Contract Document for Construction Client: of

Contractor:

Table of Contents

1. Contract agreement . . . . . . .

2. Conditions of contract
Part i: general conditions of contract . . . . .
Part ii: special conditions of contract . . . . .

3. Priced bill of quantities & technical specifications. . . .

Annexes
Annex a: drawings
Annex b: master work schedule
Annex c: project control system

Appendix of contract

P a g e 1 | 63
Contract Document for Construction Client: of
Contractor:

1. CONTRACT AGREEMENT FOR CONSTRUCTION WORKS.

This agreement, herein after also called “the Contract”, is made on the _____ day of ____________,
________.

Between
………………………………..
Registered Address: Bole Subcity Wereda-10 House No ____________
Addis Ababa, Ethiopia
Phone _______________________
Fax _______________________
Email _______________________

Herein after called “the Employer” or “the Client”, of the one part And
…………………………………………..
A company established under the commercial laws of The Federal Democratic Republic of Ethiopia
and having its principal place of business at

_______________Subcity Wereda-_____ House No. ________

Addis Ababa, Ethiopia
Phone _______________________
Fax _______________________
Email _______________________

Hereinafter called “the Contractor”, of the other part.

WHEREAS the Employer is desirous that the construction project known as .............................
Located in Addis Ababa, bole Subcity Woreda 10; herein after called “the Works”, be executed by the
Contractor,

WHEREAS the Employer has accepted the offer by the Contractor for the execution, completion
of the Works and the remedying of any defects therein for the sum of
___ _____________
15% VAT: ___________________
Grand total contract amount: ____ ETB_______
(…………………Amount in words) including 15% VAT.

Hereinafter called “the Contract Price”)

WHEREAS the Contractor has declared it has all the required capabilities, resources & skills such as
but not limited to legal, financial, professional capabilities to complete the Works as per the terms and
conditions of the contract

WHEREAS the Contractor is desirous of carrying out the Works as per the terms and conditions of
the contract for its own gain.

P a g e 2 | 63
Contract Document for Construction Client: of
Contractor:

NOW THIS AGREEMENT WITNESSES AS FOLLOWS:

1. In this Agreement, words and expressions shall have the same meanings as are respectively
assigned to them in the Conditions of Contract referred to.

2. In consideration of the payments to be made by the Employer to the Contractor as hereinafter

mentioned, the Contractor hereby covenants with the Employer to execute and complete the
Works and remedy any defects therein in conformity in all respects with the provisions of the
Contract.

3. The Employer hereby covenants to pay the Contractor in consideration of the execution and
completion of the Works and the remedying of defects therein the Contract Price including
VAT or such other sum as may become payable under the provisions of the Contract at the
times and in the manner prescribed by the Contract.

4. The documents forming the contract included in Clause 2 of the Standard Conditions of
Contract in this Contract document keeping their order of priority in times for discrepancies
among them shall be deemed to form and be read and construed as part of this contract
agreement.

5. The Contract Price or such other sum as may be payable shall be paid in Ethiopian Birr only.

IN WITNESS whereof the parties thereto have caused this Agreement to be executed in accordance
with the law specified in the Special Conditions of Contract on the day, month and year indicated
above.

for the Employer:

In the Capacity of:
Name: ______________________________
Position: ____________________________
Signature: ____________________________ Seal: _________________________

for the Contractor:

In the Capacity of:
Name: ______________________________
Position: ____________________________
Signature: ____________________________ Seal: _________________________
Witnesses
For the Employer
1. __________________________________ (Name) ___________ (Signature)
2. __________________________________ (Name) ____________ (Signature)
For the Contractor
1. __________________________________ (Name) ___________ (Signature)
2. __________________________________ (Name) ____________ (Signature)

P a g e 3 | 63
Contract Document for Construction Client: of
Contractor:

2. General Conditions of Contract

P a g e 4 | 63
 Contract Document for Construction Client: of
Contractor:

A. General Provisions
1. Definitions

1.1 The headings and titles of these General Conditions of Contract shall not limit, alter or affect the
meaning of the Contract
1.2 The following words and expressions shall have the meanings hereby assigned to them:

A.1.1.1.1 "Bill of means the document forming part of the Bid and containing an
Quantities" itemized breakdown of the works to be carried out in a unit
price contract, indicating a quantity for each item and the
corresponding unit price;
A.1.1.1.2 "Completion means the fulfillment of the Contract by the Contractor in
" accordance with the terms and conditions set forth in the in the
GCC Clause 87;
A.1.1.1.3 "Contract means the documents listed in the GCC, including all
Documents" attachments, appendices, and all documents incorporated by
reference therein, and shall include any amendments thereto;
A.1.1.1.4 "Contract Manager" means a person designated as such by the Contractor from time
to time as notified in writing to the Employer to act as the duly
authorized representative of the Contractor for all purposes
connected with the Contract, including any authorized
representative of such person;
A.1.1.1.5 "Contract Price" means the accepted contract amount stated in the this contract
agreement. The amount represents the initial estimate payable
for the execution of the works or such other sum as ascertained
by the final statement of account as due to the Contractor
under the contract;
A.1.1.1.6 "Contract" means the binding Contract Agreement entered into between
the Employer and the Contractor, comprising Contract
Documents referred to therein, including all attachments,
appendices, and all documents incorporated by reference
therein,
A.1.1.1.7 "Contractor" means a natural or juridical person under contract with the
Employer to supply works;
A.1.1.1.8 "Day" means calendar day unless specified
A.1.1.1.9 "Dayworks" mean varied work inputs subject to payment on an hourly basis
for the Contractor's employees and equipment, in addition to
payment for associated materials and plants;
A.1.1.1.10 "Defect" Defect is any part of the Works not completed in accordance
with the Contract;
A.1.1.1.11 "Defects Liability is the period stated in the Special Conditions of Contract
Period" immediately following the date of provisional acceptance,
during which the Contractor is required to complete the works
and to remedy defects or faults as instructed by the Engineer;
A.1.1.1.12 "Drawings" mean the drawings of the Works, as included in the Contract,
and any additional and modified drawings issued by (or on
behalf of) the Employer in accordance with the Contract,
include calculations and other information provided or
approved by the Engineer for the carrying out of the works.
P a g e 5 | 63
 Contract Document for Construction Client: of
Contractor:

A.1.1.1.13 "Eligible Countries" means the countries and territories eligible as listed in Section
5 of the Bidding Documents;
A.1.1.1.14 "Engineer" means a person named in the Special Conditions of Contract or
appointed as such by the Employer and notified in writing to
the Contractor to act as the representative of the Employer to
supervise and inspect works and to test and examine the
materials employed and the quality of workmanship, including
any authorized representative of such person;
A.1.1.1.15 "Equipment" is the Contractor's machinery, vehicles, apparatus, components
and any other articles brought temporarily to the Site to
construct the Works;
A.1.1.1.16 "Final Acceptance Certificate(s) issued by the Engineer to the Contractor at the
Certificate" end of the Defects Liability Period stating that the Contractor
has completed its obligations to construct, complete, and
maintain the Works concerned;
A.1.1.1.17 "General Conditions of hereinafter referred to as “GCC”, means the general
Contract" contractual provisions setting out the administrative, financial,
legal and technical clauses governing the execution of the
Contract, except where amended by the SCC or Contract
Agreement;
A.1.1.1.18 "Good Industry means the exercise of that degree of skill, diligence and
Practice" foresight which would reasonably and ordinarily be expected
from a skilled and experienced Contractor engaged in the
provision of works similar to the works under the same or
similar circumstances as those applicable to the Contract and
which are in accordance with any codes of practice published
by relevant trade associations;
A.1.1.1.19 "Government" means the Government of the Federal Democratic Republic of
Ethiopia;
A.1.1.1.20 "In writing" shall be interpreted to include any document which is recorded
in manuscript or typescript;
A.1.1.1.21 "Intended Completion is the date on which it is intended that the Contractor shall
Date" complete the Works. The Intended Completion Date is specified
in the Special Conditions of Contract. The Intended Completion
Date may be revised only by the Engineer by issuing an
extension of time or an acceleration order;
A.1.1.1.22 "Liquidated damages" means the compensation stated in the contract as being payable
by Contractor to the Employer for failure to perform the
contract or part thereof within the periods under the contract,
or as payable by Contractor to the Employer for any specific
breach identified in the contract;
A.1.1.1.23 "Materials" are all supplies, including consumables, used by the Contractor
for incorporation in the Works;
A.1.1.1.24 "Member" means any of the entities that make up the joint venture /
consortium / association; and “Members” means all these
entities;
A.1.1.1.25 "Month" means calendar month;
A.1.1.1.26 "Party" means the Employer or the Contractor and includes their
permitted successors and “Parties” means both of them;

P a g e 6 | 63
 Contract Document for Construction Client: of
Contractor:

A.1.1.1.27 "Plant" means appliances and other machinery, and, where applicable
under the law and/or practice of the Federal Democratic
Republic of Ethiopia, the temporary structures on the site
required to carry out the works but excluding equipment or
other items required to form part of the permanent works;
A.1.1.1.28 "Price Schedule" means the completed schedule of prices, including the
breakdown of the overall price, submitted by the Contractor
with his Bid, modified as necessary and forming a part of the
unit price contract;
A.1.1.1.29 "Provisional Sum" means a sum included in the contract and so designated for the
implementation of works or the supply of goods, materials,
plant or services, or for contingencies, which sum may be used
in whole or in part, or not at all, as instructed by the Engineer;
A.1.1.1.30 "Employer" means Employer, which is partly or wholly financed by the
Federal Government Budget, higher education institutions, and
public institutions of like nature which has the powers and
duties to conclude a Contract for the supply of Works, as
specified in the SCC;
A.1.1.1.31 "Site" means the piece of land(s) provided by the Employer where
the works are to be carried out, and other places stated in the
Contract as forming part of the site;
A.1.1.1.32 "Special Conditions of hereinafter referred to as “SCC”, means the conditions
Contract" attached to the Contract Agreement, which shall govern the
Contract and shall prevail over these General Conditions of
Contract;
A.1.1.1.33 "Specification" means the Specification of the Works included in the Contract
drawn up by the Employer setting out its requirements and/or
objectives in respect of the provision of works, specifying,
where relevant, the methods and resources to be used and/or
results to be achieved;
A.1.1.1.34 "Start Date" is given in the Special Conditions of Contract. It is the latest date
when the Contractor shall commence execution of the Works;
A.1.1.1.35 "Sub-Contractor" means any natural person, private or government entity, or a
combination of the above, including its legal successors or
permitted assigns who has a Contract with the Contractor to
carry out a part of the Work in the Contract, which includes
work on the Site;
A.1.1.1.36 "Third Party" means any person or entity other than the Employer, the
Contractor or a Sub-Contractor;
A.1.1.1.37 "Works" mean all work associated with the construction, reconstruction,
upgrading, demolition, repair, renovation of a building, road,
or structure, as well as services incidental to works, if the
value of those services does not exceed that of works
themselves;

P a g e 7 | 63
Contract Document for Construction Client: of
Contractor:

2. Appointment

2.1 The Employer appoints the Contractor to carry out the Works:
A.1.1.1.38 Promptly (and in any event within any time targets as may be set out in the Section 6,
Schedule of Requirements) and in a professional and courteous manner so as to reflect and
promote the image of the Employer;
A.1.1.1.39 Strictly in accordance with the Schedule of Requirements and all provisions of the
Contract; and
A.1.1.1.40 In accordance with all applicable laws and regulations of the Federal Democratic
Republic of Ethiopia and Good Industry Practice; and
A.1.1.1.41 In accordance with the policies, rules, and procedures of the appropriate Authority as
amended from time to time.
A.1.1.1.42 In accordance with the quality standards set by the Ministry of Urban Development and
Construction, Quality and Standards Authority of Ethiopia (QSAE), and applicable
international standards;
A.1.1.1.43 In accordance with the terms and conditions of appointment as provided in this Clause in
consideration of the Contract Price.

3. Relationship Between the Parties

3.1 Nothing contained herein shall be construed as establishing a relationship of master and servant or
of principal and agent as between the Employer and the Contractor. The Contractor, subject to this
Contract, has complete charge of Personnel and Sub-Contractors, if any, carrying out the Works
and shall be fully responsible for the Works carried out by them or on their behalf hereunder. The
Contractor shall not incur any liabilities on behalf of the Employer or enter into any contract or
obligation on behalf of the Employer.

4. Due Diligence

4.1 The Contractor acknowledges that it:

A.1.1.1.44 Has made and shall make its own enquiries to satisfy itself as to the accuracy and
adequacy of any information supplied to it by or on behalf of the Employer;
A.1.1.1.45 Has raised all relevant due diligence questions with the Employer before the Effective
Date; and
A.1.1.1.46 Has entered into this Contract in reliance on its own due diligence alone.
4.2 The Contractor acknowledges that it has inspected the Site Environment and has advised the
Employer of any aspect of the Site Environment that is not suitable for carrying out the Works and
that the specified actions to remedy the unsuitable aspects of the Site Environment, together with
a timetable for and the costs of those actions, have been specified in the relevant parts of the
Contract for the Pre-Operational Phase.
4.3 If the Contractor has either failed to inspect the Site Environment or failed to notify the Employer
of any required remedial actions in accordance with Clause 4.2 then the Contractor shall not be
entitled to recover any additional costs or charges from the Employer relating to any unsuitable
aspects of the Site Environment nor shall the Contractor be entitled to seek relief in respect of any
Default arising from such failure.

P a g e 8 | 63
Contract Document for Construction Client: of
Contractor:

4.4 Any disputes relating to due diligence shall be resolved in accordance with the Ethiopian Law.

5. Fraud and Corruption

5.1 If the Employer determines that the Contractor and/or its Personnel, sub-contractors, services
providers and suppliers has engaged in corrupt, fraudulent, collusive, coercive, or obstructive
practices, in competing for or in executing the Contract, then the Employer may, after giving 14
days notice to the Contractor, terminate the Contractor's employment under the Contract, and the
provisions of GCC Clause 21 shall apply as if such expulsion had been made under GCC Sub-
Clause 21.2(i).
5.2 For the purposes of these provisions, the terms set forth below shall have meanings as follows:
A.1.1.1.47 “Corrupt practice” is the offering, giving, receiving or soliciting, directly or indirectly, of
any thing of value to influence the action of a public official in the procurement process or
in contract execution, and
A.1.1.1.48 “Fraudulent practice” is any act or omission, including misrepresentation that knowingly
or recklessly misleads, or attempts to mislead, a party to obtain financial or other benefit
or to avoid an obligation.
A.1.1.1.49 “Collusive practices" is a scheme or arrangement between two or more Contractors, with
or without the knowledge of the Employer, designed to establish prices at artificial, non
competitive levels, and
A.1.1.1.50 “Coercive practices” is harming or threatening to harm, directly or indirectly, persons or
their property to influence their participation in a procurement process, or affect the
execution of a contract.
A.1.1.1.51 "Obstructive practice" is
A.1.1.1.51.1 deliberately destroying, falsifying, altering or concealing of evidence material to
the investigation or making false statements to investigators in order to materially
impede the Federal Ethics and Anticorruption Commission, the Federal Auditor
General and the Public Procurement and Property Administration Agency or their
auditors' investigation into allegations of a corrupt, fraudulent, coercive or
collusive practice; and/or threatening, harassing or intimidating any party to
prevent their from disclosing their knowledge of matters relevant to the
investigation or from pursuing the investigation, or
A.1.1.1.52 acts intended to materially impede the exercise of inspection and audit rights provided for
under GCC Sub-clause 56.2.
5.3 The Agency will debar a Contractor from participation in public procurement for a specified
period of time if it at any time determines that the Contractor has engaged in corrupt, fraudulent,
collusive, coercive or obstructive practices in competing for, or in executing, a contract.
5.4 The Agency reserves the right, where a Contractor has been found by a national or international
entity to have engaged in corrupt or fraudulent practice, to declare that such a Contractor is
ineligible, for a stated period of time, to be awarded a Government funded contract.
5.5 The Agency will have the right to require that, in contracts funded by the Government of Ethiopia,
a provision be included requiring Contractors to permit the Agency to inspect their accounts and
records relating to the performance of the contract and to have them audited by auditors appointed
by the Agency, if the Contractor engages in any corrupt practice.
5.6 Any communications between the Contractor and the Employer or the Agency related to matters
of alleged fraud or corruption must be made in writing.

P a g e 9 | 63
 Contract Document for Construction Client: of
Contractor:

6. Interpretation

6.1 In interpreting these GCC, words indicating one gender include all genders. Words indicating the
singular also include the plural and words indicating the plural also include the singular. Headings
have no significance. Words have their normal meaning under the language of the Contract unless
specifically defined. The Engineer shall provide instructions clarifying queries about these GCC.

6.2 If sectional completion is specified in the Special Conditions of Contract, references in the
General Conditions of Contract to the Works, the Completion Date, and the Intended Completion
Date apply to any Section of the Works (other than references to the Completion Date and
Intended Completion Date for the whole of the Works)..

6.3 Entire Agreement

This Contract contains all covenants, stipulations and provisions agreed by the Parties.
No agent or representative of either Party has authority to make, and the Parties shall not
be bound by or be liable for, any statement, representation, promise or agreement not set
forth herein.
6.4 Amendment
No amendment, modification or other variation of the Contract shall be valid unless an
Amendment to Contract is made in writing, is dated, expressly refers to the Contract,
and is signed by a duly authorized representative of each party thereto.
6.5 No waiver
A.1.1.1.53 Subject to GCC Sub-Clause 6.5(b) below, no relaxation, forbearance, delay, or indulgence by
either party in enforcing any of the terms and conditions of the Contract or the granting of
time by either party to the other shall prejudice, affect, or restrict the rights of that party
under the Contract, neither shall any waiver by either party of any breach of Contract operate
as waiver of any subsequent or continuing breach of Contract.
A.1.1.1.54 Any waiver of a party’s rights, powers, or remedies under the Contract must be in writing,
dated, and signed by an authorized representative of the party granting such waiver, and must
specify the right and the extent to which it is being waived.
6.6 Severability
If any provision or condition of the Contract is prohibited or rendered invalid or
unenforceable, such prohibition, invalidity or unenforceability shall not affect the validity
or enforceability of any other provisions and conditions of the Contract.
A. The Contract
7. Contract Documents

7.1 The documents forming the Contract are listed in the SCC and shall be interpreted in the order of
precedence in the event of any conflict between the documents comprising this Contract:
7.2 All documents forming the Contract are intended to be correlative, complementary, and mutually
explanatory.
7.3 Any action required or permitted to be taken, and any document required or permitted to be
provided, under the Contract by the Employer or the Contractor may be taken or provided by the
authorized representatives specified in the SCC.
7.4 The Contract constitutes the entire agreement between the Employer and the Contractor and
supersedes all communications, negotiations and agreements (whether written or oral) of parties
with respect thereto made prior to the date of Contract. No agent or representative of either Party
P a g e 10 | 63
Contract Document for Construction Client: of
Contractor:

has authority to make, and the Parties shall not be bound by or be liable for, any statement,
representation, promise or agreement not set forth herein.

8. Governing Law

8.1 The Contract, its meaning and interpretation, and relation between the Parties shall be governed
by and interpreted in accordance with the laws of the Federal Democratic Republic of Ethiopia,
unless otherwise stated in SCC.

9. Language

9.1 The Contract as well as all written and oral communication and documents relating to the Contract
exchanged by the Contractor and the Employer, shall be in language specified in the SCC.
Supporting documents and printed literature that are part of the Contract may be in another
language, but any documents provided in another language must be accompanied by an accurate
translation into language specified in the SCC. For purposes of interpretation of the Contract, this
translation shall govern.

9.2 The Contractor shall bear all costs of translation to the governing language and all risks of the
accuracy of such translation.

10. Notices and written communications

10.1 Any notice, request or consent required or permitted to be given or made pursuant to this Contract
shall be in writing. The term “in writing” means communicated in written form with proof of
receipt.
10.2 Any such notice, request or consent shall be deemed to have been given or made when delivered
in person to an authorized representative of the Party to whom the communication is addressed, or
when sent to such Party at the address specified in the SCC.
10.3 A Party may change its address for notice hereunder by giving the other Party notice in writing of
such change to the address specified in the SCC.

