Fidic Construction Contract 2nd Ed 2017 Red Book
Fidic Construction Contract 2nd Ed 2017 Red Book
GENERAL CONDITIONS
GUIDANCE FOR THE PREPARATION
OF PARTICULAR CONDITIONS AND ANNEXES:
FORMS OF SECURITIES
FORMS OF LETTER OF TENDER, LETTER OF
ACCEPTANCE, CONTRACT AGREEMENT AND DISPUTE
ADJUDICATION/AVOIDANCE AGREEMENT
FIDIC is the only Copyright owner of FIDIC publications, which are protected by the Berne
Convention for the Protection of Literary and Artistic Works, international conventions such
as TRIPS and the WIPO copyright treaty and national intellectual property laws. No part of
a FIDIC publication can be reproduced, translated, adapted, stored in a retrieval system or
communicated, in any form or by any means, mechanical, electronic, magnetic, photocopying,
recording or otherwise, without prior permission in writing from FIDIC. The version in English is
considered by FIDIC as the official and authentic text for the purposes of translation.
DISCLAIMER
While FIDIC aims to ensure that its publications represent the best in business practice, the
Federation accepts or assumes no liability or responsibility for any events or the consequences
thereof that derive from the use of its publications. FIDIC publications are provided “as is”,
without warranty of any kind, either express or implied, including, without limitation, warranties of
merchantability, fitness for a particular purpose and non-infringement. FIDIC publications are not
exhaustive and are only intended to provide general guidance. They should not be relied upon in
a specific situation or issue. Expert legal advice should be obtained whenever appropriate, and
particularly before entering into or terminating a contract.
© FIDIC 2017
CONTENTS
Acknowledgements
Notes
General Conditions
Content...................................................................................................... i
Clauses 1 to 21.......................................................................................... 1
Appendix: General Conditions of Dispute Avoidance/Adjudication
Agreement............................................................................................. 107
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Contents.................................................................................................... 1
Introductory Guidance Notes......................................................................2
Particular Conditions Part A – Contract Data...............................................3
Particular Conditions Part B – Special Provisions........................................8
Notes on the Preparation of Tender Documents............................10
Notes on the Preparation of Special Provisions.............................13
Clauses.......................................................................................14
Advisory Notes to Users of FIDIC Contracts Where the Project is to
Include Building Information Modelling Systems.......................................53
Annexes: Forms of Securities..................................................................................56
Letter of Tender.......................................................................................... i
Letter of Acceptance..................................................................................ii
Contract Agreementiii
Dispute Avoidance/Adjudication Agreementiv
© FIDIC 2017
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
ACKNOWLEDGEMENTS
Australia (task group principal drafter); Darko Plamenac, Consulting Engineer, Serbia;
Jan Ziepke, Consulting Engineer, Germany; and Zoltán Záhonyi, Z&Partners
Consulting Engineers, Hungary (Contracts Committee liaison).
The preparation was carried out under the general direction of the FIDIC Contracts
Committee:
Philip Jenkinson, Atkins, UK (past Chairman); Zoltán Záhonyi, Z&Partners Consulting
Engineers, Hungary (Chairman); Vincent Leloup, Exequatur, France; Kaj Möller, SWECO,
Sweden; Siobhan Fahey, Consulting Engineer, Ireland; Mike Roberts, Mott
MacDonald, UK; Des Barry, Consulting Engineer, Ireland; Christoph Theune, GKW
Consult GmbH, Germany; Enrico Vink, FIDIC Managing Director; and Christophe Sisto,
FIDIC Design & Edition Manager.
Advisory Notes to Users of FIDIC Contracts Where the Project is Using Building
Information Modelling Systems were provided by:
Anthony Barry, Aurecon, Australia (FIDIC Executive Committee), Andrew Read, Pedersen
Read Consulting, New Zealand (chairman FIDIC Business Practice Committee) and Stephen
Jenkins, Aurecon, New Zealand (chairman FIDIC Risk, Liability and Quality Committee).
© FIDIC 2017
Special Advisers to the Contracts Committee provided invaluable and continued
support in the various drafting and revision stages:
Christopher Seppälä, White & Case LLP, France (legal adviser, assisted by Dimitar
Kondev, White & Case LLP, France); Nael G Bunni, Ireland (risk and insurance
adviser); Axel-V. Jaeger, Germany; Michael Mortimer Hawkins, UK/Sweden; and
Christopher Wade, UK.
Drafts were reviewed by many persons and organisations, including those listed
below. Their comments were duly studied by the FIDIC Contracts Committee’s
Updates Special Group and Update Task Groups and, where considered appropriate,
have influenced the wording of the clauses.
Mahmoud Abu Hussein, Dolphin Energy, United Arab Emirates; Ihab Abu-Zahra,
CRC Hassan Dorra, Egypt; Mushtaq Ahmad Smore, Engineer, Pakistan; Richard
Appuhn, Engineer, Italy; Ulrik Bang Olsen, Bang Olsen & Partners Law Firm P/S,
Denmark; Hartmut Bruehl, Engineer, Germany; Donald Charrett, MTECC, Australia;
Edward Corbett, Corbett & Co International Construction Lawyers Ltd, UK; Cremona
Cotovelea, SCPA Tecuci-Paltineanu, Romania; Mark Etheridge, UWP Consulting
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Pty (Ltd), UK; European International Contractors, Berlin, Germany; Ciaran Fahy,
Engineer, Ireland; Stephane Giraud, Egis, France; Karen Gough, 39 Essex
Chambers, UK; Sarwono Hardjomuljadi, Special Adviser to the Minister of Public
Works, Indonesia; Sebastian Hoek, Kanzlei Dr.Hök Stieglmeier & Kollegen Berlin,
Germany; Tomohide Ichiguchi, JICA, Japan; Reza Ikani, Tehran Berkeley Group of
Companies, Iran; Levent Irmak, MC2 Modern, Turkey; Gordon Jaynes, Lawyer,
UK; Nabeel Khokhar, Driver Group, UK; Humphrey Lloyd, Queen Mary University
London, UK; Liu Luobing, Shanghai SICC Planning & Architectural Design,
Republic of China; Husni Madi, Shura Construction Management, Jordan; Malith
Mendis, ACES, Sri Lanka; Benjamin Mellors, Holman Fenwick Willan LLP, UK;
Christopher Miers, Probyn Miers, UK; Henry Musonda, Kiran & Musonda
Associates, Zambia; Kjeld B Nielsen, Sweco, Denmark; Patrizia Palmitessa-Savric,
Ginder Palmitessa Pty Ltd, Botswana; James Perry, PS Consulting, France; Mikko
Pulkkinen, Presentio Oy, Finland; John Ritchie, Consultant, Canada; Munther
Sakhet, Allied Planning & Engineering Co, Jordan; Michael Sergeant, HFW, UK;
Christian Siemer, Fichtner Consulting Engineers, Germany; Evgeny Smirnov,
EBRD, UK; Jakob B. Sorensen, M Holst, Advokater, Denmark; Benjamin Valloire,
Syntec Ingénierie, France; Kitty Villani, Council of Europe Development Bank,
France; Ahmed Faty Waly, WALY Arbitration, Egypt.
Acknowledgement of all reviewers above does not mean that such persons or
organisations approve the wording of all clauses.
FIDIC very much appreciates the time and effort devoted by all the above persons.
The ultimate decision on the form and content of the document rests with FIDIC.
© FIDIC 2017
NOTES
This Second Edition of the Conditions of Contract for Construction has been published
by the Fédération Internationale des Ingénieurs-Conseils (FIDIC) as an update of the
FIDIC 1999 Conditions of Contract for Construction (Red Book), First Edition.
Along with the FIDIC 1999 Yellow Book (the Conditions of Contract for Plant and
Design-Build) and the FIDIC 1999 Silver Book (the Conditions of Contract for
EPC/ Turnkey Projects), the FIDIC 1999 Red Book has been in widespread use
for nearly two decades. In particular, it has been recognised for, among other things,
its principles of balanced risk sharing between the Employer and the Contractor in
projects where the Contractor constructs the works in accordance with a design
provided by the Employer. However, the works may include some elements of
Contractor-designed civil, mechanical, electrical and/or construction works.
This Second Edition of the FIDIC Red Book continues FIDIC’s fundamental principles
of balanced risk sharing while seeking to build on the substantial experience
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
gained from its use over the past 18 years. For example, this edition provides:
1) greater detail and clarity on the requirements for notices and other
communications;
It should be noted, that the General Conditions and the Particular Conditions (Part
A – Contract Data and Part B – Special Provisions) are all part of the Conditions of
Contract.
© FIDIC 2017
This publication begins with a series of comprehensive flow charts which typically
show, in visual form, the sequences of activities which characterise the FIDIC
Construction form of contract. The charts are illustrative, however, and must not be
taken into consideration in the interpretation of the Conditions of Contract.
This publication also includes a number of sample forms to help both Parties to
develop a common understanding of what is required by third parties such as
providers of securities and guarantees.
Drafters of contract documents are reminded that the General Conditions of all FIDIC
contracts are protected by copyright and trademark and may not be changed
without specific written consent, usually in the form of a licence to amend, from FIDIC.
If drafters wish to amend the provisions found in the General Conditions, the place for
doing this is in the Particular Conditions Part B – Special Provisions, as mentioned
above, and not by making changes in the General Conditions as published.
FIDIC considers the official and authentic texts to be the versions in the English
language.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
© FIDIC 2017
Typical Sequence of Principal Events During Contracts for Construction
1. The Time for Completion is to be stated (in the Contract Data) as a number of days, to which is added
any extensions of time under Sub-Clause 8.5.
2. In order to indicate the sequence of events, the above diagram is based upon the example of the Contractor
failing to comply with Sub-Clause 8.2.
3. The Defects Notification Period is to be stated (in the Contract Data) as a number of days, to which is added
any extensions under Sub-Clause 11.3.
4. Depending on the type of Works, Tests after Completion may also be required.
11 Notifying of Defects
Delay attributable to the Contractor2
© FIDIC 2017
Typical Sequence of Payment Events Envisaged in Clause 14
Each of the
≤56d
monthly (or
otherwise)
interim
payments ≤28d
The final
Engineer verifies the
payment statement, Contractor
submits information
≤28d ≤56d
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
14.11.1 Contractor
submits draft final 14.11.2 Contractor submits 14.13 Engineer issues 14.7 Employer
Statement to the Engineer Final Statement and the Final Payment makes payment
14.12 discharge Certificate
© FIDIC 2017
Typical Sequence of Events in Agreement or Determination under Sub-Clause 3.7
Scenario 11
Engineer starts performing duties Sub-Clause 3.7 Parties’ agreement Sub-Clause
Notice
3.7.1
of error by a Party/Engineer Sub-Clause 3.7.4
Consultations
Scenario 22
Engineer starts Parties advise the Engineer’s Notice Notice of
performing duties Engineer: no agreement of determination Dissatisfaction
Sub-Clause 3.7 Sub-Clause 3.7.1(b) Sub-Clause 3.7.2 Sub-Clause
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
3.7.5
No Notice
of error
Scenario 33
Engineer starts performing duties Sub-Clause
No agreement
3.7 between the Parties Sub-Clause
Engineer’s
3.7.1(a)NoticeEngineer’s Notice of determinationof corre
Sub-Clause 3.7.2determination
Sub-Clause 3.7.4
1. Agreement is reached within 42 days, error found in the Engineer’s Notice of agreement and corrected.
2. The Parties’ early advice that agreement cannot be reached and so Engineer’s determination is necessary,
no error in Engineer’s determination.
3. No agreement within 42 days, Engineer determines within 42 days, error found in the Engineer’s
determination and corrected.
© FIDIC 2017
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
©
FIDIC 2017
GENERAL CONDITIONS
General Conditions
CONTENTS
FORMS
1 GENERAL PROVISIONS.............................................................................1
1.1 Definitions
1.2 Interpretation
1.3 Notices and Other Communications
1.4 Law and Language
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
2 THE EMPLOYER.......................................................................................14
3 THE ENGINEER........................................................................................ 16
4 THE CONTRACTOR..................................................................................22
GUIDANCE
5 SUBCONTRACTING.................................................................................37
5.1 Subcontractors
5.2 Nominated Subcontractors
CONDITIONS
6.12 Key Personnel
GENERAL
7 PLANT, MATERIALS AND WORKMANSHIP..............................................42
GUIDANCE
7.2 Samples
7.3 Inspection
7.4 Testing by the Contractor
7.5 Defects and Rejection
7.6 Remedial Work
7.7 Ownership of Plant and Materials
7.8 Royalties
FORMS
8 COMMENCEMENT, DELAYS AND SUSPENSION...................................46
8.3 Programme
8.4 Advance Warning
8.5 Extension of Time for Completion
8.6 Delays Caused by Authorities
8.7 Rate of Progress
8.8 Delay Damages
8.9 Employer’s Suspension
8.10 Consequences of Employer’s Suspension
8.11 Payment for Plant and Materials after Employer’s Suspension
8.12 Prolonged Suspension
8.13 Resumption of Work
9 TESTS ON COMPLETION........................................................................51
CONDITIONS
GENERAL
15.1 Notice to Correct
15.2 Termination for Contractor’s Default
15.3 Valuation after Termination for Contractor’s Default
15.4 Payment after Termination for Contractor’s Default
15.5 Termination for Employer’s Convenience
GUIDANCE
15.6 Valuation after Termination for Employer’s Convenience
15.7 Payment after Termination for Employer’s Convenience
FORMS
16.1 Suspension by Contractor
16.2 Termination by Contractor
16.3 Contractor’s Obligations After Termination
16.4 Payment after Termination by Contractor
18 EXCEPTIONAL EVENTS...........................................................................90
19 INSURANCE..............................................................................................92
20.1 Claims
20.2 Claims For Payment and/or EOT
21.6 Arbitration
21.7 Failure to Comply with DAAB’s Decision
21.8 No DAAB In Place
APPENDIX........................................................................................................... 107
FORMS
INDEX OF SUB-CLAUSES.................................................................................124
Gen
1 eral Provisions
GUIDANCE
1.1
Definitions In the Contract the following words and expressions shall have the meanings
stated, except where the context requires otherwise
1.1.1 “Accepted Contract Amount” means the amount accepted in the Letter of
Acceptance for the execution of the Works in accordance with the Contract.
FORMS
1.1.2 “Advance Payment Certificate” means a Payment Certificate issued
by the Engineer for advance payment under Sub-Clause 14.2.2
[Advance Payment Certificate].
1.1.4 “Base Date” means the date 28 days before the latest date for
submission of the Tender.
1.1.5 “Bill of Quantities” means the document entitled bill of quantities (if any)
included in the Schedules.
1.1.6 “Claim” means a request or assertion by one Party to the other Party for
an entitlement or relief under any Clause of these Conditions or
otherwise in connection with, or arising out of, the Contract or the
execution of the Works.
1.1.7 “Commencement Date” means the date as stated in the Engineer’s Notice
issued under Sub-Clause 8.1 [Commencement of Works].
1.1.10 “Contract” means the Contract Agreement, the Letter of Acceptance, the
Letter of Tender, any addenda referred to in the Contract Agreement,
these Conditions, the Specification, the Drawings, the Schedules, the
Contractor’s Proposal, the JV Undertaking (if applicable) and the further
documents (if any) which are listed in the Contract Agreement or in the
Letter of Acceptance.
1.1.12 “Contract Data” means the pages, entitled contract data which
constitute Part A of the Particular Conditions.
1.1.13 “Contract Price” means the price defined in Sub-Clause 14.1 [The Contract
Price].
such person(s).
1.1.19 “Cost” means all expenditure reasonably incurred (or to be incurred) by the
Contractor in performing the Contract, whether on or off the Site,
including taxes, overheads and similar charges, but does not include profit.
Where the Contractor is entitled under a Sub-Clause of these Conditions to
payment of Cost, it shall be added to the Contract Price.
1.1.20 “Cost Plus Profit” means Cost plus the applicable percentage for profit
stated in the Contract Data (if not stated, five percent (5%)). Such
percentage shall only be added to Cost, and Cost Plus Profit shall only
be added to the Contract Price, where the Contractor is entitled under a
Sub-Clause of these Conditions to payment of Cost Plus Profit.
1.1.21 “Country” means the country in which the Site (or most of it) is located,
where the Permanent Works are to be executed.
CONDITIONS
GENERAL
Part are deemed to have been taken over by the Employer.
1.1.26 “Daywork Schedule” means the document entitled daywork schedule (if
any) included in the Contract, showing the amounts and manner of
GUIDANCE
payments to be made to the Contractor for labour, materials and
equipment used for daywork under Sub-Clause 13.5 [Daywork].
1.1.27 “Defects Notification Period” or “DNP” means the period for notifying
defects and/or damage in the Works or a Section or a Part (as the case
may be) under Sub-Clause 11.1 [Completion of Outstanding Work and
Remedying Defects], as stated in the Contract Data (if not stated, one year),
FORMS
and as may be extended under Sub-Clause 11.3 [Extension of Defects
Notification Period]. This period is calculated from the Date of Completion of
the Works or Section or Part.
1.1.28 “Delay Damages” means the damages for which the Contractor shall be
liable under Sub-Clause 8.8 [Delay Damages] for failure to comply with
Sub-Clause 8.2 [Time for Completion].
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(a) one Party makes a claim against the other Party (which may be a
Claim, as defined in these Conditions, or a matter to be
determined by the Engineer under these Conditions, or otherwise);
(b) the other Party (or the Engineer under Sub-Clause 3.7.2
[Engineer’s Determination]) rejects the claim in whole or in part;
and
(c) the first Party does not acquiesce (by giving a NOD under Sub-Clause
3.7.5 [Dissatisfaction with Engineer’s determination] or otherwise),
provided however that a failure by the other Party (or the Engineer) to
oppose or respond to the claim, in whole or in part, may constitute a
rejection if, in the circumstances, the DAAB or the arbitrator(s), as the case
may be, deem it reasonable for it to do so.
1.1.30 “Drawings” means the drawings of the Works included in the Contract,
and any additional and modified drawings issued by (or on behalf of) the
Employer in accordance with the Contract.
1.1.31 “Employer” means the person named as the employer in the Contract Data
and the legal successors in title to this person.
1.1.35 “Engineer” means the person named in the Contract Data appointed by
the Employer to act as the Engineer for the purposes of the Contract, or
any replacement appointed under Sub-Clause 3.6 [Replacement of the
Engineer].
GUIDANCE
1.1.42 “Foreign Currency” means a currency in which part (or all) of the
Contract Price is payable, but not the Local Currency.
1.1.47 “JV Undertaking” means the letter provided to the Employer as part of
the Tender setting out the legal undertaking between the two or more
persons constituting the Contractor as a JV. This letter shall be signed
by all the persons who are members of the JV, shall be addressed to the
Employer and shall include:
CONDITIONS
GENERAL
Specification.
1.1.49 “Laws” means all national (or state or provincial) legislation, statutes,
acts, decrees, rules, ordinances, orders, treaties, international law and other
laws, and regulations and by-laws of any legally constituted public
authority.
GUIDANCE
1.1.50 “Letter of Acceptance” means the letter of formal acceptance, signed
by the Employer, of the Letter of Tender, including any annexed
memoranda comprising agreements between and signed by both
Parties. If there is no such letter of acceptance, the expression “Letter of
Acceptance” means the Contract Agreement and the date of issuing or
receiving the Letter of Acceptance means the date of signing the
FORMS
Contract Agreement.
1.1.51 “Letter of Tender” means the letter of tender, signed by the Contractor,
stating the Contractor’s offer to the Employer for the execution of the Works.
1.1.53 “Materials” means things of all kinds (other than Plant), whether on the Site
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
1.1.55 “No-objection” means that the Engineer has no objection to the Contractor’s
Documents, or other documents submitted by the Contractor under
these Conditions, and such Contractor’s Documents or other documents
may be used for the Works.
1.1.57 “Notice of Dissatisfaction” or “NOD” means the Notice one Party may give
to the other Party if it is dissatisfied, either with an Engineer’s determination
under Sub-Clause 3.7 [Agreement or Determination] or with a DAAB’s
decision under Sub-Clause 21.4 [Obtaining DAAB’s Decision].
1.1.58 “Part” means a part of the Works or part of a Section (as the case may
be) which is used by the Employer and deemed to have been taken over
under Sub-Clause 10.2 [Taking Over Parts].
1.1.60 “Party” means the Employer or the Contractor, as the context requires.
“Parties” means both the Employer and the Contractor.
1.1.65 “Plant” means the apparatus, equipment, machinery and vehicles (including
any components) whether on the Site or otherwise allocated to the Contract
and intended to form or forming part of the Permanent Works.
1.1.69 “Retention Money” means the accumulated retention moneys which the
Employer retains under Sub-Clause 14.3 [Application for Interim Payment]
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
1.1.73 “Section” means a part of the Works specified in the Contract Data as a
Section (if any).
1.1.74 “Site” means the places where the Permanent Works are to be executed
and to which Plant and Materials are to be delivered, and any other
places specified in the Contract as forming part of the Site.
1.1.75 “Special Provisions” means the document (if any), entitled special
provisions which constitutes Part B of the Particular Conditions.
CONDITIONS
GENERAL
1.1.79 “Taking-Over Certificate” means a certificate issued (or deemed to be
issued) by the Engineer in accordance with Clause 10 [Employer’s
Taking Over].
1.1.80 “Temporary Works” means all temporary works of every kind (other
GUIDANCE
than Contractor’s Equipment) required on Site for the execution of the
Works.
1.1.81 “Tender” means the Letter of Tender, the Contractor’s Proposal, the JV
Undertaking (if applicable), and all other documents which the
Contractor submitted with the Letter of Tender, as included in the
Contract.
FORMS
1.1.82 “Tests after Completion” means the tests (if any) which are stated in
the Specification and which are carried out in accordance with the
Special Provisions after the Works or a Section (as the case may be) are
taken over under Clause 10 [Employer’s Taking Over].
1.1.83 “Tests on Completion” means the tests which are specified in the Contract
or agreed by both Parties or instructed as a Variation, and which are carried
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
out under Clause 9 [Tests on Completion] before the Works or a Section (as
the case may be) are taken over under Clause 10 [Employer’s Taking Over].
1.1.84 “Time for Completion” means the time for completing the Works or a
Section (as the case may be) under Sub-Clause 8.2 [Time for Completion],
as stated in the Contract Data as may be extended under Sub-Clause
8.5 [Extension of Time for Completion], calculated from the
Commencement Date.
1.1.87 “Works” mean the Permanent Works and the Temporary Works, or either of
them as appropriate.
1.2
Interpretation In the Contract, except where the context requires otherwise:
(a) words indicating one gender include all genders; and “he”, “his” and
“himself” shall be read as “he/she”, “his/her” and “himself/herself”
respectively;
(b) words indicating the singular also include the plural and words indicating the
plural also include the singular;
(e) “may” means that the Party or person referred to has the choice of
whether to act or not in the matter referred to;
General Conditions © FIDIC 2017
7
(f) “shall” means that the Party or person referred to has an obligation under the
Contract to perform the duty referred to;
CONDITIONS
GENERAL
(g) “consent” means that the Employer, the Contractor or the Engineer (as
the case may be) agrees to or gives permission for, the requested
matter;
(h) “including”, “include” and “includes” shall be interpreted as not being limited
GUIDANCE
(j) “execute the Works” or “execution of the Works” means the construction
FORMS
and completion of the Works and the remedying of any defects (and shall be
deemed to include design to the extent, if any, specified in the Contract)
In any list in these Conditions, where the second-last item of the list is
followed by “and” or “or” or “and/or” then all of the list items going before
this item shall also be read as if they are followed by “and” or “or” or “and/or”
(as the case may be).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The marginal words and other headings shall not be taken into consideration
in the interpretation of these Conditions.
1.3
Notices and
Other Communications Wherever these Conditions provide for the giving of a Notice (including
a Notice of Dissatisfaction) or the issuing, providing, sending, submitting
or transmitting of another type of communication (including acceptance,
acknowledgement, advising, agreement, approval, certificate, Claim,
consent, decision, determination, discharge, instruction, No-objection,
record(s) of meeting, permission, proposal, record, reply, report, request,
Review, Statement, statement, submission or any other similar type of
communication), the Notice or other communication shall be in writing and:
CONDITIONS
GENERAL
it shall have effect when it is received (or deemed to have been received) at
the recipient’s current address under sub-paragraph (d) above. An
electronically transmitted Notice or other communication is deemed to have
been received on the day after transmission, provided no non-delivery
notification was received by the sender.
GUIDANCE
All Notices, and all other types of communication as referred to above, shall
not be unreasonably withheld or delayed.
FORMS
Engineer as stated under these Conditions or elsewhere in the Contract.
1.4
Law and Language The Contract shall be governed by the law of the country (or other jurisdiction)
stated in the Contract Data (if not stated, the law of the Country),
excluding any conflict of law rules.
The ruling language of the Contract shall be that stated in the Contract Data
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(if not stated, the language of these Conditions). If there are versions of any
part of the Contract which are written in more than one language, the version
which is in the ruling language shall prevail.
The language for communications shall be that stated in the Contract Data.
If no language is stated there, the language for communications shall be the
ruling language of the Contract.
1.5
Priority of Documents The documents forming the Contract are to be taken as mutually explanatory
of one another. If there is any conflict, ambiguity or discrepancy, the
priority of the documents shall be in accordance with the following
sequence:
1.7
Assignment Neither Party shall assign the whole or any part of the Contract or any
benefit or interest in or under the Contract. However, either Party:
FORMS
(a) may assign the whole or any part of the Contract with the prior
agreement of the other Party, at the sole discretion of such other
Party; and
(b) may, as security in favour of a bank or financial institution, assign
the Party’s right to any moneys due, or to become due, under the
Contract without the prior agreement of the other Party.
1.8
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall keep at all times, on the Site, a copy of:
CONDITIONS
GENERAL
or Instructions The Contractor shall give a Notice to the Engineer whenever the Works are
likely to be delayed or disrupted if any necessary drawing or instruction is
not issued to the Contractor within a particular time, which shall be
reasonable. The Notice shall include details of the necessary drawing or
instruction, details of why and by when it should be issued, and details of
the nature and amount of the delay or disruption likely to be suffered if it
GUIDANCE
is late.
FORMS
However, if and to the extent that the Engineer’s failure was caused by
any error or delay by the Contractor, including an error in, or delay in the
submission of, any of the Contractor’s Documents, the Contractor shall
not be entitled to such EOT and/or Cost Plus Profit.
1.10
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Employer’s Use of
Contractor’s Documents As between the Parties, the Contractor shall retain the copyright and other
intellectual property rights in the Contractor’s Documents (and other design
documents, if any, made by (or on behalf of) the Contractor).
The Contractor shall be deemed (by signing the Contract Agreement) to give
to the Employer a non-terminable transferable non-exclusive royalty-free
licence to copy, use and communicate the Contractor’s Documents (and
such other design documents, if any), including making and using
modifications of them. This licence shall:
1.11
Contractor’s Use of
GUIDANCE
Employer’s Documents As between the Parties, the Employer shall retain the copyright and other
intellectual property rights in the Specification and Drawings and other
documents made by (or on behalf of) the Employer. The Contractor may, at
the Contractor’s cost, copy, use and communicate these documents for the
purposes of the Contract.
These documents (in whole or in part) shall not, without the Employer’s
FORMS
1.12
Confidentiality The Contractor shall disclose all such confidential and other information
as the Engineer may reasonably require in order to verify the
Contractor’s compliance with the Contract.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Employer and the Engineer shall treat all information provided by
the Contractor and marked “confidential”, as confidential. The Employer
shall not disclose or permit to be disclosed any such information to third
parties, except as may be necessary when exercising the Employer’s
rights under Sub-Clause 15.2 [Termination for Contractor’s Default].
1.13
Compliance with Laws The Contractor and the Employer shall, in performing the Contract, comply
with all applicable Laws. Unless otherwise stated in the Specification:
(a) the Employer shall have obtained (or shall obtain) the planning,
zoning or building permit or similar permits, permissions, licences
and/or approvals for the Permanent Works, and any other permits,
permissions, licenses and/or approvals described in the Specification
as having been (or being) obtained by the Employer. The
Employer shall indemnify and hold the Contractor harmless
against and from the consequences of any delay or failure to do so,
unless the failure is caused by the Contractor’s failure to comply
with sub-paragraph (c) below;
CONDITIONS
GENERAL
approvals, as required by the Laws in relation to the execution of
the Works. The Contractor shall indemnify and hold the Employer
harmless against and from the consequences of any failure to do so
unless the failure is caused by the Employer’s failure to comply with
Sub-Clause 2.2 [Assistance];
(c) within the time(s) stated in the Specification the Contractor shall
GUIDANCE
provide such assistance and all documentation, as described in
the Specification or otherwise reasonably required by the
Employer, so as to allow the Employer to obtain any permit,
permission, licence or approval under sub-paragraph (a) above;
and
(d) the Contractor shall comply with all permits, permissions, licences
and/or approvals obtained by the Employer under sub-paragraph (a)
FORMS
above.
If, having complied with sub-paragraph (c) above, the Contractor suffers
delay and/or incurs Cost as a result of the Employer’s delay or failure to
obtain any permit, permission, licence or approval under sub-paragraph (a)
above, the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or EOT] to EOT and/or payment of such Cost
Plus Profit.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
1.14
Joint and Several Liability If the Contractor is a Joint Venture:
(a) the members of the JV shall be jointly and severally liable to the
Employer for the performance of the Contractor’s obligations
under the Contract;
(b) the JV leader shall have authority to bind the Contractor and each
member of the JV; and
(c) neither the members nor (if known) the scope and parts of the Works
to be carried out by each member nor the legal status of the JV
shall be altered without the prior consent of the Employer (but such
consent shall not relieve the altered JV from any liability under sub-
paragraph
(a)above).
1.15
Limitation of Liability Neither Party shall be liable to the other Party for loss of use of any Works,
loss of profit, loss of any contract or for any indirect or consequential loss
or damage which may be suffered by the other Party in connection with
the Contract, other than under:
This Sub-Clause shall not limit liability in any case of fraud, gross negligence,
deliberate default or reckless misconduct by the defaulting Party.
1.16
Contract Termination Subject to any mandatory requirements under the governing law of the
Contract, termination of the Contract under any Sub-Clause of these
Conditions shall require no action of whatsoever kind by either Party
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
2.1
Th
2 e Employer
Right of Access to the Site The Employer shall give the Contractor right of access to, and possession
of, all parts of the Site within the time (or times) stated in the Contract
Data. The right and possession may not be exclusive to the Contractor.
If, under the Contract, the Employer is required to give (to the Contractor)
possession of any foundation, structure, plant or means of access, the
Employer shall do so in the time and manner stated in the Specification.
However, the Employer may withhold any such right or possession until the
Performance Security has been received.
If no such time is stated in the Contract Data, the Employer shall give the
Contractor right of access to, and possession of, those parts of the Site
within such times as may be required to enable the Contractor to
proceed in accordance with the Programme or, if there is no Programme at
that time, the initial programme submitted under Sub-Clause 8.3
[Programme].
However, if and to the extent that the Employer’s failure was caused by
any error or delay by the Contractor, including an error in, or delay in the
submission of, any of the applicable Contractor’s Documents, the Contractor
shall not be entitled to such EOT and/or Cost Plus Profit.
2.2
Assistance If requested by the Contractor, the Employer shall promptly provide
reasonable assistance to the Contractor so as to allow the Contractor to
obtain:
CONDITIONS
GENERAL
(b) any permits, permissions, licences or approvals required by the Laws
of the Country (including information required to be submitted by
the Contractor in order to obtain such permits, permissions,
licences or approvals):
(i) which the Contractor is required to obtain under Sub-Clause
1.13 [Compliance with Laws];
GUIDANCE
(ii) for the delivery of Goods, including clearance through
customs; and
(iii) for the export of Contractor’s Equipment when it is removed from
the Site.
2.3
FORMS
Employer’s Personnel and
Other Contractors The Employer shall be responsible for ensuring that the Employer’s Personnel
and the Employer’s other contractors (if any) on or near the Site:
2.4
Employer’s Financial
Arrangements The Employer’s arrangements for financing the Employer’s obligations under
the Contract shall be detailed in the Contract Data.
If the Contractor:
Items of Reference The Employer shall have made available to the Contractor for information,
before the Base Date, all relevant data in the Employer’s possession on
the topography of the Site and on sub-surface, hydrological, climatic and
environmental conditions at the Site. The Employer shall promptly make
available to the Contractor all such data which comes into the
Employer’s possession after the Base Date.
GUIDANCE
The original survey control points, lines and levels of reference (the “items of
reference” in these Conditions) shall be specified on the Drawings and/or in
the Specification or issued to the Contractor by a Notice from the Engineer.
2.6
Employer-Supplied Materials
FORMS
and Employer’s Equipment If Employer-Supplied Materials and/or Employer’s Equipment are listed in
the Specification for the Contractor’s use in the execution of the Works,
the Employer shall make such materials and/or equipment available to
the Contractor in accordance with the details, times, arrangements, rates
and prices stated in the Specification.
whilst any of the Contractor’s Personnel is operating it, driving it, directing it,
using it, or in control of it.
3.1
Th
3
Engineer
e
The Engineer The Employer shall appoint the Engineer, who shall carry out the duties
assigned to the Engineer in the Contract.
The Engineer shall be vested with all the authority necessary to act as
the Engineer under the Contract.
If the Engineer is a legal entity, a natural person employed by the Engineer shall
be appointed and authorised to act on behalf of the Engineer under the
Contract.
The Engineer (or, if a legal entity, the natural person appointed to act on
its behalf) shall be:
3.2
Engineer’s Duties
and Authority Except as otherwise stated in these Conditions, whenever carrying out
duties or exercising authority, specified in or implied by the Contract, the
Engineer shall act as a skilled professional and shall be deemed to act for
the Employer.
16 © FIDIC 2017 Conditions of Contract for Construction
The Engineer shall have no authority to amend the Contract or, except
as otherwise stated in these Conditions, to relieve either Party of any
CONDITIONS
GENERAL
duty, obligation or responsibility under or in connection with the Contract.
GUIDANCE
Conditions. There shall be no requirement for the Engineer to obtain the
Employer’s consent before the Engineer exercises his/her authority under
Sub-Clause
3.7 [Agreement or Determination]. The Employer shall not impose further
constraints on the Engineer’s authority.
FORMS
which the Employer’s consent is required, then (for the purposes of the
Contract) such consent shall be deemed to have been given.
shall not relieve the Contractor from any duty, obligation or responsibility
the Contractor has under or in connection with the Contract.
3.3
The Engineer’s
Representative The Engineer may appoint an Engineer’s Representative and delegate to
him/her in accordance with Sub-Clause 3.4 [Delegation by the Engineer]
the authority necessary to act on the Engineer’s behalf at the Site, except to
replace the Engineer’s Representative.
3.4
Delegation by
the Engineer The Engineer may from time to time assign duties and delegate authority to
assistants, and may also revoke such assignment or delegation, by
giving a Notice to the Parties, describing the assigned duties and the
delegated authority of each assistant. The assignment, delegation or
revocation shall not take effect until this Notice has been received by both
Parties. However, the Engineer shall not delegate the authority to:
Each assistant, to whom duties have been assigned or authority has been
respond, within
7 days after receiving the Contractor’s Notice, reversing or varying the
assistant’s instruction or Notice (as the case may be).
3.5
Engineer’s Instructions The Engineer may issue to the Contractor (at any time) instructions which
may be necessary for the execution of the Works, all in accordance with the
FORMS
Contract. The Contractor shall only take instructions from the Engineer,
or from the Engineer’s Representative (if appointed) or an assistant to
whom the appropriate authority to give instruction has been delegated
under Sub-Clause 3.4 [Delegation by the Engineer].
3.6
Replacement of
the Engineer If the Employer intends to replace the Engineer, the Employer shall, not less
than 42 days before the intended date of replacement, give a Notice to
the Contractor of the name, address and relevant experience of the
intended replacement Engineer.
If the Contractor does not respond within 14 days after receiving this Notice,
by giving a Notice stating an objection to such replacement with reasons,
the Contractor shall be deemed to have accepted the replacement.
The Employer shall not replace the Engineer with a person (whether a
legal entity or a natural person) against whom the Contractor has raised
reasonable objection by a Notice under this Sub-Clause.
CONDITIONS
GENERAL
replacement by giving a Notice to the Contractor with reasons and the name,
address and relevant experience of the replacement. This appointment shall
be treated as a temporary appointment until this replacement is accepted by
the Contractor, or another replacement is appointed, under this Sub-Clause.
