Michael D. Robinson - Guide To The FIDIC Conditions of Contract For Construction - The Red Book 2017-Wiley-Blackwell (2023)
Michael D. Robinson - Guide To The FIDIC Conditions of Contract For Construction - The Red Book 2017-Wiley-Blackwell (2023)
Construction
Michael D. Robinson
This edition first published 2023
© 2023 John Wiley & Sons Ltd
All rights reserved. No part of this publication may be reproduced, stored in a retrieval system, or transmit-
ted, in any form or by any means, electronic, mechanical, photocopying, recording or otherwise, except as
permitted by law. Advice on how to obtain permission to reuse material from this title is available at http://
www.wiley.com/go/ permissions.
The right of Michael D. Robinson to be identified as the author of this work has been asserted in accordance
with law.
Registered Office
John Wiley & Sons Ltd, The Atrium, Southern Gate, Chichester, West Sussex, PO19 8SQ, UK
Editorial Office
9600 Garsington Road, Oxford, OX4 2DQ, UK
For details of our global editorial offices, customer services, and more information about Wiley products
visit us at www.wiley.com.
Wiley also publishes its books in a variety of electronic formats and by print‐on‐demand. Some content that
appears in standard print versions of this book may not be available in other formats.
Trademarks: Wiley and the Wiley logo are trademarks or registered trademarks of John Wiley & Sons, Inc.
and/or its affiliates in the United States and other countries and may not be used without written permis-
sion. All other trademarks are the property of their respective owners. John Wiley & Sons, Inc. is not associ-
ated with any product or vendor mentioned in this book.
Brief Contents
Preface xv
Acknowledgements xix
5 Clause 5 Subcontracting 45
Contents
Preface xv
Acknowledgements xix
1.1.65 Plant 5
1.1.66 Programme 5
1.1.68 QM System 5
1.1.70 Review 5
1.1.71 Schedules 5
1.1.75 Special Provisions 5
1.1.77 Statement 6
1.1.78 Subcontractor 6
1.1.81 Tender 6
1.1.82 Tests After Completion 6
1.1.85 Unforeseeable 6
1.2 Interpretation 6
1.3 Notices and Other Communications 6
1.4 Law and Language 7
1.5 Priority of Documents 8
1.6 Contract Agreement 8
1.7 Assignment 9
1.8 Care and Supply of Documents 9
1.9 Delayed Drawings or Instructions 9
1.10 Employer’s Use of Contractor’s Documents 11
1.11 Contractor’s Use of Employer’s Documents 11
1.12 Confidentiality 11
1.13 Compliance with Laws 12
1.14 Joint and Several Liability 12
1.15 Limitation of Liability 13
1.16 Contract Termination 13
5 Clause 5 Subcontracting 45
5.1 Subcontractors 45
5.2 Nominated Subcontractors 46
5.2.1 Definition of a ‘Nominated Subcontractor’ 46
x Contents
9.3 e-testing 70
R
9.4 Failure to Pass Tests on Completion 70
Preface
The Conditions of Contract prepared by FIDIC are well established as the standard form of
choice for use in the international construction industry.
Traditionally, in the standard FIDIC forms, the Engineer was given an authoritative role,
enabling him to make informed judgements concerning the conduct and execution of pro-
jects with a large measure of independence from the Employer. From time to time, FIDIC
updated these forms culminating in the 4th Edition 1987 (last reprinted 1992).
However, over the past 30–40 years, Employers became increasingly more involved in the
day‐by‐day administration of projects, thereby restricting the powers of the Engineer to act
independently of the parties.
In the same period, there was a significant increase in the availability of international
funding, particularly for infrastructure projects. As a consequence, more and more compa-
nies undertook construction projects outside their national borders. However, many con-
tractors were not always familiar with operating requirements of an FIDIC‐based contract.
Equally, Employers, well used to their national systems of contracting practices and law,
faced with having to deal with contracts based on unfamiliar forms.
A key feature of the dispute resolution procedure contained in the FIDIC 4th Edition
1987, Sub‐Clause 67.1 (Engineer’s Decision) was the power and authority of the Engineer
to make independent judgements. As the independence of the Engineer diminished fol-
lowing the increasing direct involvement of the Employer, the value of Engineer’s decision
was increasingly challenged by the contractors; as a result, more and more disputes were
referred to arbitration.
Few in the construction industry regard arbitration as a satisfactory means of resolving
disputes. Arbitration is a lengthy and expensive process that may or may not lead to awards.
With a more flexible, realistic approach, the disputes could be negotiated more quickly and
at a lower cost. A contractor also suffers because he is unable to foresee the outcome of the
arbitration, and his cash flow is uncertain and damaged as a consequence of lengthy arbi-
tration. Regrettably, there are instances of Employers preferring to refer some disputes to
arbitration to avoid having to make decisions that they are unwilling to make themselves
because of political or economic reasons.
Against this background, FIDIC undertook a major review of their standard forms.
xvi Preface
Following extensive consultations with other parties engaged in the field of international
construction, FIDIC issued, in 1999, a suite of four different contract forms:
CONS – Conditions of Contract for Construction (hereinafter referred to as ‘The Red Book
First Edition 1999’), which FIDIC recommends for use in building and engineering works
designed by the Employer or his representative, the Engineer.
P & DB – Conditions of Contract for Plant and Design‐Build (‘The Yellow Book’), which
FIDIC recommends for the provision of electrical and/or mechanical plant and for the
design and execution of building or engineering works to be designed by the Contractor in
accordance with the Employer’s requirements.
EPCT – Conditions of Contract for EPC/Turnkey Projects (‘The Silver Book’), which FIDIC
recommends for the provision of a process or power plant on a turnkey project.
‘Short Form of Contract’ (‘The Green Book’) – A fourth contract form that intended for
use in contracts involving small or repetitive work was also issued.
Subsequently, FIDIC has published other Conditions of Contract for specialist types of
activity. The full listing of all other available contract forms is available on the FIDIC web-
site, and these are not considered further in this book. Further, no consideration is given in
this book to the second editions of the Yellow Book or Silver Book, which were also issued
in 2017.
In the 18 years that have elapsed since the publication of the First Edition 1999, inevitably,
the substantial experience gained has shown that a further revision of this contract form
was required.
In the Notes to this Second Edition 2017, FIDIC states that
Acknowledgements
The author is grateful to the Fédération Internationale des Ingénieurs Conseil (FIDIC) for
permission to quote extracts from the Conditions of Contract for Construction, ‘The Red
Book’ Second Edition 2017. Quoted extracts from this publication are given in italics.
Throughout this book, ‘The FIDIC Conditions of Contract for Construction’ (‘The Red
Book’), First Edition 1999, is referred to as the ‘First Edition’
and
‘The FIDIC Conditions of Contract for Construction’ (‘The Red Book’), Second Edition
2017, is referred to as the ‘Second Edition’.
In this book, the Employer, the Engineer, the Contractor, and subcontractors are referred
to in the masculine gender for simplicity and uniformity. The author wishes to emphasise
that the book is intended to address ALL GENDERS on an equal basis as their male
colleagues.
1
1.1 Definitions
Of the 58 definitions included in the First Edition, 34 have been included unchanged in the
Second Edition and a further 18 included with minor changes only. Just one item, Sub‐
Paragraph 1.1.6.4 (Force Majeure), included in the First Edition, has been deleted from its
original position and is now included in Clause 18 of the Second Edition under the revised
heading ‘Exceptional Events’.
There are 37 new or revised definitions included in the Second Edition and are
listed below:
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
2 1 Clause 1 General Provisions
1.1.22 DAAB
‘Dispute Avoidance/Adjudication Board’ (DAAB) replaces the “Dispute Adjudication
Board” described in the First Edition, as it more accurately defines the purpose of the
Board as stated elsewhere in Clause 21 of the Second Edition.
1.1.29 Disputes
This is a new definition not included in the First Edition. It is a very important topic and is
to be referenced to Clause 21.
1.1.49 Laws
This is a new definition added to reflect the changed heading of Sub‐Clause 13.6
(Adjustment for Changes in Laws).
1.1.54 Month
This is a new definition. ‘Month’ is a word used occasionally in the Conditions of Contract.
1.1.55 No objection
This is a new definition and is a wording occasionally used in the Conditions of Contract.
1.1.56 Notice
This is a new definition. When read in conjunction with Sub‐Clause 1.3 (Notices and
Communications), this definition will have an important impact on the day‐to‐day man-
agement of the project. More than 100 instances where a Notice is required to be issued are
identified in Appendix D of this book.
1.1.65 Plant
The wording of this definition has been slightly enlarged in the Second Edition. The defini-
tion refers to ‘apparatus, equipment, machinery etc.’, intended to form part or forming part
of the permanent works.
1.1.66 Programme
This is a new definition. Although Sub‐Clause 8.3 of the First Edition described the
Contractor’s general obligations in respect of programming, no specific definition of the
word “Programme” was provided. A much‐enlarged Sub‐Clause 8.3 (Programme) is
included in this Second Edition.
1.1.68 QM System
This is a new definition. The First Edition Sub‐Clause 4.9, headed ‘Quality Assurance’,
contained only a brief description of the Contractor’s obligations. In this Second Edition,
Sub‐Clause 4.9, headed ‘Quality Management and Compliance Verification Systems’, con-
tains a much more detailed description of the required QM system.
1.1.70 Review
This is a new definition. The word ‘review’ was variously used in the First Edition. However,
a clear definition was not provided.
1.1.71 Schedules
The wording of this definition has been slightly amended.
1.1.77 Statement
This sub‐clause has been expanded to make it clear that in addition to Statements for
Applications for Interim Payments, the Contractor shall also provide Statements at
Completion (Sub‐Clause 14.10) and Statement at Final Completion (Sub‐Clause 14.11).
1.1.78 Subcontractor
The term ‘Subcontractor’ is extended to include any designer appointed by the
Contractor.
Note: Nominated Subcontractors are defined in Sub‐Clause 5.2.1.
1.1.81 Tender
The definition contained in the First Edition has been extended to include:
●● The Contractor’s proposal
●● The JV Undertaking (if applicable)
1.1.85 Unforeseeable
The wording in the First Edition ‘. . .. by the date for submission of the Tender’ is amended to
‘. . . by the Base Date’. Base Date is defined in Sub‐Paragraph 1.1.4.
1.2 Interpretation
This sub‐clause contains legal statements confirming (except where the context requires
otherwise):
(a) words indicating one gender – includes all genders
(b) words indicating the singular also include the plural and vice versa
(c) “Agreements” have to be recorded in writing
(d) where something is stated to be written or in writing, this shall result in a permanent
record
Two additional sub‐clauses have been added in the Second Edition:
(e) ‘may’ means that the Party or person has a choice of whether to act or not
(f) ‘shall’ indicates an obligation to perform.
In the First Edition, this Sub‐Clause was headed ‘Communications’. In this Second Edition,
the sub‐clause has been significantly expanded and its application requires a much greater
degree of formality between the Parties.
1.4 Law and Languag 7
The opening paragraph contains an extensive listing of all potential types of communica-
tion and content which could arise during the course of executing a contract. Most items in
the listing relate to routine matters arising during the performance of the contract and will
be familiar to those directly engaged in its execution.
However, this Second Edition now introduces two related new items which require spe-
cial attention, namely ‘Notice’ (refer Sub‐Paragraph 1.1.56) and ‘Notice of Dissatisfaction’
(refer Sub‐Paragraph 1.1.57).
A Notice is a written communication identified as a Notice which is sent by one Party to
another.
Examples of Notices are:
The management of ‘Notices and Other Communications’ is a burden on site staff and
will require careful handling, especially if time related issues are involved. This subject is
discussed further in Appendix D of this book.
The law governing the Contract shall be that of the country where the Contract is to be
executed.
The wording of the First Edition has been upgraded. Both the ruling language and the
language for communications are intended to be stated in the Contract Data. If not stated,
then the language of these Conditions of Contract shall be the ruling language and the
language for communications shall be the ruling language.
Should the stated governing law be not that of the country where the contract is exe-
cuted, it may happen that the local courts may claim jurisdiction regardless of the wording
of the Contract. Legal advice should be sought if such a situation arises.
8 1 Clause 1 General Provisions
Engineer or Contractor to give Notice of any discrepancy which may lead to Notice of
Claim by Contractor.
The listing provided in the First Edition has been extended in the Second Edition as
follows:
(a) the Contract Agreement }
(b) the Letter of Acceptance } unchanged in the Second Edition
(c) the Letter of Tender }
(d) The Particular Conditions item (d) of the First Edition has been amended. The First
Edition Sub‐Paragraph 1.1.1.9 describes a document titled ‘Appendix to Tender’, which
is a listing of additional information pertinent to the Tender (and to be included in the
signed Contract), and which are to be provided by the Employer.
In this Second Edition, this document is now re‐titled ‘Particular Conditions
Part A – Contract Data’.
(e) The previous format of the Particular Conditions in the First Edition is retained and
re‐titled ‘Particular Conditions Part B – Special Provisions’.
(f) the General Conditions }
(g) the Specifications } Re‐numbered but otherwise unchanged
(h) the Drawings }
(i) The Schedules }
(j) the JV Undertaking (if the Contractor is a JV) – New item (refer to Appendix G of
this book)
(k) any other documents forming part of the contract – unchanged
‘If a Party finds an ambiguity or discrepancy on the documents, that Party shall promptly
give a Notice to the Engineer, describing the ambiguity or discrepancy’.
1.6 Contract Agreement
This Second Edition follows the same procedures given in the First Edition. The
Employer is required to provide the Contractor with a Letter of Acceptance, which
the Contractor should acknowledge in writing with the date of receipt duly noted. From
the date of receipt of the Letter of Acceptance by the Contractor, a binding contract
exists between the Parties. Within 35 days (was 28 days in the First Edition) after receipt
of the Letter of Acceptance by the Contractor, the Parties shall sign a Contract Agreement
based on the standard form annexed to the Particular Conditions of Contract.
It is preferable that the full contract documentation, including the Contract Agreement
and those documents described in Sub‐Clause 1.5, are all brought together in one compre-
hensive bound document. The various annexures need only be initialled by the
signatories.
The signatories of both the Employer and the Contractor will have to be legally authorised
to do so by their respective Board of Directors (or equal).
1.9 Delayed Drawings or Instruction 9
1.7 Assignment
The wording of this sub‐clause in the Second Edition is broadly similar to the provisions
stated in the First Edition.
Concerning the supply of drawings there are two possible scenarios:
1. The Employer will have appointed an Engineer responsible for both the design and
supervision of the construction of the Works.
10 1 Clause 1 General Provisions
Although the Contractor retains the copyright and other intellectual property rights in the
Contractor’s Documents, the Employer has a free licence to use this information for the
operation and maintenance of the relevant portion of the Works.
Item (c) refers to electronic or digital files, computer programmes, and other software
which may be used at the on‐site locations of the Employer and the Engineer.
Item (d) is a new item which describes the Employer’s use of Contractor’s Documents
in the event of Termination for Contractor’s Default (Sub‐Clause 15.2) and Termination
for Employer’s Convenience (Sub‐Clause 16.2) or Optional Termination (Sub‐Clause 18.5).
In the First Edition there was a reference to ‘. . . replacements of any computers supplied
by the Contractor’, which obligation has been deleted from this Second Edition.
As in the First Edition, the Contractor is entitled to use Employer’s Documents solely for
the purpose of executing the Contract and for no other purpose without the written permis-
sion of the Employer.
1.12 Confidentiality
The corresponding sub‐clause of the First Edition was titled ‘Confidential Details’ and con-
sisted of one sentence.
In the Second Edition, this sub‐clause has been considerably enlarged and re‐titled
‘Confidentiality’, reflecting a more detailed, broader scope of the obligations of the Parties.
1st Paragraph
As in the First Edition, the Contractor is required to disclose all information (confiden-
tial or otherwise) to the Engineer, which is necessary to ensure Contractor’s compliance.
2nd Paragraph
The Contract Documents may be used only for the execution of the Works. The
Contractor is prohibited from publishing or disclosing ‘any particulars of the Contract’.
The Contractor, including his head office, is advised not to give press or media inter-
views, but refer such issues to the Employer.
3rd Paragraph
Any information provided by the Contractor to the Employer and/or the Engineer and
which is marked “Confidential” shall not be disclosed to third parties.
4th Paragraph
The above obligations do not apply if the confidential information is already in the pub-
lic domain or readily available from other sources.
12 1 Clause 1 General Provisions
The Parties have a general obligation to comply with ‘all applicable laws’.
(a) The Employer is required to obtain planning permits, zoning regulations, and similar
regulations required for the execution of the Permanent Works together with any other
permits etc. which are identified in the Specification. The Contractor has a general
obligation to assist the Employer to obtain the required permits and other documenta-
tion including that which is identified in the Specification. The Contractor is required
to comply with the permits etc. obtained by the Employer.
(b) The Contractor shall give all notices, pay all taxes, duties and fees required by Law in
relation to the execution of the Works and shall indemnify the Employer in respect of
a failure by the Contractor to comply with these requirements.
In preparing his tender, the Contractor should examine the Site in sufficient detail
in order to determine if additional land is required for the siting of crushers, concrete
plants, accommodation for personnel, etc., all of which may be subject to local plan-
ning regulations. The acquisition of land for quarrying purposes, borrow areas and
waste areas which may be located at a distance from the Site, will also require the
Contractor to obtain the appropriate permissions, licenses, etc. from the local
authorities.
Royalties may be payable in respect of any excavated materials. This potential addi-
tional tax may be significant. The legal requirements are to be clarified and the Cost
included in the Tender price. Sub‐Clause 2.2 (Assistance), sub‐paragraph b(i) states
that ‘If requested by the Contractor, the Employer shall promptly provide reasonable assis-
tance to the Contractor to enable him to obtain permissions, licences etc’.
‘Should the Contractor suffer delay and/or incurs Cost as a result of the Employer’s
delay or failure to obtain any permit, permission etc. (see paragraph (a) above), the
Contractor shall be entitled, subject to Sub‐Clause 20.2, to EOT and/or payment of such
Cost plus Profit’.
‘If the Employer incurs additional costs as a result of the Contractor’s failure to comply
with any of his obligations given above, then the Employer shall be entitled, subject to
Sub‐Clause 20.2, to payment of these costs by the Contractor’.
In a conventional JV, each of the JV members will provide a share of resources includ-
ing Contractor’s Equipment and senior staff to a pre‐agreed plan. The Contractor’s
Representative (Sub‐Paragraph 1.1.18) will almost certainly be provided by the lead com-
pany of the JV. The site organisation of administration, workshops, stores, technical sup-
port, and field crews will be a blend of the resources of the JV members. Exceptionally, it
may happen that one member of the JV is to be engaged in a specialist activity. In the
event of that specialist becoming bankrupt or otherwise unable to continue with the allot-
ted work, then the JV would need to obtain consent of the Employer for the engagement
of a replacement specialist company. To avoid such a possibility occurring, it is probably
more manageable if the specialist were to be engaged as a subcontractor to the JV.
Should a member of the JV become bankrupt or otherwise unable to continue, the
remaining members of the JV are obliged to share the share portion of the failed mem-
ber between them. The share portion of the failed member is conventionally reduced to
a nominal 0.01% of the total. This share portion becomes extinct only when the JV is
wound up after completion of all activities, including settlement of all matters between
the members of the JV.
Finally, if a grouping of contractors intends to tender for a project with the intention
of independently constructing the total project in distinctly separate parts, this would
constitute a Consortium and not a JV, requiring a different form of documentation.
1.16 Contract Termination
This is a legal statement. Subject to the requirements of the governing law, a termination of
the Contract requires no other action than that given in the relevant sub‐clause(s) of these
Conditions of Contract.
Further details concerning Termination by Employer are provided in Clause 15
(Termination by the Employer) and details of Suspension and Termination by Contractor
are provided in Clause 16 (Suspension and Termination by the Contractor). Optional
Termination is the subject of Sub‐Clause 18 (Optional Termination).
15
This sub‐clause refers not only to the Contractor’s right of access to the Site but also his
right to take possession of the Site.
The Employer may delay the hand‐over of Site until the Contractor provides the
Performance Security described in Sub‐Clause 4.2. For larger projects, constructed by more
experienced contractors, it is likely that one document accompanying the Tender will be a
statement from a major insurance provider confirming that they will be providing the con-
tract Performance Security, should their contractor client be awarded the project. The
Employer will have less confidence in smaller contractors who may struggle to obtain the
required Performance Security in the open market.
Understandably, the Employer may be reluctant to allow any contractor commence work
without the necessary Performance Security (and insurances) in place.
The relevant date(s) for the Contractor taking possession of the Site is (are) to be pro-
vided in the Contract Data. If no date(s) are given in the Contract Data, then the
Employer shall provide access to and possession of the Site in accordance with the pre-
liminary programme of works submitted with the Contractor’s tender. Attention is
drawn to the wording of Sub‐Clause 8.1, wherein it is stated that the Contractor shall
commence the Works within 42 days after the Contractor receives the Letter of
Acceptance. Thereafter, any delay in the provision of access to the Site or possession of
the Site would entitle the Contractor to claim both time and costs by reference to this
clause of the contract.
The handover of the Site is a significant event and should be properly managed by the
Employer. It is the duty of the Employer to hand over the Site and not the Engineer’s.
The Contractor should inspect the Site carefully and investigate any potential obstruc-
tions which have arisen after the date of any formal Site visit made prior to the date of the
tender. Removal of these obstructions is not the Contractor’s responsibility. Typically, an
empty, unsecured site is a magnet for third parties who might use the site as an illegal
dump site. Obstructions to a full site hand‐over may arise as private properties may not
have been purchased by the Employer and/or not yet vacated.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
16 2 Clause 2 The Employer
A formal signed protocol should be drawn up, identifying the time and date of the hand‐
over, with a statement of the condition of the Site. This protocol should be signed by
authorised representatives of the Employer and the Contractor. For partial handovers, tak-
ing place on different dates, a separate protocol is required for each hand‐over. Frequently,
the Contractor may agree to accept the Site even though there exist obstructions which are
the responsibility of the Employer. A common cause of obstruction arises from the lack of
or incomplete land acquisition.
It is not always in the interest of the Contractor to commence work in a fragmented, inef-
ficient manner. In severe cases, it may be appropriate for the Contractor to decline an
incomplete hand‐over.
In addition to handing over the Site, the Employer is also required to grant the Contractor
the right of access to the Site. This subject is examined later under the heading of Sub‐
Clause 4.15 (Access Route).
2.2 Assistance
This sub‐clause was titled ‘Permits, Licences or Approvals’ in the First Edition.
Frequently the assistance of the Employer is required to enable the Contractor to
obtain the various permits, licences, and approvals necessary for the performance of the
Contract.
The nature of the required permits, licences, and approvals will vary from country to
country and from project to project and could include building permits, trade licences,
licences for quarry operations, approvals from utility companies. These requirements
should be researched using local knowledge and their potential value and impact on the
timely performance of the Works evaluated in the preparation of the Tender.
It may be appropriate for the Contractor to raise any concerns during pre‐tender meet-
ings, so that the commitment of the Employer to assist in resolving problems is well estab-
lished. Typical problems that frequently occur include:
●● In many countries with a centralised planning, the supply of basic materials (cement,
bitumen, fuels) may be strictly controlled and bulk supplies only available with the sup-
port of the Employer. Even then the authorities are often unwilling to pre‐advise of any
supply bottlenecks, which can be extremely frustrating.
●● Most internationally financed projects are stated to be free of local taxes. Of particular
interest are customs duties and value added tax (VAT). Often these arrangements cause
problems between state ministries (e.g. the Treasury Ministry controlling the collection of
taxes and revenues) and the Employer. Important supplies and equipment can be held up
in part because the Treasury Department has failed to issue internal authorisation for duty‐
free imports. The Contractor (unless required by law) should not pay temporary deposits
unless the Employer acknowledges liability to arrange for a refund. It is often very difficult
to obtain refunds from the Treasury Departments. Again, during any pre‐tender meeting
the Employer could be asked to confirm that the appropriate arrangements are in hand. An
unforeseen need to pay customs duties even on a temporary basis can affect the Contractor’s
cash‐flow which can be damaging in the early stages of the Contract.
2.5 Site Data and Items of Referenc 17
In many countries, utility companies may be tardy in dealing with Contractor’s request
for the provision of or relocation of services, possibly because of lack of materials or skilled
workers. As a consequence, it would be expedient for the Contractor to assist in the resolu-
tion of these matters at the request of the Employer.
Sub‐clause 2.4 of the First Edition gave the Contractor the right to request the Employer to
explain how payment for executing the Works was to be financed.
The revised and expanded sub‐clause of the Second Edition confirms the Contractor
rights given in the First Edition and additionally provides three specific examples of events
which would entitle the Contractor to seek clarification.
If the Contractor:
(a) receives an instruction to execute a Variation with a price exceeding 10% of the
Accepted Contract Amount, or the accumulated total of variations exceeds 30% of the
Accepted Contract Amount
(b) does not receive payment in accordance with Sub‐Clause 14.7 (Payment)
(c) becomes aware of a material change in the Employer’s financial arrangements of
which the Contractor has not received a Notice referencing this sub‐clause,
then the Contractor may request the Employer to provide ‘reasonable evidence’ that appro-
priate financial arrangements have been made. The Employer has 28 days to respond to the
Contractor’s request. Given the sensitivity of this subject, it would be appropriate if the
Contractor were to discuss this issue with the Employer before making any written request.
In the First Edition, the provision of Site Data by the Employer was described in Sub‐
Clause 4.10. The Employer had a duty to make available to the Contractor all relevant data
in the Employer’s possession prior to the Base Date. The Employer was further required to
make available to the Contractor additional data coming into the Employer’s possession
after the Base Date.
18 2 Clause 2 The Employer
The Contractor was deemed to have inspected the Site and having taken the Employer’s
Data into account. The above requirements were supplemented by a listing of ‘relevant
matters’ to be assessed by the Contractor in preparation of his tender.
In the Second Edition, the equivalent clause is re‐numbered and retitled as Sub‐Clause
2.5 (Site Data and Items of Reference). The Employer’s obligations have not been changed
excepting that reference is also made to the ‘original survey points, lines and levels of refer-
ence’ to be specified on the Drawings or supplied by a Notice from the Engineer.
The Employer is obliged to provide the Contractor with any additional data coming into
his possession after Base Date.
Should the data provided by the Employer prove to be incorrect or incomplete, the
Contractor would have grounds to claim any additional costs incurred and EOT in accord-
ance with Sub‐Clause 20.2. The list of topics given in the First Edition, now deleted, would
provide useful guidance to the Contractor.
The Contractor’s tender is based on the information available to him at the Base Date
(28 days before the date of submittal of tenders). Tenderers may not be able to make allow-
ance for any or all additional data supplied after Base Date. The possibility of a ‘conditional’
tender may arise in extreme circumstances.
This sub‐clause replaces the more explicit Sub‐Clause 4.20 of the First Edition. The unit
rates for the use of the Employer’s Equipment will either be stated elsewhere in the
Contract Documents or separately negotiated between Employer and the Contractor. Any
insurance requirements will need clarification.
In the First Edition, the Employer‐supplied materials were to be visually inspected on
delivery for any shortages, default, or defect in the materials. Deficiencies were to be
reported to the Engineer. The Employer would then immediately rectify the shortages,
default, or defect. This procedure is not specifically stated in this Sub‐Clause 2.6.
