levied on the
undelivered portion subject to a maximum of 10% of the order value. Penalty amount so determined
along with applicable GST thereon shall be recovered.
13 Excess materials supplied beyond tolerance limit as specified in PO, will not be accounted for. Non
Deviatable
14 Rejected materials, if any, shall be collected by the vendor within 90 days of such communication to the Non
vendor .Beyond 90 days a ground rent of 0.25 % of the value of the material per Deviatable
week will be levied for a maximum period of two weeks.. Beyond this period the supplier forfeits their right
to the materials.
15 Guarantee / Warranty Period : Non
(Deviation to this clause is not acceptable.) Deviatable
Wherever required, and so provided in the specifications/Purchase Order, the seller shall guarantee that
the goods supplied shall comply with the specifications laid down, for materials, workmanship and
performance. If within the guarantee period, the delivery is found to be non-complaint, the seller shall on
his own account, replace repair, or re-execute the delivery at Purchaser's discretion on the purchaser's first
request or within the mutually agreed period, without prejudice to Purchaser’s other legal rights. If the
seller continues to default on their obligations, purchaser has the right to proceed to replace, repair or re-
execute the order at the seller’s expense, with or without help from third parties. Purchaser shall notify the
seller of the exercise of this right in advance where ever possible.
Unless otherwise specified, guarantee period shall be 12 months from the date of commissioning or 18
months from the date of supply/replacement whichever is earlier. For bought out packages which are
intended to be incorporated in installations or systems the guarantee period shall not start until the time the
installations or systems are commissioned, provided always that the period ends not later than 30 months
after the date of supply of the goods.
The guarantee period shall be extended by the period during which the goods are not in
compliance. A guarantee period as described above shall apply afresh to replaced, repaired or re-
executed parts of a delivery.
Page 5 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
NOTE: Deviations (Commercial as well as Technical) from the tender specifications and conditions are generally not
acceptable. However, deviation if any, shall be brought out clearly with proper justification in the offer. The deviation, if
considered by BHEL, shall be loaded for comparison, while evaluating the offer. If a bidder unconditionally withdraws any
deviation before price bid opening, the same shall not be loaded. Loading criteria in respect of major commercial conditions
where deviations if any are accepted shall be as per clause No.16.
The Vendors may specifically note the following.
A Evaluation of prices shall be done item-wise unless otherwise specified in the enquiry. Evaluation shall be on the basis of delivered
cost, i.e. “total cost to BHEL” w.r.t the finalized technical scope and commercial conditions (after considering incidence of applicable
taxes and duties and loading). For evaluation, exchange rate (TT selling rate of State Bank of India) as on the date of bid opening
(Part-I, in case of two-part bids) shall be considered. If the relevant day happens to be a bank holiday, then the forex rate as on the
previous bank (SBI) working day shall be taken.
B In case of foreign bidders, the quoted CIP price shall be loaded by the following factors to arrive at the Delivered Cost:
i - Import duty as applicable at the time of Price/ Part-II bid opening.
ii - Port handling/ clearing charges & inland freight and insurance: @ 5% of CIP value (10% for plates, pipes & structurals).
iii In other cases subject to acceptance by BHEL, loading for various factors (in addition to above) as the case may be will be done as follows:
0.5% for unloading at Port of Destination
Marine Freight 4% and Marine Insurance 1% (9% and 1% towards Freight and Insurance respectively for Plates, Pipes, Rounds & Structurals)
C Incase of Indigenous Bidders, Ex-works offers received (as against FOR Destination mentioned in enquiry) shall be loaded by 4% of
Ex-works value (9% for plates, pipes, rounds & structurals) unless otherwise mentioned in enquiry.
D Deviated Penalty: Any loading on penalty clause shall be 10% or to the extent to which the vendor has opted for deviation.
E Deviated Payment Terms: Terms: In case BHEL considers any deviation in payment terms, the bids shall be loaded with 18%
interest per annum to the extent of deviation.