11. Authority of Member in Charge

11.1 In case the Contractor consists of a joint venture/consortium/ association of two or more entities,
all such entities shall be jointly and severally bound to fulfill the terms of the contract according to
the law of the Federal Democratic Republic of Ethiopia. The Members hereby authorize the entity
specified in the SCC to act on their behalf as leader with authority to bind the joint venture or
consortium in exercising all the Contractor’s rights and obligations towards the Employer under
this Contract. The composition or the constitution of the joint venture or consortium shall not be
altered without the prior consent of the Employer.

12. Engineer and Engineer's Representative

12.1 Except where otherwise specifically stated and subject to any restriction in the SCC, any action
required or permitted to be taken, and any document required or permitted to be executed, under
this Contract by the Employer or the Contractor may be taken or executed by the Engineers
named in the SCC. Except as expressly stated in the SCC, the Engineer shall not have authority to
relieve the Contractor of any of his obligations under the Contract.
12.2 Any notice, information or communication given to or made by an Engineer shall be deemed to
have been given or made by the Employer.
12.3 The Engineer may delegate any of his duties and responsibilities to Engineer's representative after

P a g e 11 | 63
Contract Document for Construction Client: of
Contractor:

notifying the Contractor, and may cancel any delegation after notifying the Contractor.
12.4 The role of the Engineer’s representative shall be to supervise and inspect works and to test and
examine the materials employed and the quality of workmanship. Under no circumstances will the
Engineer's representative be empowered to relieve the Contractor of his obligations under the
contract or – except where express instructions to that effect are given in the SCC – order works
resulting in an extension of the period of performance or additional costs to be paid by the
Employer or introduce variants in the nature or scale of the works.
12.5 Any communication given by the Engineer's representative to the Contractor in accordance with
the terms of such delegation shall have the same effect as though it had been given by the
Engineer, provided that:
A.1.1.1.55 Any failure on the part of the Engineer's representative to disapprove any work, materials
or plant shall not prejudice the authority of the Engineer to disapprove such work,
materials or plant and to give the instructions necessary for the rectification thereof;
A.1.1.1.56 The Engineer shall be at liberty to reverse or vary the contents of such communication.
12.6 Instructions and/or orders issued by the Engineer shall be by way of administrative orders. Such
orders shall be dated, numbered and entered by the Engineer in a register, and copies thereof
delivered by hand, where appropriate, to the Contractor's representative.

13. Assignment

13.1 An assignment is a written agreement by which the Contractor transfers its contract or part thereof
to a third party.
13.2 The Contractor shall not, without the prior written consent of the Employer, assign the Contract or
any part thereof, or any benefit or interest thereunder, except in the following cases:
A.1.1.1.57 A charge, in favor of the Contractor's bankers, of any monies due or to become due under
the Contract; or
A.1.1.1.58 Assignment to the Contractor's insurers of the Contractor's right to obtain relief against
any other person liable in cases where the insurers have discharged the Contractor's loss
or liability.
13.3 For the purpose of GCC Clause 13.2 the approval of an assignment by the Employer shall not
relieve the Contractor of his obligations for the part of the Contract already performed or the part
not assigned.
13.4 If the Contractor has assigned his Contract without authorization, the Employer may, without
giving formal notice thereof, apply as of right the sanctions for breach of Contract provided for in
GCC Clauses 19 and 21.
13.5 Assignees must satisfy the eligibility criteria applicable for the award of the Contract and they can
not be in any of the situations excluding them from participating in Contract.
13.6 Every assignment shall be subject to the provisions of this Contract and shall incorporate the
terms and conditions of this Contract.

14. Subcontracting

14.1 A sub-contract shall be valid only if it is a written agreement by which the Contractor entrusts
performance of a part of the Contract to a third party.
14.2 In the event the Contractor requires sub-contracting of the works to Sub-Contractors that are not
included in the Contract, the Contractor shall obtain the prior written approval and clearance of
Employer for all Sub-Contractors. The work to be sub-contracted and the identity of the
subcontractors shall be notified to the Employer. The Employer shall with due regard to the
provisions of GCC Clause 10 within 15 days of receipt of the notification, notify the Contractor of
P a g e 12 | 63
Contract Document for Construction Client: of
Contractor:

its decision, stating reasons should he withhold such authorization.

14.3 The terms of any sub-contract shall be subject to and conform to the provisions of this Contract.
14.4 Sub-Contractors must satisfy the eligibility criteria applicable to the award of the contract and
they can not be in any of the situations excluding them from participating in contract.
14.5 Subject to GCC Clause 66, the Employer shall have no contractual relations with the Sub-
Contractors.
14.6 The Contractor shall be responsible for the acts, defaults and negligence of his Sub-Contractors
and their agents or employees, as if they were the acts, defaults or negligence of the Contractor,
his agents or employees. The approval by the Employer of the sub-contracting of any part of the
contract or of the Sub-Contractor to perform any part of the works shall not relieve the Contractor
of any of his obligations under the contract.
14.7 If a Sub-Contractor has undertaken any continuing obligation for a period exceeding that of the
Defects Liability Period under the contract towards the Contractor in respect of the work executed
or the goods, materials, plant or services supplied by the Sub-Contractor, the Contractor shall, at
any time after the expiration of the Defects Liability Period, transfer immediately to the
Employer, at the Employer's request and cost, the benefit of such obligation for the unexpired
duration thereof.
14.8 If the Contractor enters into a subcontract without approval, the Employer may apply, as of right
without giving formal notice thereof, the sanctions for breach of contract provided for in GCC
Clauses 19 and 21.
14.9 If a Sub-Contractor is found by the Employer or the Engineer to be incompetent in discharging its
duties, the Employer or the Engineer may request the Contractor forthwith, either to provide a
Sub-Contractor with qualifications and experience acceptable to the Employer as a replacement,
or to resume the implementation of the tasks itself.

15. Modifications by Change Orders

15.1 The Engineer shall have power to order any modification to any part of the works necessary for
the proper completion and /or functioning of the works. Such modifications may include
additions, omissions, substitutions, changes in quality, quantity, form, character, kind, position,
dimension, level or line and changes in the specified sequence, method or timing of execution of
the works. No order for a modification shall have the effect of invalidating the contract, but the
financial effect, if any, of all such modifications shall be valued in accordance with GCC Clauses
15.5 and 15.7.
15.2 All change orders shall be issued in writing, it being understood that:
A.1.1.1.59 if for any reason, the Engineer shall find it necessary to give an order orally, he shall as
soon as possible thereafter confirm the order by an change order;
A.1.1.1.60 if the Contractor shall confirm in writing an oral order given for the purpose of GCC
Clause 15.2 (a) and the confirmation shall not be contradicted in writing forthwith by the
Engineer, an change order shall be deemed to have been issued for the modification.

A change order for modification shall not be required for increase or decrease in the quantity of
any work where such increase or decrease is the result of the quantity exceeding or being less
than that stated in the bill of quantities or price schedule, as the result of valuation of works laid
down in GCC Clause 63.
15.3 Except as provided by GCC Clause 15.2 prior to any change order for modification, the Engineer
shall notify the Contractor of the nature and form of such modification. As soon as possible, after
receiving such notice, the Contractor shall submit to the Engineer a proposal containing:
A.1.1.1.61 a description of the tasks, if any, to be implemented or the measures to be taken and a
P a g e 13 | 63
Contract Document for Construction Client: of
Contractor:

program for execution; and

A.1.1.1.62 any necessary modifications to the program of implementation of tasks or to any of the
Contractor's obligations under the contract; and
A.1.1.1.63 any adjustment to the contract price in accordance with the rules as set out in this Clause.
15.4 Following the receipt of the Contractor's submission referred to in GCC Clause 15.3, the Engineer
shall, after due consultation with the Employer and, where appropriate, the Contractor, decide as
soon as possible whether or not the modification shall be carried out. If the Engineer decides that
the modification shall be carried out he shall issue the change order stating that the modification
shall be carried out at the prices and under the conditions given in the Contractor's submission
referred to in GCC Clause 15.3 or as modified by the Engineer in accordance with GCC Clause
15.5.
15.5 The prices for all modifications ordered by the Engineer in accordance with GCC Clause 15.2 and
15.4 shall be ascertained by the Engineer in accordance with the following principles:
A.1.1.1.64 where work is of similar character and executed under similar conditions to work priced in
the bill of quantities or price schedule it shall be valued at such rates and prices contained
therein;
A.1.1.1.65 where work is not of a similar character or is not executed under similar conditions, the
rates and prices in the contract to be agreed through negotiation between the Engineer and
the Contractor shall conform to the prevailing market price;
A.1.1.1.66 if the nature or amount of any modification relative to the nature or amount of the whole of
the contract or to any part thereof shall be such that in the opinion of the Engineer any
rate or price contained in the contract for any item of work is by reason of such
modification rendered unreasonable, then the Engineer shall fix such rate or price as in the
circumstances he shall think reasonable and proper;
A.1.1.1.67 where a modification is necessitated by default or breach of contract by the Contractor,
any additional cost attributable to such modification shall be borne by the Contractor.
15.6 On receipt of the change order requesting the modification, the Contractor shall proceed to carry
out the modification and be bound by these GCC in so doing as if such modification were stated
in the contract. The works shall not be delayed pending the granting of any extension of time for
completion or adjustment to the contract price. Where the order for a modification precedes the
adjustment to the contract price, the Contractor shall keep records of the costs of undertaking the
modification and of time expended thereon. Such records shall be open to inspection by the
Engineer at all reasonable times.
15.7 Where on provisional acceptance an increase or reduction in the total value of the works resulting
from a change order, or from some other circumstance which is not caused by the Contractor's
default, exceeds 25% of the initial contract price (or as modified by addendum), the Engineer
shall, after consultation with the Employer and the Contractor determine any reduction from the
contract price as a consequence of the application of GCC Clause 15.5. The sum so determined
shall be based on the amount by which the increase or decrease in value of the works exceeds
25%. The sum shall be notified by the Engineer to the Employer and the Contractor and the
contract price adjusted accordingly.
15.8 The total value of the works resulting from a change order shall not exceed 30% of the total value
of the initial contract price.
15.9 Any change to the terms of the Contract must be recorded in writing and executed by authorized
signatory of the Contractor and the Engineer. Such record of the change in question must address
all consequential amendments required to be made to the Contract as a result of such change.
15.10 Changes will take effect as from the date specified in the signed record of change and shall not
have retrospective effect unless expressly provided for in such record.
15.11 Each record of change must be dated and sequentially numbered. Each of the Employer and the

P a g e 14 | 63
Contract Document for Construction Client: of
Contractor:

Contractor will be entitled to an original executed counterpart of the record of variation.

15.12 Except as provided in any such record of variation, the Contract will continue in full force and
effect.

16. Change in Laws and Regulations

16.1 Unless otherwise expressly agreed in the SCC, if, after the deadline for submission of the Bid, any
law, regulation, ordinance, order or bylaw having the force of law is enacted, promulgated,
abrogated, or changed in the Federal Democratic Republic of Ethiopia where the Site is located
(which shall be deemed to include any change in interpretation or application by the competent
authorities) that subsequently affects the Completion Date and/or the Contract Price, then such
Contract Price shall not be correspondingly increased or decreased and/or the Completion Date
shall not be adjusted to the extent that Contractor has thereby been affected in the performance of
any of its obligations under the Contract.

17. Taxes and Duties

17.1 Unless otherwise specified in the SCC, the Contractor shall bear and pay all taxes, duties, and
levies imposed on the Contractor, by all municipal, state or national government authorities, both
within and outside the Federal Democratic Republic of Ethiopia, in connection with the Works to
be carried out under the Contract,.

18. Force Majeure

18.1 For the purposes of the Contract, “Force Majeure” shall mean an event or events which are
beyond the reasonable control of a Contractor, and which makes a Contractor’s performance of its
obligations hereunder impossible or so impractical as reasonably to be considered impossible in
the circumstances, and includes:
A.1.1.1.68 An official prohibition preventing the performance of a contract,
A.1.1.1.69 A natural catastrophe such as an earthquake, fire, explosion, storm, floods, or other
adverse weather conditions, or
A.1.1.1.70 International or civil war, or
A.1.1.1.71 Other instances of Force Majeure identified as such by the civil code.
18.2 The following occurrences shall not be deemed to be cases of Force Majeure:
A.1.1.1.72 A strike or lock-out taking of a party or affecting the branch of business in which he carries
out his activities where such strikes, lockouts or other industrial action are within the
power of the Party invoking Force Majeure to prevent, or
A.1.1.1.73 An increase or reduction in the price of raw materials necessary for the performance of the
contract, or
A.1.1.1.74 The enactment of new legislation where by the obligations of the debtor becomes more
onerous, or
A.1.1.1.75 Any event which is caused by the negligence or intentional action of a Contractor or such
Contractor’s Sub-Contractors or agents or employees; or
A.1.1.1.76 Any event which a diligent Party could reasonably have been expected to both:
A.1.1.1.76.1 Take into account from the effective date of the Contract; and
A.1.1.1.76.2 Avoid or overcome in the carrying out of its obligations; or
A.1.1.1.77 Insufficiency of funds or failure to make any payment required hereunder.
18.3 The failure of a Contractor to fulfill any of its obligations hereunder shall not be considered to be
a breach of, or default under, the Contract insofar as such inability arises from an event of Force

P a g e 15 | 63
Contract Document for Construction Client: of
Contractor:

Majeure, provided that the Contractor affected by such an event has taken all reasonable
precautions, due care and reasonable alternative measures, all with the objective of carrying out
the terms and conditions of the Contract.
18.4 A Party affected by an event of Force Majeure shall take all reasonable measures to
A.1.1.1.78 Remove such Party’s inability to fulfill its obligations hereunder with a minimum of delay;
and
A.1.1.1.79 Minimize the consequences of any event of Force Majeure.
18.5 A Contractor affected by an event of Force Majeure shall notify the Employer of such event as
soon as possible, and in any event not later than fourteen (14) days following the occurrence of
such event, providing evidence of the nature and cause of such event, and shall similarly give
notice of the restoration of normal conditions as soon as possible.
18.6 Any period within which a Contractor shall, pursuant to this Contract, complete any action or
task, shall be extended for a period equal to the time during which such Party was unable to
perform such action as a result of Force Majeure.
18.7 During the period of their inability to carry out the Works as a result of an event of Force
Majeure, the Contractor, upon instructions by the Employer, shall either:
A.1.1.1.80 Demobilize, in which case the Contractor shall be reimbursed for additional costs they
reasonably and necessarily incurred, and, if required by the Employer, in reactivating the
Works; or
A.1.1.1.81 Continue to perform his obligations under the Contract to the extent possible, in which
case the Contractor shall continue to be paid under the terms of this Contract and be
reimbursed for additional costs reasonably and necessarily incurred.
18.8 Not later than thirty (30) days after the Contractor, as the result of an event of Force Majeure, has
become unable to carry out the Works, the Parties shall consult with each other in good faith and
use all reasonable endeavors to agree appropriate terms to mitigate the effects of the Force
Majeure Event and facilitate the continued performance of the Contract.
18.9 In the case of disagreement between the Parties as to the existence or extent of Force Majeure, the
matter shall be settled according to GCC Clause 26.

19. Breach of Contract

19.1 Either party commits a breach of contract where it fails to discharge any of its obligations under
the specific contract.
19.2 Where a breach of contract occurs, the party injured by the breach shall be entitled to the
following remedies:
A.1.1.1.82 Compensation / Claim for liquidated damages as specified in GCC Clause 27; and/or
A.1.1.1.83 Termination of the contract.
19.3 In any case where the Employer is entitled to damages, it may deduct such Suspension damages
from any sums due to the Contractor or call on the appropriate guarantee.

20. Suspension

20.1 The Contractor shall, on the order of the Engineer, suspend the progress of the works or any part
thereof for such time or times and in such manner as the Engineer may consider necessary.
20.2 During the period of suspension, the Contractor shall take such protective measures as may be
necessary to safeguard the works, plant, equipment and site against any deterioration, loss or
damage. Additional expenses incurred in connection with such protective measures shall be added

P a g e 16 | 63
Contract Document for Construction Client: of
Contractor:

to the contract price, unless such suspension is:

A.1.1.1.84 otherwise provided for in the contract; or
A.1.1.1.85 necessary by reason of some default of the Contractor; or
A.1.1.1.86 necessary by reason of normal climatic conditions on site; or
A.1.1.1.87 necessary for the safety or the proper execution of the works or any part thereof insofar as
such necessity does not arise from any act or default by the Engineer or the Employer or
from any of the exceptional risks referred to in GCC Clause 44.
20.3 The Contractor shall not be entitled to such additions to the contract price unless he notifies the
Engineer, within 30 days after receipt of the order to suspend the works, of his intention to make a
claim for them.
20.4 The Engineer, after consultation with the Employer and the Contractor, shall determine such extra
payment and/or extension of the period of performance to be made to the Contractor in respect of
such claim as shall, in the opinion of the Engineer, be fair and reasonable.
20.5 If the period of suspension exceeds 120 days and the suspension is not due to the Contractor's
default, the Contractor may, by notice to the Engineer, request permission to proceed within thirty
(30) days or terminate the contract.
20.6 Where the award procedure or implementation of the contract is vitiated by substantial errors or
irregularities or by suspected or proven fraud, the payments and/or implementation of the contract
shall be suspended. Where such errors, irregularities or fraud are attributable to the Contractor, the
Employer may also refuse to make payments or may recover monies already paid, in proportion to
the seriousness of the errors, irregularities or fraud. The payments may also be suspended in cases
where there are suspected or established errors, irregularities or fraud committed by the
Contractor in the performance of another contract funded by the Federal Government of Ethiopia,
which are likely to affect the performance of the present contract

21. Termination
Termination by the Employer
21.1 Termination shall be without prejudice to any other rights or powers under the contract of the
Employer and the Contractor.
21.2 In addition to the grounds for termination defined in these General Conditions, the Employer may,
by not less than thirty days written notice of termination to the Contractor stating the reason for
termination of the contract and the date on which such termination becomes effective. (except in
the event listed in paragraph (o) below, for which there shall be a written notice of not less than
sixty days), such notice to be given after the occurrence of any of the events specified in this GCC
Sub-Clause 21.2 (a) to (p), terminate the Contract if:
A.1.1.1.88 The Contractor fails to carry out any or all of the Works within the period specified in the
Contract, or within any extension thereof granted by the Employer pursuant to GCC
Clause 73;
A.1.1.1.89 The Contractor fails to remedy a failure in the performance of their obligations as
specified in a notice of suspension pursuant to GCC Clause 20 within thirty days of receipt
of such notice of suspension of assignment or within such further period as the Employer
may has subsequently approved in writing;
A.1.1.1.90 The Contractor becomes (or, if the Contractor consists of more than one entity, if any of its
Members becomes) insolvent or bankrupt or enters into any agreements with their
creditors for relief of debt or take advantage of any law for the benefit of debtors or go into
liquidation or receivership whether compulsory or voluntary, other than for a
reconstruction or amalgamation;
A.1.1.1.91 The Contractor fails to comply with any final decision reached as a result of direct

P a g e 17 | 63
Contract Document for Construction Client: of
Contractor:

informal negotiation pursuant to GCC Sub-Clause 26.2 hereof;

A.1.1.1.92 The Contractor is unable, as the result of Force Majeure, to carry out the Works for a
period of not less than sixty (60) days;
A.1.1.1.93 The Contractor assigns the contract or sub-contracts without the authorization of the
Employer;
A.1.1.1.94 The Contractor has been guilty of grave professional misconduct proven by any means
which the Employer can justify;
A.1.1.1.95 The Contractor has been declared to be in serious breach of contract financed by the
Federal Democratic Republic of Ethiopia's budget for failure to comply with its
contractual obligations.
A.1.1.1.96 The Contractor has been engaged in corrupt or fraudulent practices in competing for or in
executing the Contract.
A.1.1.1.97 Any organizational modification occurs involving a change in the legal personality, nature
or control of the Contractor, unless such modification is recorded in an addendum to the
Contract;
A.1.1.1.98 Any other legal disability hindering performance of the Contract occurs;
A.1.1.1.99 The Contractor fails to provide the required guarantees or insurance, or the person
providing the underlying guarantee or insurance is not able to abide by its commitments.
A.1.1.1.100 Where the procurement requirement of the Employer changes for any apparent or obvious
reason;
A.1.1.1.101 Where it emerges that the gap between the value of the Contract and the prevailing market
price is so wide that allowing the implementation of the contract to proceed places the
Employer concerned at a disadvantage;
A.1.1.1.102 The Employer, in its sole discretion and for any reason whatsoever, decides to terminate
the Contract.
A.1.1.1.103 The Contractor has delayed the completion of the Works by the number of days for which the
maximum amount of liquidated damages can be paid, as defined in the GCC Clause 27.1(b).
Termination by the Contractor
21.3 The Contractor may, by not less than thirty (30) days' written notice to the Employer, of such
notice to be given after the occurrence of any of the events specified in GCC Sub -Clause 21.3 (a)
to (d) terminate the Contract if:
A.1.1.1.104 The Employer fails to pay any money due to the Contractor pursuant to the Contract and
not subject to dispute pursuant to Clause 25, within forty-five (45) days after receiving
written notice from the Contractor that such payment is overdue;
A.1.1.1.105 The Employer is in material breach of its obligations pursuant to the Contract and has not
remedied the same within forty-five (45) days (or such longer period as the Contractor may
have subsequently approved in writing) following the receipt by the Employer of the
Contractor’s notice specifying such breach;
A.1.1.1.106 The Employer suspends the progress of the works or any part thereof for more than 180
days, for reasons not specified in the Contract, or not due to the Contractor's default.
A.1.1.1.107 The Contractor is unable as the result of Force Majeure, to perform a material portion of
the Works for a period of not less than sixty (60) days; or
A.1.1.1.108 The Employer fails to comply with any final decision reached as a result of settlement of
disputes pursuant to GCC Clause 26 hereof.
Disputes About Events of Termination
21.4 If either Party disputes whether an event specified GCC Sub-Clauses 21.2 (a) to (n) or GCC Sub-
Clause 21.3 hereof has occurred, such Party may, within forty-five (45) days after receipt of
notice of termination from the other Party, refer the matter to settlement of disputes pursuant to
GCC Clause 26 and this Contract shall not be terminated on account of such event except in
P a g e 18 | 63
Contract Document for Construction Client: of
Contractor:

accordance with the terms of any resolution award.