19
3.1 The Engineer
This sub‐clause confirms the fundamental obligation of the Employer to appoint the
Engineer to carry out the duties assigned to him. The Engineer may be a named person or
may be a company. Should a company be named as the Engineer, then the company must
advise the name of the person who will specifically be allocated the duties of the Engineer.
It may be assumed that the Employer has already appointed the individual or company
identified as the Engineer before tenders are submitted.
For larger contracts, the Engineer may be named in the Tender Documents which allows
the Contractor the opportunity to assess any perceived risk arising from this appointment.
Less satisfactory is the appointment of the Engineer in the post‐tender period. The problem
of a late appointment of the Engineer is exacerbated if the Engineer appointed for execu-
tion of the design is a different Engineer appointed for the supervision of the construction
as valuable background information may be lost.
This separation of design and supervision, particularly for smaller projects, can lead to
unsatisfactory situations.
This sub‐clause has been significantly changed from the equivalent sub‐clause of the First
Edition.
The First Edition stated in part ‘If the Engineer is required to obtain the approval of the
Employer before exercising a specific authority, the requirements shall be as stated in the
Particular Conditions’. Thus, the Employer was free to include restrictions in the Particular
Conditions which prevented the Engineer from authorising any additional works (varia-
tions) or accepting Contract claims requiring additional payments to the Contractor.
The Second Edition strongly reinforces the authority of the Engineer.
Sub‐Clause 3.2 states in part:
Third paragraph: ‘If the Engineer is required to obtain the consent of the Employer before
exercising a specified authority, it shall be stated in the Particular Conditions’.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
20 3 Clause 3 The Engineer
and
‘There will be no requirement for the Engineer to obtain the Employer’s consent before the
Engineer exercises his/her authority under Sub‐Clause 3.7 (Agreement or Determination)’.
Sub‐Clause 3.7, among other issues, gives the Engineer the opportunity to make a fair
determination of (any) matter or claim without the authority of the Employer.
Clause 3 of the ‘Notes on the Preparation of Special Provisions’ (Page 20) states that any
instructions requiring the Engineer to first obtain the Employer’s consent shall be clearly
shown in the Special Provisions.
However, the above requirement is tempered by the final sentence of this sub‐clause: ‘It
should be noted that any such requirement should not be applied to any action by the Engineer
under Sub‐clause 3.7, Agreement or Determination. . .’.
Therefore, it is important that the Contractor’s tender office carefully studies Clause 3 of
the Particular Conditions of Contract.
The Engineer may from time to time assign duties and delegate authority to assistants (and
may revoke such authority) by giving Notice to the Parties (i.e. Employer and Contractor).
It will be noted that there is no specific provision for the Engineer’s Representative to del-
egate any of the duties and delegated authority assigned to him by the Engineer to these
assistants.
The Engineer shall not delegate the authority to:
●● act under Sub‐Clause 3.7 (Agreement or Determination)
●● issue a Notice to Correct under Sub‐Clause 15.1 (Notice to Correct)
The assistants must be suitably qualified, competent, and are to be fluent in the language
for communications. They are only authorised to issue instructions in respect of those mat-
ters assigned to them by the Engineer. (Reference may also be made to Appendix D of
this book).
3.7 Agreement or Determinatio 21
3.5 Engineer’s Instructions
In the First Edition, this sub‐clause was titled ‘Instructions of the Engineer’ and has been
re‐numbered.
The first sentence of this sub‐clause states that ‘the Engineer may issue the Contractor
instructions for the execution of the Works’.
The Engineer has the authority to delegate his authority (Sub‐Clause 3.4). Consequently,
the second sentence states that the Contractor shall only take instructions from:
●● the Engineer
●● or the Engineer’s Representative
●● or an assistant to whom authority has been granted by the Engineer to give instructions
to the Contractor as described in Sub‐Clause 3.4.
Should an instruction state that it constitutes a Variation, the Contractor shall follow the
procedures given in Sub‐Paragraph 13.3.1. If the Contractor considers that the instruction
does constitute a Variation, then he shall promptly give Notice to the Engineer with his
reasons before commencing any work described in the instruction. Within a period of
seven days, the Engineer may confirm or revoke the instruction, in which case the
Contractor is bound by the Engineer’s response. The Contractor may then follow the claim
procedures given in Clause 20. If the Engineer fails to respond, then the instruction is auto-
matically revoked.
If the Employer intends to replace the Engineer, he is required to give a Notice to the
Contractor with details of his replacement. It is noted that the Engineer appoints both the
Engineer’s Representative (Sub‐Clause 3.3) and assistants (Sub‐Clause 3.4).
3.7 Agreement or Determination
Before using this clause, the attention of the reader is first drawn to the requirements of
Sub‐Clauses 20.1 and 20.2.
Summarised, Sub‐Clause 20.2 (Claims for Payment and/or EOT) describes the proce-
dures to be followed by the claiming Party in order to establish that he has a valid claim
which shall be evaluated in accordance with Sub‐Clause 3.7 (Agreement or Determination).
Within 84 days of the claiming Party becoming aware of the event or circumstance giving
rise to the Claim, he shall submit a Notice of Claim to the Engineer (with reasons for the
claim). Within a further 14 days, the Engineer is required to confirm the Contractor’s
Notice to be valid.
Within 84 days of the claiming Party becoming aware of the event or circumstance giving
rise to the Claim, he shall submit a fully detailed claim to the Engineer or risk rejection of
the claim. The Engineer may request further details. Should a dispute arise in respect of the
validity of a claim, then the dispute shall be dealt with in accordance with the procedures
22 3 Clause 3 The Engineer
Unsuccessful
No Agreement
Engineer’s
Determination
(Sub-clause 3.7.2)
Formally rejected by
Acceptable to both
No response from one or both Parties
Parties
Parties within 28 days (by NOD)
Written Agreement
Sub-clause 3.7.5
Deemed Acceptable by
both Parties Wholly rejected by one
Partly Rejected
Written Agreement or both Parties
Sub-clause 3.7
Add Deduct
Unseparable Separable
Part of Part of
Acceptable Acceptable
3.8 Meetings
Considering that this sub‐clause requires the Engineer to ‘keep a record of each man-
agement meeting. . .’, either the Engineer or more likely the Engineer’s Representative
should attend and act as chairman of the meeting. The Contractor’s Representative’s
presence would also be appropriate.
As work on the project expands, there is a tendency for too many people to attend these
meetings which can greatly extend their duration and occasionally disrupt the decision‐
making process. Consideration could be given to dividing Site Meetings into two separate
segments:
(a) Technical Meetings. Key topics would include progress of the Works, programme
requirements, availability of plant, access problems, material sources and availability,
Drawings etc.
(b) Administration Meetings. These would centre on contractual issues, certification prep-
aration etc. These matters have little interest to the technical staff, who can be better
employed elsewhere. Where useful, a member of the administrative personnel could
attend the technical meetings in order to provide continuity.
Subcontractors, representatives of utility companies, etc. could be invited to either
meeting as required.
The chairman of the meeting may prepare the minutes of the meeting himself or
hand the task to a competent assistant. A broad agreed statement of the proceedings of
the meeting should be prepared as the meeting proceeds. This would allow key deci-
sions to be actioned without delay. The final Minutes of Meeting can then be prepared
and distributed without delay or complaint of their content from any party.
Irregular meetings with service providers, local or central government agencies and simi-
lar bodies are frequently necessary to resolve obstructions to the progress of the Works.
Powerlines, water supplies are required or need relocating. Land acquisition may also have
to be considered. A formal minutes of meeting should be drawn up as a matter of record if
only to ensure each of these external agencies adhere to agreements made. This is important,
particularly if additional costs are involved.
27
This sub‐clause provides an extensive description of the Contractor’s duties and responsi-
bilities during the execution of the Works. These obligations are broadly the same as those
given in the First Edition but are now defined in far greater detail. From the Contractor’s
viewpoint there are no major changes in this Second Edition that would adversely affect his
operations.
This sub‐clause confirms that, unless specifically stated elsewhere, the Contractor does not
have any responsibility for the design or specification of the Permanent Works. Exceptionally,
if the Contract Documents do require the Contractor to design any part of the Permanent
Works, the Contractor is required to prepare a detailed listing of the Contractor’s Documents,
time for the execution of this requirement (including testing, training, as built drawings,
etc.), and time for execution which must be provided for in the Programme of Works.
4.2 Performance Security
The Contractor shall provide the Employer with a Performance Security in the amount and
currencies stated in the Contract Data. If no amount is stated in the Contract Data, this
sub‐clause shall not apply.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
28 4 Clause 4 The Contractor
Sub‐Clause 11.11. It is to be noted that the requirement for the Site to be cleared as a prequel
to the return of the Performance Security was not included in the First Edition. Site clear-
ance can be a tedious operation and should not be allowed to cause an extension to the valid-
ity of the Security.
A further requirement not included in the First Edition relates to Variations and/or
adjustments under Clause 13 (Variations). Should the total amount of Variations and/
or adjustments increase/decrease the Contract Price more than 20% of the Accepted
Contract Amount, then at the Employer’s request (underscore added) the amount of
Performance Security shall be increased/decreased by the percentage of the accumula-
tive increase.
If the Contractor incurs additional cost as a consequence of any increase in the Accepted
Contract Amount, then Sub‐Paragraph 13.3.1 (Variation by Instruction) shall apply as if
the increase had been instructed by the Engineer. Should the amount of the Variations
and/or adjustments decrease the Accepted Contract Amount, then the Contractor may,
with the agreement of the Employer, decrease the amount of the Performance Certificate
by the same percentage.
4.3 Contractor’s Representative
The requirements stated in the First Edition have been retained but have been extensively
re‐stated in a more explicit manner in the Second Edition.
The Contractor is required to appoint the Contractor’s Representative and provide him
with the necessary authority to act on behalf of the Contractor.
In addition to having a necessary qualification and appropriate experience, the
Contractor’ Representative must also be fluent in the ‘language for communications’ and
‘the whole of his time shall be given to directing the Contractor’s performance of the
Contract’.
The Contractor’s Representative will have his own letter of employment provided by the
Contractor. This is a private document and is not subject to review or inspection by any
other party.
This letter of employment will necessarily place restrictions on the internal powers and
authority of the Contractor’s Representative. In essence, the Contractor’s Representative
will not be empowered to take actions which might endanger the economic interests or
financial stability of the Contractor. He will be authorised to operate a local bank account,
purchase local goods and services, and to pay local staff and any other locally based mat-
ters. All offshore interests will be safeguarded by the Contractor’s Head Office. The appar-
ent gap between the Contractor’s Representative’s total authority described in this
sub‐clause and the restricted authority described in his own personal letter of employment
will be managed by the Contractor’s Head Office. Therefore, the standard practice is that
the Contractor’s Representative will immediately refer any matter arising beyond his
authority to the Contractor for their further instruction. In extreme or delicate topics, the
Employer may prefer to discuss these matters directly with the Contractor’s Head Office
senior management.
The Contractor shall not, without the prior consent of the Engineer, revoke the appoint-
ment of the Contractor’s Representative. Reasons for the departure of the Contractor are
typically: end of personal contract, ill health, or personal reasons – as in other professions.
The departure of the Contractor’s Representative will generally be a planned event of
which the Employer and the Engineer will be informed and a proposed replacement for
whom approval has already been requested by the Contractor will be appointed.
The Contractor’s Representative will inevitably be away for short periods for a number
of reasons, including off‐site meetings, medical reasons, short holidays, etc. In such
instances, the Contractor’s Representative is required to delegate his authority to a suit-
ably qualified senior member of his staff to provide short term cover to act in his absence.
4.4 Contractor’s Documents
A broad definition of “Contractor’s Documents” was provided in the First Edition (Sub‐
Paragraph 1.1.6.1) and expanded in the Second Edition (Sub‐Paragraph 1.1.15) and this
Sub‐Clause 4.4 added.
30 4 Clause 4 The Contractor
Four categories of Contractor’s Documents are to be provided for review by the Engineer:
(a) Those documents stated in the Specification. The Specification is a tender document
which is to be included in the final Contract Document. Each specification is compiled
to define the requirements of individual projects. The Contractor’s tender office will
routinely review the contents of the given Specification in the preparation of tenders.
(b) Those documents which are obtained by the Contractor in compliance with local laws.
These requirements should be clarified by the Contractor prior to submission of ten-
ders. The Employer is likely to be able to provide informal guidance.
(c) As‐built Records – see 4.4.2 below.
(d) Operation and Maintenance Manuals – see 4.4.3 below.
The Contractor’s Documents are to be written in the language for communications (see
Sub‐Clause 1.4). When buying materials on the open market for inclusion in the Permanent
Works, the Contractor should ensure that supporting documentation is provided in the
appropriate language.
Operation and Maintenance Manuals are routinely required in respect of turbines, pumps,
gates, and other items of machinery to be provided and installed as part of the contract. This
work will routinely be undertaken by specialist subcontractors generally (but not always) act-
ing as nominated subcontractors under the Contract. Nonetheless, there may be smaller items
of machinery to be installed by ‘in‐house’ subcontractors. In both instances, the operation and
maintenance manuals will be prepared by the subcontractors (supervised by the Contractor)
for the approval with the Engineer with the involvement of the Employer who is the end user.
4.5 Training
Unless stated in the Specification, the Contractor is not required to provide any training of
the Employer’s personnel.
The extent of the training of the Employer’s staff is to be stated in the Specification. The
educational quality and previous work experience of the Employer’s staff selected for train-
ing is crucial. Those who are to be trained to maintain and operate complex machinery
should be selected at an early stage, so that they may work alongside the Contractor’s
employees during the installation stage.
Those suitable for routine maintenance duties will need less training. The Contractor
may be willing to transfer some of his own employees, who have already suitable experi-
ence, directly to the Employer for employment and additional training as the date of the
Taking Over of the Works draws closer.
4.6 Co-operation
The general obligation of the Contractor to provide ‘Appropriate opportunities for other
parties to carry out work on or near the Site’ has a number of aspects:
1. Ideally, any significant requirement to provide services to other parties on the Site
should be described in the Tender Documents in order that the Contractor may include
the cost thereof in the tender offer.
2. Access roads constructed on Site for the Contractor’s own use may be used by others for
general access purposes, but other roads specifically required for use by other parties are
to be constructed and maintained by them.
3. Facilities provided on Site by the Contractor for the use of his own employees are not for
use by others unless agreed by the Contractor or specified in the Contract.
4. Accesses on Site, Site security, etc. provided on Site by the Contractor for Health and
Safety purposes are for use by all parties. This does not negate the responsibility of the
other parties to safeguard their own staff.
5. The Contractor is not obligated to allow other parties use of his Equipment and Goods.
The above are indicative of issues which regularly occur on projects where more than
one contractor is engaged on the same Site, and which may lead to an adverse situation
where the Contractor may suffer delay or additional costs and entitled to claim by giving a
Notice to the Engineer in accordance with Sub‐Clause 20.2.
32 4 Clause 4 The Contractor
The Contractor shall, as stated in the Specification or as instructed by the Engineer, pro-
vide ‘appropriate opportunities’ for other parties to carry out work on or near the Site.
This sub‐clause continues by stating that appropriate opportunities may include the use
of Contractor’s Equipment. . .. and/or other Contractor’s facilities or services on the Site.
It is appropriate that detailed requirements (if any) are given in the Specifications in
order that they may be evaluated by the Contractor and the cost thereof included in the
Tender price.
Contractors are generally unwilling to allow their key equipment to be used by others
unless supervised and operated by their own staff, not least because of the insurance com-
plications which may otherwise arise. It is inevitable that the Contractor will give his own
needs precedence. Additional costs for relocation and return of the equipment will have to
be met by the Employer.
4.7 Setting Out
Sub‐Clause 2.5 requires that the Employer makes available to the Contractor the original
survey control points. The Employer should arrange for a check to be made before hand‐
over to ensure these control points physically exist and have not been disturbed by third
parties.
One of the first operations undertaken by the Contractor on the Site will be check and con-
firm the survey control points which will enable site clearance to commence. Preferably this
is an operation which should be jointly undertaken by the Engineer’s and Contractor’s sur-
veyors, so that corrective measures can be quickly determined. Should the Contractor find
there is an error (or errors), he should give the appropriate Notice to conform with the require-
ments of Sub‐Clause 3.7 and discuss with the Engineer the corrective actions. The bureau-
cratic process stated in this sub‐clause could and should be quickly resolved both to minimise
any delays and to avoid the cost of equipment standing idle and subsequent loss of time.
The First Edition (Sub‐Clause 4.8) provided a relatively brief listing of the obligations of the
Contractor under the heading “Safety Procedures”. This was an update of the wording of the
early FIDIC document last reprinted in 1992. A review of Sub‐Clause 19.1 of this early docu-
ment is concerned with safety and security but the subject of health is not mentioned. Times
have changed. All those engaged in the construction industry and the wider public beyond
now expect and demand high standards in respect of Health and Safety. This Sub‐Clause 4.8
provides a much wider view of the Contractor’s obligations under the heading of Health and
Safety. The contents of the Health and Safety manual will apply to all those engaged on the
project (or visiting the Site), including not only the Contractor’s own personnel but also
those of his subcontractors and suppliers and the Engineer’s and Employer’s personnel
on Site.
Contractors, when working in their own countries of origin, are likely to have available a
standardized Health and Safety manual which can be modified according to the needs of
4.9 Quality Management and Compliance Verificatio 33
The corresponding clause in the First Edition consisted of nine lines of print under the
heading of ‘Quality Assurance’. In this Second Edition, the Contractor’s obligations in
respect of quality control and verification have been significantly expanded, reflecting the
increasing importance of these topics in today’s construction industry.
The FIDIC Conditions of Contract are designed for use on projects in countries where
local Conditions of Contract, including quality management provisions, are likely to be
inadequate for large, sophisticated, and internationally financed projects. Further, the inter-
national loan agencies overwhelmingly support the use of the FIDIC Conditions of Contract.
Larger contractors will have significant experience of QMS/CVS, together with knowl-
edgeable staff able to modify standard documentation as required for individual projects.
Smaller contractors, who may be locally based, can be expected to have difficulty to com-
ply with the specified QMS/CVS requirements. The assistance of an external consultant
may be required to train local staff. Both the Engineer and the Contractor will require dedi-
cated staff in order to manage the QMS/CVS system at the performance level specified in
these Sub‐Paragraphs 4.9.1 and 4.9.2.
Detailed Requirements
The preparation of the required documentation will be on hold until the Contractor
receives a Letter of Acceptance.
The Contractor is to provide the Engineer with the QMS document within 28 days of the
Commencement Date. Sub‐Clause 8.1 (Commencement of Works) states that ‘the
Commencement Date shall be within 28 days after the Contractor receives the Letter of Acceptance’
and the Commencement Date shall be not less than 14 days before the Commencement Date’.
Therefore, the Contractor has 14 days plus 28 days = 42 days to present his QMS docu-
ments to the Engineer.
Considering that a large amount of data will not be available at the Commencement
Date, the QMS document will require continuous updating as additional data becomes
available.
The QMS shall be in accordance with the details in the Specification (included in the
Tender Documents).
34 4 Clause 4 The Contractor
Note:
The obligation of the Employer to supply Site Data is described in Sub‐Clause 2.5 of the
Conditions of Contract. The term Site Data also includes basic survey data. Sub‐Clause 4.7
(Setting Out) describes the verification of this survey data.
The Contractor is solely responsible for the analysis of the Data provided by the Employer
and the Data which he has himself obtained from other sources, including such as govern-
ment agencies.
It is a truism that a tenderer given unlimited time and unlimited resources could discover
everything necessary for a risk‐free project. This is clearly not a practical consideration for
a tenderer preparing his offer in a limited period of time. FIDIC recognises this reality by
stating that ‘. . . to the extent which was practicable (taking into account of cost and time), the
Contractor shall be deemed to have obtained all necessary information. . .’.
4.12 Unforeseeable Physical Condition 35
This criterion of practicality has a profound influence on any claim the Contractor may
wish to make under the provisions of Sub‐Clause 4.12 (Unforeseeable Physical
Conditions). The Contractor’s estimating office would be well advised to keep copies or
records of the data provided by the Employer together with copies of records of data
obtained elsewhere that had an influence on his tender. These may be important in the
evaluation of claims.
Under this sub‐clause the ‘Contractor is deemed to have inspected and examined the site
before submitting his Tender offer’.
It is not an obligatory duty, but the majority of employers organise a formal inspection of
the site which the Contractor may be obliged to attend as a precondition of the tendering
process. Should the Site be in or adjacent to a restricted area, the formal inspection may be
the only opportunity for the Contractor to inspect the site. It is recommended that the
Contractor properly prepare himself for any site inspection. Clarifications should be sought
where appropriate from the Employer/Engineer. A written record should be prepared com-
plete with a photographic record for future reference.
The Second Edition uses the same wording as the First Edition. Accuracy and complete-
ness are skills of the Contractor’s Tender Office.
●● be given promptly, so that the Engineer may inspect the unforeseeable conditions
●● describe the unforeseeable conditions and why the Contractor considers them
unforeseeable
●● evaluate any delays arising from the unforeseeable conditions and any increase in cost.
The Contractor shall be entitled to payment of additional costs and EOT referenced to
Sub‐Clause 20.2.
‘Unforeseeable’ is defined in Sub‐Paragraph 1.1.85 as ‘. . . not reasonably foreseeable by an
experienced contractor’ by the Base Date. It will be noted that definition refers to hypotheti-
cal experienced contractor and not the Contractor himself. In the presentation of any claim
under this heading, the Contractor’s logic should be to demonstrate that a typically experi-
enced contractor could not have foreseen the unforeseeable condition and therefore he, the
Contractor, also an experienced contractor, would equally not have foreseen the unforesee-
able conditions. What the Contractor himself may or may not have foreseen is not of imme-
diate concern.
Frequently secondary disputes may arise over the practical application of the word ‘rea-
sonably’ contained in Sub‐Paragraph 1.1.85. In attempting to provide guidance on this
point, the latest FIDIC Guide expressed the opinion that for a contract of three years’
36 4 Clause 4 The Contractor
The Contractor has a duty to continue with the Works regardless of his claim that he has
encountered an Unforeseen Physical Condition.
The early FIDIC Guide states that the Contractor ‘is expected to use his expertise’ to over-
come the adverse conditions. The Engineer should cooperate with the Contractor to iden-
tify technical solutions which fulfil the principles of the Engineer’s design. This cooperation
is important because remedial work or changes to the performance of the Works may in
themselves represent Variations and Adjustments as described in Clause 13.
Should the Engineer for whatever reason decline to participate in the process to find
solutions, the Contractor may have to proceed unilaterally. In such case, it is vital that he
keeps the Engineer informed of the Contractor’s proposals which should be supported by
adequate technical documentation.
In dealing with the perceived Unforeseen Physical Condition, the Contractor must main-
tain detailed records of his activities on a day‐by‐day basis and present them to the Engineer
for agreement.
The Contractor is entitled to evaluate any future claim based on those records. DAAB
and Arbitration boards may take a negative view of any non‐cooperation.
Significant costing problems can arise if major items of Contractor’s equipment and other
resources are randomly used for work relating to the Unforeseen Physical Condition and to
routine contract work. Separate cost control headings for each activity should be maintained.
In the event of a valid claim for Unforeseen Physical Conditions, Sub‐Clause 4.12, the
Contractor is entitled to payment of (additional) Costs incurred in overcoming the
Unforeseen Physical Condition. The Contractor is entitled to payment for the original work
at the billed rates (or varied rates) and, in addition, payment of the cost of any additional
measures necessary to deal with the Unforeseen Physical Condition. Payments at bill rates
include a profit allowance, whereas payment of cost excludes profit.
In practice it may be difficult, if not impractical, for the Contractor to divide the total
package of work affected by the Unforeseen Physical Condition into a component of work
directly related to the Unforeseen Physical Condition and separately into a component of
original work.
The Contractor may elect to value the total package on the basis of Cost, but would then
lose the profit element on the original work component. In preparing his records, the
Contractor should consider the possibility of separating the two components. Again, this is
a topic that could be usefully discussed in advance with the Engineer.
The First Edition introduced a proviso concerning more favourable conditions which is
retained in this Second Edition. Before any additional cost is finally agreed or determined,
the Engineer may (permissively) review whether other physical conditions in similar parts
of the Works (if any) were more favourable than could reasonably be foreseen when the
Contractor submitted the Tender. It may be presumed that the criterion of foreseeability
applies to that which could be foreseen by an experienced contractor and does not refer to
what the Engineer considers foreseeable.
The above is most likely to apply to projects involving repetitive work – building founda-
tions, machine bases, and similar. Should the Engineer determine that the Contractor has
received a benefit because of more favourable conditions, then the cost due elsewhere to
38 4 Clause 4 The Contractor
the Contractor for proven unforeseeable physical conditions shall be reduced accordingly.
This process shall not result in a net reduction in the Contract Price.
Finally, the Engineer, in making his determinations, may take account of the physical
conditions foreseen by the Contractor when submitting the Tender. The earlier FIDIC
Guide noted that if a dispute arises and is referred to the DAB or to arbitration, the mem-
bers may wish to view evidence of the Contractor’s assumptions, query the authors, and
query why this evidence was not provided to the Engineer at an earlier date.
This sub‐clause is essentially unchanged from that stated in the First Edition 1999.
Sub‐Clause 2.1 of these Conditions of Contract requires the Employer to give the
Contractor ‘right of access to, and possession of, all parts of the Site. . .’.
However, it may happen that the Contractor requires other rights of access to the Site in
addition to those provided by the Employer under the terms of the Contract. The Contractor
is required obtain such additional rights of way at his own risk and cost.
In addition, the Contractor may wish to occupy areas not within the Site and not other-
wise within areas to be provided by the Employer under the terms of the Contract. Typically,
these could be areas for quarries, borrow area, and additional storage areas. Again, the
Contractor is to obtain these areas at his own risk and cost. Restrictions on the usage of
public roads by construction traffic also require investigation.
This sub‐clause is essentially unchanged from that stated in the First Edition
‘The Contractor shall not interfere unnecessarily or improperly with (a) the convenience of
the public and (b) the access to and use of all roads and footpaths. . .’.
The Contractor shall indemnify the Employer against all damages, losses, and costs
which may arise under this heading. Third Party Insurance cover is to be provided by the
Contractor in accordance with Sub‐Clause 17.4.
4.15 Access Route
This sub‐clause is largely unchanged from that stated in the First Edition excepting that
new wording has been added, which states that if the non‐suitability or non‐availability of
an access route arises because of design changes authorised by the Employer, then the
Contractor would be entitled to payment of any additional costs arising and to an extension
of time.
Most public authorities have strict rules concerning the use by contractors of roads fall-
ing under their authority and the needs of the Contractor will have to be negotiated in
some detail.
4.16 Transport of Good 39
Difficulties may arise on contracts for the construction or reconstruction of public roads.
The Engineer, on behalf of the Employer, will routinely provide details of any road junc-
tions and any other public access routes. However, difficulties frequently arise in respect of
private dwellings located along the road whose access routes are severed by the road con-
struction. The Engineer is required to provide detailed instructions of access to these road-
side buildings (if any). The Contractor is entitled to payment for any work instructed.
