GSECL Tender
GSECL Tender
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
E-TENDER DOCUMENT
FOR
Construction of collapsed/Tilted
compound wall of P.H. due to Tauktae
Cyclone at BLTPS.
1
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
INDEX
NAME OF WORK : Construction of collapsed/Tilted compound wall of P.H.
due to Tauktae Cyclone at BLTPS.
SR.
DESCRIPTION PAGE NO.
NO.
1. SECTION-A:
ACKNOWLEDGEMENT OF TENDER FEE /EMD. 04 To 08
TENDER NOTICE.
2. SECTION-B:
DECLARATION FORM CUM UNDER TAKING TO BE SIGNED BY
BIDDER
RTGS DETAILS OF BIDDER
09 To 25
PROJECT SYNOPSIS AND DATA
SCOPE OF WORK AND SITE CONDITION
SPECIAL NOTE FOR PRE-QUALIFICATION
GENERAL INSTRUCTIONS TO THE BIDDER
3. SECTION-C:
26 To 59
GENERAL CONDITIONS OF CONTRACT
4. SECTION-D:
SPECIAL CONDITIONS FOR USE OF CEMENT IN WORK
APPROVED NAME OF MANUFACTURERS OF STEEL / CEMENT 60 To 65
SPECIAL CONDITION OF THE WORK
GENERAL GUIDELINES RELEVANT TO I.S.
5. SECTION-E:
TERMS AND CONTRACT FOR WORKS 66 To 75
GENERAL SAFETY RULES & LIST OF SAFETY TOOLS
6. SECTION-F :
PERFORMA FOR BANK GUARANTEE
INTEGRITY PACT
ANNEXURE – I (DETAILS OF BANK FOR SOLVEANCY & BG)
UNDERTAKING FOR LABOUR LAW COMPLIANCES
CERTIFICATE – A (FORM-1)
76 To 90
DEVIATION FROM BIDDER (IF ANY) (FROM-2)
UNDERTAKING IN REGARD TO STOP DEAL/BLACK LIST THEREOF
(FROM-3)
UNDERTAKING TO BE SUBMITED ON LETTERHEAD
CIRCULAR-I
DECLARATION CUM INDEMNITY BOND
7. SECTION-G:
GENERAL SPECIFICATIONS 91 To 110
TECHNICAL SPECIFICATION
2
SR.
DESCRIPTION PAGE NO.
NO.
8. SECTION-H:
111 To 116
SCHEDULE-B
3
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-A
TENDER NOTICE.
4
ACNOWLEDGMENT
NAME OF WORK : Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
1. The undersigned reserves the right to reject any or all tenders without
assigning any reasons thereof.
2. The Tender fee will be accepted in form of Demand Draft and Earnest Money Deposit
will be accepted in form of Demand Draft or Bank Guarantee of any bank as prescribe in
ANNEXURE- I drawn in favour of “GUJARAT STATE ELECTRICITY
CORPORATION LTD.” payable at BLTPS.
5
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
E-TENDER
CHIEF ENGINEER (GEN) invites “On-line Tenders” (e-tendering) for the work
“collapsed/Tilted compound wall of P.H. due to Tauktae Cyclone at BLTPS. ” of Tender
Papers & Specifications may be down loaded (If required by bidder) from Web site
http://www.nprocure.com (For view, down load and on line submission) and GSECL web sites
www.gsecl.in (For view & down load only).Tender fee & EMD shall y be paid along with
submission of tender in separate cover. “All the relevant document of tenders as stated here
under to be submitted physically will be received only by Registered Post A.D or Speed Post
addressed to CHIEF ENGINEER (GEN.), GUJARAT STATE ELECTRICITY CORPORATION
LTD, BLTPS PADVA. “No Courier Services Or Hand Delivery” Will Be Accepted.
SIGNATURE OF CONTRACTOR
CHIEF ENGINEER (Gen)
GSECL, BLTPS
6
IMPORTANT
1) Only following listed documents must be submitted on line as well as physically
(Excluding price bid) along with the D.D. of Tender Fee, EMD in sealed cover on OR
before due date and time.
Price Bid shall not be submitted in Hard copy.
1. Demand Draft for Tender Fee and EMD (Original)
2. The bidder shall have a separate Provident Fund Code of RPFC in the name of
company. The bidder, who does not possess such separate P.F. code, shall not
be considered for acceptance of tender. The contractor has to submit attested
copy of such certificate showing P.F. code along with the tender.
3. Attested copy of PAN No & GST certificate.
4. Attested copy of work experience certificate for the similar works executed.
5. List of work in progress.
6. Attested copy of firm registration [Applicable only to the firms registered under
Company Law]
7. Attested copy of partnership deed. [Applicable only to the partnership firms.]
8. Attested copy of power of attorney, if any, for signing the bid document.
9. Attested copy of balance sheet of profit & Loss account duly audited by Chartered
Accountant of at least 3 financial years, if work estimate is more than Rs. 50
Lacs.
10. Attested copy of latest solvency certificate not older than 12 months issued by
any nationalized bank OR Banks as per Annexure – I.
11. Details of equipment, tools and plants immediately available with the tenderer for
use of this work.
12. Details of technical personnel.
13. Undertaking duly Notarized as per attached Declaration Form
14. Any other documents required to verify technical, financial capability of the
bidders & other Credentials
All such documents should be strictly submitted by RPAD / Speed Post only. Otherwise
the offer will not be considered and no any further communication in the matter will be
entertained.
2) In case any deviation is found in Data / Details / Documents between on line offer (e-
tendering) and physically submitted documents then such tender will not be considered
and no any further communication in the matter will be entertained. Tenders must be un-
conditional. Conditional Tenders will be rejected.
3) Further bidders are requested to submit price – bid i.e. Schedule-B on line only and not
to submit the price bid in physical form. This is mandatory. If price bid is submitted in
physical form, same will not be opened and only on-line submitted price will be
considered for evaluation. The bidder is requested not to submit the hard copy of
downloaded tender document, condition of the contract, specification & other
relevant documents, except documents as stated here above. Instead of the same,
the bidder shall submit the duly Notarized Undertaking as stated below declaration form
on the stamp paper of Rs.300/-. However, bidder may download tender document &
preserve with them in Hard Copy for their future reference. Later on, L1 bidder
shall be asked to collect the tender documents from the tender inviting authorities
for the purpose of contract agreement execution and place their signature with
seal of the company.
7
4) It is mandatory for all the bidders to submit their tender documents viz. on-line (e-
tendering) and physically in scheduled time. Tender documents submitted in only
physical form will not be accepted and considered. Also, all bidders shall submit
required Physical documents as stated in Tender Notice.
5) GSECL reserves the rights to reject any OR all tenders without assigning any reasons
thereof.
6) Tender Notice Number & name of the work shall be clearly written on the covers
containing the Bid documents.
7) Technical / Price Bids will be opened on the day and time indicated in the tender notice
by an Officer nominated by the Purchaser in the presence of such of the bidders who
wish to be present.
Any technical questions, information and clarifications that may be required pertaining to
this tender should be referred to the CHIEF ENGINEER (GEN.) BLTPS. Also during pre-
bid meeting (if arranged) the same may please be discussed.
8
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-B
9
(To be submitted duly notarized on Rs. 300/- Non – Judicial Stamp Paper)
DECLARATION FORM
NAME OF WORK : Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
10
due to my lapse, I undertake to reimburse the same or the principle employer is
authorized to deduct the same from my dues as payable.
c) I further declare and undertake the legal consequences which may arise in future
under the said work order awarded, and I bond myself to resolve the same at the
risk and cost of M/s. ______.
12. I / We _________________________________________________________
authorized signatory of M/s ________________________________________ here by
certify that M/s __________________________________________ and their proprietor
/ any partner / any directors of the firm is not stop deal and / or banned for business
dealing and / or black listed by GUVNL and / or their any subsidiary company viz.
GSECL / GETCO / DGVCL / MGVCL / UGVCL / PGVCL as well as Government and /
or Semi Government company / department.
Address :
Phone No.
Mobile No.
E-mail ID :
11
RTGS DETAIL OF BIDDER
NAME OF WORK : Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
Following RTGS details shall be submitted by agency along with the tender for direct deposit of
payment to the beneficiary account. Bidder has to submit the details as under:
1. Name of Bidder :
3. E-Mail ID :
5. Name of Beneficiary :
9. Type of account :
SIGNATURE OF CONTRACTOR
12
PROJECT SYNOPSIS AND DATA
1. Location Bhavnagar thermal power plant
2. Purchaser Gujarat state electricity Corporation
Ltd.
3. Engineer Chief Engineer(G)
4. Site of Project Bhavnagar thermal power plant,
Dist.-Bhavnagar, Gujarat(India)
5. Nearest town Bhavnagar(25km)
6. Nearest Railway Station Bhavnagar(25km),Broad Gauge
7. Nearest Port Pipavav port
8. Nearest Air Port Bhavnagar(28km)
9. Access Road Road Highway 1.0km from state
highway SH-25/1
10. Site Elevation from MSL ---
11. Meteorological Data
* Ambient Air temperature
1 Highest monthly mean of daily Max 45 C
Temperature ( In 0C)
2 Maximum dry bulb Temperature ( In 0C)
3 Minimum dry bulb Temperature ( In 0C)
* Rainfall
1 Average annual rainfall (In mm)
2 For 01 hour ( In mm)
3 For 24 hour ( In mm)
* Wind velocity
1 Maximum wind velocity (In m/sec
2 Wind direction – N,NE & SW
3 For 24 hour ( In mm)
* Relative Humidity
1 Annual mean humidity ( In
2 Maximum humidity (In %)
3 Minimum humidity (In %)
4 Type of Atmosphere
12. * Design Data :
Seismic Data
Zone FIVE
Intensity
Ambient temperature
Other Data
13
SCOPE OF WORK AND SITE CONDITIONS
The main scope of the work is Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
Under the scope of this tender the agency has to carry out the subject work, various civil works
as per all items of Schedule B and as per detail technical specifications items. The quantities
taken under individual items are very tentative. However the agency has to carry out the works
as per the Company’s requirements.
The agency has to carry out the works as per item & specifications of the tender by providing
all materials of best quality and of standard manufactures as the samples approved by EIC and
providing best workmanship through expert manpower.
The agency has to carry out the works as per the priority & schedule given by EIC time to time
even in on or off working hours of the office. The agency will take complete care and will not
damage any other structure in premises of company.
The agency has to carry out all the works by taking all due cares of safety, security norms, with
all risks including scaffolding, strutting, shoring, etc up to any height irrespective of quantum of
the work.
Contractor has to make arrangement for workable site condition with the cooperation
of departments of company and agencies, all necessary arrangement to get work
permit is to be made by contractor. Day to day cleaning is required after completion of
job. The removed materials and any other unwanted materials are to be transported
and taken away as instructed by E.I.C.
All safety measures shall be taken by the contractor with his own cost.