21.5 In the event the Employer terminates the Contract pursuant to the GCC Sub-Clause 21.2 (a) to (n)
the Employer may complete the works himself or conclude any other contract with a third party at
the Contractor's own expense. However, the Contractor shall continue performance of the
Contract to the extent not terminated.
21.6 If the Employer terminates the Contract in the event specified in GCC Sub-Clause 21.2 (o) the
notice of termination shall specify that termination is for the Employer's convenience, the extent
to which performance of the Contractor under the Contract is terminated, and the date upon which
such termination becomes effective.

22. Payment upon Termination

22.1 If the Contract is terminated because of a fundamental breach of Contract by the Contractor, the
Engineer shall issue a certificate for the value of the work done and Materials ordered less
advance payments received up to the date of the issue of the certificate and less the percentage to
apply to the value of the work not completed, as indicated in the SCC. Additional Liquidated
Damages shall not apply. If the total amount due to the Employer exceeds any payment due to the
Contractor, the difference shall be a debt payable to the Employer.
22.2 If the Employer terminates the Contract in the event specified in GCC Sub-Clause 21.2 (o) or
because of a fundamental breach of Contract by the Employer, the Engineer shall issue a
certificate for the value of the work done, Materials ordered, the reasonable cost of removal of
Equipment, repatriation of the Contractor’s personnel employed solely on the Works, and the
Contractor’s costs of protecting and securing the Works, and less advance payments received up
to the date of the certificate.
22.3 In the event the Employer terminates the Contract pursuant to the GCC Sub-Clause 21.2 (c)
termination will be without compensation to the Contractor, provided that such termination will
not prejudice or affect any right of action or remedy that has accrued or will accrue thereafter to
the Employer.

23. Arrangements on Termination

23.1 The Employer and the Contractor agree that termination or expiry of the Contract shall not affect
either Party's obligations which the Contract provides shall survive the expiration or termination
of the Contract.
23.2 All Materials on the Site, Plant, Equipment, Temporary Works, and Works shall be deemed to be
the property of the Employer if the Contract is terminated because of the Contractor’s default.
23.3 After termination or expiry all data, documents and records (whether stored electronically or
otherwise) relating in whole or in part to the provided Works shall be delivered by the Contractor
to the Employer provided that the Contractor shall be entitled to keep copies thereof to the extent
that the information contained therein does not relate solely to the Works or to the extent that the
Contractor is required by law to maintain copies thereof or to the extent that the Contractor was
possessed of such data documents and records prior to the date of the Contract. In addition, the
Contractor shall co-operate fully with the Employer during the handover leading to the
termination of the Contract. This co-operation shall extend to full access to all documents, reports,
summaries and any other information required to achieve an effective transition without
disruption to routine operational requirements.

24. Cessation of Rights and Obligations

24.1 Upon termination of the Contract pursuant to GCC Clauses 21, or upon the issue of the Final
Acceptance Certificate pursuant to GCC Clause 89 hereof, all rights and obligations of the Parties

P a g e 19 | 63
Contract Document for Construction Client: of
Contractor:

hereunder shall cease, except

A.1.1.1.109 Such rights and obligations as may have accrued on the date of termination or expiration;
A.1.1.1.110 The obligation of confidentiality set forth in GCC Clause 28 hereof;
A.1.1.1.111 The Contractor’s obligation to permit inspection, copying and auditing of their accounts
and records set forth in GCC Clause 56 hereof; and
A.1.1.1.112 Any right which a Party may have under the Governing Law.

25. Cessation of Works

25.1 Upon termination of the Contract by notice of either Party to the other pursuant to GCC Clause 21
the Contractor shall, immediately upon dispatch or receipt of such notice, take all necessary steps
to bring the Works to a close in a prompt and orderly manner, make the Site safe and secure, leave
the Site as soon as reasonably possible, and make every reasonable effort to reduce expenditures
for this purpose to a minimum.
25.2 The Engineer shall, as soon as is possible after termination, certify the value of the works and all
sums due to the Contractor as at the date of termination.
25.3 In the event of termination a report of work performed by the Contractor shall be drawn up by the
Engineer as soon as possible after inspection of the works, and inventory taken of temporary
structures, materials, plant and equipment. The Contractor shall be summoned to be present
during the inspection and the taking of the inventory. The Engineer shall also draw up statements
of emoluments still owed by the Contractor to workers employed by him in relation to the contract
and of sums owed by the Contractor to the Employer.

26. Settlement of Disputes

26.1 During any dispute, including a dispute as to the validity of the Contract, it is mutually agreed that
the Contractor shall continue its performance of the Contract (unless the Employer requests in
writing that the Contractor does not do so).
26.2 The Employer and the Contractor shall make every effort to resolve amicably by direct informal
negotiation any disagreement, controversy or dispute arising between them under or in connection
with the Contract or interpretation thereof.
26.3 If a dispute arises between the Employer and the Contractor in relation to any matter which cannot
be resolved by the Engineer and the Contractor's Contract Manager either of them may refer such
dispute to the procedure described in GCC Sub-Clause 26.4.
26.4 In the second instance each of the Employer and the Contractor shall appoint more senior
representatives than those referred to in Sub-Clause 26.3 to meet solely in order to resolve the
matter in dispute. Such meeting(s) shall be minuted and shall be chaired by the Employer (but the
chairman shall not have a casting vote). Such meeting(s) shall be conducted in such manner and at
such venue (including a meeting conducted over the telephone) as to promote a consensual
resolution of the dispute in question at the discretion of the chairman.
26.5 If the Parties fail to resolve such a dispute or difference amicably within twenty-eight (28) days
from the commencement of such procedure, either party may require that the dispute be referred
for resolution through the courts in accordance with Ethiopian Law.
26.6 Only those Public Bodies that are allowed by law to proceed to arbitration can do so.

27. Liquidated Damages

27.1 Except as provided under GCC Clause 18, if the Contractor fails to carry out any or all of the
Works within the period specified in the Contract, the Employer may without prejudice to all its
other remedies under the Contract, deduct from the Contract Price, as liquidated damages the
P a g e 20 | 63
Contract Document for Construction Client: of
Contractor:

following:
A.1.1.1.113 A penalty of 0.1% or 1/1000 of the value of undelivered Service for each day of delay until
actual delivery or performance,
A.1.1.1.114 The cumulative penalty to be paid by the Contractor shall not exceed 10% of the contract
price.
27.2 If the delay in performing the contract affects its activities, the Employer may terminate the
contract by giving advance notice to the Contractor pursuant to GCC Clause 21 without any
obligation to wait until the penalty reaches 10% of the value of the Contract.
27.3 If the Intended Completion Date is extended after liquidated damages have been paid, the
Engineer shall correct any overpayment of liquidated damages by the Contractor by adjusting the
next payment certificate.

28. Confidentiality

28.1 The Employer and the Contractor shall keep confidential and shall not disclose to any third party
any documents, data, or other information furnished directly or indirectly by the other party hereto
in connection with the Contract, whether such information has been furnished prior to, during or
following completion or termination of the Contract if their disclosure would be contrary to law,
would impede law enforcement, would not be in public interest, would prejudice legitimate
commercial interest of the parties or would inhibit fair competition.. Notwithstanding the above,
the Contractor may furnish to its sub-contractors such documents, data, and other information it
receives from the Employer to the extent required for the sub-contractor to perform its work under
the Contract, in which event the Contractor shall obtain from such sub-contractor an undertaking
of confidentiality similar to that imposed on the Contractor under this Clause.
28.2 The Employer shall not use such documents, data, and other information received from the
Contractor for any purposes unrelated to the Contract. Similarly, the Contractor shall not use such
documents, data, and other information received from the Employer for any purpose other than
carrying out the Works in accordance with the Contract.
28.3 The obligation of a party under this Clause, however, shall not apply to any Confidential
Information that:
A.1.1.1.115 The Employer or Contractor need to share with any other institutions participating in the
financing of the Contract;
A.1.1.1.116 Now or hereafter enters the public domain other than by breach of the Contract or other
act or omissions of that Party;
A.1.1.1.117 Is obtained by a third party who is lawfully authorized to disclose such information;
A.1.1.1.118 Can be proven to have been possessed by that party at the time of disclosure and which
was not previously obtained, directly or indirectly, from the other party; or
A.1.1.1.119 Is authorized for release by the prior written consent of the other party.
28.4 The Parties shall not be prevented from using any general knowledge, experience or skills which
were in their possession prior to the commencement of the Contract;
28.5 The Contractor authorizes the Employer to disclose the Confidential Information to such person(s)
as may be notified to the Contractor in writing by the Employer from time to time to the extent
only as is necessary for the purposes of auditing and collating information so as to ascertain a
realistic market price for the Works carried out in accordance with the Contract, such exercise
being commonly referred to as "benchmarking". The Employer shall use all reasonable endeavors
to ensure that such person(s) keeps the Confidential Information confidential and does not make
use of the Confidential Information except for the purpose for which the disclosure is made. The
Employer shall not without good reason claim that the lowest price available in the market is the
realistic market price.

P a g e 21 | 63
Contract Document for Construction Client: of
Contractor:

28.6 The Contractor agrees that:

A.1.1.1.120 Subject to GCC Sub-Clause 28.6 (b), the decision on whether any exemption applies to a
request for disclosure of recorded information is a decision solely for the Employer;
A.1.1.1.121 Where the Employer is managing a request as referred to in GCC Sub-Clause 28.6 (a), the
Contractor shall co-operate with the Employer making the request and shall respond
within five (5) working days of any request by it for assistance in determining how to
respond to a request for disclosure.
28.7 The Contractor shall procure that its sub-contractors shall provide the Employer with a copy of all
information in its possession or power in the form that the Employer requires within five (5)
working days (or such other period as the Employer may specify) of the Employer requesting that
Information.
28.8 The Employer may consult the Contractor in relation to any request for disclosure of the
Contractor's Confidential Information in accordance with all applicable guidance.
28.9 The above provisions of this Clause shall not in any way modify any undertaking of
confidentiality given by either of the parties hereto prior to the date of the Contract.
28.10 This GCC Clause 28 shall remain in force without limit in time in respect of Confidential
Information which comprises Personal Data. Except as aforesaid and unless otherwise expressly
set out in the Contract, this GCC Clause 28 shall remain in force for a period of 3 years after the
termination or expiry of this Contract.
28.11 In the event that the Contractor fails to comply with this GCC Clause 28, the Employer reserves
the right to terminate the Contract by notice in writing with immediate effect.

29. Miscellaneous

29.1 Any decision, act or thing that the Employer is required or authorized to take or do under the
Contract may be taken or done by any person authorized, either generally or specifically, by the
Employer to take or do that decision, act or thing, provided that upon receipt of a written request
the Employer shall inform the Contractor of the name of any person so authorized.
29.2 The Contractor may from time to time upon the request of the Employer, execute any additional
documents and do any other acts or things which may reasonably be required to implement the
provisions of the Contract.
29.3 Any provision of the Contract which is held to be invalid or unenforceable in any jurisdiction
shall be ineffective to the extent of such invalidity or unenforceability without invalidating or
rendering unenforceable the remaining provisions hereof and any such invalidity or
unenforceability in any jurisdiction shall not invalidate or render unenforceable such provisions in
any other jurisdiction.
29.4 The failure by the Employer and Contractor to insist upon the strict performance of any provision,
term or condition of the Contract or to exercise any right or remedy consequent upon the breach
thereof shall not constitute a waiver of any such breach or any subsequent breach of such
provision, term or condition.
29.5 Each Party shall bear its own expenses in relation to the preparation, execution and
implementation of the Contract including all costs legal fees and other expenses so incurred.
29.6 The Contractor warrants represents and undertakes to the Employer that there are no pending or
threatened actions or proceedings before any court or administrative agency which would
materially adversely affect the financial condition, business or operations of the Contractor and
that there are no material contracts existing to which the Contractor is a party which prevent it
from entering into the Contract; and that the Contractor has satisfied itself as to the nature and
extent of the risks assumed by it under the Contract and gathered all information necessary to

P a g e 22 | 63
Contract Document for Construction Client: of
Contractor:

perform its obligations under the Contract and all other obligations assumed by it.
29.7 The rights and remedies provided in the Contract are cumulative and not exclusive of any rights or
remedies provided by any other contract or document. In this provision "right" includes any
power, privilege, remedy, or proprietary or security interest.

B. Obligations of the Employer

30. Assistance and Supply of Documents

30.1 The Contractor may request the assistance of the Employer in obtaining copies of laws,
regulations and information on local customs, orders or by-laws of the Federal Democratic
Republic of Ethiopia, which may affect the Contractor in the performance of his obligations under
the Contract. The Employer may provide the assistance requested to the Contractor at the
Contractor's cost.
30.2 Unless otherwise specified in the SCC, the Employer may make all efforts necessary to facilitate
the procurement by the Contractor of:
A.1.1.1.122 all required visas and permits, including work and residence permits, and such other
documents as shall be necessary to enable the Contractor, Sub-Contractors or Personnel
to carry out the Works;
A.1.1.1.123 any such other assistance as may be specified in the SCC.
30.3 Except where otherwise provided in the SCC, within 30 days of the signing of the Contract, the
Engineer shall provide to the Contractor, free of charge, a copy of the drawings prepared for the
implementation of tasks as well as two copies of the specifications and other contract documents.
The Contractor may purchase additional copies of these drawings, specifications and other
documents, insofar as they are available. Upon the final acceptance, the Contractor shall return to
the Engineer all drawings, specifications and other contract documents.
30.4 Unless it is necessary for the purposes of the Contract, the drawings, specifications and other
documents provided by the Employer shall not be used or communicated to a third party by the
Contractor without the prior consent of the Engineer.
30.5 The Engineer shall have authority to issue to the Contractor administrative orders incorporating
such supplementary documents and instructions as shall be necessary for the proper and adequate
execution of the works and the remedying of any defects therein.

31. Access to the Site

31.1 The Employer shall, in due time and in conformity with the progress of the works, place the site
and access thereto at the disposal of the Contractor in accordance with the program of
implementation of tasks referred to in these GCC. If possession of a part is not given by the date
stated in the approved work program, the Employer will be deemed to have delayed the start of
the relevant activities, and this will be a Compensation Event.
31.2 The Contractor shall allow the Engineer and any person authorized by the Engineer access to the
Site and to any place where work in connection with the Contract is being carried out or is
intended to be carried out.
31.3 Any land procured for the Contractor by the Employer shall not be used by the Contractor for
purposes other than the implementation of tasks.
31.4 The Contractor shall preserve any premises placed at his disposal in a good state while he is in
occupation and shall, if so required by the Employer or the Engineer, restore them to their original
state on completion of the contract, taking into account normal wear and tear.
31.5 The Contractor shall not be entitled to any payment for improvements resulting from work carried

P a g e 23 | 63
Contract Document for Construction Client: of
Contractor:

out on his own initiative.

32. Payment

32.1 In consideration of the Works performed by the Contractor under this Contract, the Employer
shall make to the Contractor such payments and in such manner as is provided by GCC Paragraph
E of this Contract.

33. Delayed Payments to the Contractor's Staff

33.1 Where there is a delay in the payment to the Contractor's employees of wages and salaries owing
and of the allowances and contributions laid down by the law of the Federal Democratic Republic
of Ethiopia, the Employer may give notice to the Contractor that within 15 days of the notice the
Contractor has to pay such wages, salaries, allowances and contributions.

C. Obligations of the Contractor

34. General Obligations

34.1 The Contractor shall, with due care and diligence, and in accordance with the provisions of the
Contract, design the works to the extent stated in the Contract, and execute, complete and remedy
any defects in the works. The Contractor shall provide all control and supervision of the works,
personnel, materials, plant, equipment and all other items, whether of a temporary or permanent
nature required in and for such design, execution, completion and remedying of any defects,
insofar as specified in, or can be reasonably inferred from, the Contract.
34.2 The Contractor shall take full responsibility for the adequacy, stability and safety of all operations
and methods of construction under the Contract.
34.3 The Contractor shall respect and abide by all laws and regulations in force in the Federal
Democratic Republic of Ethiopia and shall ensure that his personnel, their dependants, and his
local employees also respect and abide by all such laws and regulations. The Contractor shall
indemnify the Employer against any claims and proceedings arising from any infringement by the
Contractor, its Sub-Contractors or their employees of such laws and regulations.
34.4 The Contractor shall ensure that Works conform to applicable environmental and quality
standards, that no chemical or other product/equipment is used in such a way as to cause negative
impact on the environment in general and occupational health hazards and shall employ the most
recent technology, safe and effective equipment, machinery, materials and methods, as necessary.
34.5 The Contractor shall obtain the Employer's prior approval in writing before taking any of the
following actions:
A.1.1.1.124 Entering into a subcontract for carrying out any part of the Works, it being understood that
the Contractor shall remain fully liable for carrying out the Works by the Sub-Contractor;
A.1.1.1.125 Any other action that may be specified in the SCC.
34.6 The Contractor shall comply with any administrative orders given by the Engineer. Where the
Contractor considers that the requirements of an administrative order go beyond the authority of
the specific Engineer or of the scope of the Contract, it shall, on pain of being time-barred, notify
the specific contract manager, explaining its opinion, within 30 days after receipt thereof.
Execution of the administrative order shall not be suspended because of this notice.
34.7 The Contractor shall treat all documents and information received in connection with the contract
as private and confidential, and shall not, save in so far as may be necessary for the purposes of
the performance thereof, publish or disclose any particulars of the contract without the prior
consent in writing of the Employer or the specific contract manager after consultation with the
Employer. If any disagreement arises as to the necessity for any publication or disclosure for the
P a g e 24 | 63
Contract Document for Construction Client: of
Contractor:

purpose of the contract, the decision of the Employer shall be final.

35. Eligibility

35.1 The Contractor and its Sub-Contractors shall have the nationality of an eligible country pursuant
to Section 5 of the Bidding Documents. A Contractor or Sub-Contractor shall be deemed to have
the nationality of a country if it is a citizen or constituted, incorporated, or registered, and operates
in conformity with the provisions of the laws of that country.
35.2 The Contractor and its Sub-Contractors shall provide Personnel who shall be citizens of eligible
countries and use goods with their origin from an eligible country.