3.7
GUIDANCE
Agreement or Determination When carrying out his/her duties under this Sub-Clause, the Engineer shall act
neutrally between the Parties and shall not be deemed to act for the Employer.
FORMS
3.7.1 Consultation to reach agreement
The Engineer shall consult with both Parties jointly and/or separately,
and shall encourage discussion between the Parties in an endeavour to
reach agreement. The Engineer shall commence such consultation
promptly to allow adequate time to comply with the time limit for
agreement under Sub-Clause 3.7.3 [Time limits]. Unless otherwise
proposed by the Engineer and agreed by both Parties, the Engineer shall
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If agreement is achieved, within the time limit for agreement under Sub-Clause
3.7.3 [Time limits], the Engineer shall give a Notice to both Parties of the
agreement, which agreement shall be signed by both Parties. This
Notice shall state that it is a “Notice of the Parties’ Agreement” and shall
include a copy of the agreement.
If:
(a) no agreement is achieved within the time limit for agreement under
Sub-Clause 3.7.3 [Time limits]; or
(b) both Parties advise the Engineer that no agreement can be achieved
within this time limit
whichever is the earlier, the Engineer shall give a Notice to the Parties
accordingly and shall immediately proceed as specified under Sub-Clause
3.7.2 [Engineer’s Determination].
Within the time limit for determination under Sub-Clause 3.7.3 [Time limits],
the Engineer shall give a Notice to both Parties of his/her determination.
This Notice shall state that it is a “Notice of the Engineer’s
Determination”, and shall describe the determination in detail with
reasons and detailed supporting particulars.
days or within such other time limit as may be proposed by the Engineer
and agreed by both Parties (the “time limit for determination” in these
Conditions), after the date corresponding to his/her obligation to proceed
under the last paragraph of Sub-Clause 3.7.1 [Consultation to reach
agreement].
If the Engineer does not give the Notice of agreement or determination within
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If, within 14 days after giving or receiving the Engineer’s Notice of agreement
or determination, any error of a typographical or clerical or arithmetical nature
is found:
(a) by the Engineer: then he/she shall immediately advise the Parties
accordingly; or
(b) by a Party: then that Party shall give a Notice to the Engineer,
stating that it is given under this Sub-Clause 3.7.4 and clearly
identifying the error. If the Engineer does not agree there was an
error, he/she shall immediately advise the Parties accordingly.
The Engineer shall within 7 days of finding the error, or receiving a Notice
under sub-paragraph (b) above (as the case may be), give a Notice to
both Parties of the corrected agreement or determination. Thereafter, the
CONDITIONS
GENERAL
3.7.5 Dissatisfaction with Engineer’s determination
(a) the dissatisfied Party may give a NOD to the other Party, with a
GUIDANCE
copy to the Engineer;
(b) this NOD shall state that it is a “Notice of Dissatisfaction with the
Engineer’s Determination” and shall set out the reason(s) for
dissatisfaction;
(c) this NOD shall be given within 28 days after receiving the
Engineer’s Notice of the determination under Sub-Clause 3.7.2
[Engineer’s Determination] or, if applicable, his/her Notice of the
FORMS
corrected determination under Sub-Clause 3.7.4 [Effect of the
agreement or determination] (or, in the case of a deemed
determination rejecting the Claim, within 28 days after the time
limit for determination under Sub-Clause 3.7.3 [Time limits] has
expired); and
(d) thereafter, either Party may proceed under Sub-Clause 21.4
[Obtaining DAAB’s Decision].
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In the event that a Party fails to comply with an agreement of the Parties
under this Sub-Clause 3.7 or a final and binding determination of the
Engineer, the other Party may, without prejudice to any other rights it may
have, refer the failure itself directly to arbitration under Sub-Clause 21.6
[Arbitration] in which case the first and the third paragraphs of Sub-Clause
21.7 [Failure to Comply with DAAB’s Decision] shall apply to such
reference in the same manner as these paragraphs apply to a final and
binding decision of the DAAB.
3.8
Meetings The Engineer or the Contractor’s Representative may require the other
to attend a management meeting to discuss arrangements for future work
and/ or other matters in connection with execution of the Works.
The Engineer shall keep a record of each management meeting and supply
copies of the record to those attending and to the Employer. At any such
4.1
Th
4 e
GUIDANCE
Contractor
Contractor’s
General Obligations The Contractor shall execute the Works in accordance with the Contract. The
Contractor undertakes that the execution of the Works and the
completed Works will be in accordance with the documents forming the
Contract, as altered or modified by Variations.
FORMS
The Contractor shall provide the Plant (and spare parts, if any) and
Contractor’s Documents specified in the Contract, and all Contractor’s
Personnel, Goods, consumables and other things and services, whether of a
temporary or permanent nature, required to fulfil the Contractor’s obligations
under the Contract.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall be responsible for the adequacy, stability and safety of
all the Contractor’s operations and activities, of all methods of
construction and of all the Temporary Works. Except to the extent
specified in the Contract, the Contractor:
If the Contract specifies that the Contractor shall design any part of the
Permanent Works, then unless otherwise stated in the Particular Conditions:
(a) the Contractor shall prepare, and submit to the Engineer for
Review, the Contractor’s Documents for this part (and any other
documents necessary to complete and implement the design during
the execution of the Works and to instruct the Contractor’s
Personnel);
(b) these Contractor’s Documents shall be in accordance with the
Specification and Drawings and shall include additional
information required by the Engineer to add to the Drawings for
co-ordination of each Party’s designs. If the Engineer instructs that
further Contractor’s Documents are reasonably required to demonstrate
that the Contractor’s design complies with the Contract, the
Contractor shall prepare and submit them promptly to the Engineer
at the Contractor’s cost;
(c) construction of this part shall not commence until a Notice of
No-objection is given (or is deemed to have been given) by the
Engineer under sub-paragraph (i) of Sub-Clause 4.4.1
[Preparation and Review] for all the Contractor’s Documents which
are relevant to its design, and construction of such part shall be in
accordance with these Contractor’s Documents;
(d) the Contractor may modify any design or Contractor’s Documents
which have previously been submitted for Review, by giving a Notice
CONDITIONS
GENERAL
Contractor’s Documents are relevant, work on this part shall be
suspended, the provisions of Sub-Clause 4.4.1 [Preparation and
Review] shall apply as if the Engineer had given a Notice in respect of
the Contractor’s Documents under sub-paragraph (ii) of Sub-
Clause 4.4.1, and work shall not resume until a Notice of No-
objection is given (or is deemed to have been given) by the
GUIDANCE
Engineer for the revised documents;
(e) the Contractor shall be responsible for this part and it shall, when the
Works are completed, be fit for such purpose(s) for which the part
is intended as are specified in the Contract (or, where no purpose(s)
are so defined and described, fit for their ordinary purpose(s));
(f) in addition to the Contractor’s undertaking above, the Contractor
undertakes that the design and the Contractor’s Documents for
FORMS
this part will comply with the technical standards stated in the
Specification and Laws (in force when the Works are taken over
under Clause 10 [Employer’s Taking Over]) and in accordance
with the documents forming the Contract, as altered or modified
by Variations;
(g) if Sub-Clause 4.4.2 [As-built Records] and/or Sub-Clause 4.4.3
[Operation and Maintenance Manuals] apply, the Contractor shall
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall ensure that the Performance Security remains valid and
enforceable until the issue of the Performance Certificate and the Contractor
has complied with Sub-Clause 11.11 [Clearance of Site]. If the terms of
the Performance Security specify an expiry date, and the Contractor has
not become entitled to receive the Performance Certificate by the date
28 days before the expiry date, the Contractor shall extend the validity of
the Performance Security until the issue of the Performance Certificate and
the Contractor has complied with Sub-Clause 11.11 [Clearance of Site].
The Employer shall not make a claim under the Performance Security,
FORMS
except for amounts to which the Employer is entitled under the Contract in
the event of:
(b) failure by the Contractor to pay the Employer an amount due, as agreed
or determined under Sub-Clause 3.7 [Agreement or Determination] or
agreed or decided under Clause 21 [Disputes and Arbitration], within
42 days after the date of the agreement or determination or
decision or arbitral award (as the case may be);
(c) failure by the Contractor to remedy a default stated in a Notice
given under Sub-Clause 15.1 [Notice to Correct] within 42 days or
other time (if any) stated in the Notice;
(d) circumstances which entitle the Employer to terminate the
Contract under Sub-Clause 15.2 [Termination for Contractor’s
Default], irrespective of whether a Notice of termination has been
given; or
(e) if under Sub-Clause 11.5 [Remedying of Defective Work off Site] the
Contractor removes any defective or damaged Plant from the Site,
failure by the Contractor to repair such Plant, return it to the Site,
reinstall it and retest it by the date of expiry of the relevant
duration stated in the Contractor’s Notice (or other date agreed by
the Employer).
The Employer shall indemnify and hold the Contractor harmless against and
from all damages, losses and expenses (including legal fees and expenses)
resulting from a claim under the Performance Security to the extent that the
Employer was not entitled to make the claim.
CONDITIONS
GENERAL
Site]; or
(b) promptly after the date of termination if the Contract is terminated
in accordance with Sub-Clause 15.5 [Termination for Employer’s
Convenience], Sub-Clause 16.2 [Termination by Contractor],
Sub-Clause 18.5 [Optional Termination] or Sub-Clause 18.6 [Release
from Performance under the Law].
GUIDANCE
4.3
Contractor’s
Representative The Contractor shall appoint the Contractor’s Representative and shall give
him/her all authority necessary to act on the Contractor’s behalf under the
Contract, except to replace the Contractor’s Representative.
FORMS
The Contractor’s Representative shall be qualified, experienced and
competent in the main engineering discipline applicable to the Works
and fluent in the language for communications defined in Sub-Clause
1.4 [Law and Language].
Engineer for consent the name and particulars of the person the Contractor
proposes to appoint as Contractor’s Representative. If consent is
withheld or subsequently revoked, or if the appointed person fails to act as
Contractor’s Representative, the Contractor shall similarly submit the name
and particulars of another suitable replacement for such appointment. If the
Engineer does not respond within 28 days after receiving this submission,
by giving a Notice to the Contractor objecting to the proposed person or
replacement, the Engineer shall be deemed to have given his/her
consent.
The Contractor shall not, without the Engineer’s prior consent, revoke
the appointment of the Contractor’s Representative or appoint a
replacement (unless the Contractor’s Representative is unable to act as a
result of death, illness, disability or resignation, in which case his/her
appointment shall be deemed to have been revoked with immediate
effect and the appointment of a replacement shall be treated as a
temporary appointment until the Engineer gives his/her consent to this
replacement, or another replacement is appointed, under this Sub-Clause).
The Contractor’s Representative shall be based at the Site for the whole
time that the Works are being executed at the Site. If the Contractor’s
Representative is to be temporarily absent from the Site during the execution
of the Works, a suitable replacement shall be temporarily appointed, subject
to the Engineer’s prior consent.
All these persons shall be fluent in the language for communications defined
in Sub-Clause 1.4 [Law and Language].
4.4
FORMS
Contractor’s
Documents 4.4.1 Preparation and Review
The Contractor shall prepare all Contractor’s Documents and the Employer’s
Personnel shall have the right to inspect the preparation of all these
documents, wherever they are being prepared.
The Engineer shall, within 21 days after receiving the Contractor’s Document
and this Notice from the Contractor, give a Notice to the Contractor:
After receiving a Notice under sub-paragraph (ii), above, the Contractor shall
revise the Contractor’s Document and resubmit it to the Engineer for Review
in accordance with this Sub-Clause and the period of 21 days for Review
shall be calculated from the date that the Engineer receives it.
CONDITIONS
GENERAL
If no as-built records to be prepared by the Contractor are stated in the
Specification, this Sub-Clause shall not apply.
GUIDANCE
Contractor. The format, referencing system, system of electronic storage
and other relevant details of the as-built records shall be as stated in the
Specification (if not stated, as acceptable to the Engineer). These
records shall be kept on the Site and shall be used exclusively for the
purposes of this Sub-Clause.
The as-built records shall be submitted to the Engineer for Review, and
FORMS
the Works shall not be considered to be completed for the purposes of
taking-over under Sub-Clause 10.1 [Taking Over the Works and
Sections] until the Engineer has given (or is deemed to have given) a
Notice of No-objection under sub-paragraph (i) of Sub-Clause 4.4.1
[Preparation and Review].
The Contractor shall prepare, and keep up-to-date, the operation and
maintenance manuals in the format and other relevant details as stated
in the Specification.
4.5
Training If no training of employees of the Employer (and/or other identified
personnel) by the Contractor is stated in the Specification, this Sub-
Clause shall not apply.
utility companies,
who may be employed in the carrying out, on or near the Site, of any
work not included in the Contract. Such appropriate opportunities may
include the use of Contractor’s Equipment, Temporary Works, access
arrangements which are the responsibility of the Contractor, and/or other
Contractor’s facilities or services on the Site.
FORMS
4.7
Setting Out The Contractor shall set out the Works in relation to the items of
reference under Sub-Clause 2.5 [Site Data and Items of Reference].
4.7.1 Accuracy
(a) verify the accuracy of all these items of reference before they are
used for the Works;
(b) promptly deliver the results of each verification to the Engineer;
(c) rectify any error in the positions, levels, dimensions or alignment of
the Works; and
(d) be responsible for the correct positioning of all parts of the Works.
4.7.2 Errors
If the Contractor finds an error in any items of reference, the Contractor shall
give a Notice to the Engineer describing it:
(a) within the period stated in the Contract Data (if not stated, 28
days) calculated from the Commencement Date, if the items of
reference are specified on the Drawings and/or in the
Specification; or
(b) as soon as practicable after receiving the items of reference, if
they are issued by the Engineer under Sub-Clause 2.5 [Site Data and
Items of Reference].
CONDITIONS
GENERAL
(a) whether or not there is an error in the items of reference;
(b) whether or not (taking account of cost and time) an experienced
contractor exercising due care would have discovered such an
error
• when examining the Site, the Drawings and the Specification
GUIDANCE
before submitting the Tender; or
• if the items of reference are specified on the Drawings and/or
in the Specification and the Contractor’s Notice is given after
the expiry of the period stated in sub-paragraph (a) of Sub-
Clause 4.7.2; and
(c) what measures (if any) the Contractor is required to take to rectify the
error
FORMS
(and, for the purpose of Sub-Clause 3.7.3 [Time limits], the date the
Engineer receives the Contractor’s Notice under Sub-Clause 4.7.2 [Errors]
shall be the date of commencement of the time limit for agreement under
Sub-Clause 3.7.3).
4.8
Health and Safety
Obligations The Contractor shall:
(a) comply with all applicable health and safety regulations and Laws;
(b) comply with all applicable health and safety obligations specified
in the Contract;
(c) comply with all directives issued by the Contractor’s health and
safety officer (appointed under Sub-Clause 6.7 [Health and Safety of
Personnel]);
(d) take care of the health and safety of all persons entitled to be on
the Site and other places (if any) where the Works are being
executed;
(e) keep the Site, Works (and the other places (if any) where the
Works are being executed) clear of unnecessary obstruction so as
to avoid danger to these persons;
(f) provide fencing, lighting, safe access, guarding and watching of:
(i) the Works, until the Works are taken over under Clause 10
[Employer’s Taking Over]; and
(ii) any part of the Works where the Contractor is executing
outstanding works or remedying any defects during the DNP;
and
(g) provide any Temporary Works (including roadways, footways, guards
and fences) which may be necessary, because of the execution of the
Works, for the use and protection of the public and of owners and
occupiers of adjacent land and property.
Within 21 days of the Commencement Date and before commencing any
for the Works, the Site and other places (if any) where the Contractor
intends to execute the Works. This manual shall be in addition to any
other similar document required under applicable health and safety
regulations and Laws.
The health and safety manual shall set out all the health and safety
GUIDANCE
requirements:
other places (if any) where the Works are being executed.
This manual shall be revised as necessary by the Contractor or the
Contractor’s health and safety officer, or at the reasonable request of the
Engineer. Each revision of the manual shall be submitted promptly to the
Engineer.
4.20 [Progress Reports], the Contractor shall submit to the Engineer details
of any accident as soon as practicable after its occurrence and, in the case
of an accident causing serious injury or death, shall inform the Engineer
immediately.
The Contractor shall, as stated in the Specification and as the Engineer may
reasonably require, maintain records and make reports (in compliance with
the applicable health and safety regulations and Laws) concerning the health
and safety of persons and any damage to property.
4.9
Quality Management and
Compliance Verification
Systems 4.9.1 Quality Management System
(a) to ensure that all Notices and other communications under Sub-Clause
1.3 [Notices and Other Communications], Contractor’s
Documents, as-built records (if applicable), operation and
maintenance manuals (if applicable), and contemporary records
can be traced, with full certainty, to the Works, Goods, work,
workmanship or test to which they relate;
(b) to ensure proper coordination and management of interfaces between
the stages of execution of the Works, and between
Subcontractors; and
(c) for the submission of Contractor’s Documents to the Engineer for
Review.
30 © FIDIC 2017 Conditions of Contract for Construction
The Engineer may Review the QM System and may give a Notice to the
Contractor stating the extent to which it does not comply with the
CONDITIONS
GENERAL
Contract. Within 14 days after receiving this Notice, the Contractor shall
revise the QM System to rectify such non-compliance. If the Engineer
does not give such a Notice within 21 days of the date of submission of
the QM System, the Engineer shall be deemed to have given a Notice of
No-objection.
GUIDANCE
The Engineer may, at any time, give a Notice to the Contractor stating
the extent to which the Contractor is failing to correctly implement the
QM System to the Contractor’s activities under the Contract. After receiving
this Notice, the Contractor shall immediately remedy such failure.
The Contractor shall carry out internal audits of the QM System regularly,
and at least once every 6 months. The Contractor shall submit to the
FORMS
Engineer a report listing the results of each internal audit within 7 days of
completion. Each report shall include, where appropriate, the proposed
measures to improve and/or rectify the QM System and/or its
implementation.
external audit. If the Contractor is a JV, this obligation shall apply to each
member of the JV.
The Contractor shall prepare and submit to the Engineer a complete set
of compliance verification documentation for the Works or Section (as
the case may be), fully compiled and collated in the manner described in
the Specification or, if not so described, in a manner acceptable to the
Engineer.
4.10
Use of Site Data The Contractor shall be responsible for interpreting all data referred to under
Sub-Clause 2.5 [Site Data and Items of Reference].
To the extent which was practicable (taking account of cost and time),
the Contractor shall be deemed to have obtained all necessary information
as to risks, contingencies and other circumstances which may influence or
affect the Tender or Works. To the same extent, the Contractor shall be
deemed to have inspected and examined the Site, access to the Site, its
surroundings, the above data and other available information, and to have been
satisfied before submitting the Tender as to all matters relevant to the
execution of the Works, including:
General Conditions © FIDIC 2017
31
(a) the form and nature of the Site, including sub-surface conditions;
CONDITIONS
(b) the hydrological and climatic conditions, and the effects of climatic
GENERAL
4.11
Sufficiency of the
Accepted Contract Amount The Contractor shall be deemed to:
and all things necessary for the proper execution of the Works in accordance
with the Contract.
4.12
Unforeseeable Physical
Conditions In this Sub-Clause, “physical conditions” means natural physical conditions
and physical obstructions (natural or man-made) and pollutants, which
the Contractor encounters at the Site during execution of the Works,
including sub-surface and hydrological conditions but excluding climatic
conditions at the Site and the effects of those climatic conditions.
(a) be given as soon as practicable and in good time to give the Engineer
opportunity to inspect and investigate the physical conditions promptly
and before they are disturbed;
(b) describe the physical conditions, so that they can be inspected
and/ or investigated promptly by the Engineer;
(c) set out the reasons why the Contractor considers the physical
conditions to be Unforeseeable; and
(d) describe the manner in which the physical conditions will have an
adverse effect on the progress and/or increase the Cost of the
execution of the Works.
The Engineer shall inspect and investigate the physical conditions within
CONDITIONS
GENERAL
The Contractor shall continue execution of the Works, using such proper
and reasonable measures as are appropriate for the physical conditions and
to enable the Engineer to inspect and investigate them.
GUIDANCE
The Contractor shall comply with any instructions which the Engineer
may give for dealing with the physical conditions and, if such an
instruction constitutes a Variation, Sub-Clause 13.3.1 [Variation by
Instruction] shall apply.
FORMS
If and to the extent that the Contractor suffers delay and/or incurs Cost
due to these physical conditions, having complied with Sub-Clauses
4.12.1 to
4.12.3 above, the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or EOT] to EOT and/or payment of such Cost.
4.13
Rights of Way and Facilities The Contractor shall bear all costs and charges for special and/or temporary
rights-of-way which may be required for the purposes of the Works, including
those for access to the Site.
The Contractor shall also obtain, at the Contractor’s risk and cost, any
additional facilities outside the Site which may be required for the purposes
of the Works.
4.14
Avoidance of Interference The Contractor shall not interfere unnecessarily or improperly with:
4.15
Access Route The Contractor shall be deemed to have been satisfied, at the Base
Date, as to the suitability and availability of the access routes to the Site.
The Contractor shall take all necessary measures to prevent any road or
GUIDANCE
(a) the Contractor shall (as between the Parties) be responsible for repair
of any damage caused to, and any maintenance which may be
required for the Contractor’s use of, access routes;
(b) the Contractor shall provide all necessary signs or directions along
access routes, and shall obtain any permissions or permits which
may be required from the relevant authorities, for the Contractor’s use
of routes, signs and directions;
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(c) the Employer shall not be responsible for any third party claims which
may arise from the Contractor’s use or otherwise of any access route;
(d) the Employer does not guarantee the suitability or availability of
particular access routes; and
(e) all Costs due to non-suitability or non-availability, for the use required
by the Contractor, of access routes shall be borne by the
Contractor.
4.16
Transport of Goods The Contractor shall:
(a) give a Notice to the Engineer not less than 21 days before the
date on which any Plant, or a major item of other Goods (as stated
in the Specification), will be delivered to the Site;
(b) be responsible for packing, loading, transporting, receiving,
unloading, storing and protecting all Goods and other things
required for the Works;
(c) be responsible for customs clearance, permits, fees and charges
related to the import, transport and handling of all Goods,
including all obligations necessary for their delivery to the Site;
and
(d) indemnify and hold the Employer harmless against and from all
damages, losses and expenses (including legal fees and
expenses) resulting from the import, transport and handling of all
Goods, and shall negotiate and pay all third party claims arising from
their import, transport and handling.
4.17
Contractor’s Equipment The Contractor shall be responsible for all Contractor’s Equipment. When
brought on to the Site, Contractor’s Equipment shall be deemed to be
exclusively intended for the execution of the Works. The Contractor shall
CONDITIONS
GENERAL
transporting Goods or Contractor’s Personnel off Site.
GUIDANCE
whether the item of Contractor’s Equipment is owned by the Contractor
or a Subcontractor or another person and, if rented or leased, shall identify
the rental or leasing entity.
4.18
Protection of
the Environment The Contractor shall take all necessary measures to:
FORMS
(a) protect the environment (both on and off the Site);
(b) comply with the environmental impact statement for the Works (if
any); and
(c) limit damage and nuisance to people and property resulting from
pollution, noise and other results of the Contractor’s operations
and/ or activities.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall ensure that emissions, surface discharges, effluent and
any other pollutants from the Contractor’s activities shall exceed neither the
values indicated in the Specification, nor those prescribed by applicable
Laws.
4.19
Temporary Utilities The Contractor shall, except as stated below, be responsible for the provision
of all temporary utilities, including electricity, gas, telecommunications, water
and any other services the Contractor may require for the execution of
the Works.
The following provisions of this Sub-Clause shall only apply if, as stated
in the Specification, the Employer is to provide utilities for the Contractor’s
use. The Contractor shall be entitled to use, for the purposes of the
Works, the utilities on the Site for which details and prices are given in the
Specification. The Contractor shall, at the Contractor’s risk and cost, provide
any apparatus necessary for the Contractor’s use of these services and for
measuring the quantities consumed. The apparatus provided for
measuring quantities consumed shall be subject to the Engineer’s
consent. The quantities consumed (if any) during each period of
payment stated in the Contract Data (if not stated, each month) shall be
measured by the Contractor, and the amount to be paid by the
Contractor for such quantities (at the prices stated in the Specification)
shall be included in the relevant Statement.
4.20
Progress Reports Monthly progress reports, in the format stated in the Specification (if not
stated, in a format acceptable to the Engineer) shall be prepared by the
Contractor and submitted to the Engineer. Each progress report shall be
submitted in one paper-original, one electronic copy and additional paper
copies (if any) as stated in the Contract Data. The first report shall cover the
period up to the end of the first month following the Commencement
Date. Reports shall be submitted monthly thereafter, each within 7 days
after the last day of the month to which it relates.
certificates of Materials);
(f) a list of Variations, and any Notices given (by either Party) under
Sub-Clause 20.2.1 [Notice of Claim];
(g) health and safety statistics, including details of any hazardous
incidents and activities relating to environmental aspects and
public relations; and
(h) comparisons of actual and planned progress, with details of any
events or circumstances which may adversely affect the
completion of the Works in accordance with the Programme and
the Time for Completion, and the measures being (or to be) adopted
to overcome delays.
4.21
Security of the Site The Contractor shall be responsible for the security of the Site, and:
4.22
Contractor’s Operations
on Site The Contractor shall confine the Contractor’s operations to the Site, and
to any additional areas which may be obtained by the Contractor and
acknowledged by the Engineer as working areas. The Contractor shall take
all necessary precautions to keep Contractor’s Equipment and Contractor’s
Personnel within the Site and these additional areas, and to keep them
off adjacent land.
CONDITIONS
GENERAL
Contractor’s Equipment (subject to 4.17 [Contractor’s Equipment]) and/or
surplus materials. The Contractor shall promptly clear away and remove
from the Site any wreckage, rubbish, hazardous waste and Temporary
Works which are no longer required.
GUIDANCE
clear away and remove, from that part of the Site and Works to which
the Taking-Over Certificate refers, all Contractor’s Equipment, surplus
material, wreckage, rubbish, hazardous waste and Temporary Works. The
Contractor shall leave that part of the Site and the Works in a clean and safe
condition. However, the Contractor may retain at locations on the Site
agreed with the Engineer, during the DNP, such Goods as are required for
the Contractor to fulfil obligations under the Contract.
FORMS
4.23
Archaeological and
Geological Findings All fossils, coins, articles of value or antiquity, and structures and other
remains or items of geological or archaeological interest found on the
Site shall be placed under the care and authority of the Employer. The
Contractor shall take all reasonable precautions to prevent Contractor’s
Personnel or other persons from removing or damaging any of these
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
findings.
If the Contractor suffers delay and/or incurs Cost from complying with the
Engineer’s instructions, the Contractor shall be entitled subject to Sub-Clause
20.2 [Claims For Payment and/or EOT] to EOT and/or payment of such
Cost.
5.1
Su
5
cting
bcontra
(a) works with a total accumulated value greater than the percentage
of the Accepted Contract Amount stated in the Contract Data (if
not stated, the whole of the Works); or
(b) any part of the Works for which subcontracting is not permitted as
stated in the Contract Data.
The Contractor shall be responsible for the work of all Subcontractors,
for managing and coordinating all the Subcontractors’ works, and for the
acts or defaults of any Subcontractor, any Subcontractor’s agents or
employees, as if they were the acts or defaults of the Contractor.
General Conditions © FIDIC 2017
The Contractor shall
obtain the Engineer’s
prior consent to all
proposed
Subcontractors, except:
(i) suppliers of
Materials; or
(ii) a
subcont
ract for
which
the
Subcont
ractor
is
named
in the
Contrac
t.
37
Where the Contractor is required to obtain the Engineer’s consent to a
proposed Subcontractor, the Contractor shall submit the name, address,
CONDITIONS
GENERAL
consent.
The Contractor shall give a Notice to the Engineer not less than 28 days
before the intended date of the commencement of each Subcontractor’s
work, and of the commencement of such work on the Site.
5.2
FORMS
Nominated
Subcontractors 5.2.1 Definition of “nominated Subcontractor”
(a) there are reasons to believe that the Subcontractor does not have
sufficient competence, resources or financial strength;
(b) the subcontract does not specify that the nominated Subcontractor
shall indemnify the Contractor against and from any negligence or
misuse of Goods by the nominated Subcontractor, the nominated
Subcontractor’s agents and employees; or
(c) the subcontract does not specify that, for the subcontracted work
(including design, if any), the nominated Subcontractor shall:
(i) undertake to the Contractor such obligations and liabilities
as will enable the Contractor to discharge the Contractor’s
corresponding obligations and liabilities under the Contract, and
(ii) indemnify the Contractor against and from all obligations and
liabilities arising under or in connection with the Contract and
from the consequences of any failure by the Subcontractor to
perform these obligations or to fulfil these liabilities.
CONDITIONS
GENERAL
Before issuing a Payment Certificate which includes an amount payable
to a nominated Subcontractor, the Engineer may request the Contractor
to supply reasonable evidence that the nominated Subcontractor has
received all amounts due in accordance with the previous Payment
Certificates, less applicable deductions for retention or otherwise. Unless
the Contractor:
GUIDANCE
(a) submits this reasonable evidence to the Engineer, or
(b) (i) satisfies the Engineer in writing that the Contractor is reasonably
entitled to withhold or refuse to pay these amounts, and
(ii) submits to the Engineer reasonable evidence that the nominated
Subcontractor has been notified of the Contractor’s entitlement,
then the Employer may (at the Employer’s sole discretion) pay, directly to
FORMS
the nominated Subcontractor, part or all of such amounts previously
certified (less applicable deductions) as are due to the nominated
Subcontractor and for which the Contractor has failed to submit the
evidence described in sub-paragraphs (a) or (b) above.
Thereafter, the Engineer shall give a Notice to the Contractor stating the
amount paid directly to the nominated Subcontractor by the Employer
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
and, in the next IPC after this Notice, shall include this amount as a
deduction under sub-paragraph (b) of Sub-Clause 14.6.1 [The IPC].
6.1
Sta
Engagement of
6 ff and Labour
Staff and Labour Except as otherwise stated in the Specification, the Contractor shall make
arrangements for the engagement of all Contractor’s Personnel, and for their
payment, accommodation, feeding, transport and welfare.
6.2
Rates of Wages and
Conditions of Labour The Contractor shall pay rates of wages, and observe conditions of labour,
which comply with all applicable Laws and are not lower than those
established for the trade or industry where the work is carried out.
6.3
Recruitment of Persons The Contractor shall not recruit, or attempt to recruit, staff and labour
from amongst the Employer’s Personnel.
Neither the Employer nor the Engineer shall recruit, or attempt to recruit,
staff and labour from amongst the Contractor’s Personnel.
6.4
Labour Laws The Contractor shall comply with all the relevant labour Laws applicable
to the Contractor’s Personnel, including Laws relating to their
employment (including wages and working hours), health, safety,
welfare, immigration and emigration, and shall allow them all their legal
rights.
General Conditions © FIDIC 2017
39
The Contractor shall require the Contractor’s Personnel to obey all
applicable Laws, including those concerning health and safety at work.
CONDITIONS
GENERAL
6.5
Working Hours No work shall be carried out on the Site on locally recognised days of
rest, or outside the normal working hours stated in the Contract Data,
unless:
GUIDANCE
6.6
Facilities for
Staff and Labour Except as otherwise stated in the Specification, the Contractor shall provide
and maintain all necessary accommodation and welfare facilities for the
Contractor’s Personnel.
If such accommodation and facilities are to be located on the Site, except where
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
the Employer has given the Contractor prior permission, they shall be
located within the areas identified in the Contract. If any such
accommodation or facilities are found elsewhere within the Site, the
Contractor shall immediately remove them at the Contractor’s risk and
cost. The Contractor shall also provide facilities for the Employer’s
Personnel as stated in the Specification.
6.7
Health and Safety
of Personnel In addition to the requirements of Sub-Clause 4.8 [Health and Safety
Obligations], the Contractor shall at all times take all necessary precautions
to maintain the health and safety of the Contractor’s Personnel. In
collaboration with local health authorities, the Contractor shall ensure
that:
(a) medical staff, first aid facilities, sick bay, ambulance services and any
other medical services stated in the Specification are available at
all times at the Site and at any accommodation for Contractor’s
and Employer’s Personnel; and
(b) suitable arrangements are made for all necessary welfare and
hygiene requirements and for the prevention of epidemics.
The Contractor shall appoint a health and safety officer at the Site,
responsible for maintaining health, safety and protection against accidents.
This officer shall:
6.8
Contractor’s
Superintendence From the Commencement Date until the issue of the Performance Certificate,
the Contractor shall provide all necessary superintendence to plan, arrange,
direct, manage, inspect, test and monitor the execution of the Works.
CONDITIONS
GENERAL
(a) who are fluent in or have adequate knowledge of the language for
communications (defined in Sub-Clause 1.4 [Law and Language]);
and
(b) who have adequate knowledge of the operations to be carried out
(including the methods and techniques required, the hazards likely to
be encountered and methods of preventing accidents),
GUIDANCE
for the satisfactory and safe execution of the Works.
6.9
Contractor’s Personnel The Contractor’s Personnel (including Key Personnel, if any) shall be
appropriately qualified, skilled, experienced and competent in their
respective trades or occupations.
FORMS
The Engineer may require the Contractor to remove (or cause to be
removed) any person employed on the Site or Works, including the
Contractor’s Representative and Key Personnel (if any), who:
6.10
Contractor’s Records Unless otherwise proposed by the Contractor and agreed by the Engineer,
in each progress report under Sub-Clause 4.20 [Progress Reports], the
Contractor shall include records of:
6.11
Disorderly Conduct The Contractor shall at all times take all necessary precautions to prevent
any unlawful, riotous or disorderly conduct by or amongst the
Contractor’s Personnel, and to preserve peace and protection of persons
and property on and near the Site.
apply.
The Contractor shall appoint the natural persons named in the Tender to the
positions of Key Personnel. If not so named, or if an appointed person
fails to act in the relevant position of Key Personnel, the Contractor shall
submit to the Engineer for consent the name and particulars of another
GUIDANCE
If the Engineer does not respond within 14 days after receiving any such
submission, by giving a Notice stating his/her objection to the
appointment of such person (or replacement) with reasons, the Engineer
shall be deemed to have given his/her consent.
FORMS
The Contractor shall not, without the Engineer’s prior consent, revoke
the appointment of any of the Key Personnel or appoint a replacement
(unless the person is unable to act as a result of death, illness, disability or
resignation, in which case the appointment shall be deemed to have been
revoked with immediate effect and the appointment of a replacement
shall be treated as a temporary appointment until the Engineer gives
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
All Key Personnel shall be based at the Site (or, where Works are being
executed off the Site, at the location of the Works) for the whole time that the
Works are being executed. If any of the Key Personnel is to be
temporarily absent during execution of the Works, a suitable
replacement shall be temporarily appointed, subject to the Engineer’s
prior consent.
All Key Personnel shall be fluent in the language for communications defined
in Sub-Clause 1.4 [Law and Language].
7.1
Manner
Pla
7 nt, Materials and Workmanship
of Execution The Contractor shall carry out the manufacture, supply, installation,
testing and commissioning and/or repair of Plant, the production,
manufacture, supply and testing of Materials, and all other operations and
activities during the execution of the Works:
7.2
Samples The Contractor shall submit the following samples of Materials, and relevant
information, to the Engineer for consent prior to using the Materials in or
for the Works:
CONDITIONS
GENERAL
Each sample shall be labelled as to origin and intended use in the Works.
7.3
Inspection The Employer’s Personnel shall, during all the normal working hours stated
in the Contract Data and at all other reasonable times:
GUIDANCE
(a) have full access to all parts of the Site and to all places from which
natural Materials are being obtained;
(b) during production, manufacture and construction (at the Site and
elsewhere), be entitled to:
(i) examine, inspect, measure and test (to the extent stated in
the Specification) the Materials, Plant and workmanship,
(ii) check the progress of manufacture of Plant and production
FORMS
and manufacture of Materials, and
(iii) make records (including photographs and/or video recordings);
and
(c) carry out other duties and inspections, as specified in these
Conditions and the Specification.