The scope of work to be carried out by the Contractor shall also include Clearance of the site,
Disposal of debris, excavated material etc,
14
SPECIAL NOTE FOR PRE-QUALIFICATION
NAME OF WORK : Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
The tender documents are of two separate bids i.e. technical and price bids. Bidder is
requested to submit the technical bid with the following credentials for post-qualification.
1. Bidder should produce evidence of having experience of successfully completed OR
ongoing works having satisfactory progress of similar works as defined hereunder,
carried out in Central & State Government / Semi-Government / GSECL / GETCO /
DGVCL / MGVCL / UGVCL / PGVCL, public limited company, during the last seven
years ending last day of the month previous to the one in which tender is invited. Bidder
should submit self-attested copies of documentary evidence, preferably photo copies of
work completion certificate, certificate regarding works on hand progressing
satisfactorily along with certificate of amount of work done, work order with Schedule-B,
etc. from the respective department. The amount of work completed OR ongoing works
should be either of the following:-
a. Three similar completed works each costing not less than the amount equal to
40% of the estimated cost.
OR
b. Two similar completed works each costing not less than the amount equal to 50%
of the estimated cost
OR
c. One similar completed works each costing not less than the amount equal to 80%
of the estimated cost
2. Experience certificate of work executed with private firm shall not be accepted.
Experience as a joint venture or sub-contractor is not allowed and price bid of such
bidders will be rejected.
15
On opening of Technical Bid, if any required attested documents are missing in technical
bid submitted by the bidder, and tender inviting authority is in the opinion that in absence
of these documents sufficient competition is not possible, in that case to have fair
competition, the tender inviting authority may inform only once by Registered post to
bidder/bidders to submit the missing required documents within stipulated time limit and
failing which bidder/bidders will be declared technically disqualified for not submitting the
required documents along with technical bids without any further notice. However,
document will be considered valid only if it is for the period of last day of month previous
to the one in which tenders are invited.
9. G.S.T.NO. HAS TO BE SUBMITED WITH THE TECHNICAL BID OR OTHERWISE
TENDER WILL BE LIABLE FOR REJECTION.
16
GENERAL INSTRUCTIONS TO THE BIDDERS
1. SUBMISSIOIN OF TENDER
The tender should be submitted in one sealed main envelope marked MAIN COVER.
Tender number & name of work should be written on the cover.
TECHNICAL BID COVER:
This cover shall contain all relevant attested qualifying documents as prescribed in
tender notice along with tender fee & EMD.
Note: - If attested copies of qualifying documents stated as prescribed in tender
notice are not found in on-line Technical bid, but documents received in physical
form (i.e. in the Technical Bid Cover) will be treated as final to consider the bid for
pre-qualification. Any missing documents, if required will be asked from the
bidder as mentioned in this tender elsewhere.
PRICE BID:
The price bid shall have to be submitted online only. The percentage rates and price
shall be written both in words, and figures and the units in words. In case of any
ambiguity or mistakes, the unit rates and prices written in words shall be considered as
final.
Offered rate shall include cost of all Materials, wastage of material , Labours for all leads
and lifts, Supervision, setting out works, Machinery and equipment with its mobilization /
demobilization, transportation charges, Clearing of the site both prior to commencement
and after completion of work. Consumables such as, but not limited to petrol, oil, diesel,
lubricants, drill bits, pipes, ropes etc. Construction facilities such as scaffolding,
tarpaulins, wind break, etc., Overheads / profits of Contractor for due performance of the
work under this contract.
All royalties, sales tax, toll tax, local tax, development charges, VAT tax, and any other
taxes including works contract tax etc., in respect of this contract and also any statutory
variation in future towards above mentioned taxes & any other taxes if levied in future by
statutory authority applicable to the this contract shall be payable by the contractor and
GSECL will not entertain any claim whatsoever in this respect.
The rates will be "Excluding the GST”, The reimbursement against “GST" will be paid to
the contractor as per Govt. Rules & Regulations. Contractor has to ascertain that
whether he is availing abatement for GST purpose or not. If no clarification is received, it
shall be assumed that the contractor is availing benefit of abatement.
Further information required, if any, can be had from the office of the Chief Engineer,
GSECL, BLTPS. But it must be clearly noted that the tenders must be received
complete in every respect by the due date and time.
(a) The bidder must clearly quote rates in figure as well as in words. In case of any
discrepancy, whatever written in words shall prevail.
(b) No deviation in terms & conditions, Schedule-B and technical specifications will
be entertained. Any ignorance for this shall not relieve the contractor from his
contractual liability arising as per tender documents and conditions contained in
it.
(c) The bidders are required to quote only firm prices. No variation will be accepted
on price/ raw materials/ finished products or on any other cause.
(d) The bidders should note that the completion of above mentioned works in all
17
respect in accordance with the time limit given is very important and should be
strictly adhered to. The work is to be completed in time limit from the date of issue
of written order to commence the work by the Chief Engineer (Gen.), GSECL,
BLTPS.
(e) The bids should be valid for a minimum period of 180 Days from the date of
opening of technical bid. During this period tenderer shall not be allowed to
withdraw their tender and if withdrawn, the Earnest Money Deposit submitted with
the tender will be forfeited.
(f) The works covered under these specification shall be carried-out and governed
by “Tender and contract for Works” booklet appended herewith except where
conditions specified in this specifications.
(g) The successful bidder shall have to enter in to an agreement for contract as per
G.S.E.C.L rules on a stamp paper of Rs.300/- and necessary stamp duty charge
shall be borne by the contractor / consultant.
You will also have to execute indemnity bond for workmen compensation worth
Rs.300.00 and should be presented along with above contract agreement.
(h) The complete specification comprises of the following.
Bill of Quantities (Schedule-B), instructions to the bidders, Tender specifications
and scope of work, Tender and contract for Works booklet, General Conditions,
Instructions to bidder & Technical specifications. All these sections are
complimentary to each other. The particulars and requirements contained herein
shall cover the execution of the works covered under these specifications.
(i) The tenderer must visit the site of works and see for himself the site conditions
regarding availability of approach road during all seasons and other matters
affecting the above works before submitting the tender.
(j) The submission of tender by a contractor implies that he has read these
instructions the conditions of contract etc. and has himself aware of the scope
and specifications of the work to be done and of conditions and local conditions
and other factors bearings on the execution of the works. GSECL will not
therefore after acceptance of contractor's rate pay any extra charge for any other
reason; in case the contractor is found later on to have misjudged the site
condition.
(k) GSECL’s authorized officers who accepts tender, shall have the right of rejecting
all or any of the tenders and will not be bound to accept the lowest offer nor to
assign any reason whatsoever for the rejection of any tender or all tenders.
(l) Bidders shall provide evidence of their continued eligibility to the satisfaction of
the owner.
(m) Bidders shall not be listed under a declaration of ineligibility for corrupt or
fraudulent Practices issued by the Govt., the list of black listed Contractors
announced by GSECL (erstwhile GEB) Govt. of Gujarat or its Public Sector
undertakings or the contractors who are under stop dealing in GUVNL and /or
their any subsidiary company viz. GETCO/MGVCL/UGVCL/PGVCL/DGVCL.
(n) The bid, and in case of a successful bid, the Form of Contract Agreement, shall
be signed with the name of Firm / company which will be legally binding on all
partners / parties.
(o) If the application is made by an individual, it shall be signed by the individual
above his full typed written name and current address.
(p) If the application is made by a proprietary firm. It shall be signed by the proprietor
18
above his full typed written name and the full name of his firm with its current
address.
(q) If the application is made by a partnership firm, it shall be signed by all the
partners of the firm above their full type written names and current addresses or
alternatively by partner holding power of attorney for the firm in which case a
certified copy of the power of attorney shall accompany the application. A certified
copy of the partnership deed, full names and current addresses of all the partners
of the firm shall also accompany the application.
(r) If the application is made by a limited company or a Corporation, it shall be
signed by the authorized person holding power of attorney for signing application
in which case a certified copy of the power of attorney shall accompany the
application. Such Limited company or Corporation may be required to furnish
satisfactory evidence of its existence before the pre-qualification evaluation. They
should also furnish Articles of Memorandum of Association. If the application is
made by group of companies, it shall be signed by the authorized person. The
authority letter shall be accompanied with the application.
2. SECURITY DEPOSIT
As per the prevailing rules of the GSECL, successful bidder have to pay Security
Deposit (S.D.) equivalent to 5 % of the contract value. The same shall be paid in DD or
in the form of Bank Guarantee on any of the banks describe in Annexure-I as per the
GoG notification issued from time to time will be applicable. Total S.D. equivalent 5% of
contract value shall be paid to GSECL within 10 days along with acceptance of LOI.
After lapse of 10 days, if successful bidder not paying SD then, RPAD notice will be
issued to the successful bidder mentioning that on failing to pay security deposit within
next 07 days from the date of issue of RPAD Notice the EMD will be forfeited. However,
Tender inviting authority at his discretion may decide and prolong the time period for
paying of the Security Deposit as per the urgency of the work.
In case successful bidder not at all responding within notice period or withdraws
his offer then his EMD shall be forfeited and he will not be allowed to participate
in the tenders invited from BLTPS office for the period of One year.
The security deposit amounting to 5% shall be released immediately after passing of
final bill.
3. MAINTENANCE:
i] The contractor shall be responsible to make good and remedy at his own expense any
defect which may develop or may be noticed before the period mentioned hereunder
from the certified date of completion. The same shall be attended within 15 days of
receipt of the notice. In the case of failure on the part of the contractor, the Engineer-in-
charge may rectify or remove or re-execute the work at the risk & cost of the contractor.
The Engineer-in-charge shall be entitled to appropriate the whole or any part of the
amount of security deposit towards the expenses, if any, incurred by him in rectification,
removal or re-execution. The defects liability period shall be as under,
a) For all works costing more than Rs. 50,000 and up to Rs. 1 crore (amount put to
tender), the period shall be 06 months from the certified date of completion OR one
monsoon whichever is later.
For the purpose of deciding monsoon period, the 30th September may be treated as the
last date.
19
The scheduled time limit for the completion of work shall be 04 (four) month from the
date of issue of letter to commence the work. However extension in time limit will be
granted by GSECL for the genuine reasons only as per terms of the contracts.
5. TERMS OF PAYMENTS:
Contractor shall be paid RA bill after observing GSECL’s general procedure and
submission of bill by the agency. 100% bill amount within 30 days after recording of
Bill. The above payment term is applicable to all the bills of general civil works &
ARC/BRC works, provided the bills are recorded regularly and submitted to Account
Section within Thirty [30] days. If the contractor fails to submit the bills regularly in
such a way so that the same cannot be recorded and submitted to account section
within Thirty [30] days, ad-hoc payment may not be released and payment will be
released as per GSECL’s general procedure. The period of Thirty [30] days shall be
considered from the date of receipt of last R.A. Bill by Account Section. Amount of GST
& applicable cess will be kept under retention till submission of documentary proof of
payment of GST or till reflection of GST pertain to respective bill amount in GST return
for concern order after due verification.