17 Procurement directly from the manufacturers/ suppliers shall be preferred. However, no agent shall be allowed to represent more
than one manufacturer/ supplier in the same tender. Moreover, either the agent could bid on behalf of the manufacturer/ supplier or
the manufacturer / supplier could bid directly but not both. In case bids are received from both from the manufacturer/ supplier and
the agent, bid received from the agent shall be ignored.
18 RIGHT OF REJECTION /NON- PLACEMENT OF PO: BHEL reserves the right to accept or reject any or all bid/s in full or part
without assigning any reason whatsoever.
19 INTEGRITY PACT
Vendors shall have to enter into Integrity Pact with BHEL as per attachment - for order value of rupees five crores and above and
shall be signed by the competent authority before the issue of purchase order, failing which vendor’s offer will be rejected.
20 Make in India
For this Procurement , Public Procurement ( Preference to Make in India ) , Order 2017 dated 15.06.2017 & 28.05.2018 and
subsequent Orders issued by the respective Nodal Ministry shall be applicable even if issued after issue of the NIT but before
finalization of Contract / PO/ WO against this NIT . In the event of any Nodal Ministry prescribing higher or lower percentage of
Purchase preference and / or local content in respect of this procurement , same shall be applicable . Preference to Make in India
including counter offering will be as per the Public Procurement (Preference to Make in India ) , Order 2017 available in the following
links
https://dipp.gov.in/sites/default/files/publicProcurement_MakeinIndia_15June2017.pdf
https://dipp.gov.in/sites/default/files/Revised-PPP-MII-Order-2017_28052018.pdf
Proforma for self certification for minimum local content and auditor’s certification is given in Annexure III .
21 Benefits earmarked for Purchase from Micro & Small Enterprises (MSEs) – Indigenous Purchase
21 A All Micro and Small Enterprises (MSEs) as defined in MSE Procurement Policy are exempt from Paying earnest money deposit .
NSIC registered unit bidders shall submit NSIC Certificate along with bid documents. Date to be reckoned for determining the
deemed validity will be the last date of Technical bid submission. Non- submission of such document will lead to consideration of
their bid, at par with other bidders and MSE status of such bidders shall be shifted to Non- MSE Category till the supplier submits
these documents
21 B In tender,if MSEs quoting price within price band of L1+15% shall also be allowed to supply a portion of requirement by bringing
down their price to L1 price in a situation where L1 price is from someone other than a MSE and such MSE shall be allowed to
supply up to 25% of total tendered value. In case of more than one such MSE, the supply shall be shared proportionately. Out of
these 25% minimum 3% shall be earmarked for MSEs owned by women and 6.25% for MSEs owned by SC/STs who submit the
bid along with relevant documents . This is applicable in case of item-level evaluation tenders and divisible tenders .
21 C If an enterprise falling under MSME category as defined in the Act, graduates to a higher category from its original category or
beyond the purview of the Act, it shall continue to avail all non-tax benefits of its original category notified by the Ministry of Micro,
Small and Medium Enterprise for a period of three years from the date of such graduation to the higher category.
Page 6 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
22 Startups :
For Startups Medium Enterprises, Condition of prior turnover and prior experience in Public Procurement may be relaxed subject to
meeting of Quality and Technical Specifications . Startups are exempt from paying earnest money deposit .
23 For Claiming Payments for goods received at BHEL works / Site from Vendors' Works)
a. Original of Invoice marked as ORIGINAL FOR RECIPIENT
b. Duplicate of Invoice marked as DUPLICATE FOR TRANSPORTER
c. Packing List - clearly showing number of packages, gross weight and net weight.
d. Warranty/Guarantee certificates (If applicable as per PO terms)
e. Insurance certificate
f. Third Party Inspection Certificates.
g. LR Copy signed & stamped by Site incharge / Customer for site deliveries)
(For material received at BHEL payment will be made against GR for accepted quantity)
24 Inspection Measuring and Test Equipment (IMTE) whether used by the Seller/ Contractor or sub-contractor shall be calibrated,
maintained and controlled. Calibration shall be valid and IMTE maintained in sound condition during usage.