The Contractor shall give the Employer’s Personnel full opportunity to carry
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall give a Notice to the Engineer whenever any Materials,
Plant or work is ready for inspection, and before it is to be covered up,
put out of sight, or packaged for storage or transport. The Employer’s
Personnel shall then either carry out the examination, inspection,
measurement or testing without unreasonable delay, or the Engineer
shall promptly give a Notice to the Contractor that the Employer’s
Personnel do not require to do so. If the Engineer gives no such Notice
and/or the Employer’s Personnel do not attend at the time stated in the
Contractor’s Notice (or such time as may be agreed with the Contractor),
the Contractor may proceed with covering up, putting out of sight or
packaging for storage or transport.
7.4
Testing by the Contractor This Sub-Clause shall apply to all tests specified in the Contract, other than
the Tests after Completion (if any).
The Contractor shall give a Notice to the Engineer, stating the time and
place for the specified testing of any Plant, Materials and other parts of the
Works. This Notice shall be given in reasonable time, having regard to
the location of the testing, for the Employer’s Personnel to attend.
to carry out additional tests. If these varied or additional tests show that
the tested Plant, Materials or workmanship is not in accordance with the
Contract, the Cost and any delay incurred in carrying out this Variation shall
be borne by the Contractor.
The Engineer shall give a Notice to the Contractor of not less than 72 hours
GUIDANCE
of his/her intention to attend the tests. If the Engineer does not attend at
the time and place stated in the Contractor’s Notice under this Sub-
Clause, the Contractor may proceed with the tests, unless otherwise
instructed by the Engineer. These tests shall then be deemed to have
been made in the Engineer’s presence. If the Contractor suffers delay
and/or incurs Cost from complying with any such instruction or as a
result of a delay for which the Employer is responsible, the Contractor
shall be entitled subject to Sub-Clause 20.2 [Claims For Payment and/or
FORMS
The Contractor shall promptly forward to the Engineer duly certified reports
of the tests. When the specified tests have been passed, the Engineer shall
endorse the Contractor’s test certificate, or issue a test certificate to the
Contractor, to that effect. If the Engineer has not attended the tests,
he/she shall be deemed to have accepted the readings as accurate.
Sub-Clause 7.5 [Defects and Rejection] shall apply in the event that any
Plant, Materials and other parts of the Works fails to pass a specified
test.
7.5
Defects and Rejection If, as a result of an examination, inspection, measurement or testing, any
Plant, Materials, Contractor’s design (if any) or workmanship is found to
be defective or otherwise not in accordance with the Contract, the
Engineer shall give a Notice to the Contractor describing the item of
Plant, Materials, design or workmanship that has been found to be
defective. The Contractor shall then promptly prepare and submit a
proposal for necessary remedial work.
The Engineer may Review this proposal, and may give a Notice to the
Contractor stating the extent to which the proposed work, if carried out,
would not result in the Plant, Materials, Contractor’s design (if any) or
workmanship complying with the Contract. After receiving such a Notice the
Contractor shall promptly submit a revised proposal to the Engineer. If
the Engineer gives no such Notice within 14 days after receiving the
Contractor’s proposal (or revised proposal), the Engineer shall be deemed to
have given a Notice of No-objection.
If the Contractor fails to promptly submit a proposal (or revised proposal) for
remedial work, or fails to carry out the proposed remedial work to which the
Engineer has given (or is deemed to have given) a Notice of No-
objection, the Engineer may:
CONDITIONS
GENERAL
Defects] shall apply.
After remedying defects in any Plant, Materials, design (if any) or workmanship,
if the Engineer requires any such items to be retested, the tests shall be
repeated in accordance with Sub-Clause 7.4 [Testing by the Contractor]
at the Contractor’s risk and cost. If the rejection and retesting cause the
GUIDANCE
Employer to incur additional costs, the Employer shall be entitled subject
to Sub-Clause 20.2 [Claims For Payment and/or EOT] to payment of
these costs by the Contractor.
7.6
Remedial Work In addition to any previous examination, inspection, measurement or testing,
or test certificate or Notice of No-objection by the Engineer, at any time
FORMS
before the issue of the Taking-Over Certificate for the Works the
Engineer may instruct the Contractor to:
(a) repair or remedy (if necessary, off the Site), or remove from the
Site and replace any Plant or Materials which are not in
accordance with the Contract;
(b) repair or remedy, or remove and re-execute, any other work which
is not in accordance with the Contract; and
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(c) carry out any remedial work which is urgently required for the
safety of the Works, whether because of an accident,
unforeseeable event or otherwise.
The Contractor shall comply with the instruction as soon as practicable and
not later than the time (if any) specified in the instruction, or immediately
if urgency is specified under sub-paragraph (c) above.
The Contractor shall bear the cost of all remedial work required under
this Sub-Clause, except to the extent that any work under sub-paragraph
(c) above is attributable to:
If the Contractor fails to comply with the Engineer’s instruction, the Employer
may (at the Employer’s sole discretion) employ and pay other persons to
carry out the work. Except to the extent that the Contractor would have
been entitled to payment for work under this Sub-Clause, the Employer
shall be entitled subject to Sub-Clause 20.2 [Claims For Payment and/or
EOT] to payment by the Contractor of all costs arising from this failure. This
entitlement shall be without prejudice to any other rights the Employer
may have, under the Contract or otherwise.
7.7
Ownership of Plant
and Materials Each item of Plant and Materials shall, to the extent consistent with the
mandatory requirements of the Laws of the Country, become the property of
the Employer at whichever is the earlier of the following times, free from
liens and other encumbrances:
(b) when the Contractor is paid the value of the Plant and Materials under
GENERAL
7.8
Royalties Unless otherwise stated in the Specification, the Contractor shall pay all
royalties, rents and other payments for:
extent that disposal areas within the Site are stated in the
Specification.
8.1
Co
8 mmencement, Delays and Suspension
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Commencement of Works The Engineer shall give a Notice to the Contractor stating the Commencement
Date, not less than 14 days before the Commencement Date. Unless
otherwise stated in the Particular Conditions, the Commencement Date shall
be within 42 days after the Contractor receives the Letter of Acceptance.
8.2
Time for Completion The Contractor shall complete the whole of the Works, and each Section (if any),
within the Time for Completion for the Works or Section (as the case may
be), including completion of all work which is stated in the Contract as being
required for the Works or Section to be considered to be completed for the
purposes of taking over under Sub-Clause 10.1 [Taking Over the Works and
Sections].
8.3
Programme The Contractor shall submit an initial programme for the execution of the
Works to the Engineer within 28 days after receiving the Notice under
Sub-Clause 8.1 [Commencement of Works]. This programme shall be
prepared using programming software stated in the Specification (if not
stated, the programming software acceptable to the Engineer). The
Contractor shall also submit a revised programme which accurately reflects
the actual progress of the Works, whenever any programme ceases to
reflect actual progress or is otherwise inconsistent with the Contractor’s
obligations.
(a) the Commencement Date and the Time for Completion, of the Works
and of each Section (if any);
(b) the date right of access to and possession of (each part of) the
Site is to be given to the Contractor in accordance with the time (or
times)
46 © FIDIC 2017 Conditions of Contract for Construction
stated in the Contract Data. If not so stated, the dates the
Contractor requires the Employer to give right of access to and
CONDITIONS
GENERAL
possession of (each part of) the Site;
(c) the order in which the Contractor intends to carry out the Works,
including the anticipated timing of each stage of design (if any),
preparation and submission of Contractor’s Documents, procurement,
manufacture, inspection, delivery to Site, construction, erection,
installation, work to be undertaken by any nominated
GUIDANCE
Subcontractor (as defined in Sub-Clause 5.2 [Nominated
Subcontractors]) and testing;
(d) the Review periods for any submissions stated in the Specification or
required under these Conditions;
(e) the sequence and timing of inspections and tests specified in, or
required by, the Contract;
(f) for a revised programme: the sequence and timing of the remedial
FORMS
work (if any) to which the Engineer has given a Notice of No-objection
under Sub-Clause 7.5 [Defects and Rejection] and/or the remedial
work (if any) instructed under Sub-Clause 7.6 [Remedial Work];
(g) all activities (to the level of detail stated in the Specification), logically
linked and showing the earliest and latest start and finish dates for
each activity, the float (if any), and the critical path(s);
(h) the dates of all locally recognised days of rest and holiday periods
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(if any);
(i) all key delivery dates of Plant and Materials;
(j) for a revised programme and for each activity: the actual progress
to date, any delay to such progress and the effects of such delay
on other activities (if any); and
(k) a supporting report which includes:
(i) a description of all the major stages of the execution of the
Works;
(ii) a general description of the methods which the Contractor
intends to adopt in the execution of the Works;
(iii) details showing the Contractor’s reasonable estimate of the
number of each class of Contractor’s Personnel, and of each
type of Contractor’s Equipment, required on the Site, for each
major stage of the execution of the Works;
(iv) if a revised programme, identification of any significant change(s)
to the previous programme submitted by the Contractor; and
(v) the Contractor’s proposals to overcome the effects of any
delay(s) on progress of the Works.
The Engineer shall Review the initial programme and each revised programme
submitted by the Contractor and may give a Notice to the Contractor stating
the extent to which it does not comply with the Contract or ceases to
reflect actual progress or is otherwise inconsistent with the Contractor’s
obligations. If the Engineer gives no such Notice:
If, at any time, the Engineer gives a Notice to the Contractor that the Programme
fails (to the extent stated) to comply with the Contract or ceases to
reflect actual progress or is otherwise inconsistent with the Contractor’s
obligations, the Contractor shall within 14 days after receiving this Notice
GUIDANCE
8.4
Advance Warning Each Party shall advise the other and the Engineer, and the Engineer shall
advise the Parties, in advance of any known or probable future events or
circumstances which may:
FORMS
8.5
Extension of Time
for Completion The Contractor shall be entitled subject to Sub-Clause 20.2 [Claims
For Payment and/or EOT] to Extension of Time if and to the extent that
completion for the purposes of Sub-Clause 10.1 [Taking Over the Works and
Sections] is or will be delayed by any of the following causes:
The Contractor shall be entitled subject to Sub-Clause 20.2 [Claims For Payment
and/or EOT] to EOT if the measured quantity of any item of work in
accordance with Clause 12 [Measurement and Valuation] is greater than
the estimated quantity of this item in the Bill of Quantities or other Schedule
by more than ten per cent (10%) and such increase in quantities causes a
delay to completion for the purposes of Sub-Clause 10.1 [Taking Over the
Works and Sections]. The agreement or determination of any such Claim,
under Sub-Clause 20.2.5 [Agreement or determination of the Claim], may
include a review by the Engineer of measured quantities of other items of
work which are significantly less (by
CONDITIONS
GENERAL
quantities, the Engineer may take account of any favourable effect on the critical
path of the Programme. However, the net effect of all such consideration
shall not result in a net reduction in the Time for Completion
When determining each EOT under Sub-Clause 20.2 [Claims For Payment
and/or EOT], the Engineer shall review previous determinations under
GUIDANCE
Sub-Clause 3.7 [Agreement or Determination] and may increase, but
shall not decrease, the total EOT.
FORMS
not stated, as appropriate taking due regard of all relevant
circumstances).
8.6
Delays Caused
by Authorities If:
(a) the Contractor has diligently followed the procedures laid down by the
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
8.7
Rate of Progress If, at any time:
(a) actual progress is too slow to complete the Works or a Section (if any)
within the relevant Time for Completion; and/or
(b) progress has fallen (or will fall) behind the Programme (or the initial
programme if it has not yet become the Programme) under Sub-
Clause
8.3 [Programme],
other than as a result of a cause listed in Sub-Clause 8.5 [Extension of Time
for Completion], then the Engineer may instruct the Contractor to submit,
under Sub-Clause 8.3 [Programme], a revised programme describing
the revised methods which the Contractor proposes to adopt in order to
expedite progress and complete the Works or a Section (if any) within
the relevant Time for Completion.
49
8.8
Delay Damages If the Contractor fails to comply with Sub-Clause 8.2 [Time for Completion],
CONDITIONS
GENERAL
exceed the maximum amount of Delay Damages (if any) stated in the
Contract Data.
These Delay Damages shall be the only damages due from the Contractor
for the Contractor’s failure to comply with Sub-Clause 8.2 [Time for
Completion], other than in the event of termination under Sub-Clause 15.2
[Termination for Contractor’s Default] before completion of the Works. These
Delay Damages shall not relieve the Contractor from the obligation to
FORMS
This Sub-Clause shall not limit the Contractor’s liability for Delay
Damages in any case of fraud, gross negligence, deliberate default or
reckless misconduct by the Contractor.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
8.9
Employer’s Suspension The Engineer may at any time instruct the Contractor to suspend progress
of part or all of the Works, which instruction shall state the date and
cause of the suspension.
During such suspension, the Contractor shall protect, store and secure such
part or all of the Works (as the case may be) against any deterioration, loss or
damage.
To the extent that the cause of such suspension is the responsibility of the
Contractor, Sub-Clauses 8.10 [Consequences of Employer’s Suspension],
8.11 [Payment for Plant and Materials after Employer’s Suspension] and
8.12 [Prolonged Suspension] shall not apply.
8.10
Consequences of
Employer’s Suspension If the Contractor suffers delay and/or incurs Cost from complying with an
Engineer’s instruction under Sub-Clause 8.9 [Employer’s Suspension] and/
or from resuming the work under Sub-Clause 8.13 [Resumption of
Work], the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or EOT] to EOT and/or payment of such Cost
Plus Profit.
8.11
Payment for Plant and Materials
after Employer’s Suspension The Contractor shall be entitled to payment of the value (as at the date of
suspension instructed under Sub-Clause 8.9 [Employer’s Suspension]) of
Plant and/or Materials which have not been delivered to Site, if:
50 © FIDIC 2017 Conditions of Contract for Construction
(a) the work on Plant, or delivery of Plant and/or Materials, has been
suspended for more than 28 days and
CONDITIONS
GENERAL
(i) the Plant and/or Materials were scheduled, in accordance
with the Programme, to have been completed and ready for
delivery to the Site during the suspension period; and
(ii) the Contractor provides the Engineer with reasonable
evidence that the Plant and/or Materials comply with the
Contract; and
GUIDANCE
(b) the Contractor has marked the Plant and/or Materials as the
Employer’s property in accordance with the Engineer’s
instructions.
8.12
Prolonged Suspension If the suspension under Sub-Clause 8.9 [Employer’s Suspension] has
continued for more than 84 days, the Contractor may give a Notice to the
FORMS
Engineer requesting permission to proceed.
agree the EOT and/or Cost Plus Profit (if the Contractor incurs Cost),
and/or payment for suspended Plant and/or Materials, arising from
the total period of suspension;
or (and if the Parties fail to reach agreement under this sub-paragraph (a))
8.13
Resumption of Work The Contractor shall resume work as soon as practicable after receiving a
Notice from the Engineer to proceed with the suspended work.
At the time stated in this Notice (if not stated, immediately after the
Contractor receives this Notice), the Contractor and the Engineer shall
jointly examine the Works and the Plant and Materials affected by the
suspension. The Engineer shall record any deterioration, loss, damage or
defect in the Works or Plant or Materials which has occurred during the
suspension and shall provide this record to the Contractor. The
Contractor shall promptly make good all such deterioration, loss, damage
or defect so that the Works, when completed, shall comply with the
Contract.
9.1 Tes
9 ts on Completion
Contractor’s Obligations The Contractor shall carry out the Tests on Completion in accordance with
this Clause and Sub-Clause 7.4 [Testing by the Contractor], after submitting
the documents under Sub-Clause 4.4.2 [As-Built Records] (if applicable)
and Sub-Clause 4.4.3 [Operation and Maintenance Manuals] (if applicable).
General Conditions © FIDIC 2017
51
The Contractor shall submit to the Engineer, not less than 42 days
before the date the Contractor intends to commence the Tests on
CONDITIONS
GENERAL
The Engineer may Review the proposed test programme and may give a
Notice to the Contractor stating the extent to which it does not comply
with the Contract. Within 14 days after receiving this Notice, the Contractor
GUIDANCE
In addition to any date(s) shown in the test programme, the Contractor shall
FORMS
give a Notice to the Engineer, of not less than 21 days, of the date after
which the Contractor will be ready to carry out each of the Tests on
Completion. The Contractor shall commence the Tests on Completion
within 14 days after this date, or on such day or days as the Engineer
shall instruct, and shall proceed in accordance with the Contractor’s test
programme to which the Engineer has given (or is deemed to have given) a
Notice of No-objection.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
9.2
Delayed Tests If the Contractor has given a Notice under Sub-Clause 9.1 [Contractor’s
Obligations] that the Works or Section (as the case may be) are ready
for Tests on Completion, and these tests are unduly delayed by the
Employer’s Personnel or by a cause for which the Employer is responsible,
Sub-Clause
10.3 [Interference with Tests on Completion] shall apply.
If the Contractor fails to carry out the Tests on Completion within this period
of 21 days:
CONDITIONS
GENERAL
For Payment and/or EOT] to payment by the Contractor of the
costs reasonably incurred.
GUIDANCE
9.3
Retesting If the Works, or a Section, fail to pass the Tests on Completion, Sub-Clause
7.5 [Defects and Rejection] shall apply. The Engineer or the Contractor may
require these failed tests, and the Tests on Completion on any related work,
to be repeated under the same terms and conditions. Such repeated
tests shall be treated as Tests on Completion for the purposes of this
FORMS
Clause.
9.4
Failure to Pass Tests
on Completion If the Works, or a Section, fail to pass the Tests on Completion repeated
under Sub-Clause 9.3 [Retesting], the Engineer shall be entitled to:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In the event of sub-paragraph (d) above, the Contractor shall then proceed
in accordance with all other obligations under the Contract, and the
Employer shall be entitled subject to Sub-Clause 20.2 [Claims For
Payment and/or EOT] to payment by the Contractor or a reduction in the
Contract Price as described under sub-paragraph (b) of Sub-Clause 11.4
[Failure to Remedy Defects], respectively. This entitlement shall be
without prejudice to any other rights the Employer may have, under the
Contract or otherwise.
10.1 Em
Works and Sections Except as stated in Sub-Clause 9.4 [Failure to Pass Tests on Completion],
Sub-Clause 10.2 [Taking Over Parts] and Sub-Clause 10.3 [Interference with
Tests on Completion], the Works shall be taken over by the Employer when:
(a) the Works have been completed in accordance with the Contract,
including the passing of the Tests on Completion and except as
allowed in sub-paragraph (i) below;
(b) if applicable, the Engineer has given (or is deemed to have given)
a Notice of No-objection to the as-built records submitted under
Sub-Clause 4.4.2 [As-Built Records];
General Conditions © FIDIC 2017
53
(c) if applicable, the Engineer has given (or is deemed to have given)
a Notice of No-objection to the operation and maintenance
CONDITIONS
GENERAL
If any Part of the Works is taken over under Sub-Clause 10.2 [Taking
FORMS
Over Parts], the remaining Works or Section shall not be taken over until
the conditions described in sub-paragraphs (a) to (e) above (where
applicable) have been fulfilled.
If the Engineer does not issue the Taking-Over Certificate or reject the
Contractor’s application within this period of 28 days, and if the
conditions described in sub-paragraphs (a) to (d) above (where applicable)
have been fulfilled, the Works or Section shall be deemed to have been
completed in accordance with the Contract on the fourteenth day after
the Engineer receives the Contractor’s Notice of application and the
Taking-Over Certificate shall be deemed to have been issued.
10.2
Taking Over Parts The Engineer may, at the sole discretion of the Employer, issue a Taking-Over
Certificate for any part of the Permanent Works.
The Employer shall not use any part of the Works (other than as a temporary
measure, which is either stated in the Specification or with the prior
agreement of the Contractor) unless and until the Engineer has issued a
Taking-Over Certificate for this part. However, if the Employer does use any
part of the Works before the Taking-Over Certificate is issued the Contractor
shall give a Notice to the Engineer identifying such part and describing such
use, and:
(a) that Part shall be deemed to have been taken over by the
Employer as from the date on which it is used;
CONDITIONS
GENERAL
(c) the Engineer shall immediately issue a Taking-Over Certificate for this
Part, and any outstanding work to be completed (including Tests
on Completion) and/or defects to be remedied shall be listed in
this certificate.
After the Engineer has issued a Taking-Over Certificate for a Part, the
GUIDANCE
Contractor shall be given the earliest opportunity to take such steps as
may be necessary to carry out the outstanding work (including Tests on
Completion) and/or remedial work for any defects listed in the certificate.
The Contractor shall carry out these works as soon as practicable and,
in any case, before the expiry date of the relevant DNP.
If the Contractor incurs Cost as a result of the Employer taking over and/
FORMS
or using a Part, the Contractor shall be entitled subject to Sub-Clause
20.2 [Claims For Payment and/or EOT] to payment of such Cost Plus
Profit.
If the Engineer issues a Taking-Over Certificate for any part of the Works, or
if the Employer is deemed to have taken over a Part under sub-paragraph
(a) above, for any period of delay after the date under sub-paragraph (a)
above, the Delay Damages for completion of the remainder of the Works
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
shall be reduced. Similarly, the Delay Damages for the remainder of the
Section (if any) in which this Part is included shall also be reduced. This
reduction shall be calculated as the proportion which the value of the
Part (except the value of any outstanding works and/or defects to be
remedied) bears to the value of the Works or Section (as the case may
be) as a whole. The Engineer shall proceed under Sub-Clause 3.7
[Agreement or Determination] to agree or determine this reduction (and
for the purpose of Sub-Clause
3.7.3 [Time limits], the date the Engineer receives the Contractor’s
Notice under this Sub-Clause shall be the date of commencement of the
time limit for agreement under Sub-Clause 3.7.3). The provisions of this
paragraph shall only apply to the daily rate of Delay Damages, and shall
not affect the maximum amount of these damages.
10.3
Interference with
Tests on Completion If the Contractor is prevented, for more than 14 days (either a continuous
period, or multiple periods which total more than 14 days), from carrying
out the Tests on Completion by the Employer’s Personnel or by a cause
for which the Employer is responsible:
(a) the Contractor shall give a Notice to the Engineer describing such
prevention;
(b) the Employer shall be deemed to have taken over the Works or
Section (as the case may be) on the date when the Tests on
Completion would otherwise have been completed; and
(c) the Engineer shall immediately issue a Taking-Over Certificate for the
Works or Section (as the case may be).
10.4
Surfaces Requiring
Reinstatement Except as otherwise stated in the Taking-Over Certificate, a certificate for a
GUIDANCE
De
1 1 fect s after Taking Over
FORMS
11.1
Completion of Outstanding Work
and Remedying Defects In order that the Works and Contractor’s Documents, and each Section and/
or Part, shall be in the condition required by the Contract (fair wear and tear
excepted) by the expiry date of the relevant Defects Notification Period or as
soon as practicable thereafter, the Contractor shall:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If a defect appears (including if the Works fail to pass the Tests after
Completion, if any) or damage occurs during the relevant DNP, a Notice
shall be given to the Contractor accordingly, by (or on behalf of) the
Employer. Promptly thereafter:
(i) the Contractor and the Employer’s Personnel shall jointly inspect
the defect or damage;
(ii) the Contractor shall then prepare and submit a proposal for
necessary remedial work; and
(iii) the second, third and fourth paragraphs of Sub-Clause 7.5
[Defects and Rejection] shall apply.
11.2
Cost of Remedying
Defects All work under sub-paragraph (b) of Sub-Clause 11.1 [Completion of
Outstanding Work and Remedying Defects] shall be executed at the risk and
cost of the Contractor, if and to the extent that the work is attributable to:
(a) design (if any) of the Works for which the Contractor is responsible;
(b) Plant, Materials or workmanship not being in accordance with the
Contract;
(c) improper operation or maintenance which was attributable to matters
for which the Contractor is responsible (under Sub-Clauses 4.4.2
[As-Built Records], Sub-Clause 4.4.3 [Operation and Maintenance
Manuals] and/or Sub-Clause 4.5 [Training] (where applicable) or
otherwise); or
CONDITIONS
GENERAL
If the Contractor considers that the work is attributable to any other
cause, the Contractor shall promptly give a Notice to the Engineer and the
Engineer shall proceed under Sub-Clause 3.7 [Agreement or Determination]
to agree or determine the cause (and, for the purpose of Sub-Clause
3.7.3 [Time limits], the date of this Notice shall be the date of
GUIDANCE
commencement of the time limit for agreement under Sub-Clause 3.7.3). If
it is agreed or determined that the work is attributable to a cause other
than those listed above, Sub-Clause 13.3.1 [Variation by Instruction] shall
apply as if such work had been instructed by the Engineer.
11.3
Extension of Defects
FORMS
Notification Period The Employer shall be entitled to an extension of the DNP for the Works, or
a Section or a Part:
(a) if and to the extent that the Works, Section, Part or a major item of
Plant (as the case may be, and after taking over) cannot be used
for the intended purpose(s) by reason of a defect or damage
which is attributable to any of the matters under sub-paragraphs
(a) to (d) of Sub-Clause 11.2 [Cost of Remedying Defects]; and
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
11.4
Failure to Remedy Defects If the remedying of any defect or damage under Sub-Clause 11.1 [Completion
of Outstanding Works and Remedying Defects] is unduly delayed by the
Contractor, a date may be fixed by (or on behalf of) the Employer, on or
by which the defect or damage is to be remedied. A Notice of this fixed
date shall be given to the Contractor by (or on behalf of) the Employer,
which Notice shall allow the Contractor reasonable time (taking due
regard of all relevant circumstances) to remedy the defect or damage.
If the Contractor fails to remedy the defect or damage by the date stated
in this Notice and this remedial work was to be executed at the cost of
the Contractor under Sub-Clause 11.2 [Cost of Remedying Defects], the
Employer may (at the Employer’s sole discretion):
(a) carry out the work or have the work carried out by others
(including any retesting), in the manner required under the
Contract and at the Contractor’s cost, but the Contractor shall
have no responsibility for this work. The Employer shall be entitled
subject to Sub-Clause 20.2 [Claims For Payment and/or EOT] to
payment by the Contractor of the costs reasonably incurred by the
Employer in remedying the defect or damage;
EOT] to recover from the Contractor all sums paid for the Works,
plus financing charges and any costs incurred in dismantling the
same, clearing the Site and returning Plant and Materials to the
Contractor.
11.5
Remedying of Defective
Work off Site If, during the DNP, the Contractor considers that any defect or damage
in any Plant cannot be remedied expeditiously on the Site the Contractor
shall give a Notice, with reasons, to the Employer requesting consent to
remove the defective or damaged Plant off the Site for the purposes of
repair. This Notice shall clearly identify each item of defective or
damaged Plant, and shall give details of:
The Contractor shall also provide any further details that the Employer may
reasonably require.
When the Employer gives consent (which consent shall not relieve the
Contractor from any obligation or responsibility under this Clause), the
Contractor may remove from the Site such items of Plant as are
defective or damaged. As a condition of this consent, the Employer may
require the Contractor to increase the amount of the Performance
Security by the full replacement cost of the defective or damaged Plant.
CONDITIONS
GENERAL
Remedying Defects Within 7 days of completion of the work of remedying of any defect or
damage, the Contractor shall give a Notice to the Engineer describing
the remedied Works, Section, Part and/or Plant and the proposed
repeated tests (under Clause 9 [Tests on Completion]). Within 7 days
after receiving this Notice, the Engineer shall give a Notice to the
Contractor either:
GUIDANCE
(a) agreeing with such proposed testing; or
(b) instructing the repeated tests that are necessary to demonstrate
that the remedied Works, Section, Part and/or Plant comply with
the Contract.
If the Contractor fails to give such a Notice within the 7 days, the Engineer
FORMS
may give a Notice to the Contractor, within 14 days after the defect or
damage is remedied, instructing the repeated tests that are necessary to
demonstrate that the remedied Works, Section, Part and/or Plant comply
with the Contract.
11.7
Right of Access
after Taking Over Until the date 28 days after issue of the Performance Certificate, the
Contractor shall have the right of access to the Works as is reasonably
required in order to comply with this Clause, except as may be
inconsistent with the Employer’s reasonable security restrictions.
Whenever the Contractor intends to access any part of the Works during the
relevant DNP:
11.8
Contractor to Search The Contractor shall, if instructed by the Engineer, search for the cause of
any defect, under the direction of the Engineer. The Contractor shall
carry out the search on the date(s) stated in the Engineer’s instruction or
other date(s) agreed with the Engineer.
General Conditions © FIDIC 2017
59
Unless the defect is to be remedied at the cost of the Contractor under
Sub-Clause 11.2 [Cost of Remedying Defects], the Contractor shall be
CONDITIONS
GENERAL
If the Contractor fails to carry out the search in accordance with this
Sub-Clause, the search may be carried out by the Employer’s Personnel.
The Contractor shall be given a Notice of the date when such a search
GUIDANCE
will be carried out and the Contractor may attend at the Contractor’s own
cost. If the defect is to be remedied at the cost of the Contractor under Sub-
Clause
11.2 [Cost of Remedying Defects], the Employer shall be entitled subject
to Sub-Clause 20.2 [Claims For Payment and/or EOT] to payment by the
Contractor of the costs of the search reasonably incurred by the
Employer.
FORMS
11.9
Performance Certificate Performance of the Contractor’s obligations under the Contract shall not
be considered to have been completed until the Engineer has issued the
Performance Certificate to the Contractor, stating the date on which the
Contractor fulfilled the Contractor’s obligations under the Contract.
The Engineer shall issue the Performance Certificate to the Contractor (with
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
a copy to the Employer and to the DAAB) within 28 days after the latest
of the expiry dates of the Defects Notification Periods, or as soon thereafter
as the Contractor has:
If the Engineer fails to issue the Performance Certificate within this period of
28 days, the Performance Certificate shall be deemed to have been
issued on the date 28 days after the date on which it should have been
issued, as required by this Sub-Clause.
11.10
Unfulfilled Obligations After the issue of the Performance Certificate, each Party shall remain liable
for the fulfilment of any obligation which remains unperformed at that
time. For the purposes of determining the nature and extent of
unperformed obligations, the Contract shall be deemed to remain in
force.
However in relation to Plant, the Contractor shall not be liable for any defects
or damage occurring more than two years after expiry of the DNP for the
Plant except if prohibited by law or in any case of fraud, gross
negligence, deliberate default or reckless misconduct.
11.11
Clearance of Site Promptly after the issue of the Performance Certificate, the Contractor shall:
CONDITIONS
GENERAL
If the Contractor fails to comply with sub-paragraphs (a), (b) and/or (c) above
within 28 days after the issue of the Performance Certificate, the
Employer may sell (to the extent permitted by applicable Laws) or
otherwise dispose of any remaining items and/or may reinstate and
clean the Site (as may be necessary) at the Contractor’s cost.
GUIDANCE
The Employer shall be entitled subject to Sub-Clause 20.2 [Claims For
Payment and/or EOT] to payment by the Contractor of the costs reasonably
incurred in connection with, or attributable to, such sale or disposal and
reinstating and/or cleaning the Site, less an amount equal to the moneys
from the sale (if any).
FORMS
12.1
Me
Works to be Measured
1 2 asu rement and Valuation
The Works shall be measured, and valued for payment, in accordance with
this Clause.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If, for any part of the Works, the Contractor attends the measurement on
Site or examines the measurement records (as the case may be) but the
Engineer and the Contractor are unable to agree the measurement, then
the Contractor shall give a Notice to the Engineer setting out the reasons
why the Contractor considers the measurement on Site or records are
inaccurate. If the Contractor does not give such a Notice to the Engineer
12.2
Method of Measurement The method of measurement shall be as stated in the Contract Data or, if
not so stated, that which shall be in accordance with the Bill of Quantities or
other applicable Schedule(s).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
12.3
Valuation of the Works Except as otherwise stated in the Contract, the Engineer shall value
each item of work by applying the measurement agreed or determined
in accordance with Sub-Clauses 12.1 [Works to be Measured] and 12.2
[Method of Measurement], and the appropriate rate or price for the item.
For each item of work, the appropriate rate or price for the item shall be
the rate or price specified for such item in the Bill of Quantities or other
Schedule or, if there is no such an item, specified for similar work.
(a) the item is not identified in, and no rate or price for this item is
specified in, the Bill of Quantities or other Schedule and no specified
rate or price is appropriate because the item of work is not of
similar character, or is not executed under similar conditions, as
any item in the Contract;
(b) (i) the measured quantity of the item is changed by more than
10% from the quantity of this item in the Bill of Quantities or
other Schedule,
(ii) this change in quantity multiplied by the rate or price specified
in the Bill of Quantities or other Schedule for this item
exceeds 0.01% of the Accepted Contract Amount,
(iii) this change in quantity directly changes the Cost per unit quantity
of this item by more than 1%, and
CONDITIONS
GENERAL
referring to a rate or price which is not subject to adjustment for
any change in quantity; and/or
(c) the work is instructed under Clause 13 [Variations and
Adjustments] and sub-paragraph (a) or (b) above applies.
Each new rate or price shall be derived from any relevant rates or prices
GUIDANCE
specified in the Bill of Quantities or other Schedule, with reasonable
adjustments to take account of the matters described in sub-paragraph (a),
(b) and/or (c), as applicable. If no specified rates or prices are relevant for
the derivation of a new rate or price, it shall be derived from the reasonable
Cost of executing the work, together with the applicable percentage for
profit stated in the Contract Data (if not stated, five percent (5%)), taking
account of any other relevant matters.
FORMS
If, for any item of work, the Engineer and the Contractor are unable to agree
the appropriate rate or price, then the Contractor shall give a Notice to
the Engineer setting out the reasons why the Contractor disagrees. After
receiving a Contractor’s Notice under this Sub-Clause, unless at that
time such rate or price is already subject to the last paragraph of Sub-
Clause
13.3.1 [Variation by Instruction], the Engineer shall:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
12.4
Omissions Whenever the omission of any work forms part (or all) of a Variation;
13.1
Right to Vary
Va
1 3 riatio ns and Adjustments
(a) the varied work was Unforeseeable having regard to the scope
and nature of the Works described in the Specification;
(b) the Contractor cannot readily obtain the Goods required for the
Variation; or
(c) it will adversely affect the Contractor’s ability to comply with
FORMS
Promptly after receiving this Notice, the Engineer shall respond by giving
a Notice to the Contractor cancelling, confirming or varying the
instruction. Any instruction so confirmed or varied shall be taken as an
instruction under Sub-Clause 13.3.1 [Variation by instruction].
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(i) changes to the quantities of any item of work included in the Contract
(however, such changes do not necessarily constitute a Variation);
(ii) changes to the quality and other characteristics of any item of work;
(iii) changes to the levels, positions and/or dimensions of any part of
the Works;
(iv) the omission of any work, unless it is to be carried out by others
without the agreement of the Parties;
(v) any additional work, Plant, Materials or services necessary for the
Permanent Works, including any associated Tests on Completion,
boreholes and other testing and exploratory work; or
(vi) changes to the sequence or timing of the execution of the Works.
13.2
Value Engineering The Contractor may, at any time, submit to the Engineer a written proposal
which (in the Contractor’s opinion) will, if adopted:
The proposal shall be prepared at the cost of the Contractor and shall
include the details as stated in sub-paragraphs (a) to (c) of Sub-Clause
13.3.1 [Variation by Instruction].
CONDITIONS
GENERAL
awaiting a response.
GUIDANCE
[Variation by Instruction] shall apply which shall include consideration by the
Engineer of the sharing (if any) of the benefit, costs and/or delay between
the Parties stated in the Particular Conditions.
FORMS
(i) the Contractor shall design this part at his/her cost; and
(ii) sub-paragraphs (a) to (h) of Sub-Clause 4.1 [Contractor’s General
Obligations] shall apply.
13.3
Variation Procedure Subject to Sub-Clause 13.1 [Right to Vary], Variations shall be initiated by
the Engineer in accordance with either of the following procedures:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall proceed with execution of the Variation and shall within
28 days (or other period proposed by the Contractor and agreed by the
Engineer) of receiving the Engineer’s instruction, submit to the Engineer
detailed particulars including:
Thereafter, the Contractor shall submit any further particulars that the
Engineer may reasonably require.
13.4
Provisional Sums Each Provisional Sum shall only be used, in whole or in part, in accordance
with the Engineer’s instructions, and the Contract Price shall be adjusted
accordingly. The total sum paid to the Contractor shall include only such
amounts for the work, supplies or services to which the Provisional Sum
relates, as the Engineer shall have instructed.
CONDITIONS
GENERAL
(ii) a sum for overhead charges and profit, calculated as a
percentage of these actual amounts by applying the relevant
percentage rate (if any) stated in the applicable Schedule. If
there is no such rate, the percentage rate stated in the Contract
Data shall be applied.