6. ASSIGNMENT:
The rights and liabilities of the contractor shall not be assigned or transferred by them
without the consent in writing of the GSECL to any other person, firm or
organization.
7. The successful Bidder, on receipt of letter of intent will submit within a week's time his
planning / program of works, for scrutiny of the GSECL in a Bar Chart format, clearly
indicating GSECL's inputs also. Contractor will plan his works such that simultaneous
work should progress in such a way that entire job is completed in scheduled time limit
on all the fronts released by GSECL.
8. The successful bidder will have to depute his authorized representative to attend
progress review meetings to be held at GSECL, BLTPS without any extra cost.
9. The Contractor will be responsible for complying with all rules and regulations and
labour laws applicable to him and the GSECL will not be responsible for any lapses
committed by them. If there is any claim from any Government authority pertaining to the
contract, the same amount will be deducted from the Contractor's bill.
10. The time limit for completion of work is stipulated as in the tender will be adhered to.
11. The Contractor's rates should be firm and no variation clause is to be quoted by the
Contractor and GSECL will not accept the same, during contractual period including
extended time limit if any.
12. BIDDER TO STUDY, ANALYSE & CONSIDER:
a) The information given in this specification is in good faith and meant to serve as a
guide to the Bidder. It is, therefore, imperative that Bidder shall obtain and
examine for himself all the data, information and particulars required for the
satisfactory execution of the work under this tender. The submission of a bid by
Bidder implies that he has fully read the specifications, bid drawings, instruction
to the bidder along with Contract Document and Conditions of Contract,
applicable labour laws, safety norms etc., and has made himself aware of the
scope and the specifications for the work to be performed and local conditions
and other features which have a bearing on the cost and execution of the work.
This specification is intended as a general description of quality envisaged for
materials and workmanship and of the finished work. It is not intended to cover
minute details. The work shall be executed in accordance with the best modern
practice and to the complete satisfaction of the Purchaser. Special techniques
20
approved by the Purchaser shall be used if and where found necessary. This
specification shall have precedence if anything contrary to this is stated
elsewhere in the contract documents. The Purchaser’s decision shall be final and
binding on the contractor on any issue arising out of such discrepancies.
b) Inspection of site by bidder:
Before submission of his bid, Bidder shall inspect the site, examine and obtain all
information required and satisfy himself regarding matters such as:
weather characteristics,
Location of site and access, right of way, means of communication & mode
of Transport to site,
Labours condition.
Local working conditions, obstructions and hindrances that may arise etc.
All materials brought to site only after making entries in security register at
Control gate
c) These factors are likely to affect the satisfactory completion of work and or cost
thereof. The submission of a bid by the Bidder will be construed as evidence that
such an examination was made and any later claims/ disputes in regard to rates
quoted shall not be entertained or considered by the GSECL.
d) The site visit shall be done by the bidder on his own responsibility and all
liabilities including cash, arising out of the site visit shall be at the bidder’s
account.
e) Contractor’s scope of work shall also include making all necessary arrangements
for access to work sites, stores and site offices etc. from the nearest approach
road to facilitate transportation of man power, machinery and equipment duly
considering the existing site conditions. No extra claims / costs will be entertained
by GSECL.
f) The bidder shall carefully study the work to be carried out & consider all the
factors & shall take into account & consider all the factors such as lead, lift
haulage of materials, sequence of construction, etc. & shall allow for all such
information / data in the rates quoted.
g) The GSECL will not pay any extra charges or rate for any reason in case the
contractor claims, after acceptance of contract to have misjudged the site
condition. Ignorance of the intents and contents of the specification document
and site conditions shall not be accepted by the Owner as basis for any claims for
compensation.
h) BIDDER shall inspect the site, examine and obtain all information required and
satisfy himself regarding matters such as sub-surface conditions, water records,
access to site, communication, transport, right of way, the type and number of
21
equipment and facilities required for the satisfactory completion of work, the
quantity of various items of the work, the availability and rates of material, local
working conditions, uncertainties of weather, obstructions and hindrances that
may arise etc. which may affect the work or cost thereof, before submission of his
bid. Ignorance of site conditions shall not be accepted by the ENGINEER IN
CHARGE as basis for any claim for compensation.
i) The rates quoted by BIDDER shall be based on his own knowledge and judgment
of the conditions and hazards involved and shall not be based on any
representations of the Engineer in Charge. No claim on this account shall be
admitted by the GSECL.
j) The bidders shall submit their offer without any deviations in general terms and
conditions of the contract or in technical specifications.
k) Tenders received after the time and date specified in the tender notice will not be
accepted. Once the offer is submitted by bidder before due date of submission,
the bidder shall not be allowed to submit revised/ additional/ modified offer even
before due date and time of submission of tender. However, if the date of issue
and/or submission of tender are extended by the Corporation due to any reason,
the bidder may submit if their wishes the revised/additional/modified offer before
extended due date and time of submission.
l) The Corporation reserves the right to accept any tender irrespective of whether it
is lowest or not or to reject all the tenders without assigning any reasons thereof.
Tenders deferring from the technical specifications or the method of bidding in a
radical manner may also be rejected.
m) The bidder shall be presumed to have carefully examined the drawings,
conditions & specifications of work & to have fully acquainted themselves with all
details of the site conditions, locations, materials, geological & weather
characteristics, labour conditions & in general all the necessary information and
data etc. pertaining to and need for the work.
n) This specification is intended as a general description of quality envisaged for
materials and workmanship and of the finished work. It is not intended to cover
minute details. The work shall be executed in accordance with the best modern
practice and to the complete satisfaction of the Purchaser. Special techniques
approved by the Purchaser shall be used if and where found necessary. This
specification shall have precedence if anything contrary to this is stated
elsewhere in the contract documents. The Purchaser’s decision shall be final and
binding on the contractor on any issue arising out of such discrepancies.
o) Each bidder shall also submit a 'Declaration' to the effect that the tenderer is an
engineering construction firm or an association of firm or firm which has
successfully carried out large works of this nature and has adequate organization
and experienced personnel to handle this type and magnitude of work.
Information should also be given regarding the constitution of the firm; it’s
authorized, subscribed & paid up capital, the date & place of registration, the
place of business, the names of the directors and other relevant information.
p) It is the intent of the ENGINEER IN CHARGE to incorporate these specification
documents in the final ‘Contract’. BIDDERS are required to review these
documents and clearly state in their proposals their acceptance of the same.
q) Each page of the bid document including the bid drawings shall be signed,
stamped and dated in ink by the BIDDER as a token of having examined the
same. Any correction in price and the rates entered in the Schedule of Price shall
also be signed and dated by the BIDDER in ink, before submitting the bid. Non-
compliance with this condition will make the bid liable for rejection.
22
r) All safety measures as required to be adopted as per the Statutory
Regulations and the Safety Rules of the Plant shall be strictly followed by the
Contractor during the execution of the Contract. The Contractor shall set up
a suitable safety organization of his own in this regard.
s) In connection with the execution of the Contract, the Contractor shall comply
with all applicable statutory Rules & Regulations including employment of
labours at site.
t) The Contractor shall carry out any and all such works, as may be required,
for civil work to be completed in all respect as per the Contract Specification.
u) If the GSECL Engineer-in-Charge is not satisfied with the progress of work at
site, he shall direct the Contractor to depute more numbers of supervisory
personnel/workers to meet the completion schedules as per the Contract.
Upon receiving such direction, Contractor shall deploy additional personnel
within 7 days without any extra cost.
v) The GSECL may during the progress of work, order the removal of part or
whole of the work executed, found not in accordance with the specifications/
instructions. No extra claims shall be entertained for re-executing or altering
of such work.
13. SAFETY MEASURES
The contractor shall ensure the safety of workers, material and structure including
existing structures during execution of the contract. Safety measures shall be followed
during operations of equipments/machinery being used. No separate payment shall be
made for the safety measures and the quoted rates shall include the cost for all safety
measures.
14. COMPLETENESS:
Any technical services as set forth here in above and which might not have been
specifically mentioned in this Contract relating to the work or in the specifications and
which are not expressly excluded therefore but which are necessary for the performance
in accordance with the specifications as an integral part of the painting and misc. Civil
works shall be rendered by the Contractor without any extra cost.
15. TOTAL RESPONSIBILITY
The Contractor shall be solely responsible for the entire technical works / services
irrespective of works / services have been made /rendered by him.
16. PAYMENT TO THE LABOURES
(a) Contractor has to contribute as per EPF & MP act the CPF as well as salary to
his skilled/unskilled manpower through bank transfer, as per minimum wages &
prevailing applicable rules on or before 7th day of next month.
(b) Contractor has to produce challan of PF with list of employees.
(c) HR compliances to be submitted by party as per GSECL rules.
17. CONTRACT AGGREMENT ON ACCEPTANCE
The successful contractor will have to sign an agreement as per the Gujarat State
Electricity Corporation Ltd.'s rules on stamped paper and the necessary stamp
duty charges shall be borne by the contractor.
On acceptance of the tender the name (s) of the accredited representative (s) of
the tenderer who would be responsible for taking instructions from the Engineers
23
of the GSECL shall be communicated to Chief Engineer (Gen.) BLTPS, Gujarat
State Electricity Corporation Limited.
18. UNSATISFACTORY PROGRESS OF THE WORK
If the work is found not progressing as per the requirement or found not satisfactory then
GSECL will take such action to get the work done through the other agency at agency’s
risk and cost with 15% supervision charges and same will be recovered from agency.
19. The EMD will be returned promptly to the unsuccessful bidder except that of L1, L2 & L3
till the successful contractor pays the Security Deposit as mentioned in tender document
or after the expiry of the validity of the offer, whichever is earlier.
The EMD will be returned to the successful tenderer after he furnishes the Security
Deposit for the tender work. If he fails to furnish the SD, his EMD shall be forfeited and
the tenderer will not be allowed to participate in the tenders invited by this office for a
period of ONE Year in respective Power Station.
THE EMD IN FORM OF BANK GUARANTEE SHALL BE VALID FOR TEN MONTHS
FROM THE DATE OF SUBMISSION OF THE TENDER.
20. EFFECT AND VALIDITY OF BID The submission of bid with these documents and
specification shall constitute an agreement that bidder shall have no cause of action or
claim against the GSECL for rejection of his bid. The GSECL shall always be at liberty to
reject or accept, split any bid or bids at its sole discretion and any action will not be
called into question and the bidder shall have no claim in that regards against the
GSECL.
21. STOP DEAL / BANNED FOR BUSINESS DEALING / BLACKLISTING :-
Has revised/ withdrawn price bid after opening of Techno-commercial bid, until
and unless it is sought for,
Has refused to accept Letter of Acceptance / Purchase order / Work Order after
the same is issued by the company within the validity period and as per agreed
terms and conditions,
Has failed to provide suitable expertise for the work as per pre-scheduled
program.