36. Code of Conduct

36.1 The Contractor shall, at all times, act loyally and impartially in respect of any matter relating to
this Contract and as a faithful adviser to the Employer in accordance with the rules and/or code of
conduct of its profession as well as with appropriate discretion. The Contractor shall, in particular,
at all times refrain from making any public statements concerning the Works without the prior
approval of the Employer, and from engaging in any activity which conflicts with its obligations
towards the Employer under the contract. It shall not commit the Employer without its prior
written consent, and shall, where appropriate, make this obligation clear to third parties.
36.2 If the Contractor or any of its Sub-Contractors, personnel, agents or servants offers to give or
agrees to offer or to give or gives to any person, any bribe, gift, gratuity or commission as an
inducement or reward for doing or forbearing to do any act in relation to the contract or any other
contract with the Employer, or for showing favor or disfavor to any person in relation to the
contract or any other contract with the Employer, then the Employer may terminate the contract,
without prejudice to any accrued rights of the Contractor under the contract.
36.3 The payments to the Contractor under the contract shall constitute the only income or benefit it
may derive in connection with the contract and neither it nor its personnel shall accept any
commission, discount, allowance, indirect payment or other consideration in connection with, or
in relation to, or in discharge of, its obligations under the contract.
36.4 The Contractor shall not have the benefit, whether directly or indirectly, of any royalty, gratuity or
commission in respect of any patented or protected article or process used in or for the purposes of
the contract or the project, without the prior written approval of the Employer.
36.5 The Contractor and its staff shall maintain professional secrecy, for the duration of the contract
and after completion thereof. In this connection, except with the prior written consent of the
Employer, neither the Contractor nor the personnel employed or engaged by it shall at any time
communicate to any person or entity any confidential information disclosed to them or discovered
by them, or make public any information as to the recommendations formulated in the course of
or as a result of the Works. Furthermore, they shall not make any use prejudicial to the Employer,
of information supplied to them and of the results of studies, tests and research carried out in the
course and for the purpose of performing the contract.
36.6 The execution of the contract shall not give rise to unusual commercial expenses. If such unusual
commercial expenses emerge, the contract will be terminated. Unusual commercial expenses are
commissions not mentioned in the contract or not stemming from a properly concluded contract
referring to the contract, commissions not paid in return for any actual and legitimate service,
commissions remitted to a tax haven, commissions paid to a recipient who is not clearly identified
or commission paid to a company which has every appearance of being a front company.
36.7 The Contractor shall supply to the Employer on request supporting evidence regarding the
conditions in which the contract is being executed. The Employer may carry out whatever
documentary or on-the spot checks it deems necessary to find evidence in case of suspected

P a g e 25 | 63
Contract Document for Construction Client: of
Contractor:

unusual commercial expenses.

37. Control and Supervision of the Works

37.1 The Contractor shall himself control and supervise the works or shall appoint a Contract Manager
to do so. Such appointment shall be submitted to the Engineer for approval.
37.2 The Contract Manager shall be suitably qualified in accordance with the Schedule of
Requirements. In addition a work history/biography will be submitted to the Engineer for
approval.
37.3 The Contractor shall forthwith give notice in writing to the Engineer of the identity of the person
appointed as Contract Manager for approval. The approval may at any time be withdrawn. Should
the Engineer refuse to approve, or withdraw approval of the appointment, he shall set out the
grounds on which his decision is based, and the Contractor shall submit an alternative
appointment without delay. The address of the Contractor's representative shall be deemed to be
the address for service given by the Contractor.
37.4 If the Engineer withdraws his approval of the Contractor's Contract Manager, the Contractor shall,
as soon as is practicable, after receiving notice of such withdrawal, remove the Contract Manager
from the works and replace him with another Contract Manager approved by the Engineer.
37.5 The Contractor's Contract Manager shall have full authority to make any decision necessary for
the execution of the works, to receive and carry out administrative orders and to countersign the
work register referred to in GCC Clause 79 or attachment, where appropriate. In any event, the
Contractor shall be responsible for ensuring that the works are carried out satisfactorily including
ensuring that the specifications and administrative orders are adhered to by his own employees
and by his sub-Contractors and their employees.
37.6 Any notice, information, instruction or other communication given or made to the Contract
Manager shall be deemed to have been given or made to the Contractor.
37.7 The Contractor shall inform the Engineer of the identity of any person authorized to act for any
period as deputy for the Contract Manager before the start of that period.
37.8 The Contractor shall provide a sufficient complement of supervisory staff in addition to the
Contract Manager, to ensure that the Contractor’s staff engaged in and about the provision of the
Works at the Site are adequately supervised and properly perform their duties at all times.
37.9 All persons appointed to managerial and supervisory positions in accordance with the Schedule of
Requirements must be to the acceptance of the Engineer who will have the right to veto the
appointment of any candidate who is deemed to be unsuitable.

38. Personnel

38.1 The persons employed by the Contractor must be sufficient in number, and permit the optimum
use of the human resources. Such employees must have the skills and experience necessary to
ensure due progress and satisfactory execution of the works.
38.2 The Contractor shall make his own arrangements for the engagement of all staff and labor. The
rates of remuneration and the general working conditions, as laid down by the law of the Federal
democratic Republic of Ethiopia, shall apply as a minimum to employees on the Site.
38.3 The Contractor shall employ the key personnel named in the Schedule of Key Personnel, as
referred to in the SCC, to carry out the functions stated in the Schedule of Requirements or other
personnel approved by the Engineer. The Engineer will approve any proposed replacement of key
personnel only if their relevant qualifications and abilities are substantially equal to or better than
those of the personnel listed in the Schedule of Requirements.
38.4 The Contractor acknowledges that the Key Personnel are essential to the proper provision of the

P a g e 26 | 63
Contract Document for Construction Client: of
Contractor:

Works to the Employer. The Contractor shall ensure that the role of any Key Personnel is not
vacant for any longer than [10] Working Days and that any replacement shall be as or more
qualified and experienced as the previous incumbent of such role and is fully competent to carry
out the tasks assigned to the role of the member of Key Personnel whom he or she has replaced.
38.5 The Contractor shall immediately replace all employees indicated by the Engineer, in a letter
stating reasons, as likely to jeopardize the satisfactory execution of the works
38.6 If the Engineer asks the Contractor to remove a person who is a member of the Contractor’s staff
or work force, stating the reasons, the Contractor shall ensure that the person leaves the Site
within seven days and has no further connection with the work in the Contract.
38.7 The Employer shall not be liable for the cost of replacing any member of the Contractor’s staff
and the Contractor shall indemnify the Employer against all Employee Liabilities that may arise in
this respect.

39. Indemnification and Limitation of Liability

39.1 At its own expense, the Contractor shall indemnify, protect and defend, the Employer, its agents
and employees, from and against all actions, claims, losses or damage arising from any act or
omission by the Contractor in the performance of the Works, including any violation of any legal
provisions, or rights of third parties, in respect of patents, trade marks and other forms of
intellectual property such as copyrights.
39.2 At its own expense, the Contractor shall indemnify, protect and defend the Employer, its agents
and employees, from and against all actions, claims, losses or damages arising out of the
Contractor’s failure to perform its obligations provided that:
A.1.1.1.126 The Contractor is notified of such actions, claims, losses or damages not later than 30 days
after the Employer becomes aware of them;
A.1.1.1.127 The ceiling on the Contractor’s liability shall be limited to an amount equal to total
Contract Price as stated in the SCC, but such ceiling shall not apply to actions, claims,
losses or damages caused by the Contractor’s willful misconduct;
A.1.1.1.128 The Contractor’s liability shall be limited to actions, claims, losses or damages directly
caused by such failure to perform its obligations under the contract and shall not include
liability arising from unforeseeable occurrences incidental or indirectly consequential to
such failure.
39.3 The aggregate liability of the Contractor to the Employer shall not exceed the total contract value.
39.4 The Contractor shall have no liability whatsoever for actions, claims, losses or damages
occasioned by:
A.1.1.1.129 The Employer omitting to act on any recommendation, or overriding any act, decision or
recommendation, of the Contractor, or requiring the Contractor to implement a decision or
recommendation with which the Contractor disagrees or on which it expresses a serious
reservation; or
A.1.1.1.130 The improper execution of the Contractor’s instructions by agents, employees or
independent Contractors of the Employer.
39.5 The Contractor shall remain responsible for any breach of its obligations under the contract for
such period after the Works have been performed as may be determined by the law governing the
contract.

40. Insurance to be Taken Out by the Contractor

40.1 The Contractor shall provide, in the joint names of the Employer and the Contractor, insurance
cover against loss or damage for which he is liable under the contract in the amounts and

P a g e 27 | 63
Contract Document for Construction Client: of
Contractor:

deductibles stated in the SCC. Such insurance shall, unless the SCC provide otherwise, cover:
A.1.1.1.131 the Works, together with Materials and Plant for incorporation therein, to the full
replacement cost against all loss or damage from whatever cause arising other than from
Force Majeure or risks attributable under the contract to the Employer;
A.1.1.1.132 an additional sum of 15% of such replacement cost, or as may be specified in the SCC, to
cover any additional costs of and incidental to the rectification of loss or damage including
professional fees and the cost of demolishing and removing any part of the works and of
removing debris of whatever nature;
A.1.1.1.133 the Contractor's Equipment and other things brought onto the Site by the Contractor, for a
sum sufficient to provide their replacement at the Site.
40.2 The Contractor shall take out insurance covering his liability with regard to industrial accidents
and civil liabilities to any person employed by him on the works, to the Employer and any
employee of that authority, arising from the execution of the works. Such liability shall be
unlimited in the case of personal injuries.
40.3 The Contractor shall take out insurance covering liability with regard to risks and civil liability
resulting from an act or omission attributed to him, to his legal successors or agents. Such
insurance shall be for at least the amount stated in the SCC. Furthermore, he shall ensure that all
his sub-contractors have taken out a similar insurance.
40.4 By requiring such insurance, Employer shall not be deemed or construed to have assessed the risk
that may be applicable to the Contractor under this Contract. The Contractor shall assess its own
risks and if deemed to be appropriate and/or prudent, should maintain adequate limits and/or
broader insurance coverage than that stipulated above. The Contractor is not relieved of any
liability or other obligations assumed or pursuant to the Contract by reason of its failure to obtain
or maintain insurance in sufficient amounts, duration, or types.
40.5 Insurance shall be provided at the Contractor’s expense and shall not be charged directly to the
Employer.
40.6 All the insurance referred to in this Clause shall be taken out within 30 days of the notification of
the award of the Contract, and shall be subject to approval by the Employer. Such insurance shall
take effect from the commencement of the Works and remain in force until final acceptance of the
Works.
40.7 The Employer shall be notified by the Contractor or its Insurance Carrier at least 30 days prior to
any material change to or cancellation of any of insurance coverage.
40.8 Prior to the commencement of the Works under this Contract, the Contractor or its Insurance
Carrier shall provide a Certificate(s) of Insurance (COI) evidencing compliance with all
requirements for insurance coverage. The COI shall be submitted to the Employer for review and
approval. For the duration of the Contract, the Contractor or its Insurance Carrier shall provide
updated COI’s to evidence renewals or other changes to insurance policies or coverage, and
payment of the current premiums whenever they are required to do so by the Employer or the
Engineer.
40.9 Notwithstanding the obligations of the Contractor to insure in accordance with this Clause, the
Contractor shall be solely liable and shall indemnify the Employer and the Engineer against any
claims for damage to property or personal injuries arising from the execution of the works by the
Contractor, his sub-contractors and employees in connection with the Works

41. Program of Implementation of Tasks

41.1 Completing the work program given as part of the Bid, the Contractor shall within the time stated
in the SCC provide the Engineer with a program of implementation of the tasks, broken down by
activity and by month and include the following information:

P a g e 28 | 63
Contract Document for Construction Client: of
Contractor:

A.1.1.1.134 the order in which the Contractor proposes to carry out the works;
A.1.1.1.135 the time limits within which submission and approval of the drawings are required;
A.1.1.1.136 an organization chart containing the names, qualifications and curricula vitae of the staff
responsible for the Site,
A.1.1.1.137 a general description of the method including the sequence, by month and by nature which
the Contractor proposes to carry out the works;
A.1.1.1.138 a plan for the setting out and organization of the Site, and
A.1.1.1.139 such further details and information as the Engineer may reasonably require.
41.2 The Engineer shall return these documents to the Contractor with his approval or any relevant
remarks within ten days of receipt, except where the Engineer, within those ten days, notifies the
Contractor of his wish for a meeting.
41.3 An update of the program shall be a program showing the actual progress achieved on each
activity and the effect of the progress achieved on the timing of the remaining work, including any
changes to the sequence of the activities.
41.4 The Contractor shall submit to the Engineer for approval an updated program at intervals no
longer than the period stated in the SCC. If the Contractor does not submit an updated Program
within this period, the Engineer may withhold the amount stated in the SCC from the next
payment certificate and continue to withhold this amount until the next payment after the date on
which the overdue Program has been submitted.
41.5 The approval of the program by the Engineer shall not relieve the Contractor from any of his
obligations under the contract. The Contractor may revise the program and submit it to the
Engineer again at any time. A revised program shall show the effect of modifications and
Compensation Events.
41.6 No material alteration to the program shall be made without the approval of the Engineer. If,
however, the progress of the works does not conform to the program, the Engineer may instruct
the Contractor to revise the program and submit the revised program to him for approval.

42. Contractor's Drawings

42.1 The Contractor shall submit to the Engineer for approval:

A.1.1.1.140 Such drawings, documents, samples and /or models as may be specified in the contract
within the time limits laid down therein or in the program of implementation of tasks;
A.1.1.1.141 Such drawings as the Engineer may reasonably require for the implementation of tasks.
A.1.1.1.142 In the case of bridges and other reinforced concrete structures, the Contractor shall carry
out the requisite soil surveys before commencing work on the foundations. The Contractor
must submit the results of these surveys and the calculations for the foundations, in
triplicate, to the Engineer at least one month before commencing construction of the works
in question.
A.1.1.1.143 The Contractor shall prepare, at its own expense, all design and construction drawings
and other documents and objects necessary for the proper execution of the Contract, and in
particular drawings and design calculations and the reinforcement drawings for reinforced
concrete structures. The Contractor shall submit, in triplicate, construction, design and
reinforcement drawings, design calculations and any other documents or objects it is to
provide for the Engineer’s approval at least one month before commencing construction of
the works in question.

Within 15 days of receiving the drawings, design calculations, objects and other documents
required under (c) and (d), the Engineer shall return them to the Contractor with either his
endorsement or his remarks.

P a g e 29 | 63
Contract Document for Construction Client: of
Contractor:

42.2 If the Engineer fails to notify his decision of approval referred to in GCC Clause 41.1 within the
time limits referred to in the contract or the approved program of implementation of tasks, such
drawings, documents, samples or models shall be deemed to be approved at the end of the time
limits specified. If no time limit is specified, they shall be deemed to be approved 30 days after
receipt.
42.3 Approved drawings, documents, samples and models shall be signed or otherwise identified by
the Engineer and shall not be departed from except as otherwise instructed by the Engineer. Any
Contractor's drawings, documents, samples or models which the Engineer fails to approve, shall
be forthwith modified to meet the requirements of the Engineer and resubmitted by the Contractor
for approval. Within 15 days of being notified of the Engineer’s remarks, the Contractor shall
make the requisite corrections, adjustments etc. to the documents, drawings, design calculations
etc. The corrected or adjusted documents, drawings, design calculations etc. shall be resubmitted
for the Engineer’s approval under the same procedure.
42.4 The Contractor shall supply additional copies of approved drawings in the form and number stated
in the contract or in subsequent administrative orders.
42.5 The approval of the drawings, documents, samples or models by the Engineer shall not relieve the
Contractor from any of his obligations under the contract.
42.6 The Engineer shall have the right at all reasonable times to inspect all contract drawings,
documents, samples or models at the Contractor's premises.
42.7 Before provisional acceptance of the works, the Contractor shall supply operation and
maintenance manuals together with drawings, which shall be in such detail as will enable the
Employer to operate, maintain, adjust and repair all parts of the works. Unless otherwise stated in
the Special Conditions, the manuals and drawings shall be in the language of the Contract. The
works shall not be considered to be completed for the purpose of provisional acceptance until such
manuals and drawings have been supplied to the Employer.

43. Sufficiency of Bid Prices

43.1 The Contractor shall be deemed to have inspected and examined the Site and its surroundings and
to have satisfied himself before submitting his Bid, as to the nature of the ground and sub-soil, and
to have taken into account the form and nature of the Site, the extent and nature of the work and
materials necessary for the completion of the works, the means of communication with and access
to the site, the accommodation he may require and in general to have obtained for himself all
necessary information as to risks, contingencies and all other circumstances influencing or
affecting his tender.
43.2 The Contractor shall be deemed to have satisfied himself before submitting his tender as to the
correctness and sufficiency of the tender and of the rates and prices stated in the bill of quantities
or price schedule which shall, except in so far as it is otherwise provided in the Contract, cover all
his obligations under the contract.
43.3 Since the Contractor is deemed to have determined his prices on the basis of his own calculations,
operations and estimates, he shall carry out without additional charge any work which is the
subject of any item whatsoever in his tender for which he neither indicates a unit price nor a firm
sum.

44. Exceptional Risks

44.1 If during the execution of the works the Contractor encounters artificial obstructions or physical
conditions which could not reasonably have been foreseen by an experienced Contractor, and if
the Contractor is of the opinion that additional costs will be incurred and/or an extension of the
period of implementation of the tasks will be necessary as a result of this, he shall give notice to
the Engineer in accordance with GCC Clauses 69 and/or 73. The Contractor shall specify in such
P a g e 30 | 63
Contract Document for Construction Client: of
Contractor:

notice the artificial obstructions and/or physical conditions, giving details of the anticipated
effects thereof, the measures he is taking or intends to take and the extent of the anticipated delay
in or interference with the execution of the works.
44.2 Following receipt of the notice, the Engineer may inter alia:
A.1.1.1.144 Require the Contractor to provide an estimate of the cost of the measures he is taking or
intends to take;
A.1.1.1.145 Approve measures referred to in GCC Sub-Clause 44.2 (a) with or without modification;
A.1.1.1.146 Give written instructions as to how the artificial obstructions or physical conditions are to
be dealt with;
A.1.1.1.147 Order a modification, a suspension, or termination of the contract.
44.3 To the extent that the Engineer shall decide that the whole or part of the said artificial obstructions
or physical conditions could not reasonably have been foreseen by an experienced Contractor, the
Engineer shall:
A.1.1.1.148 take into account any delay suffered by the Contractor as a result of such obstructions or
conditions in determining any extension of the period of implementation of tasks to which
the Contractor is entitled under GCC Clause 73; and/or
A.1.1.1.149 in case of artificial obstructions or physical conditions other than weather conditions,
determine additional payments due to the Contractor in accordance with GCC Clause 69.
44.4 Weather conditions shall not entitle the Contractor to claims under GCC Clause 69.
44.5 If the Engineer decides that the artificial obstructions or physical conditions could, in whole or in
part, have been reasonably foreseen by an experienced Contractor, he shall so inform the
Contractor as soon as practicable.

45. Health and Safety on Sites

45.1 The Contractor shall have the right to forbid access to the Site to any person not involved in the
performance of the contract, with the exception of persons authorized by the Engineer or the
Employer.
45.2 The Contractor shall ensure the safety on sites during the whole period of execution and shall be
responsible for taking the necessary steps, in the interests of his employees, agents of the
Employer and third parties, to prevent any loss or accident which may result from carrying out the
works.
45.3 The Contractor shall take all essential steps, on his own responsibility and at his expense, to
ensure that existing structures and installations are protected, preserved and maintained. He shall
be responsible for providing and maintaining at his expense all lighting, protection, fencing and
security equipment which proves necessary for the proper implementation of the tasks or which
may reasonably be required by the Engineer.
45.4 If, during the implementation of the tasks, urgent measures are necessary to obviate any risk of
accident or damage or to ensure security following any accident or damage, the Engineer shall
give formal notice to the Contractor to do what is necessary. If the Contractor is unwilling or
unable to undertake the necessary measures, the Engineer may carry out the work at the expense
of the Contractor to the extent that the Contractor is liable.
45.5 While carrying out the Works, the Contractor shall comply, and shall ensure that its employees
comply with, the requirements of relevant Health and Safety and other relevant legislation,
45.6 The Contractor shall nominate a Health and Safety Representative to liaise with the Engineer on
all Health and Safety matters.
45.7 The Contractor’s staff shall follow a system of accident recording in accordance with the

P a g e 31 | 63
Contract Document for Construction Client: of
Contractor:

Contractor’s own accident reporting procedures.