GUIDANCE
If the Engineer instructs the Contractor under sub-paragraph (a) and/or
(b) above, this instruction may include a requirement for the Contractor
to submit quotations from the Contractor’s suppliers and/or subcontractors
for all (or some) of the items of the work to be executed or Plant,
Materials, works or services to be purchased. Thereafter, the Engineer
may respond by giving a Notice either instructing the Contractor to
accept one of these quotations (but such an instruction shall not be taken
FORMS
as an instruction under Sub-Clause 5.2 [Nominated Subcontractors]) or
revoking the instruction. If the Engineer does not so respond within 7 days
of receiving the quotations, the Contractor shall be entitled to accept any
of these quotations at the Contractor’s discretion.
Each Statement that includes a Provisional Sum shall also include all
applicable invoices, vouchers and accounts or receipts in substantiation
of the Provisional Sum.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
13.5
Daywork If a Daywork Schedule is not included in the Contract, this Sub-Clause shall
not apply.
For work of a minor or incidental nature, the Engineer may instruct that a
Variation shall be executed on a daywork basis. The work shall then be
valued in accordance with the Daywork Schedule, and the following
procedure shall apply.
Before ordering Goods for such work (other than any Goods priced in the
Daywork Schedule), the Contractor shall submit one or more quotations from
the Contractor’s suppliers and/or subcontractors to the Engineer. Thereafter,
the Engineer may instruct the Contractor to accept one of these
quotations (but such an instruction shall not be taken as an instruction under
Sub-Clause
5.2 [Nominated Subcontractors]). If the Engineer does not so instruct the
Contractor within 7 days of receiving the quotations, the Contractor shall be
entitled to accept any of these quotations at the Contractor’s discretion.
Except for any items for which the Daywork Schedule specifies that payment
is not due, the Contractor shall deliver each day to the Engineer
accurate statements in duplicate (and one electronic copy), which shall
include records (as described under Sub-Clause 6.10 [Contractor’s
Records]) of the resources used in executing the previous day’s work.
Unless otherwise stated in the Daywork Schedule, the rates and prices in the
Daywork Schedule shall be deemed to include taxes, overheads and profit.
13.6
Adjustments for
GUIDANCE
Changes in Laws Subject to the following provisions of this Sub-Clause, the Contract Price
shall be adjusted to take account of any increase or decrease in Cost
resulting from a change in:
(a) the Laws of the Country (including the introduction of new Laws
and the repeal or modification of existing Laws);
(b) the judicial or official governmental interpretation or implementation of
FORMS
made and/or officially published after the Base Date, which affect the
Contractor in the performance of obligations under the Contract. In
this Sub-Clause “change in Laws” means any of the changes under
sub-paragraphs (a), (b), (c) and/or (d) above.
13.7
Adjustments for
Changes in Cost If Schedule(s) of cost indexation are not included in the Contract, this
Sub-Clause shall not apply.
The amounts payable to the Contractor shall be adjusted for rises or falls
in the cost of labour, Goods and other inputs to the Works, by the
addition or deduction of the amounts calculated in accordance with the
Schedule(s) of cost indexation.
CONDITIONS
GENERAL
Accepted Contract Amount shall be deemed to have included amounts
to cover the contingency of other rises and falls in costs.
GUIDANCE
be applied to work valued on the basis of Cost or current prices.
Until such time as each current cost index is available, the Engineer
shall use a provisional index for the issue of Interim Payment Certificates.
When a current cost index is available, the adjustment shall be
recalculated accordingly.
FORMS
If the Contractor fails to complete the Works within the Time for Completion,
adjustment of prices thereafter shall be made using either:
(a) each index or price applicable on the date 49 days before the
expiry of the Time for Completion of the Works; or
(b) the current index or price
whichever is more favourable to the Employer.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
14.1
Co
(a) the Contract Price shall be the value of the Works in accordance
with Sub-Clause 12.3 [Valuation of the Works] and be subject to
adjustments, additions (including Cost or Cost Plus Profit to which
the Contractor is entitled under these Conditions) and/or deductions
in accordance with the Contract;
(b) the Contractor shall pay all taxes, duties and fees required to be paid
by the Contractor under the Contract, and the Contract Price shall
not be adjusted for any of these costs except as stated in Sub-Clause
13.6 [Adjustments for Changes in Laws];
(c) any quantities which may be set out in the Bill of Quantities or
other Schedule(s) are estimated quantities and are not to be taken
as the actual and correct quantities:
(i) of the Works which the Contractor is required to execute, or
(ii) for the purposes of Clause 12 [Measurement and Valuation]; and
(d) the Contractor shall submit to the Engineer, within 28 days after
the Commencement Date, a proposed breakdown of each lump
sum price (if any) in the Schedules. The Engineer may take
account of the breakdown when preparing Payment Certificates, but
shall not be bound by it.
14.2
Advance Payment If no amount of advance payment is stated in the Contract Data, this
Sub-Clause shall not apply.
After receiving the Advance Payment Certificate, the Employer shall make
an advance payment, as an interest-free loan for mobilisation (and design, if
valid and enforceable until the advance payment has been repaid, but its
amount may be progressively reduced by the amount repaid by the
Contractor as stated in the Payment Certificates.
If the terms of the Advance Payment Guarantee specify its expiry date, and
the advance payment has not been repaid by the date 28 days before
the expiry date:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(a) the Contractor shall extend the validity of this guarantee until the
advance payment has been repaid;
(b) the Contractor shall immediately submit evidence of this extension to
the Employer, with a copy to the Engineer; and
(c) if the Employer does not receive this evidence 7 days before the
expiry date of this guarantee, the Employer shall be entitled to
claim under the guarantee the amount of advance payment which
has not been repaid.
The Engineer shall issue an Advance Payment Certificate for the advance
payment within 14 days after:
(a) the Employer has received both the Performance Security and the
Advance Payment Guarantee, in the form and issued by an entity
in accordance with Sub-Clause 4.2.1 [Contractor’s Obligations]
and Sub-Clause 14.2.1 [Advance Payment Guarantee] respectively;
and
(b) the Engineer has received a copy of the Contractor’s application for
the advance payment under Sub-Clause 14.2.1 [Advance
Payment Guarantee].
14.2.3 Repayment of Advance Payment
(a) deductions shall commence in the IPC in which the total of all
certified interim payments in the same currency as the advance
payment (excluding the advance payment and deductions and
release of retention moneys) exceeds ten percent (10%) of the
portion of the
70
© FIDIC 2017 Conditions of Contract for Construction
Accepted Contract Amount payable in that currency less
Provisional Sums; and
CONDITIONS
GENERAL
(b) deductions shall be made at the amortisation rate of one quarter
(25%) of the amount of each IPC (excluding the advance payment
and deductions and release of retention moneys) in the currencies
and proportions of the advance payment, until such time as the
advance payment has been repaid.
GUIDANCE
If the advance payment has not been repaid before the issue of the
Taking-Over Certificate for the Works, or before termination under
Clause 15 [Termination by Employer], Clause 16 [Suspension and
Termination by Contractor] or Clause 18 [Exceptional Events] (as the
case may be), the whole of the balance then outstanding shall
immediately become due and payable by the Contractor to the
Employer.
FORMS
14.3
Application for
Interim Payment The Contractor shall submit a Statement to the Engineer after the end of the
period of payment stated in the Contract Data (if not stated, after the end
of each month). Each Statement shall:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Statement shall include the following items, as applicable, which shall
be expressed in the various currencies in which the Contract Price is
payable, in the sequence listed:
(i) the estimated contract value of the Works executed, and the
Contractor’s Documents produced, up to the end of the period of
payment (including Variations but excluding items described in
sub-paragraphs (ii) to (x) below);
(ii) any amounts to be added and/or deducted for changes in Laws
under Sub-Clause 13.6 [Adjustments for Changes in Laws], and
for changes in Cost under Sub-Clause 13.7 [Adjustments for
Changes in Cost];
(iii) any amount to be deducted for retention, calculated by applying
the percentage of retention stated in the Contract Data to the total
of the amounts under sub-paragraphs (i), (ii) and (vi) of this Sub-
Clause, until the amount so retained by the Employer reaches the
limit of Retention Money (if any) stated in the Contract Data;
(iv) any amounts to be added and/or deducted for the advance
payment and repayments under Sub-Clause 14.2 [Advance
Payment];
(v) any amounts to be added and/or deducted for Plant and Materials
under Sub-Clause 14.5 [Plant and Materials intended for the Works];
(vi) any other additions and/or deductions which have become due under
the Contract or otherwise, including those under Sub-Clause 3.7
[Agreement or Determination];
(vii) any amounts to be added for Provisional Sums under Sub-Clause
13.4 [Provisional Sums];
General Conditions © FIDIC 2017
71
(viii) any amount to be added for release of Retention Money under
Sub-Clause 14.9 [Release of Retention Money];
CONDITIONS
GENERAL
14.4
GUIDANCE
Schedule of Payments If the Contract includes a Schedule of Payments specifying the instalments
in which the Contract Price will be paid then, unless otherwise stated in this
Schedule:
14.5
Plant and Materials
intended for the Works If no Plant and/or Materials are listed in the Contract Data for payment when
shipped and/or payment when delivered, this Sub-Clause shall not apply.
CONDITIONS
GENERAL
(a) the Contractor has:
(i) kept satisfactory records (including the orders, receipts, Costs
and use of Plant and Materials) which are available for inspection
by the Engineer;
(ii) submitted evidence demonstrating that the Plant and
GUIDANCE
Materials comply with the Contract (which may include test
certificates under Sub-Clause 7.4 [Testing by the Contractor]
and/or compliance verification documentation under Sub-
Clause 4.9.2 [Compliance Verification System]) to the
Engineer; and
(iii) submitted a statement of the Cost of acquiring and shipping
or delivering (as the case may be) the Plant and Materials to
FORMS
the Site, supported by satisfactory evidence;
and either:
(a) the Employer has received the Performance Security in the form,
and issued by an entity, in accordance with Sub-Clause 4.2.1
[Contractor’s obligations]; and
(b) the Contractor has appointed the Contractor’s Representative in
accordance with Sub-Clause 4.3 [Contractor’s Representative].
Before the issue of the Taking-Over Certificate for the Works, the
Engineer may withhold an IPC in an amount which would (after retention
and other deductions) be less than the minimum amount of the IPC (if
any) stated in the Contract Data. In this event, the Engineer shall promptly
give a Notice to the Contractor accordingly.
For each amount so withheld, in the supporting particulars for the IPC
the Engineer shall detail his/her calculation of the amount and state the
reasons for it being withheld.
CONDITIONS
GENERAL
The Engineer may in any Payment Certificate make any correction or
modification that should properly be made to any previous Payment
Certificate. A Payment Certificate shall not be deemed to indicate the
Engineer’s acceptance, approval, consent or Notice of No-objection to
any Contractor’s Document or to (any part of) the Works.
GUIDANCE
If the Contractor considers that an IPC does not include any amounts to
which the Contractor is entitled, these amounts shall be identified in the next
Statement (the “identified amounts” in this paragraph). The Engineer
shall then make any correction or modification that should properly be
made in the next Payment Certificate. Thereafter, to the extent that:
(a) the Contractor is not satisfied that this next Payment Certificate
includes the identified amounts; and
FORMS
(b) the identified amounts do not concern a matter for which the
Engineer is already carrying out his/her duties under Sub-Clause 3.7
[Agreement or Determination]
the Contractor may, by giving a Notice, refer this matter to the Engineer
and Sub-Clause 3.7 [Agreement or Determination] shall apply (and, for
the purpose of Sub-Clause 3.7.3 [Time limits], the date the Engineer
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
receives this Notice shall be the date of commencement of the time limit
for agreement under Sub-Clause 3.7.3).
14.7
Payment The Employer shall pay to the Contractor:
(a) the amount certified in each Advance Payment Certificate within the
period stated in the Contract Data (if not stated, 21 days) after the
Employer receives the Advance Payment Certificate;
(b) the amount certified in each IPC issued under:
(i) Sub-Clause 14.6 [Issue of IPC], within the period stated in the
Contract Data (if not stated, 56 days) after the Engineer receives
the Statement and supporting documents; or
(ii) Sub-Clause 14.13 [Issue of FPC], within the period stated in
the Contract Data (if not stated, 28 days) after the Employer
receives the IPC; and
(c) the amount certified in the FPC within the period stated in the
Contract Data (if not stated, 56 days) after the Employer receives
the FPC.
Payment of the amount due in each currency shall be made into the
bank account, nominated by the Contractor, in the payment country (for
this currency) specified in the Contract.
14.8
Delayed Payment If the Contractor does not receive payment in accordance with Sub-Clause
14.7 [Payment], the Contractor shall be entitled to receive financing charges
compounded monthly on the amount unpaid during the period of delay.
This period shall be deemed to commence on the expiry of the time for
payment specified in Sub-Clause 14.7 [Payment], irrespective (in the
case of sub-paragraph (b) of Sub-Clause 14.7) of the date on which any
IPC is issued.
Unless otherwise stated in the Contract Data, these financing charges shall
be calculated at the annual rate of three percent (3%) above:
(b) where no such rate exists at that place, the same rate in the
country of the currency of payment, or
(c) in the absence of such a rate at either place, the appropriate rate
fixed by the law of the country of the currency of payment.
14.9
Release of
Retention Money After the issue of the Taking-Over Certificate for:
(a) the Works, the Contractor shall include the first half of the
Retention Money in a Statement; or
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(b) for a Section, the Contractor shall include the relevant percentage of
the first half of the Retention Money in a Statement.
After the latest of the expiry dates of the Defects Notification Periods,
the Contractor shall include the second half of the Retention Money in a
Statement promptly after such latest date. If a Taking-Over Certificate
was (or was deemed to have been) issued for a Section, the Contractor
shall include the relevant percentage of the second half of the Retention
Money in a Statement promptly after the expiry date of the DNP for the
Section.
In the next IPC after the Engineer receives any such Statement, the
Engineer shall certify the release of the corresponding amount of
Retention Money. However, when certifying any release of Retention
Money under Sub-Clause
14.6 [Issue of IPC], if any work remains to be executed under Clause
11 [Defects after Taking Over], the Engineer shall be entitled to withhold
certification of the estimated cost of this work until it has been executed.
The relevant percentage for each Section shall be the percentage value
of the Section as stated in the Contract Data. If the percentage value of a
Section is not stated in the Contract Data, no percentage of either half of the
Retention Money shall be released under this Sub-Clause in respect of such
Section.
14.10
Statement at Completion Within 84 days after the Date of Completion of the Works, the Contractor
shall submit to the Engineer a Statement at completion with supporting
documents, in accordance with Sub-Clause 14.3 [Application for Interim
Payment], showing:
(a) the value of all work done in accordance with the Contract up to
the Date of Completion of the Works
(b) any further sums which the Contractor considers to be due at the
Date of Completion of the Works; and
(c) an estimate of any other amounts which the Contractor considers
have or will become due after the Date of Completion of the
Works under the Contract or otherwise. These estimated amounts
shall be
76 © FIDIC 2017 Conditions of Contract for Construction
shown separately (to those of sub-paragraphs (a) and (b) above) and
shall include estimated amounts for:
CONDITIONS
GENERAL
(i) Claims for which the Contractor has submitted a Notice under
Sub-Clause 20.2 [Claims For Payment and/or EOT];
(ii) any matter referred to the DAAB under Sub-Clause 21.4
[Obtaining DAAB’s Decision]; and
(iii) any matter for which a NOD has been given under Sub-
Clause
GUIDANCE
21.4 [Obtaining DAAB’s Decision].
The Engineer shall then issue an IPC in accordance with Sub-Clause
14.6 [Issue of IPC].
14.11
Final Statement Submission by the Contractor of any Statement under the following
FORMS
provisions of this Sub-Clause shall not be delayed by reason of any referral
under Sub-Clause 21.4 [Obtaining DAAB’s Decision] or any arbitration under
Sub-Clause 21.6 [Arbitration].
Within 56 days after the issue of the Performance Certificate, the Contractor
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
14.12
Discharge When submitting the Final Statement or the Partially Agreed Final Statement
(as the case may be), the Contractor shall submit a discharge which
FORMS
confirms that the total of such Statement represents full and final
settlement of all moneys due to the Contractor under or in connection
with the Contract. This discharge may state that the total of the
Statement is subject to any payment that may become due in respect of
any Dispute for which a DAAB proceeding or arbitration is in progress
under Sub-Clause 21.6 [Arbitration] and/or that it becomes effective after
the Contractor has received:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
A discharge under this Sub-Clause shall not affect either Party’s liability
or entitlement in respect of any Dispute for which a DAAB proceeding or
arbitration is in progress under Clause 21 [Disputes and Arbitration].
14.13
Issue of FPC Within 28 days after receiving the Final Statement or the Partially Agreed
Final Statement (as the case may be), and the discharge under Sub-Clause
14.12 [Discharge], the Engineer shall issue to the Employer (with a copy
to the Contractor), the Final Payment Certificate which shall state:
(a) the amount which the Engineer fairly considers is finally due, including
any additions and/or deductions which have become due under
Sub-Clause 3.7 [Agreement or Determination] or under the
Contract or otherwise; and
(b) after giving credit to the Employer for all amounts previously paid
by the Employer and for all sums to which the Employer is
entitled, and after giving credit to the Contractor for all amounts (if
any) previously paid by the Contractor and/or received by the
Employer under the Performance Security, the balance (if any) due
from the Employer to the Contractor or from the Contractor to the
Employer, as the case may be.
If the Contractor has not submitted a draft final Statement within the time
specified under Sub-Clause 14.11.1 [Draft Final Statement], the
Engineer shall request the Contractor to do so. Thereafter, if the
Contractor fails to submit a draft final Statement within a period of 28 days,
the Engineer shall issue the FPC for such an amount as the Engineer fairly
considers to be due.
CONDITIONS
GENERAL
(i) the Contractor has submitted a Partially Agreed Final Statement
under Sub-Clause 14.11.2 [Agreed Final Statement]; or
(ii) no Partially Agreed Final Statement has been submitted by the
Contractor but, to the extent that a draft final Statement submitted
by the Contractor is deemed by the Engineer to be a Partially Agreed
Final Statement
GUIDANCE
the Engineer shall proceed in accordance with Sub-Clause 14.6 [Issue of
IPC] to issue an IPC.
14.14
Cessation of
Employer’s Liability The Employer shall not be liable to the Contractor for any matter or thing
FORMS
under or in connection with the Contract or execution of the Works,
except to the extent that the Contractor shall have included an amount
expressly for it in:
However, this Sub-Clause shall not limit the Employer’s liability under the
Employer’s indemnification obligations, or the Employer’s liability in any case
of fraud, gross negligence, deliberate default or reckless misconduct by the
Employer.
14.15
Currencies of Payment The Contract Price shall be paid in the currency or currencies named in the
Contract Data. If more than one currency is so named, payments shall
be made as follows:
Ter
1 5 min ation by Employer
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
15.1
Notice to Correct If the Contractor fails to carry out any obligation under the Contract the
Engineer may, by giving a Notice to the Contractor, require the
Contractor to make good the failure and to remedy it within a specified
time (“Notice to Correct” in these Conditions).
The time specified in the Notice to Correct shall not imply any extension
of the Time for Completion.
15.2
Termination for
Contractor’s Default Termination of the Contract under this Clause shall not prejudice any
other rights of the Employer under the Contract or otherwise.
15.2.1 Notice
The Employer shall be entitled to give a Notice (which shall state that it
is given under this Sub-Clause 15.2.1) to the Contractor of the
Employer’s intention to terminate the Contract or, in the case of sub-
paragraph (f), (g) or
(h) below a Notice of termination, if the Contractor:
CONDITIONS
(i) a Notice to Correct;
GENERAL
(ii) a binding agreement, or final and binding determination,
under Sub-Clause 3.7 [Agreement or Determination]; or
(iii) a decision of the DAAB under 21.4 [Obtaining DAAB’s Decision]
(whether binding or final and binding)
and such failure constitutes a material breach of the Contractor’s obligations
GUIDANCE
under the Contract;
FORMS
or, if there is a maximum amount of Delay Damages stated in the
Contract Data, his failure to comply with Sub-Clause 8.2 [Time for
Completion] is such that the Employer would be entitled to Delay
Damages that exceed this maximum amount;
(d) without reasonable excuse fails to comply with a Notice of
rejection given by the Engineer under Sub-Clause 7.5 [Defects and
Rejection] or an Engineer’s instruction under Sub-Clause 7.6
[Remedial Work], within 28 days after receiving it;
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
15.2.2 Termination
(ii) for the protection of life or property or for the safety of the Works;
(b) deliver to the Engineer:
(i) any Goods required by the Employer,
(ii) all Contractor’s Documents, and
(iii) all other design documents made by or for the Contractor to
the extent, if any, that the Contractor is responsible for the
FORMS
After termination under this Sub-Clause, the Employer may complete the
Works and/or arrange for any other entities to do so. The Employer
and/or these entities may then use any Goods and Contractor’s
Documents (and other design documents, if any) made by or on behalf
of the Contractor to complete the Works.
After such completion of the Works, the Employer shall give another Notice
to the Contractor that the Contractor’s Equipment and Temporary Works
will be released to the Contractor at or near the Site. The Contractor
shall then promptly arrange their removal, at the risk and cost of the
Contractor. However, if by this time the Contractor has failed to make a
payment due to the Employer, these items may be sold (to the extent
permitted by applicable Laws) by the Employer in order to recover this
payment. Any balance of the proceeds shall then be paid to the
Contractor.
15.3
Valuation after Termination
for Contractor’s Default After termination of the Contract under Sub-Clause 15.2 [Termination
for Contractor’s Default], the Engineer shall proceed under Sub-Clause
3.7 [Agreement or Determination] to agree or determine the value of the
Permanent Works, Goods and Contractor’s Documents, and any other
sums due to the Contractor for work executed in accordance with the
Contract (and, for the purpose of Sub-Clause 3.7.3 [Time limits], the date
of termination shall be the date of commencement of the time limit for
agreement under Sub-Clause 3.7.3).
This valuation shall include any additions and/or deductions, and the
balance due (if any), by reference to the matters described in sub-
paragraphs (a) and
(b) of Sub-Clause 14.13 [Issue of FPC].
This valuation shall not include the value of any Contractor’s Documents,
Materials, Plant and Permanent Works to the extent that they do not comply
with the Contract.
CONDITIONS
GENERAL
for Contractor’s Default The Employer may withhold payment to the Contractor of the amounts
agreed or determined under Sub-Clause 15.3 [Valuation after Termination
for Contractor’s Default] until all the costs, losses and damages (if any)
described in the following provisions of this Sub-Clause have been
established.
GUIDANCE
After termination of the Contract under Sub-Clause 15.2 [Termination for
Contractor’s Default], the Employer shall be entitled subject to Sub-Clause
20.2 [Claims For Payment and/or EOT] to payment by the Contractor of:
(a) the additional costs of execution of the Works, and all other costs
reasonably incurred by the Employer (including costs incurred
in clearing, cleaning and reinstating the Site as described under
Sub-Clause 11.11 [Clearance of Site]), after allowing for any sum due
FORMS
to the Contractor under Sub-Clause 15.3 [Valuation after Termination
for Contractor’s Default];
(b) any losses and damages suffered by the Employer in completing the
Works; and
(c) Delay Damages, if the Works or a Section have not been taken
over under Sub-Clause 10.1 [Taking Over the Works and
Sections] and if the date of termination under Sub-Clause 15.2
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
15.5
Termination for
Employer’s Convenience The Employer shall be entitled to terminate the Contract at any time for the
Employer’s convenience, by giving a Notice of such termination to the
Contractor (which Notice shall state that it is given under this Sub-Clause
15.5).
After giving a Notice to terminate under this Sub-Clause, the Employer shall
immediately:
Termination under this Sub-Clause shall take effect 28 days after the
later of the dates on which the Contractor receives this Notice or the
Employer returns the Performance Security. Unless and until the
Contractor has received payment of the amount due under Sub-Clause 15.6
[Valuation after Termination for Employer’s Convenience], the Employer
shall not execute (any part of) the Works or arrange for (any part of) the
Works to be executed by any other entities.
for Employer’s Convenience After termination under Sub-Clause 15.5 [Termination for Employer’s
Convenience] the Contractor shall, as soon as practicable, submit detailed
supporting particulars (as reasonably required by the Engineer) of:
The Engineer shall issue a Payment Certificate for the amount so agreed or
determined, without the need for the Contractor to submit a Statement.
15.7
Payment after Termination
for Employer’s Convenience The Employer shall pay the Contractor the amount certified in the Payment
Certificate under Sub-Clause 15.6 [Valuation after Termination for
Employer’s Convenience] within 112 days after the Engineer receives the
Contractor’s submission under that Sub-Clause.
16.1
Su
1 6spen
Suspension by Contractor
sion and Termination by Contractor
If:
the Contractor may, not less than 21 days after giving a Notice to the
Employer (which Notice shall state that it is given under this Sub-Clause
16.1), suspend work (or reduce the rate of work) unless and until the
Employer has remedied such a default.
CONDITIONS
GENERAL
under Sub-Clause 16.2 [Termination by Contractor].
GUIDANCE
If the Contractor suffers delay and/or incurs Cost as a result of
suspending work (or reducing the rate of work) in accordance with this
Sub-Clause, the Contractor shall be entitled subject to Sub-Clause 20.2
[Claims For Payment and/or EOT] to EOT and/or payment of such Cost
Plus Profit.
FORMS
16.2
Termination by Contractor Termination of the Contract under this Clause shall not prejudice any other
rights of the Contractor, under the Contract or otherwise.
16.2.1 Notice
The Contractor shall be entitled to give a Notice (which shall state that it
is given under this Sub-Clause 16.2.1) to the Employer of the
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(a) the Contractor does not receive the reasonable evidence within 42
days after giving a Notice under Sub-Clause 16.1 [Suspension by
Contractor] in respect of a failure to comply with Sub-Clause 2.4
[Employer’s Financial Arrangements];
(b) the Engineer fails, within 56 days after receiving a Statement and
supporting documents, to issue the relevant Payment Certificate;
(c) the Contractor does not receive the amount due under any
Payment Certificate within 42 days after the expiry of the time
stated in Sub-Clause 14.7 [Payment];
(d) the Employer fails to comply with:
(i) a binding agreement, or final and binding determination under
Sub-Clause 3.7 [Agreement or Determination]; or
(ii) a decision of the DAAB under 21.4 [Obtaining DAAB’s Decision]
(whether binding or final and binding)
and such failure constitutes a material breach of the Employer’s obligations
under the Contract;
16.2.2 Termination
If the Contractor suffers delay and/or incurs Cost during the above period of
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
16.3
Contractor’s Obligations
After Termination After termination of the Contract under Sub-Clause 15.5 [Termination for
Employer’s Convenience], Sub-Clause 16.2 [Termination by Contractor] or
Sub-Clause 18.5 [Optional Termination], the Contractor shall promptly:
(a) cease all further work, except for such work as may have been
instructed by the Engineer for the protection of life or property or
for the safety of the Works. If the Contractor incurs Cost as a
result of carrying out such instructed work the Contractor shall be
entitled subject to Sub-Clause 20.2 [Claims For Payment and/or
EOT] to be paid such Cost Plus Profit;
(b) deliver to the Engineer all Contractor’s Documents, Plant,
Materials and other work for which the Contractor has received
payment; and
(c) remove all other Goods from the Site, except as necessary for safety,
and leave the Site.
16.4
Payment after
Termination by Contractor After termination under Sub-Clause 16.2 [Termination by Contractor], the
Employer shall promptly:
CONDITIONS
Ca re o f the Works and Indemnities
GENERAL
17.1
Responsibility for
Care of the Works Unless the Contract is terminated in accordance with these Conditions or
otherwise, subject to Sub-Clause 17.2 [Liability for Care of the Works]
GUIDANCE
the Contractor shall take full responsibility for the care of the Works, Goods
and Contractor’s Documents from the Commencement Date until the
Date of Completion of the Works, when responsibility for the care of the
Works shall pass to the Employer. If a Taking-Over Certificate is issued (or
is deemed to be issued) for any Section or Part, responsibility for the care
of the Section or Part shall then pass to the Employer.
FORMS
If the Contract is terminated in accordance with these Conditions or
otherwise, the Contractor shall cease to be responsible for the care of
the Works from the date of termination.
17.2
Liability for
Care of the Works The Contractor shall be liable for any loss or damage caused by the
Contractor to the Works, Goods or Contractor’s Documents after the
issue of a Taking-Over Certificate. The Contractor shall also be liable for
any loss or damage, which occurs after the issue of a Taking-Over
Certificate and which arose from an event which occurred before the
issue of this Taking-Over Certificate, for which the Contractor was liable.
other contractors.
(i) any of the events described in sub-paragraphs (a) to (f) above, and
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
17.3
Intellectual and Industrial
Property Rights In this Sub-Clause, “infringement” means an infringement (or alleged
infringement) of any patent, registered design, copyright, trademark,
trade name, trade secret or other intellectual or industrial property right
relating to the Works; and “claim” means a third party claim (or proceedings
pursuing a third party claim) alleging an infringement.
Whenever a Party receives a claim but fails to give notice to the other
Party of the claim within 28 days of receiving it, the first Party shall be
deemed to have waived any right to indemnity under this Sub-Clause.
The Employer shall indemnify and hold the Contractor harmless against and
from any claim (including legal fees and expenses) alleging an infringement
which is or was:
The Contractor shall indemnify and hold the Employer harmless against
and from any other claim (including legal fees and expenses) alleging an
infringement which arises out of or in relation to:
CONDITIONS
(ii) the use of Contractor’s Equipment.
GENERAL
If a Party is entitled to be indemnified under this Sub-Clause, the
indemnifying Party may (at the indemnifying Party’s cost) assume overall
responsibility for negotiating the settlement of the claim, and/or any
litigation or arbitration which may arise from it. The other Party shall, at the
request and cost of the indemnifying Party, assist in contesting the claim.
GUIDANCE
This other Party (and the Contractor’s Personnel or the Employer’s
Personnel, as the case may be) shall not make any admission which might
be prejudicial to the indemnifying Party, unless the indemnifying Party
failed to promptly assume overall responsibility for the conduct of any
negotiations, litigation or arbitration after being requested to do so by the
other Party.
FORMS
17.4
Indemnities by Contractor The Contractor shall indemnify and hold harmless the Employer, the
Employer’s Personnel, and their respective agents, against and from all
third party claims, damages, losses and expenses (including legal fees and
expenses) in respect of:
To the extent, if any, that the Contractor is responsible for the design of
part of the Permanent Works under Sub-Clause 4.1 [Contractor’s
General Obligations], and/or any other design under the Contract, the
Contractor shall also indemnify and hold harmless the Employer against all
acts, errors or omissions by the Contractor in carrying out the
Contractor’s design obligations that result in the Works (or Section or Part
or major item of Plant, if any), when completed, not being fit for the
purpose(s) for which they are intended under Sub-Clause 4.1
[Contractor’s General Obligations].
17.5
Indemnities by Employer The Employer shall indemnify and hold harmless the Contractor, the
Contractor’s Personnel, and their respective agents, against and from all
third party claims, damages, losses and expenses (including legal fees and
expenses) in respect of:
18.1 Ex
1 8
Exceptional Events
cept ional Events
An Exceptional Event may comprise but is not limited to any of the following
events or circumstances provided that conditions (i) to (iv) above are
satisfied:
18.2
Notice of
an Exceptional Event If a Party is or will be prevented from performing any obligations under the
Contract due to an Exceptional Event (the “affected Party” in this
Clause), then the affected Party shall give a Notice to the other Party of
such an Exceptional Event, and shall specify the obligations, the
performance of which is or will be prevented (the “prevented obligations”
in this Clause).
This Notice shall be given within 14 days after the affected Party became
aware, or should have become aware, of the Exceptional Event, and
90 © FIDIC 2017 Conditions of Contract for Construction
the affected Party shall then be excused performance of the prevented
obligations from the date such performance is prevented by the Exceptional
CONDITIONS
GENERAL
Event. If this Notice is received by the other Party after this period of 14
days, the affected Party shall be excused performance of the prevented
obligations only from the date on which this Notice is received by the
other Party.
GUIDANCE
prevented obligations for so long as such Exceptional Event prevents the
affected Party from performing them. Other than performance of the
prevented obligations, the affected Party shall not be excused performance
of all other obligations under the Contract.
FORMS
Event.
18.3
Duty to Minimise Delay Each Party shall at all times use all reasonable endeavours to minimise any
delay in the performance of the Contract as a result of an Exceptional Event.
If the Exceptional Event has a continuing effect, the affected Party shall give
further Notices describing the effect every 28 days after giving the first
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The affected Party shall immediately give a Notice to the other Party when
the affected Party ceases to be affected by the Exceptional Event. If the
affected Party fails to do so, the other Party may give a Notice to the
affected Party stating that the other Party considers that the affected
Party’s performance is no longer prevented by the Exceptional Event,
with reasons.
18.4
Consequences of
an Exceptional Event If the Contractor is the affected Party and suffers delay and/or incurs Cost
by reason of the Exceptional Event of which he/she gave a Notice under
Sub-Clause 18.2 [Notice of an Exceptional Event], the Contractor shall
be entitled subject to Sub-Clause 20.2 [Claims For Payment and/or EOT]
to:
18.5
Optional Termination If the execution of substantially all the Works in progress is prevented for a
continuous period of 84 days by reason of an Exceptional Event of which
Notice has been given under Sub-Clause 18.2 [Notice of an Exceptional
Event], or for multiple periods which total more than 140 days due to the
same Exceptional Event, then either Party may give to the other Party a
Notice of termination of the Contract.
In this event, the date of termination shall be the date 7 days after the Notice
is received by the other Party, and the Contractor shall proceed in
accordance with Sub-Clause 16.3 [Contractor’s Obligations After
Termination].
General Conditions © FIDIC 2017
After the date of
termination the
Contractor shall,
as soon as
practicable, submit
detailed supporting
particulars (as
reasonably
required by the
Engineer) of the
value of the work
done, which shall
include:
91
(a) the amounts payable for any work carried out for which a price is
stated in the Contract;
CONDITIONS
GENERAL
(b) the Cost of Plant and Materials ordered for the Works which have
been delivered to the Contractor, or of which the Contractor is
liable to accept delivery. This Plant and Materials shall become the
property of (and be at the risk of) the Employer when paid for by the
Employer, and the Contractor shall place the same at the
Employer’s disposal;
GUIDANCE
(c) any other Cost or liability which in the circumstances was reasonably
incurred by the Contractor in the expectation of completing the
Works;
(d) the Cost of removal of Temporary Works and Contractor’s Equipment
from the Site and the return of these items to the Contractor’s
place of business in the Contractor’s country (or to any other
destination(s) at no greater cost); and
FORMS
(e) the Cost of repatriation of the Contractor’s staff and labour employed
wholly in connection with the Works at the date of termination.
18.6
Release from Performance
under the Law In addition to any other provision of this Clause, if any event arises
outside the control of the Parties (including, but not limited to, an
Exceptional Event) which:
(a) makes it impossible or unlawful for either Party or both Parties to fulfil
their contractual obligations; or
(b) under the law governing the Contract, entitles the Parties to be
released from further performance of the Contract,
and if the Parties are unable to agree on an amendment to the Contract that
would permit the continued performance of the Contract, then after either
Party gives a Notice to the other Party of such event:
(i) the Parties shall be discharged from further performance, and without
prejudice to the rights of either Party in respect of any previous
breach of the Contract; and
(ii) the amount payable by the Employer to the Contractor shall be the
same as would have been payable under Sub-Clause 18.5 [Optional
Termination], and such amount shall be certified by the Engineer, as if
the Contract had been terminated under that Sub-Clause.
19.1
Ins
1 9 uran
General Requirements
ce
CONDITIONS
GENERAL
Acceptance.
The insurances required to be provided under this Clause are the minimum
required by the Employer, and the Contractor may, at the Contractor’s
own cost, add such other insurances that the Contractor may deem
prudent.
GUIDANCE
Whenever required by the Employer, the Contractor shall produce the
insurance policies which the Contractor is required to effect under the
Contract. As each premium is paid, the Contractor shall promptly submit
either a copy of each receipt of payment to the Employer (with a copy to the
Engineer), or confirmation from the insurers that the premium has been paid.