Has failed to submit all the necessary tests reports / documents within time
scheduled / as per company’s time limit, as mentioned in the LOA, if the Letter of
Acceptance (LOA) is placed subject to submission of type reports / documents to
the firm.
Has supplied inferior quality / defective materials and refused to replace with
stipulated time frame, as specified by the company,
Has substituted materials in lieu of materials supplied by the company or has not
returned or has short returned or has unauthorisely disposed of materials /
documents / drawings / tools or plants or equipment supplied by the Company,
24
Has involved in malpractices such as bribery, corruption, fraud, canvassing and
pilferage,
Any other ground for which in the opinion of the Company makes it undesirable to
deal with the Firm
In case the state Government directs the Company to place a firm in stop dealing
/ banned for business dealing / blacklisting.
As If in any company, the interest of any employee of the Gujarat State Electricity
Corporation Ltd. or his relative as defined in Section-6 of the Company’s Act.
1956, is 10% or more, GSECL will not deal with such company at all. Tenderer
therefore, must specifically disclose this fact in his technical Bid. Nondisclosure of
such facts would disqualify the Tenderer for further dealing with Gujarat State
Electricity Corporation Ltd.”
25
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-C
26
GENERAL CONDITIONS OF CONTRACT
1. DEFINITIONS :
(a) The Contract means the documents forming the tender and acceptance thereof,
together with the documents referred to therein or individual work order in the
case of term contract, including these conditions, schedules and/or additional
conditions attached to the form of tender or individual works, order, rate schedule,
the specifications and the drawings and all these documents, as applicable, taken
together shall be deemed to form the contract.
(b) The “Tender Document” means the form of tender, the applicable schedules
and/or additional conditions and the specifications and/or drawing as issued to
the contractors for the purpose of preparing tender.
(c) The expression “Works” or “Work” when used in the condition of contract shall,
unless there be something in the subject or context repugnant to such
construction means, the works or the work contracted to be executed under or in
virtue of the contract whether original or altered.
(d) The “Contractor” means the individual or firm or Corporation, whether
incorporated or not, undertaking the words and shall include his or its legal
personal representatives, successors and permitted assignees.
(e) “Corporation” means The Gujarat State Electricity Corporation Ltd. and the
“Accepting Officer” means the Officer who is authorized to sign and signs the
contract on behalf of the “Corporation”.
(f) The letter “EE” means Executive Engineer who in the case of measurement and
lump sum contract, direct the contract and the letters “SE” means Superintending
Engineer and “GM” means General Manager who administers and in the case of
the term contracts, directs the contract.
(g) The “Engineer-in-charge” means all officers of the Corporation appointed by the
General Manager to supervise the works or part of the works.
(h) “Approved” and “Directed” means the approval or direction of the
Chief Engineer (Gen), BLTPS to Superintending Engineer or the person deputed
by him for the particular purpose.
(i) “BS.” means “British Standards” as issued by the British Standards Institution.
“A.S.” means the “American Standards” as issued by the American Standards
Institution, and “I.S.” means the “Indian Standards” as issued by the Indian
Standards Institution. Wherever the above-mentioned abbreviations are referred
to, in the specifications and/or work orders, they mean the addition with all
amendments current at the date of issue of tender document of work orders.
(j) In the case of measurement and terms of contract “Specifications” mean those
contained in Gujarat State Electricity Corporation Ltd. scheduled together with
any amendments etc. embodied in the tender documents. “Drawing” refers to
those incorporating the tender documents and/or any work orders referred
therein.
(k) The “Contract Sum” means the sum accepted or the sum calculated in
accordance with the prices accepted in the tender and/or the contract rate as
payable to the contractor for the full and entire executing and completion of
works.
(l) “The date for completion” is the date or dates of completion of the work or any
part of the works set out or ascertained in accordance with the individual work
27
orders and the tender documents or any subsequent agreed amendments
thereto.
2. CONTRACTOR TO INFORM HIMSELF FULLY:
(a) Notwithstanding anything contained to the contrary in the specifications or
tenders in subsequent exchange of correspondence, the conditions of contract
shall be binding on the Contractor and any change or variation expressed or
implied, however made in the said conditions, shall not be valid or operative
unless expressly sanctioned by the Corporation. The Contractor shall be deemed
to have fully informed himself and to have special knowledge of the provisions of
the conditions of the Contract herein contained.
(b) The contractor shall be deemed to have carefully examined the work and site
conditions, the general conditions, the special conditions, specifications,
schedules and drawing and shall be deemed to have visited the site of the works
and to have fully informed himself regarding the local conditions.
(c) If there shall have any doubt as to the meaning of any portion of these general
conditions or special conditions of the scope of work of the specifications or any
other matter concerning the contract, he shall in good time before submitting his
tender, send for the particulars thereof and submit them to the Engineer-in-
charge in writing in order that such doubt may be removed.
3. CONTRACT DRAWING AND SPECIFICATIONS:
(a) The contractor will be entitled to receive one set of agreement along with one
certified copy of accepted tender.
(b) The drawings which form part of these specifications show the work to be done in
as much detail as is possible at the present stage. They will be supplemented by
such additional detailed drawings as may be necessary as the work progresses.
The contractor shall perform the work on these features and in accordance with
these additional or revised drawings as the case may be and at the applicable
rates as per the contract.
(c) The contractor shall check all drawings carefully and shall bring to the notice to the
Engineer-in-charge immediately of any errors or omissions discovered. The
contractor shall not take advantages of errors or omissions of any kind in the
drawings supplied.
4. INPUTS BY GSECL:
(a) The electric power supply connection and power supply for construction /
maintenance work purpose shall be given at one mutually agreed point at work site
free of cost by the GSECL. Further extension for construction/maintenance site as
well as bore well site for using water will have to be carried out by the contractor
as per requirement at their cost.
(b) If there are any surplus quarters available after meeting the requirement of
GSECL's staff, then GSECL will consider allotment of quarters on rent as per
GSECL's rule.
(c) The contractor will have to make their own arrangement of water for
construction work as well as for their labourers at his own cost. If possible,
water for construction purpose only at one point may be given as decided by
EIC and recovery for water charges shall be affected at the rate of 2 % of the
item in which water is used or quantity of water measured by meter system
installed by contractor, rate of water supply will be charged at prevailing
purchase rates of GSECL, for water supplied by GSECL is used as certified
28
by EIC. In case of agency is installing bore well and pumps at his cost, after
completion of work agency will hand over the bore well in good condition with
pumps to the GSECL.
5. DATA TO BE FURNISHED BY CONTRACTOR:
(a) The contractor shall submit to the Executive Engineer for approval within one week
of the date of contract, a layout plan of construction plant and equipment for the
execution of work which the contractor proposes to adopt at site.
(b) Prior to commencement of work, the contractor shall submit to the Executive
Engineer for approval, plans in triplicate showing the location of Major plant shop
and storage buildings, storage yards, offices, contractor's power house including
its services and housing facilities which he proposes to put up at site and also
indicate the programme of the work.
(c) The successful bidder on receipt of letter of intent will submit within a week's time
his planning/programme of works for scrutiny of GSECL in a PERT/Bar chart
format, clearly indicating GSECL inputs also.
(d) Contractor will plan his works such that on all the fronts released by GSECL,
simultaneous work should progress in such a way that entire job is completed in
scheduled time limit.
(e) No change in the approved layout shall be carried out without specific written
approval of the Executive Engineer.
6. ERRORS, OMISSIONS AND DISCREPANCIES:
In all cases of errors, omissions, doubts or discrepancies in the dimensions, or
discrepancies in the drawings and items of work in specification, reference shall be
made to the Executive Engineer whose elucidation and elaboration shall be considered
as authoritative. The contractor shall be held responsible for any error that may occur in
the work thorough lack of such reference and precautions.
7. SECURITY DEPOSIT:
The contractor shall, within 10 days of the issue of letter of intent, pay 5% of the contract
value in the form of the unconditional bank guarantee from schedule bank in lieu of cash
or Government securities towards Security Deposit which will be accepted provided
amount of security deposit payable exceeds Rs. 10,000/-. Security Deposit can also be
paid as fixed deposit receipt as prescribed in Section “F”.
After lapse of 10 days, if successful bidder not paying SD then, RPAD notice will be
issued to the successful bidder mentioning that on failing to pay security deposit within
next 07 days from the date of issue of RPAD Notice the EMD will be forfeited. However,
Tender inviting authority at his discretion may decide and prolong the time period for
paying of the Security Deposit as per the urgency of the work.
In case successful bidder not at all responding within notice period or withdraws
his offer then his EMD shall be forfeited and he will not be allowed to participate
in the tenders invited from BLTPS office for the period of One year.
All damages, costs, charges, expenses and other sums which may be or may become
due or payable by the contractor to the Corporation under the terms of the contract, may
be deducted from the cash in the proceeds of sale of the securities/bank guarantee so
deposited (which the officer or person to whom the same may be endorsed as aforesaid
is hereby authorized to sell/to encash for that purpose) or from the interest of any such
securities or from any sums due or which may become due to the contractor by the
Corporation or from the whole or the balance unpaid as aforesaid of the encashed
29
securities so deposited being repaid or transferred and returned as the case may be, to
the contractor on finalization of final bill.
Entire Security Deposit paid in approved form of Bank Guarantee should remain valid
during the contractual period and such bank Guarantee should not be reduced on the
basis of the work actually done.
8. USE OF LAND:
The land required for office, godowns and for labour camp if not available with GSECL,
then the contractor has to arrange the same at his cost. GSECL will give the land only if
the spare land is available with the following conditions.
The contractor shall be permitted to use for the bonafide purpose of execution of this
contract free of cost. The contractor shall be permitted to use for the bonafide purpose
of execution of this contract free of cost.
(a) Site required for the construction of the work.
(b) Required approach road. The contractor shall make their own arrangements for
the necessary approach, road, for transport of their materials and be responsible
for the compensation on account of damage to crop etc. and shall till completion
of work.
(c) He will be charged the rent at the annual rate of rupees one hundred per every
acre or part thereof, for the construction of temporary hutments and his store yard.
However area required for such purpose may be clearly indicated in this offer.
All areas of operation, including those for his staff and labour colonies
handed over to the contractor shall be cleared and handed over back in
good condition to the Engineer except areas under works as per this
contract or those for which specific approval has been obtained from the
Engineer. The contractor shall make good to the satisfaction of the
Engineer any damage or alternation made to areas which he has to hand
over back or to other property land handed over to him for purpose of this
work.
All produce from cutting of trees; grass etc. shall be the property of GSECL
30
and shall be stocked at the place specified by the Engineer. No claim shall
be made for such cutting and stacking of trees or grass etc. by the
contractor
The contractors shall not unnecessarily or for use as fuel, cut any trees
brush wood, grass or other vegetation nor shall set fire there to without the
written permission of the Engineer. When such permission is given, the
contractor shall take necessary measures to prevent damage or to prevent
fire spreading to surrounding property, and shall be responsible for any such
damage, if cause.