27 Being PMD Vendor, if you are not quoting against this tender enquiry, please send your regret letter positively for our reference with
valid reasons for not participating in the tender enquiry. Repeated lack of response on the part of bidder may lead to deletion such
PMD vendor from BHEL's approved vendor list
Vendor shall ensure that PAN details are available/updated with BHEL, else Vendor shall attach PAN details with enquiry failing
which offer shall be liable for rejection.
28 Kindly quote your prices in figures and words both. In case of any discrepancy in value, the prices quoted in words shall be
considered for evaluation and establishing L1 Status
29 Any discount / revised offer / bids submitted by a bidder on its own shall be considered, provided it is received on or before the due
date and time of offer / bid submission (Part-1). Conditional discounts shall not be considered for evaluation of tenders.
30 The bidder whose bid is technically not accepted will be informed & EMD wherever submitted shall be returned after finalization of
contract. EMD shall be forfeited in the event of bidder opting out after tender opening.
31 In case of abnormal delays (beyond the maximum late delivery period as per Penalty clause) in supplies / defective supplies or non-
fulfillment of any other terms and conditions given in Purchase Order, BHEL may cancel the Purchase Order in full or part thereof,
and may also make the purchase of such material from elsewhere / equivalent market price at the risk and cost of the supplier.
BHEL will take all reasonable steps to get the material from alternate source at optimum cost. If bidder does not agree to the above
Risk Purchase Clause, BHEL reserves the right to reject the offer. Nonperformance of contract attracts penal provisions inline with
BHEL's Suspension of Business dealings.
32 Any other terms and conditions of the bidder attached / referred against the tender enquiry will not be considered.
33 All drawings as also all patterns and tool supplied by BHEL or made at BHEL's expense are BHEL's property. These cannot be
used or referred to any other party and must only be used in the execution of BHEL's orders.
34 Any amount payable by the consignor / supplier under any of the condition of this contract shall be liable to be adjusted against any
amount payable to the consignor / supplier under any other work / contract awarded to him. This is without prejudice to any other
action as may be deemed fit by BHEL.
35 The bids of the bidders who are on the banned list and also the bids of the bidders, who engage the services of the banned firms,
shall be rejected. The list of firms banned by BHEL is available on BHEL web site www.bhel.com
36 Definitions
Throughout these conditions and in the specifications, the following terms shall have the meanings assigned to them, unless the subject
matter or the context requires otherwise.
7A34
‘The P Purchaser’ means BHEL-HPEP, Ramachandrapuram, Hyderabad-502 032 of Bharat Heavy Electricals Limited (A Govt. of India
36 Undertaking) incorporated under the companies Act having its registered office at BHEL House, Siri fort, New Delhi-110049, India
A and shall be deemed to include its successors and assigns. It may also be referred to as BHEL.
‘The seller’ means the persons, firm, company or organization on whom the Purchase order is placed and shall be deemed to
36 B include the seller’s successors, representatives, heirs, executors and administrator as the case may be. It may also be
referred to as Contractor, supplier or vendor.
Page 7 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
36 c ‘Contract’ shall mean and include the Purchase order incorporating various documents viz., tender/offer, letter of intent/acceptance,
the General Conditions of contract and special conditions of contract for Purchase, specifications, inspection/quality plan, schedule
of prices and quantities, drawings, if any enclosed are to be provided by the Purchaser or his authorized nominee and the samples
or patterns if any to be provided under the provision of the contract.
In case of any inconsistency or contradiction between any of the documents, the order of precedence shall be Purchase Order,
LOI/LOA followed by specific conditions, special conditions of contract and general conditions of contract for commercial conditions;
and specific agreement on technical conditions, special technical conditions and general technical conditions, tender/ offer.
37 ‘Parties to the contract’ shall mean the seller and the purchaser as named in the main body of the Purchase Order.