FORMS
If the Contractor fails to effect and keep in force any of the insurances
required under Sub-Clause 19.2 [Insurances to be provided by the
Contractor] then, and in any such case, the Employer may effect and
keep in force such insurances and pay any premium as may be
necessary and recover the same from the Contractor from time to time
by deducting the amount(s) so paid from any moneys due to the Contractor
or otherwise recover the same as a debt from the Contractor. The provisions
of Clause 20 [Employer’s and Contractor’s Claims] shall not apply to this
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Sub-Clause.
If either the Contractor or the Employer fails to comply with any condition of
the insurances effected under the Contract, the Party so failing to comply
shall indemnify the other Party against all direct losses and claims (including
legal fees and expenses) arising from such failure.
The permitted deductible limits allowed in any policy shall not exceed the
amounts stated in the Contract Data (if not stated, the amounts agreed with
the Employer).
Where there is a shared liability the loss shall be borne by each Party in
proportion to each Party’s liability, provided the non-recovery from
insurers has not been caused by a breach of this Clause by the
Contractor or the Employer. In the event that non-recovery from insurers
has been caused by such a breach, the defaulting Party shall bear the
loss suffered.
19.2
Insurance to be provided
by the Contractor The Contractor shall provide the following insurances:
The Contractor shall insure and keep insured in the joint names of the
Contractor and the Employer from the Commencement Date until the
date of the issue of the Taking-Over Certificate for the Works:
The insurance cover shall cover the Employer and the Contractor against all
loss or damage from whatever cause arising until the issue of the Taking-
Over Certificate for the Works. Thereafter, the insurance shall continue
until the date of the issue of the Performance Certificate in respect of any
incomplete work for loss or damage arising from any cause occurring
FORMS
before the date of the issue of the Taking-Over Certificate for the Works,
and for any loss or damage occasioned by the Contractor in the course of
any operation carried out by the Contractor for the purpose of complying
with the Contractor’s obligations under Clause 11 [Defects after Taking
Over] and Clause 12 [Tests after Completion].
However, the insurance cover provided by the Contractor for the Works may
exclude any of the following:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(i) the cost of making good any part of the Works which is defective
(including defective material and workmanship) or otherwise does not
comply with the Contract, provided that it does not exclude the
cost of making good any loss or damage to any other part of the
Works attributable to such defect or non-compliance;
(ii) indirect or consequential loss or damage including any reductions
in the Contract Price for delay;
(iii) wear and tear, shortages and pilferages; and
(iv) unless otherwise stated in the Contract Data, the risks arising from
Exceptional Events.
19.2.2 Goods
The Contractor shall insure, in the joint names of the Contractor and the
Employer, the Goods and other things brought to Site by the Contractor
to the extent specified and/or amount stated in the Contract Data (if not
specified or stated, for their full replacement value including delivery to Site).
The Contractor shall maintain this insurance from the time the Goods are
delivered to the Site until they are no longer required for the Works.
To the extent, if any, that the Contractor is responsible for the design of
part of the Permanent Works under Sub-Clause 4.1 [Contractor’s
General Obligations], and/or any other design under the Contract, and
consistent with the indemnities specified in Clause 17 [Care of the Works
and Indemnities]:
CONDITIONS
GENERAL
Contractor’s design obligations under the Contract that results in
the Works (or Section or Part or major item of Plant, if any), when
completed, not being fit for the purpose(s) for which they are intended
under Sub-Clause 4.1 [Contractor’s General Obligations].
The Contractor shall maintain this insurance for the period specified in
GUIDANCE
the Contract Data.
The Contractor shall insure, in the joint names of the Contractor and the
Employer, against liabilities for death or injury to any person, or loss of or
damage to any property (other than the Works) arising out of the
FORMS
performance of the Contract and occurring before the issue of the
Performance Certificate, other than loss or damage caused by an
Exceptional Event.
The insurance policy shall include a cross liability clause such that the
insurance shall apply to the Contractor and the Employer as separate
insureds.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Such insurance shall be effected before the Contractor begins any work
on the Site and shall remain in force until the issue of the Performance
Certificate and shall be for not less than the amount stated in the
Contract Data (if not stated, the amount agreed with the Employer).
The Contractor shall effect and maintain insurance against liability for claims,
damages, losses and expenses (including legal fees and expenses) arising
out of the execution of the Works in respect of injury, sickness, disease
or death of any person employed by the Contractor or any of the
Contractor’s other personnel.
The Employer and the Engineer shall also be indemnified under the
policy of insurance, except that this insurance may exclude losses and
claims to the extent that they arise from any act or neglect of the
Employer or of the Employer’s Personnel.
The insurance shall be maintained in full force and effect during the
whole time that the Contractor’s Personnel are assisting in the execution
of the Works. For any person employed by a Subcontractor, the insurance
may be effected by the Subcontractor, but the Contractor shall be
responsible for the Subcontractor’s compliance with this Sub-Clause.
The Contractor shall provide all other insurances required by the Laws of
the countries where (any part of) the Works are being carried out, at the
Contractor’s own cost.
20.1
In the case of a Claim under sub-paragraph (c) above, where the other Party
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
or the Engineer has disagreed with the requested entitlement or relief (or
is deemed to have disagreed if he/she does not respond within a
reasonable time), a Dispute shall not be deemed to have arisen but the
claiming Party may, by giving a Notice refer the Claim to the Engineer and
Sub-Clause 3.7 [Agreement or Determination] shall apply. This Notice shall
be given as soon as practicable after the claiming Party becomes aware of
the disagreement (or deemed disagreement) and include details of the
claiming Party’s case and the other Party’s or the Engineer’s disagreement
(or deemed disagreement).
20.2
Claims For Payment
and/or EOT If either Party considers that he/she is entitled to any additional payment by
the other Party (or, in the case of the Employer, a reduction in the
Contract Price) and/or to EOT (in the case of the Contractor) or an
extension of the DNP (in the case of the Employer) under any Clause of
these Conditions or otherwise in connection with the Contract, the
following Claim procedure shall apply:
The claiming Party shall give a Notice to the Engineer, describing the event
or circumstance giving rise to the cost, loss, delay or extension of DNP
for which the Claim is made as soon as practicable, and no later than 28
days after the claiming Party became aware, or should have become
aware, of the event or circumstance (the “Notice of Claim” in these
Conditions).
If the claiming Party fails to give a Notice of Claim within this period of 28
days, the claiming Party shall not be entitled to any additional payment,
the Contract Price shall not be reduced (in the case of the Employer as
the claiming Party), the Time for Completion (in the case of the
Contractor as the claiming Party) or the DNP (in the case of the
Employer as the claiming Party) shall not be extended, and the other
Party shall be discharged from any liability in connection with the event
or circumstance giving rise to the Claim.
CONDITIONS
GENERAL
If the Engineer considers that the claiming Party has failed to give the Notice
of Claim within the period of 28 days under Sub-Clause 20.2.1 [Notice of
Claim] the Engineer shall, within 14 days after receiving the Notice of Claim,
give a Notice to the claiming Party accordingly (with reasons).
If the Engineer does not give such a Notice within this period of 14 days,
GUIDANCE
the Notice of Claim shall be deemed to be a valid Notice. If the other
Party disagrees with such deemed valid Notice of Claim the other Party shall
give a Notice to the Engineer which shall include details of the
disagreement. Thereafter, the agreement or determination of the Claim
under Sub-Clause
20.2.5 [Agreement or determination of the Claim] shall include a review
by the Engineer of such disagreement.
FORMS
If the claiming Party receives a Notice from the Engineer under this Sub-
Clause and disagrees with the Engineer or considers there are
circumstances which justify late submission of the Notice of Claim, the
claiming Party shall include in its fully detailed Claim under Sub-Clause 20.2.4
[Fully detailed claim] details of such disagreement or why such late submission
is justified (as the case may be).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Without admitting the Employer’s liability, the Engineer may monitor the
Contractor’s contemporary records and/or instruct the Contractor to
keep additional contemporary records. The Contractor shall permit the
Engineer to inspect all these records during normal working hours (or at
other times agreed by the Contractor), and shall if instructed submit
copies to the Engineer. Such monitoring, inspection or instruction (if any)
by the Engineer shall not imply acceptance of the accuracy or completeness
of the Contractor’s contemporary records.
Within either:
(i) 84 days after the claiming Party became aware, or should have
become aware, of the event or circumstance giving rise to the Claim,
(ii) such other period (if any) as may be proposed by the claiming
GENERAL
If within this time limit the claiming Party fails to submit the statement under
sub-paragraph (b) above, the Notice of Claim shall be deemed to have
lapsed, it shall no longer be considered as a valid Notice, and the
GUIDANCE
Engineer shall, within 14 days after this time limit has expired, give a
Notice to the claiming Party accordingly.
If the Engineer does not give such a Notice within this period of 14 days,
the Notice of Claim shall be deemed to be a valid Notice. If the other
Party disagrees with such deemed valid Notice of Claim the other Party shall
give a Notice to the Engineer which shall include details of the
FORMS
If the claiming Party receives a Notice from the Engineer under this Sub-Clause
20.2.4 and if the claiming Party disagrees with such Notice or considers
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
there are circumstances which justify late submission of the statement under
sub-paragraph (b) above, the fully detailed claim shall include details of the
claiming Party’s disagreement or why such late submission is justified (as
the case may be).
(a) the additional payment (if any) to which the claiming Party is
entitled or the reduction of the Contract Price (in the case of the
Employer as the claiming Party); and/or
(b) the extension (if any) of the Time for Completion (before or after
its expiry) under Sub-Clause 8.5 [Extension of Time for
Completion] (in the case of the Contractor as the claiming Party),
or the extension (if any) of the DNP (before its expiry) under Sub-
Clause 11.3 [Extension of Defects Notification Period] (in the case
of the Employer as the claiming Party),
to which the claiming Party is entitled under the Contract.
CONDITIONS
GENERAL
• in the case of the time limit under Sub-Clause 20.2.1 [Notice of
Claim], any evidence of the other Party’s prior knowledge of the event
or circumstance giving rise to the Claim, which the claiming Party may
include in its supporting particulars; and/or
• in the case of the time limit under Sub-Clause 20.2.4 [Fully
detailed Claim], any evidence of the other Party’s prior knowledge
GUIDANCE
of the contractual and/or other legal basis of the Claim, which the
claiming Party may include in its supporting particulars.
If, having received the fully detailed Claim under Sub-Clause 20.2.4
[Fully detailed Claim], or in the case of a Claim under Sub-Clause 20.2.6
[Claims of continuing effect] an interim or final fully detailed Claim (as the
case may be), the Engineer requires necessary additional particulars:
FORMS
(i) he/she shall promptly give a Notice to the claiming Party,
describing the additional particulars and the reasons for requiring
them;
(ii) he/she shall nevertheless give his/her response on the contractual
or other legal basis of the Claim, by giving a Notice to the claiming
Party, within the time limit for agreement under Sub-Clause 3.7.3 [Time
limits];
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(a) the fully detailed Claim submitted under Sub-Clause 20.2.4 [Fully
detailed Claim] shall be considered as interim;
(b) in respect of this first interim fully detailed Claim, the Engineer
shall give his/her response on the contractual or other legal basis
of the Claim, by giving a Notice to the claiming Party, within the time
limit for agreement under Sub-Clause 3.7.3 [Time limits];
(c) after submitting the first interim fully detailed Claim the claiming Party
shall submit further interim fully detailed Claims at monthly
intervals, giving the accumulated amount of additional payment
claimed (or the reduction of the Contract Price, in the case of the
Employer as the claiming Party), and/or extension of time claimed
(in the case of the Contractor as the claiming Party) or extension of
the DNP (in the case of the Employer as the claiming Party); and
(d) the claiming Party shall submit a final fully detailed Claim within 28
days after the end of the effects resulting from the event or
circumstance, or within such other period as may be proposed by the
claiming Party and agreed by the Engineer. This final fully detailed
Claim shall give the total amount of additional payment claimed (or the
reduction of the Contract Price, in the case of the Employer as the
claiming Party), and/or extension of time claimed (in the case of the
Contractor as the claiming Party) or extension of the DNP (in the case
of the Employer as the claiming Party).
General Conditions © FIDIC 2017
99
20.2.7 General requirements
After receiving the Notice of Claim, and until the Claim is agreed or
determined under Sub-Clause 20.2.5 [Agreement or determination of the
Claim], in each Payment Certificate the Engineer shall include such amounts
for any Claim as have been reasonably substantiated as due to the
claiming Party under the relevant provision of the Contract.
The Employer shall only be entitled to claim any payment from the
Contractor and/or to extend the DNP, or set off against or make any
deduction from any amount due to the Contractor, by complying with this
Sub-Clause 20.2.
21.1 Dis
2 1 put
The DAAB shall comprise, as stated in the Contract Data, either one suitably
qualified member (the “sole member”) or three suitably qualified
members (the “members”). If the number is not so stated, and the Parties do
not agree otherwise, the DAAB shall comprise three members.
The sole member or three members (as the case may be) shall be selected
from those named in the list in the Contract Data, other than anyone who
is unable or unwilling to accept appointment to the DAAB.
If the DAAB is to comprise three members, each Party shall select one
member for the agreement of the other Party. The Parties shall consult both
these members and shall agree the third member, who shall be appointed to
act as chairperson.
The DAAB shall be deemed to be constituted on the date that the Parties
and the sole member or the three members (as the case may be) of the
DAAB have all signed a DAAB Agreement.
The terms of the remuneration of either the sole member or each of the
three members, including the remuneration of any expert whom the
DAAB consults, shall be mutually agreed by the Parties when agreeing the
terms of the DAAB Agreement. Each Party shall be responsible for paying
one-half of this remuneration.
If at any time the Parties so agree, they may appoint a suitably qualified
person or persons to replace any one or more members of the DAAB.
Unless the Parties agree otherwise, a replacement DAAB member shall
be appointed if a member declines to act or is unable to act as a result of
death,
GENERAL
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org FORMS GUIDANCE CONDITIONS
100
© FIDIC 2017
Conditions of Contract for Construction
illness, disability, resignation or termination of appointment. The replacement
member shall be appointed in the same manner as the replaced member
was required to have been selected or agreed, as described in this Sub-
Clause.
(a) on the date the discharge shall have become, or deemed to have
become, effective under Sub-Clause 14.12 [Discharge]; or
(b) 28 days after the DAAB has given its decision on all Disputes,
referred to it under Sub-Clause 21.4 [Obtaining DAAB’s Decision]
before such discharge has become effective,
whichever is later.
(i) the DAAB has given its decision on all Disputes, which were
referred to it (under Sub-Clause 21.4 [Obtaining DAAB’s Decision])
within 224 days after the date of termination; or
(ii) the date that the Parties reach a final agreement on all matters
(including payment) in connection with the termination
whichever is earlier.
21.2
Failure to Appoint
DAAB Member(s) If any of the following conditions apply, namely:
(a) if the DAAB is to comprise a sole member, the Parties fail to agree
the appointment of this member by the date stated in the first
paragraph of Sub-Clause 21.1 [Constitution of the DAAB]; or
(b) if the DAAB is to comprise three persons, and if by the date stated
in the first paragraph of Sub-Clause 21.1 [Constitution of the
DAAB]:
(i) either Party fails to select a member (for agreement by the other
Party);
(ii) either Party fails to agree a member selected by the other Party;
and/or
(iii) the Parties fail to agree the appointment of the third member
(to act as chairperson) of the DAAB;
(c) the Parties fail to agree the appointment of a replacement within
42 days after the date on which the sole member or one of the
three members declines to act or is unable to act as a result of
death, illness, disability, resignation, or termination of
appointment; or
(d) if, after the Parties have agreed the appointment of the member(s)
or replacement, such appointment cannot be effected because
one Party refuses or fails to sign a DAAB Agreement with any
such member or replacement (as the case may be) within 14 days
of the other Party’s request to do so,
then the appointing entity or official named in the Contract Data shall, at the
request of either or both Parties and after due consultation with both Parties,
appoint the member(s) of the DAAB (who, in the case of sub-paragraph
(d)
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
General Conditions
© FIDIC 2017
101
(i) the monthly services fee and daily fee shall be as stated in the
terms of the appointment; and
GUIDANCE
(ii) the law governing the DAAB Agreement shall be the governing law of
the Contract defined in Sub-Clause 1.4 [Law and Language].
accordance with the Contract. If the Employer pays the remuneration in full,
the Engineer shall include one-half of the amount of such remuneration
as a deduction under sub-paragraph (b) of Sub-Clause 14.6.1 [The IPC].
21.3
Avoidance of Disputes If the Parties so agree, they may jointly request (in writing, with a copy to
the Engineer) the DAAB to provide assistance and/or informally discuss
and attempt to resolve any issue or disagreement that may have arisen
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
between them during the performance of the Contract. If the DAAB becomes
aware of an issue or disagreement, it may invite the Parties to make such a
joint request.
Such joint request may be made at any time, except during the period
that the Engineer is carrying out his/her duties under Sub-Clause 3.7
[Agreement or Determination] on the matter at issue or in disagreement
unless the Parties agree otherwise.
Such informal assistance may take place during any meeting, Site visit
or otherwise. However, unless the Parties agree otherwise, both Parties
shall be present at such discussions. The Parties are not bound to act on
any advice given during such informal meetings, and the DAAB shall not be
bound in any future Dispute resolution process or decision by any views
or advice given during the informal assistance process, whether provided
orally or in writing.
21.4
Obtaining DAAB’s Decision If a Dispute arises between the Parties then either Party may refer the Dispute
to the DAAB for its decision (whether or not any informal discussions
have been held under Sub-Clause 21.3 [Avoidance of Disputes]) and the
following provisions shall apply.
CONDITIONS
(e) for a DAAB of three persons, be deemed to have been received
GENERAL
by the DAAB on the date it is received by the chairperson of the
DAAB.
The reference of a Dispute to the DAAB under this Sub-Clause shall, unless
prohibited by law, be deemed to interrupt the running of any applicable
statute of limitation or prescription period.
GUIDANCE
21.4.2 The Parties’ obligations after the reference
Both Parties shall promptly make available to the DAAB all information,
access to the Site, and appropriate facilities, as the DAAB may require
for the purposes of making a decision on the Dispute.
FORMS
Unless the Contract has already been abandoned or terminated, the Parties
shall continue to perform their obligations in accordance with the
Contract.
However, if at the end of this period, the due date(s) for payment of any
DAAB member’s invoice(s) has passed but such invoice(s) remains unpaid,
the DAAB shall not be obliged to give its decision until such outstanding
invoice(s) have been paid in full, in which case the DAAB shall give its
decision as soon as practicable after payment has been received.
The decision shall be given in writing to both Parties with a copy to the
Engineer, shall be reasoned, and shall state that it is given under this
Sub-Clause.
The decision shall be binding on both Parties, who shall promptly comply
with it whether or not a Party gives a NOD with respect to such decision
under this Sub-Clause. The Employer shall be responsible for the Engineer’s
compliance with the DAAB decision.
(a) such Party may give a NOD to the other Party, with a copy to the
DAAB and to the Engineer;
(b) this NOD shall state that it is a “Notice of Dissatisfaction with the
DAAB’s Decision” and shall set out the matter in Dispute and the
GUIDANCE
If the DAAB fails to give its decision within the period stated in Sub-Clause
21.4.3 [The DAAB’s decision], then either Party may, within 28 days after
this period has expired, give a NOD to the other Party in accordance
FORMS
If the dissatisfied Party is dissatisfied with only part(s) of the DAAB’s decision:
21.5
Amicable Settlement Where a NOD has been given under Sub-Clause 21.4 [Obtaining DAAB’s
Decision], both Parties shall attempt to settle the Dispute amicably
before the commencement of arbitration. However, unless both Parties
agree otherwise, arbitration may be commenced on or after the twenty-
eighth (28th) day after the day on which this NOD was given, even if no
attempt at amicable settlement has been made.
21.6
Arbitration Unless settled amicably, and subject to Sub-Clause 3.7.5 [Dissatisfaction
with Engineer’s determination], Sub-Clause 21.4.4 [Dissatisfaction with
DAAB’s decision], Sub-Clause 21.7 [Failure to Comply with DAAB’s
Decision] and Sub-Clause 21.8 [No DAAB In Place], any Dispute in
respect of which the DAAB’s decision (if any) has not become final and
binding shall be finally settled by international arbitration. Unless otherwise
agreed by both Parties:
(a) the Dispute shall be finally settled under the Rules of Arbitration of the
International Chamber of Commerce;
(b) the Dispute shall be settled by one or three arbitrators appointed
in accordance with these Rules; and
104
©
FIDIC
2017
Conditi
ons of
Contra
ct for
Constr
uction
(c) the arbitration shall be conducted in the ruling language defined in
Sub-Clause 1.4 [Law and Language].
CONDITIONS
GENERAL
The arbitrator(s) shall have full power to open up, review and revise any
certificate, determination (other than a final and binding determination),
instruction, opinion or valuation of the Engineer, and any decision of the
DAAB (other than a final and binding decision) relevant to the Dispute.
Nothing shall disqualify the Engineer from being called as a witness and
GUIDANCE
giving evidence before the arbitrator(s) on any matter whatsoever relevant to
the Dispute.
In any award dealing with costs of the arbitration, the arbitrator(s) may
take account of the extent (if any) to which a Party failed to cooperate
with the other Party in constituting a DAAB under Sub-Clause 21.1
[Constitution of the DAAB] and/or Sub-Clause 21.2 [Failure to Appoint
FORMS
DAAB Member(s)].
21.7
Failure to Comply
with DAAB’s Decision In the event that a Party fails to comply with any decision of the DAAB, whether
binding or final and binding, then the other Party may, without prejudice
to any other rights it may have, refer the failure itself directly to arbitration
under Sub-Clause 21.6 [Arbitration] in which case Sub-Clause 21.4
[Obtaining DAAB’s Decision] and Sub-Clause 21.5 [Amicable
Settlement] shall not apply to this reference. The arbitral tribunal
(constituted under Sub-Clause
21.6 [Arbitration]) shall have the power, by way of summary or other
expedited procedure, to order, whether by an interim or provisional measure
or an award (as may be appropriate under applicable law or otherwise), the
enforcement of that decision.
In the case of a binding but not final decision of the DAAB, such interim
or provisional measure or award shall be subject to the express reservation
that the rights of the Parties as to the merits of the Dispute are reserved until
they are resolved by an award.
21.8
No DAAB In Place If a Dispute arises between the Parties in connection with, or arising out of,
the Contract or the execution of the Works and there is no DAAB in
place (or no DAAB is being constituted), whether by reason of the expiry
of the DAAB’s appointment or otherwise:
CONDITIONS
GENERAL
General Conditions of Dispute Avoidance/Adjudication
Agreement
GUIDANCE
1
Definitions 1.1 “General Conditions of Dispute Avoidance/Adjudication Agreement”
or “GCs” means this document entitled “General Conditions of Dispute
Avoidance/Adjudication Agreement”, as published by FIDIC.
1.2 In the DAA Agreement (as defined below) and in the GCs, words and
expressions which are not otherwise defined shall have the meanings
FORMS
assigned to them in the Contract (as defined in the DAA Agreement).
(c) the DAAB Member who is defined in the DAA Agreement as being
either:
(i) the sole member of the DAAB, or
(ii) one of the three members (or the chairman) of the DAAB.
1.3 “DAAB’s Activities” means the activities carried out by the DAAB in
accordance with the Contract and the GCs, including all Informal Assistance,
meetings (including meetings and/or discussions between the DAAB
members in the case of a three-member DAAB), Site visits, hearings and
decisions.
1.4 “DAAB Rules” means the document entitled “DAAB Procedural Rules”
published by FIDIC which are annexed to, and form part of, the GCs.
1.6 “Term of the DAAB” means the period starting on the Effective Date (as
defined in Sub-Clause 2.1 below) and finishing on the date that the term
of the DAAB expires in accordance with Sub-Clause 21.1 [Constitution of
the DAAB] of the Conditions of Contract.
1.7 “Notification” means a notice in writing given under the GCs, which
shall be:
2
General Provisions 2.1 The DAA Agreement shall take effect:
2.2 Immediately after the Effective Date, either or both Parties shall give a
Notification to the DAAB Member that the DAA Agreement has come
into effect. If the DAAB Member does not receive such a notice within
182 days after entering into the DAA Agreement, it shall be void and
ineffective.
2.3 The employment of the DAAB Member is a personal appointment. No
assignment of, or subcontracting or delegation of the DAAB Member’s rights
and/or obligations under the DAA Agreement is permitted.
3
Warranties 3.1 The DAAB Member warrants and agrees that he/she is, and will remain
at all times during the Term of the DAAB, impartial and independent of
the Employer, the Contractor, the Employer’s Personnel and the
Contractor’s Personnel (including in accordance with Sub-Clause 4.1
below).
3.2 If, after signing the DAA Agreement (or after he/she is deemed to have
signed the DAA Agreement under the Contract), the DAAB Member
becomes aware of any fact or circumstance which might:
3.3 When appointing the DAAB Member, each Party relies on the DAAB
Member’s representations that he/she is:
108
© FIDIC 2017
Conditions of Contract for Construction
4
Independence and
Impartiality 4.1 Further to Sub-Clauses 3.1 and 3.2 above, the DAAB Member shall:
(a) have no financial interest in the Contract, or in the project of which the
Works are part, except for payment under the DAA Agreement;
(b) have no interest whatsoever (financial or otherwise) in the Employer, the
Contractor, the Employer’s Personnel or the Contractor’s
Personnel;
(c) in the ten years before signing the DAA Agreement, not have
been employed as a consultant or otherwise by the Employer, the
Contractor, the Employer’s Personnel or the Contractor’s
Personnel;
(d) not previously have acted, and shall not act, in any judicial or
arbitral capacity in relation to the Contract;
(e) have disclosed in writing to the Employer, the Contractor and the
Other Members (if any), before signing the DAA Agreement (or before
he/she is deemed to have signed the DAA Agreement under the
Contract) and to his/her best knowledge and recollection, any:
(i) existing and/or past professional or personal relationships
with any director, officer or employee of the Employer, the
Contractor, the Employer’s Personnel or the Contractor’s
Personnel (including as a dispute resolution practitioner on
another project),
(ii) facts or circumstances which might call into question his/her
independence or impartiality, and
(iii) previous involvement in the project of which the Contract
forms part;
(f) not, while a DAAB Member and for the Term of the DAAB:
(i) be employed as a consultant or otherwise by, and/or
(ii) enter into discussions or make any agreement regarding
future employment with
the Employer, the Contractor, the Employer’s Personnel or the
Contractor’s Personnel, except as may be agreed by the Employer, the
Contractor and the Other Members (if any); and/or
(g) not solicit, accept or receive (directly or indirectly) any gift, gratuity,
commission or other thing of value from the Employer, the Contractor,
the Employer’s Personnel or the Contractor’s Personnel, except
for payment under the DAA Agreement.
5
General Obligations
of the DAAB Member 5.1 The DAAB Member shall:
(a) comply with the GCs, the DAAB Rules and the Conditions of Contract
that are relevant to the DAAB’s Activities;
(b) not give advice to the Employer, the Contractor, the Employer’s
Personnel or the Contractor’s Personnel concerning the conduct
of the Contract, except as required to carry out the DAAB’s
Activities;
(c) ensure his/her availability during the Term of the DAAB (except in
exceptional circumstances, in which case the DAAB Member shall
give a Notification without delay to the Parties and the Other
Members (if any) detailing the exceptional circumstances) for all
meetings, Site visits, hearings and as is necessary to comply with
sub-paragraph (a) above;
(d) become, and shall remain for the duration of the Term of the
DAAB, knowledgeable about the Contract and informed about:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
General Conditions
© FIDIC 2017
109
(iii) the progress of the Works (and of any other parts of the
project of which the Contract forms part)
including by visiting the Site, meeting with the Parties and by studying all
documents received from either Party under Rule 4.3 of the DAAB Rules
(which shall be maintained in a current working file, in hard-copy or
GUIDANCE
6
General Obligations
FORMS
of the Parties 6.1 Each Party shall comply with the GCs, the DAAB Rules and the
Conditions of Contract that are relevant to the DAAB’s Activities. The
Employer and the Contractor shall be responsible for compliance with this
provision by the Employer’s Personnel and the Contractor’s Personnel,
respectively.
6.2 Each Party shall cooperate with the other Party in constituting the DAAB,
under Sub-Clause 21.1 [Constitution of the DAAB] and/or Sub-Clause 21.2
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
6.4 The Parties, the Employer’s Personnel and the Contractor’s Personnel shall
not request advice from or consultation with the DAAB Member
regarding the Contract, except as required for the DAAB Member to
carry out the DAAB’s Activities.
6.5 At all times when interacting with the DAAB, each Party shall not
compromise the DAAB’s warranty of independence and impartiality under
Sub-Clause
3.1 above.
6.6 In addition to providing documents under Rule 4.3 of the DAAB Rules, each
Party shall ensure that the DAAB Member remains informed as is necessary
to enable him/her to comply with sub-paragraph (d) of Sub-Clause 5.1
above.
7
Confidentiality 7.1 Subject to Sub-Clause 7.4 below, the DAAB Member shall treat the
details of the Contract, all the DAAB’s Activities and the documents provided
under Rule 4.3 of the DAAB Rules as private and confidential, and shall not
publish or disclose them without the prior written consent of the Parties
and the Other Members (if any).
7.2 Subject to Sub-Clause 7.4 below, the Employer, the Contractor, the
Employer’s Personnel and the Contractor’s Personnel shall treat the details
of all the DAAB’s Activities as private and confidential.
CONDITIONS
GENERAL
information:
GUIDANCE
(c) is lawfully obtained by the person from a third party which is not
bound by an obligation of confidentiality.
7.4 If a DAAB Member is replaced under the Contract, the Parties and/or the
Other Members (if any) shall disclose details of the Contract, the documents
provided under Rule 4.3 of the DAAB Rules and previous DAAB’s Activities
(including decisions, if any) to the replacement DAAB Member as is necessary
FORMS
in order to:
8
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
8.2 The Employer and the Contractor hereby jointly and severally indemnify and
hold the DAAB Member harmless against and from all damages, losses and
expenses (including legal fees and expenses) resulting from any claim from
which he/she is relieved from liability under Sub-Clause 8.1 above.
9
Fees and Expenses 9.1 The DAAB Member shall be paid as follows, in the currency named in the
DAA Agreement:
(a) a monthly fee, which shall be a fixed fee as payment in full for:
(i) being available on 28-days’ notice for all meetings, Site visits
and hearings under the DAAB Rules (and, in the event of a
request under Rule 3.6 of the DAAB Rules, being available for
an urgent meeting or Site visit);
(ii) becoming and remaining knowledgeable about the Contract,
informed about the progress of the Works and maintaining
a current working file of documents, in accordance with
sub-paragraph (d) of Clause 5.1 above;
(iii) all office and overhead expenses including secretarial
services, photocopying and office supplies incurred in
connection with his/ her duties; and
This fee shall be paid monthly with effect from the last day of the month
in which the Effective Date occurs until the end of the month in which the
Term of the DAAB expires, or the DAAB Member declines to act or is
unable to act as a result of death, illness, disability, resignation or
termination of his/her DAA Agreement.
GUIDANCE
(b) a daily fee, which shall be considered as payment in full for each day:
(i) or part of a day, up to a maximum of two days’ travel time in
FORMS
9.2 Subject to Sub-Clause 9.3 below, the amounts of the DAAB Member’s
monthly fee and daily fee, under Sub-Clause 9.1 above, shall be as
specified in the DAA Agreement signed (or, under the Contract, deemed to
have been signed) by the Parties and the DAAB Member.
9.3 If the Parties and the DAAB Member have agreed all other terms of the DAA
Agreement but fail to jointly agree the amount of the monthly fee or the daily
fee in the DAA Agreement (the “non-agreed fee” in this Sub-Clause):
CONDITIONS
GENERAL
the amount of the non-agreed fee, which amount shall be
reasonable taking due regard of the complexity of the Works, the
experience and qualifications of the DAAB Member, and all other
relevant circumstances;
(d) once the appointing entity or official has set the amount of the
non-agreed fee, this amount shall be final and conclusive, shall
GUIDANCE
replace the fee under sub-paragraph (a) above, and shall be deemed
to have applied from the Effective Date; and
(e) thereafter, after giving credit to the Parties for all amounts
previously paid in respect of the non-agreed fee, the balance (if
any) due from the DAAB Member to the Parties or from the Parties
to the DAAB Member, as the case may be, shall be paid.
FORMS
9.4 The DAAB Member shall submit invoices for payment of the monthly fee
and air fares quarterly in advance. Invoices for other expenses and for daily
fees shall be submitted following the conclusion of a meeting, Site visit
or hearing; and following the giving of a decision or an informal written
note (under Rule 2.1 of the DAAB Rules). All invoices shall be
accompanied by a brief description of the DAAB’s Activities performed
during the relevant period and shall be addressed to the Contractor.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
9.5 The Contractor shall pay each of the DAAB Member’s invoices in full
within 28 days after receiving each invoice. Thereafter, the Contractor
shall apply to the Employer (in the Statements under the Contract) for
reimbursement of one-half of the amounts of these invoices. The Employer
shall then pay the Contractor in accordance with the Contract.
9.6 If the Contractor fails to pay to the DAAB Member the amount to which
he/ she is entitled under the DAA Agreement within the period of 28 days
stated at Sub-Clause 9.5 above, the DAAB Member shall inform the
Employer who shall promptly pay the amount due to the DAAB Member
and any other amount which may be required to maintain the function of
the DAAB. Thereafter the Employer shall, by written request, be entitled
to payment from the Contractor of:
The Employer shall be entitled to such payment from the Contractor without
any requirement to comply with Sub-Clause 20.2 [Claims For Payment and/
or EOT] of the Conditions of Contract, and without prejudice to any other
right or remedy.
9.7 If the DAAB Member does not receive payment of the amount due within 56
days after submitting a valid invoice, the DAAB Member may:
(a) not less than 7 days after giving a Notification to the Parties and
the Other Members (if any), suspend his/her services until the
payment is received; and/or
(b) resign his/her appointment by giving a Notification under Sub-Clause
10.1 below.
and Termination 10.1 The DAAB Member may resign at any time for any reason, by giving a
Notification of not less than 28 days (or other period as may be agreed by
the Parties) to the Parties and to the Other Members (if any). During this
period the Parties shall take the necessary steps to appoint, without delay, a
replacement DAAB Member in accordance with Sub-Clause 21.1
[Constitution of the DAAB] of the Conditions of Contract (and, if
GUIDANCE
10.2 On expiry of the period stated in Sub-Clause 10.1 above, the resigning
DAAB Member’s DAA Agreement shall terminate with immediate effect.
However (except if the DAAB Member is unable to act as a result of
illness or disability) if, on the date of the DAAB Member’s notice under Sub-
FORMS
Clause
10.1 above, the DAAB is dealing with any Dispute under Sub-Clause
21.4 [Obtaining DAAB’s Decision] of the Conditions of Contract, the
DAAB Member’s resignation shall not take effect and his/her DAA
Agreement shall not terminate until after the DAAB has given all the
corresponding decisions in accordance with the Contract.
10.3 At any time the Parties may jointly terminate the DAA Agreement by giving a
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
10.4 If the DAAB Member fails, without justifiable excuse, to comply with
Sub-Clause 5.1 above, the Parties may, without prejudice to their other
rights or remedies, jointly terminate his/her DAA Agreement by giving a
Notification (by recorded delivery) to the DAAB Member. This notice shall
take effect when it is received by the DAAB Member.
10.5 If either Party fails, without justifiable excuse, to comply with Clause 6
above, the DAAB Member may, without prejudice to his/her other rights or
remedies, terminate the DAA Agreement by giving a Notification to the
Parties. This notice shall take effect when received by both Parties.
10.6 Any resignation or termination under this Clause shall be final and
binding on the Parties and the DAAB Member. However, a notice given
under Sub-Clause 10.3 or 10.4 above by either the Employer or the
Contractor, but not by both, shall be of no effect.
10.9 Subject to any mandatory requirements under the governing law of the
DAA Agreement, termination of the DAA Agreement under this Clause shall
require no action of whatsoever kind by the Parties or the DAAB Member (as
the case may be) other than as stated in this Clause.
11.2 The decision issued under Rule 11 of the DAAB Rules (the “Decision on the
Challenge” in the GCs) shall be final and conclusive.
11.3 At any time before the Decision on the Challenge is issued, the
challenged DAAB Member may resign under Sub-Clause 10.1 above and,
in such case, the challenging Party shall inform the International
Chamber of Commerce (ICC). However, Sub-Clause 10.2 shall not apply to
such resignation and the resigning DAAB Member’s DAA Agreement shall
terminate with immediate effect.