38
designs, drawings, specifications, estimates, instructions, orders or these conditions or
otherwise concerning, the works or the execution or failure to execute the same,
whether arising during the progress of the work or after the completion or abandonment
thereof.
37. ARBITRATION
“ALL QUESTIONS, DISPUTES OR DIFFERENCES, WHATSOEVER WHICH MAY AT
ANY TIME ARISE BETWEEN THE PARTIES TO THIS CONTRACT IN CONNECTION
WITH THE CONTRACT OR ANY MATTER ARISING OUT OF OR IN RELATION
THERETO, SHALL BE REFERRED TO THE – “GUJARAT PUBLIC WORKS
CONTRACT DISPUTES ARBITRATION TRIBUNAL” AS PER THE PROVISIONS OF
THE GUJARAT PUBLIC WORKS CONTRACT DISPUTES ARBITRATION TRIBUNAL
ACT 1992.”
The reference to Arbitration proceedings under this Clause shall not:
a. Affect the right of the Engineer-in-charge to take possession of all or any tools,
plants, materials and stores, in or upon the work or site thereof or belonging to
the Contractor or procured by him and intended to be used for the execution of
the work or any part thereof.
b. Preclude the Engineer-in-charge from utilizing the materials purchased by
contractor in any work or from removing such materials to other place, during the
period the work is stopped or suspended in pursuance of Notice given to the
contractor under General Conditions.
c. Entitle the contractor to stop the progress of the work or carrying out the
additional or altered work in accordance with the provision of General Conditions
for the work where there is no specification.
d. Preclude the Corporation from getting work done by other agency.
Neither party is entitled to bring a claim to Arbitration latest by thirty days after the
expiration of the defects liability period.
The provisions of the Arbitration and conciliation Act – 1996, Gujarat Public
Works Contract Disputes Arbitration Tribunal Act, 1992, and Rules made there
under shall apply to the Arbitration Proceedings under this Clause.
38. STORES TO BE OBTAINED FROM CORPORATION [APPLICABLE ONLY WHERE
MATERIAL IS TO BE SUPPLIED BY CORPORATION AS MENTIONED IN
SCHEDULE A]
The contractor shall obtain from the Corporation stores, such articles as are mentioned
in schedule “A” which may be required for the work or any part of the work or in making
up any articles required therefore or in connection therewith, unless he has obtained
permission in writing from the Executive Engineer or obtained such stores and articles
from elsewhere. The value of such stores and articles as may be supplied to the
contractor by the Engineer-in-charge will be debited to the contractor in his account at
the rate shown in the schedule “A” attached to the contract and if they are not entered in
said Schedule, they shall be debited to him at cost price which for the purpose of this
contract shall include cost of carriage and all other expenses whatsoever which may
have to be incurred in obtaining delivery of the same at the stores aforesaid and further
overhead charges 15%.
The Contractor shall be responsible for the loss, destruction or deterioration of the
materials, stores or articles supplied to him by the Corporation, even if such loss,
destruction or deterioration has occurred under any circumstances whatsoever beyond
his control as if the materials, stores or articles so supplied were his property. The
39
contractor shall be responsible for returning the residual materials after completion of
the contract and it fails to return, the balance materials supplied to him by the
Corporation, the cost of the residual materials will be recovered from the contractor at
the market rate or stock issue rate whichever be higher at the time of materials account
plus 15%.
39. LUMP SUMS IN ESTIMATE
When the estimate on which tender is made, includes lump sums in respect of parts of
the works the contractor shall be entitled to payment in respect of the items of works
involved or the part of the work in question at the same rates as are payable under this
contract or such items or if the part of work in question is not in the opinion of the
Engineer-in-charge capable of measurement the Engineer-in-charge may at his
discretion pay the lump sum amount entered in the estimate and the certificate in writing
of the Engineer shall be final and conclusive against the contractor with regard to any
sum or sums payable to him under the provision of this clause.
40. LUMP SUM TENDERS
Whenever lump sum tenders have been invited for buildings or other structures of the
same type, design, the contractor shall submit his bill stated in Clause No. 18 and the
Engineer-in-charge not below the rank of work, Executive Engineer shall certify by
general measurement or by other method considered suitable to him, the value of work
done and the contractor shall be paid monthly a sum equal to 90% of the total value the
work so certified, since the last payment, after deducting a part or whole of the secured
advance if not already paid for the materials utilized on the works. An additional secured
advance for any fresh materials utilized on the works. An additional secured advance for
any fresh materials brought on site will also be paid if certified by the officer not below
the rank of Executive Engineer. After the work is completed final bill would be paid on
the certification of officer not below the rank of Executive Engineer, that the work, is
done according to drawing and specifications attached to the tender. If any additions
and alterations have been carried out, detailed measurement in respect thereof shall be
recorded and extra payment or deductions are regulated as per item rates quoted by the
contractor while submitting the tender and if there are any items in the additions and
alterations for which the contractor has not quoted a rate, the payment shall be as per
Clause 39 above.
41. ACTION WHERE NO SPECIFICATION
In the case of any class of work for which there is no such specification as is mentioned,
such work shall be carried out in accordance with the PWD and in the event of there
being no PWD specification, the work shall be carried out in all respects in accordance
with the instructions and requirements of the Engineer-in-charge of the Corporation etc.
42. NO CLAIM FOR VARIATION IN QUANTITIES OR WORK
Quantities shown in the tender are approximate and no claim shall be entertained for
quantities of work actually executed, being either more or less up to any extent than
those entered in the tender or less than those entered in the tender or estimate.
43. NO CLAIM FOR COMPENSATION FOR DELAY IN STARTING WORK
No compensation shall be allowed for any delay caused into starting of work on account
of acquisition of land and in the case of clearance for works or any delay in according
sanction to estimates.
44. NO CLAIM FOR COMPENSATION FOR DELAY IN EXECUTION OF WORK
No compensation shall be allowed for any delays in execution of the work on account of
water standing in borrow pits or compartment. The rates are inclusive for hard or
40
cracked soil, excavation in mud, sub-soil water or water standing in borrow pits and no
claim for any extra rate shall be entertained unless otherwise expressly specified and
mentioned in the tender.
45. EMPLOYMENT OF TECHNICAL PERSONS
The contractor shall keep one full time qualified Civil Engineer at the site, who shall be
fully authorized to receive and comply with such instructions, as given by the Executive
Engineer. The contractor shall intimate the name of such Engineer with his qualifications
and experience. The Executive Engineer shall have the right to demand the removal of
any technical personnel, skilled or unskilled workmen, who in his opinion are considered
to cause bad workmanship in the execution of works or to cause indiscipline
46. INDUSTRIAL LABOUR LAWS
1.0 Wages to be paid and time of payment etc. by the contractor
The contractor shall comply with the labour laws and shall furnish the
returns and information as may be specified from time to time.
At plant gate or at Colony gate, biometric punching system is adopted by
GSECL. Agency has to ensure that their laborers shall punch while entry
and exit from the premises.
Agency has to ensure that labour Payment shall be deposited to the bank
account of concern labour directly and evidence thereof shall be submitted
to Labour welfare officer for verification along with each bills.
The contractor shall as far as possible obtain his requirements of labour,
skilled, and unskilled from the local area. No person below the age of 18
years and above 60 years shall be employed as laborers.
The contractor shall pay fair and reasonable wages (whether or not such
wages are controlled by any laws existing at the time), to the workmen
employed by him for the work. In the event of any dispute arising
between the contractor and his workmen on the grounds that the wages
paid are not fair and reasonable, the dispute shall in the absence of legal
or other relief to the workmen shall be referred to the Engineer-in-charge
who shall decide the same. The decision of the Engineer-in-charge shall
be conclusive and binding on the contractor but such decision or any other
decision in this behalf that the contractor's workmen may obtain by
recourse to law or other level means available to them, shall not in any
way, effect the condition in the contract regarding payments to be made by
Corporation to the contractor only at the rates accepted in this contract.
The contractor shall provide reasonable facilities to the satisfaction of the
Engineer-in-charge, for the labour employed by him where no such natural
facilities exist. The usual facilities are weather proof shelter for rest and
meal, supply of wholesome drinking water, facilities for obtaining food,
reasonable washing and sanitary facilities, special facilities, for women
workers, suitable residential accommodation, recreational and cultural
activities, general sanitation and health measures etc.
The implementation of any and all provisions of this clause shall in no way
entitle the contractor to claim compensation or rates higher than tendered
in this contract.
The Monthly payment of wages to the contract labourers will be
compulsorily made through bank. The Contractor shall supply copy of Bank
Statement duly stamped by the concern Bank as a Token of Proof towards
41
payment of wages to HR Dept. If any problem may arise for payment of
wages through bank, same may inform to Chief Engineer (G) and after
approval the payment shall be disbursed in presence of the GSECL
representative i.e. HR officer during the working hours in the factory
premises and the contractor shall get the entries certified in the register of
wages by the representative of the GSECL. Any default will result in
cancellation of contract forthwith or else the contractor shall be punishable
to the extend of Rs. 100/- per day by way of fine.
The Contractor shall give his telephone number and address to the
GSECL so that in case of labour troubles etc. the contractor can be
contacted. The contractor shall arrange to have his office outside the
factory premises and the contractor has keep himself present
throughout the working hours. The Contractor shall intimate immediately
to Engineer in charge of GSECL in case of any labour troubles etc.
2.0 LABOUR LAWS
(a) Persons below the age of 18 years and above 60 years shall not be
employed for the work.
(b) No female worker shall be employed in the night shift between 7 p.m. to 6
a.m.
(c) Contractor shall maintain a valid labour license from Office of Labour
Commissioner under Contract Labour (Regulation and Abolition) Act for
employing necessary manpower to be required by him. The Contractor
shall submit the required returns to concern authorities and submit one
copy to Corporation. In the absence of such license the contract shall be
liable to be terminated without assigning any reasons thereof.
(d) The contractor shall at his own expense comply with all labour laws and
keep the Corporation indemnified in respect thereof. Some of the major
liabilities under various labour and industrial laws which the contractor
shall comply are as under:
1) Payment of Contribution by way of Employer's Contribution towards
Provident Fund, Family Pension Scheme, Deposit Linked Insurance
Scheme, Administrative charges etc., at the rates made applicable
from time to time by Government of Gujarat/Government of India or
other Statutory Authority. The contractor shall submit along with his
bill (month vice) a statement regarding deductions against
Employees Provident Fund and Family Pension Scheme in respect
of each concerned employee. Provident Fund and Family Pension
Scheme at the rate of 12% (or at the rate made applicable by the
Government from time to time) of the wages. The contractor's
contribution and his workers contribution towards Provident Fund
and Family Pension Scheme shall be deposited by the contractor
with Regional Provident Fund Commissioner, Ahmedabad.