38 Ordering and confirmation of order
The seller shall send the order acceptance in Toto within one week from the date of LOI/Purchase order or such other period as
specified/agreed by the Purchaser. Purchaser reserves the right to revoke the order placed if the order confirmation differs from the
original order placed. Purchaser shall only be legally bound if agreed explicitly in writing to be in agreement with the deviation. The
acceptance of deliverables or supplies by Purchaser as well as payments made in this regard shall not imply acceptance of any
deviations.
The Purchaser order will be deemed to have been accepted if no communication to the contrary is received within one week (or the
time limit as specified /agreed by the Purchaser) from the date of P.O.
Purchaser, is at liberty to send signed P.O. through electronic media such as e-mail and the receipt of which shall be treated as
receipt of order.
39 Execution
The whole contract is to be executed in the most workman like manner, substantial and approved as per the contracted terms.
40 Progress Report
The seller shall render such report as to the progress of work and in such form as may be called for by the Purchaser from time to
time. The submission and acceptance of such reports shall not prejudice the rights of the purchaser in any manner. Seller shall
communicate to BHEL immediately, change of address, ownership, contact person(s), the mobile numbers and e-mail of the dealing
person concerned.
Milestones shall be periodically updated by vendor/subcontractor through PRADAN Portal (https://web.bhelhyd.co.in/mm/ ).Non
updation will adversely affect service rating of vendor performance.
Page 8 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
42 B Purchaser or his authorized representative shall be entitled at all reasonable times during execution to inspect, examine and test at
the seller’s premises the material and workmanship of all stores to be supplied under the contract, and if the part of the stores are
being manufactured at other premises, the seller shall obtain for purchaser or his authorized representative permission to inspect,
examine and test as if the said stores are being manufactured at the seller’s premises. Such inspection, examination and testing, if
made shall not release the seller from any obligation under the contract.
For indigenous suppliers all costs related to first inspection request shall be borne by the purchaser and the cost of subsequent
inspections due to non-readiness of material/rework/ rejections shall be borne by the seller. In case of imports all inspection
charges including third party inspections if any shall be borne by the seller. The cost of inspection staff/third party specified by the
Purchaser shall be borne by seller unless otherwise specifically agreed. Whether the contract provides for tests on the premises of
the seller or any of his sub-contractor/s, seller shall be responsible to provide such assistance, labor, materials, electricity, fuels,
stores, apparatus, instruments as may be required and as may be reasonably demanded to carry out such tests efficiently.
Cost of any type test or such other special tests shall be borne by the seller unless otherwise specifically agreed in the contract.
The Seller shall give the authorized representative of the purchaser reasonable notice in writing of the date on and the place at
which any stores will be ready for inspection/ testing as provided in the Contract. Annexure - I may be strictly be complied with for
the time lines. Any delay in submission of the documents by the vendor will not alter the delivery date.
46 Penalty
The time or period of delivery as stipulated in the schedule of delivery shall be deemed to be the essence of the contract. Should
circumstances arise whereby the deadline for an agreed delivery date(s) or period(s) is expected to be exceeded, the seller shall
inform Purchaser hereof without delay. If delay in delivery is caused by any of the circumstances mentioned in clause 52 (Force
Majeure) or which are caused exclusively by the acts of Purchaser, the Purchaser shall extend the time for delivery by a period
which is reasonable having regard to all the circumstances in the case.
If the Seller delays beyond any agreed delivery date(s) or period(s), Purchaser shall levy penalty for such delay @ 0.5% per week
(7 days) or part thereof on delayed portion of the order value subject to a maximum of 10% of the value of the Purchase Order.
However, penalty for delayed delivery will be calculated on 100% of the purchase order value if the material supplied cannot be put
to intended use.
The penalty will be charged on the value of the purchase order excluding statutory levies, freight and insurance wherever not
included in the price. Penalty amount so determined along with applicable GST thereon shall be recovered.
Imposition, recovery or settlement of this penalty shall not affect Purchaser’s right to performance, compensation and termination of
the agreement.