During their pre‐tender visit, the Contractor’s tender personnel should review the issue
of access to the site in general terms supplemented by preliminary discussions with the
appropriate authorities.
Note:
The heading of this sub‐clause does not include reference to the inter‐related subject of
customs arrangements. Guidance on customs arrangements is to be sought elsewhere in
the Contract Documents.
‘Plant’ is defined in Sub‐Paragraph 1.1.65 as equipment, machinery etc. intended to form
part of the Permanent Works. It is assumed that any Plant to be provided by the Contractor
will be identified in the Specifications and/or the Bill of Quantities. The Employer may
himself provide items of Plant under separate contracts with other contractors or suppliers.
In this eventuality the Contract Documents should identify any involvement of the
Contractor and how any services provided will be paid for.
‘Goods’ are defined in Sub‐Paragraph 1.1.44 as Contractor’s Equipment, Materials, Plant
and Temporary Works. These will not be incorporated in the Permanent Works. It is impor-
tant for the Contractor to know if any Plant provided by him, and any Goods are subject to
imposition of local taxes and/or customs duties. Considering the administrative difficulties
which would arise if this were allowed, it is likely any concession allowed will be limited to
supplies of fuel and cement which may be under direct government control.
Most Goods are likely to be sourced from outside the country of execution of the Contract.
The Employer must therefore clearly indicate if the Contract is to have a ‘tax free’ status
and/or if temporary imports are subject to payment of ‘deposit payments’ to be reimbursed
on re‐export.
On completion of the Contract, it is likely that the Contractor will want to re‐export the
majority of his plant and equipment, excluding any items the Employer may wish to pur-
chase and scrap‐only items. Therefore, ideally, the Contractor would prefer a temporary
tax‐free importation permit for those items which will be re‐exported.
Materials and other minor items are likely to be consumed or otherwise scrapped and
permanent tax‐free importation is required.
Concerning item (b) of this sub‐clause: to facilitate inspection, an organised contractor
will arrange for permanent materials to be separated in his warehousing arrangements.
Concerning item (c): customs clearance is most likely to be arranged by a specialist clear-
ing agency with support from the Contractor.
40 4 Clause 4 The Contractor
Concerning item (d): most items ordered by the Contractor will be shipped free on board
(f.o.b.). A separate shipping insurance may be provided but the insurances required for the
transport to site onwards are likely to be part of the Contractor’s general All‐Risk insur-
ance policy.
4.17 Contractor’s Equipment
Contractor’s Equipment brought on the Site is deemed to be exclusively intended for the
execution of the Works and shall not be removed from the Site without the Engineer’s
consent.
The Contractor is required to give a Notice of the date on which any major item of equip-
ment arrived on Site. Subcontractor equipment is to be separately identified. Frequently,
subcontractor equipment is required for haulage of materials such as cement, crushed
rock, gravel, etc. from off‐site locations, as not all Contractor’s equipment will be suitable
for use on public roads.
Occasionally, the off‐site use of specialised Contractor’s equipment may be requested by
the Employer or other parties. Should the Contractor be willing or able to assist the request-
ing party, he should request the Engineer to provide his agreement for the temporary
removal from Site. The need for appropriate insurances has to be addressed.
The corresponding sub‐clause of the First Edition has been slightly expanded in this
Second Edition.
The Contractor is required to:
●● protect the environment on or off the Site
●● comply with any environmental impact statement which may be assumed to be included
in the Contract Documents
●● limit damage and nuisance to people and property resulting from pollution, noise etc.
An additional paragraph has been added, requiring the Contractor to ensure that emis-
sions, surface discharges, etc. shall not exceed the values indicated in the Specification or
those described by applicable laws. It is suggested that a suitable member of the Contractor’s
laboratory staff be trained and given charge of this subject.
4.19 Temporary Utilities
This sub‐clause was titled ‘Electricity, Water and Gas’ in the First Edition
4.20 Progress Report 41
4.20 Progress Reports
It has long been a requirement of FIDIC contracts that the Contractor prepares monthly
progress reports for submittal to the Engineer.
The First Edition provided for the first time a detailed listing of eight main topics to be
addressed in these monthly reports. The same eight topics with small modifications are
included in the Second Edition
There is one notable amendment. The First Edition Sub‐Clause 4.21 item (a) included a
provision for data provided by each nominated Subcontractor to be included in the monthly
progress prepared by the Contractor.
This wording has been deleted in the Second Edition. However, this Second Edition,
Sub‐Clause 5.1 (Subcontractors) states that ‘the Contractor shall be responsible for the work,
for managing and coordinating all Subcontractors’ work. . .’. The presumption is that the
Contractor is to continue to include Subcontractor data in the Monthly Progress Report.
The listing of topics to be included in the Monthly Report is lengthy and multifaced and is
most suited to a major international project, including a significant content of Plant (mechan-
ical and electrical) which is likely to be produced outside the country of where the contract
is to be performed. It is not suitable for a relatively small routine road project where the lan-
guage of the contract is not the language of the country, adding to difficulties in preparing
the report. However, it is noted that Sub‐Clause 4.21 starts with the wording ‘Unless otherwise
stated in the Particular Conditions . . .’, opening the possibility that the listing of topics to be
included in the Monthly Report can be modified to best suit the needs of individual projects.
Consequently, it is important that the Particular Conditions are reviewed to ascertain what
modifications, if any, have been made to the listing of topics provided in the General Conditions.
The detailed requirements are onerous and will require careful planning by the Contractor
in order that these reports shall be prepared as scheduled.
42 4 Clause 4 The Contractor
The format and content of any report does not have to be agreed or approved by the
Engineer. However, it would be appropriate if the Engineer and Contractor were to infor-
mally review the general format of the report to ensure that it was fit for purpose.
The first report is to cover the period of the first calendar month following the Commencement
Date. Thereafter reports are to be submitted monthly and shall continue to be submitted until
the Date of Completion of the Works (or until any outstanding work is complete). Each report
is to be provided within seven days after the last day of period covered by the report. Allowing
for non‐work days, this means that the Contractor has approximately 5 days to complete and
submit each report. However, this is the same period of the monthly cycle that the Contractor
is required to finalize and submit his Application for Interim Payment (Sub‐Clause 14.3).
It is likely that the Contractor’s Representative will delegate prime responsibility for
preparation of the Monthly Reports to a suitably qualified member of his staff. This indi-
vidual is to ensure that other members of the Contractor’s staff provide suitably collated
data for inclusion in the report. Much of the required data will already be compiled by vari-
ous departments on the Contractor’s organisation for internal use.
It is noted that Sub‐Clause 14.3 (Application for Interim Payment) requires that the
application is accompanied by a further copy of the Progress Report.
This Sub‐Clause 4.20 (Progress Reports) concludes with a statement stating ‘. . . nothing
stated in a progress report shall constitute a Notice under a Sub‐Clause of these Conditions’.
Should the progress report contain reference to an event which may give rise to a claim, the
Contractor should give a separate Notice referenced to Sub‐Clause 20.2 (Claims for Payment
and/or EOT).
This sub‐clause was numbered as Sub‐Clause 4.22 in the First Edition and has the same
wording.
There are many elements to be provided and controlled by an effective security system.
These requirements will vary significantly according to the location of the Works (urban,
countryside, isolated etc.); the Contract may be executed at a number of locations etc. The
list of topics to be evaluated is seemingly endless.
Health and Safety requirement of the Contract also must be taken into account. Security
staff have to be identified and trained. Many of these items will need to be in place at the
commencement of operations. Consequently, the services of a company specialised in
security matters may be required.
The second paragraph requires the Contractor to keep the Site free from all unnecessary
obstructions and to remove from Site all waste and items no longer required. Waste materi-
als taken to a registered dump may incur charges.
The third paragraph states that ‘promptly’ after receiving a Taking‐Over Certificate, the
Contractor shall remove his equipment, waste materials etc. from Site, leaving the Works
in a clean and safe condition.
At the date of the issue of a Taking‐Over Certificate much of the Contractor’s Equipment
is likely to have been removed from Site to another more convenient location, particularly
so if it is to be re‐exported.
This sub‐clause was numbered as Sub‐Clause 4.24 in the First Edition under the heading
“Fossils”. Items of interest are to be secured by the Contractor and a Notice describing the
finding is to be sent to the Engineer who shall issue instructions for dealing with it.
Items of geological or archaeological interest found on the Site shall be handed to the
Employer (for the Engineer to hand on to the Employer). The Contractor shall also give a
Notice to the Engineer, describing the finding and requesting instructions for dealing
with it.
If the Contractor suffers delay or incurs costs complying with the Engineer’s instructions,
then, subject to Sub‐Clause 20.2, the Contractor shall be entitled to EOT and payment
of Costs.
The FIDIC Guide comments that ‘this sub‐clause makes no reference to the finding (of fos-
sils) having to be unforeseeable because the Contract should specify the procedure in respect of
foreseeable findings’.
Although this sub‐clause requires that any findings are to be placed in the care of the
Employer, the Contractor should be aware of any requirements of the local law.
45
Clause 5 Subcontracting
Clause 5 of the First Edition was headed ‘Nominated Sub‐Contractors’ which implied none
of the sub‐clauses which followed related to subcontractors who are directly engaged by
the Contractor.
5.1 Subcontractors
In contrast, this opening sub‐clause of the Second Edition refers to both Nominated
Subcontractors and the Contractor’s own subcontractors hereafter referred to as a ‘in‐house
Sub‐Contractor’. Sub‐Paragraph 1.1.78 defines a ‘Subcontractor’ as ‘any person appointed
by the Contractor as a subcontractor for a part of the Works. . .’.
The Contractor shall obtain the Engineer’s prior consent to all proposed subcontractors,
except for the following:
(i) Suppliers of materials. Effectively, the Contractor is obliged to obtain the Engineer’s
consent to all in‐house subcontractors
(ii) All nominated subcontractors named in the Contract.
Sub‐Clause 5.1 also states that the Contractor is ‘responsible for the Work of all
Subcontractors’ and ‘for the acts or defaults of any subcontractor. . . as if they were acts or
defaults of the Contractor’.
The above requirements represent a significant additional risk placed on the Contractor.
By definition, a nominated subcontractor is likely to be a specialist engaged in the manu-
facture of complex machinery or equal which is outside the Contractor’s technical knowl-
edge. As written, the ‘acts and defaults’ of a Nominated Subcontractor could include design
faults, delayed shipment of components, faulty assembly and testing by the nominated
subcontractor etc. The Contractor is expected to manage any interface work between him
and the nominated subcontractor and provide assistance to him on request.
In comparison, the Contractor is always responsible for work of his in‐house
subcontractors.
There are limitations on the value of works which the Contractor may sub‐let to in‐
house subcontractors (refer to Contract Data for details) and there may be parts of the
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
46 5 Clause 5 Subcontracting
Works which the Contractor will not allowed to sub‐let and which he is obliged to execute
himself.
Where the Contractor intends to engage in‐house subcontractors, he shall submit the
necessary details to the Engineer for his consent to engage any individual subcontractor.
The Engineer is required to approve or disapprove the Contractor’s request within a period
of 14 days of receiving the request, failing which, he is deemed to have approved the
Contractor’s request.
Thereafter the Contractor is required to give Notice of the intended commencement date
of the in‐house subcontractor and the date of his commencement of work on Site.
In addition to the above, the Subcontractor(s) may have taken goods and services from
the Contractor for which payment is due. A normal commercial invoice should be provided
by the Contractor to the Subcontractor for settlement. These matters should not become
intermingled with payment under the (main) Contract.
During the pre‐tender period, the Contractor’s tender preparation team will visit the gen-
eral area where the project will be executed and assess the local labour market and related
issues. Local knowledge will be obtained from the appropriate Government ministry and
local labour offices. The Contractor may already have a local office or partner who will
assess the project requirements.
Concerning accommodation, there are many possibilities:
●● Local workers may be able to live in their own homes and be transported to work by the
Contractor. This is always a better option for social reasons than living in purpose‐built
barracks close to the workplace.
●● Expatriate staff and senior local staff may be largely accommodated in existing housing
where available. If travel distances are too great, then a purpose‐built village may be the
better option.
The Rate of Wages and Conditions of Labour are to be in conformity with local law. There
is a strong probability that there will be a local trade union with whom the Contractor will
need to negotiate wages and conditions.
The Contractor and the Employer may not attempt to recruit staff and labour from each
other. However, as the project draws to a close, the Employer may have a long‐term interest
to recruit some of the Contractor’s staff for operation and maintenance duties with which
they will already be familiar.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
50 6 Clause 6 Staff and Labour
The Contractor is to comply with the relevant labour laws on all matters. Expatriate staff
will require work permits enabling them to reside and work in the country. At the conclu-
sion of the Contract, the expatriate staff are to be returned to their country of origin.
(a) This sub‐clause opens with the wording ‘No work shall be carried out on the Site on
locally recognised days of rest or outside the normal working hours stated in the
Contract Data unless stated in the Contract’.
Working practices will vary from project to project and from country to country. For
example, a road rehabilitation project executed in Eastern Europe will likely adopt a
conventional 5‐day working week. In contrast, a hydro‐electric project at an isolated
site in Africa will likely adopt a 6‐day working week (not least because the Employer
would require the resultant electric power supply at the earliest date). The actual per-
mitted working hours are to be found in the Contract Data (Page 4).
(b) On major projects certain operations are continuous – examples include tunnel
excavation/lining, formwork/concreting in two shifts, crusher operations and trans-
port of materials (subject to local restrictions). Security and safety staff are required to
be continuously available together with medical care. The Engineer is required to give
his consent to these types of operations.
(c) It may happen that work may have to be performed in an emergency situation. The
Contractor is to give immediately Notice to the Engineer, describing the emergency
and the remedial or recovery work required.
considerable from project to project, from location to location, from the size and complexity
of the site operations and not least from the amount of support available from local hospitals
and health services. Should a sizeable part of the Contractor’s staff be expatriate in origin,
evacuation plans to return injured or sick expatriates to their own country may also be
required.
As a first step, it is necessary to meet with local medical professionals to ascertain what
facilities are locally available and how they might be accessed by the Contractor. This will
have an impact on decisions taken in respect of medical facilities and staff to be provided
by the Contractor on Site.
It may be expected that the Engineer will require the Contractor to provide a detailed
proposal to cover all medical aspects of health and safety. Sub‐Clause 6.7 further requires
the Contractor to make all necessary welfare arrangements and to be responsible for hygiene.
Welfare arrangements in this context would include messing and feeding arrangements,
the provision of drying rooms and similar. Hygiene requirements would include adequate
toilet and washing facilities and a general regard for the preventative measures against
disease and unhealthy work practices.
The Contractor is required ‘to appoint a health and safety accident prevention officer at the
Site, responsible for maintaining health, safety and protection against accidents’. The person
shall be required to be qualified for this work and to be given authority to issue instructions
and take protective measures.
These general requirements can be expected to be amplified in the Contract and will be
subject to the relevant laws of the country.
Most major contractors will have available formal Health and Safety Manuals. The
accident‐prevention officer will need to supplement these manuals to conform with the
requirements of the Contract and the local law. Parts of the safety manuals may require
translation into the local language(s). Periodic reporting is required and will form part of
the Progress Report described in Sub‐Clause 4.20.
In staffing an overseas project, the Contractor may be assumed to already have in his
employ a number of key staff and workers with suitable experience gained on similar pro-
jects. Additional staff can be recruited ‘by word of mouth’ or more general advertising. The
CVs of the key staff will be available with the Contractor’s Representative.
The Contractor’s Personnel in question will be hourly paid local staff. Disruptive personnel
will be dealt with according to the Employment Laws of the country.
52 6 Clause 6 Staff and Labour
The occupations and actual work hours of personnel and the type and actual work hours
of plant will be recorded on time sheets prepared by ‘time clerks’ stationed in each sector
of the works.
Local disturbances on site can be dealt with by site security staff. More serious disturbances
may require the intervention of the local authorities.
The opening sentence of this sub‐clause states ‘If no Key Personnel are stated in the
Specification, this sub‐clause should not apply’. Note also the reference to this Sub‐Clause
6.12 in the Contract Data (Page 30). The organisation of the Contractor’s Key Staff is best
dealt with as part of Sub‐Clause 4.3.
53
This sub‐clause (which is identical to that included in the First Edition) serves as a reminder
to the Contractor of the expectations of the Employer. Should the Employer have signifi-
cant doubts with regard to the ability of a potential contractor to execute the Work to the
required level of expertise then these concerns should be expressed during any pre‐award
meetings.
7.2 Samples
This sub‐clause has been significantly expanded from that given in the First Edition
The provision of samples by the Contractor and his suppliers for testing and confirma-
tory testing by the Contractor in cooperation with the Engineer fall into several
categories:
(1) Aggregates for concrete or asphalt or for use as filler material
–– locally obtained from quarries or borrow
–– sampled and tested in Site laboratory
(2) As for (1) but produced by off‐site commercial quarries
–– Initial testing by producer
–– Confirmatory sampling and testing on Site by Contractor
(3) Imported re‐bar and steel sections
–– Manufacturer’s test certificates to be provided
–– Confirmatory site tests and sampling as required by the Engineer
(4) Re‐bar and steel sections obtained from local suppliers acting as agents for foreign
suppliers
–– Test certificates by foreign supplier to be provided (fake certificates are not
uncommon)
–– Sampling for on‐site check testing required
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
54 7 Clause 7 Plant, Materials, and Workmanship
(5) Products of all sorts provided and certified by manufacturer as conforming to specified
standards.
(6) Machinery and Plant Manufacturer may be a general manufacturer, ‘in‐house’ subcon-
tractor to the Main Contractor, or a nominated subcontractor or supplied (and fixed) by
another contractor.
Items under this heading would include:
–– Transformers, Excitation cubicles, Gates, Valves, etc.
–– Motors, Transport Cranes, Weighbridges, etc.
These items will be manufactured off‐site (and very likely in another country).
Exceptional items may require the Engineer to attend the assembly plant. Sampling
requirements to be clarified either in the Contract or otherwise arranged by the
Engineer acting on behalf of the Employer.
1. Engineer is to have access to all places on site from which natural materials are being
obtained.
2. The Engineer should have full access to check the progress of manufacture of Plant and
production and manufacture of Materials. The authority of the Engineer under this
sub‐head is clear, but, as noted in the commentary on Sub‐Clause 7.2, this may be com-
plex in certain circumstances.
Good housekeeping by the Contractor’s storekeeper is important for safe and appropriate
storage of Plant and Materials intended for inclusion in the Works (the so‐called ‘Permanent
Material’). Where practical, a section of the store area is to be reserved for these items,
enabling the Engineer to carry out any inspections he may require.
These items must not be removed for any purpose other than for the specific usage noted
in the purchase order and store card.
The general inspection of the Site will be a continuous duty of the relevant Engineer’s
Staff who are entitled to use the accesses, walkways, pathways, ladders, scaffolding, etc.
provided by the Contractor for his own (and subcontractors’) staff.
The Contractor is required to give formal Notice to the Engineer that work items are
ready for his inspection. Prime instances would be inspection prior to commencing a
concrete operation or that a work area is ready for commencement of a filling opera-
tion. Present convention is that the relevant permission forms are prepared and
approved by the Engineer’s and Contractor’s field staff directly supervising these
operations.
The Engineer may have to make special arrangements for inspection/approvals to be car-
ried out at a foreign location. The services of specialist testing agencies, such as TÜV,
Lloyds, may be required.
These requirements (if any) should be clarified in these Conditions of Contract.
7. Defects and Rejection 55
●● The Engineer gives Notice to the Contractor of any defects or otherwise (It would be
hoped that the relevant staff of the Engineer and Contractor would discuss and arrange
the correction of the majority of defects without formality).
●● The Contractor prepares a proposal for remedial work for the approval of the Engineer.
●● Within 14 days of receipt of the Contractor’s proposal, the Engineer may accept or reject,
asking for a more detailed proposal. If not rejected, the Contractor can commence work
immediately.
●● If the defects persist, the work will be re‐tested and the cycle repeated.
56 7 Clause 7 Plant, Materials, and Workmanship
Should re‐testing be required, necessitating the attendance of the Engineer, then ‘. . . the
Employer shall be entitled, subject to Sub‐Clause 20.2, to payment of these costs by the
Contractor’.
This sub‐clause refers to remedial work to be undertaken by the Contractor before a Taking‐
Over Certificate is issued.
(i) The Contractor is required to repair or remedy or replace Plant and Materials not in
accordance with the Contract.
(ii) The Contractor is to repair or remedy any other work not in accordance with the
Contract.
(iii) The Contractor is to carry out remedial work which is urgently required for the safety
of the Works.
The Contractor shall bear the cost of all remedial work excepting for remedial work
which is necessitated by an act of the Employer or the Employer’s Personnel or by an
Exceptional Event (defined in Sub‐Clause 18.1). The Contractor is entitled to EOT and
Payment of Cost plus Profit in respect of both these events.
Should the Contractor fail to comply with the Engineer’s instructions in respect of any
remedial work, the Employer may employ another party to carry out the repair work.
Except to the extent the Contractor would have been entitled to payment for the remedial
work, the Employer, subject to Sub‐Clause 20.2, would be entitled to payment by the
Contractor for all costs arising from the failure.
7.8 Royalties
The Contractor is responsible for payment of royalties and rents for natural materials
obtained from outside the Site. Rents are to be paid to the owner of the quarry/borrow and
royalties are taxes to be paid to the government.
In addition, the Contractor is responsible for any costs arising from the use of disposal
sites outside the Site. It may be possible to dispose of uncontaminated surplus excavated
material by careful landscaping.
Domestic waste and industrial waste also are to be disposed of in accordance with the
local laws. Fees may become due.
These matters should be discussed with the Employer during the official site visit prior to
tender date.
59
The Engineer is required to give a Notice to the Contractor stating the Commencement
Date not less than 14 days before Commencement Date.
The Engineer will only be authorised to issue such a Notice when instructed by the
Employer to do so, implying that the Employer has issued a Letter of Intent to the Contractor,
requiring him to commence mobilisation. The signing of the full Contract Agreement will
follow later.
In some jurisdictions, the concept of a Letter of Intent is not legally acceptable, so there
may be delays whilst copies of the full Contract Agreement are prepared for signature.
These requirements may have a delaying effect on the date on which the Engineer issues a
Notice to Commence.
With the contractual formalities being finalised, including the Engineer’s Notice to
Commence, the Contractor should insist on a formal inspection of the Site, to ensure that
there are no additional obstructions to commencement, including continuous occupation
of the Site by third parties, often as a consequence of delayed expropriation. The access
road to the Site may have been inspected at the time of the official inspection but now must
be fully available to the Contractor.
As soon as the precise Commencement Date is known, the Contractor can now activate
his insurances accordingly (reference: Clause 19 (Insurances)).
The wording of the corresponding sub‐clause of the First Edition has been slightly modi-
fied in the Second Edition without changing the intent of the sub‐clause.
‘The Contractor shall complete the whole of the Works, and each Section within the Time for
Completion for the Works or Section’.
The cross‐reference to Sub‐Clause 10.1 (Taking Over the Works and Sections) is main-
tained and it is to that sub‐clause that the detailed requirements for the Employer’s Taking
Over are provided.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
60 8 Clause 8 Commencement, Delays, and Suspension
8.3 Programme
This sub‐clause has been significantly expanded and re‐written in the Second Edition
The opening sentence reads ‘The Contractor shall submit an initial [underscoring added]
programme for the Works to the Engineer within 28 days after receiving the Notice under Sub‐
Clause 8.1 (Commencement of the Works)’.
The programming software to be used shall be stated in the Specifications. Otherwise,
the programming software shall be acceptable to the Engineer. Depending on the scale
and complexity of the Works to be executed, the Employer may have provided in the
Tender documents for the guidance of tenderers an outline programme of the Works to be
executed.
Consequently, the Contractor, in preparing his tender, may elect to use the programming
software used by the Employer in preparing the outline programme.
However, the agreement or determination of any such claim (Sub‐Paragraph 20.2.5) may
include a review by the Engineer of measured quantities of other items of work which are
significantly less (by more than 10%) and determine any favourable effect on the critical
path of the Programme.
When determining each EOT, ‘. . . the Engineer shall review previous determinations
under Sub‐Clause 3.7 and may increase but not decrease the total EOT’.
In respect of concurrent delays caused by Employer/Contractor, the text refers to the
‘rules and procedures stated in the Special Procedures’. The guidance is given in Sub‐Clause
8.5 of the Special Procedures (Page 34). However, the guidance acknowledges that ‘. . . there
are no one standard set of rules/procedures in use internationally’ and ‘different rules/proce-
dures may apply in different legal jurisdictions’. Compromise may be required in order to
reach a fair solution.
Provided the Contractor has diligently followed the procedures of the public authorities,
utility companies and these authorities delay or disrupt the Contractor’s work and the
delay or disruption was unforeseeable, then this delay or disruption will be considered a
cause of delay under Sub‐Clause 8.5 (Extension of Time).
Although there is no mention of a Notice to the Engineer (Sub‐Clause 20.2), it would be
appropriate to issue such a Notice for the avoidance of doubt. It will be noted that this sub‐
clause does not itself provide for payment of the Contractor’s costs.
The assistance of public authorities and private utility is frequently required by the
Contractor to provide various services, including:
●● the provision of electricity, water, communication facilities to the Site and other loca-
tions (new services)
●● relocation or repair of an existing service
●● land expropriation issues
●● general access and use of public roads
It may happen that the authority may not have the necessary finance, equipment, or
manpower to provide the requested services. Consequently, the Contractor may be
requested to assist the public authority by supplying materials and use of Contractor’s
equipment in order that the execution of the Works is not delayed.
Although not stated in this sub‐paragraph, should the progress of the Works be dis-
rupted, it is appropriate to give a Notice to the Engineer when these obstructions arise, with
a claim of Extension of Time and/or payment of additional Costs incurred (referencing
Sub‐Clause 20.2).
Progress and Production will always be a key topic for discussion in the Contractor’s inter-
nal management meetings. Key staff, including senior site staff, workshop manager,
8.8 Delay Damage 63
programmer, and a technical office manager should be among the attendees. The causes of
any obstructions causing delay or deviations are to be identified.
●● Was Site mobilisation too slow? If so, can lost time be recovered by providing additional
resources?
●● Is the execution of primary activities below the production levels on which the pro-
gramme of work is based? (e.g. earth moving quantities, quarry production, concrete
plant capacity, asphalt plant production etc.)?
●● Is one activity under‐resourced and under‐producing and therefore disrupting the fol-
lowing activities? If so, additional resources available for deployment?
●● Do the field supervisors have a clear understanding of both short‐term and long‐term
targets?
Should remedial measures be put in place, they must be seen to be effective. Actual pro-
gress must be continuously monitored.
Sub‐Clause 8.7 also states that if actual progress is too slow to complete the Works or
Section within the Time for Completion and/or progress is not in accordance with the
Programme, then the Engineer may instruct the Contractor to submit a revised programme
describing the revised methods which the Contractor proposes to introduce to ensure com-
pletion in accordance with the Contract. Due allowance shall be made for any EOT entitle-
ment due to the Contractor. Unless the Engineer issues a Notice to the Contractor to the
contrary, the Contractor shall proceed in accordance with the revised programme and
methods at his own risk and cost.