2) Payment of security deposit and License Fee as prescribed
under the Contract Labour (Regulation and Abolition) Act and
rules framed there under depending upon the number of
workmen employed by the contractor.
3) Identity cards as prescribed under the Factories Act with photo
affixed thereto, the same for identification.
4) Payment of retrenchment compensation, Notice pay and other
liabilities as per Industrial Disputes Act. Any payment to the
42
contractor's employees arising out of any claim or disputes under
the Industrial Disputes Act 1947 or any other labour laws.
5) Payment of compensation in case of accidental injury.
6) Provision of crèches if the female laborers employed are more than
30 numbers.
7) Maternity Leave as per the provision of the Maternity Benefit Act.
3.0 LIABILITY FOR ACCIDENTS TO PERSONS
The contractor or sub-contractor shall indemnify the Corporation against any
claims which may be made under the Employee Compensation Act, 2010, or any
statutory modification or otherwise for or in respect of any damages or
compensation payable in consequence of any accident or injury caused, by fault
of contractor or sub-contractor and sustained by any workman or other person in
the employment of the contractor or sub-contractor. In every case in which by
virtue of the provisions of sub-section (1) of section 12 of the Employee
Compensation Act, 2010, the Corporation is obliged to pay compensation to a
workman employed by the contractor or sub-contractor in execution of the work,
the Corporation will recover from the contractor the amount of compensation so
paid, and without prejudice to the rights if the Corporation under sub- section (2)
of section 12 of the said Act any such amount shall be paid by contractor within
30 days, failing which the Corporation shall be at liberty to recover such amount
of any part thereof by deducting it from any some due by the Corporation to the
contractor under this contract or otherwise. The board shall not be bound to
contract any claim made against either of them under section 12, sub- section
(1) of its said Act, except on written request from the contractor and upon his
giving to the Corporation full security for all costs for which the Corporation
might become liable in consequence for entertaining such claim.
The contractor and/or sub-contractor named in the contract shall indemnify
the Corporation against all claims based upon injury or death to any person
in the employment of the contractor or sub-contractor, or to third parties to
the extent of any sums recovered under the insurance policy.
On the occurrence of an accident which results in the death of workman
employed by the contractor or sub-contractor, which is so serious as to be
likely to result in the death of any such workman, the contractor shall within
24 hours of happening of such accidents intimate in writing to the Engineer-
in-charge the fact of such accidents. The contractor or sub-contractor shall
indemnify Corporation against all loss or damage sustained, by the
Corporation resulting directly or indirectly from his failure to give intimation in
the manner aforesaid including penalties or fine if any, payable by
corporation as a consequence of Corporation’s failures, to give notice under
workman's compensation Act or otherwise to confirm to the provisions of the
said Act in regard to such accident.
The contractor will be responsible for complying with all rules and
regulations and labour laws applicable to him and the corporation will not be
responsible for any lapses committed by them. If there is any claim from any
Govt. Authority pertaining to the contractor the same amount will be
deducted from the contractor’s bills or any other amount payable to him.
The above are some of the major liabilities of the contractor in addition to
other liabilities prescribed under the various labour laws in force from time to
time from Statutory Authorities like State Government/ Government of India
which the contractor shall have to comply with.
43
4.0.0 BOCW:- For any construction happening outside the Factory premises, BOCW,
Act will be applicable and the contractor / sub-contractor shall be replied to
comply its labour Laws/Rules.
4.0.1 INSURANCE: "The contractor shall procure, or arrange for the sub-
contractor to procure insurance coverage in amount approved by the
Corporation and sufficient to protect against the following risks arising out
of the work. The contractor shall cover all his employees under
Employee’s Compensation Act if ESI Act is not applicable. The Contractor
has to fulfill his liabilities i.e. contribution, filing of returns etc. if ESI Act is
applicable.
Accidents and professional and non-professional sickness of all laborers
and personnel engaged in the work as required by law pursuant to
Employee compensation Act, 2010.
Injury or death to third parties including without limitation injury or death
caused by any of the construction aids or other vehicles or rented
equipment used by the contractor or subcontractor, whether at the site or
elsewhere".
(a) All insurance referred to under a) of this condition shall be in effect
from the date of commencement of work and shall remain in force
until the work has been completed and finally accepted by the
Corporation or such extended period as may be decided by the
Corporation.
(b) In the policies covering the insurance referred to above, contractor
and sub-contractor shall be named as co-insured where possible.
(c) The cost of insurance shall be borne by the contractor.
(d) Insurance shall be affected for all the contractor’s employees
engaged in the performance of this contract. If any of the work is
subletted to the sub-contractor, the contractor shall require to
provide employee’s compensation and employer’s liability insurance
for the sub latter’s employees unless such employee covered under
the principal contractor’s insurance.
5.0 ACCOMMODATIONS TO LABOURS
(a) The contractor shall, at their own expense make all necessary provisions
for Housing, water supply and sanitary arrangements for their employees
as well as for works and shall pay direct to the authorities concerned, all
rates and taxes.
(b) The contractor shall construct the quarters for his staff on a good spot
selected by him. The contractor shall maintain at his own cost an efficient
staff to clean sewage as may be suggested by Engineer-in-charge.
(c) Suitable fire preventive measures to the satisfaction of the Engineer-in-
charge shall be taken by the contractor.
(d) The contractor shall construct trench or semi-permanent latrines for the
use of laborers. Such latrines shall be on a scale of not less than 5 per 100
persons in the camp. Separate latrines shall be provided for men and
women. The huts for laborers shall be sufficient in nos. and shall confirm to
the following requirement:
(e) Huts of bamboo and grass may be constructed.
44
(f) The camp shall not be established close to a large cutting or earthwork.
(g) The lines of huts shall have open spaces at least 10 yards between two
rows. Due attention shall be given to drainage.
(h) A floor space at a minimum rate of 30 sft. Per head shall be provided in the
hutments.
(i) The contractor shall construct at least one bathing place per 20 persons.
The baths shall be properly screened and separate bathing places for men
and women shall be provided. Washing places shall be provided at
minimum one per 30 persons.
(j) Sufficient arrangements for drainage of sewage water from bath, washing,
etc. shall be made to the satisfaction of the Engineer-in-charge.
(k) Contractor shall maintain necessary staff for conservancy and cleanliness
of the camp to the satisfaction of Engineer-in-charge. At least one sweeper
per 200 persons should be employed. The Assistant Director of Public
Health shall be consulted before opening a layout camp and his
instructions in respect of water supply, sanitary conveniences, camp site
accommodation and food supply etc. should be followed by the
contractors. The contractor shall make arrangement for all anti malaria
measures or in case of epidemic shall take necessary measures as
directed by the Assistant Director of Public Health. Safety precaution as
laid down by the safety manual published by C.W. and T.C. shall be
followed by the contractor; a copy of the manual will be available for
reference at the Office, of the Engineer-in-charge.
6.0 PAID LEAVE FACILITY
Paid leave facility at the rate of one day for every twenty days worked by the
contract labour shall be provided by the contractor to his workers. He shall
maintain leave records/leave cards for individual laborers which shall be duly
verified and certified by the authorized officer of the GSECL.
7.0 GRATUITY / BONUS LIABILITIES
The contractor shall pay Gratuity and Bonus to its eligible employees under the
Gratuity Act and Bonus Act if it is applicable.
8.0 The Contractor shall employ adequate number of experienced staff at site for
daily supervision and for maintenance of various registers and records required
under the law and contract. No payment for supervision shall be admissible.
9.0 CONTRACTOR TO INDEMNIFY THE CORPORATION
The contractor shall indemnify and keep indemnified the Corporation and every
officer and employees of the Corporation and also Engineer-In-Charge and his
staff against all actions, proceedings, claims, demands, costs and expenses
whatsoever arising out of or in connection with the matters referred in above
clauses and elsewhere and against all actions, claims, demands, costs and
expenses which may be made against the Corporation by any
workman/employee of the contractor or any sub contractor and/or from any
liability may arise to any workman/employees of the contractor or any sub
contractor under any laws, rules or regulation having the force of law including
but not limited to claims against the owner under workmen compensation Act,
1923. The employee’s Provident Act 1952, and/or the contract Labour (Abolition
and Regulation) Act 1979. The Corporation shall not be liable for or in respect of
or in consequence of any accident or injury to any workmen or other person in the
45
employment of the contractor or his sub-contractors, and the contractor shall
indemnify and keep indemnified the Corporation against all such damage and
compensation and against all claims, demands, proceedings costs, charges and
expenses whatsoever in respect thereof or in relation thereto.
10.0 The Corporation reserves the right to terminate this rate contract at any time
during its pendency without giving notice of termination or any reasons thereof.
11.0 The Corporation will be entitled to deduct directly from the bills, to be paid to the
Sub-contractor and Laborers any sum or sums payable by contractor and which
sum/sums the Corporation is required to pay as a principal employer on account
of contractor’s default in respect of all liabilities referred to in above clauses.
12.0 Nothing in the contract document stated shall place obligation or liability upon the
corporation in respect of any such workmen/employee of contractor or sub-
contractor.
13.0 Bidder should note that the prevailing Act at the time of execution of work over
and above act specified herein shall be binding to the Contractor.
14.0 EMPLOYMENT OF SCARCITY LABOUR
If Government declares a state of scarcity or famine to exist in any village
situated within 20 Kms of the work, the piece worker/contractor shall employ upon
such part of the work as are suitable for unskilled labour; any person certified to
him by the Executive Engineer or by any person to whom Executive Engineer
may have delegated this duty in writing to be in need of relief and shall be bound
to pay such person wage not below the minimum, which Government may have
fixed in this behalf from time to time. Any implementation of this clause shall be
decided by the Superintending Engineer/Engineer-in-charge whose decision shall
be final and binding on the piece worker/contractor.
15.0 DEPOSIT LINKED INSURANCE SCHEME
The contractor shall have to deposit 0.50% (half percent) or the rate applicable
from time to time of the wages in respect of employees who are members of the
PF, as the contribution to the Deposit Linked Insurance Scheme, with the
Regional Provident Fund Commissioner.
16.0 MINIMUM WAGES ACT
The contractor shall pay prevailing minimum wages as applicable from time to
time to the laborers engaged by him as per the Minimum Wages Act payment in
Bank / presence of the GSECL’s officer or representative.
17.0 ADMINISTRATIVE CHARGES
Administrative charges for maintaining Provident Fund account shall be deposited
by the contractor with the Regional Provident Fund Commissioner, Ahmedabad,
at the rates applicable.
18.0 E.S.I. ACT
The contractors shall comply with the provisions of E.S.I. Act wherever applicable
as per the prevailing provisions of the Act and as amended from time to time.
19.0 LABOUR LICENSE FOR LABOUR CONTRACT
The Contractor / Agency shall have to obtain the copy of Labour Contract License
under contract Labour (Regulation & Abolition) Act from the appropriate
authorities before commencement of work.