11.4 Unless the challenged DAAB Member has resigned, or his/her DAA
Agreement has been terminated under Sub-Clause 10.3 above, the
DAAB Member and the Other Members (if any) shall continue with the
DAAB’s Activities until the Decision on the Challenge is issued.
12
Disputes under
the DAA Agreement Any dispute arising out of or in connection with the DAA Agreement, or
the breach, termination or invalidity thereof, shall be finally settled by
arbitration under the Rules of Arbitration of the International Chamber of
Commerce
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
General Conditions
© FIDIC 2017
115
CONDITIONS
GENERAL
Rule 1
Objectives 1.1 The objectives of these Rules are:
GUIDANCE
(b) to achieve the expeditious, efficient and cost effective resolution of
any Dispute that arises between the Parties.
1.2 These Rules shall be interpreted, the DAAB’s Activities shall be
conducted and the DAAB shall use its powers under the Contract and
these Rules, in the manner necessary to achieve the above objectives.
Rule 2
FORMS
Avoidance of Disputes 2.1 Where Sub-Clause 21.3 [Avoidance of Disputes] of the Conditions of
Contract applies, the DAAB (in the case of a three-member DAAB, all
three DAAB Members acting together) may give Informal Assistance during
discussions at any meeting with the Parties (whether face-to-face or by
telephone or by video conference) or at any Site visit or by an informal
written note to the Parties.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Rule 3
Meetings and Site Visits 3.1 The purpose of meetings with the Parties and Site visits by the DAAB is
to enable the DAAB to:
3.2 As soon as practicable after the DAAB is appointed, the DAAB shall
convene a face-to-face meeting with the Parties. At this meeting, the
DAAB shall establish a schedule of planned meetings and Site visits in
consultation with the Parties, which schedule shall reflect the requirements
of Rule 3.3 below and shall be subject to adjustment by the DAAB in
consultation with the Parties.
3.3 The DAAB shall hold face-to-face meetings with the Parties, and/or visit the
Site, at regular intervals and/or at the written request of either Party. The
frequency of such meetings and/or Site visits shall be:
3.4 In addition to the face-to-face meetings referred to in Rules 3.2 and 3.3
above, the DAAB may also hold meetings with the Parties by telephone
or video conference as agreed with the Parties (in which case each Party
bears the risk of interrupted or faulty telephone or video conference
transmission and reception).
3.6 Either Party may request an urgent meeting or Site visit by the DAAB.
This shall be a written request and shall give reasons for the urgency of
the meeting or Site visit. If the DAAB agrees that such a meeting or Site
visit is urgent, the DAAB Members shall use all reasonable endeavours
to:
3.7 The time of, and agenda for, each meeting and Site visit shall be set by
the DAAB in consultation with the Parties.
3.8 Each meeting and Site visit shall be attended by the Employer, the
Contractor and the Engineer.
3.9 Each meeting and Site visit shall be co-ordinated by the Contractor in
co-operation with the Employer and the Engineer. The Contractor shall
ensure the provision of appropriate:
(a) personal safety equipment, security controls (if necessary) and site
transport for each Site visit;
(b) meeting room/conference facilities and secretarial and copying
services for each face-to-face meeting; and
(c) telephone conference or video conference facilities for each meeting
by telephone or video conference.
3.10 At the conclusion of each meeting and Site visit and, if possible before
leaving the venue of the face-to-face meeting or the Site (as the case
may be) but in any event within 7 days, the DAAB shall prepare a report
on its activities during the meeting or Site visit and shall send copies of this
report to the Parties and the Engineer.
Rule 4
Communications
and Documentation 4.1 The language to be used:
(a) in all communications to and from the DAAB and the Parties (and,
in the case of a three-member DAAB, between the DAAB
Members);
(b) in all reports and decisions issued by the DAAB; and
(c) during all Site visits, meetings and hearings relating to the DAAB’s
Activities
4.2 All communications and/or documents sent between the DAAB and a
Party shall simultaneously be copied to the other Party. In the case of a
GENERAL
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org FORMS GUIDANCE CONDITIONS
118
© FIDIC 2017
Conditions of Contract for Construction
three-member DAAB, the sending Party shall send all communications and/
or documents to the chairman of the DAAB and simultaneously send copies
CONDITIONS
GENERAL
of these communications and/or documents to the Other Members.
4.3 The Parties shall provide the DAAB with a copy of all documents which
the DAAB may request, including:
GUIDANCE
(b) progress reports under Sub-Clause 4.20 [Progress Reports] of the
Conditions of Contract;
(c) the initial programme and each revised programme under Sub-Clause
8.3 [Programme] of the Conditions of Contract;
(d) relevant instructions given by the Engineer, and Variations under
Clause 13.3 [Variation Procedure] of the Conditions of Contract;
(e) Statements submitted by the Contractor, and all certificates issued by
FORMS
the Engineer under the Contract;
(f) relevant Notices;
(g) relevant communications between the Parties and between either
Party and the Engineer
Rule 5
Powers of the DAAB 5.1 In addition to the powers granted to the DAAB under the Conditions of
Contract, the General Conditions of the DAA Agreement and elsewhere
in these Rules, the Parties empower the DAAB to:
5.2 The DAAB shall have discretion to decide whether and to what extent
any powers granted to the DAAB, under the Conditions of Contract, the
GCs and these Rules, may be exercised.
Rule 6
GUIDANCE
Disputes 6.1 If any Dispute is referred to the DAAB in accordance with Sub-Clause
21.4.1 [Reference of a Dispute to the DAAB] of the Conditions of
Contract, the DAAB shall proceed in accordance with Sub-Clause 21.4
[Obtaining DAAB’s Decision] of the Conditions of Contract and these
DAAB Rules, or as otherwise agreed by the Parties in writing.
6.2 The DAAB shall act fairly and impartially between the Parties and, taking
FORMS
due regard of the period under Sub-Clause 21.4.3 [The DAAB’s decision] of
the Conditions of Contract and other relevant circumstances, the DAAB
shall:
(a) give each Party a reasonable opportunity (consistent with the
expedited nature of the DAAB proceeding) of putting forward its case
and responding to the other Party’s case; and
(b) adopt a procedure in coming to its decision that is suitable to the
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Rule 7
Hearings 7.1 In addition to the powers under Rule 5.1 above, and except as otherwise
agreed in writing by the Parties, the DAAB shall have power to:
(a) decide on the date and place for any hearing, in consultation with the
Parties;
(b) decide on the duration of any hearing;
(c) request that written documentation and arguments from the
Parties be submitted to it prior to the hearing;
(d) adopt an inquisitorial procedure during any hearing:
(e) request the production of documents, and/or oral submissions by
the Parties, at any hearing that the DAAB considers may assist in
exercising the DAAB’s power under sub-paragraph (g) of Rule 5.1
above;
(f) request the attendance of persons at any hearing that the DAAB
considers may assist in exercising the DAAB’s power under
sub-paragraph (g) of Rule 5.1 above;
(g) refuse admission to any hearing, or audience at any hearing, to
any persons other than representatives of the Employer, the
Contractor and the Engineer;
(h) proceed in the absence of any party who the DAAB is satisfied
received timely notice of the hearing;
(i) adjourn any hearing as and when the DAAB considers further
investigation by one Party or both Parties would benefit resolution
of the Dispute, for such time as the investigation is carried out,
and resume the hearing promptly thereafter.
7.2 The DAAB shall not express any opinions during any hearing concerning the
merits of any arguments advanced by either Party in respect of the Dispute.
7.3 The DAAB shall not give any Informal Assistance during a hearing, but if the
Parties request Informal Assistance during any hearing:
CONDITIONS
GENERAL
(b) if the hearing is so adjourned for longer than 2 days, the period
under Sub-Clause 21.4.3 [The DAAB’s decision] of the Conditions
of Contract shall be temporarily suspended until the date that the
hearing is resumed; and
(c) the hearing shall be resumed promptly after the DAAB has given such
Informal Assistance.
GUIDANCE
Rule 8
The DAAB’s Decision 8.1 The DAAB shall make and give its decision within the time allowed under
Sub-Clause 21.4 [Obtaining DAAB’s Decision] of the Conditions of Contract,
or other time as may be proposed by the DAAB and agreed by the Parties in
writing.
FORMS
8.2 In the case of a three-member DAAB:
(a) it shall meet in private (after the hearing, if any) in order to have
discussions and to start preparation of its decision;
(b) the DAAB Members shall use all reasonable endeavours to reach
a unanimous decision;
(c) if it is not possible for the DAAB Members to reach a unanimous
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
8.4 If, within 14 days of receiving a decision from the DAAB, either Party
finds a typographical, clerical or arithmetical error in the decision, that
Party may request the DAAB to correct such error. This shall be a written
request and shall clearly identify the error.
8.5 If, within 14 days of receiving a decision from the DAAB, either Party
believes that such decision contains an ambiguity, that Party may request
clarification
8.6 The DAAB shall respond to a request under Rule 8.4 or Rule 8.5 above
within 14 days of receiving the request. The DAAB may decline (at its sole
discretion and with no requirement to give reasons) any request for
clarification under Rule 8.5. If the DAAB agrees (in the case of a three-
member DAAB they agree unanimously or by majority) that the decision
GUIDANCE
Rule 9
In the event of
Termination of
DAA Agreement 9.1 If, on the date of termination of a DAAB Member’s DAA Agreement
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
(a) the period under Sub-Clause 21.4.3 [The DAAB’s decision] of the
Conditions of Contract shall be temporarily suspended; and
(b) when a replacement DAAB Member is appointed in accordance
with Sub-Clause 21.1 [Constitution of the DAAB] of the Conditions
of Contract, the full period under Sub-Clause 21.4.3 [The DAAB’s
decision] of the Conditions of Contract shall apply from the date of
this replacement DAAB Member’s appointment.
9.2 In the case of a three-member DAAB and if one DAAB Member’s DAA
Agreement is terminated as a result of resignation or termination under
Clause 10 of the GCs, the Other Members shall continue as members of the
DAAB except that they shall not conduct any hearing or make any
decision prior to the replacement of the DAAB Member unless otherwise
agreed jointly by the Parties and the Other Members.
Rule 10
Objection Procedure 10.1 The following procedure shall apply to any objection against a DAAB
Member:
(a) the objecting Party shall, within 7 days of becoming aware of the
facts and/or events giving rise to the objection, give a Notification
to the DAAB Member of its objection. This Notification shall:
(i) state that it is given under this Rule;
(ii) state the reason(s) for the objection;
(iii) substantiate the objection by setting out the facts, and describing
the events, on which the objection is based, with supporting
particulars; and
(iv) be simultaneously copied to the other Party and the Other
Members;
(b) within 7 days after receiving a notice under sub-paragraph (a) above,
the objected DAAB Member shall respond to the objecting Party.
CONDITIONS
GENERAL
Member within this period of 7 days, the DAAB Member shall be
deemed to have given a response denying the matters on which the
objection is based;
(c) within 7 days after receiving the objected DAAB Member’s
response under sub-paragraph (b) above (or, if there is no such
response, after expiry of the period of 7 days stated in sub-
GUIDANCE
paragraph (b) above) the objecting Party may formally challenge
a DAAB member in accordance with Rule 11 below;
(d) if the challenge is not referred within the period of 7 days stated in
sub-paragraph (c) above, the objecting Party shall be deemed to have
agreed to the DAAB Member remaining on the DAAB and shall
not be entitled to object and/or challenge him/her thereafter on the
basis of any of the facts and/or evidence stated in the notice given
FORMS
under sub-paragraph (a) above;
Rule 11
Challenge Procedure 11.1 If and when the objecting Party challenges a DAAB Member, within 21 days
of learning of the facts upon which the challenge is based, the provisions
of this Rule shall apply. Any challenge is to be decided by the
International Chamber of Commerce (ICC) and administered by the ICC
International Centre for ADR.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
11.2 The procedure for such challenge and information on associated charges to
be paid are set out at http://fidic.org and http://iccwbo.org.
Sub-Clause Page
CONDITIONS
GENERAL
DAAB - see Dispute Avoidance/Adjudication Board
Daywork 13.5 67
Defective Work off Site, Remedying of 11.5 58
Defects, Failure to Remedy 11.4 57
Defects and Rejection 7.5 44
GUIDANCE
Defects Notification Period, Extension of 11.3 57
Defects, Remedying of 11.1 56
Definitions 1.1 1
Delay Damages 8.8 50
Delayed Drawings or Instructions 1.9 11
Delays Caused by Authorities 8.6 49
FORMS
Discharge 14.12 78
Disorderly Conduct 6.11 41
Dispute Avoidance/Adjudication Board, Constitution of the 21.1 100
Dispute Avoidance/Adjudication Board’s Decision,
Failure to Comply with 21.7 105
Dispute Avoidance/Adjudication Board’s Decision, Obtaining 21.4 102
Dispute Avoidance/Adjudication Board, No DAAB In Place 21.8 105
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Payment 14.7 75
Payment after Termination by the Contractor 16.4 86
Payment, Currencies of 14.15 79
Payment, Delayed 14.8 75
Payments, Schedule of 14.4 72
Performance Certificate 11.9 60
Performance Security 4.2 23
CONDITIONS
Personnel, Contractor’s 6.9 41
GENERAL
Personnel and other Contractors, Employer’s 2.3 15
Persons, Recruitment of 6.3 39
Plant and Materials intended for the Works 14.5 72
Plant and Materials, Ownership of 7.7 45
Priority of Documents 1.5 9
GUIDANCE
Programme 8.3 46
Progress, Rate of 8.7 49
Progress Reports 4.20 35
Provisional Sums 13.4 66
FORMS
Records, Contractor’s 6.10 41
Release from Performance under the Law 18.6 92
Remedial Work 7.6 45
Remedy Defects, Failure to 11.4 57
Remedying Defects 11.1 56
Remedying Defects, Cost of 11.2 56
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Samples 7.2 42
Schedule of Payments 14.4 72
Search, Contractor to 11.8 63
Security of the Site 4.21 36
Security, Performance 4.2 23
Setting Out 4.7 28
Site, Clearance of 11.11 60
Site, Contractor’s Operations on 4.22 36
Site Data, Use of 4.10 31
Site Data and Items of Reference 2.5 16
Site, Right of Access to the 2.1 15
Site, Security of the 4.21 36
Staff and Labour, Engagement of 6.1 39
Staff and Labour, Facilities for 6.6 40
Statement at Completion 14.10 76
Statement, Final 14.11 77
Subcontractors 5.1 37
Subcontractors, nominated 5.2 38
Superintendence, Contractor’s 6.8 40
CONDITIONS
GENERAL
for the Preparation of Particular Conditions
CONTENTS
INTRODUCTORY GUIDANCE NOTES.............................................2
GUIDANCE
CONTRACT DATA...............................................................3
INTRODUCTION..................................................................8
FORMS
1 General Provisions................................................................................14
2 The Employer........................................................................................18
3 The Engineer........................................................................................ 20
4 The Contractor......................................................................................22
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
5 Subcontracting......................................................................................28
9 Tests on Completion..............................................................................35
15 Termination by Employer........................................................................44
18 Exceptional Events................................................................................46
19 Insurance.............................................................................................. 46
© FIDIC 2017
1
Particular Conditions Part A – Contract Data
CONDITIONS
GENERAL
Certain Sub-Clauses in the General Conditions require that specific information is provided in
the Contract Data.
The Employer should amend as appropriate and complete all data and should insert “Not
Applicable” in the space next to any Sub-Clause which the Employer does not wish to use.
FORMS
The Employer should insert “Tenderer to Complete” in the space next to any Sub-Clause which
the Employer wishes Contract Data to be completed by the tenderers. Except where indicated
“Tenderer to Complete” tenderers shall not amend the Contract Data as provided by the Employer.
All italicised text and any enclosing square brackets are for use in preparing the Contract Data and
should be deleted from the final version of the Contract Data.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Failure by the Employer to provide the information and details required in the Contract Data
could mean either that the documents forming the Contract are incomplete with vital information
missing, or that the fall-back provisions to be found in some of the Sub-Clauses in the General
Conditions will automatically take effect.
CONDITIONS
GENERAL
Sub-Clause Data to be given Data
1.1.19..........
where the Contract allows for Cost Plus Profit,
percentage profit to be added to the Cost:...................... %
GUIDANCE
1.1.27..........
Defects Notification Period (DNP):..................................... days
1.1.31..........
Employer’s name and address:..........................................
FORMS
1.1.35..........
Engineer’s name and address:.......................................
1.1.85..........
Time for Completion:......................................................... days
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
1.3(d)...........
address of Employer for communications: ....................
1.3(d)...........
address of Engineer for communications: ......................
1.3(d)...........
address of Contractor for communications: ...................
1.4...............
Contract shall be governed by the law of:
1.4...............
ruling language: .............................................................
1.4...............
language for communications: .......................................
1.8...............
number of additional paper copies of Contractor’s
Documents.......................................................................
1.15.............
total liability of the Contractor to the Employer under or in
connection with the Contract:........................................... (sum)
2.1...............
after receiving the Letter of Acceptance, the Contractor
shall be given right of access to all or part of the Site
within:............................................................................... days
© FIDIC 2017
3
Sub-Clause Data to be given Data
CONDITIONS
GENERAL
2.4...............
Employer’s financial arrangements:....................................
4.2...............
Performance Security (as percentages of the Accepted
GUIDANCE
4.7.2............
period for notification of errors in the items of reference .
12.3
percentage profit: .......................................................... as stated under 1.1.19
above
13.4(b)(ii)......
percentage rate to be applied to Provisional Sums for
overhead charges and profit.............................................. %
14.2.............
total amount of Advance Payment (as a percentage
%
of Accepted Contract Amount)
..........................................
14.2.............
currency or currencies of Advance Payment ..................
4 © FIDIC 2017 Conditions of Contract for Construction
Sub-Clause Data to be given Data
CONDITIONS
GENERAL
14.2.3..........
percentage deductions for the repayment of the Advance
Payment........................................................................... %
14.3.............
period of payment............................................................
GUIDANCE
14.3(b).........
number of additional paper copies of Statements...............
14.3(iii) ........
percentage of retention..................................................... %
.
FORMS
Plant and Materials for payment when shipped..................
14.5(b)(i) ......
...........................................................................
14.7(b)(i) ...... period for the Employer to make interim payments to the
Contractor under Sub-Clause 14.6 [Interim Payment]........ days
14.7(c) ......... period for the Employer to make final payment to the
Contractor........................................................................ days
© FIDIC 2017 5
Sub-Clause Data to be given Data
CONDITIONS
GENERAL
14.15(c) ......
currencies and proportions for payment of Delay
.
Damages.........................................................................
GUIDANCE
rates of exchange..............................................................
14.15(f) ........
19.2.3(b)......
insurance required against liability for fitness for purpose yes/no
(delete as appropriate)
19.2.3..........
period of insurance required for liability for breach of
professional duty ...........................................................
CONDITIONS
GENERAL
19.2.4.......... amount of insurance required for injury to persons and
damage to property..........................................................
GUIDANCE
(give details).....................................................................
FORMS
21.1.............
list of proposed members of DAAB
- proposed by Employer ................................................ 1.
2.
3.
2.
3.
(Unless otherwise
stated here, it shall
be the President of
FIDIC or a person
appointed
by the President)
* These percentages shall also be applied to each half of the Retention Money under Sub-Clause 14.9.
© FIDIC 2017
7
Particular Conditions Part B – Special Provisions
CONDITIONS
GENERAL
INTRODUCTION
The terms of the Conditions of Contract for Construction have been prepared by the Fédération
Internationale des Ingénieurs-Conseils (FIDIC) and are recommended for general use for the
GUIDANCE
Modifications to the General Conditions may well be required to account for local legal
requirements, particularly if they are to be used on domestic contracts.
Under the usual arrangements for this type of contract, the Contractor is responsible for the
FORMS
construction, in accordance with the design of the Employer, of building and/or engineering works.
These Conditions allow for the possibility that the Contractor may be required to design a small
proportion or a minor element of the Permanent Works, but they are not intended for use where
significant design input by the Contractor is required or the Contractor is required to design a large
proportion or any major elements of the Permanent Works. In this latter case, it is
recommended that the Employer consider using FIDIC’s Conditions of Contract for Plant and
Design-Build, Second Edition 2017 (or, alternatively and if suitable for the circumstances of the
project, FIDIC’s Conditions of Contract for EPC/Turnkey Projects, Second Edition 2017).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The guidance hereafter is intended to assist drafters of the Special Provisions (Particular Conditions
– Part B) by giving options for various sub-clauses where appropriate. In some cases example
wording is included between lines, while in other instances only an aide-memoire is given.
FIDIC strongly recommends that the Employer, the Contractor and all drafters of the
Special Provisions take all due regard of the five FIDIC Golden Principles:
GP1: The duties, rights, obligations, roles and responsibilities of all the Contract
Participants must be generally as implied in the General Conditions, and
appropriate to the requirements of the project.
GP3: The Particular Conditions must not change the balance of risk/reward allocation
provided for in the General Conditions.
GP4: All time periods specified in the Contract for Contract Participants to perform
their obligations must be of reasonable duration.
These FIDIC golden principles are described and explained in the publication FIDIC’s
Golden Principles (http://http://fidic.org/bookshop †), and are necessary to ensure that
modifications to the General Conditions:
- are limited to those necessary for the particular features of the Site and the
project, and necessary to comply with the applicable law;
- do not change the essential fair and balanced character of a FIDIC contract; and
Before incorporating any new or changed sub-clauses, the wording must be carefully checked
to ensure that it is wholly suitable for the particular circumstances. Unless it is considered
suitable, example wording should be amended before use.
CONDITIONS
GENERAL
the Conditions of Contract, does not inadvertently change the obligations assigned to the Parties or
the balance of risks shared between them and/or does not create any ambiguity or misunderstanding
in the rest of the Contract documents.
Each time period stated in the General Conditions is what FIDIC believes is reasonable, realistic and
achievable in the context of the obligation to which it refers, and reflects the appropriate balance
GUIDANCE
between the interests of the Party required to perform the obligation, and the interests of the
other Party whose rights are dependent on the performance of that obligation. If consideration is
given to changing any such stated time period in the Special Provisions (Particular Conditions –
Part B), care should be taken to ensure that the amended time period remains reasonable,
realistic and achievable in the particular circumstances.
There are a number of Sub-Clauses in the General Conditions which require data to be provided by
the Employer and/or the Contractor and inserted into the Contract Data (Particular Conditions – Part
FORMS
A). However, there are no Sub-Clauses in the General Conditions which require data or information
to be included in the Special Provisions (Particular Conditions – Part B).
Provisions found in the Contract documents under Special Provisions (Particular Conditions – Part B)
indicate that the General Conditions have been amended or supplemented.
In describing the Conditions of Contract in the tender documents, the following text can be used:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
“The Conditions of Contract comprise the “General Conditions”, which form part of
the “Conditions of Contract for Construction” Second Edition 2017 published by the
Fédération Internationale des Ingénieurs-Conseils (FIDIC), the Contract Data (Particular
Conditions – Part A) and the following “Special Provisions” (Particular Conditions – Part
B), which include amendments and additions to such General Conditions.”
The provisions of the Special Provisions (Particular Conditions – Part B) will always over-rule
and supersede the equivalent provisions in the General Conditions, and it is important that the
changes are easily identifiable by using the same clause numbers and titles as appear in the
General Conditions. Furthermore, it is necessary to add a statement in the tender documents for
a contract that:
†
Please Note: all web links referred to in these guidance notes are up-to-date as of the date of
this publication but it is recommended that users of these guidance notes check online, at the
time that they wish to reference the relevant document, for the most up-to-date version of the
document.
© FIDIC 2017
9
NOTES ON THE PREPARATION OF TENDER DOCUMENTS
CONDITIONS
GENERAL
When preparing the tender documents and planning the tender process, Employers should
read the publication FIDIC Procurement Procedures Guide 1st edition 2011
(http://fidic.org/books/ fidic-procurement-procedures-guide-1st-ed-2011) which presents a
systematic approach to the procurement of engineering and building works for projects of all
sizes and complexity, and gives invaluable help and advice on the contents of the tender
documents, and the procedures for receiving and evaluating tenders. This publication provides
GUIDANCE
The tender documents should be prepared by suitably qualified engineers who are familiar with the
FORMS
technical aspects of the required works and the particular requirements and contractual provisions
of a construction project. Furthermore, a review by suitably-qualified lawyers is advisable.
The tender documents issued to tenderers should normally include the following:
- Letter of invitation to tender
wishes tenderers to include in their Tenders but which do not form part of the
Specification and/ or Drawings)
- Technical information and data (including the data referred to in Sub-Clause 2.5 [Site Data
and Items of Reference] of the General Conditions)
- the Specification
- the Drawings
The publication FIDIC Procurement Procedures Guide referred to above provides useful guidance
as to the content and format of each of the above.
For this type of contract where the Works are normally valued by measurement, the Bill of
Quantities will usually be the most important Schedule. A Daywork Schedule may also be necessary
to cover minor works to be executed at cost. In addition, each of the tenderers should receive
the data referred to in Sub-Clause 2.5 [Site Data and Items of Reference], and the lnstructions to
Tenderers should advise them of any special matters which the Employer wishes them to take
into account when pricing the Works but which are not to form part of the Contract.
When the Employer accepts the Letter of Tender, the Contract (which then comes into full force and
effect) includes these completed Schedules.
The following Sub-Clauses make express reference to matters to be stated in the Specification and/
or Drawings. However, it may also be necessary under other Sub-Clauses for the Employer to give
specific information in the Specification (for example, under Sub-Clause 7.2 [Samples]).
CONDITIONS
GENERAL
1.13 Compliance with Laws
GUIDANCE
4.1 Contractor’s General Obligations
4.5 Training
4.6 Co-operation
FORMS
4.8 Health and Safety Obligations
7.3 Inspection
7.8 Royalties
8.3 Programme
Many Sub-Clauses in the General Conditions make reference to data being contained in the Contract
Data (Particular Conditions – Part A). This data must be provided in the tender documents, and
these Conditions of Contract assume that all such data will be provided by the Employer, except as
expressly noted in the example form of Contract Data included in this publication. If the
Employer requires tenderers to provide any of the other information required in the Contract
Data, the tender documents must make this clear.
If the Employer requires tenderers to provide additional data or information, a convenient way of
doing this is to provide a suitably worded questionnaire with the tender documents.
The Instructions to Tenderers may need to specify any constraints on the completion of the Contract
Data and/or Schedules, and/or specify the extent of other information which each tenderer is to
© FIDIC 2017
11
include with his/her Tender. If each tenderer is to produce a tender security and/or a parent
company guarantee, these requirements should be included in the Instructions to Tenderers:
CONDITIONS
GENERAL
The Instructions to Tenderers may require the tenderer to provide information on the matters
referred to in some or all of the following Sub-Clauses:
4.3 Contractor’s Representative
GUIDANCE
19 Insurance
It is important for the Parties to understand which of the documents included in the tender
dossier, and which of the documents submitted by tenderers, will form part of the Contract and
therefore have continuing effect. For example, the Instructions to Tenderers are not, by
FORMS
definition, a part of the Contract. They are simply instructions and information on the preparation
and submission of the tender, and they should not contain anything of a binding or contractual
nature.
Finally, when planning the overall programme for the project, Employers must remember to allow a
realistic time for:
- tenderers to prepare and submit a responsive Tender (avoiding time that is either too
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
short which can reduce competition and result in inadequate submittals, or too long which
can be wasteful to all parties involved); and
- the review and evaluation of tenders and the award of the Contract to the successful
tenderer. This will be the minimum time which tenderers should be asked to hold their
tenders valid and open to acceptance.
CONDITIONS
GENERAL
It is very important that Employers (and all drafters of the Special Provisions) work with their
professional advisers to review specific terminology in the General Conditions for compliance
and consistency with accepted practice in the legal jurisdiction they are operating in.
For example:
GUIDANCE
• under a number of legal systems (notably in some common law jurisdictions) the term
“gross negligence” has no clear definition and, as such, is often avoided in legal
documents; and
• under English law, the term “indemnity” or “indemnify” has a specific meaning, entitling
the indemnified party to recover certain losses that may not otherwise be recoverable
at law. For example, a Contractor’s indemnity may be construed to permit the
Employer to recover losses or damages that might otherwise be considered indirect or
FORMS
consequential, whereas for some events which may arise both Parties’ losses or
damages are intended to be limited by Sub-Clause 1.15 [Limitation of Liability] to
direct damages only.
The following references and examples show some of the Sub-Clauses in the General
Conditions which may need amending to suit the needs of the project or the requirements of the
Employer. The selected Sub-Clauses and the example wording are included as examples only.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
They also include, as an aide-memoire, references to other documents such as the Specification
and/or Drawings and the Contract Data, where particular issues may need to be addressed.
The selected Sub-Clauses do not necessarily require changing and the example wording may
not suit the needs of a particular project or Employer. It is the responsibility of the drafter of the
Special Provisions to ensure that the selection of the Sub-Clauses and the choice of wording is
appropriate to the project concerned.
Furthermore, there may be other Sub-Clauses, not mentioned below, which need to be
amended. Great care must be taken when amending the wording of Sub-Clauses from the General
Conditions, or adding new provisions, to ensure that the balance of obligations and rights of the
Parties are not unintentionally compromised.
© FIDIC 2017
13
Clause 1 General Provisions
CONDITIONS
GENERAL
The opening words of Sub-Clause 1.1 mean that the definitions apply, not only to the
Conditions of Contract, but to all the documents of the Contract. Therefore, the Employer
should take care (particularly when drafting the Specification) and the Contractor should take care
(particularly when drafting the documents of the Tender) to use terms in accordance with those
GUIDANCE
Regarding the definition of “Base Date” under Sub-Clause 1.1.4, if the Employer makes significant
data/information available to tenderers 28 days or less before the due date for submission of
tenders, then it is recommended that the Employer consider extending that date so that such
information is provided before the Base Date for the purposes of the Contract conditions
(including Sub-Clause
2.5 [Site Data and Items of Reference] and Sub-Clause 4.12 [Unforeseeable Physical Conditions]).
FORMS
The defined term “Site”, under Sub-Clause 1.1.74, is used for a number of different purposes in
the General Conditions (for example: insurances and security) and so, if it is anticipated that
any item(s) of equipment, Plant, Materials and Temporary Works are to be located or stored in
places other than where the Permanent Works are to be executed, it is recommended that
consideration be given to specifying such places in the Contract (by the Employer in the
Specification and/or by the Contractor in the Tender).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In general, changes should not be made to the definitions as this could have serious consequences
on the interpretation of the documents of the Contract, particularly the Conditions of Contract.
However, there are limited circumstances where it may be desirable to amend some of the
definitions. For example:
Also, some of the defined terms in the General Conditions may not be appropriate and may
need changing or developing.
For example, if the extent of the Site crosses the border between two countries, it is recommended
that consideration be given to the following changes:
EXAMPLE 1.1.20
EXAMPLE 1.1.52
If the Contract specifies that the Contractor shall design any part of the Permanent Works and
if, after such part has been taken over, the Employer wishes to carry out Tests after Completion on
that part, detailed requirements regarding these tests should be stated in the Specification.
The Specification should describe the tests the Employer will carry out to verify that the part
designed by the Contractor fulfils the Employer’s performance requirements, which requirements
should also be stated in the Specification.
CONDITIONS
GENERAL
Design-Build Projects, Second Edition 2017.
If it is necessary to introduce new terminology into the text of the Special Provisions, each
term should be carefully and properly defined, using a clear Sub-Clause numbering system
for the new/additional defined terms. It is recommended, that the numbering of new
definitions does not interfere with the numbering as originally included in the General
GUIDANCE
Conditions. For example:
FORMS
In some jurisdictions, it may be advisable to add additional definitions to clarify certain terms/
expressions which appear in the General Conditions but are not defined. A typical
example might be:
In relation to the meaning of “consent” under sub-paragraph (g), it should be noted that
this does not mean “approve” or “approval” which, under some legal jurisdictions, may be
interpreted as accepting or acceptance that the requested matter is wholly satisfactory -
following which the requesting party may no longer have any responsibility or liability for
it.
If Notices are only to be given in paper format by post, then consideration may be given
to increasing the particular timescales for Notices in the Conditions of Contract to allow
extra days for the Notice to be delivered to the recipient.
“The documents forming the Contract are to be taken as mutually explanatory of one another. If an am
© FIDIC 2017
15
Sub-Clause 1.6 Contract Agreement
CONDITIONS
The form of the Contract Agreement should be included in the tender documents as an
GENERAL
annex to the Special Provisions: an example form is included at the end of this publication (in
the section “Sample Forms”).
Entry into a formal Contract Agreement may be mandatory under the applicable law. In such
a case, the words “unless they agree otherwise” should be deleted from the text.
Additional provisions may be required if all rights to particular items of computer software (for
FORMS
example) are to be assigned to the Employer. These provisions should take account of
the applicable law.
In respect of sub-paragraphs (b) and (c) of this Sub-Clause, if (in addition to the provisions of
Sub-Clause 4.18 [Protection of the Environment]) the applicable law requires the Contractor
to apply for and/or comply with particular environmental permits, these permits should be
stated in the Specification together with the Contractor’s obligations associated with
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
each permit.
If it is likely that one or more of the tenderers will be a Joint Venture, detailed requirements for
the JV may need to be specified in addition to those listed in the definition of “JV
Undertaking” under Sub-Clause 1.1.47. For example, it may be desirable for each
member of the JV to produce a parent company guarantee: an example form is included
at the end of this publication (in the section “Sample Forms”).
These requirements should be included in the Instructions to Tenderers. Normally the
Employer will wish the leader of the JV to be appointed at an early stage, providing a
single point of contact thereafter, and will not wish to be involved in a dispute between the
members of a JV.
The Employer should scrutinise the JV Undertaking carefully and, where relevant, check if the
project’s financing institution(s) has/have to give consent.
If it is required that the limitation of each Party’s liability to the other Party is to include certain
“indirect or consequential loss or damage” and is also to take into account liabilities
which are to be insured under Clause 19 [Insurance], the Contract Data and this Sub-
Clause may be varied:
A:
Amount of Sum B:
Amount of Sum C:
“
CONDITIONS
GENERAL
(a) for failure to comply with Sub-Clause 8.2 [Time for
Completion], the limit shall be the maximum amount of
Delay Damages stated in the Contract Data;
(b) for loss of profit, loss of any contract or loss of use of any
part of the Permanent Works (after taking over under the
Contract), caused by:
GUIDANCE
(i) defects attributable to the Contractor, the limit shall
be the sum A stated in the Contract Data;
(ii) damage to the Works caused by the Contractor,
the limit shall be the sum B stated in the Contract
Data;
(iii) damage caused by the Contractor to the
Employer’s property other than the Works, the limit
FORMS
shall be fifty percent (50%) of the sum B stated in
the Contract Data; and
(iv) any other matter attributable to the Contractor, the
limit shall be fifty percent (50%) of the sum A stated in
the Contract Data;
(c) for damage caused by the Contractor to the Works, the limit
shall be the required value of cover of the insurance
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
© FIDIC 2017
17
of cover of the insurance under Sub-Clause 19.2.1
[The Works];
CONDITIONS
GENERAL
and
(vi) for all matters other than those described in
sub-paragraph (i) to (v) above and other than
under Sub-Clause 17.3 [Intellectual and Industrial
Property Rights], the limit shall be in accordance with
Sub-Clause
14.14 [Cessation of Employer’s Liability] as may
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
It may be necessary for the Contractor to have early access to the Site for the purposes
of survey and sub-surface investigations. If so, the details of such early right of access
should be stated in the Specification, including any restrictions on such access and
whether or not it shall be exclusive to the Contractor.
If right of access to, and possession of, the Site cannot be granted by the Employer in
the normal way, details should be stated in the Specification and appropriate amendments
made to the first paragraph of this Sub-Clause and, if necessary, to the second
paragraph.
If Employer-Supplied Materials are listed in the Specification for the Contractor’s use in
the execution of the Works, the following provisions may be added:
CONDITIONS
GENERAL
promptly give a Notice to the Engineer of any shortage, defect or
default in them. Thereafter, the Contractor shall rectify such
shortage, defect or default to the extent instructed by the
Engineer. Such instruction shall be deemed to have been given
under Sub-Clause 13.3.1 [Variation by Instruction].
GUIDANCE
After this visual inspection, the Employer-Supplied Materials
shall come under the care, custody and control of the
Contractor. The Contractor’s obligations of inspection, care,
custody, and control shall not relieve the Employer of liability for
any shortage, defect or default not apparent from a visual
inspection.”