For delay analysis, period referred in Annexure-I will be considered as standard time lines for various major activities.
Page 9 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
The agreed prices are fixed prices in the currency as specified in the Purchase Order. They shall include packing, forwarding ,
loading and carriage to the place specified by the purchaser and are exclusive of all applicable taxes, duties etc., except for those
specifically agreed by the Purchaser. Invoices shall be submitted bearing the Purchase Order number & date, item number/s and
supporting documents as called for in the Purchaser order.
The direct payments (including LC/documents through Bank on collection basis), shall be made by E-payment mode and not by
cheque /bank drafts except in special circumstances. Vendors shall furnish the E-payment particulars in the prescribed formats
duly authenticated by their respective Bankers, If not got registered earlier with the Buyer.
. Invoice has to be raised quoting HSN Code of Goods or Accounting Code of Services. Invoice should mention BHEL-HPEP-
HYDERABAD GSTIN: 36AAACB4146P1ZG or GSTIN of BHEL Nodal Agency as mentioned in PO.
Indian Agency commission if payable and so specified in the Purchase order shall be paid in Indian Rupees, considering the SBI
TT selling exchange rate prevailing on the date of tender opening (part 1 in case of two part bid), after successful completion of the
contract.
If so stipulated in the order, the seller shall furnish, on receipt of the Purchase Order or along with order acknowledgement, the
billing break-up of prices (BBU) for approval by the purchaser in respect of the major items/components going into the equipment.
This BBU is required by the Purchaser for admitting the claims of the seller if part shipments are contemplated and also to facilitate
custom clearance after payment of duties in case of imports.
In case of delay in receipt of supporting document details, consequential demurrage/wharf age
/detention charges shall be to the account of the seller.
Payment does not imply in any respect whatsoever a waiver of Purchaser’s right to performance of the agreement. Purchaser is
entitled to set off claimable debts against claimable liabilities with the seller by means of a setoff Note.
49 Contract variations; Increase or decrease in the scope of supply
Purchaser may vary the contracted scope during execution due to exigencies of project requirement.
If the seller is of the opinion that the variation has an effect on the agreed price or delivery period, Purchaser shall be informed of
this immediately in writing along with technical details, and in the event of additional work, submit a quotation with regards to the
price and period involved, as well as the effect this additional work will have on the other work to be performed by the seller.
Provided, that if unit rates are available in the contract, the same shall be applied to such additional work. The seller shall not
perform additional work before purchaser has issued written instructions/amendment to the purchase order to that effect. The work
which the seller should have or could have anticipated in terms of delivering the service (s) and functionality (ies) as described in
this agreement should be executed by the vendor without any price implication.
Purchaser shall have the right to completely or partially terminate the agreement by means of written notice to that effect without
prejudicing their other rights in the event that :
-The seller is declared bankrupt, its business has been shut down or liquidated, a substantial part of its assets have been
attached/destroyed, or the business has been transferred to a third party.
-Any misrepresentation or hiding of material fact if detected at a later stage.
-The delivery is rejected after inspection or re-inspection.
-In the event of termination, the risk of the items already delivered but not of use to Purchaser, as determined by purchaser,
remains with the seller. The items shall then be at the seller’s disposal and they are to be collected by the seller. The seller shall
refund any payments made by purchaser in terms of the terminated agreement immediately, not later than 30 days,
- In the event of Cancellation/ termination of contract, BHEL reserves the right to procure the items which are not delivered as per
PO and charge the excess cost from the defaulting seller. Incase the excess cost is not repaid by or recovered from the defaulting
seller within 30 days, apart from legal recourse for effecting such recoveries, Penal action in line with BHEL's Suspension of
Business dealings will be taken.
54 Force Majeure
Page 10 of 11
BHARAT HEAVY ELECTRICALS LTD. , RC.PURAM, HYDERABAD Document No. HY:MM:ITB Rev:08
The supplier shall not be considered in default if delay occurs due to causes beyond their control such as Acts of God, Natural
calamities, Fire, Frost, Flood, Civil War, civil commotion, riot, Government Restrictions.