46
20.0 WORKMEN’S COMPENSATION FUND AND EMPLOYER’S LIABILITY
INSURACE
Insurance shall be affected for all the contract employees engaged in the
performance of this contract. If any of the work is sublet after due permission in
writing from the GSECL, the contractor shall require the sub – contractor to
provide workmen’s compensation and employer’s liability insurance for the later
employees, unless such employees are covered under the contractor’s
insurance. It shall be the liability of contractor for employees of his sub –
contractor. The contractor must insure that all the laborers may cover before
starting the works.
21.0 SUBMISSION OF RETURNS & MAINTENANCE OF RECORDS
The contractor shall submit the returns under the Contract Labour Act, payment
of Bonus Act, Payment of Gratuity Act etc. and shall have to maintain all up to
date records / registers in respect his employee as prescribed under various
Labour Laws and produce the same as and when demanded by GSECL’s or
Govt. appropriate authorities.
22.0 Contractor / Agency shall have to issue the contractual appointment letter for a
specific period to their Labour engaged during the contract period each and every
instance & should narrated clear out terms & conditions for the liabilities of the
concerned employees.
23.0 As a contractor, the contractor shall be responsible and liable to pay difference in
wages, if any, and / or observe the revised service conditions that may be
awarded by the Honorable Industrial Tribunal effective from the date directed in
the award.
24.0 The contractor must be maintaining regular Labour record and should be paying
all acquired benefits to Labour force and contractor should obtain certificates to
this effect from HR Officer of GSECL.
25.0 The contractor will make arrangements at his own cost to insure all men,
materials and equipment employed for this work. The GSECL will to be
responsible for any loss or damage either to the contractor’s personnel or his
equipment.
26.0 Dispute, if any, taking place between the contractor and laborers must be
intimated to LWO/DGM, BHAVNAGAR LIGNITE TPS, immediately.
27.0 Any casualty will also have to be borne by the contractor for the period the
contract continues.
28.0 For ARC/BRC contract, The Contractor shall deposit 15 days salary at the rate of
last drawn salary for every completed one year of services for each worker for the
liabilities of Gratuity.
29.0 The Contractor / Agency shall have to produce / submit the copy of Wage
Register, Muster Roll, PF Deposition Challan, PF Schedule, Copy of Bank
Statement duly stamped by the concern Bank and relevant records under various
Labour Laws for the contract work to HR Department to ensure compliance to
provisions of various legislations.
30.0 Attendance of contract labourers will be through punching machines for which
punching machines shall installed to facilitate the contractors by GSECL for which
monthly charges of Rs. 10/- will be levied on contractor as administrative
charges.
47. MATTERS RELATED TO EXECUTION OF WORK
47
a) Work shall commence from the date given in letter to commence the work by
EIC at site. The Contractor shall make all necessary arrangements at site to
mobilize labour, operators, divers and materials and maintain necessary number
of machinery and equipment, barge, pontoons etc., to guarantee the agreed rate
of progress of work as per schedule.
b) A detailed work schedule showing how he proposes to carry out the work,
specifically mentioning time periods as well as date of commencement and
completion of each activity and such approved schedules must be strictly
adhered to by the CONTRACTOR. After the owner has agreed with the schedule,
the Contractor shall prepare detailed program of each work front/activity breaking
it down giving daily quantifiable/measure of progress. The schedules are to be
reviewed periodically with the OWNER / ENGINEER to ensure that the
completion date will be met or to institute corrective steps (at no extra cost to the
ENGINEER) to adhere to the completion dates. The OWNER reserves the right
to revise the schedule at his discretion in order to keep up to the completion date
and to suit the project requirement and such alterations shall not entitle the
CONTRACTOR to any extra payment.
c) A work schedule with PERT / Bar Chart for carrying out the work in prescribed
time limit mentioning date of commencement, activity to be carried with its time
period, starting & finishing event for each activity, completion of total project in
critical path etc, shall be jointly fixed and approved by the GSECL. Such
approved schedules must be strictly adhered by the Contractor.
d) After the GSECL has agreed with the schedule, the Contractor shall prepare
detailed program of each work front / activity breaking it down to daily quantifiable
measure of progress. The schedules are to be reviewed periodically with the
Owner / E.I.C to ensure that the completion date will be met or to institute
corrective steps (at no extra cost to the GSECL) to adhere to the completion
dates. The Owner reserves the right to revise the schedule at his discretion in
order to keep up to the completion date and to suit the project requirement and
such alterations shall not entitle the Contractor to any extra payment.
e) The GSECL reserves the right to delete any item of schedule-B for which
contractor shall not have any right to claim on this account.
f) One permanent reference bench mark and a reference base line shall be given
for lay out of work, which shall be maintained without disturbance by the
CONTRACTOR during the tenure of the contract. CONTRACTOR shall establish
local bench marks as directed by the ENGINEER IN CHARGE.
g) The contract or any part thereof shall not be subject to change without the written
permission of the Chief Engineer (Gen.) GSECL, BHAVNAGAR LIGNITE TPS or
his authorized representatives.
h) During the execution of the work if it is found that the work is not progressing as
per the scheduled program approved by the GSECL & planned by the contractor,
due to the reasons attributable to the contractor, suitable action shall be taken as
per Clauses in this tender elsewhere & other relevant clauses appearing in the
section of “Terms & condition of tender & works contract, Legal conditions of
works contract” of tender document. And the GSECL may also take such action
as it may deem fit to ensure that the work is completed in time at Risk and Cost of
the contractor.
i) Contractor shall attend meetings at EIC's office at site or any other place as fixed
by the EIC, as and when required for review, discussion, coordination etc.
Attending these meetings shall be obligatory on the part of the Contractor, at no
cost to the GSECL.
48
j) The Contractor shall take all requisite & necessary care to observe that no
damage is caused to the existing, pumps, existing works, service road, or any
other structure etc. For any damage to the existing structures of the GSECL, the
Contractor shall be held responsible and he will have to rectify the damage
immediately up to the satisfaction of Engineer in Charge, at his own cost.
k) The work shall be completed within the period stipulated in the contract. & site
clearance arranged according to the progress of work at site. Therefore, the
contractor has to organize & coordinate the work to suit these circumstantial
conditions. In the event of any delay due to the above or due to any other reason
not attributable to the contractor, reasonable extension in completing the work
may be given at the discretion and as decided by the GSECL but no
compensation or idle charges will be payable to the contractor on this account or
any site conditions under any circumstances.
l) No idle charges shall be entertained by GSECL for any site condition or any
circumstances. The corporation will not pay any type of advances including
mobilization advance
48. RECOVERIES
a) In case of any damage to equipment / machinery or structure / building of
GSECL or any public property due to negligence of contractor or any other
reasons attributed to contractor, the decision of E.I.C. regarding the amount of
recovery shall be final.
b) If the contractor fails to execute the work as per direction of E.I.C. within the time
frame given, the GSECL shall get the work done through any other contractor at
the risk and cost of the contractor and the cost of execution of such work along
with 15% overhead charges shall be deducted from contractor’s monthly bill over
and above recovery as per rules.
c) Recoveries due from the contractor, up to the end of the month previous to the
one in which the bill is prepared shall be made from bills approved for payment
every month or at other periods when the bills are prepared, for the various items
in the following order of priorities and extents.
d) Deduction on account of security deposit in full together with shortage, if any, to
be made good.
e) Penalty in full, if levied.
f) Expenditure, if any, incurred by the Corporation on Contractor’s behalf in labour
or materials in full.
g) Charges for services such as water and power supply etc. in full.
h) Charge on account of supply of materials like cement and steel in case of
shortages found in balance or excess consumption than specified.
i) Hire charges for Corporation or Government machinery if any.
j) Recoveries of advance and secured payment or payments for preliminary work in
full or the installment due if and as the same as may have been allowed.
k) Rent recovery on account of allotting quarters on rent as per Corporation’s rules.
l) Income tax and sales tax in full as per Government rules.
m) Outstanding recoveries in respect of other contracts awarded by the Corporation
if any.
49
n) Other recoveries. (If any)
49. WORK TO BE EXECUTED TO THE SATISFACTION OF THE ENGINEER -IN-
CHARGE
The contractor shall proceed with the work with diligence and expedition and the whole
of the work herein specified as well as the mode of execution shall be under the
supervision and direction and shall be carried on to the entire satisfaction of the
Engineer-in-charge, who shall have full power to order the contractor to alter, enlarge or
diminish the form, dimensions, positions, or quantities of any of the work or to make use
of material and workman-ship of different descriptions and qualities from this herein
specified.
The whole of the works, together with any temporary works, associated therewith, shall
be carried on in the most substantial proper and mannered workman like manner, with
the best materials and workmanship and to the entire satisfaction of the Engineer-in-
charge and in such order of time as he may direct. The contractor shall attend to and
execute without delay all orders and instruction which may from time to time be issued
by the Engineer-in-charge.
50. MATERIALS WORKMANSHIP ETC.
The work shall be executed in thoroughly substantial manner with material and
workmanship of best quality and strictly in accordance with the specifications and with
the drawings, or with such other drawings or written instruction as may from time to time
be furnished to the contractor, in accordance with terms of this contract and shall be
completed in every respect with all materials and workmanship implied and necessary
according to the fair interpretation and meaning of the same and should there be any
discrepancy between the drawings and specifications or any difference or disputes as
to the dimensions to be worked to or the quality of the materials to be used, or the mode
of doing periodical quantity of the work to be executed or with respect to any subject
arising out of this contract, the decision of the Engineer-in-charge shall be final and
binding on all parties. Rejected material shall be so disposed off as to obviate any
possibility of their use on works. The place, method and period of disposal shall be as
directed by the Engineer-in-charge.
51. SAMPLES OF DESCRIPTIVE DATE
Samples of descriptive date, requiring approval, shall be submitted by contractor to the
Engineer-in-charge in good time before the use of such material for inspection and
permission of testing if required. The samples shall be properly marked to show the
name of the material, manufacture, place of origin, and place where to be used etc.
Failure of any sample to pass specified tests will be sufficient cause for the refusal to
consider any further sample from the same source.
52. FENCING AND LIGHTING AND VENTILATION
Except as herein after provided, the contractor shall unless otherwise specified, be
responsible for the proper fencing, guarding, lighting and taking of the necessary
safety measures for all works comprised in the contract and or the proper provision of
temporary roadway, footways, guards fences, caution notices etc. as far as the same
may be rendered necessary by reasons for the work for the accommodation and
protection of workman foot passenger or other traffic and of the owners and occupiers
of adjacent property and of the public and shall remain responsible for any accidents
that may occur on account of his failure to take proper and timely precautions.
All the arrangements made for fencing, lighting and ventilation shall be maintained by
the contractor throughout the tendency of the contract till physical taking over of the
work by the department.