45.8 All notifiable accidents shall immediately be brought to the attention of the Engineer.
45.9 The Contractor shall ensure the co-operation of its personnel in all prevention measures designed
against fire, or any other hazards, and shall notify the Employer of any change in the Contractor's
working practices or other occurrences likely to increase such risks or to cause new hazards.
45.10 The Contractor shall provide such first aid facilities and ensure that his staffs abide by such first
aid procedures as shall be required by the Employer.

46. Safeguarding Adjacent Properties

46.1 On his own responsibility and at his expense, the Contractor shall take all the precautions required
by good construction practice and by the prevailing circumstances to safeguard adjacent
properties and avoid causing any abnormal disturbance therein.
46.2 The Contractor shall indemnify the Employer against the financial consequences of all claims by
neighboring landowners or residents to the extent that the Contractor is liable and to the extent
that the damage to adjacent properties is not the result of a hazard created through the design or
method of construction imposed by the Employer or the Engineer upon the Contractor

47. Interference with Traffic

47.1 The Contractor shall ensure that the works and installations do not cause damage to, or obstruct
traffic on, communication links such as roads, railways, waterways and airports, except as
permitted under the SCC. He shall, in particular, take account of weight restrictions when
selecting routes and vehicles.
47.2 Any special measures which the Contractor considers necessary or which are specified in the SCC
or which are required by the Employer in order to protect or strengthen sections of roads, tracks or
bridges, shall be at the expense of the Contractor, whether or not they are carried out by the
Contractor. The Contractor shall inform the Engineer of any special measures he intends to take
before carrying them out. The repair of any damage caused to roads, tracks or bridges by the
transport of materials, plant or equipment shall be at the expense of the Contractor.

48. Cables and Conduits

48.1 Where, in the course of carrying out the works, the Contractor encounters bench-marks indicating
the course of underground cables, conduits and installations, he shall keep such bench-marks in
position or replace them, should execution of the works have necessitated their temporary
removal. Such related operations require the authorization of the Engineer.
48.2 The Contractor shall be responsible for the preservation, removal and replacement, as the case
may be, of the cables, conduits and installations specified by the Employer in the contract and for
the cost thereof.
48.3 Where the presence of cables, conduits and installations has not been specified in the contract but
is revealed by bench-marks and references, the Contractor shall be under a general duty of care
and similar obligations regarding preservation, removal and replacement to those set out above. In
this case, the Employer shall compensate him for expenditure, to the extent that such work is
necessary for the execution of the contract.
48.4 However, the obligations to remove and replace cables, conduits and installations and the
expenditure resulting therefrom shall not be the responsibility of the Contractor if the Employer
decides to accept that responsibility. The same shall apply where this obligation and the
expenditure resulting therefrom devolve upon another specialist administration or an agent.

P a g e 32 | 63
Contract Document for Construction Client: of
Contractor:

48.5 When any work on the site is likely to cause disturbances in or damage to a public utility service,
the Contractor shall immediately inform the Engineer in writing, giving a reasonable period of
notice so that suitable measures can be taken in time to allow work to continue normally.

49. Setting-out of the Works

49.1 The Contractor shall be responsible for:

A.1.1.1.150 the accurate setting-out of the Works in relation to original marks, lines and levels of
reference given by the Engineer;
A.1.1.1.151 the correctness, of the position, levels, dimensions and alignment of all parts of the Works;
and
A.1.1.1.152 the provision of all necessary instruments, appliances and labor in connection with the
foregoing responsibilities.
49.2 If, at any time during the execution of the Works, any error appears in the position, levels,
dimensions or alignment of any part of the Works, the Contractor, shall, if the Engineer so
requires, at the Contractor's cost, rectify such error to the satisfaction of the Engineer, unless such
error is based on incorrect data supplied by the Engineer, in which case the Employer shall be
responsible for the cost of rectification.
49.3 The checking of any setting-out or of any line or level by the Engineer shall not in any way relieve
the Contractor of his responsibility for the accuracy thereof and the Contractor shall carefully
protect and preserve all bench-marks, sight-rails, pegs and other items used in setting-out the
Works.

50. Demolished Materials

50.1 Where the contract includes demolition work, materials and articles obtained therefrom shall,
unless the SCC and /or the law of the Federal Democratic Republic of Ethiopia otherwise provide
and subject to the provisions of GCC Clause 51, be the property of the Contractor.
50.2 If the SCC reserve to the Employer the right of ownership of materials or all or part of the articles
obtained from the demolition work, the Contractor shall take all the necessary precautions to
ensure that these are preserved. He shall be liable for any destruction of, or damage to, such
materials or articles caused by him or his agents.
50.3 Irrespective of the use to which the Employer intends to put the materials or articles, in respect of
which he reserves the right of ownership, all costs incurred in transporting and storing them and
all warehouse charges at the place indicated by the Engineer shall be borne by the Contractor for
any carriage not exceeding 100 meters.
50.4 Except where the SCC provide otherwise, the Contractor shall, at his expense, progressively
remove rubble and other demolition materials, rubbish and debris from the Site.

51. Discoveries

51.1 Discoveries of any interest whatsoever made during excavation or demolition work shall be
brought immediately to the attention of the Engineer. The Engineer shall decide how such
discoveries are to be dealt with, taking due account of the law of the Federal Democratic Republic
of Ethiopia.
51.2 The Employer reserves the right of ownership of materials found during the excavation and
demolition work carried out on land belonging to him, subject to compensating the Contractor for
any special efforts.
51.3 Artifacts, antiquities and natural, numismatic, or other objects which are of scientific interest, and
also rare objects or objects made of precious metals found during excavation or demolition work
P a g e 33 | 63
Contract Document for Construction Client: of
Contractor:

shall be the property of the Employer.

51.4 In the event of disagreements, the Employer shall have sole authority to decide as to the
qualifications set out in GCC Clauses 51.1 and 51.3.

52. Temporary Works

52.1 The Contractor shall carry out at his expense all the temporary works to enable the Works to be
carried out. He shall submit specification and drawings showing the proposed temporary work to
the Engineer, who is to approve them if they comply with the specification and drawings. The
Contractor shall take into account any observations made to him by the Engineer while assuming
responsibility for these drawings.
52.2 The Contractor shall be responsible for design of Temporary Works.
52.3 The Engineer’s approval shall not alter the Contractor’s responsibility for design of the temporary
works.
52.4 The Contractor shall obtain approval of third parties to the design of the temporary works, where
required.
52.5 Where the design of particular temporary works is specified in the SCC to be the responsibility of
the Employer, the Engineer shall provide the Contractor with all drawings necessary in reasonable
time to enable the Contractor to undertake the temporary works in accordance with his program.
In such cases, the Employer shall be solely responsible for the safety and adequacy of the design.
However, the Contractor shall be responsible for the proper construction.

53. Soil Studies

53.1 Subject to the SCC and to the technical specifications, the Contractor shall make available to the
Engineer, the personnel and equipment necessary for carrying out any soil survey which the
Engineer considers reasonably necessary. The Contractor shall be compensated for the actual cost
of the manpower and equipment used or made available in such work, if not already provided for
in the contract.

54. Overlapping Contracts

54.1 The Contractor shall, in accordance with the requirements of the Engineer, afford all reasonable
opportunities for carrying out their work to any other Contractors employed by the Employer or
any other public authorities who may be employed on or near the Site in the execution of any
work not included in the contract, or of any contract which the Employer may enter into in
connection with, or ancillary to, the works.
54.2 If, however, the Contractor, on the written request of the Engineer, makes available to any such
Contractor, or public authority, or to the Employer, any roads or ways for the maintenance of
which the Contractor is responsible, or permits the use by any such other persons of the
Contractor's temporary works, scaffolding or other equipment on the site, or provides any other
service of whatsoever nature, which was not provided for in the contract, the Employer shall pay
to the Contractor in respect of such use or service, such sums and/or grant such extension of time,
as shall, in the opinion of the Engineer, be reasonable.
54.3 The Contractor shall not by reason of this Clause be relieved of any of his obligations under the
Contract nor shall he be entitled to any claims other than those provided for in GCC Clause 54.2.
54.4 In no circumstances may difficulties arising with regard to one contract entitle the Contractor to
modify or delay implementation of other contracts. Similarly, the Employer may not take
advantage of such difficulties to suspend payments due under another contract.

P a g e 34 | 63
Contract Document for Construction Client: of
Contractor:

55. Patents and Licenses

55.1 Except where otherwise provided in the SCC, the Contractor shall indemnify the Employer and
the Engineer against any claim resulting from the use as specified in the contract of patents,
licenses, drawings, designs, models, or brand or trade marks, except where such infringement
results from compliance with the design or specification provided by the Employer and /or the
Engineer.

56. Accounting, Inspection and Auditing

56.1 The Contractor shall keep, and shall cause its Sub-Contractors to keep, accurate and systemic
accounts and records in respect of the Contract, in accordance with internationally accepted
accounting principles and in such form and detail as will clearly identify all relevant time charges
and costs.
56.2 For the purpose of the examination and certification of the Employer's accounts; or any
examination of the economy, efficiency and effectiveness with which the Employer has used its
resources, the Federal Auditor General and the Public Procurement and Property Administration
Agency or its auditors may inspect all accounts and records relating to the performance of the
Contract and the submission of the Proposal to provide the Works which are owned, held or
otherwise within the control of the Contractor and may require the Contractor to produce such oral
or written explanation as he considers necessary. The Contractor acknowledges that it will fully
cooperate with any counter fraud policy or investigation carried out by authorized body at any
time.

57. Data Protection

57.1 The Contractor shall comply with all applicable data protection legislation. In particular the
Contractor agrees:
A.1.1.1.153 To maintain appropriate technical and organizational security measures;
A.1.1.1.154 To only process Personal Data for and on behalf of the Employer, in accordance with the
instructions of the Employer and for the purpose of performing its obligations under the
Contract;
A.1.1.1.155 To allow the Employer to audit the Contractor's compliance with the requirements of this
Clause on reasonable notice and/or to provide the Employer with evidence of its
compliance with the obligations set out in this Clause.
57.2 The Contractor agrees to indemnify and keep indemnified the Employer against all claims and
proceedings and all liability, loss, costs and expenses incurred in connection therewith by the
Employer as a result of any claim made or brought by any individual or other legal person in
respect of any loss, damage or distress caused to that individual or other legal person as a result of
the Contractor's unauthorized processing, unlawful processing, destruction of and/or damage to
any Personal Data processed by the Contractor, its employees or agents in the Contractor's
performance of the Contract or as otherwise agreed between the Parties.

58. Performance Security

58.1 The Contractor shall, within fifteen (15) days from signing the contract, provide a Performance
Security for the due performance of the Contract in the amount specified in the SCC.
58.2 Notwithstanding the provision of Sub-clause above a conditional insurance bond shall be accepted
as Performance Security.
58.3 The proceeds of the Performance Security shall be payable to the Employer as compensation for
any loss resulting from the Contractor’s failure to complete its obligations under the Contract.

P a g e 35 | 63
Contract Document for Construction Client: of
Contractor:

58.4 The Performance Security shall be denominated in currency specified in the SCC, and shall be in
the form of cash, cheque certified by a reputable bank, letter of credit, or Bank Guarantee in the
format specified in the SCC.
58.5 No payments shall be made in favor of the Contractor prior to the provision of the Performance
Security. The Performance Security shall continue to remain valid until the contract has been fully
and properly implemented.
58.6 During the performance of the contract, if the natural or legal person providing the Performance
Security is not able to abide by his commitments, the Performance Security shall cease to be valid.
The Employer shall give formal notice to the Contractor to provide a new Performance Security
on the same terms as the previous one. Should the Contractor fail to provide a new Performance
Security the Employer may terminate the Contract.
58.7 The Employer shall demand payment from the Performance Security of all sums for which the
guarantor is liable under the Performance Security due to the Contractor's default under the
Contract, in accordance with the terms of the Performance Security and up to the value thereof.
The guarantor shall, without delay, pay those sums upon demand from the Employer and may not
raise any objection for any reason whatsoever. Prior to making any claim under the Performance
Security, the Employer shall notify the Contractor stating the nature of the default in respect of
which the claim is to be made.
58.8 The Performance Security shall be discharged by the Employer and returned to the Contractor not
later than twenty-eight (28) days following the date of issuing of the signed Final Statement of
Account referred to in GCC Clause 65, for its total amount except for amounts which are the
subject of amicable settlement of disputes, unless specified otherwise in the SCC.
58.9 Notwithstanding the provision of GCC Sub-Clause 58.2 above, the Performance Security may be
returned to the Contractor where the Procurement Endorsing Committee ascertains that the
noncompliance of the Contractor does not affect the interest of, or entail additional cost on the
Employer and is not due to the fault of the Contractor.
58.10 The Employer shall be required to submit any document in its possession in relation to a
procurement in which it authorizes the return of the Performance Security to the Contractor and
account for its action under the preceding GCC Sub-Clause 58.9 of this GCC to the Public
Procurement and Property Administration Agency or other competent body if and when required
to do so.

D. Payments to the Contractor

59. General Principles

59.1 Payments shall be made in currency as specified in the SCC. The SCC shall lay down the
administrative or technical conditions governing advance payments, interim and/or final payments
made in accordance with the GCC.
59.2 Payments due by the Employer shall be made to the bank account mentioned on the Bidder
Certification of Compliance form completed by the Contractor.
59.3 Payments to the Contractor of the amounts due under each of the interim payment certificates and
the final statement of account issued by the Engineer shall be made by the Employer within 90
days of such certificate of statement being delivered to the Employer. The date of payment shall
be the date on which the paying institution's account is debited. The payment certificate shall not
be admissible if one or more essential requirements are not met.
59.4 Interim payment certificates or final statement of account must be accompanied with copies of
invoices and other appropriate supporting materials of the amounts payable.
59.5 The Contractor's invoice shall be correctly rendered if:

P a g e 36 | 63
Contract Document for Construction Client: of
Contractor:

A.1.1.1.156 The invoice is addressed to the Employer's officer specified in the Contract to receive
invoices and identifies the number of relevant Contract;
A.1.1.1.157 The invoice includes date of issuance and its serial number;
A.1.1.1.158 The amount claimed in the invoice is due for payment;
A.1.1.1.159 The amount specified in the invoice is correctly calculated in accordance with the
Contract;
A.1.1.1.160 The invoice includes the name and address of Contractor to whom payment is to be sent;
A.1.1.1.161 The invoice includes the name, title, and phone number of person to notify in the event of
defective invoice;
A.1.1.1.162 The invoice includes Contractor's bank account information, and
A.1.1.1.163 The invoice is, where appropriate, certified as sales tax exempt.

Failure to provide such information will entitle the Employer's to delay payment
until such information is provided.
59.6 The period referred to in GCC Clause 59.3 may be suspended by notifying the Contractor that the
payment certificate or the final statement of accounts cannot be fulfilled because the sum is not
due, because appropriate substantiating documents have not been provided or because there is
evidence that the expenditure might not be eligible. In the latter case, an inspection may be carried
out on the spot for the purpose of further checks. The Contractor shall provide clarifications,
modifications or further information within 30 days of being asked to do so. Within 30 days of
receipt of the clarification, the Engineer shall decide and issue if need be a revised payment
certificate or a final statement of account and the payment period shall continue to run from this
date.
59.7 The Contractor undertakes to repay any amounts paid in excess of the final amount due to the
Employer before the deadline indicated in the debit note which is 45 days from the issuing of that
note.
59.8 Should the Contractor fail to make repayment within the deadline set by the Employer, the
Employer may (unless the Contractor is a government-owned enterprise) increase the amounts
due by adding interest at the rediscount rate applied by the National bank of Ethiopia on the first
day of the month in which the time-limit expired, plus three and a half percentage points. The
default interest shall be incurred over the time which elapses between the date of the payment
deadline set by the Employer and the date on which payment is actually made. Any partial
payments shall first cover the interest thus established.
59.9 Amounts to be repaid to the Employer may be offset against amounts of any kind due to the
Contractor. This shall not affect the parties' right to agree on payment in installments. Bank
charges involved in the repayment of amounts due to the Employer shall be borne entirely by the
Contractor.

60. Advance Payment

60.1 If the SCC so provide, advance payment shall be granted to the Contractor, at his request, for
operations connected with the implementation of the tasks, in the cases listed hereinafter:
A.1.1.1.164 as a lump-sum advance enabling Contractor to meet expenditure resulting from the
commencement of the contract;
A.1.1.1.165 if Contractor affords proof of the conclusion of a contract for the purchase or order of
materials, plant, equipment, machines and tools, necessary for the execution of the
contract, and of any other substantial prior expenses such as the acquisition of patents or
study costs.
60.2 The SCC shall state the amount of the advance payment which shall not exceed 30% of the total

P a g e 37 | 63
Contract Document for Construction Client: of
Contractor:

contract price.
60.3 No advance payment shall be granted until:
A.1.1.1.166 The conclusion of the Contract;
A.1.1.1.167 Provision to the Employer by the procedure of the Performance Security in accordance
with GCC Clause 58; and by
A.1.1.1.168 Provision to the Employer by the Contractor of an advance payment security in an amount
equal to the advance payment they receive in the form of a certified cheque or
unconditional bank guarantee at their option from a reputable bank or letter of guarantee
written by a competent body organizing and overseeing small and micro enterprises
established under the relevant law.
60.4 Advance payment security shall remain effective until the advance payment has been completely
repaid by the Contractor out of interim payments under the contract.
60.5 The Contractor shall use the advance payment only to pay for Equipment, Plant, Materials, and
mobilization expenses required specifically for execution of the Contract. The Contractor shall
demonstrate that advance payment has been used in this way by supplying copies of invoices or
other documents to the Engineer. Should the Contractor misuse any portion of the advance
payment, it shall become due and repayable immediately and no further advance payments will be
made to him.
60.6 Should the advance payment security cease to be valid and the Contractor fail to re-validate it,
either a deduction equal to the amount of the advance payment may be made by the Employer
from future payments due to the Contractor under the contract, or the Employer may apply the
provisions of GCC Clause 58.6.
60.7 If the contract is terminated for any reason whatsoever, the guarantees securing the advance
payment may be invoked forthwith in order to repay the balance of the advance payment still
owed by the Contractor, and the guarantor shall not delay payment or raise objection for any
reason whatever.
60.8 The advance payment security provided for in this GCC Clause shall be released as and when
advance payment is repaid.
60.9 Further conditions and procedures for granting and repaying advance payment shall be as laid
down in the SCC.

61. Retention Monies

61.1 The sum which shall be retained from interim payments by way of guarantee to meet the
Contractor's obligations during the Defects Liability Period, and the detailed rules governing that
guarantee, shall be stipulated in the SCC, provided that it shall, in no case, exceed 10% of the
contract price.
61.2 Subject to the approval of the Employer, the Contractor may, if he so wishes, substitute, not later
than the date fixed for the commencement of the works, these retention sums by a retention
guarantee issued in accordance with GCC Clause 58.
61.3 The sum retained or the retention guarantee shall be released within 45 days of the issuing of the
signed final statement of account referred to in GCC Clause 65.