Sub‐Clause 8.7 also states ‘the revised methods to expedite progress may include increases
in working hours’. The provisions of Sub‐Clause 6.5 (Working Hours) states in part ‘No work
shall be carried out on the Site. . .. outside the normal working hours stated in the Contract
Data. . .’. Large projects may require multi‐shift continuous 24‐hour operations, whereas
the standard working hours on an urban contract may be strictly restricted by local laws to
a single shift/five days a week operation. These issues require clarification in the
Contract Data.
If the revised method of working causes the Employer to incur additional costs (pre-
sumed to indicate additional supervision costs), then the Employer shall be entitled to
recover those additional costs from the Contractor subject to Sub‐Clause 20.2.
This sub‐clause concludes by stating that revised methods, including acceleration meth-
ods instructed by the Engineer to reduce delays listed under Sub‐Clause 8.5 (Extension of
Time for Completion) shall be evaluated in accordance with Sub‐Paragraph 13.3.1
(Variation by Instruction).
In some circumstances, it may be difficult to determine if the acceleration is a conse-
quence of delays, which are the responsibility of the Contractor, or a consequence of delays,
which are the responsibility of the Employer.
This sub‐clause is a repeat of Sub‐Clause 8.7 of the First Edition, excepting that an addi-
tional sentence has been added, which states that the Contractor’s liability for Delay
64 8 Clause 8 Commencement, Delays, and Suspension
Damages shall not be limited in case of fraud, gross negligence, deliberate default or reck-
less misconduct. Otherwise Delay Damages are limited to the amounts stated in the
Contract Data. The Employer cannot claim his actual costs but does not have to demon-
strate his actual costs or losses.
The Contractor cannot prevent the imposition of Delay Damages by submitting late or
fictious claims for Extension of Time. However, the Employer may lose his entitlement to
claim delay damages if he prevents a valid Extension of Time being agreed or determined
in accordance with Sub‐Clause 20.2.
Should the Employer intend to claim Delay Damages, he is required to present a docu-
mented claim as provided for in Sub‐Clause 20.2. The Engineer is required to formally
consult with the Parties before making a determination.
The heading of this sub‐clause in the First Edition was ‘Suspension of the Works’. The
amended title makes it clear that the Contractor does not have a formal role to play in the
ordering of a suspension of the Works, although doubtlessly he will make representations
to the Engineer if he considers a suspension is required or inevitable.
It is the Engineer who instructs the Contractor to suspend the Works. Considering the
significance of any suspension of the Works, it may be presumed that the Engineer has
discussed the need for a suspension with the Employer in advance of any instruction issued
to the Contractor. The Contractor has a general obligation to protect the Works (or parts
thereof) against loss or damage (refer to Clause 9 (Insurance)).
The following Sub‐Clauses 8.10, 8.11, and 8.12 are applicable only if the event giving rise
to the issuance of a suspension order is within the contractual responsibility of the
Employer.
However, it may be that the responsibility for the event leading to the suspension is not
immediately clear. In such a situation, the Contractor should proceed as described in Sub‐
Clauses 8.10, 8.11, and 8.12 until responsibility is decided. The co‐operation of the Engineer
to agree records should be sought accordingly.
If the Contractor suffers delay and/or incurs Cost from complying with the Employer’s
Suspension, he is entitled to an Extension of Time and/or payment for any Cost incurred
plus profit.
Two exclusions are noted:
●● The consequences of Contractor’s faulty or defective workmanship, Plant or Materials
(i.e. Permanent Materials). Note: this exclusion refers only to items which are ‘. . .faulty
or defective. . .’. Should the Employer’s suspension cause damage or loss to items which
are (or were) not defective, the Employer would be responsible for the consequences
(time and money).
8.11 Payment for Plant and Materials after Employer’s Suspensio 65
●● The failure of the Contractor to protect against loss or damage. It may not be feasible to
provide full protection in certain circumstances. The Contractor must make every effort
to provide protection but cannot be responsible for losses in extreme circumstances.
In complying with an instruction to suspend and protect the Works, the Contractor will
inevitably incur costs. The Site, generally, and particularly static equipment, will have to be
secured; mobile equipment will need to be brought to a secure area, and most of the work
force will be placed on stand‐by or released, etc. A detailed status of the Site will have to be
recorded and agreed with the Engineer on (at least) a daily basis. The evaluation of the
Contractor’s Costs will not be a simple task and if the Contractor does not have an effective
cost office on Site, it will be difficult and take time to achieve. The Contractor would also be
entitled to including a portion of both Site and home office overheads in his total costing.
The Contractor would also be entitled to claim for lost profit.
The entitlement of the Contractor to EOT can only be quantified once the suspension is
lifted, but Costs and EOT entitlement will continue in part until all of the Contractor’s
operations are working at the rate existing before the suspension was instructed.
The Contractor is not entitled to EOT or payment of Cost incurred
●● if the suspension arises from a cause which is the responsibility of the Contractor
●● if the suspension is the consequence of defective workmanship, Plant and Materials pro-
vided by the Contractor.
Further, the Contractor has no entitlement in respect of the Contractor’s failure to fully
protect the Site and all assets located and stored on Site. The level of protection to be pro-
vided should be discussed and agreed with the Engineer at the earliest opportunity.
The Contractor is entitled to payment of the value at the date of suspension for Plant and
Materials which have not been delivered to Site if
(a) the work on Plant or delivery of Plant and Materials has been suspended for more than
28 days and
(i) the Plant and Materials were programmed to have been completed and ready for
delivery to Site
(ii) the Contractor provides the Engineer with reasonable evidence that the Plant and
Materials comply with the Contract
(b) the Plant and Materials are marked as the Employer’s property.
In practical terms the word ‘value’ could be interpreted as the amount of the relevant
supplier invoices for Plant and Materials ordered by the Contractor to which must be added
transport costs, insurance costs and customs/clearing charges.
or
If the Plant and Materials are provided by a Nominated Subcontractor, the value may be
calculated from original invoices (in a similar manner adopted by the Contractor noted
above) or by reference to a priced listing in the sub‐contract documents.
66 8 Clause 8 Commencement, Delays, and Suspension
It is not clear if value is subject to deductions and adjustment (refer to Sub‐Clause 14.3),
including the Contractor’s mark‐up on subcontract work.
If the suspension exceeds 84 days, the Contractor may give a Notice to the Engineer request-
ing permission to proceed. If the Engineer does not respond within 28 days of the Notice,
the Contractor may either:
●● agree to a further extension entitling the Contractor to Extension of Time and payment
of his continuing Costs plus profit
or
●● after giving a second Notice, treat the suspension as an omission of the affected part of
the Works, immediately releasing the Contractor from any obligation to protect, store or
secure the Employer’s property
or
●● if the suspension affects the whole of the Works, the Contractor may give a Notice of
Termination under Sub‐Clause 16.12.
In an extreme situation, a period of 112 days could elapse before the Contractor is advised
whether the Works are to continue or if the period of suspension is to be extended by agree-
ment or if the Works are to be terminated. The Contractor is placed at considerable com-
mercial risk by any suspension and the uncertainty arising from an extended suspension
amplifies those risks.
It is important for the Contractor to maintain close contact with the Employer and the
Engineer in order to obtain an agreement concerning the future of the Contractor’s
resources both on and off Site. Good record‐keeping by the Contractor is essential to sup-
port any claims subsequently presented by him.
The Contractor shall resume Work as soon as practical after receiving a Notice from the
Engineer to re‐commence the suspended work.
The Contractor and the Engineer have an obligation to jointly examine the affected
Works and the Engineer shall record their findings.
A lengthy suspension of Work may affect more work areas than the original affected
parts of the Site and these should be noted in the Engineer’s report. It is possible that ele-
ments of the Contractor’s work force may have been laid off and are to be recalled. The
affected parts of the Site require re‐activation and made ready to commence normal opera-
tions. These restorative activities require recording as they constitute additional Contractor
Cost, requiring reimbursement.
8.13 Resumption of Wor 67
The Works and the Plants and Materials shall be inspected for deterioration, loss, or dam-
age, which is to be made good by the Contractor. According to Sub‐Clause 8.10, the
Contractor is responsible for any Costs arising as a consequence of protective measures
employed. The Costs of these protective measures are not foreseen in the Contractor’s ten-
der, are not a Contractor’s risk item and must be included and recovered as part of the Costs
to be reimbursed under Sub‐Clause 8.9, Employer’s Suspension, or Sub‐Clause 8.10,
Consequences of Employer’s Suspension.
The so‐called protective measures to be provided should ideally be agreed between the
Contractor and the Engineer.
69
9.1 Contractor’s Obligations
This sub‐clause opens with a reference to Sub‐Clause 7.4 (Testing by the Contractor),
which serves as a reminder of all those preparatory matters to be addressed before any test-
ing can begin, notably the provision of calibrated equipment and availability of experi-
enced personnel to perform the testing.
The bulk of the testing to be performed is likely to be centred on the testing of electric
and mechanical Plant and Equipment and Communication Equipment, all with their con-
nective systems.
The Contractor is required to prepare a comprehensive testing programme for presenta-
tion to the Engineer at least 42 days before the intended start date of the test programme.
Nominated Subcontractor input, if any, will also be required. The Engineer may review the
proposed test programme and give a Notice to the Contractor, identifying items of non‐
compliance. Within a further 14 days, the Contractor shall present a revised test programme
to the Engineer. The Contractor shall not commence the test programme until a Notice of
No‐objection is given by the Engineer.
In practice it is customary for the concerned staff of the Contractor and Engineer to hold
a series of working meetings with the objective of agreeing the detail of a test programme.
Effectively, there will be a number of test programmes, each covering a different part of the
total testing programme. The attendance of the Employer should be welcomed, particu-
larly if he is to be the operator/maintenance agency after the Taking‐Over is satisfactorily
completed. It is also possible that the Employer will have an input on the testing pro-
gramme for on‐load testing.
The sub‐clause then specifies that the Contractor shall give a Notice to the Engineer of
the date after which the Contractor will be ready to carry out each of the Tests on
Completion. The Contractor shall commence the Tests on Completion within 14 days after
this date.
The results of the Test Programme(s) will be recorded as the testing programme proceeds
and signed by the Contractor or Subcontractor staff. A copy is to be provided to the author-
ised Engineer’s staff member present during the performance of the testing. A formal doc-
ument will be provided to the Engineer for each group of type of test.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
70 9 Clause 9 Test on Completion
9.2 Delayed Tests
Having given due Notice to the Engineer of an intention to commence testing, should the
testing be unduly delayed by the Engineer’s personnel (or another party for whom the
Engineer is responsible), then the issue will be dealt with in accordance with Sub‐Clause
10.3. Sub‐Clause 10.3 entitles the Contractor to recovery of any additional Costs and EOT
in accordance with Sub‐Clause 20.2.
If Tests on Completion are delayed by the Contractor, the Engineer may give Notice to
the Contractor, requiring him to carry out the testing within a further period of 21 days
after receipt of the Notice. Should the Contractor continue to delay the Tests on Completion,
then the Engineer may give the Contractor a second Notice. If the second Notice is not
acted upon by the Contractor, the Engineer may carry out the tests himself. Copies of the
test results are to be sent to the Contractor by the Engineer. The Employer is entitled to
recovery of additional costs incurred because of delayed testing for payment by the
Contractor, all subject to Sub‐Clause 20.2.
Note:
These Conditions of Contract do not refer to the possibility of the Engineer operating and
testing affecting a supplier’s warranty.
9.3 Re-testing
If the Works (or a Section) fail to pass the Tests on Completion, the Engineer or the
Contractor may require these failed tests to be repeated on the same terms and conditions.
This sub‐clause refers to the possibility that the Works (or a Section) may fail to pass the
Tests on Completion following re‐testing as described in Sub‐Clause 9.3. It may be assumed
that the Contractor and his suppliers/subcontractors and nominated subcontractors will be
aware of the circumstances of the repeated failure and will make every effort to correct the
causes of failure.
The following options are then open to the Engineer:
(a) The Engineer may order a further repetition of Tests on Completion
(b) The Engineer may reject the Works if the effect of the failure is to deprive the Employer
of substantially the whole benefit of the Works. The options available to the Engineer
are stated in Sub‐Clause 11.4 (Failure to Remedy Defects).
(c) Should the continuing failure relate to a Section of the Works, the options available to
the Employer are also provided in Sub‐Clause 11.4.
(d) The Engineer may issue a Taking‐Over Certificate if requested by the Employer. The
Contractor shall proceed in accordance with the execution of the Works. The Employer
is then entitled to claim his costs from the Contractor (Sub‐Clause 20.2 refers) or a
reduction in the Contract Price (Sub‐Clause 11.4b refers).
71
10
The Works shall be taken over by the Employer when the Works have been completed in
accordance with the Contract including the Tests on Completion (refer to Clause 9 (Tests
on Completion)).
The basic procedure for the Employer’s Taking Over given in the First Edition has been
retained: ‘The Works shall have been completed in accordance with the Contract, including
the passing of the Tests on Completion.
The Engineer shall issue the Taking-Over Certificate excepting for any minor outstanding
works, and defects which will not substantially affect the use of the Works . . . for their intended
purpose’.
In this Second Edition, three additional conditions have been added:
1. ‘if applicable, the Engineer has given . . . a Notice of No-objection to the as-built records
submitted under Sub-Paragraph 4.4.2 (As-Built Records)’.
2. ‘if applicable, the Engineer has given . . . a Notice of No-objection to the operation and main-
tenance manuals under Sub-Paragraph 4.4.3 (Operation and Maintenance Manuals)’.
3. ‘if applicable, the Contractor has carried out the training under Sub-Clause 4.5 (Training)’.
The First Edition did not specify that items 2 and 3 above were conditions to be fulfilled
before the Engineer’s Taking-Over Certificate could be issued. Consequently, in the past,
Contractors have tended not to give these activities a high precedence.
The Contractor may apply for a Taking-Over Certificate by giving a Notice to the Engineer
not more than 14 days before the Works will be complete and ready for taking over.
Consequently, as the anticipated date for Taking Over draws nearer, it is recommended
that the Contractor maintains an increasingly detailed dialogue with the Engineer and
continuously review the status of the Works, thereby establishing the extent of the Works
yet to be completed.
A ‘punch list’ of outstanding work items should be prepared for review at appropriate
intervals with completed items marked as complete. Such a continuous dialogue would
greatly facilitate the Taking Over process.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
72 10 Clause 10 Employers Taking Over
However, in some jurisdictions, it may be unlawful for the Engineer to issue a Taking-
Over Certificate without obtaining the consent of the Employer. Matters can be yet more
complicated if the Employer in turn is required to hand over to an end user who may not
be specifically mentioned in the Contract Document. Such bureaucratic processes can
severely delay the actual date of the Works for reasons not of the Contractor’s making.
The Contractor, preferably in cooperation with the Engineer, who may also not be famil-
iar with local procedures, should seek authoritative guidance at an early stage of the execu-
tion of the Contract.
Sub-Clause 10.1 continues by stating that if the Engineer fails to issue the Taking-Over
Certificate or fails to reject the Contractor’s application within the stated period of 28 days,
and if the Works are indeed substantially completed in accordance with the Contract, the
Taking-Over Certificate shall be deemed to have been issued on the last day of that period.
It seems inevitable that the Employer will insist on the Engineer rejecting the Contractor’s
application without due cause or with improper reasoning rather than allow the Taking
Over to take place by default. Additionally, the provisions of local law as described earlier
may make such Taking Over procedure illegal.
The Contractor should be very wary that he does not find himself trapped in a situation
where a delay can be engineered between the Employer, the end user, and the authorities,
preventing the rightful issue of the Taking-Over Certificate, in order to meet the conveni-
ence of the Employer rather than complying with the stated intentions of the Contract. The
Engineer may find his authority undermined in these circumstances. It further leaves the
Contractor in a difficult position because it is not possible to estimate the time to be allowed
in the programme for completion of this activity.
The Employer has no right to use the Works if the Contractor has failed to complete them
in accordance with the Contract except after Termination.
The issue of the Taking-Over Certificate for the Works or Sections results in a reduc-
tion of the amount of Delay Damages. The value of the Delay Damages shall be reduced
proportionately by the value that the works taken over bears to the Accepted Contract
Amount.
‘The Engineer may, at the sole discretion of the Employer issue a Taking-Over Certificate for
any part of the Permanent Works’.
Should the Employer require access to (and possibly operate) parts of the Works prior to
the issue of a Taking-Over Certificate, then such requirement either must be stated in the
Contract or regularised in a separate agreement made between the Parties.
Whilst the Employer and Contractor may make a supplementary agreement permitting
the Employer to occupy parts of the Works without formal Taking Over, in practice this
should be used sparingly. Not only are there plenty of opportunities for disputed liability
for any damage caused to already completed work and problems with insurers, but also
there is the fact that the Employer is obtaining a principal benefit in advance which may
unreasonably delay the eventual issue of the Taking-Over Certificate.
10.3 Interference with Tests on Completio 73
‘If the Contractor is prevented for more than 14 days (either a continuous period, or multiple
periods which total more than 14 days) from carrying out the Tests on Completion by the
Employer’s Personnel or by a cause for which the Employer is responsible, then:
(a) the Contractor shall give a Notice to the Engineer describing such prevention
(b) the Employer shall be deemed to have taken over the Works (or Section) on the date when
the Tests on Completion would otherwise have been completed
(c) the Engineer shall immediately issue a Taking-Over Certificate as soon as practical.
Finally, the Engineer shall give Notice to the Contractor of not less than 14 days after which
the Contractor can recommence the outstanding tests’.
During the execution of the Tests on Completion the following typical situation could
arise which prevents the Contractor from completing the test programme:
The Contractor has satisfactorily completed all tests on completion including static tests
on hydraulic equipment installed by him, but the final load test requires the provision of
the final connections to power and water supply which is a responsibility of the Employer,
as he is relying on another contractor or public utility company to provide the final
74 10 Clause 10 Employers Taking Over
connections. It is inevitable that the final load testing will be delayed, and the Contractor
will be unable to complete the Tests on Completion on schedule.
If the Contractor suffers delay and incurs Cost as a result of being prevented from carry-
ing out the Tests on Completion, the Contractor shall be entitled, subject to Sub-Clause
20.2, to EOT and/or payment of such Cost plus Profit.
11
This sub-clause has been re-titled from ‘Defects Liability’ used in the First Edition. The
formal identification of defects is the subject of Sub-Clause 7.5 (Defects and Rejection) and
the general procedures for the correction of any defects is given in Sub-Clause 7.6 (reme-
dial Work). This Clause 11 overlaps with Sub-Clauses 7.5 and 7.6 and is centred on other
aspects of the remedying of defects.
The term ‘Defects Notification Period’ (DNP) is defined in Sub-Paragraph 1.1.27 as ‘the
period for notifying defects in the Works. . .’. The period is given in the Contract Data and is
calculated from the date of issuance of the Taking-Over Certificate (Sub-Clause 10.1 refers).
During the Defects Notification Period the Contractor is required to:
●● complete any work outstanding on the Date of Completion. However, the wording
‘within a reasonable time as instructed by the Engineer’ used in the First Edition 1999 has
been enlarged to ‘within the Times stated in the Taking-Over Certificate or such other rea-
sonable time as instructed by the Engineer’. This implies that the Contractor will have an
input into the timing of the execution of any repairs. This requirement reinforces the
need for the Contractor (in co-operation with the Engineer) to prepare a ‘punch list’ of
outstanding works, including any remedial works, ahead of the likely Date of Completion
in order that the list of outstanding work is kept to a minimum
●● execute all remaining outstanding work and repair before the expiry date of the Defects
Notification Period. Assuming a Defects Notification Period of twelve months, it is rec-
ommended that the Engineer and Contractor inspect the Works at approximately three-
monthly intervals and identify those outstanding works completed and if new defects
have arisen, within each time interval. At this stage of the Contract, the Contractor will
have significantly reduced his site establishment in accordance with the requirements of
Sub-Clause 11.11 (Clearance of Site). Consequently, outstanding works (if any) and
repair works should be completed expeditiously to ensure that the Date for Completion
is not extended.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
76 11 Clause 11 Defects after Taking Over
The Contractor is not responsible for damage to the Works caused by the Employer or
others permitted to use the Works by the Employer, including the general public. However,
the Contractor remains responsible for any damage caused by his own employees and sub-
contractors completing any activities during the Defects Liability Period. It is important in
this period that the Contractor works in an orderly and controlled manner in order that his
employees do not cause further damage while carrying out their tasks.
The satisfactory completion of any outstanding work and the rectification of defects and
repairs should be formally recorded and signed-off by the Parties. Periodic joint inspections
of the Works by the Parties during the Defects Liability Period would be beneficial, particu-
larly for larger and more complex projects.
The Contractor is responsible for all costs arising out of his obligation to correct defects and
repair damages that are within his contractual responsibility. However, should the
Contractor consider that the repair works are attributable to other causes, not the respon-
sibility of the Contractor, then he shall give a Notice to the Engineer accordingly. The
Engineer is required to ‘agree and determine’ the cause of the defect. The date of the Notice
by the Contractor is the date of commencement of the time for limit for agreement under
Sub-Paragraph 3.7.3 (Time Limits).
In this Second Edition, the Contractor is responsible for other defects or damages aris-
ing from:
●● design (if any) of the Works for which the Contractor is responsible
●● Plant, Materials, or workmanship not being in accordance with the Contract
●● improper operation or maintenance attributable to errors or inadequacies in As Built
Records or operational manuals, or damages arising from inadequate training of the
Employer’s staff.
There are other issues which may cause damage to the Works:
●● Damages arising on the Site as a consequence of breaches of site security are likely to be
the Contractor’s responsibility.
●● Damages arising from the actions of other contractors engaged by the Employer are the
responsibility of the Employer (although the matter may directly be settled by the insur-
ers of the other contractors).
●● Damages caused to the parts of the Site by the Public. Occasionally the Employer may
request the Contractor to allow public usage of part of the Site prior to the issuing of a
Taking-Over Certificate. This situation may particularly arise on a lengthy road project
and should be discussed and agreed between the Parties before implementation. One
solution is that a Taking-Over Certificate for part of the Works could be issued.
●● However, the Contractor remains responsible for any damage caused by his own employ
ees and subcontractors completing any activities during the Defects Notification Period.
It is important in this period that the Contractor works in an orderly and controlled
manner in order that his employees do not cause further damage while carrying out
their tasks.
11.5 Remedying of Defective Work off Sit 77
In preparing a Notice to the Engineer the Contractor should carefully review the contrac-
tual basis of his claim.
The satisfactory completion of any outstanding work and rectification of defects and
repairs should be formally recorded and signed-off by the Parties. Periodic joint inspections
of the Works by the Parties during the Defects Notification Period would be beneficial,
particularly for larger and more complex projects.
It may happen during the Defects Notification Period that the Works or Section or Part can-
not be used as intended due to a defect or damage. The Employer is entitled to an extension
of the Defects Notification Period (DNP) corresponding to the period of non-serviceability.
The extension is limited to the defective item. The Defects Notification Period is not to be
extended for a period of more than two years after the DNP stated in the Contract Data.
If the Contractor fails to remedy any defect or damage notified in Sub-Clause 11.1 within
a reasonable time, a date may be fixed by the Employer by which the defect or damage is
to be remedied. A Notice of this fixed date shall be given to the Contractor by the
Employer.
If the Contractor fails to remedy the defect or damage by the notified date and, provided
this remedial work was to be executed at the cost of the Contractor, then the Employer may:
(a) carry out the work himself or by other contractors at the Contractor’s cost. The
Employer is entitled to reimbursement of his costs in accordance with Sub-Clause 20.1
(Claims)
(b) accept the damaged or defective work, in which case the Employer shall be entitled to
a reduction in the Contract Price in accordance with Sub-Clause 20.1 (Claims)
(c) require the Engineer to treat any part of the Works which cannot be used for its
intended purpose as an omission as if it were instructed under Sub-Clause 20.1
(Claims)
(d) terminate the Contract with immediate effect. This is self-evidently a very extreme
situation and will rarely occur. Legal advice would be essential if such a situation were
to occur.
In giving consent to the removal, the Employer may require the Contractor to increase
the amount of the Performance Security by the full replacement cost of the defective or
damaged Plant.
If the defective or damaged Plant was provided by Subcontractors (either the Contractor’s
in-home subcontractor or a Nominated Subcontractor), then the Contractor may be enti-
tled to reimbursement of the cost of increasing the value of the Performance Security by
the Subcontractor.
Difficulties may arise if the Plant taken for repair off Site delays or interferes with the
Employer’s operations on a Section of the Works already taken over by the Employer.
Temporary replacements may be required. It is important that the period in which the
damaged plant is likely to be off Site is established before removal.
Within seven days of remedying any defect or damage, the Contractor shall give a Notice to
the Engineer of any repeat testing which the Contractor intends to perform. Within a fur-
ther seven-day period the Engineer is to give a Notice agreeing with the Contractor’s pro-
posal or instructing the repeat testing required.
Should the Contractor fail to respond to the proposals of the Engineer within 14 days of the
remedial works, then the Contractor shall perform the repeat testing stated by the Engineer.
These tests shall be carried out at the risk and cost of the Party liable.
Until the 28th day after the issue of the Performance Certificate the Contractor has a right
of access to the Site for the purpose of rectifying defects and executing repairs. For security
reasons, the Employer may impose controls and restraints on the Contractor’s activities.
Whenever the Contractor requires access during the Defects Notification Period, the
Contractor is required to give a Notice to the Employer giving the reasons for requiring
access and the preferred date for access. Within seven days, the Employer shall respond
accepting the Contractor’s proposal or proposing an alternative date.
If there are unreasonable delays in obtaining access, the Contractor may, subject to Sub-
Clause 20.2, claim for any additional Costs incurred plus Profit.
This sub-clause then continues to state that if the Employer fails to respond within seven
days, the Employer is deemed to have given consent to the Contractor’s proposals. This
appears to be an unworkable solution should access be physically impossible and a discus-
sion between the Employer and Contractor would provide a mutually better solution.
The Contractor shall, ‘if required by the Engineer, search for the cause of any defect’ or by
extension the circumstances of any damage. The Engineer is to direct this operation, which
is to be performed on a date specified by the Engineer.
11.11 Clearance of Sit 79
Should the Contractor be liable for the defect or damage, then the search will be carried
out at his cost. If the Contractor is not responsible, then he is entitled to payment of his
costs of search plus profit.
Should the Contractor fail to carry out the instructed search, then the Employer, by
Notice to the Contractor, is entitled to specify a date on which the search will take place.
The Contractor may attend at his own cost. If the defect is to be remedied at the Contractor’s
expense, the Employer is entitled to recover his costs from the Contractor.
The obligations of the Contractor under the Contract are not complete ‘until the Engineer
has issued a Performance Certificate’ (which shall state the date on which the Contractor
completed his obligations).
The Performance Certificate shall be issued within 28 days after the latest of the expiry
dates of the Defects Notification Period, provided the Contractor has supplied all
Contractor’s Documents and completed all testing of the Works.
‘Only the Performance Certificate shall be deemed to constitute acceptance of the Works’.
There is no formal action required by the Contractor other than to advise the insurers.
Notwithstanding the issue of the Performance Certificate there will remain unfulfilled
obligations between the Parties. The most significant of these will relate to the settlement
of financial matters and resolution of any remaining disputed issues.
