Builder Agreement
Builder Agreement
Where as the first party is the owner of the plot of land admeasuring .................... sq. meters
bearing plot No. ........... city survey No. ...................... Khasra No. ..................... situate, lying and
being at ...................... Tahsil and District ...................... (hereinafter referred to as the "said plot of land")
and is desirous of getting a house constructed on the said plot of land. and Whereas the first party has
appointed Shri ................. as the architect and the said architect has prepared the plans, drawings and
elevations of the said intended house and the specification of the works to be done and of the materials.
and Where as the second party is a big contractor and is having vast experience in construction of big
buildings and has agreed to construct the house on the said plot of land.
1. The builders will construct the building on the said plot of land in conformity with the plans,
drawings, specifications and elevations as prepared by the architect which has been annexed
hereto and marked as Annexure A, with the material of best quality and in the most
substantial and workman like manner and to the satisfaction of the architect.
2. The builders hereby undertake to commence the construction within fifteen days of execution
of these presents and complete the construction on or before the expiry of ...................
months from the date of execution of these presents in accordance with the plans duly
approved and sanctioned by the Municipal Corporation of .................................. and
specifications and conditions as are set out in Annexure A hereunder written.
3. If the builders fail to complete the said work within the period as stipulated in the foregoing
provision, the builders shall, at the option of the owner but without prejudice to the other
rights under law of the owner and other provisions herein, pay liquidated damages calculated
at the rate of Rs.......... per day (but subject to a maximum of 2% of the total contract amount
payable by the owner under this agreement) for the period between the said stipulated time
for completion of the works. The builders hereby specifically agree and authorise the owner
to deduct such liquidated damages, if any, from any installment of payment becoming due
and payable to the builders in terms of this agreement.
4. The owner will pay to the builders a sum of Rs............. out of which the owner shall pay to the
builders weekly such sum as may be sufficient to defray the expenses incurred by the
builders in respect of materials used in the works, checked and certified by the architect, Rs
......... on the certificate by the architect that the work upto first floor has been completed, the
further sum of Rs ............. on the certificate by the architect that the work upto second floor
has been completed and the balance shall be paid on the certificate by the architect that the
said works have been completed in all respects according to the agreement and the builders
have at their own expenses removed and cleared all scaffolding, fencing, unused materials
and rubbish from the premises and made and prepared the bungalow fit for use and
habitation and immediate occupation. However, a sum equivalent to 5 per cent of the total
contract amount payable by the owner under this agreement shall be retained by the owner
as retention money, which shall be paid after a period of 12 months from the date of handing
over the said bungalow complete in all respects and fit for occupation. The builders hereby
agree and undertake to rectify all such defects as may be found or detected during the period
of 12 months. If the builders fail to rectify the defects pointed out or decline to cure such
defects as pointed by the owner within fifteen days from the date of reporting to the builders,
the owner shall be entitled to have such defects cured by such other agencies as it may
deem fit at the entire cost and risk of the builders and utilise the retention money; Provided
further that in the event of the said retention money being inadequate to meet such costs,
charges and expenses incurred by the owner for curing the defects in the construction, the
builders shall within 7 days of a demand in writing made by the owner make good the defect,
failing which the builders shall be liable to pay the same together with the interest at 15% per
annum.
5. The owner shall allow free ingress to and egress from the premises to the builder’s servants,
employees, sub-contractors and all other persons, who are necessary in connection with the
carrying out of the works under the agreement.
6. The builders shall indemnify the owner in respect of all claims, damages or expenses payable
in consequence to any injury to any employee, workman, nominee, invitee while in or upon
the said premises. The builders shall also be responsible for any damage to buildings,
whether immediately adjacent or otherwise and any damage to roads, streets, foot-paths,
bridges or ways as well as all damages caused to the buildings, and work forming the subject
to this contract by frost, rain, wind or other inclemency of weather.