62. Price Adjustments

62.1 Adjustments of contract prices shall be allowed after twelve (12) months from the effective date
of the Contract where it is verified that the performance of the contract requires more than 18
months.
62.2 Request for price adjustment in relation to a particular work items under this Contract may be
P a g e 38 | 63
Contract Document for Construction Client: of
Contractor:

filed by the Contractor after twelve (12) months from the effective date of the Contract where it is
verified that the performance of the contract requires more than 18 months, which adjusted price
takes effect as the new Contract Price in relation to that work item on the expiration of 30 days
from the date on which the Employer receives notification of that adjusted price from the
Contractor, unless another date is agreed in writing between the Parties.
62.3 All prices shall be firm unless the Contractor has provided claim for price adjustment. The
Contractor may invoke this provision at any time during the Contract by notice in writing to the
Engineer.
62.4 The Employer can increase or decrease the Contract Price amount as described by this Clause.
62.5 Price Adjustment shall be applicable as payable in full for the original scheduled completion
period.
62.6 In the event the completion of contract exceeds the original scheduled period:
A.1.1.1.169 In case of default on the part of the Contractor causing delay in original scheduled
completion, the rate of Price Adjustment will be frozen at the original scheduled date of
completion; however Price Adjustment will be applicable till actual completion. While
computing Price Adjustment beyond the scheduled completion period, in the event the rate
is reduced, then that reduced rate will be applied.
A.1.1.1.170 The Price Adjustment will be payable in full for the extended period if the Contractor has
been granted an extension of time for no fault on the part of the Contractor, duly approved
by the Employer.
62.7 Unless specifically stated otherwise in the Contract, the basis for compensation will be only those
categories of inputs, which are specifically listed as specified items in the SCC.
62.8 An adjustment of the Contract Price, depending of selected categories of contract price, shall be
limited to an amount which takes account of price indexes or price indicators issued by Ethiopian
Central Statistical Agency or Public Procurement and Property Administration Agency.
62.9 Notwithstanding the provision of GCC Sub-Clause above, price information available from a
renowned local producer or competent foreign institution may be used in case the Ethiopian
Central Statistical Agency or Public Procurement and Property Administration Agency are not in
a position to issue current price indexes,
62.10 Contractor shall submit to the Employer for review and approval all calculations and supporting
information necessary to determine the price adjustment.
62.11 Adjustments in compensation may be either plus or minus depending on the differences between
the Benchmark Price Index and the Monthly Price Index.
62.12 To determine the adjustment on each item any such price variation shall be calculated in
accordance with the following formula by applying the combination of above said criteria:

PA   NV  A
 MLI  BLI   B  MMI  BMI   C  MEI  BEI   D  MFI  BFI   BC  Q
BLI BMI BEI BFI 
 
Where:
PA = The amount of the Price adjustment to be paid to, or recovered from, the
Contractor, in currency specified in SCC;
NV= The fraction which represents Non Variable element of the Contract Price that is
free of contract price adjustment, as specified in the Contractor's Bid;
A= The fraction of the Contract Price subject to adjustment in accordance with
movements of the selected Average Labor Category Earnings Index;
MLI = The most recently available selected Average Labor Category Earnings Index on
the

P a g e 39 | 63
Contract Document for Construction Client: of
Contractor:
date on which the Employer received notification of the proposed increased price
from the Contractor;
BLI = Benchmark Average Labor Category Earnings Index applicable to the Works
either:
A.1.1.1.171 at the bid closing date, or
A.1.1.1.172 if the Contract Price has been adjusted previously, the date on which the
Employer received notification from the Contractor in respect of the last
adjustment to effect the current Contract Price;
B= The fraction of the Contract Price subject to adjustment in accordance with
movements of the selected Material Price Index
MMI = The most recently available selected Material Price Index on the date on which
the
Employer received notification of the proposed increased price from the
Contractor;
BMI = Benchmark selected Material Price Index applicable to the Works either:
A.1.1.1.173 at the bid closing date, or
A.1.1.1.174 if the Contract Price has been adjusted previously, the date on which the
Employer received notification from the Contractor in respect of the last
adjustment to effect the current Contract Price;
C= The fraction of the Contract Price subject to adjustment in accordance with
movements of the selected Equipment Price Index
MEI = The most recently available selected Equipment Price Index on the date on
which the
Employer received notification of the proposed increased price from the
Contractor;
BEI = Benchmark selected Equipment Price Index applicable to the Works either:
A.1.1.1.175 at the bid closing date, or
A.1.1.1.176 if the Contract Price has been adjusted previously, the date on which the
Employer received notification from the Contractor in respect of the last
adjustment to effect the current Contract Price;
D= The fraction of the Contract Price subject to adjustment in accordance with
movements of the Average Fuel Price Index
MFI = The most recently available Average Fuel Price Index on the date on which the
Public
Body received notification of the proposed increased price from the Contractor;
BFI = Benchmark Average Fuel Price Index applicable to the Works either:
(a) at the bid closing date, or
(b) if the Contract Price has been adjusted previously, the date on which the
Employer received notification from the Contractor in respect of the last
adjustment to effect the current Contract Price;
BC = Current Contract Price applicable to the Works
Q= Quantity;
And where:
(a) NV+A+B+C+D are equal to 1.00
62.13 The fraction for each specified element and exact combination of elements that will be applied in
the formula for price adjustment shall be determined in the SCC.
62.14 An increase in the Contract Price takes effect as the new Contract Price in relation to the selected
category on the first day of the next Payment Period following receipt of an application for
increase provided the application is received no later than 14 days prior to the commencement of
P a g e 40 | 63
Contract Document for Construction Client: of
Contractor:

that Payment Period.

62.15 An increase in the Contract Price takes effect as the new Contract Price in relation to the selected
categories of inputs on the expiration of 30 days from the date on which the Employer receives
notification of the increased price from the Contractor, unless another date is agreed in writing
between the Parties;
62.16 When the Contractor varies the Contract Price of a Product or Service it must supply a copy of a
revised Pricing Schedule which incorporates the proposed changes in price and specifies the date
on which the proposed variation in price is to take effect in accordance with GCC Sub-Clauses
62.14 and 62.15.
62.17 The Contractor shall, when it notifies or requests a price adjustment under GCC Sub-Clause
62.12, provide to the Employer such Document or other information as the Contractor considers
appropriate for the purpose of substantiating the requested price adjustment.
62.18 Where the Employer questions a price increase notified or requested under GCC Sub-Clause
62.12, and the Contractor is not able, on the basis of the information it provided to the Employer,
to substantiate to the Employer any, or a part of, the notified or requested price adjustment, the
Contract Price shall be increased by only so much as the Contractor is able to substantiate and:
A.1.1.1.177 the substantiated increased Contract Price shall take effect as the new Contract Price in
relation to the Works as the case may be, on the date referred to in GCC Sub-Clause 62.14
or 62.15 unless another date is agreed in writing between the Parties; and
A.1.1.1.178 the Contractor shall, if it has not already done so, supply a suitably revised Pricing
Schedule in accordance with the requirements of GCC Sub-Clause 62.16.
62.19 Any discount offered by the Contractor under this Agreement cannot be reduced during the Term
of this Contract without the agreement in writing of the Employer.

63. Valuation of Works

63.1 The following methods shall apply to the valuation of works:

A.1.1.1.179 For unit-price (admeasurement) contracts:
A.1.1.1.179.1 The amount due under the contract shall be calculated by applying the
unit rates to the quantities actually executed for the respective items, in
accordance with the Contract;
A.1.1.1.179.2 The quantities set out in the bill of quantities shall be the estimated
quantities of the works, which shall not be taken as the actual and correct
quantities of the works to be executed by the Contractor in fulfillment of his
obligations under the Contract;
A.1.1.1.179.3 The Engineer shall determine by measurement the actual quantities of the
works executed by the Contractor, and these shall be paid for in accordance
with GCC Clause 64. Unless otherwise provided in the SCC no additions shall
be made to the items in the bill of quantities except as a result of a
modification in accordance with GCC Clause 15 or another provision of the
Contract entitling the Contractor to additional payment;
A.1.1.1.179.4 The Engineer shall, when he requires any parts of the works to be
measured, give reasonable notice to the Contractor to attend, or to send a
qualified agent to represent him. The Contractor or his agent shall assist the
Engineer in making such measurements and shall furnish all particulars
required by the Engineer. Should the Contractor not attend, or omit to send
such agent, the measurement made by the Engineer or approved by him shall
be binding on the Contractor;
P a g e 41 | 63
Contract Document for Construction Client: of
Contractor:

A.1.1.1.180 For lump-sum contracts, the amount due under the Contract shall be determined on the
basis of the breakdown of the overall contract price, or on the basis of a breakdown
expressed as a percentage of the contract price corresponding to completed stages of the
works. Where items are accompanied by quantities, these shall be firm quantities for which
the Contractor has submitted his all-in price, and shall be paid for irrespective of the
quantities of work actually carried out.

64. Interim Payment

64.1 Unless otherwise specified in the SCC, the Contractor shall submit monthly statement for interim
payment to the Engineer at the end of each period referred to in GCC Clause 64.7 in a form
approved by the Engineer. The monthly statement shall include the following items, as applicable:
A.1.1.1.181 The estimated contract value of the permanent works implemented up to the end of the
period in question;
A.1.1.1.182 An amount reflecting any price adjustment pursuant to GCC Clause 62;
A.1.1.1.183 An amount to be withheld as retention sum under GCC Clause 61;
A.1.1.1.184 Any credit and/or debit for the period in question in respect of plant and materials on Site
intended for, but not yet incorporated in, the permanent works in the amount and under the
conditions set out in GCC Clause 64.2;
A.1.1.1.185 An amount to be deducted on account of the advance payment repayment under the
provisions of GCC Clause 60; and
A.1.1.1.186 Any other sum to which the Contractor may be entitled under the Contract.
64.2 The Contractor shall be entitled to such sums as the Engineer may consider proper in respect of
plant and materials intended for, but not yet incorporated in, the permanent works provided that:
A.1.1.1.187 The plant and materials conform with the specifications for the permanent works and are
set out in batches in a way that they may be recognized by the Engineer;
A.1.1.1.188 Such plant and materials have been delivered to the Site, and are properly stored and
protected against loss or damage or deterioration to the satisfaction of the Engineer;
A.1.1.1.189 The Contractor's record of requirements, orders, receipts and use of plant and materials
under the contract are kept in a form approved by the Engineer and such records are
available for inspection by the Engineer;
A.1.1.1.190 The Contractor submits with his statement, the estimated value of the plant and materials
on Site together with such documents as may be required by the Engineer for the purpose
of valuation of the plant and materials and providing evidence of ownership and payment
therefore; and
A.1.1.1.191 Where the SCC so provide, ownership of the plant and materials referred to in GCC
Clause 83 shall be deemed to be vested in the Employer.
64.3 Approval by the Engineer of any interim payment certified by him in respect of plant and
materials pursuant to this GCC Clause shall be without prejudice to the exercise of any power of
the Engineer under the Contract to reject any plant or materials which are not in accordance with
the provisions of the Contract.
64.4 The Contractor shall be responsible for any loss or damage to, and for the cost of storing and
handling of, such plant and materials on site and shall effect such additional insurance as may be
necessary to cover the risk of such loss or damage from any cause.
64.5 Within 30 days of receipt of the said statement for interim payment, it shall be approved or
amended in such manner that, in the Engineer's opinion, the application reflects the amount due to
the Contractor in accordance with the Contract. In cases where there is a difference of opinion as
to the value of an item, the Engineer's view shall prevail. On determination of the amount due to
the Contractor, the Engineer shall, within the same 30 days deadline, issue and transmit to the
Employer for payment and to the Contractor for information, an Interim Payment Certificate for
P a g e 42 | 63
Contract Document for Construction Client: of
Contractor:

the amount due to the Contractor and shall inform the Contractor of the works for which payment
is being made.
64.6 The Engineer may, by an Interim Payment Certificate, make any corrections or modifications to
any previous certificate issued by him and shall have power to modify the valuation in or withhold
the issue of, any Interim Payment Certificate if the works or any part thereof is not being carried
out to his satisfaction.
64.7 Unless the SCC provide otherwise, the frequency shall be one interim payment per month.

65. Final Statement of Account

65.1 Unless otherwise agreed in the SCC, the Contractor shall not later than 90 days after the issue of
the Final Acceptance Certificate referred to in GCC Clause 89, submit to the Engineer a draft final
statement of account with supporting documents showing in detail the value of the work done in
accordance with the Contract, together with all further sums which the Contractor considers to be
due to him under the Contract in order to enable the Engineer to prepare the final statement of
account.
65.2 Within 60 days after receipt of the draft final statement of account and of all information
reasonably required for its verification, the Engineer shall prepare the final statement of account,
which determines:
A.1.1.1.192 the amount which in his opinion is finally due under the Contract; and
A.1.1.1.193 after establishing the amounts previously paid by the Employer and all sums to which the
Employer is entitled under the Contract, the balance, if any, due from the Employer to the
Contractor, or from the Contractor to the Employer, as the case may be.
65.3 The Engineer shall issue to the Employer or to its duly authorized representative, and to the
Contractor, the final statement of account showing the final amount to which the Contractor is
entitled under the Contract. The Employer or its duly authorized representative and the Contractor
shall sign the final statement of account as an acknowledgement of the full and final value of the
work implemented under the Contract and shall promptly submit a signed copy to the Engineer.
However, the final statement of account shall not include amounts in dispute which are the subject
of negotiations or amicable settlement.
65.4 The final statement of account signed by the Contractor shall constitute a written discharge of the
Employer confirming that the total in the final statement of account represents full and final
settlement of all monies due to the Contractor under the Contract, other than those amounts which
are the subject of amicable settlement. However, such discharge shall become effective only after
any payment due in accordance with the final statement of account has been made and the
performance security referred to in GCC Clause 58 has been returned to the Contractor.
65.5 The Employer shall not be liable to the Contractor for any matter or thing whatsoever arising out
of, or in accordance with, the Contract or execution of the works, unless the Contractor shall have
included a claim in respect thereof in his draft final statement of account.

66. Direct Payments to Sub-Contractors

66.1 When the Engineer receives a claim from a Sub-Contractor duly approved under GCC Clause 14
to the effect that the Contractor has not met his financial obligations so far as the Sub-Contractor
is concerned, the Engineer shall give notice to the Contractor either to pay the Sub-Contractor or
to inform him of the reasons why payment should not be made. Should such payment not be
made, or reasons not be given within the period of notice, the Engineer may, after satisfying
himself that the work has been carried out, certify, and the Employer shall meet the debt claimed
by the Sub-Contractor out of the sums remaining due to the Contractor. The Contractor shall
remain entirely responsible for the work in respect of which direct payment has been made.

P a g e 43 | 63
Contract Document for Construction Client: of
Contractor:

66.2 If the Contractor gives adequate reasons for refusing to meet all or part of the debt claimed by the
Sub-Contractor, the Employer shall only pay to the Sub-Contractor such sums as are not in
dispute. Sums claimed by the Sub-Contractor in respect of which the Contractor has given
adequate reasons for his refusal to pay shall be paid by the Employer only after the parties have
come to an amicable settlement or after a judgment of a court has been duly notified to the
Engineer.
66.3 Direct payments to Sub-Contractors shall not exceed the value at contract prices of the services
performed by the Sub-Contractors for which they request payment; the value at contract prices
shall be calculated or assessed on the basis of the bill of quantities, the price schedule or the
breakdown of the lump sum price.
66.4 Direct payments to Sub-Contractors shall be made entirely in the currency specified in SCC
Clause 59.1.
66.5 The provisions of this GCC Clause shall apply subject to the requirements of the law applicable
by virtue of GCC Clause 68 concerning the right to payment of creditors who are beneficiaries of
an assignment of credit or of a collateral security.

67. Delayed Payments

67.1 Once the time-limit referred to in GCC Clause 59.3 has expired, the Contractor – unless the
Contractor is a Employer which is partly or wholly financed by the Federal Government Budget –
shall upon demand, submitted within two months of receiving late payment, be entitled to late-
payment interest at the rediscount rate applied by the National bank of Ethiopia on the first day of
the month in which the time-limit expired, plus three and a half percentage points. The interest
shall be payable for the time elapsed between the expiry of the payment deadline and the date on
which the Employer’s account is debited. .
67.2 Any default in payment of more than 120 days from the expiry of the period laid down in GCC
Clause 67.1 shall entitle the Contractor either not to perform the Contract or to terminate it.

68. Payments to Third Parties

68.1 All orders for payments to third parties may be carried out only after an assignment made in
accordance with GCC Clause 13. The assignment shall be notified to the Employer.
68.2 Notification of beneficiaries of the assignment shall be the sole responsibility of the Contractor.
68.3 In the event of a legally binding attachment of the property of the Contractor affecting payments
due to him under the contract, without prejudice to the time limit laid down in GCC Clause 67, the
Employer shall have 30 days, starting from the day when it receives notification of the definitive
lifting of the obstacle to payment, to resume payments to the Contractor.

69. Claims for Additional Payment

69.1 If under the Contract there are circumstances which the Contractor considers entitle him to
additional payment, the Contractor shall:
A.1.1.1.194 if he intends to make any claim for additional payment, give to the Engineer notice of his
intention or make such claim within 15 days after the said circumstances become known to
the Contractor, stating the reason for his claim; and
A.1.1.1.195 submit full and detailed particulars of his claim as soon as it is reasonably practicable, but
no later than 60 days after the date of such notice, unless otherwise agreed by the
Engineer. In case the Engineer agrees to another deadline than the said 60 days, the
agreed upon deadline will in any event, require that such particulars shall be submitted no
later than the date of submission of the draft final statement of account. The Contractor
shall thereafter promptly submit such further particulars as the Engineer may reasonably
P a g e 44 | 63
Contract Document for Construction Client: of
Contractor:

require assessing the validity of the claim.

69.2 When the Engineer has received the full and detailed particulars of the Contractor's claim that he
requires, he shall, without prejudice to GCC Clause 44.4, after due consultation with the
Employer and, where appropriate, the Contractor, determine whether the Contractor is entitled to
additional payment and notify the parties accordingly.
69.3 The Engineer may reject any claim for additional payment which does not comply with the
requirements of this GCC Clause.

E. Performance of the Contract

70. Scope of Works

70.1 Subject to the SCC, the Works to be carried out shall be as specified in the Section 6, Schedule of
Requirements.
70.2 The Contractor shall construct and install the Works at sites and locations as are specified in the
SCC in accordance with the Specifications and Drawings or as agreed by the Parties in writing.

71. Commencement of Works

71.1 The Employer shall fix the Start Date on which execution of the Works is to commence in the
SCC or by administrative order issued by the Engineer.
71.2 The Start Date for commencing execution of the Works shall be not later than 120 days following
notification of award of contract unless agreed otherwise by the parties.

72. Period of Execution of Works

72.1 The period of execution of Works shall commence on the Start Date fixed in accordance with
GCC Clause 71.1 and shall be as laid down in the SCC, without prejudice to extensions of the
period which may be granted under GCC Clause 73.
72.2 The Contractor shall carry out the Works in accordance with the Program of implementation of
tasks submitted by the Contractor, as updated with the approval of the Engineer, and complete
them by the Intended Completion Date.
72.3 If provision is made for distinct periods of implementation for separate lots, in cases where one
Contractor is awarded more than one lot per contract, the periods of implementation for the
separate lots will not be accumulated.

73. Extension of Intended Completion Date

73.1 The Contractor may request an extension of the Intended Completion Date if he is or will be
delayed in completing the contract by any of the following causes:
A.1.1.1.196 Exceptional weather conditions in the Federal Democratic Republic of Ethiopia;
A.1.1.1.197 Artificial obstructions or physical conditions which could not reasonably have been
foreseen by an experienced Contractor;
A.1.1.1.198 Compensation Event occurs or a change order for modification is issued which makes it
impossible for completion to be achieved by the Intended Completion Date;
A.1.1.1.199 Administrative orders affecting the date of completion other than those arising from the
Contractor's default;
A.1.1.1.200 Failure of the Employer to fulfill his obligations under the Contract;
A.1.1.1.201 Any suspension of the works which is not due to the Contractor's default;
A.1.1.1.202 Force majeure;

P a g e 45 | 63
Contract Document for Construction Client: of
Contractor:

A.1.1.1.203 Any other causes referred to in these GCC which are not due to the Contractor's default.
73.2 The Contractor shall, within 15 days of becoming aware that delay may occur, notify the Engineer
of his intention to make a request for extension of the Intended Completion Date to which he may
consider himself entitled, and shall, unless otherwise agreed between the Contractor and the
Engineer, within 21 days from the notification deliver to the Engineer full and detailed particulars
of the request, in order that such request may be investigated at the time.
73.3 Within 21 days from receipt of the Contractor's detailed particulars of the request, the Engineer
shall, by written notice to the Contractor after due consultation with the Employer and, where
appropriate, the Contractor, grant such extension of the Intended Completion Date as may be
justified, either prospectively or retrospectively, or inform the Contractor that he is not entitled to
an extension.
73.4 If the Contractor has failed to give early notification of a delay or has failed to cooperate in
dealing with a delay, the delay by this failure shall not be considered in assessing the new
Intended Completion Date.

74. Compensation Events for Allowing Time Extension

74.1 The following shall be Compensation Events allowing for time extension:
A.1.1.1.204 The Employer does not give access to a part of the Site by the Site Possession Date stated
in the Contractor’s approved work program;
A.1.1.1.205 The Employer modifies the Schedule of other Contractors in a way that affects the work of
the Contractor under the Contract;
A.1.1.1.206 The Engineer orders a delay or does not issue Drawings, Specifications, or instructions
required for execution of the Works on time;
A.1.1.1.207 The Engineer instructs the Contractor to uncover or to carry out additional tests upon
work, which is then found to have no Defects;
A.1.1.1.208 The Engineer unreasonably does not approve a subcontract to be let;
A.1.1.1.209 The Engineer gives an instruction for dealing with an unforeseen condition, caused by the
Employer, or additional work required for safety or other reasons.
A.1.1.1.210 Other Contractors, public authorities, utilities, or the Employer do not work within the
dates and other constraints stated in the Contract, and they cause delay;
A.1.1.1.211 The advance payment is delayed;
A.1.1.1.212 The Engineer unreasonably delays issuing Interim Payment Certificates;
A.1.1.1.213 Other Compensation Events described in the SCC or determined by the Employer and
force majeure.
74.2 If a Compensation Event would prevent the work being completed before the Intended
Completion Date, the Intended Completion Date shall be extended. The Engineer shall decide
whether and by how much the Intended Completion Date shall be extended.
74.3 The Contractor shall not be entitled to compensation to the extent that the Employer’s interests are
adversely affected by the Contractor not having given early warning.