The Employer is to return the Performance Security to the Contractor within 21 days of
the date of the Engineer issuing the Performance Certificate.
Most contractors will remove their equipment, surplus materials, temporary works etc.
from site as soon as possible. Alternatively, the Contractor may be allowed to use the Site
(by agreement with the Employer) as a storage point pending removal of the Contractor’s
property to another project.
However, upon receiving the Performance Certificate, the Contractor is required to
remove his remaining property within a further period of 28 days, unless agreed otherwise
with the Employer. Failure to do so entitles the Employer to dispose of and sell the
Contractor’s property and to restore the Site. The Employer would be entitled to recover his
costs and pay only the residual amounts to the Contractor.
Frequently, the Contractor may locate some part of his storage area outside the Site on
land not belonging to the Employer. The Employer has no jurisdiction in respect of these
external areas.
81
12
This sub-clause in part states ‘Whenever the Engineer requires a part of the Works to be meas-
ured on Site, he shall give a Notice to the Contractor . . . of the part to be measured and the date
and place on Site where the measurement shall be made’.
and
‘Any part of the Permanent Works that is to be measured from records shall be identified in
the Specification . . . such records shall be prepared by the Engineer’.
The Engineer is to give Notice to the Contractor’s Representative when he requires any
part of the Works to be measured and the Contractor is required to support and attend the
Engineer. The Works are to be measured based on these records by the Engineer and agreed
by the Contractor.
If the Contractor disagrees with the Engineer’s records and/or measurement, he shall
give Notice of his disagreement to the Engineer. The Engineer shall review the records and
confirm or vary them. If the Contractor remains in dispute with the Engineer’s records
and/or measurement, he is obliged to give a second Notice of dispute to the Engineer
within a further period of 14 days, otherwise the Engineer’s records and/or measurement
are considered accurate and correct.
There are two separate measurement processes to be considered:
(1) Interim measurements are required for the purpose of preparing the Application(s) for
Interim Payment (Sub-Clause 14.3 refers).
These interim measurements are routinely prepared on a monthly basis by land sur-
veyors, quantity surveyors and others from both the Engineer’s and Contractor’s staff.
These measurements can be modified in any future IPC but shall be as accurate as
possible (with due recognition of the limited time available for the preparation of each
monthly IPC). They do not constitute a final measurement since they are likely to be
only a portion of the total of each bill item.
However, in many instances, including work to be disturbed or covered up, or items
of work which are complete but no longer accessible, can be measured as final
measurements.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
82 12 Clause 12 Measurement and Valuation
In practice the structured approach described in this Sub-Clause 12.1 is rarely adhered
to. It is the Contractor who has the vested interest in ensuring that the measurement of
work performed is maximised and, equally importantly, that is measured as quickly as
possible after execution for inclusion in the next Interim Payment Application.
Whilst the Engineer may equally have the intention to measure the Works accurately
and fairly, he is not under the same economic pressures as the Contractor. As a conse-
quence, it is the Contractor who drives this measurement process and is prepared and
able to commit resources to accomplish measurement as soon as practicable.
Significant portions of the measurement may be made from Drawings, but other
operations such as major earthworks, particularly if construction is spread over a long
period of time, may require several field surveys to be made as a basis for measurement.
Not all items of work are visible or accessible after their execution. In such cases,
agreed measurement records must be progressively prepared and maintained. Equally,
owing to site vagaries, additional operations may have had to be performed that cannot
be later discerned from the As-Built Drawings.
Experienced Site staff will recognise the crucial need to maintain accurate records of
measurement, which should be updated as appropriate.
Wherever possible and whenever items of work are completed, the measurement
should be finalised and not left for agreement at some future, undefined date. Memories
can be selective and unreliable. In addition, there may be changes in the relevant staff
of both Engineer and Contractor, which may further delay finalisation of measure-
ment. The Contractor should be particularly wary, since replacement Engineer’s staff
may not be receptive to agreeing earlier measurement not formally agreed by their
predecessors. It is the Contractor who suffers financially and who is obliged to protect
his interests by giving the issue of measurement its due priority.
It would be mutually beneficial for the Engineer and the Contractor to agree a stand-
ard format for recording agreed measurements prior to the commencement of Works.
In addition to the measurement of the physical works, there are usually a number of
administrative bill items contained in the Contract, which are paid according to certified
documentation to be provided by the Contractor. Paper items such as receipts, invoices,
and records of numbers of vehicles provided for the Engineer and similar items have to be
securely stored for future reference, particularly if the Contract is to be audited at a later
date by third parties.
(2) Final measurement is a summation of the various parts or sub-parts of the Works exe-
cuted in accordance with the Contract specifications. Some parts of this final measure-
ment will have, effectively, been agreed in the preparation of IPCs as noted in 1) above
and the remaining items progressively agreed as the Works progress to completion.
The actual amounts of work performed by the Contractor may not be the subject of a
dispute between Engineer and Contractor. However, the Engineer may consider that the
Contractor is not entitled to payment for all of the quantities of work actually performed,
leading to a formal dispute.
If the difference between performed quantities and proposed paid quantities cannot be
resolved, then the Contractor would be entitled to give a Notice to the Engineer and pro-
ceed with a claim in accordance with Sub-Clause 20.1 (Claims).
12.2 Method of Measuremen 83
This Sub-Clause 12.2 has been revised from that given in the First Edition.
‘The method of measurement shall be as stated in the Bill of Quantities’
and
‘Except as otherwise stated in the Bill of Quantities, measurement shall be made of the net
actual quantity of each item of the Permanent Works and no allowance shall be made for
bulking, shrinkage and waste’.
It is an unfortunate fact that there does not exist an internationally recognised method of
measurement. The method of measurement most frequently encountered is the Civil
Engineering Standard Method of Measurement sponsored by the Institute of Civil
Engineers London, but regrettably even this standard is not yet in widespread use on inter-
national contracts.
The Conditions of Contract are understandably somewhat vague on the issue of method
of measurement and state only that ‘measurement shall be made of the net actual quantity
of each item’ and ‘the method of measurement shall be in accordance with the Bill of Quantities
or other applicable schedules’.
It is unreasonable to assume that a contractor with international experience is necessar-
ily familiar with local practices in any specific country. Unless he has staff member with
appropriate local knowledge, he is, in the preparation of the Tender, going to be dependent
on intelligent assessment of the Tender documentation. Given the limited time available
for the preparation of the Tender, it will be difficult for a tenderer to make more than a brief
check of the correctness of the quantities shown in the Bill of Quantities.
However, a tenderer should undertake a review of the descriptions included in the items
in the Bill of Quantities, to check they are comprehensive and conform to the technical speci-
fications. Any omissions or anomalies should be immediately formally queried with the
Engineer.
Most unreasonably, it frequently happens that a Bill of Quantities will include a general
preliminary statement to the effect that the individual bill item descriptions are not to be
taken as a full description of the work included in the item. Sometimes this is interpreted
by the Engineer to mean that for any work not specifically identified, but necessary because
of work descriptions contained in the Specifications, the cost is deemed to be included in
the individual bill item or spread over a group of bill items (refer to Sub-Clause 4.11).
Further complications can arise when the Specifications contain misplaced references to
the Bill of Quantities or in some cases contradict the descriptions in the Bill of Quantities.
A tenderer has little option but to carefully review the wording of the Bill of Quantities and
report any anomalies. In the absence of a standardised Method of Measurement, this
remains an unsatisfactory process which hopefully will receive attention from FIDIC and
the various trade organisations in the near future.
For the present the FIDIC Contracts Guide contains the following advisory considerations:
‘(a) If the Bill of Quantities includes principles of measurement which clearly require that an
item be measured and if the Bill of Quantities does not contain such an item, then an
additional Bill Item will be required.
(b) If the Bill of Quantities includes (either by reference or specified) principles of measure-
ment which do not clearly require that a particular item of work be measured and the
84 12 Clause 12 Measurement and Valuation
work was described in the Contract and does not arise from a Variation, then measure-
ment does not require an additional Bill Item.
(c) If the Bill of Quantities does not contain principles of measurement for a particular item
of work and the work was described in the Contract and did not arise from a variation,
then measurement does not require an additional Bill Item’.
Items (b) and (c) above emphasizes the need for the Contractor’s estimating office to
make a study to ascertain how and where each item of work will be paid for.
The contents of this sub-clause have been re-written and expanded significantly from that
included in the equivalent clause of the First Edition.
This sub-clause opens with the basic statement that the Engineer shall ‘value each item
of work by applying the measurement agreed or determined in accordance with Sub-Clause
12.1 and Sub-Clause 12.2 and the appropriate rate or price for the item. The appropriate rate
or price for the item shall be the rate or price specified in the Bill of Quantities or if there is no
such item, specified for similar work. Any item of work . . . . for which no rate or price is speci-
fied, shall be deemed to be included in other rates and prices in the Bill of Quantities’.
The last sentence above is somewhat ambiguous. Does ‘specified’ mean that the item is
not to be separately valued, or does it mean that the item has in error not been priced by the
Contractor in the preparation of his Tender?
To clarify the matter, the Contractor could query the intention in any Q and A exchange
with the Engineer; or price the item fairly and have the issue clarified in any pre-contract
review of the Tender offer.
A new rate or price is appropriate for any item of work if:
(a) no specific rate or price is appropriate because the item of work is not of similar char-
acter or is not executed under similar conditions as any item in the Contract
(b) (i) the measured quantity of the item is changed by more than 10% from the quantity
in the Bill of Quantities
(ii) t his change in quantity multiplied by the rate or price given in the Bill of Quan-
tities exceeds by more than 0.01% of the Contract Amount
(iii) t his change in quantity directly changes the cost per unit quantity by
more than 1%
(iv) t his item is not specified in the Bill of Quantities as a ‘fixed rate item’, fixed
charge or similar term referencing to a rate or price that is subject to adjustment
for any change in quantity
(c) the work is instructed under Clause 13 (Variations and Adjustments) and sub-
paragraph (a) and (b) above applies.
Each rate shall be derived from any relevant rate or prices specified in the Bill of Quantities,
considering the matters referred to in (a), (b) or (c) above. Otherwise, the new rate or price
shall be based on the Cost of executing the Work with a profit margin of 5% added.
12.4 Omission 85
Should the Engineer and the Contractor not be able to agree the appropriate rate or price,
then the Contractor shall give a Notice of the disagreement to the Engineer and shall pro-
ceed in accordance with Sub-Clause 3.7 (Agreement or Determination) to agree or deter-
mine the appropriate rate or price.
Until such time as the rate or price is agreed, the Engineer shall assess a provisional rate
or price for the purpose of Interim Payment Certificates.
12.4 Omissions
13
The title of this clause ‘Variations and Adjustments’ is used in the First Edition and is
retained in this Second Edition but significant changes have been made to the various
sub-clauses.
A significant proportion of disputes have their origins in the formation and evaluation of
Variations.
The Contractor is required to proceed expeditiously with the Works and yet is not author-
ised to vary the Works without first receiving appropriate instructions from the Engineer.
Sub-Clause 13.1 states that the Variations will be initiated by the Engineer and Sub-
Paragraph 13.3.1 (Variations by Instruction) states that ‘the Engineer may instruct a
Variation . . .’. The Employer is not formally involved in this process although it can be
assumed that the Engineer will keep the Employer fully informed of actions taken. Should
the Employer issue instructions directly to the Contractor, then the Contractor shall imme-
diately refer the instruction directly to the Engineer for confirmation.
However, it may happen that the Particular Conditions of Contract contain wording
which requires the Engineer to obtain the formal authorisation of the Employer before
authorising a Variation (refer to the third paragraph of Sub-Clause 3.2 (Engineer’s Duty
and Authority)). Such a procedure is not in accordance with the General Conditions of
Contract. This requirement may arise because project budget is limited or insufficient.
Delays may occur whilst additional funding is obtained. Furthermore, Employers who are
Public Authorities, may require the authorisation of higher authorities.
The resultant uncertainty can leave both Contractor and the Engineer having to deal
with significant administrative uncertainties.
Variations may be initiated by the Engineer under Sub-Clause 13.3 (Variation Procedure)
at any time before the issue of the Taking-Over Certificate for the Works. However, it is
important that the Variation be issued expeditiously and not allowed to extend the Time for
Completion, ensuring that the issue of any Taking-Over Certificate is not delayed.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
88 13 Clause 13 Variations and Adjustments
The Contractor is not obligated to carry out work not within the scope of the Contract or
variation work instructed after issue of the Taking-Over Certificate. Often requests for such
extra-contractual work arise close to the conclusion of the Works, as the Employer uses
surplus funds to finance additional works not included in the original scope of the Contract.
However, the Contractor may find it sufficiently profitable to carry out these works regard-
less of their contractual status.
Any varied work performed in the Defects Notification Period may require a revised pric-
ing structure since the Contractor’s cost base existing prior to the issue of the Taking-Over
Certificate may no longer be applicable. This aspect requires a careful review by the
Contractor without undue delay.
The Contractor shall be bound by and execute the Variation with due expedition and
without delay. If the Contractor cannot comply, he shall give a Notice to the Engineer with
detailed reasons, including:
(a) the Work was Unforeseeable. Having regard to the scope and nature of the Works
described in the Specifications, the Contractor may not have the resources or the tech-
nical expertise to execute the varied works in good order.
(b) the required goods are not readily available
(c) The Contractor’s liability in respect of Sub-Clause 4.8 (Health and Safety Obligations)
and Sub-Clause 4.18 (Protection of the Environment) may be adversely affected.
These and any other issues are to be reviewed by the Engineer and instructions con-
firmed or varied.
‘Each variation may include:’
(a) ‘changes to the quantities of any item of work included in the Contract’
The Quantities of work included in the Bill of Quantities are estimates only. The final
measured quantities of work may be different. Conventionally, changes in quantities
that arise as a normal consequence of carrying out the originally planned works are
measured within the existing bill items. Changes in quantities that arise as a conse-
quence of a Variation are separately measured within the Variation.
(b) ‘changes to quality and other characteristics of any item of work’
Typically, a change in the strength of concrete may be instructed which requires a
change in cement content and aggregate grading. Other elements of costs including
placement costs may be unaltered.
(c) ‘changes to the levels, positions and/or dimensions of any part of the Works’
The quantities of work may be varied by these instructions. Some reworking is also a
possibility.
(d) ‘omission of any work’ (not to be performed by others)
Reference is to be made to the valuation procedures described in Sub-Clause 12.4.
Work that the Employer requires to be omitted from the Contract and performed by
others requires that the Employer and the Contractor make a formal supplementary
agreement to that effect. A unilateral act by the Employer would be a breach of con-
tract. The Contractor may have already incurred cost in preparing for the execution of
13.2 Value Engineerin 89
‘The Contractor may at any time submit to the Engineer a written value engineering proposal
at his own cost’ but he is under no obligation to do so. The proposal is required to meet one
or more of four given criteria:
●● it must accelerate the works
●● it must reduce the cost to the Employer
●● it must improve efficiency or value to the Employer
●● it must otherwise be of benefit to the Employer
Any proposal is to be prepared in the manner given in Sub-Clause 13.3 (Variation
Procedure) and, if accepted, the Contractor shall be responsible for design (if any).
‘The Engineer shall, after receiving the Contractor’s proposal, respond by giving a Notice
to the Contractor stating his consent or otherwise shall be at the sole discretion of the
Employer’. The sub-clause continues ‘The Contractor shall not delay any work while
awaiting a response’. It is not reasonable that the Contractor is required to take the risk
to start work and incur costs in such circumstances without (at least) the Engineer’s
consent. It would be a better approach for the Contractor to informally offer the Value
Engineering proposal and confirm the same only when the proposal is acceptable to the
Employer. If the proposed change results in a reduction in the contract value of this
part, the Contractor shall receive 50% of this value (excluding adjustments under Sub-
Clauses 13.7 and 13.8).
90 13 Clause 13 Variations and Adjustments
The same sub-clause numbering and sub-clause headings were used in the First Edition. In
this Second Edition, the original sub-clause has been divided into two parts:
Sub-Paragraph 13.3.1 (Variation by Instruction) and
Sub-Paragraph 13.3.2 (Variation by Request for Proposal)
The inference is that Variation by Instruction indicates varied work that will definitely be
required, whilst Variation by Request for Proposal indicates varied work which may or may
not be finally required.
Sub-Paragraph 13.3.1 states in part ‘. . . the Contractor shall proceed with the execution of
Variation . . . .’, whereas Sub-Paragraph 13.3.2 states in part ‘. . . the Contractor shall not
delay any work whilst awaiting a response . . . .’. In this sub-paragraph, the word ‘work’ is
understood to refer to work already instructed and in progress.
13.5 Daywork
The opening sentence of this sub-clause states: ‘If a Daywork Schedule is not included in the
Contract, this sub-clause shall not apply’. However, the subject of Daywork Schedules is not
mentioned in the Guidance for the Preparation of Particular Conditions (neither the
Contract Data or the Special Provisions). Therefore, it is incumbent on the Employer (or
the Engineer on behalf of the Employer) to provide a suitable daywork schedule in the
Tender Documents for completion by tenderers.
The United Kingdom offers a different practice which is based on a standard Daywork
Schedule. Tenderers are required to offer a percentage adjustment (plus/minus) to the
Standard Daywork Schedule. An estimate of the total value of Dayworks forms part of the
Contractor’s tender offer for tender evaluation purposes.
Frequently site disputes arise concerning the value and applicability of unit rates
for labour.
It is accepted practice that the costs of miscellaneous hand-tools, protective clothing, etc.
are to be included in the daywork-labour rates. Tenderers should clarify the cost of trans-
porting workers (including idle time) to the place where the daywork will be executed,
whether it is to form part of the labour rates or whether the transport and driver will be
paid for separately. If there is no separate provision for these costs, then the daywork-labour
rates will need to be significantly enhanced to cover these costs.
Frequently site disputes arise concerning the value and applicability of unit rates
for labour.
13.6 Adjustments for Changes in Law 93
In summary:
●● the direct cost of labour includes wages, allowances, leave pay, sick pay, protective cloth-
ing, union contribution, pension contributions
●● the gross cost of labour is essentially the direct cost plus the Contractor’s overhead costs
including profit and risk
●● the daywork rate for labour is the gross cost as above plus an allowance for travel time,
idle time, suspension, and any other factor directly related to the performance of
dayworks
The Contract requires the Contractor to provide the Engineer with daily records of
resources used in the previous day’s work. It frequently happens in international construc-
tion that the language of the Contract is the English language, but not all low-level supervi-
sors have adequate language skills to keep records of the standard required. The Contractor’s
Representative is well advised to ensure that standardised report forms are available for use
by the supervisors. Plant and Equipment fleet numbers and employee company-badge
numbers can be used to assist the supervisor to overcome language difficulties. A standard
form is provided for guidance (Appendix E refers).
It will be noted that this standard form can be utilised in a variety of situations where the
Contract requires the Contractor to keep records to support his claims, particularly those
where the Contractor is entitled to receive payment of cost.
This sub-clause has been extended and made more explicit than the comparable clause of
the First Edition.
‘The Contract Price shall be adjusted to take account of any increase or decrease in Costs
resulting from change in:’
(a) the Laws of the Country (including changed laws and new laws)
(b) the judicial or official government or implementation of Laws in (a) above
(c) changes in any permit, permission, licence, or approval as described in Sub-Clause
1.13 (Compliance with Laws), which are obtained by the Employer or Contractor
(d) changes in the requirements for any permit, permission, licence, or approval which are
obtained by the Contractor made and/or published after the Base Date.
The Employer and/or the Contractor shall give Notice to the Engineer of any adjust-
ments required with detailed particulars.
If the Contractor suffers delay or incurs an increase on Cost resulting any change in
Laws, the Contractor shall be entitled to EOT and/or payment for such cost, subject to Sub-
Clause 20.2. If there is a decrease in Cost, the Employer shall be entitled to a reduction in
the Contract Price, subject to Sub-Clause 20.2.
Tenderers are deemed to have included in their Tender Price the consequences of legisla-
tion in force on the Base Date.
94 13 Clause 13 Variations and Adjustments
To comply with the various time limitations imposed by Sub-Clause 20.2, it is most
important that the Contractor promptly obtains information concerning changes in law
having an effect on the Contract Price. It should not be overlooked that changes in law can
occur in the period between the Base Date and the award of Contract when the Contractor
may not have a presence in the country. Should the validity of tenders be extended, there is
an increasing likelihood of new legislation affecting the Contract Price being promulgated.
Most changes in legislation require a formal authorisation by Parliament or a state
authority of similar status. The authorisation typically appears within a state publication,
and it is recommended that the Contractor makes a subscription to such a publication if
available. Other sources of information are the major suppliers (e.g. fuels, cement, timber
merchants etc.), the trade unions and, not least, the local newspapers. In the preparation of
his tender, the Contractor may have already established rates and prices at the Base Date.
Evidence of these rates and prices will be required in order to quantify the consequences of
any subsequent changes in law.
Finally, it is to be noted that there may be a partial overlap between the entitlements due
under this sub-clause and the entitlements due under Sub-Clause 13.8 (Adjustment for
Changes in Cost). An appropriate adjustment in required.
This sub-clause opens with the wording ‘If Schedule(s) of cost indexation are not included in
the Contract, this sub-clause will not apply’.
Contracts without provisions for ‘Adjustment for Changes in Cost’ may be acceptable on
a short-term contract (say one year duration) but longer-term contracts will have progres-
sively higher uncertainties, and therefore represent an unacceptable risk factor which is
likely to deter Contractors from tendering.
The document ‘Notes on the Preparation of Special Provisions’ (pages 36–37) provides a
template for the calculation of adjustment for changes in cost based on the indices method.
This method is in use on the most projects using FIDIC documentation.
In most contracts the Contractor is entitled to claim reimbursement of the increase in
cost on a limited number of key items, labour, steel, bitumen, cement, etc. In such circum-
stances, the Contractor will have to include in his Tender Offer an allowance for all other
items not specified. The FIDIC document ‘Notes on the Preparation of Special Provisions’
identified above recognises this problem by proposing a factor labelled ‘fixed’ and with a
coefficient of 0.10 as provision for ‘all items not specified’.
The Contractor should take care to select indices whose values are readily available from
official sources. Other factors which could affect the choice of indices are the currency of
payment and the currency in which the Contractor expects to incur most of his expenditure.
Fluctuations in the relative values of currencies are frequently of concern to contractors.
Many contracts specify a fixed exchange rate between local and the selected foreign cur-
rency. The real exchange rate may during the execution of the Contract become markedly
different, often to the Contractor’s disadvantage. There is no remedy in the standard
General Conditions of Contract for currency fluctuations and the Contractor may find it
opportune to take precautionary measures. The advance purchase of foreign currency
13.7 Adjustment for Changes in Cos 95
options is one possible course of action to minimise the effects of any currency fluctua-
tions. Every effort should be made to avoid the use of general indices, such as cost-of-living
index which is unlikely to be representative of the changes in cost of material, labour,
plant, and equipment used in construction.
Occasionally, it may happen that one element of cost may increase dramatically for rea-
sons that could not have been foreseen at the Base Date. Unless this cost element is included
in whole or in part of one of the indices used to calculate the changes in cost, the Contractor
is left with a problem, since there is no other clause in the Contract that provides an alter-
native means of compensation. In equity, it is also correct to state that a dramatic decrease
in costs would produce the opposite effect. The only remedy may lie in the laws of the
country.
The values of the various indices are prepared by various international agencies and the
appropriate Government authorities. It takes time to collect, analyse, and publish the indi-
ces. Typically, there is a delay of two to three months before the updated indices are avail-
able. In preparing his monthly evaluation of changes in cost (for inclusion in the Monthly
Payment Application), the Contractor should use the latest available value of the index as
an interim measure to calculate the changes in cost for the months where data is not yet
available. These interim values are to be adjusted once the correct values of the indices
become available.
97
14
The Contract Price is the value of the Works performed in accordance with the Contract at
any stage of the Contract. To facilitate payment to the Contractor, the Contract Price is
routinely calculated at calendar month intervals (refer to Sub‐Clause 14.3 (Application for
Interim Payment Certificates)).
(a) The Contract Price shall be evaluated in accordance with Sub‐Clause 12.3 and is subject
to adjustments in accordance with the Contract.
(b) The Contractor shall pay all taxes, duties, and fees. The cost is deemed to be included
in the Contract Price.
(c) Quantities set out in the Bill of Quantities are estimated quantities and are not to be
taken as the actual and correct quantities to be executed.
(d) Within 28 days of Commencement Date the Contractor is required to provide a price
breakdown for each lump sum. Although not so stated, it may be assumed that these
price breakdowns are required for using them in the preparation of the monthly
Application for Interim Payment. The Contractor’s tender office should be requested to
supply this detailed information, as it may not be available on Site.
14.2 Advance Payment
The Employer shall make an advance payment as an interest‐free loan for mobilisation.
The amount of the advance payment (10% of the Contract Price is the norm) shall be paid
as stated in the Contract Data (Notes on the Preparation of Special Provisions, Annex E,
Page 63 refers).
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
98 14 Clause 14 Price and Payment
Deductions will commence when the running total of IPCs exceeds 10% of the
Accepted Contract Amount (less Provisional Sums). Thereafter deductions will be made
at a rate of 25% from each of the subsequent IPCs (excluding the advance payment itself
and any release of retention money) until the total of the advance payment has been
repaid).
Typically, the advance payment will have been repaid when approximately 75–80% of the
Works have been completed. However, if the total of the advance payment has not been
repaid before the issue of the Taking-Over Certificate, then the whole of the balance still
outstanding shall immediately become due and payable by the Contractor. The Employer
may use the Advance Payment Guarantee to make good the deficit. Alternatively, the
Contractor may agree that any return of retention money to which he may be entitled can
be used to pay the outstanding amount of Advance Payment.
The First Edition required that a copy of the Progress Report be provided as part of the sup-
porting documents for any Application for Interim Payment Certificates. This requirement
has been deleted in the Second Edition.
The Contractor is required to submit a Statement to the Engineer after the end of each
month, showing in detail the amounts to which the Contractor considers himself to be
entitled, together with all supporting documents including the report described in Sub‐
Clause 4.21 ‘Progress Reports’. The above extract quite clearly entitles the Contractor to
include in his application the amounts to which he, the Contractor, considers himself enti-
tled. The preparation of the corresponding Interim Payment Certificate for presentation by
the Engineer to the Employer is the duty and responsibility of the Engineer and does not
contractually involve the Contractor. Despite this wording, invariably the Engineer and/or
the Employer require the Contractor to modify his application to conform to the certifica-
tion of the Engineer. In some jurisdictions the Employer requires the Contractor to sign the
Engineer’s Interim Payment Certificate in order to comply with the Employer’s internal
accountancy procedures. This comment particularly applies where the Employer is a gov-
ernment agency or parastatal company. This procedure is not provided for in the Conditions
of Contract and Employers generally do not consider it necessary to specify their precise
requirements by including modified clauses in the Particular Conditions of Contract. Sub‐
Clause 14.3 (c) clearly states in part (the Contractor shall show) ‘in detail the amount [he]
considers himself to be entitled . . .’. Doubt may arise that, by signing, the Contractor accepts
the Engineer’s figures to represent his full entitlement.