FORMS
the Works] after the two instances of “Goods” add
“, Employer-Supplied Materials,”.
If Employer’s Equipment is listed in the Specification for the Contractor’s use in the execution
of the Works, the following provisions may be added:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The Contractor shall not remove from the Site any items of the
Employer’s Equipment without the consent of the Employer.
However, consent shall not be required for vehicles transporting
Goods or Contractor’s Personnel to or from the Site.”
In the last paragraph of Sub-Clause 17.1 [Responsibility for Care of
the Works] after the two instances of “Goods” add:
“, Employer’s Equipment”,
© FIDIC 2017
19
Clause 3 The Engineer
CONDITIONS
GENERAL
It is recommended that the engineer who was appointed by the Employer to carry out the
Employer’s design of the Works is retained by the Employer to act as the Engineer under the
Contract for services during construction of the Works.
GUIDANCE
In the appointment of the Engineer, it is recommended that the Employer and the
Engineer use the form of agreement FIDIC Clients/Consultants Model Services Agreement
fifth Edition, 2017 (http://fidic.org/books/clientconsultant-model-services-agreement-
5th-ed- 2017-white-book).
In performing the Engineer’s duties and in exercising his/her authority under the Contract, the
FORMS
EXAMPLE “The Engineer shall obtain the consent of the Employer before
taking action under the following Sub-Clauses of these Conditions:
(a) Sub-Clause *
(b) Sub-Clause *“
This list should be extended or reduced as necessary. If the obligation to obtain the
Employer’s consent only applies beyond certain limits, financial or otherwise, the example
wording should be varied accordingly.
It should be noted that any such requirement shall not be applied to any action by the
Engineer under Sub-Clause 3.7 [Agreement or Determination], as stated in Sub-Clause 3.2
[Engineer’s Duties and Authority] of the General Conditions.
CONDITIONS
GENERAL
“If any assistants are not fluent in this language the Engineer shall
make competent interpreters available during all working hours, in
a number sufficient for those assistants to properly perform
their assigned duties and/or exercise their delegated authority.”
GUIDANCE
Sub-Clause 3.5 Engineer’s Instructions
If the applicable law prevents the Contractor from complying with any Engineer’s instruction
that may have an adverse effect on the health and safety of the Contractor’s Personnel,
sub-paragraph (b) of this Sub-Clause may be amended:
FORMS
“or will adversely affect the health and safety of the
Contractor’s Personnel”.
If the Conditions of Contract are to allow for the giving of oral instructions by the Engineer,
this Sub-Clause may be amended:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
assistant:
(a) gives an oral instruction;
(b) receives a written confirmation of the instruction, from
the Contractor, within two working days after giving the
oral instruction; and
(c) does not reply by issuing a written rejection and/or
instruction within two working days after receiving the
confirmation
then the Contractor’s confirmation shall constitute the written
instruction of the Engineer or delegated assistant (as the case may
be).”
The Engineer shall not delegate any of his/her duties under this Sub-Clause to the Engineer’s
Representative (if appointed) or to any assistant, as stated under Sub-Clause 3.4 [Delegation
by the Engineer].
The opening words of this Sub-Clause state that the Engineer “shall act neutrally between the
Parties” when carrying out his/her duties under this Sub-Clause and “shall not be
deemed to act for the Employer”. By these statements it is intended that, although the
Engineer is appointed by the Employer and acts for the Employer in most other respects
under the Contract, when acting under this Sub-Clause the Engineer treats both Parties
even-handedly, in a fair-minded and unbiased manner.
In some projects there may be an item or items of Temporary Works for which the Contractor
will not be fully responsible. For example, an Employer-designed temporary diversion of an
existing road or waterway may be necessary to facilitate the Works. In this case, and in order for
the second sentence of the third paragraph to apply (“Except to the extent specified in the
GUIDANCE
Contract …”), the item(s) of Temporary Works and the extent of the Employer’s responsibility
should be clearly stated in the Contract (by the Employer in the Specification, or by the
Contractor in the Tender).
The acceptable form(s) of Performance Security should be included in the tender documents.
Example forms are included at the end of this publication (in the section “Sample Forms”).
FORMS
They incorporate two sets of Uniform Rules published by the International Chamber of
Commerce (the “ICC”, which is based at 33-43 Avenue du Président Wilson, 75116 Paris,
France), which also publishes guides to these Uniform Rules.
These example forms and the wording of the Sub-Clause may have to be amended to comply
with applicable law.
Obligations], insert:
The example forms of Performance Security that are included at the end of this publication (in
the section “Sample Forms”) provide for the option to reduce the amount of the Performance
Security following issue of the Taking-Over Certificate for the whole of the Works under
Clause
10. If neither of the example forms is to be used, consideration should be given to adding
provisions for this option to Sub-Clause 4.2.1.
If the Contractor’s Representative is known at the time of submission of the tender, the
tenderer may propose that person in his/her tender. The tenderer may wish to propose
alternatives, especially if the contract award seems likely to be delayed.
The “main engineering discipline applicable to the Works” in which the Contractor’s
Representative is required to be qualified, experienced and competent should be the
engineering discipline of the Works which is of highest value proportionate to the value of the
Works. If it is necessary to stipulate that the Contractor’s Representative shall be
qualified, experienced and competent in a particular engineering discipline in relation to the
Works, the following amendment will need to be made to this Sub-Clause:
CONDITIONS
GENERAL
“The Contractor’s Representative shall also be fluent in
(insert name of language).”
If it is permissible that the Contractor’s Representative is not fluent in the language for
communications defined in Sub-Clause 1.4 [Law and Language], consideration should
be given to amending this Sub-Clause:
GUIDANCE
EXAMPLE Insert at the end of the second paragraph of Sub-Clause 4.3:
FORMS
his/her authority under the Contract.”
If it is permissible that the Contractor’s Representative’s delegates are not all fluent in
the language for communications defined in Sub-Clause 1.4 [Law and Language],
consideration should be given to amending this Sub-Clause:
It is important that the Specification should clearly specify which Contractor’s Documents the
Employer requires the Contractor to prepare, which may not necessarily include (for example)
all the technical documents which the Contractor’s Personnel will need in order to
execute the Works.
Further, if there are Contractor’s Documents that the Contractor must submit to the Engineer
for review, it is important that they are clearly identified in the Specification.
If a different Review Period than that stated under Sub-Clause 4.4.1 is considered necessary,
or different Review Periods are considered necessary for different (types of) Contractor’s
Documents, such different Review Period(s) should be clearly stated in the Specification.
If the Contractor is required to supply spare parts under the Contract, these should be
detailed in the Specification, which should also specify the required guarantee period for
these spare parts.
If the Works include Plant that comprises (in whole or in part) new or innovative
technology in the Country or at the Employer’s location, it is recommended that the
Parties consider including in the Contract provision for training (by the Employer in the
Specification and/or by the Contractor in the Tender) of the Employer’s Personnel at the
location of another plant facility, or at a number of other plant facilities, that are similar in
nature to the Works.
© FIDIC 2017
23
Sub-Clause 4.8 Health and Safety Obligations
CONDITIONS
If the Contractor is sharing occupation of the Site with others, it may not be appropriate
GENERAL
so that it is clear which Party is responsible for what in respect of the health and safety
obligations for the Site and for the Works.
If the Employer requires the Contractor to have a Quality Manager employed on the Site, such
position should be stated in the Specification as one of the positions of Key Personnel.
If the Employer requires the Contractor to interface with others and/or with the Employer, the
Specification should clearly describe all such interfaces and should specify the extent in which
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If this risk is to be shared between the Parties, this Sub-Clause will need to be amended:
In order to assist the Engineer in performing his duties under Sub-Clause 14.12.5 [Agreement
or Determination of Delay and/or Cost] in the event that Unforeseeable physical conditions are
encountered by the Contractor, the Employer may consider including the physical/geological/
sub-surface conditions that are known at the Base Date in the Contract - in the form of a
‘”Baseline Report”.
In some cases, the Contractor may be required to get permission prior to delivery of Goods to
the Site. In such cases those Goods for which permission is required should be stated in
the Specification, and the following wording may be added to this Sub-Clause:
CONDITIONS
GENERAL
If the Contractor is not to provide all the Contractor’s Equipment necessary to execute
the Works, the Employer’s obligations should be specified: please see Sub-Clause 2.6
[Employer-Supplied Materials and Employer’s Equipment] and the guidance notes for
Sub-Clause 2.6 above.
GUIDANCE
Clause:
FORMS
This vesting of property from the Contractor to the Employer
shall not:
(a) affect the responsibility or liability of the Employer under the
Contract;
(b) prejudice the Contractor’s right to exclusive use of all
items of Contractor’s Equipment for the purpose of the
Works; and/or
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If services are to be available on the Site for the Contractor to use, details of such
services should be stated in the Specification, including a description of each utility, the
capacity of each utility that is available for the Contractor’s use, its location and the price
per unit of consumption.
If the Contractor is sharing occupation of the Site with others, it may not be appropriate for the
Contractor to be responsible for its security. In these circumstances, it is recommended
that:
a) this Sub-Clause should be amended to specify exactly what security obligations are
the Contractor’s under the Contract,
and
b) the security obligations which are to be fulfilled by the Employer and/or others should
be stated in the Specification
so that it is clear which Party is responsible for what in respect of the security of the Site.
© FIDIC 2017
25
Sub-Clause 4.22 Contractor’s Operations on Site
CONDITIONS
If the Contractor is sharing occupation of the Site with others, it is recommended that this
GENERAL
Sub-Clause is amended by identifying and allocating responsibility for clearance and removal
from the Site of any wreckage, rubbish, hazardous waste, temporary works and surplus
material.
If the Employer wishes to have certain parts of the Works completed within certain times
but does not wish to take over such parts when completed (as distinct from the parts of
the Works which the Employer wishes to take over after completion, which should be defined
as Sections in the Contract Data), such parts of the Works should be clearly described in
the Specification as ‘Milestones’ and it is recommended that the following provisions are
added to the Contract Data and to the Conditions of Contract:
CONDITIONS
GENERAL
apply to each Milestone, such that “Time for Completion” under
Sub-Clause 8.5 shall be read as the time for completion of a
Milestone under this Sub-Clause.
GUIDANCE
will, in the Contractor’s opinion, be complete. The Engineer
shall, within 28 days after receiving the Contractor’s Notice:
(a) issue the Milestone Certificate to the Contractor, stating the
date on which the works of the Milestone were
completed in accordance with the Contract, except for
any minor outstanding work and defects (as shall be
listed in the Milestone Certificate); or
FORMS
(b) reject the application, giving reasons and specifying the
work required to be done and defects required to be
remedied by the Contractor to enable the Milestone
Certificate to be issued.
© FIDIC 2017
27
Clause 5 Subcontracting
CONDITIONS
GENERAL
It may be appropriate and/or desirable, taking account of the circumstances and locality of the
project, to encourage the Contractor to employ local contractors in the execution of the Work:
“or
(iii) a Subcontractor where the value of his/her subcontract is
less than one percent (1%) of the Accepted Contract Amount.”
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If the Engineer’s consent is required to the suppliers of certain Materials, this Sub-Clause may
be amended:
If the Employer requires that all the Contractor’s subcontracts should provide for assignment
of the subcontract to the Employer in the event that Sub-Clause 15.2 [Termination for
Contractor’s Default] applies, the following amendment will need to be made to this Sub-
Clause:
If the Employer requires that the Contractor assigns the benefit of the relevant subcontract in
the event that a Subcontractor’s obligations continue after expiry of the DNP relating to
that Subcontractor’s work, the following amendment will need to be made to this Sub-
Clause:
CONDITIONS
GENERAL
obligations to the Employer. Unless otherwise stated in the
assignment, the Contractor shall have no liability to the
Employer for work carried out by the Subcontractor after the
assignment takes effect.”
GUIDANCE
Normally the Contractor will select and employ subcontractor(s), (subject to any constraints
stated in the Contract), but this Sub-Clause provides for the situation where the
Employer may wish to select a particular subcontractor or subcontractors to be employed
by the Contractor in the execution of the Works.
If this is the case, it is recommended that the Employer names the particular subcontractor(s)
in the Specification so that tenderers are aware of this requirement before submitting their
FORMS
tenders
- although this Sub-Clause also makes provision for the Engineer to instruct the Contractor to
employ a subcontractor or subcontractors selected by the Employer after contract award.
It should be noted that:
a) once the Contractor has employed a subcontractor who has been nominated by the
Employer, the second paragraph of Sub-Clause 5.1 [Subcontractors] applies;
and
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
It may be necessary to review and revise this Sub-Clause (or delete it in its entirety) if
the relevant labour Laws applicable to the Contractor’s Personnel and/or the Employer’s
Personnel do not permit any restriction on the right of any worker to seek other positions.
If the Employer plans to make any facilities and/or accommodation (for example, office
accommodation) available for the Contractor’s occupation and/or use, the Employer’s
obligations to do so and details of such facilities and/or accommodation should be stated
in the Specification. See also the guidance under Clause 17 [Care of the Works and
Indemnities] below for the suggested additional sub-clause in respect of responsibility for
care of such facilities and/or accommodation.
If it is permissible that the Contractor’s superintending staff are not all fluent in the
language for communications defined in Sub-Clause 1.4 [Law and Language], then
consideration should be given to amending this Sub-Clause:
“or, if not, the Contractor shall make competent interpreters available during all working hours, in a nu
© FIDIC 2017
29
If it is necessary to stipulate that the Contractor’s superintending staff shall be fluent in a
particular language, the following sentence should be added.
CONDITIONS
GENERAL
If it is permissible that all Key Personnel are not fluent in the language for
communications defined in Sub-Clause 1.4 [Law and Language], then consideration
should be given to amending this Sub-Clause:
“If any of the Key Personnel are not fluent in this language the
Contractor shall make competent interpreter(s) available during all
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Additional Sub-Clauses
“The Contractor may bring into the Country any foreign personnel who
are necessary for the execution of the Works to the extent
allowed by the applicable Laws. The Contractor shall ensure
that these personnel are provided with the required residence
visas and work permits. The Employer shall, if requested by the
Contractor, use all reasonable endeavours in a timely and
expeditious manner to assist the Contractor in obtaining any local,
state, national, or government permission required for bringing in
the Contractor’s personnel.
CONDITIONS
GENERAL
“The Contractor shall at all times take the necessary
precautions to protect the Contractor’s Personnel employed on
the Site from insect and pest nuisance, and to reduce the danger
to their health. The Contractor shall comply with all the
regulations of the local health authorities, including use of
appropriate insecticide.”
GUIDANCE
EXAMPLE SUB-CLAUSE FOR ALCOHOLIC LIQUOR OR DRUGS
“The Contractor shall not, other than in accordance with the Laws
of the Country, import, sell, give, barter or otherwise dispose of
any alcoholic liquor or drugs, or permit or allow importation,
sale, gift, barter or disposal thereto by the Contractor’s
Personnel.”
FORMS
EXAMPLE SUB-CLAUSE FOR ARMS AND AMMUNITION
If the Contractor is to provide high-value items of Plant and/or Materials under the Contract,
consideration may be given to amending this Sub-Clause:
“No Plant and/or Materials that is the property of the Employer shall
be removed from the Site. If it becomes necessary to:
(i) remove any item of such Plant from the Site for the
purposes of repair, the Contractor shall give a Notice, with
reasons, to the Engineer requesting consent to remove the
defective or damaged item off the Site. This Notice shall
clearly identify the item of defective or damaged Plant, and
shall give details of: the defect or damage to be repaired;
the place to which defective or damaged item of Plant is
to be taken for repair; the transportation to be used (and
insurance cover for such transportation); the proposed
inspections and testing off the
32 © FIDIC 2017 Conditions of Contract for Construction
Site; and the planned duration required before the repaired
item of Plant shall be returned to the Site. The
CONDITIONS
GENERAL
Contractor shall also provide any further details that the
Employer may reasonably require; or
(ii). replace any item(s) of such Plant and/or Materials, the
Contractor shall give a Notice, with reasons, to the
Engineer clearly identifying the item(s) of Plant and/or
Materials to be replaced, and giving details of the due
GUIDANCE
date of delivery to the Site of the replacement item(s).
Where any item of Plant and/or Materials has become the property
of the Employer under this Sub-Clause before it has been
delivered to the Site, the Contractor shall ensure that such an
item is not moved except for its delivery to the Site.
FORMS
The Contractor shall indemnify and hold the Employer
harmless against and from the consequences of any defect in
title or encumbrance or charge (except any reasonable
restriction arising from the intellectual property rights of the
manufacturer or producer) on any item of Plant and/or Materials
that has become the property of the Employer under this Sub-
Clause.”
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Additional Sub-Clause
If the Contract is being financed by an institution whose rules or policies require a restriction
on the use of its funds, a further sub-clause may be added:
If the Works are to be completed and taken over in stages it is important that each stage
is defined as a Section, and the Time for Completion of each Section is stated, in the
Contract Data (please also see the guidance below under Sub-Clause 10.1 [Taking Over
the Works and Sections].
It is strongly recommended that the programming software that is preferable to the Engineer
(in his/her monitoring of the Contractor’s progress in executing the Works) be clearly
identified in the Specification, and that such software is drawn to the attention of
tenderers in the Instructions to Tender.
For less complex projects, the Employer may consider simplifying the requirements for
the Contractor’s programme as listed in sub-paragraphs (a) to (k) in this Sub-Clause (for
example, by replacing sub-paragraphs (a) to (k) in this Sub-Clause with sub-paragraphs (a) to
© FIDIC 2017
33
(d) as they appear under Sub-Clause 8.3 [Programme] of FIDIC’s Conditions of Contract for
Construction, First Edition 1999).
CONDITIONS
GENERAL
Sub-paragraph (c) of this Sub-Clause entitles the Contractor to an extension of the Time
for Completion for “exceptionally adverse climatic conditions”. It may be preferable to set
out in the Specification what constitutes an “exceptionally adverse” event - for example, by
reference to available weather statistics and return periods. It may also be appropriate to
GUIDANCE
compare the adverse climatic conditions that have been encountered with the frequency with
which events of similar adversity have previously occurred at or near the Site. For example, an
exceptional degree of adversity might be regarded as one which has a probability of
occurrence of once every four or five times the Time for Completion of the Works (for
example, once every eight to ten years for a two-year contract).
The final paragraph of this Sub-Clause provides that the rules and procedures for assessing
FORMS
the Contractor’s entitlement to an EOT where there is concurrency between delays attributable
to both Parties shall be stated in the Special Provisions. This provision has been drafted by
FIDIC in this manner because there is no one standard set of rules/procedures in use
internationally (though, for example the approach given in the Delay and Disruption
Protocol published by the Society of Construction Law (UK):
https://www.scl.org.uk/sites/default/files/SCL_Delay_Protocol_2nd_Edition_Final.pdf† is
increasingly being adopted internationally) and different rules/procedures may apply in
different legal jurisdictions.)
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In preparing the Special Provisions, therefore, it is strongly recommended that the Employer
be advised by a professional with extensive experience in construction programming, analysis
of delays and assessment of extension of time in the context of the governing law of the
Contract.
Under the laws of many countries or other jurisdictions, the amount of these pre-defined
damages must be a reasonable estimate of the anticipated or actual loss caused to the
Employer by the delay. Therefore if the Delay Damages are fixed at an unreasonably
large amount, they may be unenforceable in common law jurisdictions or subject to
downward adjustment in civil law jurisdictions.
If the Accepted Contract Amount is to be quoted as the sum of figures in more than one
currency, it may be preferable to define these damages (per day) as a percentage to be
applied to each of these figures. If the Accepted Contract Amount is expressed in the
Local Currency, the damages per day may either be defined as a percentage or be
defined as a figure in Local Currency: see Sub-Clause 14.15(c).
Additional Sub-Clause
Incentives for early completion may be included (in addition to sub-paragraph (a) of Sub-Clause
13.2 [Value Engineering] which refers to accelerated completion):
For the purposes of calculating any bonus payment, the applicable Time for Completion stated in the C
CONDITIONS
GENERAL
Sub-Clause 9.1 Contractor’s Obligations
The Specification should describe the tests which the Contractor is to carry out before being entitled
to a Taking-Over Certificate. It may also be appropriate for the Contractor’s Proposal to include
detailed arrangements, instrumentation, etc.
GUIDANCE
If the Works are to be tested and taken over in Sections, it is strongly recommended that
consideration is given to testing requirements in the Specification that take due account of the effect
of other parts of the Works being incomplete.
For less complex projects, the Employer may consider simplifying the testing requirements
under this Sub-Clause.
FORMS
Sub-Clause 10.1 Taking Over the Works and Sections
If the Works are to be completed and taken over in stages it is important that each stage
is defined as a Section in the Contract Data. Precise geographical definitions are advisable,
and the Contract Data should include a table to also define for each Section:
• the relevant percentage for release of Retention Money,
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Depending on the complexity of the project and the nature of the Works, the Employer
may consider amending the period of “two years” stated at the end of the first paragraph
of this Sub-Clause to be a longer or a shorter period.
It may be necessary to review the effect of this Sub-Clause in relation to the period of
liability imposed by the applicable law.
In particular, the second paragraph of this Sub-Clause may require amending to take account
of the applicable law.
Additional Sub-Clause
If the Works include the Plant that comprises (in whole or in part) new or innovative
technology in the Country or at the Employer’s location, consideration may be given to
including in the Specification a requirement for the Contractor to provide supervisory
assistance to the Employer’s permanent operating personnel in the operation and
maintenance of the Plant during the DNP of the Works.
“The Contractor shall provide supervisory assistance to the Employer during the DNP for the Works. S
© FIDIC 2017
35
Clause 12 Measurement and Valuation
CONDITIONS
GENERAL
If any part of the Permanent Works is to be measured according to records of its construction,
this part should be identified, and the records to be made should be stated in the
Specification. If the Contractor is to be responsible for any such records, this should be
specified in the Contract (by the Employer in the Specification or by the Contractor in the
GUIDANCE
Tender).
c) the Engineer may request a proposal from the Contractor under Sub-Clause 13.3.2
[Variation by Request for Proposal].
Provisional Sums may be required for parts of the Works which are not required to be priced
at the risk of the Contractor. For example, a Provisional Sum may be necessary to cover
goods or services which the Employer wishes to select after award of the Contract, or to deal
with a major uncertainty regarding sub-surface conditions. It is essential to define the scope
of each Provisional Sum (it is recommended that this be included in a Schedule prepared by
the Employer), since the amount of each Provisional Sum corresponding to the defined scope
will then be excluded from the other elements of the Accepted Contract Amount.
The provision for adjustments under this Sub-Clause may be required if it would be
unreasonable for the Contractor to bear the risk of escalating costs due to inflation.
If the amounts payable to the Contractor are to be adjusted for rises or falls in the cost of
labour, Goods and other inputs to the Works, for this Sub-Clause to apply it is important that a
Schedule (or Schedules) of cost indexation is (are) included in the Contract and that such
Schedule(s) include a formula or formulae for calculation of the applicable adjustment under
this Sub-Clause.
Pn = a+b Ln +c En +d Mn + ......
Lo Eo Mo
where:
“Pn” is the adjustment multiplier to be applied to the estimated
contract value in the relevant currency of the work carried out
in period “n”, this period being a month;
CONDITIONS
GENERAL
the Works, such tabulated cost elements may be indicative of
resources such as labour, equipment and materials;
GUIDANCE
“Ln”, “En”, “Mn”, … are the current cost indices or reference
prices (stated in the Schedule of cost indexation) for period “n”,
expressed in the relevant currency of payment, each of which
is applicable to the relevant tabulated cost element on the date
49 days prior to the last day of the period (to which the
particular Payment Certificate relates); and
FORMS
“Lo”, “Eo”, “Mo”, … are the base cost indices or reference
prices, expressed in the relevant currency of payment, each of
which is applicable to the relevant tabulated cost element on the
Base Date.
Coefficient;
Country of Source of Value on stated
scope of index;
origin; date(s)*
index
currency of Title/definition Value.......Date
index
a= 0.10 Fixed
b= Labour
c=
d=
e=
* These values and dates confirm the definition of each index, but
do not define Base Date indices
When writing the Special Provisions, consideration should be given to the amount and timing
of payment(s) to the Contractor. A positive cash-flow is clearly of benefit to the
Contractor, and tenderers will take account of the interim payment procedures when
preparing their tenders.
Cost-plus contracts, under which the actual Cost is determined and Cost Plus Profit is
paid to the Contractor, are unusual and only used when (for reasons of urgency or
otherwise) the
© FIDIC 2017
37
Employer is willing to accept the risks involved. If the Contractor is to be paid Cost Plus Profit,
Clause 12 should be replaced by provisions describing the method of determining the
CONDITIONS
GENERAL
Cost and the Contract Price. As a result, the provisions in the General Conditions which
entitle the Contractor to payment of additional Cost will generally be of no effect.
Additional Sub-Clauses may be required to cover any exceptions to the provisions set out
in Sub-Clause 14.1, and any other matters relating to payment.
GUIDANCE
Lump sum contracts may be suitable if the tender documents include details which are
sufficiently complete for construction and for significant Variations to be unlikely. From
the information supplied in the tender documents, the Contractor can prepare any other
details necessary, and construct the Works, without having to refer back to the Engineer for
clarification or further information. However, as noted in the Introduction above, if significant
design input by the Contractor is required, it is recommended that the Employer consider
using FIDIC’s Conditions of Contract for Plant and Design-Build, Second Edition 2017 (or,
alternatively and if suitable for the circumstances of the project, FIDIC’s Conditions of
FORMS
For a lump sum contract, the tender documents should include a schedule of
payments (see Sub-Clause 14.4 [Schedule of Payments]).
CONDITIONS
GENERAL
Contract Amount and be subject to adjustments in accordance
with the Contract;”.
GUIDANCE
correct quantities of the Works which the Contractor is required to
execute; and”.
If the Contractor is not required to pay import duties on Goods imported by the Contractor into
the Country, an additional Sub-Clause should be added and sub-paragraph (b) of Sub-Clause
14.1 [The Contract Price] of the General Conditions should be amended accordingly:
FORMS
EXAMPLE SUB-CLAUSE FOR EXEMPTION FROM DUTIES
exemption documents:
If expatriate staff are exempted from paying local income tax, a suitable Sub-Clause
should be added and sub-paragraph (b) of Sub-Clause 14.1 [The Contract Price] of the
General Conditions should be amended accordingly. However, advice should be sought
from a qualified tax expert before drafting any such additional Sub-Clause.
© FIDIC 2017
39
EXAMPLE SUB-CLAUSE FOR EXEMPTION FROM TAXES
CONDITIONS
GENERAL
When writing the Particular Conditions, consideration should be given to the benefits of
the Employer making an advance payment to the Contractor. Unless this Sub-Clause is
not to apply, the advance payment and the currencies in which it is to be paid must be
specified in the Contract Data. The rate of deduction for the repayments should be checked
to ensure that repayment is achieved before the Contractor’s completion of the Works.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
The typical figures in sub-paragraphs (a) and (b) of Sub-Clause 14.2.3 [Repayment of
Advance Payment] of the General Conditions are based on the assumption that the advance
payment is less than 22% of the Accepted Contract Amount.
The acceptable form of Advance Payment Guarantee should be included in the tender
documents, annexed to the Particular Conditions: an example form is included at the end
of this publication (in the section “Sample Forms”).
If the Employer wishes to provide the advance payment in instalments, the Contract Data and
this Sub-Clause will need to be amended.
“The total amount of the advance payment, the number and timing
of instalments, and the applicable currencies and proportions shall
be as stated in the Contract Data.”.
- delete the words “equal to the advance payment” from the first
sentence and replace with: “equal to the total amount of the
advance payment”.
CONDITIONS
GENERAL
- in the third paragraph before “the advance payment has not been
repaid” add the words: “the total amount of”.
GUIDANCE
- in the last sentence, before “the advance payment” add the words:
“the first instalment of”.
FORMS
- delete sub-paragraph (b) replace with: “(b) the Engineer has received
a copy of the Contractor’s application for the first instalment of the
advance payment”.
The General Conditions contains provisions for interim payments to the Contractor,
which may be based on a Schedule of Payments. If another basis is to be used for
determining interim valuations, details should be added in the Special Provisions.
a) an amount, or percentage of the estimated final Contract Price, for each month
(or other period) during the Time for Completion (but this can prove
unreasonable if the Contractor’s progress differs significantly from the
expectation on which the Schedule was based); or
b) amounts based on the actual progress achieved by the Contractor in executing the
Works, which necessitates careful definition of the payment milestones (but
disagreements may arise when the work required for a payment milestone is nearly
achieved but the balance of the work, albeit minor, cannot be completed until some
months later).
The figures inserted by a tenderer in the Schedule of Payments may be compared with
his/ her tender programme (if any), in order to assess whether they are reasonably consistent
with each other.
Periods for payment should be long enough for the Employer to meet, but not so long as
to prejudice the Contractor’s positive cash-flow.
© FIDIC 2017
41
If the country or countries of payment need to be specified, details may be included in a
Schedule.
CONDITIONS
GENERAL
If all payments are to be made in Local Currency, this currency must be named in the
Letter of Tender, and this Sub-Clause may be replaced:
CONDITIONS
GENERAL
For major contracts in some markets, there may be a need to secure finance from
entities such as aid agencies, development banks, export credit agencies, or other
international financing institutions. If financing is to be procured from any of these
sources, the Special Provisions may need to incorporate the financing institution’s special
requirements. The exact wording will depend on the relevant institution, so reference will
need to be made to the institution to ascertain its requirements, and to seek approval of the
draft tender documents.
GUIDANCE
These requirements may include tendering procedures which need to be adopted in order to
render the eventual contract eligible for financing, and/or additional Sub-Clauses which may
need to be incorporated into the Special Provisions. The following examples indicate some of
the topics which the institution’s requirements may cover:
• prohibition from discrimination against the shipping companies of any one country;
FORMS
• ensuring that the Contract is subject to a widely-accepted neutral law;
• provision for arbitration under recognised international rules and at a neutral location;
• giving the Contractor the right to suspend/terminate in the event of default under the
financing arrangements;
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
• specifying that the Contract does not become effective until certain conditions
precedent have been satisfied, including pre-disbursement conditions for the
financing arrangements; and
• obliging the Employer to make payments from his own resources if, for any reason,
the funds under the financing arrangements are insufficient to meet the
payments due to the Contractor, whether due to a default under the financing
arrangements or otherwise.
The financing institution may wish the Contract to include references to the financing
arrangements, especially if funding from more than one source is to be arranged to
finance different elements of supply. It is not unusual for the Special Provisions to include
particular provisions identifying different categories of Works and specifying the
documents to be presented to the relevant financing institution to obtain payment. If the
financing institution’s requirements are not met, it may be difficult (or even impossible) to
secure suitable financing for the project, and/or the institution may decline to provide
finance for part or all of the Contract.
Where the financing is not tied to the export of goods and services from any particular country
but is simply provided by commercial banks lending to the Employer, those banks may
wish to satisfy themselves regarding the extent of the Contractor’s rights under the
Contract.
Alternatively, the Contractor may be prepared to initiate financing arrangements for the
Contract and retain responsibility for them, although the Contractor would probably be unable
or unwilling to provide finance from the Contractor’s own resources. The Contractor’s
financing bank’s requirements are then likely to affect the Contractor during contract
negotiations. For example, the financing bank may require the Employer to make interim
payments, although a large proportion of the Contract Price might be withheld until the
Works are complete. Since the Contractor would then have to arrange financing to cover
the shortfall between the payments and the Contractor’s outgoings, the Contractor (and the
financing bank) would probably require some form of security from the Employer,
guaranteeing payment when due.
It may be appropriate for the Employer, when preparing the tender documents, to
anticipate the latter requirement by undertaking to provide a guarantee for the element of
payment which the Contractor is to receive when the Works are complete. The acceptable
form(s) of
© FIDIC 2017
43
guarantee should be included in the tender documents, annexed to the Particular Conditions:
an example form is included at the end of this publication (in the section “Sample Forms”).
CONDITIONS
GENERAL
been discharged; or
(c) when the Employer has performed all obligations under
the Contract.”
Before inviting tenders, the Employer should verify that the wording of this Sub-Clause,
and each anticipated ground for termination, is consistent with the law governing the
Contract.
Sub-paragraph (h) in this Sub-Clause is intended to include situations, where the Contractor
or any of the Contractor’s employees, agents, Subcontractors or Contractor’s Personnel gives
or offers to give (directly or indirectly) to any person any bribe, gift, gratuity, commission
or other thing of value, as an inducement or reward for showing or forbearing to show
favour or disfavour to any person in relation to the Contract. However, this is not intended
to include lawful inducements and rewards by the Contractor to the Contractor’s
Personnel.
If the Employer has made available any Employer-Supplied Materials and/or Employer’s
Equipment in accordance with Sub-Clause 2.6, consideration should be given to an additional
sub-paragraph under this Sub-Clause:
EXAMPLE Insert the following new sub-paragraph at the end of sub-paragraph (b) of
Sub-Clause 15.2.3:
In many jurisdictions under the applicable law it may not be permissible for the Employer
to terminate the Contract for convenience (termination of the Contract only being
permitted in the event of default on the part of the Contractor and, thereafter, arranging
an equitable,
44 © FIDIC 2017 Conditions of Contract for Construction
non-discriminatory and transparent procurement process to select a replacement contractor).
Therefore, before inviting tenders the Employer should verify that the wording of this
CONDITIONS
GENERAL
Sub-Clause is consistent with the law governing the Contract.
GUIDANCE
Before inviting tenders, the Employer should verify that the wording of this Sub-Clause is
consistent with the law governing the Contract.
FORMS
other thing of value, as an inducement or reward for showing or forbearing to show
favour or disfavour to any person in relation to the Contract. However, this is not
intended to include lawful inducements and rewards by the Employer to the Employer’s
Personnel.
If the Employer has made available any Employer-Supplied Materials and/or Employer’s
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In respect of the Contractor’s obligation to indemnify under the second paragraph of this
Sub-Clause, it should be noted that this applies only to the extent, if any, that the Contractor
is required to carry out any design of the Permanent Works under the Contract. If this is the
case:
a) as this liability is not excluded under the first paragraph of Sub-Clause 1.15
[Limitation of Liability], the Contractor has no liability for any indirect or
consequential loss or damage suffered by the Employer as a result of any
negligence by the Contractor in designing the Works to be fit for purpose;
b) as this liability is not excluded under the second paragraph of Sub-Clause 1.15
[Limitation of Liability], it falls within the Contractor’s limitation of liability under
Sub-Clause 1.15; and
c) this liability may be covered by the insurance to be taken out by the Contractor
under Sub-Clause 19.2.3 [Liability for breach of professional duty], in which case
a statement to this effect should be included in the Contract Data.
Additional Sub-Clause
If the Contractor is to be allowed to use and/or occupy any of the Employer’s facilities
and/ or accommodation temporarily during the Contract, it is recommended that an
additional sub-clause be added to Clause 17 to cover the responsibility for care of such
facilities and/ or accommodation:
© FIDIC 2017
45
EXAMPLE SUB-CLAUSE FOR CONTRACTOR’S USE OF EMPLOYER’S FACILITIES/
ACCOMMODATION
CONDITIONS
GENERAL
“The Contractor shall take full responsibility for the care of the
items of the Employer’s facilities and/or accommodation listed
below, from the date of use and/or occupation by the Contractor
until the date on which such use and/or occupation is re-vested
in the Employer.
GUIDANCE
In respect of sub-paragraph (f) of this Sub-Clause, it should be noted that any event of
“exceptionally adverse climatic conditions” is excluded from the definition of what constitutes
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
an Exceptional Event. While this means that there is no right for either Party to suspend the
Works in the case of an event of “exceptionally adverse climatic conditions”, if this type of
event has the effect of delaying completion and taking-over of the Works or Section the
Contractor shall be entitled to EOT under sub-paragraph (c) of Sub-Clause 8.5 [Extension
of Time].
Clause 19 Insurance
If the Employer wishes to change the insurance provisions of this Clause – for example
by providing some of the insurance cover under the Employer’s own policy(ies) – it will be
necessary to review and revise the relevant Sub-Clause(s) under this Clause 19.
a) the tender documents include details of such insurances as an annex to the Special
Provisions so that tenderers can estimate what other insurances they may wish
to have for their own protection. The details should include the conditions of
insurance, limits, exceptions and deductibles; preferably in the form of a copy of each
insurance policy; and
In respect of any Claim under sub-paragraph (c) of this Sub-Clause, it should be noted
that “another entitlement or relief …or the execution of the Works” may include such
matters as:
CONDITIONS
GENERAL
- any other matter of entitlement under the Conditions of Contract or in connection
with, or arising out of, the Contract that does not involve payment by one Party
to the other Party and/or EOT and/or extension of the DNP.