75. Acceleration

75.1 When the Employer wants the Contractor to finish before the Intended Completion Date, the
Engineer will obtain priced proposals for achieving the necessary acceleration from the
Contractor. If the Employer accepts these proposals, the Intended Completion Date will be
adjusted accordingly and confirmed by both the Employer and the Contractor.
75.2 If the Contractor’s priced proposals for acceleration are accepted by the Employer, they are
incorporated in the Contract Price and treated as a modification.

P a g e 46 | 63
Contract Document for Construction Client: of
Contractor:

76. Management Meetings

76.1 Either the Engineer or the Contractor may require the other to attend a formal management
meeting, to discuss the Employer's levels of satisfaction in respect of the Works carried out under
the Contract, to review the plans for remaining work, and to agree any necessary action to address
areas of dissatisfaction. The Contractor will not obstruct or withhold its agreement to any such
necessary action. Such meetings shall be attended by duly authorized and sufficiently senior
employees of both the Employer and the Contractor together with any other relevant attendees.
The Parties shall agree a standing agenda for such Reviews.
76.2 The Engineer shall record the business of management meetings and provide copies of the record
to those attending the meeting and to the Employer. The responsibility of the parties for actions to
be taken shall be decided by the Engineer either at the management meeting or after the
management meeting and stated in writing to all who attended the meeting.

77. Early Warning

77.1 The Contractor shall warn the Engineer at the earliest opportunity of specific likely future events
or circumstances that may adversely affect the quality of the work increase the Contract Price or
delay the execution of the Works. The Engineer may require the Contractor to provide an estimate
of the expected effect of the future event or circumstance on the Contract Price and Completion
Date. The estimate shall be provided by the Contractor as soon as reasonably possible.
77.2 The Contractor shall cooperate with the Engineer in making and considering proposals for how
the effect of such an event or circumstance can be avoided or reduced by anyone involved in the
work and in carrying out any resulting instruction of the Engineer.

78. Delays in Implementation of Tasks

78.1 If the Contractor fails to complete the works within the time period(s) specified in the Contract the
Employer shall, without formal notice and without prejudice to his other remedies under the
contract be entitled to liquidated damages for every day or part thereof which shall elapse between
the end of the period specified for implementation of tasks or extended Intended Completion Date
under GCC Clause 72 and the actual date of completion, at the rate and up to the maximum
amount specified in the GCC Clause 27. If the works have been the subject of partial acceptance
in accordance with GCC Clause 86, the liquidated damages specified in the GCC Clause 27 may
be reduced in the proportion which the value of the accepted part bears to the value of the whole
of the works.
78.2 If the Employer has become entitled to the maximum claim under GCC Clause 78.1 he may, after
giving notice to the Contractor:
A.1.1.1.214 Seize the performance guarantee; and /or
A.1.1.1.215 Terminate the contract; and
A.1.1.1.216 Enter into a contract with a third party at the Contractor's cost for the provision of the
balance of the works.

79. Work Register

79.1 A work register shall, unless otherwise provided by the SCC, be kept on the site by the Engineer,
who shall enter in it at least the following information:
A.1.1.1.217 the weather conditions, interruptions of work owing to inclement weather, hours of work,
number and type of workmen employed on the site, materials supplied, equipment in use,
equipment not in working order, tests carried out, samples dispatched, unforeseen
circumstances, as well as orders given to the Contractor;

P a g e 47 | 63
Contract Document for Construction Client: of
Contractor:

A.1.1.1.218 detailed statements of all the quantitative and qualitative elements of the work done and the
supplies delivered and used, capable of being checked on the Site and relevant in
calculating payments to be made to the Contractor.
79.2 The statements shall form an integral part of the work register but may, where appropriate, be
recorded in separate documents. The technical rules for drawing up the statements shall be as set
out in the SCC.
79.3 The Contractor shall ensure that statements are drawn up, in good time and in accordance with the
SCC, in respect of work, services and supplies which cannot be measured or verified
subsequently; failing this, he shall accept the decisions of the Engineer, unless, at his own
expense, he provides evidence to the contrary.
79.4 Entries made in the work register as work progresses shall be signed by the Engineer and
countersigned by the Contractor or his representative. If the Contractor objects, he shall
communicate his views to the Engineer within 15 days following the date on which the entry or
the statements objected to be recorded. Should Contractor fail to countersign or to submit his
views within the period allowed, the Contractor shall be deemed to agree with the notes shown in
the register. The Contractor may examine the work register at any time and may, without
removing the document, make or receive a copy of entries which he considers necessary for his
own information.
79.5 The Contractor shall, on request, provide the Engineer with the information needed to keep the
work register in good order.

80. Origin and Quality of Works and Materials

80.1 All goods purchased under the contract shall have their origin in any eligible source country as
defined in the Section 5 of the Bidding Documents.
80.2 The works, components and materials shall conform to the specifications, drawings, surveys,
models, samples, patterns and other requirements in the SCC which shall be held at the disposal of
the Employer or the Engineer for the purposes of identification throughout the period of
performance.
80.3 Any preliminary technical acceptance stipulated in the SCC shall be the subject of a request sent
by the Contractor to the Engineer. The request shall indicate the reference to the contract, the lot
number and the place where such acceptance is to take place, as appropriate. The components and
materials specified in the request must be certified by the Engineer as meeting the requirements
for such acceptance prior to their incorporation in the works.
80.4 Even if materials or items to be incorporated in the works or in the manufacture of components
have been technically accepted in this way, they may still be rejected and must be replaced
immediately by the Contractor if a further examination reveals defects or faults. The Contractor
may be given the opportunity to repair and make good materials and items which have been
rejected, but such materials and items will be accepted for incorporation in the works only if they
have been repaired and made good to the satisfaction of the Engineer.

81. Inspection and Testing

81.1 The Contractor shall ensure that the components and materials are delivered to the site in time to
allow the Engineer to proceed with acceptance of the components and materials. The Contractor is
deemed to have fully appreciated the difficulties which he might encounter in this respect, and he
shall not be permitted to advance any grounds for delay in fulfilling his obligations.
81.2 The Engineer shall be entitled, either by himself or his agent, to inspect, examine, measure and
test the components, materials and workmanship, and check the progress of preparation,
fabrication or manufacture of anything being prepared, fabricated or manufactured for delivery
under the contract in order to establish whether the components, materials and workmanship are
P a g e 48 | 63
Contract Document for Construction Client: of
Contractor:

of the requisite quality and quantity. This shall take place at the place of manufacture, fabrication,
preparation or on the site or at such other places as may be specified in the contract.
81.3 For the purposes of such tests and inspections, the Contractor shall:
A.1.1.1.219 provide to the Engineer, temporarily and free of charge, such assistance, test samples,
parts, machines, equipment, tools or materials and labor as are normally required for
inspection and testing;
A.1.1.1.220 agree, with the Engineer, on the time and place for tests;
A.1.1.1.221 provide access for the Engineer at all reasonable times to the place where the tests are to
be carried out.
81.4 If the Engineer is not present on the date agreed for tests, the Contractor may, unless otherwise
instructed by the Engineer, proceed with the tests, which shall be deemed to have been made in
the Engineer's presence. The Contractor shall forthwith forward duly certified copies of the test
results to the Engineer, who shall, if he has not attended the test, be bound by the test results.
81.5 When components and materials have passed the tests referred to in this GCC Clause, the
Engineer shall notify the Contractor or endorse the procedure's certificate to that effect.
81.6 If the Engineer and the Contractor disagree on the test results, each shall give a statement of his
views to the other within 15 days after such disagreement arises. The Engineer or the Contractor
may require such tests to be repeated on the same terms and conditions or, if either party so
requests, by an expert to be selected by common consent. All test reports shall be submitted to the
Engineer who shall communicate the results of these tests without delay to the Contractor. The
results of the re-testing shall be conclusive. The cost of the re-testing shall be borne by the party
whose views are proved wrong by the re-testing.
81.7 In the performance of his duties, the Engineer and all persons authorized by him shall disclose
only to those persons who are entitled to know of it information which he has obtained by reason
of his inspection and testing of the methods of manufacture and operation of the undertaking.

82. Rejection

82.1 Components and materials which are not of the specified quality shall be rejected. A special mark
may be applied to the rejected components or materials. This shall not be such as to alter them or
affect their commercial value. Rejected components and materials shall be removed by the
Contractor from the site within a period which the Engineer shall specify, failing which they shall
be removed by the Engineer as of right at the expense and risk of the Contractor. Any work
incorporating rejected components or materials shall be rejected.
82.2 The Engineer shall, during the progress of the works and before the works are taken over, have the
power to order or decide:
A.1.1.1.222 the removal from the Site, within such time limits as may be specified in the order, of any
components or materials which, in the opinion of the Engineer, are not in accordance with
the contract;
A.1.1.1.223 the substitution of proper and suitable components or materials; or
A.1.1.1.224 the demolition and proper re-execution, or satisfactory repair, notwithstanding any
previous test thereof or interim payment therefore, of any work which, in respect of
components, materials, workmanship or design by the Contractor for which he is
responsible, is not, in the opinion of the Engineer, in accordance with the Contract.
82.3 The Engineer shall, as soon as reasonably practicable, give to the Contractor notice in writing of
his decision specifying particulars of the alleged defects.
82.4 The Contractor shall with all speed and at his expense make good the defects so specified. If the
Contractor does not comply with such order, the Employer shall be entitled to employ other
persons to carry out the same and all expenses consequent thereon or incidental thereto may be
P a g e 49 | 63
Contract Document for Construction Client: of
Contractor:

deducted by the Employer from any monies due or which may become due to the Contractor.
82.5 The provisions of this GCC Clause shall not affect the right of the Employer to claim under GCC
Clauses 19 and 78.

83. Ownership of Plant and Materials

83.1 All equipment, temporary works, plant and materials provided by the Contractor shall, when
brought on the Site, be deemed to be exclusively intended for the execution of the works and the
Contractor shall not remove the same or any part thereof, except for the purpose of moving it from
one part of the site to another, without the consent of the Engineer. Such consent shall, however,
not be required for vehicles engaged in transporting any staff, labor, equipment, temporary works,
plant or materials to or from the Site.
83.2 The SCC may provide that all equipment, temporary works, plant and materials on Site owned by
the Contractor or by any company in which the Contractor has a controlling interest shall, for the
duration of the execution of the works, be:
A.1.1.1.225 vested in the Employer; or
A.1.1.1.226 made subject to a lien in favor of the Employer; or
A.1.1.1.227 made subject to any other arrangement regarding priority interest or security.
83.3 In the event of termination of the contract in accordance with GCC Clause 21 due to the
Contractor's breach of Contract, the Employer shall be entitled to use the equipment, temporary
works, plant and materials on Site in order to complete the works.
83.4 Any agreement for the hire by the Contractor of equipment, temporary works, plant and materials
brought onto the Site, shall contain a provision that on request in writing made by the Employer
within 7 days after the date on which the termination under GCC Clause 21 becomes effective,
and on the Employer undertaking to pay all hire charges in respect thereof from such date, the
owner thereof will hire such equipment, temporary works, plant or materials to the Employer on
the same terms as they were hired by the Contractor, except that the Employer shall be entitled to
permit the use thereof by any other Contractor employed by him for completing the works under
the provisions of GCC Clause 21.5.
83.5 Upon termination of the contract before completion of the works, the Contractor shall deliver to
the Employer any plant, temporary works, equipment or materials the property in which has
vested in the Employer or been made subject to a lien by virtue of GCC Clause 83.2. If he fails to
do so, the Employer may take such appropriate action as it deems fit in order to obtain possession
of such plant, temporary works, equipment and materials and recover the cost of so doing from
the Contractor.

F. Acceptance and Defects Liability

84. General Principles

84.1 Verification of the works by the Engineer with a view to provisional or final acceptance shall take
place in the presence of the Contractor. The absence of the Contractor shall not be a bar to
verification on condition that the Contractor has been summoned in due form at least 30 days
prior to the date of verification.
84.2 Should exceptional circumstances make it impossible to ascertain the state of the works or
otherwise proceed with their acceptance during the period fixed for provisional or final
acceptance, a statement certifying such impossibility shall be drawn up by the Engineer after
consultation, where possible, with the Contractor. The verification shall take place and a statement
of acceptance or rejection shall be drawn up by the Engineer within 30 days following the date on
which such impossibility ceases to exist. The Contractor shall not invoke these circumstances in

P a g e 50 | 63
Contract Document for Construction Client: of
Contractor:

order to avoid his obligation to present the works in a state suitable for acceptance.

85. Tests on Completion

85.1 The works shall not be accepted until the prescribed verifications and tests have been carried out
at the expense of the Contractor. The Contractor shall notify the Engineer of the date on which
such verification and tests may commence.
85.2 Works which do not satisfy the terms and conditions of the Contract, or in the absence of such
terms and conditions, which are not carried out in accordance with trade practices in the Federal
Democratic Republic of Ethiopia, shall, if required, be demolished and rebuilt by the Contractor
or repaired to the satisfaction of the Engineer, otherwise this shall be done as of right after due
notice at the expense of the Contractor, by order of the Engineer. The Engineer may also require
the demolition and reconstruction by the Contractor, or repair to the satisfaction of the Engineer,
under the same conditions of work, in which unacceptable materials have been used, or carried out
in the periods of suspension provided for in GCC Clause 20.

86. Partial Acceptance

86.1 The Employer may make use of the various structures, parts of structures or sections of the works
forming part of the contract as and when they are completed. Any taking over of the structures,
parts of structures or sections of the works by the Employer shall be preceded by their partial
provisional acceptance. However, works may in cases of urgency be taken over prior to
acceptance provided an inventory of outstanding work is drawn up by the Engineer and agreed to
by the Contractor and the Engineer beforehand. Once the Employer has taken possession of a
structure, a part thereof or section of the works, the Contractor shall no longer be required to make
good any damage resulting otherwise than from faulty construction or workmanship.
86.2 The Engineer may, at the request of the Contractor and if the nature of the works so permits
proceeds with partial provisional acceptance, provided that the structures, parts of structures or
sections of the works are completed and suited to the use as described in the Contract.
86.3 In the cases of partial provisional acceptance referred to in GCC Sub-Clauses 86.1 and 86.2 the
Defects Liability Period provided for in GCC Clause 88 shall, unless the SCC provide otherwise,
run as from the date of such partial provisional acceptance.

87. Provisional Acceptance

87.1 The works shall be taken over by the Employer when they have satisfactorily passed the tests on
completion and a certificate of provisional acceptance has been issued or is deemed to have been
issued.
87.2 The Contractor may apply, by notice to the Engineer, for a certificate of provisional acceptance
not earlier than 15 days before the works, in the Contractor's opinion, are complete and ready for
provisional acceptance. The Engineer shall within 30 days after the receipt of the Contractor's
application either:
A.1.1.1.228 issue the certificate of provisional acceptance to the Contractor with a copy to the
Employer stating, where appropriate, his reservations, and, inter alia, the date on which,
in his opinion, the works were completed in accordance with the Contract and ready for
provisional acceptance; or
A.1.1.1.229 reject the application giving his reasons and specifying the action which, in his opinion, is
required of the Contractor for the certificate to be issued.
87.3 If the Engineer fails either to issue the certificate of provisional acceptance or to reject the
Contractor's application within the period of 30 days, he shall be deemed to have issued the
certificate on the last day of that period. The certificate of provisional acceptance shall not be

P a g e 51 | 63
Contract Document for Construction Client: of
Contractor:

deemed to be an admission that the works have been completed in every respect. If the works are
divided by the contract into sections, the Contractor shall be entitled to apply for separate
certificates for each of the sections.
87.4 Upon provisional acceptance of the works, the Contractor shall dismantle and remove temporary
structures as well as materials no longer required for use in connection with the performance of
the contract. He shall also remove any litter or obstruction and redress any change in the condition
of the Site as required by the contract.
87.5 Immediately after provisional acceptance, the Employer may make use of all the works as
completed.

88. Defects Liability

88.1 The Contractor shall be responsible for making good any defect in, or damage to, any part of the
works which may appear or occur during the Defects Liability Period and which arises either
from:
A.1.1.1.230 the use of defective plant or materials or faulty workmanship or design of the Contractor;
and/or
A.1.1.1.231 any act or omission of the Contractor during the Defects Liability Period.
88.2 The Contractor shall at his own cost make good the defect or damage as soon as practicable. The
Defects Liability Period for all items replaced or renewed shall recommence from the date when
the replacement or renewal was made to the satisfaction of the Engineer. If the contract provides
for partial acceptance, the Defects Liability Period shall be extended only for the part of the works
affected by the replacement or renewal.
88.3 If any such defect appears or such damage occurs, during the period referred to in GCC Clause
88.1, the Employer or the Engineer shall notify the Contractor. If the Contractor fails to remedy a
defect or damage within the time limit stipulated in the notification, the Employer may:
A.1.1.1.232 carry out the works himself, or employ someone else to carry out the works, at the
Contractor's risk and cost, in which case the costs incurred by the Employer shall be
deducted from monies due to or from securities held against the Contractor or from both;
or
A.1.1.1.233 terminate the Contract.
88.4 If the defect or damage is such that the Employer has been deprived substantially of the whole or
a part of the benefit of the works, the Employer shall, without prejudice to any other remedy, be
entitled to recover all sums paid in respect of the parts of the works concerned together with the
cost of dismantling such parts and clearing the Site.
88.5 In case of emergency, where the Contractor cannot be reached immediately or, having been
reached, is unable to take the measures required, the Employer or the Engineer may have the work
carried out at the expense of the Contractor. The Employer or the Engineer shall as soon as
practicable inform the Contractor of the action taken.
88.6 Where the SCC stipulates that the maintenance work, necessitated by normal wear and tear, shall
be carried out by the Contractor, such work shall be paid for from a provisional sum.
Deterioration resulting from the circumstances provided for in GCC Clause 44 or from abnormal
use shall be excluded from this obligation unless it reveals a fault or defect justifying the request
for repair or replacement under GCC Clause 88.
88.7 The defects liability shall be stipulated in the SCC. If the duration of the Defects Liability Period
is not specified, it shall be 365 days. The Defects Liability Period shall commence on the date of
provisional acceptance.
88.8 After provisional acceptance and without prejudice to the defects liability referred to in this GCC
Clause, the Contractor shall no longer be responsible for risks which may affect the works and
P a g e 52 | 63
Contract Document for Construction Client: of
Contractor:

which result from causes not attributable to him. However, the Contractor shall be responsible as
from the date of provisional acceptance for the soundness of the construction, as laid down in the
in the Ethiopian law.

89. Final Acceptance

89.1 Upon the expiry of the Defects Liability Period, or where there is more than one such period, upon
the expiry of the latest period, and when all defects or damage have been rectified, the Engineer
shall issue to the Contractor a Final Acceptance Certificate and a copy thereof to the Employer
stating the date on which the Contractor completed his obligations under the Contract to the
Engineer's satisfaction. The Final Acceptance Certificate shall be given by the Engineer within 30
days after the expiration of the above stated period, or as soon as any works ordered under GCC
Clause 88 have been completed to the satisfaction of the Engineer.
89.2 The works shall not be considered as completed until the Final Acceptance Certificate has been
signed by the Engineer and delivered to the Employer, with a copy to the Contractor.
89.3 Notwithstanding the issue of the Final Acceptance Certificate, the Contractor and the Employer
shall remain liable for the fulfillment of any obligation incurred under the contract prior to the
issue of the Final Acceptance Certificate, which remains unperformed at the time such Final
Acceptance Certificate is issued. The nature and extent of any such obligation shall be determined
by reference to the provisions of the contract.