Regrettably, this non‐contractual process often can obscure and diminish the very real
concerns that the Contractor may have in respect of unpaid items and disputes. Under the
circumstances described above, it is recommended that the Contractor prepare a further
listing of claims and other unresolved issues and their valuations not included in the
Engineer’s Interim Payment Certificate. This letter is to be sent to the Engineer, copy to the
Employer, stating that ‘the listing is a summary of all claims and unresolved issues and
their valuations as at (date) which are not included in the Engineer’s Interim Payment
Certificate No . . . . for the month of . . . ’.
100 14 Clause 14 Price and Payment
This listing should be prepared in sufficient detail to comply with the requirements of
Sub‐Clause 4.20 (f), as this will avoid duplication of effort.
The Contractor’s Statement shall include:
(a) the estimated contract value of the Works produced up to the end of the month. This is
essentially a measurement of the items included in the Bill of Quantities. Most of the
measurement will relate to physical work, but some administrative items are likely to
require evaluation.
(b) ‘any amounts to be added or deducted for changes in legislation (Sub‐Clause 13.7) and
changes in cost (Sub‐Clause 13.8)’
(c) Any amount to be deducted for retention up to the limit stated in the Contract Data
(Page 5, Limit of Retention). A partial Taking Over of the Works would entitle the
Contractor to a partial return of retention (refer to Sub‐Clause 14.9).
(d) ‘any amounts to be added and deducted for the advance payment and repayments’
(e) ‘any amounts to be added and deducted for Plant and Materials conforming to the
requirements of Sub‐Clause14.5’
(f) ‘any other additions or deductions due under the Contract’ including claims, variations,
dayworks
(g) previous certified amounts shall be deducted.
It is strongly recommended that the Contractor does not wait until the last day of the
month before commencing the preparation of this Statement. Many items can be measured
as the Works proceed: field surveys can be made; administrative payment items such as
invoices can be prepared in advance etc.
The Contractor could consider commencement of the measurement by the 25th day of
each month. Draft copies of the sections of the measurement could be submitted to the
Engineer’s staff in a progressive manner for checking, the last few items being quickly
evaluated at the month’s end.
Particularly in respect of uncomplicated projects, the Engineer’s measurement staff
should not require the full allowed period of 28 days to agree an interim measurement for
the purposes of producing a pre‐agreed Statement and Interim payment Certificate. Both
the Engineer’s and Contractor’s staff entrusted with this task should have a clear under-
standing of the significance of the word ‘interim’ as used in this sub‐clause. However, it
is an unfortunate fact that in many countries even the interim measurements must be
precise and wholly accurate even though they will be out of date before they are finalised.
therefore require their own separate Schedule of Payments to be prepared once the
Subcontract is finalised.
A Schedule of Payments may require adjustment if:
(a) the Contractor’s proposed Schedule of Payments requires adjustment if it is shown to
be inaccurate. Considering that the Engineer (Design) will have produced both an ini-
tial programme of work and cost estimates for use by the Employer in the preparation
of the Tender documents, the accuracy of the Contractor’s own proposal could be
assessed reasonably well, avoiding the formal time‐consuming negotiation process
envisaged in the penultimate paragraph of this sub‐clause.
(b) There may be programme slippages (whatever the cause) which will delay the Works
and the Contractor’s earnings.
The last clause envisages a contract arrangement wherein the Contractor provides the
Engineer with estimates of payments to become due in the next three months. Revised esti-
mates are to be submitted at three monthly intervals. Over/under‐estimates may be expected.
This arrangement is best limited to short term contracts with repetitive work dominant.
This sub‐clause provides for the Interim Payment Certificates to include amounts for Plant
and Materials that have been delivered to Site for incorporation in the Permanent Works.
Payments under this sub‐clause may be limited to specific items of Plants and Materials
identified in the Contract Data (Page 5) which are categorised as:
(1) Plant and Materials for payment when shipped or
(2) Plant and Materials when delivered to the Site
These descriptions are repeated in the text of Sub‐Clause 14.5 and additional wording
added requiring that these interim amounts be deducted when the Plant and Materials are
included in the Permanent Works, when payment in full becomes due.
It is not practical for every minor item to be considered, not least because the administra-
tive costs would probably exceed the potential benefits to the Contractor.
In respect of Plant and Materials to be shipped to the Site from another country, two pos-
sibilities exist:
(a) Payment is permitted once the Plant and Materials are shipped but not yet delivered to
Site. A bank guarantee similar to that required for Advance Payment (Sub‐Clause 14.2)
has to be provided. This guarantee must be valid until the Plant and Materials are on
site and safely stored and protected.
(b) Payment is permitted once the Plant and Materials are on site and safely stored and
protected.
The Contractor will be required to produce documentary evidence of costs and evidence
demonstrating that the Plant and Materials are in conformity with the Contract. The latter
requirement may demand testing and/or inspection certification on or off the Site.
102 14 Clause 14 Price and Payment
More commonly the above requirements will permit payment for other permanent mate-
rials (e.g. cement, bitumen, reinforcement etc.) purchased locally and delivered to Site. In
addition, payment may be due for permanent materials manufactured on site by the
Contractor. Typically, this would include crushed stone, precast items and similar. Again,
evidence of cost and evidence of conformity with the contract specifications are required.
The cost of materials manufactured by the Contractor will have to be negotiated with the
Engineer.
Materials on Site will be progressively consumed as the Works proceed but will be
replaced as new Materials are manufactured. Consequently, the value of Materials on Site
will rise or fall when compared with the value at the end of the previous month. Eventually
the value will become zero as the operations incorporating the Materials on Site are
completed.
Plant on Site will eventually be installed as the Works proceed and will become included
in the bill items forming part of the IPC.
In all cases the amount to be certified by the Engineer is the equivalent of 80% of the
agreed amounts. The currency split will be the same as provided in the relevant Bill of
Quantities item.
Proof of ownership of Plant and Materials can be problematic, particularly if the subcon-
tractors and sub‐suppliers are involved. Sub‐Clause 7.7 recognises that there may be prob-
lems: Each item of Plant and Materials shall, to the extent consistent with the Laws of the
Country, become the property of the Employer . . . ’. This is potentially a complex issue, and
the Employer may require additional guarantees from the Contractor in order to protect his
interests.
It is a pre‐condition that no amount will be certified or paid to the Contractor until the
Contractor has provided the Employer with the Performance Security (Sub‐Paragraph
4.2.1) and the Contractor has appointed the Contractor’s Representative (Sub‐Clause 4.3).
It is noted that these pre‐conditions do not apply to the Advance Payment (Sub‐
Clause 14.2).
for Interim Payment (Sub‐Clause 14.3). A similar situation may arise closer to the date by
which the Engineer anticipates the Taking-Over Certificate will be issued. Whilst not
obliged to do, the Employer may decide to allow the Engineer to issue the IPC.
Once the Taking-Over Certificate issued, no such restriction exists. Retention Money is
to be repaid to the Contractor together with any residual amounts due for minor outstand-
ing work and claim settlements. Following discussions with the Engineer, an additional
IPC may be required.
14.7 Payment
14.8 Delayed Payment
Employers may be reliant on project financing from external funding agencies with which
to make payments to the Contractor. Occasionally it may happen that the Employer experi-
ences administrative difficulties in the timely provision of those funds and is unable to pay
the Contractor as required. Funding agencies are reluctant to allow their funding to be used
for payment of financing charges to the Contractor.
104 14 Clause 14 Price and Payment
‘If the Contractor does not receive payment in accordance with Sub‐Clause 14.7 above, he is
entitled to payment of financial charges at an annual rate of three percent above:
–– the average bank short‐term lending rate to prime borrowers for the currency of payment at
the place of payment or
–– where no such rate exists at that place, the same rate in the currency of the country of
payment or
–– in the absence of such rate at a place, the appropriate rate fixed by law of the country of the
currency of payment.
The period of delay is deemed to commence on the expiry of the time for payment (Sub‐
Clause 14.7)’.
The Contractor is not required to submit a Statement or formal Notice.
‘Within 84 days after receiving the Date of Completion for (the whole of) the Works, the
Contractor shall submit to the Engineer a Statement at Completion showing’
(a) ‘the value of all works done in accordance with the Contract at the date of the Taking-
Over Certificate’. This would include the measured works, the value of varied works
performed, the value of accepted claims, as well as any amounts due under Sub‐Clauses
13.7 (Changes in Legislation) and 13.8 (Changes in Cost).
(b) ‘any further sums which the Contractor considers to be due’. This would include an
estimate of the value of unresolved claims including ongoing measurement disputes.
(c) ‘an estimate of any other amounts which the Contractor considers may become due to
him under the Contract’. This would include the value of ongoing events and claims
after the date of issue of the Date of Completion of the Works. The value of any out-
standing work should also be included. It is not for the Contractor to anticipate any
future additional work which might be instructed by the Engineer.
The Statement on Completion shall include:
–– claims for which the Contractor has submitted a Notice under Sub‐Clause 20.2
(Claims for Payment and EOT)
–– any matter referred to the DAAB under Sub‐Clause 21.4 (Obtaining DAAB Decision)
–– any matter for which a NOD has been given under Sub‐Clause 21.4 (Obtaining a
DAAB Decision)
It is important that the Contractor evaluates the Statement at Completion accurately.
It represents the maximum revenue that could be due to him and equally indicates to
the Employer the likely maximum amount of his financing commitment.
14.11 Final Statement
●● show in detail
(i) the value of all work done in accordance with the Contract
At this stage of the Contract the final measurement of the Works should be com-
plete excepting for very few outstanding items. In effect it is a minor updating of the
penultimate IPC.
(ii) any further sums which the Contractor considers to be due at the date of the issue
of the Performance Certificate
During the Defects Notification Period it is likely that the Contractor will have exe-
cuted a number of minor works (not being repairs of defects) for which the
Contractor is entitled payment. It is likely that the sums involved are minor. Also, it
is possible that some administrative items (not previously quantifiable) are to
be added.
(iii) an estimate of any other amounts which the Contractor has or will become due after
the issue of the Performance Certificate
This estimate will be the total amount of unresolved Contractor claims including
those which may have been referred as a Dispute to the DAAB. The Engineer will be
aware of these claims and their value. However, should the Engineer disagree or be
unable to verify any part of the Contractor’s Draft Final Statement, then by Notice
to the Contractor he may request clarification or further details.
If there are no amounts under sub‐section (iii) of Sub‐Paragraph 14.11.1, then the
Contractor shall prepare and submit to the Engineer the Final Statement. At this stage of
the Contract, it may be assumed that the Employer and the Contractor would agree to dis-
cuss outstanding issues and reach an amicable solution.
However, if outstanding issues are not resolved, then the Contractor shall prepare and
submit to the Engineer a Partially Agreed Final Statement, identifying separately the esti-
mated amounts and the disagreed amounts.
14.12 Discharge
When submitting the Final Statement (or the Partially Agreed Final Statement) the
Contractor shall provide written confirmation (a letter of ‘discharge’) that the total of the
Statement is a final and full settlement of all moneys due to the Contractor under or in con-
nection with the Contract, excluding any amount that may become due in respect of any
Dispute for which a DAAB proceeding or arbitration is in progress.
The letter of discharge should also state that it becomes effective upon the Contractor
receiving the full amount certified in the Final Payment Certificate (FPC) and the
Performance Security has been returned.
In consideration of the importance of this letter of discharge, it is recommended that the
drafting of the letter be provided by the Contractor’s legal advisors. The preparation and
submittal of the letter of discharge should not be unduly delayed, as the discharge is stated
14.15 Currencies of Paymen 107
to be effective once the Final IPC has been paid and the Performance Security returned.
The above does not affect either party’s liability or entitlement in respect of any dispute
which is in progress (ref. Clause 21 (Disputes and Arbitration)).
Within 28 days after receiving the Final Statement (or the Partially Agreed Final Statement)
the Engineer shall issue the Final Payment Certificate (FPC) which shall:
(a) state the amount which the Engineer considers is finally due to the Contractor after
giving credit to the Employer for all amounts already paid by him
(b) give due allowance for other debits and credits due between the parties.
If the Contractor has not provided a Draft Final Statement within the time specified
under Sub‐Paragraph 14.11.1 (Draft Final Statement), the Engineer shall again request the
Contractor to do so. Should the Contractor not respond within a further period of 28 days,
the Engineer shall issue the FPC for the amount the Engineer considers is due.
However, if the Contractor has submitted a Partially Agreed Final Statement or, alterna-
tively, if the Contractor has submitted a Draft Final Statement (Sub‐Paragraph 14.11.1
refers) which corresponds to the Partially Agreed Final Statement, the Engineer shall pro-
ceed in accordance with Sub‐Clause 14.6 (Issue of IPC), to issue an IPC.
Contractors should be aware that a failure to cooperate with the Engineer to follow the
specified procedures leading to the issue of a FPC will not prevent the Engineer fulfilling
his contractual duties.
‘The Employer shall not be liable to the Contractor for any matter or thing in connection with
the Contract, excepting to the extent that the Contractor shall have included an amount
expressedly for it
(a) in the Final Statement (or Partially Agreed Statement)
(b) except for matters arising after the issue of the Taking-Over Certificate (refer Sub‐Clause
14.10) in the Statement described in Sub‐Clause 14.10’.
The contents of this Sub‐Clause emphasize the obligation of the Contractor to check the
Final Statement very carefully to ensure that he has included for all claims and payment
issues (refer Sub‐Clause 14.10).
This sub‐clause does not limit any liability of the Employer in respect of his indemnifica-
tion obligations or liability arising from fraud, deliberate default, or reckless misconduct.
The Advance Payment (refer Sub‐Clause 14.2) will be paid in the same proportions
unless otherwise stated or agreed.
(i) Any taxes, duties and fees which are to be paid by the Contractor and are
known to him at the date of tender will likely have been allowed for in the cal-
culation of general overheads. However, if new taxes are introduced or existing
taxes increased, then the Contractor would be entitled to make a formal claim
of the additional expenditure.
(ii) The calculation of the amounts due for works described as Provisional Sums
(refer Sub‐Clause 13.4) is dependent on the type of work to be carried out. For-
eign currency may be expended for imported industrial goods, whilst site activi-
ties may be valued at existing bill rates. Consequently, payment for Provisional
Sums may have a unique local/foreign currency split.
It is recommended that the Contractor ensures that all quotations, invoices, or
services from foreign suppliers are priced solely in the local currency or the for-
eign currency of the Contract. This procedure will avoid any time‐wasting verify-
ing exchange rates between differing foreign currencies.
Adjustments for Changes in Law (ref. Sub‐Clause 13.6) refer to local changes
which might be promulgated in a State Gazette or similar official document.
These changes may affect the price of petroleum products, cement prices, labour
rates and conditions. The amount of any increase (or decrease) in cost would be
evaluated in local currency only.
(iii) The following items shall be paid (or repaid) in the same currency proportions
as given in the Contract Data Item 14.15 (a)(i)
–– the value of work executed
–– the amounts to be deducted for Retention and the amounts of Retention
returned
–– the amount of advance made and subsequent repayment
(b) Whenever an adjustment (Value Engineering or Variation) is agreed, the applicable
currencies shall be specified.
(c) Payment of Delay Damages shall be made in the proportions specified in the Contract
Data (Page 6, Items 14/15c)
(d) Other payments to the Employer by the Contractor shall be made in the currency spec-
ified in the Contract (where not otherwise identified).
(e) If in any given period the Contractor has a net debit in favour of the Employer in one
of the contract currencies, the Employer may recover the balance in another currency.
(f) Exchange rates not stated in the Contract Data shall, if required, be those prevailing in
the Base Data and published by the central bank of the country.
The Contractor should give consideration as to how he might protect himself against
excessive exchange rate fluctuations during the execution of the Contract.
109
15
Note:
This Clause deals with two differing causes which may give rise to a termination of the
Contract:
●● Sub‐Clause 15.2 (et al.) deals with termination of the Contract because of the
Contractor’s Default.
●● Sub‐Clause 15.5 (et al.) deals with termination of the Contract for the Employer’s
convenience.
In addition, termination of the Contract by the Contractor due to default of the Employer
is described in Clause 16, and termination of the Contract as a consequence of an Exceptional
Event is described in Sub‐Clause 18.5 (Optional Termination). The obligations and entitle-
ments of the Parties vary considerably, according to the reasons causing the termination.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
110 15 Clause 15 Termination by the Employer
Contractor. The overall intent should be to identify and execute the correct solution with
minimum delay.
Consequently, this Sub‐Clause 15.1 should only be actioned when other solutions are
exhausted. The remaining portion of this sub‐clause specifies the intended contents of the
Notice to Correct.
15.2.1 Notice
‘The Employer shall be entitled to give a . . . Notice. . . of the Employer’s intention to terminate
the Contract. . . or in the case of sub‐paragraph (f), (g) or (h) below a Notice of Termination’
(underscoring added).
The implication is that should the Contractor take the appropriate corrective action in
respect of items (a) to (e), the Employer may reconsider whether to terminate the Contract.
However, the matters referred to in items (f) to (h) cannot be corrected and the Contract is
to be terminated if the Contractor
(a) fails to comply with:
(i) a Notice to Correct
(ii) a binding agreement under Sub‐Clause 3.7
(iii) a decision of the DAAB under Sub‐Clause 21.4
and such failure constitutes a material breach of the Contractor’s obligations under the
Contract.
(b) abandons the Works
(c) without release fails to proceed with the Works in accordance with Clause 8
(Commencement, Delays and Suspension) or
the Contractor’s failure to comply with Clause 8 entitles the Employer to Delay
Damages in excess of the maximum stated in the Contract Data
(d) fails to comply with a Notice of Rejection (Sub‐Clause 7.5)
(e) fails to comply with Sub‐Clause 4.2 (Performance Security). The Performance Security
is a key financial security specifically intended to ensure completion of the Works.
(f) subcontracts the whole or part of the Works without permission (ref. Sub‐Clause 1.7
(Assignment))
It is a not uncommon ply that a Contractor in financial difficulties will engage sub‐
contract labour without the knowledge or permission of the Engineer. Almost inevita-
bly the subcontractor will not be paid and will leave the site without notice.
(g) becomes bankrupt or insolvent etc.
It frequently happens that the contract revenues projected by the Contractor are being
achieved. However, other contracts or financial issues are draining the Contractor’s
resources to an extent that his whole business becomes insolvent leading to bankruptcy.
or if the Contractor is a JV
15.2 Termination for Contractor’s Defaul 111
15.2.2 Termination
Unless the Contractor remedies the matter described in Sub‐Paragraph 15.2.1 (Notice)
within 14 days or receiving the Notice, the Employer may by giving a second Notice to the
Contractor immediately terminate the Contract. The date of termination shall be the date
the Contractor receives this second Notice.
However, in the case of Sub‐Paragraph 15.2.1 items (f), (g) or (h) the Employer may by
giving a Notice immediately terminate the Contract. The date of termination shall be the
date the Contractor receives the Notice.
The Notice of Termination should be delivered by hand or courier to the Contractor’s
registered address and a signed and dated receipt obtained.
As soon as the Termination is announced, the site must be secured by the Employer in
order to prevent the removal of any item that is not personal.
The above requirements do not reflect the reality of a Contract that is terminated for
several reasons, including:
1. It will be very difficult to persuade the Contractor’s employees to remain on Site, not
least because they will be concerned that their salaries/wages will not be paid. Any
expatriate staff are likely to request repatriation to their own countries. The Contractor’s
staff are to be allowed to remove their personal belongings without hindrance.
2. It is important that the Site is immediately secured by the Employer’s own personnel.
The Employer should prepare for this eventuality in advance of the issuing of the Notice
of termination.
3. A full inventory of the Site is to be taken, including:
●● All Contractor’s Goods (refer also to Sub‐Clause 4.17)
IPC. Suppliers’ materials delivered to Site but not yet paid for should not be removed.
However, if it is intended that a replacement contractor shall use the materials, the
Employer should pay for them.
4. The condition of the Site must be accurately recorded. The quantities of work properly
performed at the Date of Termination are also to be recorded. This will enable a bill of
quantities required for a replacement contract to be quickly drawn up.
‘Following termination of the Contract the Engineer shall proceed to agree or determine the
value of the Permanent Works, Goods and Contract Documents and any other sums due to the
Contractor for work executed in accordance with the Contract. This valuation shall not
include the value of any Contract Documents, Materials, Plant and Permanent Works to the
extent they do not comply with the Contract’.
Sub‐Clauses 15.3 (Valuation After Termination for Contractor’s Default) and Sub‐Clause
15.4 (Payment After Termination for Contractor’s Default) describe how the Employer’s
15.5 Termination for Employer’s Convenienc 113
entitlement to recovery of additional costs, losses and damages and Delay Damages shall
be evaluated. Inevitably, this process will be a lengthy and complex process. Sub‐Clause
15.4 describes how the elements of Employer’s Costs shall be evaluated, which notably
includes provision for payment of Delay Damages.
If the Contractor is bankrupt and without appropriate staff, it is not clear who will repre-
sent the Contractor in these matters.
The Employer may withhold payment to the Contractor of the amounts agreed or deter-
mined under Sub‐Clause 15.3 until the following have been established:
(a) the additional costs of executing the (remaining) Works
(b) any losses and damages suffered by the Employer in completing the Works.
(Prolongation costs in respect of Employer’s personnel may be significant.)
(c) Delay Damages
Unless and until the Contractor has received any amounts due under Sub‐Clause 15.6,
the Employer shall not execute (or arrange for others to execute) any part of the Works.
After termination the Contractor shall proceed in accordance with Sub‐Clause 16.3.
The Employer will pay the Contractor the amount certified under Sub‐Clause 15.6 within
112 days after the Engineer receives the Contractor’s submission under that sub‐clause.
115
16
This sub-clause identifies four potential breaches of the Employer’s contractual obligations
which would entitle the Contractor to suspend the Works:
(a) the Engineer fails to certify in accordance with Sub-Clause 14.6 (Issue of IPC)
(b) the Employer fails to provide evidence of his financial arrangements in the Contract
Data (Sub-Clause 2.4 (Employer’s Financial Arrangements))
(c) the Employer fails to comply with Sub-Clause 14.7 (Payment)
(d) the Employer fails to comply with binding agreements (Sub-Clause 3.7 (Agreement or
Determination)) or a decision of the DAAB (Sub-Clause 21.4 (Obtaining DAAB’s
Decision)).
All four headings relate to financial events which would delay or deprive the Contractor
of payments rightfully due under the terms of the Contract. Disruptions to the Contractor’s
cash-flow can have unintended consequences to the routine progress of the Works on
resumption of the Works.
Public authority employers with financing provided by international financing agencies
are less likely to interrupt the Contractor’s cash-flow. However, contracts to be executed
using private funding may cause the Contractor to request strong financial guarantees from
the investor.
In the event of a breach of contract by the Employer as described above, the Contractor
is entitled to give the Employer a Notice of Suspension of the Works. The Notice of
Suspension becomes effective not less than 21 days after the giving of the Notice. The sus-
pension continues until the Employer rectifies the default, after which normal working
shall recommence as soon as possible.
The Contractor is entitled to payment of financial charges as a consequence of the delay
in payment (Sub-Clause 14.8 (Delayed Payment)).
The Contractor is also entitled to reimbursement of any additional costs plus profit
incurred because of the suspension of the Works and to EOT (Sub-Clause 20.2 (Claims for
Payment and/or EOT)). Additional costs arising from a suspension of the Works are likely
to far exceed the additional financing costs.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
116 16 Clause 16 Suspension and Termination by the Contractor
‘Termination of the Contract under this Clause shall not prejudice any other rights of the
Contractor, under the Contract or otherwise’.
16.2.1 Notice
This sub-clause identifies 11 causes which entitle the Contractor to either
A give a Notice to the Employer which shall state that it is given under this sub-clause
with an intention to terminate the Contract. This wording implies that the Contractor
intends to terminate the Contract unless the Employer corrects the defaults within a
reasonable time
or
B give a Notice to the Employer which states that the Contractor is terminating the
Contract.
Items falling under Category A above:
(a) the Employer does not provide evidence of financial arrangements
(b) the Engineer fails to issue IPC
(c) the Contractor does not receive amount due under any Payment Certificate within
42 days after expiry of time for payment
(d) the Employer fails to comply with
(i) a binding agreement made under Sub-Clause 3.7
(ii) a decision of the DAAB under Sub-Clause 21.4
(e) the Employer substantially fails to perform (a material breach of the Employer’s obli-
gations under the Contract)
(f) the Contractor does not receive a Notice of Commencement Date
(g) (i) the Employer fails to comply with Sub-Clause 1.6 (Contract Agreement)
Items falling under Category B above
(g) (ii) the Employer assigns the Contract without the required agreement under Sub-
Clause 1.7 (Assignment)
(h) a prolonged suspension affects the whole of the Works as described in Sub-Clause 8.12
(Prolonged Suspension)
(i) the Employer becomes bankrupt or insolvent
(j) the Employer is engaged in corrupt, fraudulent, etc. practice
16.2.2 Termination
Before taking action under this sub-clause, it would be appropriate for the Contractor to
obtain legal advice to ensure that the giving of a Notice is legally sound.
(a) Unless the Employer remedies any matter described in the Contractor’ 14 days of
receiving the Notice, the Contractor may terminate the Contract by giving a second
Notice to the Employer. The date of termination shall be the date on which the
Employer receives this second Notice.
16.4 Payment after Termination by the Contracto 117
(b) In the case of any matter referred to in Sub-Clause 16.2.1 Category B above, the
Contractor, by giving a Notice to the Employer, may immediately terminate the
Contract. The date of termination shall be the date on which the Employer receives
this Notice.
If the Contractor suffers delay or incurs cost in the 14 days period ((a) above), then the
Contractor shall be entitled to payment of Costs with Profit and EOT.
‘After Termination under Sub-Clause 16.2 (Termination by Contractor), the Employer shall
promptly
(a) pay the Contractor in accordance with Sub-Clause 18.5 (Optional Termination) and
(b) subject to the Contractor’s compliance with Sub-Clause 20.2 (Claims for Payment and/or
EOT) pay the Contractor the amount of any loss of profit or other losses suffered by the
Contractor as a result of this termination’.
In addition to the above, the routine Measurement and Valuation (Clause 12) including
Variations, Claims, etc. have also to be finalised and agreed.
119
17
This clause was titled ‘Risk and Responsibility’ in the First Edition, and in this edition, it
has been re‐written and re‐titled.
The separation of Employer’s Risks and Contractor’s Risks is clearly stated and a new
sub‐clause, Sub‐Clause 17.6 (Shared Indemnities) has been added.
This sub‐clause provides the basic requirement that the Contractor shall be fully responsi-
ble for the care of the Works, Goods and Contractor’s Documents from the Commencement
Date until the Date of Completion of the Works (i.e. the date stated in the Taking‐Over
Certificate issued by the Engineer). On receipt of the Taking‐Over Certificate, the Contractor
will advise the Insurance provider and responsibility for the Works will pass to the
Employer.