Only those causes that have duration of more than seven days shall be considered cause of force majeure. Notification to this
effect duly certified by local chamber of commerce/statutory authorities with supporting documents shall be given by the supplier to
BHEL by registered letter/courier service immediately without loss of time.
In the event of delay due to such causes the delivery schedule shall be extended for a length of time equal to the period of Force
Majeure or at the option of BHEL the order may be cancelled. Such cancellation would be without any liability whatsoever on the
part of BHEL.
In the event of such cancellation the supplier shall refund any amount advanced or paid to the supplier by BHEL and deliver back
any material issued to him by BHEL and release facilities, if any provided by BHEL.
55 Non-waiver of Defaults
If any individual provision of the contract is invalid, the other provisions shall not be affected.
56 Settlement of Disputes
Except as otherwise specifically provided in the contract, all disputes concerning questions of the facts arising under the contract,
shall be decided by the Purchaser, subject to written appeal by the seller to the purchaser, whose decision shall be final.
Any disputes of differences shall to the extent possible be settled amicably between the parties thereto, failing which the disputed
issues shall be settled through arbitration.
The seller shall continue to perform the contract, pending settlement of disputes(s).
57 Arbitration & conciliation clause and Interest clause :
(I).Except as provided elsewhere in this contract, in case amicable settlement is not reached between the parties, in respect of any dispute or
difference; arising out of the formation, breach, termination, validity or execution of the contract; or, the respective rights and liabilities of the
parties; or, in relation to interpretation of any provision of the contract; or, in any manner touching upon the contract, then, either party may, by
a notice in writing to the other party refer such dispute or difference to the sole arbitration of an arbitrator appointed by head of the BHEL unit
issuing the contract.
The Arbitrator shall pass a reasoned award and the award of the Arbitrator shall be final and binding upon the parties.
Subject as aforesaid, the provisions of Arbitration and Conciliation Act 1996 (India) or statutory modifications or re-enactments thereof and the
rules made thereunder and for the time being in force shall apply to the arbitration proceedings under this clause, the seat of arbitration shall be
at Hyderabad.
The cost of arbitration shall be borne as per the award of the Arbitrator.
Subject to the arbitration in terms of clause 55, the courts at Sangareddy, Telangana State shall have exclusive jurisdiction over any matter
arising out of or in connection with this contract.
Notwithstanding the existence or any dispute or differences and / or reference for the arbitration, the contractor shall proceed with and continue
without hindrance the performance of its obligations under this contract with due diligence and expedition in a professional manner except
where the contract has been terminated by either party in terms of this contract.
In case of contract with Public Sector Enterprise (PSE) or a Government Department, the following shall be applicable:
In the event of any dispute or difference relating to the interpretation and application of the provisions of the contract, such dispute or difference
shall be referred by either party for arbitration to the sole arbitrator in the Department of Public Enterprises to be nominated by the secretary to
the Government of India in–charge of the Department of Public Enterprises. The Arbitration and Conciliation Act, 1996 shall not be applicable
to arbitration under this clause. The award of the arbitrator shall be binding upon the parties to the dispute, provided, however, any party
aggrieved by such award may make further reference for setting aside or revision of the award to the Law Secretary, Department of Legal
Affairs, Ministry of Law and justice, Government of India. Upon such reference the dispute shall be decided by the Law secretary or the special
Secretary or Additional secretary when so authorized by the Law secretary, whose decision shall bind the parties hereto finally and
conclusively. The parties to the dispute will share equally the cost of arbitration as intimated by the arbitrator.
(2) INTEREST CLAUSE:
In order to bring uniformity in all the contracts / agreements entered between BHEL and its contractors / vendors / suppliers / service providers
etc., it is hereby advised to incorporate the following clause in all tenders and agreements.
“No interest shall be payable by BHEL on earnest money or security deposit or any money due to the contractor by BHEL.”
Page 11 of 11