7. If the builders abandon the contract or fail to commence the work or suspend the progress of
the work for 14 days without any lawful excuse under these conditions, or fail to proceed with
the works with such due diligence and fail to make such due progress as would enable d the
works to be completed within the time agreed upon or fail to remove materials from the site or
to pull down and replace work for seven days after receiving from the architect written notice
that the said materials or the works were defective and rejected by the said architect or
neglect or fail persistently to observe and perform all or any of the acts, materials or things
required by this contract to be observed and performed by the owner for seven days after
written notice shall have given to the builders requiring them to observe or perform the same
and the architect certifies in writing to the owner to the said effect, then and in any of the said
cases the owner may, notwithstanding any previous waiver, after giving seven days notice
through the said architect in writing to the builders terminate the licence in favour of the
builders and in so far as it relates to the completion of the remaining construction work, but
without thereby affecting the powers of the architect, or the obligations and liabilities of the
builders, the whole of which shall continue in force as fully as if this Agreement had not been
so determined. And the owner by his servants or agents may enter upon and take possession
of the work, tools, scaffolding, sheds, machinery, power, utensils and materials lying upon the
premises or in the adjoining lands or roads and use the same as its own property or may
employ the same by means of its own servants and workmen in carrying on and completing
the work or by employing any other contractor or other person to complete the works and the
builders shall not in any way interrupt or do any act, matter or thing to prevent or hinder such
other contractor or other person or persons employed for completing and finishing the works
or using the material and plant for the works.
8. When the said works are terminated in the manner as stipulated in the foregoing provision,
the architect shall give a notice in writing to the builders to remove their surplus materials and
plant, and should the builders fail to as so within a period of seven days, after receipt thereof
by them, the owner may sell the same by public auction and give credit to the builders for the
net amount realised. The architect shall thereafter ascertain and certify in writing, what (if any
thing) shall be due or payable to or by the owner, for the value of the said building and
materials so taken possession of by the owner and the expense or loss which the owner shall
have been put to in procuring the work to be completed and the amount, if any, owing to the
builders and the amount which shall be so certified shall thereupon be paid by the owner to
the builders or by the builders to the owner, as the case may be, and the certificate of the
architect shall be final and conclusive between the parties.
9. The builders shall be bound to appoint an engineer competent to receive instructions from the
architect from time to time, on behalf of the builders at all reasonable hours and all directions
given to him by the architect shall be deemed to have been given to the builders.
10. The owner or his representatives shall be entitled to inspect the progress of the construction
work and materials used for the construction and they shall be entitled to point out to the
architect any defects in the construction work, quality of workmanship or materials d used
when such defective work is in progress or being executed or such material is brought on
site. If the architect will be satisfied about the objections raised, the said architect shall certify
the same in writing and direct the builders to rectify at their own cost the defect in the said
construction work or remove such defective materials and the same shall be rectified or
removed by the builders as directed.
11. All disputes or differences relating to the specifications, designs, drawings and as to quality of
workmanship or material used in the work or as to any other question arising out of or relating
to the contract, design, drawings, specifications, orders or otherwise in connection with the
agreement or the carrying out of the works, whether during the progress of the work or after
the completion or abandonment thereof shall be referred to the sole arbitration of two
arbitrators, one to be appointed by each party. The arbitrators shall appoint an umpire before
entering upon the reference. The parties would cooperate and lead evidence, etc. with the
arbitrators and if one of the parties does not cooperate or remains absent at the reference,
the arbitrators or the umpire would be at liberty to proceed with the reference ex-parte. The
arbitrators or the umpire shall keep record of the oral evidence adduced by the parties and
submit the same to the court at the time of filing of the award, along with documentary
evidence produced before them or him by the parties or their witnesses. The proceeding of
the arbitrators or the umpire shall be recorded in English and a carbon copy whereof shall be
furnished to each party. The arbitrators or umpire shall be entitled to appoint stenographer,
for recording proceedings of the arbitration, consult an expert, after previous notice to the
parties to the reference, the cost whereof shall be borne equally by the parties. The fees of
the arbitrator appointed by a party shall be borne by the party, so appointing and the fees of
the umpire and the other arbitration expenses shall be borne equally by the parties. The
arbitrators shall make their award, with reasons for the decision, within six months from the
date of entering upon the reference. If the arbitrators have allowed their time to expire without
making an award or have delivered to any party or to the umpire a notice in writing stating
that they cannot agree, the umpire shall forthwith enter on the reference. The umpire shall
make his award within tour months of entering on the reference or within such extended time,
as the parties may agree. The award of the arbitrators, or umpire, as the case may be, shall
be final, conclusive and binding on the parties and shall not be challenged on any ground
except collusion, fraud or an error apparent on the face of the award. This reference to
arbitration shall be deemed to be a reference within the meaning of the Arbitration and
Conciliation Act, 1996 or any statutory modification thereof. No action can be taken under this
agreement for the enforcement of any right without resorting to arbitration under this clause.
12. This agreement shall be executed in duplicate, the original shall be retained by the owner and
the duplicate by the builders.
In Witness Where of the parties have signed these presents and a duplicate thereof, the day and year
first hereinabove written.
Signed and delivered by M/s ABC Builders and Contractors, the builders, by its partners
WITNESSES;
1.
2.