However, the Contractor remains responsible for the care of any outstanding work until
completed. The Contractor should ensure that the satisfactory completion of outstanding
work is signed off by the Engineer. The date of the handover is to be agreed and recorded.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
120 17 Clause 17 Care of the Works and Indemnities
of the following events (excepting to the extent that such Works, Goods, or Contractor’s
Documents have been rejected under Sub‐Clause 7.5 (Defects and Rejection):
(a) interference, whether temporary or permanent, with any right of way, light, air, water,
or other easement (other than that resulting from the Contractor’s method of construc-
tion) which is the unavoidable result of the execution of the Works in accordance with
the Contract
(b) use of occupation by the Employer of any part of the Permanent Works except as may
be specified in the Contract
(c) fault, error, defect, etc. in any element of the design. . . ‘which an experienced contractor. . .
would not have discovered when examining the Site and the Specification and Drawings. . .’.
It has been long pointed out that given the limited time, the Contractor is given to pre-
pare his tender offer, the possibility of the Contractor identifying errors in the Employer’s
design are limited. Additionally, the Contractor’s staff are not necessarily experienced
designers as are the Employer’s designers. Any errors and omissions detected in the prep-
aration of tenders are conventionally addressed either in the official site visits prior to
tender or by written correspondence addressed to the Employer.
(d) the Contractor is liable for the consequences of forces of nature which are allocated to
him in the Contract Data. It can be expected that the dominant force of nature identified
in the Contract Data will relate to hydraulic issues (river flows, cofferdam designs, mon-
soon weather etc.). The insurance provider will have his own engineering team to advise
him in relation to these issues and can be expected to request a significant amount of
detailed information from both the Employer and the Contractor.
A further source of difficulty can arise from heavy rainstorms including monsoon
weather. It is advisable that the Contractor identifies official weather stations in the
general area of a given project and obtains past weather data from those weather sta-
tions that can be studied, and the potential risk assessed. Records of past river flows
provide essential information to the insurers, designers, and those engaged in the
actual construction.
A decision whether an experienced contractor could reasonably be expected to have
taken adequate precautions is often largely based on historical records.
(e) any of the events or circumstances identified in Sub‐Clause 18.1 (Exceptional Events)
(f) any act or default of the Employer’s personnel.
If any of the events listed above occur and cause damage, the Contractor shall promptly
give a Notice to the Engineer. Thereafter the Contractor shall repair the damage in accord-
ance with the Engineer’s instructions. However, it frequently happens that an individual
event may happen very quickly, requiring emergency measures to be taken without delay
to protect lives and property.
In such an event, Contract formalities may have to be suspended temporarily. The
Contractor should keep all appropriate records and liaise very closely with the Engineer in
any on‐going emergency.
The Contractor shall, subject to Sub‐Clause 20.2 (Claims for Payment and/or EOT), be
entitled to payment of cost and award of an EOT. Should the Contractor be partly respon-
sible for the cause of the event, then a proportional payment only shall be made to the
Contractor.
17.4 Indemnities by Contracto 121
Note:
Sub‐Clause 18.4 (Exceptional Events) lists ‘Exceptional Events’ as not foreseeable events at
Base Date and are to be administered in a different manner to those events described above.
The Contractor indemnifies the Employer from third party claims in respect of:
(a) bodily injury, sickness, disease, or death of any person arising from the Contractor’s
execution of the Works unless attributable to any wilful act or breach of the Contract
by the Employer, the Employer’s Personnel, or any of their respective agents
or
(b) damage to or loss of property (real or personal) (other than the Works) which arises by
reason of the Contractor’s execution of the Works and is attributable to any negligence,
wilful act, or breach by the Contractor.
In addition, the Contractor will indemnify the Employer against all acts, errors, or omis-
sions by the Contractor in carrying out the Contractor’s design obligations (if any) that
results in the Works (or Section or Part or major item of Plant), when completed, not being
fit for their intended purpose.
122 17 Clause 17 Care of the Works and Indemnities
The Employer indemnifies the Contractor and his staff from third party claims in terms of
(a) bodily injury, sickness, disease, or death which is attributable to any negligence, wilful
act or breach of the Contract by the Employer
or
(b) damage to or loss of any property (other than the Works) to the extent that such dam-
age or loss arises out of any event described under sub‐paragraph (a) to (f) of
Sub‐Clause 17.2 (Liability for Care of the Works)
This provision for ‘Shared Indemnities’ is introduced for the first time in this Second
Edition.
The Contractor’s liability to indemnify the Employer under Sub‐Clause 17.4 (Indemnities
by Contractor) and/or under Sub‐Clause 17.3 (Intellectual and Industrial Property Rights)
shall be reduced proportionately to the extent that any event described under sub‐
paragraphs (a) to (f) of Sub‐Clause 17.2 may have contributed to the said damage, loss,
or injury.
Similarly, the Employer’s liability to indemnify the Contractor under Sub‐Clause 17.5
(Indemnities by Employer) shall be reduced proportionately to the extent described under
Sub‐Clause 17.1 (Responsibility for Care of the Works) and/or under Sub‐Clause 17.3 may
have contributed to the said damage, loss, or injury.
Claims falling under the above headings are uncommon. The Employer and Contractor
have a joint interest in disputing any third‐party claim and the amount thereof. Should
amounts have to be paid to a third party and the parties cannot agree proportionate respon-
sibility, it may be mutually convenient for the DAAB to give their opinion in the matter as
described in Sub‐Clause 21.3 (Avoidance of Disputes).
123
18
In the First Edition, this clause was titled ‘Force Majeure’ and numbered Clause 19.
However, the general content of this clause is similar to that previously provided.
18.1 Exceptional Events
Provided that the above conditions are met, an Exceptional Event may comprise but not
be limited to:
(a) war, hostilities, invasion act of foreign enemies
(b) rebellion, terrorism, revolution, insurrection, military or usurped power or civil war
(c) riot, commotion by persons other than the Contractor’s personnel or other employees of
the Contractor or subcontractors
(d) strike or lock-out not solely involving the Contractor’s personnel and other employees of
the Contractor and subcontractors
(e) encountering munitions of war, explosive materials, etc. excepting as may be attributable
to the Contractor’s activities
(f) natural catastrophes such as earthquakes, hurricanes, etc.
The relationship of this sub-clause to Sub-Clause 17.2 (Liability for Care of the Works) is
to be noted.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
124 18 Clause 18 Exceptional Events
If a Party is prevented from performing any obligations under the Contract due to an
Exceptional Event, then the affected Party (which is likely to be the Contractor) shall give
a Notice to the other Party, detailing the Exceptional Event. The Notice shall describe the
activities which are hindered or prevented because of the occurrence of an Exceptional
Event. The Notice is to be given within 14 days after the affected Party became aware of the
Exceptional Event and the affected Party is excused further performance until the affected
Party can safely recommence normal operations.
Should the affected Party give the Notice after the stated period of 14 days, then the
affected Party shall only be excused further performance from the date of the delayed
Notice. Notwithstanding all of the above, the affected Party shall continue to perform those
operations not affected by the Exceptional Event.
Each Party shall at all times use all reasonable endeavours to minimise any delay arising as
a result of an Exceptional Event.
Exceptional events may arise with little prior warning and the situation is likely to change
quickly. Having given the Notice described above, the Contractor may provide the other
Party with periodic reporting of the actual situation and of the Contractor’s activities to
minimise the consequences of the Exceptional Event. This Sub-Clause indicates that the
affected Party shall ‘describe the effect (or any delay) each 28 days’. This would appear to be
too long an interval for accurate record keeping which will be required for evaluation of
both cost and EOT as described in Sub-clause 18.4 below.
This sub-clause affirms that if the Contractor (assumed to be the affected Party) suffers
delay and/or incurs cost as a consequence of the Exceptional Event of which he gave Notice
under Sub-Clause 18.2 (Notice of an Exceptional Event), he is entitled to EOT, and pay-
ment of Cost provided that the Exceptional Event occurred in the country. On occasions an
Exceptional Event which occurs in another country may cause delays (e.g. supply of fuels
or material may be disrupted). This is an inconvenience to the Contractor, however, no
remedy is provided in these FIDIC forms of Contract.
The evaluation of the Contractor’s costs will be a difficult task for the Contractor to pre-
pare and for the Engineer to check, even if accurate records are made of the standing work
hours of both manpower and goods normally employed in the Works but made idle by the
Exceptional Event. In particular, the evaluation of cost/hour will be difficult to assess,
requiring a detailed review of any cost data in the Contractor’s possession. It will be noted
that this sub-clause does not provide for the payment of profit to the Contractor.
18.5 Optional Terminatio 125
If the execution of a substantial part of all the Works is prevented for a continuous period
of 84 days by reason of an Exceptional Event or for multiple periods which total more than
140 days due to the same Exceptional Event, then either Party may give a Notice of
Termination of the Contract. This situation would be extreme and is unlikely to take place
without consultations between the Parties, as the ramifications of such termination may
have serious consequences elsewhere.
Should a Notice of Termination be issued, the date of the termination shall be seven days
after receipt of the Notice by the other Party. Thereafter, the Contractor shall as soon as
possible submit detailed supporting particulars of the value of work done, as follows:
(a) the amounts payable for any work for which a price is stated in the Contract
(b) the cost of Plant and Materials ordered for the Works which have been delivered or
which the Contractor is obliged to take delivery. The Plant and Materials shall become
the property of the Employer following payment for the same to the Contractor
(c) any other Cost or liability which in the circumstances was reasonably incurred in
expectation of completing the Works. This may be referred to as a ‘catch all’ clause.
Many items required for temporary works may be on site, e.g. aggregates, cement, etc.
The Contractor’s stores are likely to contain a significant amount of project specific
materials and spare parts requiring disposal at a loss.
(d) the cost of removal of Temporary Works and Contractor’s Equipment from the Site and
the return of these items to the Contractor’s home country (or countries if the
Contractor is a JV). The Contractor may decide to send all or part of the Temporary
Works and Contractor’s Equipment to another project in another country, but the cost
claimed under this heading shall not exceed the cost of return to the Contractor’s home
country.
(e) the cost of repatriation of Contractor’s staff and labour employed wholly in connection
with the Works at the date of termination.
The Engineer shall then proceed under Sub-Clause 3.7 (Agreement or Determination) to
agree or determine the value of work done. It is further stated that ‘the date the Engineer
receives the Contractor’s particulars under this sub-clause shall be the date of commencement
of the time limit for agreement under Sub-Paragraph 3.7.3’. Sub-Paragraph 3.7.3 states in
part ‘The Engineer shall give the Notice of agreement, if agreement is achieved, within 42 days
or within such other time limit as may be proposed by the Engineer and agreed by both
Parties. . . ’.
However, the time required for evaluation and assessment of Contractor’s Cost of termi-
nation will depend on two principal factors:
1. The size and complexity of the project
Smaller, less complex projects are likely to be easier and more quickly evaluated. In
comparison, a large, more complex project, which has been under construction for a
lengthy time period will be more difficult to evaluate and more time will be required to
make an evaluation. The assistance of specialist cost accountants may also be required.
126 18 Clause 18 Exceptional Events
‘In addition to any other provision of this Clause if an event arises outside the control of the
Parties, including but not limited to an Exceptional Event which
(a) makes it impossible or unlawful for either Party (or both Parties) to fulfil their contractual
obligations, or
(b) under the law governing the Contractor entitles the Parties to be released from further
performance of the Contract’
and if the Parties are unable to agree an amendment to the Contract, then after one Party
gives a Notice to the other Party, the Contract may be terminated. The Contractor shall be
paid as described in Sub-Clause 18.5.
Events which could trigger application of this Sub-Clause could include:
●● an abrupt change in the political direction in the host country
●● significant worldwide economic and fiscal downturn
●● a pandemic or an outbreak of a major health issue
Should the Contract be terminated in exceptional circumstances as noted above, the
Contractor will be concerned that he may not receive payments rightfully due to him.
Note:
Several countries are able to offer contractors based in those countries’ special export insur-
ance against the possibility of a foreign State Employer failing or being unable to pay con-
tractors the amounts due. Notably this situation arose in the aftermath of the Iran-Iraq war
of the 1980s, when the Iraqi government was unable to pay the amounts due to foreign
contractors. After due legal process, many contractors were able to access the state spon-
sored insurance available in their own countries.
127
19
Clause 19 Insurance
Note:
Sub-Clause 19.1, which follows, requires that insurances will be provided and managed by
the Contractor. In the Contract Data, there are nine items referring to insurances which
have to form part of the insurance package to be provided by the Contractor.
There is no reference to any insurance to be provided by the Employer. However, occa-
sionally the Employer may choose to provide insurances. The Employer is most likely to
provide insurances when the contract is one of the number of contracts required for the
construction of a very large project. The Employer may consider that he can obtain such
insurances at more favourable rates and that the insurances can be tailored to best meet all
of his requirements. In the absence of information to the contrary, the Contractor would be
entitled to assume that the Employer-provided insurances would be compliant with this
Sub-Clause 19.1. Of immediate concern to a tenderer would be the amount of excess to be
deducted from any insurance payments.
19.1 General Requirements
The opening sentence of this Sub-Clause states that ‘. . . the Contractor shall effect and
maintain all insurances for which the Contractor is responsible with insurers and in terms,
both of which are subject to consent by the Employer’ . (Underscoring added)
The time interval between the issue of the Tender Documents and submittal of tenders is
not fixed in these Conditions of Contract. However, the Contractor must have completed
all arrangements with his chosen insurer and have agreed the cost of the insurance policy
for inclusion in his tender offer. In addition, the above quoted underscored extract from
Sub-Clause 19.1 requires the Contractor to have obtained the consent of the Employer to
both the insurer and the terms of any policy also before a Letter of Acceptance is issued.
The Contractor, having selected his proposed insurer, will provide a draft insurance pro-
posal in conformity with the Conditions of Contract with terms indicated together with
costing for inclusion in his tender offer. Should the tender prove successful, the finer detail
of the insurance may be readily agreed. The FIDIC Conditions of Contract were originally
intended for use on projects in other countries where the local conditions of contract
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
128 19 Clause 19 Insurance
(if any) were unsuitable for major projects. Financing in foreign currencies is increasingly
provided by international agencies (World Bank, etc.) enabling foreign contractors to be
paid in convertible currencies. Consequently, the type of insurances indicated in this edi-
tion will likely be provided by a reputable offshore provider whose premiums and settle-
ments will also be valued in a convertible currency.
However, in more recent years the FIDIC Conditions of Contract have been increasingly
specified for use on infrastructure projects, notably in Eastern Europe. These have been
used largely financed by the EU and valued in Euros. Local contractors have successfully
bid for these contracts. However, many of these contractors have difficulty in understand-
ing and providing project insurances conforming to the FIDIC model. In addition, State
Employers also face difficulty in assessing these insurance proposals. The outcome is that
where a contractor has failed, the insurance policy has frequently proved inadequate and
in a number of instances of no value.
It is suggested that an alternative version of Clause 19 be developed to better suit the
conditions highlighted above.
Proof of payment of Insurance Premiums
This sub-paragraph states, ‘the Contractor shall produce the insurance policies . . .’ and ‘the
Contractor shall . . . submit a copy of each receipt of payment to the Employer (with a copy to
the Engineer)’. This requirement can be met by providing the Employer with an authenti-
cated copy of the insurance policy in its final approved form. Copies of receipts of payment
provided by the insurers are best directed through the Contractor to the Employer.
Failure to maintain policies
Should the Contractor fail to pay insurance premiums, the Employer may himself pay the
premiums and back-charge the Contractor (possibly by deduction from interim payments).
The danger of this procedure is that the failure of the Contractor to pay premiums may be
an indicator of financial problems. A safeguard would be to require the insurer to immedi-
ately notify the Parties of any failure on the part of the Contractor.
Compliance
‘If either the Contractor or the Employer fails to comply with any condition of the insurances,
the Party so failing shall indemnify the other Party against all direct losses and claims . . . ’.
Notification of Changes
The Contractor is responsible for notifying the insurers of any changes in the execution
of the Works and the adequacy and validity of the insurances through the performance of
the Works.
These are routine matters to be attended by the Contractor:
(1) The insurer may require a periodic report from the Contractor detailing not only the
physical progress of the Works but its financial status, including details and values of
varied works, additional works which are likely to change the final valuation of the
Works. The arrival and departure dates of the Contractor’s major items of Equipment
to and from the Site should be included in the report, as premiums may vary according
to the actual value of the Contractor’s Equipment on Site.
19.2 Insurance to be provided by the Contracto 129
(2) On larger projects the insurer may send a delegate to the Site (at say 3 months inter-
vals) to review the status of the Works at first hand. During this visit, the delegate will
collect from both Parties any data required for settlement of existing claims. The
Employer may also wish to meet with the delegate.
Shared liability
Where there is a shared liability, the loss shall be borne by each Party in proportion to the
liability of each Party. Should the non-recovery from the insurers arise because of a breach
of this clause by one Party, then the defaulting party shall bear the loss suffered.
The Contractor shall have a clear policy on these issues to be followed by all subcontrac-
tors. It is also possible that there may already exist State sponsored insurance/medical
insurance scheme available to all local employees engaged on the Site. In addition to paying
the subscriptions to these services, the Contractor may consider providing additional insur-
ance benefits as this usually will be appreciated by the local employees.
Expatriate personnel will have accident/medical insurance provided as part of their
employment package, including a medivac provision. Depending on the scale of the project
and numbers of personnel on site, a site hospital may be provided in addition to the stand-
ard first aid facilities.
20
Notes:
(a) The Second Edition contains significant changes from the arrangements included in
the First Edition. Notably, in the First Edition there was limited specific reference to
the entitlement of the Employer to make claims against the Contractor, other than for
Delay Damages.
In this Second Edition, the Employer may make claims against the Contractor in
much the same manner as the Contractor makes claims against the Employer.
Although the authority of the Engineer is confirmed and strengthened in the Second
Edition (reference Clause 3 generally and Sub‐Clause 3.7 specifically), it remains that
the Engineer is an employee of the Employer and is assigned to fairly evaluate the
respective claims of both the Employer and the Contractor. Therefore, the Engineer can
not participate in the preparation and submittal of either the Employer’s or the
Contractor’s claims. The criteria adopted for the evaluation of claims must be consistent.
(b) Reference is made to the FIDIC Document ‘The FIDIC Golden Principles. First Edition
2019’. (This is available online free of cost and a reading of this document is
recommended.)
Golden Principle GP1 on Page 8 of this FIDIC document states:
‘GP1: The duties, rights, obligations, roles and responsibilities of all the Contract
Participants must be generally as implied in the General Conditions, and appropriate to
the requirements of the project’.
and
‘the following are examples of modifications that do not comply with GP1:
–– Under a Red Book, or Yellow Book contract, the Engineer is required to obtain the
Employer’s approval before making any determination of a Contractor’s claim or
granting any extension of time pursuant to Sub‐Clause 3.7 (or Sub‐Clause 3.5 in the
1999 Editions). The Engineer’s role as defined in a FIDIC Contract is to fairly deter-
mine the Contractor’s entitlements in accordance with the Contract conditions, and
this should not be subject to influence or control by the Employer. If the Employer disa-
grees with the Engineer’s determination, the Contract provides an avenue for resolving
this by the Dispute Avoidance/Adjudication Board’.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
134 20 Clause 20 Employer’s and Contractor’s Claims
The effects of restrictions on the power and authority of the Engineer to take actions
leading to additional payment to the Contractor are reported elsewhere. This issue is
unlikely to be resolved soon because in a number of jurisdictions it is unlawful for addi
tional payment to be made in the manner given in these Conditions of Contract. However,
it is not correct that some Employers employ these restrictive practices when it is not neces
sary and not required by the local law.
However unsatisfactory the current situation may be, the Engineer and the Contractor
can only proceed with the administration of a Contract as it is written. The Contractor
may elect to add potential additional financial charges in his tender, which may put him
at a disadvantage to his competitors. Alternatively, it would be beneficial if the Engineer
and Contractor were to informally cooperate to identify at an early stage those site issues
that will likely result in additional payments becoming due to the Contractor. This
knowledge may assist the Employer organise his financial planning in a more cohe
sive manner.
20.1 Claims
The general opening sentence of this sub‐clause specifically refers to Sub‐Clause 20.1
above and states that the following claim procedure shall apply.
20.2 Claims for Payment and EO 135
This statement will be derived from any document forming part of the Contract
Documents, the Engineer’s instructions, contemporary records, external documents
including central and local government regulations, external hydrological records, etc.
(c) all contemporary records (reference Sub‐Paragraph 20.2.3 (Contemporary Records))
(d) (i) detailed supporting particulars of the additional payment and EOT claimed by the
Contractor or
(ii) detailed supporting particulars of the amount of reduction of the Contract Price or
extension of the DNP, claimed by the Employer.
Within either
‘(i) 84 days after the claiming Party becomes aware, or should have become aware, of the
event or circumstance giving rise to the Claim,
or
(ii) such other period (if any) as may be proposed by the claiming Party and agreed by the
Engineer
The claiming Party shall submit to the Engineer a fully detailed claim’.
Should the claiming Party fail to submit the Statement under sub‐paragraph (b) within
the time limit of 84 days, the Notice of Claim shall be deemed to have lapsed and the
Engineer shall, within a further period of 14 days give a Notice to the claiming Party
accordingly.
If the Engineer does not give such a Notice within a period of 14 days, the original Notice
of Claim shall be deemed to be a valid Notice. (By what criteria the Engineer shall or shall
not issue a Notice of an elapsed claim is not stated.)
If the other Party disagrees with the deemed valid Notice of Claim, he shall in turn issue
a Notice to the Engineer giving details of the reasons why he disagrees with the Engineer.
Thereafter the agreement or determination of the Claim under Sub‐Paragraph 20.2.5 shall
include a review by the Engineer of such disagreement.
These additional costs can be readily evaluated on a monthly basis from labour records
and purchasing office/stores data.
This sub‐clause states that:
(a) the fully detailed claim submitted under Sub‐Paragraph 20.2.4 shall be considered
as interim
(b) the Engineer shall respond to the contractual or legal basis of the Claim by giving a
Notice to the claiming Party (generally 42 days if not agreed otherwise)
(c) the valuation of the Claim shall be updated at monthly intervals and submitted to the
Engineer for approval and inclusion in the next IPC
(d) a final Claim valuation within 28 days of the end of the effects of the event or cir
cumstance.
It is possible that events or circumstances may arise which will reduce costs and entitle
the Employer to formally present a claim for a reduction in Cost. The necessary data will be
available only with the Contractor who will likely be requested to provide the same to the
Engineer for his review. The appropriate adjustments can be made in the next IPC.
21
The arrangements for the appointment and operation of a DAAB (formerly referred to as
DAB) are very similar to those included in the First Edition excepting that this Second
Edition provides an Annex containing two supplementary documents titled: ‘General
Conditions of Dispute Avoidance/Adjudication’ and ‘DAAB Procedural Rules’.
●● The DAAB shall be comprised of either three members or a single member (the ‘sole
member’) as stated in the Contract Data. If the number of members is not stated in the
Contract Data, then the DAAB will consist of three members unless agreed otherwise by
the Parties.
●● Each Party shall select one member named in a listing in the Contract Data. The Parties
and the two nominated members shall select the third member who shall act as
chairperson.
●● The DAAB shall be deemed to be constituted on the date that the members (or sole mem-
ber) have all signed a DAAB Agreement (refer to Appendix titled ‘General Conditions of
Dispute/Adjudication Agreement’, Pages 107–116, which will form the basis of the
Employment Contract of a DAAB member).
●● The terms of the remuneration of the DAAB board members of member shall be mutu-
ally agreed by the Parties when agreeing the terms of a DAAB Agreement. Each Party
shall be responsible for paying one‐half of any remuneration to the DAAB board
member(s). This remuneration shall include the remuneration of any expert whom the
DAAB consults. It is assumed that the Parties will give their authority in advance for this
additional cost.
The Parties are to agree which Party will make the full payment of remuneration and
any other approved costs to the DAAB member(s). Should the Employer pay the full
amount due to the DAAB members, then the Contractor shall include his 50% share of
this payment as a credit to the Employer in the next IPC.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
140 21 Clause 21 Disputes and Arbitration
There are a number of scenarios by which one Party may fail to select other DAAB mem-
bers, thereby preventing the formation of a DAAB. Considering that a DAAB should be
appointed and operational as soon as practical after Commencement Date, it is important
that any failure to nominate should be addressed without further delay. To this end ‘the
appointing entity or official named in the Contract Data (page 7) shall at the request of either
or both Parties . . . appoint the members of the DAAB’.
The Contract Data states, ‘Unless otherwise stated, the appointing entity shall be the
President of FIDIC or a person appointed by the President’.
Each Party shall be responsible for paying 50% of the remuneration of the appointing
entity. Arrangement for settlement of this account is likely to follow the same process used
to that applied in the payment of the remuneration due to the DAAB members as described
above in Sub‐Clause 20.1.
Should a dispute remain unresolved having followed the procedures given in the Contract
Documents, then either Party may refer the dispute to the DAAB for its decision. The
21.4 Obtaining DAAB’s Decisio 141
DAAB is to be kept informed of the status of any unresolved claims made by either of the
Parties. However, the DAAB will not be able to efficiently process all referrals unless these
are submitted in an orderly, pre‐arranged manner which should take into consideration
that the DAAB has a time limit of 84 days after the date of referral to give its decision
(N.B. a ‘day’ is a calendar day. Refer Sub‐Paragraph 1.1.27).
The preparation of a referral for a DAAB decision may require a significant time to pre-
pare. Consequently, the arrangements for making a referral must be carefully planned.
Implementation of the matters examined above in Sub‐Clause 21.3 (Avoidance of
Disputes) may be a valuable aid to settlement.
The DAAB shall not be obliged to give its decision if there are unpaid invoices outstand-
ing in their favour.
The decision shall be binding on both Parties who shall promptly comply with the deci-
sion whether or not a Party gives a NOD.
Whilst the DAAB’s decision will concentrate on the contractual merits of the referral
and, if appropriate, provide guidelines for evaluation of the claim, as they are unlikely to
agree to carry out a forensic examination of voluminous accountancy documents. In this
situation, there are two possibilities: a separate group of accountants perform this task on
behalf of the Parties with attendant costs or the Parties perform this task themselves.
If the decision of the DAAB requires a payment of an amount by one Party to the other
Party, then this amount shall be immediately due and payable.
‘The DAAB proceeding shall not be deemed to be an arbitration and the DAAB shall not act
as arbitrator(s)’.
21.5 Amicable Settlement
Where a NOD has been given under Sub‐Clause 21.4 (Obtaining the DAAB’s Decision), both
Parties shall attempt to settle the Dispute amicably before commencement of arbitration.
Unless the participating senior staff fully understand the detail of unresolved claims and
have full authority to make key decisions, amicable settlement will be difficult. Too often
one Party has a fixed position (often established by others elsewhere) which is unalterable
and amicable settlement is not achievable. Consequently, the requirement for seeking an
amicable settlement is reduced to a ‘box‐ticking’ exercise as a prelude to arbitration
proceedings.
21.6 Arbitration
The Arbitration has full power to open up, review, revise any certificate, determination
(if not final and binding), determination opinion or valuation of the Certificate of the
Engineer or any Decision of the Engineer. Nothing shall disqualify the Engineer from being
called as a witness.
Prior to the opening of proceedings, legal advisors of both Parties will have identified
those individuals they intend to call as witnesses. Each Party may cross‐examine the wit-
nesses called by the other Party. Any decision of the DAAB shall be admissible in evidence
in the arbitration.