P a g e 53 | 63
1. Special Conditions of Contract
The following Special Conditions of Contract (SCC) shall supplement the General Conditions of Contract
(GCC). Whenever there is a discrepancy between them, the provisions herein shall prevail over those in the
GCC.

GCC Clause
Section 8. Special Conditions of Contract
Reference
A. General Provisions

GCC 1.2(d) The Employer is: BGI Beteseb Housing Cooperative Society
Town/City: ADDIS ABABA
PO Box No/Postal Code:
Country: Ethiopia
Telephone: ____________________________________
Electronic mail address: ______________________________________

The Works consist of: The structural Skeleton Construction Works of a B+G+6
Apartment.

The Site is located at : Addis Ababa, Bole Sub city Around Ayat
The Start Date shall be: in 10 (Ten ) calendar days after signing the contract
The Intended Completion Date for the Works shall be 180 Calendar days from
commencement of works
GCC 1.2 (g) The Contractor is: GT Building Contractor
Town/City: ADDIS ABABA
PO Box No/Postal Code:
Country: Ethiopia

AHENK REAL ESTATE Page 54

Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
Telephone: ____________________________________
Electronic mail address: ______________________________________

B. The Contract
GCC 7.1 (i) In addition to documents listed in GCC Clause 7.1 the following documents shall form the
Contract:
1. This special condition of the Contract
2. General Conditions of the Contract
3. Priced Bill of Quantities
4. The Drawings
5. The Technical Specifications and Method of Measurements issued BATACoDTA
March 1991
6. Instruction of the Engineer Issued from time to time within the contract period
7. Construction Methodology, Work plan, Activities schedule
8. List of materials to be delivered by the employer
GCC 8.1 The governing law shall be :
Federal Democratic Republic of Ethiopia.
GCC 9.1 Language of the Contract shall be ENGLISH.
GCC 10.2 For notices, the Public Employer's address shall be:
Employer: BGI Beteseb Housing Corporative Society
Attention: GENERAL MANAGER
P.O. Box:
Town/City: ADDIS ABABA
Post Code:
Country: ETHIOPIA
Telephone:
E-mail address
For notices, the Contractor’s address shall be:
Contractor: GT Building Contractor
Attention: GENERAL MANAGER
P.O. Box:
Town/City: ADDIS ABABA
Country: Ethiopia
Telephone:
E-mail address
GCC 12.1 The Employer's Engineer shall be: BLUDOT SERVICE PLC
Engineer: Ato Michael Yilma
P.O. Box:
Street Address: Bole Road, Genete Building Room No 755/34-2
Town/City: ADDIS ABABA
Country: Ethiopia
Telephone: + 251 -930-071453
E-mail address Mail: [email protected]
GCC 15 Variations
The Engineer with the consent of the employer shall make any variation of the form,
quality or quantity of the Works or any part thereof that may, in his opinion, be necessary
and for that purpose, or if for any other reason it shall, in his opinion be desirable, he shall
have power to order the Contractor to do any of the following:-
(a) increase or decrease the quantity of any work included in the Contract,
(b) omit any such work,
(c) change the character or quality or kind of any such work,

P a g e 55 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
(d) change the levels, lines, position and dimensions of any part of the Works,
(e) Execute additional work of any kind necessary for completion of the Works and no such
variation shall in any way vitiate or invalidate the Contract, but the value, if any, of all such
variations shall be taken into account in ascertaining the amount of the Contract Price.

Orders for Variations to be in Writing

No such variations shall be made by the Contractor without an order in writing of the
Engineer. Provided that no order in writing shall be required for increase or decrease in the
quantity of any work where such increase or decrease is not the result of an order given
under this Clause, but is the result of the quantities exceeding or being less than those stated
in the bill of quantities. Provided also
that if for any reason the Engineer shall consider it desirable to give any such order verbally,
the Contractor shall comply with such order and any confirmation in writing of such verbal
order given by the Engineer, whether before or after the carrying out of the order, shall be
deemed to be an order in writing within the meaning of this Clause. Provided further that if
the Contractor shall within seven days confirm in writing to the Engineer and such
confirmation shall not be contradicted in writing within fourteen days by the Engineer, it
shall be deemed to be an order in writing by the Engineer.

Valuation of Variations
All extra or additional work done or work omitted by order of the Engineer shall be valued
at the rates and prices set out in the Contract If the Contract does not contain any rates or
prices applicable to the extra or additional work then suitable rates or prices shall be agreed
upon between the Engineer and the Contractor. In the event of disagreement the Engineer
shall fix such rates or prices as shall, in his opinion, are reasonable and proper.

Power of Engineer to Fix Rates

Provided that if the nature or amount of any omission or addition relative to
the nature or amount of the whole of the Works or to any part thereof shall be such that, in
the opinion of the Engineer, the rate or price contained in the contract for any item of the
Works is, by reason of such omission or addition, rendered unreasonable or inapplicable,
then a suitable rate or price shall be agreed upon between the Engineer (with the consent of
the Employer) and the Contractor. In the event of disagreement the Engineer shall fix such
other rate or price as shall, in his opinion, be reasonable and proper having regard to the
circumstances.
Provided also that no increase or decrease or variation of rate or price under
shall be made unless, as soon after the date of the order as is practicable
and, in the case of extra or additional work, before the commencement of
the work or as soon thereafter as is practicable, notice shall have been given
in writing:-
a. by the Contractor to the Engineer of his/her intention to claim extra
payment or a varied rate or price, or
b. by the Engineer to the Contractor of his/her intention to vary a rate or price.
c. (c) the Contractor shall give the varied rate to the Engineer within not more than 30 days
from the date of instruction by the Engineer of the variation. The Engineer shall give his
comments on the varied rate within 15 days of receipt from the Contractor.

GCC 16.1 In case of change of laws and regulation after the deadline for submission of the Bid
Contract Price shall not be correspondingly increased or decreased and/or the Delivery Date
shall not be adjusted to the extent that Contractor has thereby been affected in the
performance of any of its obligations under the Contract.
GCC 22.1 The percentage to apply to the value of the work not completed, representing the Employer’s
additional cost for completing the Works, is 15%
P a g e 56 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
GCC 26.3 If any dispute or difference of any kind whatsoever shall arise between the Employer and
(Additional the Contractor in connection with or arising out of the Contract, or the execution of the
clause) Works whether during the progress of the work or after their completion and whether before
or after the termination, abandonment or breach of the Contract, it shall, in the first place, be
referred to and settled by the Engineer who shall, within a period of ninety days after being
requested by either party to do so give written notice of his decision to the Employer and the
Contractor. Such decision in respect of every matter so referred shall be final and binding
upon the Employer ,and the Contractor and shall forthwith be given effect to by the
Employer and by the Contractor, who shall proceed with the execution of the Works with all
due diligence whether the Employer or Contractor requires arbitration as hereinafter
provided, or not.
If the Engineer has given written notice of his decision to the Employer and the Contractor
and no claim to appeal has been communicated to him by either the Employer or the
Contractor within a period of Thirty days from receipt of such notice, the said decision shall
remain final and binding upon the Employer and the Contractor. If the Engineer shall fail to
give notice of his decision, as aforesaid, within a period of ninety days after being requested
as aforesaid or if either the Employer or the Contractor be dissatisfied with any such
decision then and in any such case either the Employer or the Contractor may within ninety
days after receiving notice of such decision or within Thirty days after the expiration of the
first named period of ninety days, as the case may be required that the matter or matters in
dispute be referred to Arbitrator. All disputes or differences in respect of which the decision,
if any of the Engineer has not become final and binding as aforesaid shall be finally settled
by the Arbitrator and its decision shall be final and binding.

No decision given by the Engineer in accordance with the foregoing provisions shall
disqualify him from being called as a witness and giving evidence before the authority or his
Authorized Representative on any matter whatsoever relevant to the dispute or difference
referred to the arbitrator as aforesaid. The reference to the Arbitrator may proceed
notwithstanding that the Works shall not then be or be alleged to be complete provided
always that the obligations of the Employer, the Engineer and the Contractor shall not be
altered by reason of the appeal being conducted during the progress of the Works.
GCC 27.1
(Additional The liquidated damages for the whole of the works are 0.1% of the final contract price per
clause 1) day. The maximum amount of liquidated damages for the whole of the works is 10% of the
total Contract price.
GCC 28.1 Confidentiality
The Contractor shall treat the Contract and everything in connection with it as private and
confidential. In particular the Contractor shall not publish or issue any information or
photograph concerning the Works and shall not use the site for any commercial purpose
except with the consent of the Engineer and Employer and subject to any conditions he may
impose.
B. Obligations of the employer
GCC 30.3 The documents to be provided by the employer and the Engineer are the following:

Custody of Drawings
The drawings shall remain in the sole custody of the Engineer, but one copy in A3 size
thereof shall be furnished to the Contractor free of charge. The Contractor shall provide and
make at his/her expense any further copies required by him/her.

The employer shall pay interim payments to the contractor as soon as the bank
releases finance to the employer.
The Contractor shall be deemed to have inspected and examined the site and its
surroundings and to have satisfied himself before submitting his/her Tender as to all matters

P a g e 57 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
GCC 31.1 necessary for the due performance of the Contract including the for and nature of the site,
and 43 geological, Hydrological, subsurface and climatic conditions, details, location and levels of
all existing and projected utility and services above and below ground., The nature and
carrying capacity of existing and projected roads, The extent and nature of the work,
materials, labor and all things necessary for the completion of the works. The access to and
egress from the site and the accommodation he may require, and in general shall be deemed
to have obtained all necessary information as the risks, contingencies and all other
circumstances which may influence or affect his/her \tender.

The employer shall when and wherever possible give information on the soil investigation
report for the initial guidance of the Contractor.
C. Obligations of the Contractor
GCC 34.1 1. The Contractor shall allocate adequate amount of experienced labour, all construction
(Additional materials, equipment, all machineries, & hand tools; including but not limited to
Clause) mixers, vibrators, water pumps, winches, crane etc. required to carry out the works as
per the specification and provisions made in this contract.
However; regarding site utilities i.e. water & electricity; the client shall provide utility
lines to the site but the consumption fees for water & electricity shall be borne by the
contractor. In the event where there is outage of supply for any reason in the provided
water & electricity lines the contractor shall supply for the utilities at its own cost
until the utility lines are functional again.
Furthermore the Contractor shall provide all resources timely so as to meet the
required rate of progress indicated in the work schedule.
2. The Contractor shall take full responsibility for the adequacy, stability and safety of
all site operations and methods of construction, provided that the Contractor shall not
be responsible, except as may be expressly provided in the contract, For the design
and specification of the permanent works, or the design or specification of any
temporary works prepared by the Engineer.
3. The Contractor shall within 24 ( Twenty Four) Hours inform the Employer and
Engineer of any error, omissions, fault, and other defect in the design of or
specifications for the works which are discovered when reviewing the Contract
documents or in the process of execution of the works.
GCC 38.1 Rates of Wages and Conditions of Labor
(Additional The Contractor shall pay rates of wages and observe employment conditions not less
clause 1) favorable than those established for the trade and industry where the work is being carried
out. In the absence of any established rates or conditions in the locality, the Contractor shall
follow those by other employers for similar trades and industries.
Burial of the Dead
The Contractor shall be responsible for the transport to his /her home of any expatriate
employee or members of their families who may die for any reason in Ethiopia. The
Contractor shall be responsible for arrangements for the burial of local employees who may
die while engaged upon the Works.

Visas and Permits

The Contractor shall be responsible for all arrangements and costs of obtaining visas, work
permits and other documents for his employees and shall comply with all immigration and
residence regulations of Ethiopia.

Repatriation of Employees
The Contractor shall be responsible for repatriation of all non-Ethiopian national employees
to their country of residence or to their point of recruitment and for their maintenance until
the time of the return.
GCC 39.3 The amount of aggregate liability shall be: the total contract value.

P a g e 58 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
The minimum insurance cover and deductibles shall be:
A.1.1.1.234 The mínimum cover for insurance of the Works, Plant and Materials is 110%
A.1.1.1.235 The maximum deductible for insurance of the Works, Plant and Materials is 500,000.
A.1.1.1.236 The minimum cover for insurance of Equipment is 100%
GCC 40.1
A.1.1.1.237 The maximum deductible for insurance of Equipment is 250,000.00
A.1.1.1.238 The minimum cover for insurance of property is 2,500,000.00
A.1.1.1.239 The maximum deductible for insurance of property is 2,500.000
A.1.1.1.240 The minimum cover for personal injury or death insurance is 500,000 with no
deductible
GCC 41.4 The period between Program updates upon the request of the engineer is 15 days.
The amount to be withheld by the employer for late submission of an updated Program is
1% of the payment.The payement shall be released upon final payement.
GCC 45.6 Safety Officer
The Contractor shall employ a full time qualified safety officer on site until the works have
been completed. The safety officer shall be responsible for compliance with the Contractor’s
site safety plan by all employees and shall hold regular safety meetings with all employees
and shall hold regular safety meetings with all employees. He shall be given authority to halt
any unsafe working methods or practices on site. All Contractors’ staff, the management,
Engineers staff and people visiting the site shall wear helmet while on site. The color of the
helmet shall be blue for the Contractors staff and yellow for Engineers staff.
GCC 58.1 The amount of the Performance Security shall be: 10% of the Contract Price
The types of acceptable Performance Securities are: shall be in bank
GCC 58.4 Guarantee/Insurance.
The currency shall be: Ethiopian Birr (ETB).
GCC 34 The contractor shall provide office space with adequate area with all the necessary utilities
(Additional including water, electricity, telephone, for Engineer's
Clauses) Representatives on site for the duration of the contract. Facilities required for the engineer's
office comprises of the following items. The Contractor shall be responsible for the cleaning
and maintenance the office space, furniture and equipment of the Engineer's office.
Equipment and materials
provided by the Contractor to the Engineer shall be the property of the
Contractor upon completion or termination of the project and shall be included on rates as
profit and overhead. The cost should include fixed and running costs.
Office Space:
• Resident Engineer Office 20m²
• Toilet with shower (attached to office) 4 m²
B. Office Equipment:
• Desk top RAM 4GB Memory 750GB ,core i3…............ 1
• HP Laser jet printer all in one (A4) ……….…………………….. 1
• All the necessary papers/A3, A4/ tonners, as per the request. And all the necessary routine
as well as full maintenance in case of failure.
C. Office Furniture /New/:
• Swivel Chair …………………………………..… 2
• Table……………………………………….……. 2
• Shelves……………………………………….… 1
• Filing Cabinet………………………………….. 1
• Framed Wall Soft Board (1.2x3.6m)……………. 1
D. Transport
The contractor shall give service to the engineer's representative from the site to Addis
Ababa.
E. Utilities /fixed plus running cost/
•One telephone line
• EVDO
• Electric power

P a g e 59 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
• Water
None of the Permanent Works shall be carried on during the night or on
Sundays, or holidays. But should the Contractor opt to work on such times he shall pay the
Engineer’s representatives on site overtime, hours factored in accordance to the Labor law.
The rates shall be fixed by the Engineer and payments shall be made to the Consultant
E. Payments to the Contractor
GCC 59.1 All payment to the Contractor under this Contract shall be made in Ethiopian Birr (ETB).
GCC 60.1 Advance payment shall Not be granted to the Contractor, upon signing of this contract.
GCC 60.2 The amount of the advance payment shall be: 0% (Zero Percent ) of the Contract Price.
GCC 60.9 The following provisions shall apply to the advance payment and the
advance payment security:
a. An Advance Payment Security shall be required. A n advance payment shall be
made within 15 days after the Effective Date.
b. The advance payment will be set off by the Public Body in equal installments
against the statements for the first months of the Works until the advance
payment has been fully set off.
c. The Advance Payment Security shall be in the amount and in the currency
proportional to the amount received.
d. The repayment of the advance payments shall take the form of deductions based on
the monthly claims
A.1.1.1.240.1 The advance payment (maximum of 20%) shall be repaid by means of
deductions from the installments and, if necessary, the balance due to the
Contractor. This repayment shall begin with the first installment and be
completed, at the very latest; by the time 80% of the amount of the contract has
been paid. Repayment shall be made in the same currency as the advance
payment.

The Advance payment will be repaid by deducting proportionate amounts from each interim
payment certificate (IPC) during the period starting from the first IPC to the 80 % of the
contract value.
Payment shall be subject to retention in the sum of 5% of value certified until completion of
the defect Liability Period which is 365 days after the date of temporary acceptance.

Delete sub clause 61.3 and add;

GCC 61.1,
When the Engineer has granted a Certificate or Certificates of Completion for the whole of
61.3
the Works, the Engineer shall, after allowing for the amount of all previous payments and
(Additional
after determining and allowing for any sum due to the Employer from the Contractor, certify
Clause)
as payable to the Contractor such a sum out of the balance so calculated as remaining due to
the Contractor as will leave to be retained by the employer a sum equal to 2.5 % of the value
of work executed of the complete sections of the Works. The retained money shall be
released after the end of 365 days Defect Liability Period.
GCC 62 The Contract shall not be subjected to Price adjustment.
GCC 63.1 The Contract is admeasurement contract.
GCC 64.1 The frequency of interim payment shall be floor by floor i.e. the contractor shall present all
interim payments upon completion of structural works of at least one floor.
The Contractor shall submit to the Engineer after the completion of structural works of at
least one floor, statements signed by the Contractor showing
a. The quantities and value of the work executed on Site.
b. The value of temporary work, as included in the Bill of Quantities and completed on Site.
c. An amount reflecting any changes in cost by virtue of any Act, Statute, Decree,
Regulation and the like applicable to the site/guaranteed by a mandated body/.

i. The Engineer shall, after checking and agreeing to the contents attach the statements to the

P a g e 60 | 63
Contract Document for Construction Client: of
Contractor:
GCC Clause
Section 8. Special Conditions of Contract
Reference
Interim Payment Certificate.
ii. The rates and prices, used to ascertain the values of permanent works, in such monthly
statements shall be those in the priced Bills of Quantities, in so far as such rates and prices
are in the opinion of the Engineer applicable.
iii. If the said Bill of Quantities do not, in the opinion of the Engineer, contain any rates or
prices applicable to some or any part of the work executed and there has not been a rate or
price fixed at the time when the statement is prepared, then temporary rates or prices shall
be assigned thereto by the Engineer.
iv. Neither the temporary rates or prices assigned under paragraph (iii) of this sub clause nor
the Quantities mentioned in the statement submitted under paragraph (i) of this sub clause
shall be binding on the Employer or the Contractor.
No payement shall be made for material on site.

g. The contractor shall submit an application for interim payment in four copies (takeoff
three copies) to the Engineer at the end of each month in a form approved by the Engineer.
The application shall include the following items, as applicable, which shall be taken in to
account in the sequence listed
i. The estimated contract value in local currency of the permanent works executed up to the
end of the month in question, obtained by applying the base unit rates and prices in the Bill
of Quantities to the quantities measured by the Engineer.
ii. The estimated contract value of the permanent works obtained as in above executed up to
the end of the previous month.
iii. The estimated contract value at base unit rates and prices expressed in local currency of
the permanent works for the month in question obtained by deduction (ii) from (i)
iv. Any amount to be withheld under the retention provisions)
v. Any credit or debit for the month in question in respect of materials on site intended for,
but not yet incorporated in, permanent works in the amount & under the conditions set forth
sub clause (2)
vi. Any other sum to which the contractor may be entitled under the contract
Interim Payment
The Contractor will be paid by The employer as soon as the bank releases finance to
the employer.,
GCC 64.5 After the receipt of the said application for interim payment it shall be approved or amended
(Additional such that, in the Engineer's opinion, the certificate reflects the amount due to the contractor
Clause) in accordance with the contract. In cases where there is a difference of opinion as to the
value of any item, the Engineer's view shall prevail. When the Engineer has determined the
amount due to the contractor, he shall issue to the Employer and the contractor a certificate
hereinafter called "Interim Payment Certificate" certifying the amount due to the contractor.

GCC 64.7 The frequency of interim payment shall be: floor by floor.
The draft Final Statement of Account shall be submitted at the latest at the moment of the
GCC 65.1
Contractor's application for the provisional acceptance certificate.
The Engineer shall prepare and sign the Final Statement of Account within 30 days from the
GCC 65.2
issue of the certificate of final acceptance referred to in GCC Clause 89.

P a g e 61 | 63
Contract Document for Construction Client: of
Contractor:

Bill of quantity and Technical Specification

P a g e 62 | 63
Contract Document for Construction Client: of
Contractor:

Drawings
Refer Annex - B

P a g e 63 | 63