Consideration may be given to replacing the words “within a reasonable time” in the last
paragraph of this Sub-Clause by a specified time period.
GUIDANCE
Clause 21 Disputes and Arbitration
Sub-Clause 21.1 Constitution of the DAAB
It is generally accepted that construction projects depend for their success on the avoidance
of Disputes between the Employer and the Contractor and, if Disputes do arise, the
FORMS
timely resolution of such Disputes.
Therefore, the Contract should include the provisions under Clause 21 which, while not
discouraging the Parties from reaching their own agreement on Disputes as the Works
proceed, allow them to bring contentious matters to an independent and impartial
dispute avoidance/adjudication board (“DAAB”) for resolution.
The provisions of this Sub-Clause are intended to provide for the appointment of the
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
DAAB, and FIDIC strongly recommends that the DAAB be appointed, as a ‘standing
DAAB’
– that is, a DAAB that is appointed at the start of the Contract who visits the Site on a regular
basis and remains in place for the duration of the Contract to assist the Parties:
a) in the avoidance of Disputes,
and
It is for this reason that, under the first paragraph of this Sub-Clause, the Parties are under a
joint obligation to appoint the member(s) of the DAAB within 28 days after the Contractor
receives the Letter of Acceptance if no other time is stated in the Contract Data. That said, it is
preferable that the member(s) of the DAAB are appointed before the Letter of Acceptance is
issued.
At an early stage in the Employer’s planning of the project, consideration should be given
as to whether a sole-member DAAB or a three-member DAAB is preferable for a
particular project, taking account of its size, duration and the fields of expertise which will be
involved.
This Sub-Clause provides for two alternative arrangements for the DAAB:
- a sole-member DAAB of one natural person, who has entered into a tripartite
agreement with both Parties;
or
- a three-member DAAB of three natural persons, each of whom has entered into
a tripartite agreement with both Parties.
The tripartite agreement above is referred to as the DAAB Agreement under the
Conditions of Contract. It is recommended that the form of this agreement be one of the
two alternative example forms included at the end of this publication (in the section
“Sample Forms”), as appropriate to the arrangement adopted.
It should be noted that both forms of the DAAB Agreement incorporate (by reference) the General
Conditions of Dispute Avoidance/Adjudication Agreement with its Annex DAAB
Procedural Rules, which are included as the Appendix to the General Conditions in this
publication.
© FIDIC 2017
47
Under either of these alternative forms of DAAB Agreement, each natural person of the DAAB
is referred to as a DAAB Member.
CONDITIONS
GENERAL
Contractor each avail himself/herself, of the opportunity at the tender stage of the Contract
to name potential DAAB members in the Contract Data.
The Contract Data includes two lists for potential DAAB Members to be named: one for
the Employer to list three names, the other for the Contractor to list three names. This
ensures that both Parties have equal opportunity to put forward (the same number of)
names for potential DAAB Members, and so avoid any question that DAAB Member(s) may
be imposed on one Party by the other Party.
FORMS
This provides a total of six potential DAAB Members from which the sole member or three
members (as the case may be) can be selected by the Parties. If it is considered necessary to
have a wider selection of DAAB Member(s) to choose from, then provision may be made
for longer lists in the Contract Data for both the Contractor and the Employer to name (the
same number of) additional DAAB Members.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If the Parties cannot agree on any DAAB member, Sub-Clause 21.2 [Failure to Appoint DAAB
Member(s)] applies and the selection and appointment of the DAAB member(s) should be
made by a wholly impartial entity with an understanding of the nature and purpose of a DAAB.
The President of FIDIC is prepared to perform this role if this authority has been delegated in
accordance with the example wording in the Contract Data. FIDIC maintains a list of approved
and experienced adjudicators for this specific purpose: The FIDIC President’s List of Approved
Dispute Adjudicators (http://fidic.org/president-list†).
If no potential DAAB members’ names are given in the Contract Data, consideration
should be given to stating a time period in the Contract Data that is greater than the default
period of 28 days stated in the first paragraph of this Sub-Clause.
The period of 224 days stated in sub-paragraph (i) of this Sub-Clause has been arrived at by
taking account of certain time allowances, as follows:
+ 84 days to submit detailed particulars for the Claim under Sub-Clause 20.2.4 [Fully
detailed Claim]
+ 84 days for the Engineer’s agreement/determination of the Claim under Sub-Clause 3.7
[Agreement or Determination]
As noted above, FIDIC strongly recommends that the DAAB be appointed at the start of
the Contract and remain in place for the duration of the Contract. However, as an alternative
to the ‘standing DAAB’ envisaged under this Sub-Clause, the Parties may prefer the dispute
board to be appointed on an ‘ad-hoc’ basis. In such case, the dispute board would be
appointed when a Dispute arises, its appointment would be limited to resolution of the
Dispute, it would have no role to play in the avoidance of Disputes between the Parties,
and its appointment would cease when it had given its decision on that Dispute. Should a
new Dispute arise, a new ad-hoc DAAB would be appointed. Given that such a dispute
board would have no
CONDITIONS
GENERAL
recommended ‘standing DAAB’, then the following amendments will be needed:
EXAMPLE Delete the definitions under Sub-Clause 1.1.22 and 1.1.23 and
replace with:
“ “Dispute Adjudication Board” or “DAB” means the person or
three persons (as the case may be) so named in the Contract,
GUIDANCE
or appointed under Clause 21.”
FORMS
contained in the corresponding provisions of FIDIC’s Conditions of
Contract for Plant and Design-Build, First Edition 1999.
To facilitate the appointment of the member(s) of an ‘ad-hoc DAB’, it is important that the
Employer and the Contractor each avail themselves of the opportunity at the tender stage of
the Contract to name three potential members in the Contract Data.
In circumstances where the DAAB has given its decision but one or both Parties is/are
dissatisfied with the decision, the provisions of this Sub-Clause are intended to
encourage the Parties to settle a Dispute amicably, without the need for arbitration.
Rather than considering the 28 day period stated in this Sub-Clause as a ‘cooling-off period’,
FIDIC recommends that the Parties avail themselves of this opportunity to actively
engage with each other with a view to settling their Dispute.
• expert determination (using, for example, the Expert Rules published by the
International Chamber of Commerce (the “ICC”, which is based at 33-43 Avenue du
Président Wilson, 75116 Paris, France) https://iccwbo.org/publication/icc-expert-
rules-english-version/ †);
© FIDIC 2017
49
In this regard, it is recommended that consideration be given by the Parties to agree to a
longer time period than the period of 28 days stated in this Sub-Clause in an effort to arrive at
CONDITIONS
GENERAL
Amicable settlement procedures typically depend for their success on the consensual
involvement of both Parties, on confidentiality and on both Parties’ acceptance of the
particular procedure. Therefore, while it is recommended that both Parties engage actively to
settle the Dispute amicably, neither Party should seek to impose the procedure on the
GUIDANCE
other Party.
If the Parties wish to adopt a mediation procedure in their attempt to settle the Dispute
amicably, then consideration may be given to the Mediation Rules, 2017 published by the
International Chamber of Commerce (the “ICC”, which is based at 33-43 Avenue du Président
Wilson, 75116 Paris, France)
https://iccwbo.org/dispute-resolution-services/mediation/mediation-rules/ †
FORMS
Appointment of Mediator
Once the mediator has been appointed, the Dispute shall immediately
be referred to the mediator by the Parties or by either Party.
Confidentiality
CONDITIONS
GENERAL
If the Parties accept the mediator’s recommendations, or
otherwise reach agreement on the settlement of the Dispute, such
agreement shall be recorded in writing and, once signed by the
designated representative(s) of both Parties, shall be binding
on the Parties.
Mediator’s Opinion
GUIDANCE
If no agreement is reached by the Parties after negotiations
have been facilitated by the mediator, either Party may invite
the mediator to provide to both Parties a non-binding opinion in
writing. Such opinion shall not be used in evidence in any
concurrent or subsequent proceedings.
Costs of Mediation
FORMS
The Parties will bear their own costs of participating in the
mediation, including but not limited to the costs of preparing
and submitting evidence to the mediator and attending the
mediation meeting.
The Contract should include provisions for the resolution by international arbitration of
any Dispute which is not settled amicably by the Parties. In international contracts,
international commercial arbitration has numerous advantages over litigation in national
courts and is likely to be more acceptable to the Parties.
Careful consideration should be given to ensuring that the international arbitration rules that
are chosen are compatible with the provisions of Clause 21 and with the other elements
to be set out in the Contract Data. The Arbitration Rules published by the International
Chamber of Commerce (the “ICC”, which is based at 33-43 Avenue du Président Wilson,
75116 Paris, France) https://iccwbo.org/dispute-resolution-services/arbitration/rules-of-
arbitration/† are frequently incorporated by reference in international contracts.
It is important that the Parties agree on the number of arbitrators and the language of
arbitration. In the absence of specific stipulations as to the number of arbitrators and the
place of arbitration in the Contract, the International Court of Arbitration of the ICC will decide
these matters.
If the arbitration rules published by the United Nations Commission on International Trade
Law (“UNCITRAL” which is based at the Vienna International Centre, A-1400 Vienna, Austria)
http:// www.uncitral.org/pdf/english/texts/arbitration/arb-rules-revised/arb-rules-revised-2010-e.
pdf† or other non-ICC arbitration rules are preferred, it may be necessary to designate, in
the Contract Data, an institution to appoint the arbitrators or to administer the arbitration,
unless the institution is named (and their role specified) in the arbitration rules. It may
also be necessary to ensure, before so designating an institution in the Contract Data,
that the institution is prepared to appoint or administer.
© FIDIC 2017
51
For major projects tendered internationally, it is desirable that the place of arbitration be
situated in a country other than that of the Employer or Contractor. This country should have a
CONDITIONS
GENERAL
modern and liberal arbitration law and should have ratified a bilateral or multilateral convention
(such as the 1958 New York Convention on the Recognition and Enforcement of Foreign
Arbitral Awards), or both, that would facilitate the enforcement of an arbitral award in the
states of the Parties.
It may be considered desirable in some cases for other Parties to be joined into any
GUIDANCE
arbitration between the Parties or for two or more pending arbitrations to be consolidated,
thereby creating a multi-party arbitration. While the ICC Arbitration Rules address multi-party
arbitration, such arbitration may in some cases be feasible only if the parties have
included multi-party arbitration clauses in their contracts. Such clauses require skilful
drafting, and usually need to be prepared on a case-by-case basis
It is not unusual that the arbitration of a complex dispute is concluded sometime after
performance of the Contractor’s obligations under the Contract has been completed, in which
FORMS
case it may not be fair and reasonable in the circumstances for any arbitral award which
requires the payment of an amount by one Party to the other Party to be in the currencies
of payment and in the proportions provided for under Sub-Clause 14.15 [Currencies of
Payment]. For example, the Contractor may no longer have any need for local currency after
completion of the Works; or the local currency may have declined in value in the interim or
be a ‘blocked currency’ that, consequently, cannot be removed from the country
concerned.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
CONDITIONS
is to Include Building Information Modelling Systems
GENERAL
Building Information Modelling (BIM), is a process which is changing many elements of
the design profession, the construction industry and, possibly, even the operation and
maintenance of a facility.
GUIDANCE
BIM is one of the digital data technologies used in all aspects of project planning,
investigation, design, construction and operation. Digital data technologies include
systems for: data acquisition; document management; design and process management;
estimating, planning, and scheduling; contract management; performance management; and
building information modelling.
BIM has varying degrees of complexity ranging from rather isolated use of computer
aided design tools to full sharing of models and information by the entire project team.
FORMS
Currently, BIM is more often used and better understood in developed countries, many of
which are encouraging or even mandating its use to improve quality, accuracy and
delivery times for projects as well as to provide cost savings. BIM has the potential to
dramatically improve productivity in the construction industry and reduce operational
costs of facilities as well.
where all parties have access to information relevant to their role in the design and
construction of a project. Wherever possible, a combined (sometimes called federated or
collaborative) model is developed for all parties to share, even if, as is often the case, various
designers have used different computer aided design programs to develop their respective
designs. Drawings and specifications are held in a common database accessible to
everyone. These can be used for clash detection, coordination of designs,
communication of changes, and construction sequencing.
Coordination of goals and effort is essential and is generally achieved by a BIM Protocol
and a BIM Execution Plan, both key documents to access and understand work in this
environment. A designer needs to understand and work to the Levels of Design (or
Detail) (LOD) that will be spelled out in these documents to ensure that there is sufficient
detail at each level to allow all designs to progress efficiently and avoid unnecessary
changes.
BIM is founded on a team approach and successful projects utilising BIM encourage
collaboration. FIDIC contracts are designed to be fair to all parties and are considered
suitable for use with projects featuring the use of BIM - providing that the parties recognise the
difference in approach and use the contract appropriately. This starts with proper planning
and, unless an employer has appropriate expertise in house, they are well advised to retain
an engineer who is appropriately qualified to assist them in the solicitation of interest,
proposals, selection and negotiation of contracts with the selected project team. Legal advice
is also necessary, of course, especially during the latter steps. The request for proposal
(RFP) must clearly outline what the client’s (employer’s) expectations of the consultant
are. The expectations should focus on the specific BIM goals and benefits desired. If
properly developed, the RFP will help the proposers be responsive and the employer select
the consultant (or in the case of a design build project, the project team) best qualified to
deliver the desired BIM outcome. This process will in turn help all parties develop appropriate
contract terms and conditions. Ideally the selection process would use FIDIC’s Quality
Based Selection (QBS) guideline.
It should be noted that the improved quality of information in projects utilising BIM can result
in a significant reduction in variations. It is worth thinking about how the traditional roles
of Contractor and Employer fit into this structure. In general, BIM is well suited for
integrated project delivery, including Design Build and especially Design Build Operate
projects where early proactive involvement of the design engineer, contractor and employer
are essential. If advanced levels of BIM are anticipated for the project, the possibility of
adding operation and maintenance elements of the constructed facility might be
considered.
© FIDIC 2017
53
For advanced levels of BIM where fully open sharing of information is required, a
qualified individual needs to be assigned the duty of managing the combined model. This
CONDITIONS
GENERAL
should be separate from the project manager’s role to ensure clear delineation of project
responsibilities. This may require special outsourcing, if such skills are not available from
the employer or engineer. Managing the BIM elements of a project may also involve risks that
are beyond the normal coverage of professional indemnity (PI) insurance policies. Specialist
advice should be sought from PI insurers if there is any doubt on coverage for this role.
The competence and responsibilities of this position need to be understood and should
GUIDANCE
include experience in data back-up and integrity, continuity planning and cyber security.
All parties involved in a project utilising BIM should take special care in checking their
assigned scope and contract to ensure that they are aware of their BIM related
responsibilities. The risks that FIDIC has identified in working in a BIM environment arise
from these key features:
FORMS
To manage these and other digital technology related risks, the consultant is encouraged
to clearly define adequately their proposed services, addressing such issues as:
• the systems and versions or releases they propose and the management processes
they will adopt
• access rights and limitations of the client, other consultants and contractors
• reliance other parties in the project may place on data in the digital environment
• limitations in terms of uptime and access and potential exclusion of liability for
downtime
• access to the current and previous issues of the combined model and to the
complete audit trail of changes to the model
At the completion of the project the model may need to be brought up to as-built status.
This involves not only the drawing elements but also the embedded data. Experience shows
that this is a significant effort, so responsibilities for completing this task should be clear
and appropriate allowances provided.
The process for the delivery of contractual notices should be checked to determine if this will
be through the common data environment or by more traditional means.
If sub-contractors are to be utilised, they should be bound by the BIM Protocol and Execution
Plan.
Legal counsel should review the contract to ensure that it does not create an unintended joint
venture which may be a risk in some jurisdictions.
CONDITIONS
GENERAL
Make sure that audit trails for modifications to the composite or federated model are
controlled by a process which can generate an audit trail that is preserved during and after
completion. The audit trail should be accessible by appropriate parties during and after
project completion. Given that there will be many parties involved in the design and
construction effort, ensure that there are appropriate limits of liability in place for each
participant and for the project as a whole.
GUIDANCE
For construction or building projects involving BIM, in addition to considering the general
principles as introduced above, the following (non-exhaustive) list of Sub-Clauses of the
General Conditions of Contract for Construction [ ©FIDIC 2017 Second Edition ] should
be thoroughly reviewed when drafting the Particular Conditions:
FORMS
1.1 Definitions
1.3 Notices and Other Communications
1.5 Priority of Documents
1.10 Employer’s Use of Contractor’s Documents
1.11 Contractor’s Use of Employer’s Documents
1.15 Limitation of Liability
2.3 Employer’s Personnel and Other Contractors
2.5 Site Data and Items of Reference
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
© FIDIC 2017
55
Annexes FORMS OF SECURITIES
CONDITIONS
GENERAL
Acceptable form(s) of security should be included in the tender documents: for Annex A and/or
B, in the Instructions to Tenderers; and for Annexes C to G, annexed to the Particular
Conditions. The following example forms, which (except for Annex A) incorporate Uniform Rules
published by the International Chamber of Commerce (the “ICC”, which is based at 33-43
GUIDANCE
Avenue du Président Wilson, 75116 Paris, France, www.iccwbo.org), need to be carefully reviewed
against, and may have to be amended to comply with, applicable law. Although the ICC publishes
guides to these Uniform Rules, legal advice should be taken before the securities are written.
Note that the guaranteed amounts should be quoted in all the currencies, as specified in the
Contract, in which the guarantor pays the beneficiary.
FORMS
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
CONDITIONS
COMPANY GUARANTEE
GENERAL
Name of Contract/Contract No.:
Name and address of Employer:
(together with successors and assigns).
GUIDANCE
We have been informed that (hereinafter called the
“Contractor”) is submitting an offer for such Contract in response to your invitation, and that the
conditions of your invitation require his/her offer to be supported by a parent company
guarantee.
In consideration of you, the Employer, awarding the Contract to the Contractor, we (name of
parent company) irrevocably and unconditionally guarantee to you, as a primary obligation, the
FORMS
due performance of all the Contractor’s obligations and liabilities under the Contract, including
the Contractor’s compliance with all its terms and conditions according to their true intent and
meaning.
If the Contractor fails to so perform his/her obligations and liabilities and comply with the
Contract, we will indemnify the Employer against and from all damages, losses and expenses
(including legal fees and expenses) which arise from any such failure for which the Contractor
is liable to the Employer under the Contract.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
This guarantee shall come into full force and effect when the Contract comes into full force and
effect. If the Contract does not come into full force and effect within a year of the date of this
guarantee, or if you demonstrate that you do not intend to enter into the Contract with the
Contractor, this guarantee shall be void and ineffective. This guarantee shall continue in full
force and effect until all the Contractor’s obligations and liabilities under the Contract have
been discharged, when this guarantee shall expire and shall be returned to us, and our liability
hereunder shall be discharged absolutely.
This guarantee shall apply and be supplemental to the Contract as amended or varied by the Employer
and the Contractor from time to time. We hereby authorise them to agree any such amendment
or variation, the due performance of which and compliance with which by the Contractor are
likewise guaranteed hereunder. Our obligations and liabilities under this guarantee shall not be
discharged by any allowance of time or other indulgence whatsoever by the Employer to the
Contractor, or by any variation or suspension of the works to be executed under the Contract, or by
any amendments to the Contract or to the constitution of the Contractor or the Employer, or by
any other matters, whether with or without our knowledge or consent.
This guarantee shall be governed by the law of the same country (or other jurisdiction) as that which
governs the Contract and any dispute under this guarantee shall be finally settled under the Rules
of Arbitration of the International Chamber of Commerce by one or more arbitrators appointed
in accordance with such Rules. We confirm that the benefit of this guarantee may be assigned
subject only to the provisions for assignment of the Contract.
(name) (name)
Whether one or more signatories for the parent company are required will depend on the parent
(1)
© FIDIC 2017
57
Annex B EXAMPLE FORM OF TENDER SECURITY
CONDITIONS
GENERAL
The Beneficiary (the “Employer”): [insert name and address of the Beneficiary]
We have been informed that [insert
name and address of the Tenderer] (hereinafter called the “Applicant”) is submitting an offer for such
Contract in response to your invitation, and that the conditions of your invitation (the “Conditions
of Invitation”, which are set out in a document entitled Instructions to Tenderers) require his/her offer
FORMS
(a) the Applicant has, without your agreement, withdrawn his/her offer after the latest
time specified for its submission and before the expiry of its period of validity, or
(b) the Applicant has refused to accept the correction of errors in his/her offer in
accordance with such Conditions of Invitation, or
(c) you awarded the Contract to the Applicant and he/she has failed to comply with
Sub-Clause 1.6 of the Conditions of Contract, or
(d) you awarded the Contract to the Applicant and he/she has failed to comply with
Sub-Clause 4.2.1 of the Conditions of Contract.
Any demand for payment must contain your signature(s) which must be authenticated by your
bankers or by a notary public. The authenticated demand and statement must be received by us
at the following office [insert address of office] on or before [insert
the date 35 days after the expiry of the validity of the Letter of Tender], when this guarantee shall
expire.
(name) (name)
Date:
Whether one or more signatories for the bank are required will depend on the bank and/or
(1)
applicable law.
CONDITIONS
- DEMAND GUARANTEE
GENERAL
Guarantee No.: [insert guarantee reference number]
The Guarantor:
[insert name and address of place of issue, unless indicated in the letterhead]
GUIDANCE
Name of Contract/Contract No.: [insert
reference number or other information identifying the contract between the Applicant and the
Beneficiary on which the guarantee is based]
FORMS
We have been informed that [insert
name and address of the Contractor] (hereinafter called the “Applicant”) is your Contractor
under such Contract, which requires him/her to obtain a Performance Security.
At the request of the Applicant, we [insert
name of Guarantor] hereby irrevocably undertake to pay you, the Beneficiary/Employer, any sum or
sums not exceeding in total the amount of [insert in figures and
words the maximum amount payable and the currency in which it is payable] (the “Guaranteed
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Amount”) upon receipt by us of your demand in writing and your written statement indicating in what
respect the Applicant is in breach of its obligations under the Contract.
[Following receipt by us of an authenticated copy of the Taking-Over Certificate for the whole of the
Works under clause 10 of the Conditions of Contract, the Guaranteed Amount shall be reduced by
% and we shall promptly notify you that we have received such certificate
and have reduced the Guaranteed Amount accordingly.] (1)
[insert name and address of the Engineer under the Contract] that, pursuant to Sub-Clause 4.2.1 of
the Conditions of Contract, variations or adjustments under Clause 13 of the Conditions of Contract
have resulted in an accumulative increase or decrease of the Contract Price by more than
twenty percent (20%) of the Accepted Contract Amount, and that therefore the Guaranteed Amount
should be adjusted by the percentage specified in the statement equal to the accumulative
increase or decrease, respectively, we shall promptly inform you that we have received such
statement and have adjusted the Guaranteed Amount accordingly. In the case of a request for
a decrease of the amount of the Performance Security, the above statement shall be
accompanied by your written consent to such decrease.
Any demand for payment must contain your signature(s) which must be authenticated by your
bankers or by a notary public. The authenticated demand and statement must be received by
us at the following office [insert address of office] on or before (insert the
date 70 days after the expected expiry of the Defects Notification Period for the Works) (the “Expiry
Date”), when this guarantee shall expire.
The party liable for the payment of any charges: [insert the name of the party].
This guarantee shall be governed by the laws of [insert the law
governing the guarantee], and shall be subject to the Uniform Rules for Demand Guarantees,
(URDG) 2010 Revision, ICC Publication No. 758.
© FIDIC 2017
59
SIGNED by: SIGNED by(2):
CONDITIONS
(signature) (signature)
GENERAL
(name) (name)
Date:
GUIDANCE
(1)
When drafting the tender documents, the writer should ascertain whether to include the
optional text, shown in parentheses [ ].
(2)
Whether one or more signatories for the bank are required will depend on the bank and/or
applicable law.
FORMS
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
CONDITIONS
- SURETY BOND
GENERAL
Name of Contract/Contract No.:
Name and address of Beneficiary (the “Employer”):
GUIDANCE
We have been informed that [insert
name of the Contractor] (hereinafter called the “Principal”) is your contractor under such
Contract, which requires him/her to obtain a Performance Security.
By this Bond,
[insert name and address of contractor]
FORMS
[insert
name and address of Guarantor] as Guarantor are irrevocably held and firmly bound to the
Beneficiary in the total amount of [insert in figures and words the maximum
amount payable and the currency in which it is payable] (the “Bond Amount”) for the due
performance of all such Principal’s obligations and liabilities under the above named Contract.
[Such Bond Amount shall be reduced by % upon the issue of the Taking-
Over Certificate for the whole of the Works under Clause 10 of the Conditions of Contract.](1)
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
This Bond shall become effective on the Commencement Date defined in the Contract.
Upon Default by the Principal to perform any contractual obligation, or upon the occurrence of
any of the events and circumstances listed in Sub-Clause 15.2.1 of the Conditions of Contract,
the Guarantor shall satisfy and discharge the damages sustained by the Beneficiary due to
such Default, event or circumstances.(2) However, the total liability of the Guarantor shall not
exceed the Bond Amount.
The obligations and liabilities of the Guarantor shall not be discharged by any allowance of time or
other indulgence whatsoever by the Beneficiary to the Principal, or by any variation or suspension
of the Works to be executed under the Contract, or by any amendments to the Contract or to
the constitution of the Principal or the Beneficiary, or by any other matters, whether with or
without the knowledge or consent of the Guarantor.
Any claim under this Bond must be received by the Guarantor on or before
[insert the date six months after the expected expiry of the Defects Notification Period for the Works]
(the “Expiry Date”), when this Bond shall expire and shall be returned to the Guarantor.
The benefit of this Bond may be assigned subject to the provisions for assignment of the Contract,
and subject to the receipt by the Guarantor of evidence of full compliance with such provisions.
This Bond shall be governed by the law of [insert the law
governing the bond] being the same country (or other jurisdiction) as that which governs the
Contract. This Bond incorporates and shall be subject to the Uniform Rules for Contract Bonds,
published as number 524 by the International Chamber of Commerce, and words used in this Bond
shall bear the meanings set out in such Rules.
Whereas this Bond has been issued by the Principal and the Guarantor on
(signature) (signature)
(name)
(name)
© FIDIC 2017
61
Signatures for and on behalf of the Guarantor(4):
CONDITIONS
GENERAL
(signature) (signature)
(name) (name)
GUIDANCE
When writing the tender documents, the writer should ascertain whether to include the
(1)
Insert: [and shall not be entitled to perform the Principal’s obligations under the Contract.]
(2)
Or: [or at the option of the Guarantor (to be exercised in writing within 42 days of receiving the claim
FORMS
specifying such Default) perform the Principal’s obligations under the Contract.]
Whether one or more signatories for the Principal are required will depend on the Principal and/or
(3)
applicable law.
Whether one or more signatories for the Guarantor are required will depend on the Guarantor and/
(4)
or applicable law.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
CONDITIONS
PAYMENT GUARANTEE
GENERAL
Guarantee No.: [insert guarantee reference number]
The Guarantor:
[insert name and address of place of issue,
GUIDANCE
unless indicated in the letterhead]
FORMS
[insert name and address of the Beneficiary]
irrevocably undertake to pay you, the Beneficiary/Employer, any sum or sums not exceeding in total
the amount of [insert in figures and words the maximum amount payable and the
currency in which it is payable] (the “Guaranteed Amount”) upon receipt by us of your demand
in writing and your written statement that:
(a) the Applicant has failed to repay the advance payment in accordance with the
Conditions of Contract, and
(b) the amount of the advance payment which the Applicant has failed to repay.
This guarantee shall become effective upon receipt [of the first instalment] of the advance payment
by the Applicant. The Guaranteed Amount shall be reduced by the amounts of the advance payment
repaid to you, as evidenced by interim payment certificates issued under Sub-Clause 14.6 of
the Conditions of Contract. Following receipt of a copy of each interim payment certificate, we
shall promptly notify you of the revised Guaranteed Amount accordingly.
Any demand for payment must contain your signature(s) which must be authenticated by your
bankers or by a notary public. The authenticated demand and statement must be received by
us at the following office [insert address of office] on or before [insert
the date 70 days after the expected expiry of the Time for Completion] (the “Expiry Date”),
when this guarantee shall expire.
The party liable for the payment of any charges: [insert the name of the party].
This guarantee shall be governed by the laws of [insert the law
governing the guarantee], and shall be subject to the Uniform Rules for Demand Guarantees
(URDG) 2010 Revision, ICC Publication No. 758.
(name) (name)
Date:
Whether one or more signatories for the bank are required will depend on the bank and/or
(1)
applicable law.
© FIDIC 2017
63
Annex F EXAMPLE FORM OF RETENTION
CONDITIONS
MONEY GUARANTEE
GENERAL
The party liable for the payment of any charges: [insert the name of the party].
This guarantee shall be governed by the laws of [insert the law
governing the guarantee] and shall be subject to the Uniform Rules for Demand Guarantees (URDG)
2010 Revision, ICC Publication No. 758.
(name) (name)
Date:
Whether one or more signatories for the bank are required will depend on the bank and/or
(1)
applicable law.
64 © FIDIC 2017 Conditions of Contract for Construction
Annex G EXAMPLE FORM OF PAYMENT GUARANTEE
CONDITIONS
BY EMPLOYER
GENERAL
Guarantee No.: [insert guarantee reference number]
The Guarantor:
[insert name and address of place of issue,
unless indicated in the letterhead]
GUIDANCE
Name of Contract/Contract No.:
[insert reference number or other information
identifying the contract between the Applicant and the Beneficiary on which the guarantee is based]
FORMS
We have been informed that
[insert name and address of the
Employer] (hereinafter called the “Applicant”) is required to obtain a bank guarantee.
the currency in which it is payable] upon receipt by us of your demand in writing and your
written statement that:
(a) in respect of a payment due under the Contract, the Applicant has failed to make
payment in full by the date fourteen days after the expiry of the period specified
in the Contract as that within which such payment should have been made, and
The party liable for the payment of any charges: [insert the name of the party].
This guarantee shall be governed by the laws of [insert the law governing
the guarantee] and shall be subject to the Uniform Rules for Demand Guarantees (URDG)
2010 Revision, ICC Publication No. 758.
(name) (name)
Date:
Whether one or more signatories for the bank are required will depend on the bank and/or
(1)
applicable law.
© FIDIC 2017
65
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
GENERAL CONDITIONS
CONDITIONS
GENERAL
NAME OF CONTRACT:
TO:
We have examined the Conditions of Contract, Specification, Drawings, Schedules including the Bill
of Quantities, the Contract Data and Addenda Nos for the above-named
GUIDANCE
Contract and the words and expressions used herein shall have the meanings assigned to them
in the Conditions of Contract. We offer to execute and complete the Works and remedy any
defects therein, in conformity with this Tender which includes all these documents, for the sum
of
FORMS
[currency and amount in words]
We agree to abide by this Tender until [date] and it shall remain binding upon
us and may be accepted at any time before that date.
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
If this offer is accepted, we will provide the specified Performance Security, commence the
Works as soon as is reasonably practicable after the Commencement Date, and complete the
Works in accordance with the above-named documents within the Time for Completion.
Unless and until a Contract Agreement is prepared and executed this Letter of Tender, together with
your written acceptance thereof, shall constitute a binding contract between us.
We understand that you are not bound to accept the lowest or any tender you may receive.
Address:
Date:
i
LETTER OF ACCEPTANCE •
CONDITIONS
GENERAL
NAME OF CONTRACT:
CONTRACT NUMBER:
TO:
GUIDANCE
Date:
Your Reference:
Our Reference:
FORMS
We have pleasure in accepting your Tender for the Accepted Contract Amount of:
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
In consideration of you properly and truly performing the Contract, we agree to pay you the
Accepted Contract Amount or such other sums to which you may become entitled under the
terms of the Contract, at such times and as prescribed by the Contract.
We acknowledge that this Letter of Acceptance creates a binding Contract between us, and
we undertake to fulfil all our obligations and duties in accordance with the terms of this
Contract.
Date:
•
Memoranda (if any) to be annexed [see Sub-Clause 1.1.51]
CONDITIONS
GENERAL
This Agreement made the day of
Between of (hereinafter called “the Employer”) of the one part,
and of (hereinafter called “the Contractor”) of the other part
GUIDANCE
by the Contractor for the execution and completion of these Works and the remedying of any
defects therein.
1. In this Agreement words and expressions shall have the same meanings as are respectively
assigned to them in the Conditions of Contract hereinafter referred to.
FORMS
2. The following documents shall be deemed to form and be read and construed as part of
this Agreement:
(a) The Letter of Acceptance dated
(b) The Letter of Tender dated
(c) The Addenda Nos
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
4. The Employer hereby covenants to pay the Contractor, in consideration of the execution and
completion of the Works and the remedying of defects therein, the Contract Price at the times
and in the manner prescribed by the Contract.
In Witness whereof the parties hereto have caused this Agreement to be executed the day and year
first before written in accordance with their respective laws.
SIGNED by:
SIGNED by:
for and on behalf of the Employer in the
for and on behalf of the Contractor in
presence of
the presence of
Witness:
Witness:
Name:
Name:
Address:
Address:
Date:
Date:
iii
DISPUTE AVOIDANCE/ADJUDICATION AGREEMENT
CONDITIONS
GENERAL
[All italicised text and any text within square brackets (except sub-clause headings) in this form of
agreement is for use in preparing the form and should be deleted from the final product].
and
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
Whereas:
A. the Employer and the Contractor have entered (or intend to enter) into the Contract;
B. under the Contract, the “DAAB” or “Dispute Avoidance/Adjudication Board” means the
sole member or three members (as stated in the Contract Data of the Contract) so named
in the Contract, or appointed under Sub-Clause 21.1 [Constitution of the DAAB] or Sub-
Clause
21.2 [Failure to Appoint DAAB Members] of the Conditions of Contract;
C. the Employer and the Contractor desire jointly to appoint the above-named DAAB Member to
act on the DAAB as:
(a) the sole member of the DAAB, and where this is the case, all references to the
“Other Members” do not apply; or
(b) one of three members/chairman [delete the one which is not applicable] of the
DAAB and, where this is the case, the other two persons are:
(name) (name)
(address) (address)
(telephone) (telephone)
(email/ (email/
other contact details) other contact details)
CONDITIONS
GENERAL
1. The conditions of this DAA Agreement comprise:
(a) Clause 21 [Disputes and Arbitration] of the Conditions of Contract, and any other
provisions of the Contract that are applicable to the DAAB’s Activities; and
(b) the “General Conditions of Dispute Avoidance/Adjudication Agreement”, which is
appended to the General Conditions of the “Conditions of Contract for
GUIDANCE
Construction” Second Edition 2017 published by FIDIC (“GCs”), as amended and/or
added to by the following provisions.
3. The DAAB Member shall be paid in accordance with Clause 9 of the GCs. The currency
FORMS
of payment shall be .
In respect of Sub-Clauses 9.1 and 9.2 of the GCs, the amounts of the DAAB Member’s
monthly fee and daily fee shall be:
monthly fee per month,
and daily fee of per day
(or as otherwise set under Sub-Clause 9.3 of the GCs).
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org
4. In consideration of the above fees, and other payments to be made to the DAAB
Member in accordance with the GCs, the DAAB Member undertakes to act as DAAB
Member in accordance with the terms of this DAA Agreement.
5. The Employer and the Contractor shall be jointly and severally liable for the DAAB Member’s
fees and other payments to be made to the DAAB Member in accordance with the GCs.
6. This DAA Agreement shall be governed by the law of (if not stated, the
law that governs the Contract under Sub-Clause 1.4 of the Conditions of Contract).
SIGNED by:
SIGNED by: SIGNED by:
Print name:
Print name: the DAAB Member
Title:
Title: Title:
for and on behalf of
for and on behalf of
the Employer
the Contractor
in the presence of in the presence of in the presence of
Witness: Witness: Witness:
Name: Name: Name:
Address: Address: Address:
Date:
Date: Date:
v
This document is restricted for distribution within the Lexis Nexis platform - NOT FOR CONTRACT USE AND NOT PRINTABLE - ORIGINAL FOR SALE AT www.fidic.org