Arbitration may be commenced both before and after completion.
If an award requires a payment of an amount by one Party to the other Party, this amount
shall be immediately due and payable without further certification or Notice.
The Conditions of Contract are silent on the possibility that the losing Party will not pay
the amount of any award. Legal advice should be sought immediately.
In the event that a Party fails to comply with any decision of the DAAB (binding or final
and binding), then the other Party may refer the failure itself directly to arbitration under
Sub‐Clause 21.6 (Arbitration). The arbitral tribunal shall have the power to order the
enforcement of that decision.
If the decision is binding but not final, the rights of the Parties are reserved until resolved
by a final award.
Failure to comply with DAAB’s decision may result in an award of damages.
If a dispute arises between the Parties and there is no DAB in place (or being consti-
tuted), then
(a) Sub‐Clause 21.4 (obtaining DAAB’s Decision) and Sub‐Clause 21.5 (Amicable
Settlement) shall not apply and
(b) the Dispute may be referred by either Party directly to arbitration under Sub‐Clause
21.6 (Arbitration) without prejudice to any other rights the Party may have.
145
This book is focussed on the preparation of tenders and the award and execution of a con-
tract in conformity with the standard ‘General Conditions of Contract’.
However, these General Conditions require modification to comply with the Employer’s
specific requirements in respect of an individual project.
These specific requirements are addressed in the supplementary FIDIC document titled
‘Guidance for the Preparation of the Particular Conditions’.
Two items require the attention of both Parties.
1. Particular Conditions Part A – Contract Data
In the First Edition 1999, this document was titled ‘Appendix to Tender’.
2. Particular Conditions Part B – Special Provisions
In the First Edition 1999, this document was titled ‘Particular Conditions of Contract’.
Contract Data
As part of the documentation provided to tenderers, the Employer will provide a listing
derived from the Contract Data (Pages 3–7). The Employer may have added new items and
deleted others. The Employer will have included data which can only be provided by him.
This is important because the Contractor will need this information to complete his tender.
The Contractor will complete the Contract listing in respect of items where only he has the
necessary information. The Contractor’s data input will be evaluated during the subse-
quent tender evaluation.
There are many references in the General Conditions of Contract to information and
data to be provided in the Particular Conditions. Most of this information will be contained
in the Contract Data as described above.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
146 Appendix A. Guidance for the Preparation of Particular Conditions
Special Provisions
The Employer may wish to modify selected clauses of the General Conditions of Contract
for inclusion in the Special Provisions. Under the heading ‘Notes on the Preparation of
Special Provisions’ FIDIC have provided references and examples [showing] some of the
Sub‐Clauses in the General Conditions which may need amending to suit the needs of the
project or the requirements of the project.
It is also stated that
●● Modifications shall suit the local law
●● New wording must be suitable – reflecting existing definitions given in Clause 1 of the
General Conditions.
●● New wording should not change the obligations of the Parties.
●● New wording should not create ambiguity or misunderstandings.
In their publication ‘The FIDIC Golden Principles’ (published in 2019), FIDIC expresses
concern at the practices adopted by some employers.
There are five golden principles:
GP 1 – D uties, rights, obligations. . . must be generally as implied in the General
Conditions
GP 2 – The Particular Conditions must be drafted clearly and unambiguously.
GP 3 – The Particular Conditions must not change the balance of risk‐reward in the
General Conditions
GP 4 – All time periods . . . must be of a reasonable duration.
GP 5 – . . . all formal disputes must be referred to the DAAB.
With reference to GP 1 above, FIDIC provides the following additional observations:
Example of proper application of GP 1:
The Employer is obliged to make payments under the Contract, irrespective of the Employer’s
financial arrangements.
Example of modifications that do not comply with GP 1:
Under a Red Book or Yellow Book contract, the Engineer is required to obtain the Employer’s
approval before making any determination of a Contractor’s claim or granting any extension
of time pursuant to Sub‐Clause 3.7.
147
The Employer’s claims identified in the Second Edition are similar to those contained in
the First Edition, subject to minor changes in clause numbering:
1. Sub‐Clause 1.13 (Compliance with Laws) provides for the Employer to claim additional
costs should the Contractor fail to comply with his obligations under this sub‐clause,
thereby causing the Employer to incur additional costs.
2. Sub‐Clause 4.19 (Temporary Utilities) requires the Contractor to provide all contempo-
rary utilities, including electricity, gas, telecommunications, water, etc., which he
requires for the execution of the Works. Should the Contractor be required to provide
temporary utilities to the Employer and/or Engineer, this obligation may be included in
the Particular Conditions or Specifications. Should the Employer already be established
on site, he may choose to provide the temporary utilities (in whatever part). Terms and
conditions may also be provided in the Particular Conditions or Specifications and clar-
ify the fiscal responsibilities of the provider.
3. In the First Edition, Sub‐Clause 4.20 (Employer’s Equipment and Free‐Issue Material)
clarified the conditions by which any of these items would be included in the Works.
The Employer shall, at his risk and cost, provide these materials at the time and place
specified in the Contract. Additionally, the Employer remains responsible for any short-
age, defect, or default, which may cause the Contractor to incur additional cost. This
sub‐clause has been deleted in its entirety in this Second Edition but may be re‐introduced
in the Particular Conditions or Specifications.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
148 Appendix B. Employer’s Claims
The number of occurrences entitling the Employer to give a Notice of Claim is very simi-
lar to that stated in the First Edition. The Employer is now required to provide the Engineer
with a Notice of Claim for each occurrence as it arises and follows the same procedures as
the Contractor.
For several claims, the Employer is entitled to recover his costs. This entitlement would
particularly apply to testing delayed by the Contractor or where he has failed to rectify
defects in good order. Considering that the Engineer’s staff are confirmed to be employees
of the Employer, any potential additional costs may be related to additional work hours or
standing time of the Engineer.
149
Throughout this Second Edition the Contractor’s claims and entitlements are described in
greater detail than in the First Edition.
The following commentary identifies new or retitled Contractor entitlements for Costs
and/or EOT together with details of any deletion of claim headings used in the First
Edition.
Some sub‐clause headings have been changed in the Second Edition. These are also
noted to provide continuity for the benefit of personnel who are transiting from use of the
First Edition to the Second Edition.
Sub‐Clause 1.13 (Compliance with Laws) provides for the Contractor to claim additional
costs consequent upon the failures of the Employer.
Sub‐Clause 4.6 (Co‐operation) shall, as stated in the Specification or instructed by the
Engineer, allow opportunities for carrying out work by Employer’s personnel, other
contractors employed by the Employer (note, it does not state the other contractors are nec-
essarily working on Site), and employees of Public authorities or private utility companies.
Sub‐Clause 4.15 (Access Route)
This sub‐clause has been modified. At the Base Date the Contractor is required to have
satisfied himself of the availability and suitability of the access route(s) to the Site.
Presumably, the Contractor will have stated his intended access route in his tender submit-
tal. Should the designated access become unavailable because of changes required by the
Employer or a third party after the Base Date, and a new access route must be provided,
then the Contractor is entitled to claim his additional costs with EOT.
Sub‐Clause 7.6 (Remedial Works)
Generally, the Contractor is responsible for any costs incurred in carrying out remedial
works. This sub‐clause has been slightly expanded and now confirms that the Contractor is
entitled to reimbursement of his Costs (with EOT) if the remedial works arise because of
●● any act by the Employer of the Employer’s Personnel
●● an Exceptional Event (Sub‐Clause 18.4 refers)
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
150 Appendix C. Contractor’s Claims
For a majority of claims, the Contractor is entitled to payment of Cost together with
EOT. For the remaining claims the Contractor’s entitlement is limited to payment of Cost.
It is essential that the Contractor provides the Engineer with a Notice of claim for each
occurrence entitling him to make a claim. Refer to Appendix D (Notices and Site
Organisation).
153
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
154 Appendix D. Notices and Site Organisation
The respondent would respond with similar headings. This arrangement would not only
minimise the possibility of misunderstandings but equally importantly would help provide
a continuous record of any dispute which was unresolved for a lengthy period of time.
The Engineer’s Representative and the Contractor’s Representative are key figures in the
organisation of their respective staff members. Both are likely to be signatories to any
Notice or response and have ultimate responsibility for the content of the Notices.
Consequently, the duties allocated to their respective staff members have to be carefully
arranged to minimise the administrative burden on both the Engineer’s Representative and
the Contractor’s Representative.
The attached organigram is typical of the site organisation of a medium ‐large construc
tion project and shows the positions of not only the executives of the Employer, the
Engineer, and the Contractor, but also the positions occupied by the senior on‐site staff of
the Engineer and the Contractor. Suggested lines of delegation are also shown.
A1. Delegation by the Engineer (to the Engineer’s Representative on Site)
Sub‐Clause 3.3 (The Engineer’s Representative) states in part ‘The Engineer may appoint an
Engineer’s Representative and delegate to him. . . the authority to act on the Engineer’s behalf
at the Site’.
Note: This sub‐clause does not mention any requirement for the Engineer to issue a Notice.
A2. Delegation by the Engineer (to assistants)
Sub‐Clause 3.4 (Delegation by the Engineer) states ‘The Engineer may from time to time
assign duties and delegate authority to assistants. . . . By giving a Notice to the Parties, describ-
ing the assigned duties and the delegated authority of each assistant. . .’.
Note:
This sub‐clause requires the issuance of a Notice by the Engineer. The delegation of author
ity is made by the Engineer and not the Engineer’s Representative. It is not specifically
stated if Notices issued by the Contractor’s Representative shall be directed to the Engineer
or the Engineer’s Representative. This requires clarification from the Engineer when issu
ing the delegation of duties to the Engineer’s Representative.
B1. Delegation by the Contractor (to the Contractor’s Representative)
The term “Contractor” in this context refers to an entity which has entered into the Contract
with the Employer.
Sub‐Clause 4.3 states in part ‘The Contractor shall appoint the Contractor’s Representative
and shall give him all authority necessary to act on the Contractor’s behalf under the Contract’.
Note:
The appointment of the Contractor’s Representative is subject to the approval of the engi
neer (not the Employer) and ‘The Contractor’s Representative may delegate any functions
and authority except:
●● the authority to issue and receive Notices and other communications. . .
●● the authority to receive instructions under Sub‐Clause 3.5 (Engineer’s Instructions). . .’.
Neither the Engineer’s Representative nor the Contractor’s Representative will be fully aware
of the detail of each site activity. However, there are several key site activities which will require
a Notice to be issued by one party and responded to by the other party with minimum delay.
Appendix D. Notices and Site Organisation 155
EMPLOYER
ENGINEER BOARD
THE ENGINEER
ENGINEER’S
REPRESENTATIVE
FIELD TECH.
SURVEY LAB. ASSISTANT TO E.R.
SUPERVISOR OFFICE
INTERFACES
CHIEF OF TECH.
SURVEY LAB. ASSISTANT TO C.R.
WORKS OFFICE
CONTRACTOR’S
REPRESENTATIVE
CONTRACTOR’S
STORES WORKSHOP ADMIN
EXECUTIVE BOARD
CONTRACTOR BOARD
OF MANAGEMENT
Appendix D. Notices and Site Organisation 157
(1) Dayworks
The opening sentence of Sub‐Clause 13.5 (Dayworks) states ‘If a Daywork Schedule is not
included in the Contract, this Sub‐Clause shall not apply’. If there is no Daywork Schedule
included in the tender documents, then payment cannot be made on a Daywork basis.
Sub‐Clause 12.3 (Valuation of the Works) provides opportunity for valuation of Dayworks
to be negotiated, provided they are of a minor and incidental nature.
The supplementary documents ‘Guidance for the Preparation of Particular Conditions’
and ‘Notes on the Preparation of Special Provisions’ do not provide any indicators of what
requirements would be included in a Daywork Schedule.
One solution would be for the inclusion in the Tender Documents of a ‘Schedule of
Dayworks’ prepared by the Employer with a limited number of items most relevant to
Daywork operations. The quantities of each of the Schedule items are also to be provided
by the Employer. The Schedule shall be priced by Tenderers, noting that the unit prices are
deemed to include taxes, overhead and profit. The total value of the Schedule is to be
included as a Provisional Sum in the Bill of Quantities. This procedure ensures that the
daywork rates offered by each tenderer is reflected in the total tendered amount.
The procedure given in Sub‐Clause 13.5 (Dayworks) for obtaining any Goods for use on
a Daywork task is cumbersome. To avoid delays and reduce costs, much of the required
Goods are frequently sourced from the Contractor’s own stores (where supporting invoices
are available). The Engineer is authorised to instruct the Contractor to obtain other quota-
tions (for Goods not immediately available with the Contractor’s stores) from other
sources.
Sub‐Clause 13.5 (Dayworks) requires the Contractor ‘to deliver each day to the Engineer
accurate statements in duplicate. . . which shall include records (as described in Sub‐Clause
6.10 (Contractor’s Records)) of the resources used in executing the previous day’s work’. These
records are to be priced for inclusion in the next Statement.
It is noted that the rates and prices in the daywork Schedule (if included in the Contract)
shall be deemed to include taxes, overhead, and profit.
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
166 Appendix E. Daywork and Contemporary Record Sheets
Following is a proposed standard format which can be varied to suit the requirements
of an individual site. These daywork/daily record sheets should be colour‐printed in
groups of five and bound in sets of 100 (20 × 5). Each set of five would have a unique
sequential number. This would help identify records that are not signed, not presented,
or simply ‘lost’ in the system. The top copy and one other would be taken by the Engineer
and the next two copies by the Contractor’s site office. These four copies would be perfo-
rated for separation. A fifth copy, unperforated, would be kept in the Contractor’s field
office responsible for producing the record sheets. It may happen that the Contractor’s
supervisory staff are not fluent in the language of the Contract. Provided that Badge No./
Fleet No./Material Codes are correctly recorded, together with the relevant quantities,
the form can be conveniently completed by a junior staff member with the correct lan-
guage skills.
The valuation of the individual sheets takes place in the Contractor’s site office. The
quantum, whether for daywork or other purposes, can be sent to the Engineer as part of the
monthly Application for Interim Certificate or as part of a claim presentation accompanied
by a copy of the original, signed daywork/daily record sheet.
2) Contemporary Records
Sub‐Clause 20.2 (Claims for Payment and/or EOT) states in part:
‘The claiming Party shall keep contemporary records as may be necessary to substantiate
the claim’
and
‘The Engineer may monitor the Contractor’s contemporary records and/or instruct the
Contractor to keep additional contemporary records’.
Routinely, the Contractor generates a considerable amount of data for his own purposes
(cost control, taxes, financial planning, etc.). This can be made available to the Engineer for
his review (subject to confidentiality). However, the evaluation of some claims will require
more specific records of actual site events relating to the basis of any claim. These may
require the Contractor to maintain contemporary records in more detail than for dayworks.
Diaries, minutes of meetings, correspondence, construction drawings, etc., will all form
part of Contemporary Records.
Any requirement for ‘Contemporary Records’ applies to any claim made by the Employer
and which is to be evaluated by the Engineer.
Appendix E. Daywork and Contemporary Record Sheets 167
PROJECT SECTION
DESCRIPTION
Badge Name Trade Hours Fleet No. Description Hours Code Description Quantity Unit
1 1 1
2 2 2
3 3 3
4 4 4
5 5 5
6 6 6
7 7 7
8 8 8
9 9 9
10 10 10
11 11 11
CONTRACTOR: ENGINEER:
(1) The term ‘Cost’ is defined in Sub‐Paragraph 1.1.9: Cost means all expenditure reason-
ably incurred (or to be incurred) by the Contractor in performing the Contract, whether
on or off the Site, including taxes, overheads and similar charges.
(2) ‘Overheads’ may be more broadly defined as those expenses that together with the
taxes and planned profit are not directly chargeable to the cost of production.
Production costs, principally the cost of the plant, labour, and materials are conven-
tionally referred to as direct costs. Thus, the summation of overhead costs and direct
costs represents the total cost of a given project to the Contractor. Additionally, a per-
centage for profit and risk is to be added to the total cost to give the Contractor’s tender
price. Occasionally, in other literature, the reader may find reference to ‘indirect costs’
in substitution to ‘overhead costs’. For consistency, this book follows the FIDIC prefer-
ence for ‘overhead’.
(3) In order to maintain commercial confidentiality, access to the Contractor’s tender sum-
mary sheet or so‐called ‘top sheet’ is normally restricted to a limited number of the
Contractor’s senior management.
Nonetheless, it seems inevitable that at some point essential pricing data will have to
be made available to the Engineer in order to facilitate the valuation of variations,
claim valuation, and settlement, particularly those claims related to extension of time.
It has been the author’s experience that it is preferable that the principal features of
the Contractor’s ‘top sheet’ are presented to, and accepted by, the Employer/Engineer
at an early stage of the Contract and before claims and disputes arise. It becomes
increasingly difficult to reach a general agreement on the value of overheads after
claims or disputes have arisen, particularly if the Engineer’s relevant site staff have lit-
tle understanding of the principles used in the compilation of the Contractor’s
‘top sheet’.
The contractor’s ‘top sheet’ is prepared by his estimating office and requires adjust-
ment prior to commencement of the Works to reflect the consequences of agreements
reached in any post‐tender meetings with the Employer.
(4) Conventionally, the Contractor’s overhead costs are expressed as a percentage of direct
costs even though the Contractor’s estimating office will, for the most part, have calcu-
lated the various elements of the overhead costs as individual sums of money. This
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
170 Appendix F. Contractor’s Costs
percentage can vary considerably from more than 40% on a large, isolated project
(where the Contractor has to provide a large number of facilities and services, e.g.
housing, schools, hospitals) to less than 20% on a small project in a developed location,
where site establishment is minimal and full use is made of local suppliers and services.
The Contractor’s overhead costs may be reduced if some of these costs are paid
directly by means of specific bill items in the Bill of Quantities.
A proportion of the overhead will be incurred off site (‘Head Office Expenses’) and
the remainder on the site (‘Site Office Expenses’). Both the Head Office Expenses and
the Site Office Expenses can be sub‐divided into time‐related costs and fixed‐over-
head costs.
The Contractor’s ‘top sheet’ will typically contain the following information:
Direct Costs % %
Equipment 30
Labour 25
Materials 25
Sub‐contractors 20 100
Fixed‐Overhead Costs
●● provide office, etc. 5
●● establishment 2 16
demobilisation costs
Total Costs 122
Profit, Risk, Financing (6% of 7.32 7.32
total cost)
129.32
The breakdown of the Accepted Contract Amount demonstrated above is an important aid
in the following matters:
(a) the agreement of new rates for changes in quantities of work to be performed (Sub‐
Clause 12.3 refers)
Appendix F. Contractor’s Costs 171
(b) the agreement of new rates for works that are the subject of a Variation (Sub‐Clause
12.3 refers)
(c) the evaluation of financial claims arising from any award of an Extension of Time for
Completion (Sub‐Clause 8.5 refers). As summarized in Appendix A, there are 14 in
number of events or circumstances that permit the Contractor to claim additional
payment in respect of Extension of Time for Completion. Of those fourteen instances,
four restrict the Contractor’s entitlement to his costs only.
In the administration of those matters summarised above, there is a general assumption
that Overhead Costs are spread evenly over all bill items and over the full period of the
Contract. In particular, Variations made under the provisions of Sub‐Clause 12.3 are most
likely to be evaluated on this assumption. It is impractical to assess the individual overhead
applicable to individual bill items, and the use of a global average percentage for all items
is seemingly inevitable, excluding only those items where specific alternative measures are
provided (e.g. the percentage for adjustment of Provisional Sums – Sub‐Clause 13.4 refers).
Referring to the breakdown given in the previous page, it can be stated as a generalisation
that a fixed overhead of 29.32% would be applicable to all new evaluations made under the
provisions summarised in (a), (b), and (c) above, excluding items where the evaluation is
specified to be based on cost only.
Nonetheless, there are occasions when the practice of averaging overheads over the
period of the Contract is not appropriate. The reality is that the Contractor does not incur
his Overhead Costs evenly over the period of the Contract.
Mobilisation Period
In the initial stages of a Contract, it takes time for the Contractor to mobilise his resources
and establish himself on Site. His expenditure on Fixed‐Overhead Costs will be relatively
high, and Time‐Related Costs will gradually increase over this period as more and more
operations are commenced.
Construction Period
Once the mobilisation period is completed, expenditure on Fixed Overheads can be
assumed to fall to a relatively constant level for the construction period. Equally, Time‐
Related Costs can also be assumed to fall to a relatively constant level, although this
depends considerably on the incidence of high‐value work items. These Time‐Related
Costs will eventually reduce as the date of Taking Over approaches, when sections of the
Works are completed, and the Contractor’s resources are reduced.
Defects Liability Period
Fixed‐overhead Costs will chiefly derive from the final demobilisation of the Contractor’s
resources. Time‐Related Costs will relate to completion of outstanding works and the cor-
rection of defects, which under average circumstances will be largely complete within the
first few months of the Defects Liability Period.
If no specific cost data is available, the incidence of expenditure for all Overhead Costs
may be estimated from other documents, including the Contractor’s cash‐flow projections
and the Programme of Works.
173
(a) Full Joint Venture Agreement for the Contractor’s internal use only
Individual contractors may decide that a project is too large or too complex, with attendant
high risk, to be executed solely on their own account, and consequently they will seek reli-
able partners to reduce the risk to an acceptable level.
Many contractors will have worked together on other projects and would be prepared in
a joint venture for another project.
Having decided to form a Joint Venture for a specific project, a Full Joint Venture
Agreement will be drawn up, which will precisely define the many elements of the Joint
Venture. This document should be drawn up as soon as possible.
Principal elements to be considered are listed below:
(1) Definitions
(2) Joint Venture (Structure and Name)
(3) Commencement and Term
(4) Preparation and Submission of Tender
(5) Failure to agree Tender or Unsuccessful Tender
(6) Successful Tender
(7) Profits and Losses
(8) Tender Costs
(9) Supervisory Board
(10) Executive Board
(11) Sponsor
(12) Project Manager
(13) Liability of the Joint Venturers to each other
(14) Bank Accounts
(15) Working Capital
(16) Invoicing
(17) Partners’ Accounts
(18) Provision of Resources and Services
(19) Realization of Assets
(20) Information
(21) Security
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
174 Appendix G. Joint Ventures
(22) Insurance
(23) Taxation
(24) Confidentiality
(25) Exclusivity
(26) Assignment
(27) Publicity
(28) Default
(29) Nature of Agreement
(30) Illegality
(31) Amendments
(32) Notices
(33) Waivers
(34) Applicable Law
(35) Arbitration
(36) Duration of Agreement
(b) Joint Venture Prequalification (if required)
The prequalification process, initiated by the Employer, typically by means of advertising,
will describe how to obtain prequalification documents containing all necessary instruc-
tions which are to be followed by prospective tenderers. The submittal of prequalification
documents will require individual contractors having to decide whether to prequalify solely
on their own account or as part of a joint venture or consortium.
Having decided to join with other contractors in a Joint Venture, the Contractor is effec-
tively committed not only to involvement in the prequalification and tender process, but
also to participate in the execution of the project (if awarded).
(c) Joint Venture Agreement (JVA) for submittal to the Employer
This is a condensed version of the Full Joint Venture Agreement discussed in (a) above,
with confidential matter removed.
Immediately following an award of the Contract to the JV, this document is to be pre-
pared and submitted to the Employer for approval and inclusion in the Contract documents.
175
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
176 Model Form of a Pre-Bid Joint Venture Agreement
be appropriate for the senior partner to be given the title and duties of Sponsor. The
role of the Sponsor is given in Chapter 4 following.
2. The Joint Venture shall be known as . . . . . . . . . . . . . . . . . . . . . . or by such other name
as hereafter the Partners agree.
3. The percentage of participation of the Parties in the Joint Venture shall be as follows:
Contractor ‘A’. . .% (describe those parts of the tender to be prepared)
Contractor ‘B’. . .% (describe ditto as above)
Each Party shall furnish in accordance with the above percentages its respective
share in any deposit, bond and other security required in connection with the Tender.
4. The preparation of the Tender shall be shared between the Parties as far as practical in
the participation shares given in the item above. Each Party shall bear all and any costs
they may occur in the participation of the Tender (see Note 4.4 of attachment).
5. The Tender shall be jointly submitted by the Parties. Each Party shall provide all appro-
priate authorisations and documentation that will permit the Tender to be submitted
in compliance with the Tender requirements specified by the Employer.
6. Not Party hereto shall sell, assign, or in any manner encumber or transfer its interest
or any part thereof in this Agreement or the Tender, whether by operation of the law
or otherwise, without obtaining the consent of the other Party.
7. Except through this Joint Venture, no Party to this Agreement shall directly tender for
or take interest for its own benefit in tendering for or in the execution of the Project.
8. The Joint Venture shall cease to exist, and this Agreement shall terminate in the event
that the Contract has not been awarded to the Joint Venture until (date) (as such date
may be extended by the Parties in writing) and the Tender surety (if any) has been
returned to the Employer.
9. The Parties hereby agree that in the event of the Tender being accepted by the Employer,
this Pre‐Bid Joint Venture Agreement shall be superseded by a Joint Venture
Agreement, which shall fully detail the legal framework of the Joint Venture and the
responsibilities and duties of the respective Joint Venture partners.
10. This Agreement shall be governed by and construed in accordance with the laws of
. . . . . . . (specify).
Note:
It is important that the law governing this Pre‐Bid Joint Venture be clearly specified.
The Partners may be of differing nationalities and laws of a country perceived to be
“neutral” may be preferred. The laws of Switzerland are a common choice for
European‐based contractors and are likely to be acceptable to any local (i.e. based in
the country of execution) partner. Legal advice may be required.
Model Form of a Pre-Bid Joint Venture Agreement 177
11. The Parties shall endeavour to settle amicable any dispute arising out of or in connec-
tion with this Agreement. Failing amicable settlement, any such dispute shall be
finally settled under the Rules of Arbitration of the International Chamber of
Commerce, Paris, by a single arbitrator appointed in accordance with the said Rules.
The venue of arbitration shall be . . . (specify place and country) and the proceedings
shall be conducted in the . . . (specify) language.
Judgement upon the award rendered may be entered in any court having jurisdic-
tion or application may be made to such court for a judicial acceptance or the award
and an order of enforcement, as the case may be.
No Party shall be released from due performance under the terms and conditions of
this Agreement because an arbitral proceeding has been initiated.
Note:
The Rules of Arbitration in this model are stated to be those of the International
Chamber of Commerce, Paris. Other rules are available, such as UNCITRAL.
The venue for any arbitral proceedings can be any place mutually convenient to the
partners.
The proceedings can be conducted in any language, but there is merit in selecting
the language of the construction contract.
These choices are likely to be reflected in the adjudication of disputes with the
Employer under the construction contract.
IN WITNESS WHEROF, the Parties execute this Agreement the day and year fist
above written.
CONTRACTOR “A” CONTRACTOR “B”
(date) (date)
179
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
180 Index of Clauses and Sub-Clauses
Index of Sub-Clauses
Based on the original FIDIC document
Guide to the FIDIC Conditions of Contract for Construction: The Red Book 2017, First Edition.
Michael D. Robinson.
© 2023 John Wiley & Sons Ltd. Published 2023 by John Wiley & Sons Ltd.
184 Index of Sub-Clauses