50
53. LIABILITY FOR DAMAGE TO WORKS OR PLANTS
(a) The contractor shall during, the progress of the work, properly cover up and protect
the work, and plant, and materials placed at his disposal or acquired for him by
the Corporation, from injury by exposure to the weather, or any cause what so
ever and shall take every reasonable proper timely and useful precaution against
accident or injury to the same from any cause and shall be and remain answerable
and liable for all accidents, or injuries thereto which until the same be or be
deemed to be, taken over by the Corporation, may arise or be occasioned by the
acts or omissions of the contractor or his workmen of sub-contractors, and all
losses and damages to the works or such plant or material arising from such
accidents or injuries as aforesaid shall be made good in the most complete and
substantial manner by and at the sole cost of the contractor and to the reasonable
satisfaction of the Engineer-in-charge. If the contractor fails to make good such
losses & damages within the time given by the Engineer-in-charge, the Corporation
shall be at liberty to recover the amount fixed by the Engineer-in-charge for such
losses or damages or any part thereof by deducting it from any sum due by the
Corporation to the contractor under this contract or otherwise.
(b) Further the contractor shall, at all time, protect and preserve all materials, plant and
equipment that he may himself have procured for the execution of the work. All
reasonable requests of the Engineer-in-charge to enclose or especially protect any
of the above shall be expeditiously compiled with.
(c) If the Engineer-in-charge considers that the work or materials or plant is not
sufficiently protected by the contractor, he shall be entitled to arrange for such
protection at his unfettered discretion and recover the cost thereof from the
contractor.
(d) Until the work shall be or be deemed to be taken, over as aforesaid, the
contractor shall also be liable for and shall be deemed to have indemnified the
Corporation in respect of all damage or injury to any person or any property of the
Corporation or of others, occasioned by the negligence of the contractor or his
workmen, or his sub-contractor, or by defective design, work or materials.
54. EXPLOSIVE PROCUREMENT AND STORAGE (IF APPLICABLE)
(a) Explosives, petrol, oils, fuels and other inflammable materials shall be stored
strictly in accordance with the rule of the Explosive Department.
(b) ii) The contractor shall at his own expense construct and maintain, proper
magazines which are required for the storage of explosive and arrange for proper
storage facilities for oils, fuels etc. for use in connection with the work.
(c) iii) The contractor shall at his own expense obtain such license or licenses as may
be necessary for strong and using explosives, oils, fuels etc. The department shall
not take any responsibility whatsoever in connection with the storage or use of
explosives on the site, or any accident or occurrence whatsoever in connection
therewith. All operation of the contractor in which or for which Explosives are
employed shall be at risk of contractor and upon his own responsibility.
55. MATERIALS TOOLS AND PLANT BROUGHT ON THE SITE OF WORK
All materials, tools and tackle of the contractor brought to and delivered upon the site for
the purpose of the work shall from the time of their being so brought shall be deemed to
be the property of the Corporation in its possession to be used for the purpose of the
work and for that purpose only and shall not on any account be removed or taken away
by the contractor or any other person without the written permission of the Engineer-in-
charge but the contractor shall nevertheless be solely liable and responsible for and
loss destruction thereof or damage thereto. The Corporation shall have a lien on such
51
materials, tools and tackle for any sum of sums which may at any time prior to the
completion of the works be due or owing to the Corporation by the contractor, under in
respect of and dispose of any such materials, tools and tackle in such manner as the
Corporation may think fit and to apply the proceeding in or towards the satisfaction of
such sum or sums so due or owing as aforesaid but subject to such lien and power of
sale and disposal such surplus materials, tools and tackle shall belong to the contractor
and may be removed and disposed of by him as he may think fit.
56. ACCESS TO SITE AND WORK ON SITE
The Engineer-in-charge or his authorized representative may if he consider fit from time
to time enter upon any lands which may be in the possession of the contractor under
this contract, for the purpose of executing any work not included in this contract and may
execute such work not included in this contract by agents, or by other contractors at his
option and the contractor shall in accordance with the requirements of the Engineer-in-
charge, afford all reasonable facilities for execution of the works including occupation of
lands by structure or otherwise for any other contractor employed by the Corporation
and his workmen or for the workmen of the Corporation who may be employed in the
execution on or near the site of the work not included in the contractor’s any contract in
connection with or ancillary to the works and in default, the contractor shall be liable to
the Corporation for any delay or expense incurred by reason of such default. Provided
always that if the exercise of those power shall cause any damage to the contractor he
may within fifteen days of such damage arising make a statement of the same to the
Engineer-in-charge who shall from time to time assess the value in his Judgment of
such damage and the Corporation shall from time to time shall pay to the contractor the
amounts (if any accepted as justified) by the Engineer-in-charge. The contractor shall
not however, on account of any such modified, new or extra work executed by or for the
same of the Corporation be entitled to claim relief from the obligation to execute other
works.
57. INSPECTION OF WORKS
The Engineer-in-charge or his duly authorized agent shall have at all time full power to
inspect the works, wherever in progress, either on the site, on the contractor's premises
or at the premises wherever situated, of any firm or Corporation where work in
connection with this contract may be in hand.
Further, the contractor shall not allow, without written authorization permit entry on site
of work, any person except authorized agents of the Corporation of the Engineer-in-
charge or the contractor's staff and labour directly engaged on and in connection with
the work.
The contractor shall, during working hours, maintain supervisors having sufficient
training and experience to supervise the various items and operations of the work and
the said supervisors shall remain present during the inspections of the Engineer-in-
charge. All orders and directions given to such supervisors or other staff of the
contractor shall be deemed to have been given to contractor. Further the Engineer-in-
charge may be due notice, desire a higher ranking members of the supervisory staff of
the contractor to be present on any specified inspection and the contractor shall comply
with such direction.
58. CLEANING UP
(a) The contractor shall at all times keep the construction area and his power house
and storage areas free from accumulation of waste, or rejected materials.
(b) Prior to the completion of the work the contractor shall remove all rubbish from and
about the premises, and all tools, scaffolding, equipment and materials which are
not part of permanent structure. The premise will be left in a manner fully
52
satisfactory to the Engineer-in-charge, thereafter only the completion certificate will
be issued.
59. CONTRACTOR TO KEEP INVENTORY OF MATERIALS ETC.
The contractor shall prepare and maintain an inventory of all materials temporary rolling
stock, plant purchased or hired for use of employment or for any of the purposed for this
contract and such inventory or a copy thereof shall at all times be available for
inspection by the Engineer-in-charge. A complete and up to date copy of the inventory
shall be submitted to the Engineer-in-charge in the beginning and once a year;
thereafter changes in the interim period, if any shall be communicated on every three
months.
60. CONTRACTOR TO RESTORE PLANT
Upon completion of the work, the contractor shall deliver to the Corporation, all
appliances, materials, and plants which may have been loaned or hired to him by the
Corporation and make good all damages which may have occurred to them, except
such as shall be caused by fair wear and tear in execution of the works.
61. PROGRESS SCHEDULE
(a) The contractor shall furnish, within one week unless extended by the Engineer of
the order to start the work, a progress schedule in quadruplicate indicating the
date of start the weekly progress expected to be achieved and the anticipated
completion date of each major items of work to be done by him, also indicating
dates of procurement and setting up of materials, plant and machinery. The
schedule should be such as is practicable of achievement towards completion of
the whole work in the time limit and of the particular items on due dates specified
in the contract and shall have the approval of the Engineer. Further, the dates for
the progress as in this schedule shall be kept up-to-date. In case it is
subsequently found necessary to alter this schedule, the contractor shall submit
in good time a revised schedule incorporating necessary modifications proposed
and get the same approved by the Engineer. No revised schedule shall be
operative within such acceptance in writing.
(b) Detailed schedules for each week showing the progress proposed to achieve
shall be submitted to the Engineer and got approved. The Engineer is further
empowered to ask for more detailed schedule or schedules any week by week,
for any items or items, and the contractor shall supply the same as and when
asked for.
(c) The Engineer shall have, at all times the right without in any way vitiating this
contract, or forming grounds for any claim to alter the order of the works or any
part thereof and the contractor shall after receiving such direction proceed in the
order directed. The contractors shall also revise the progress schedule
accordingly and submit four copies of the revised schedule to the Engineer within
seven days of the Engineer's direction to alter the order of works.
(d) The contractor shall furnish sufficient plant equipment and labour and shall work
such hours and shifts as may be necessary to maintain the progress on the work
as per the approved progress schedule. The working and shift hours shall comply
with all GSECL's regulations in force and shall be such as may be approved by
the Engineer. They shall not be varied without the prior approval of the Engineer.
(e) The contractor shall from time to time as may be required by the Engineer,
furnish the Engineer, with a statement in writing of the arrangement he proposes
to adopt for the execution of this contract and the Engineer may if he considers,
necessary at any time advise alteration in the same, which the contractor shall
adopt on notice thereof.
53
(f) The progress schedules shall be in the form of progress charts, forms, statement
and/or reports as may be approved by the Engineer. Further, the contractor shall
submit four copies showing the progress of work in forms and charts etc. at
periodicals intervals as may be specified by the Engineer.
62. DATE OF COMPLETION
The contractor shall supply, erect, equip and construct the whole of the works and
hand over them to the Corporation on or before the date specified in the tender
document including "Special Conditions" and save as herein provided, in no
circumstances whatever shall extend or alter the date for the completion of works.
Provided always that if in the opinion of the Engineer-in-charge the completion of the
works shall be delayed by any change of original design or by the order of the
Engineer-in-charge, of any altered, modified substituted or additional works or materials
omitted or by strikes, lock outs or stoppages of labour, or revolution, riots, civil or
political disturbance or by causes directly due to war or by the contractor not being
given possession of the site or any part there-of or by the Corporation taking possession
of and using the site or any part thereof or the works or any part thereof, whether any
nonperformance of work under the powers herein contained or otherwise or by any
nonperformance of work or non-supply of materials to be performed or supplied by the
Corporation or by the contractor not receiving any orders, drawings, instructions or
directions in time or by the suspensions of the works or by fire, flood exceptionally bad
weather tempest, storm, or by from unforeseen circumstances (and whether the same
shall be due to any act or omission of the Corporation or its agents or those in their
respective service or not) the Engineer-in-charge may, if in his unfettered discretion, he
thinks fit either forthwith or at any later time and from time to time not withstanding
that the prescribed or extended time for completion has expired or that the work have
been completed, by writing under his hand, extend the time for the completion of the
works to such date as he shall appoint. Provided always that unless the contractor
makes a written application to the Engineer-in-charge within one month of the cause of
delay and unless the time is extended by the Engineer-in-charge, the prescribed time
shall not be extended notwithstanding delays from the aforesaid foregoing or any other
causes of whatsoever kind.
63. SUBLETTING OF CONTRACT
There will be generally no objection on the component parts for the work, being given
over to responsible sub-contractors but Corporation shall under no circumstances
recognize these sub-contractors and the responsibility of executing the work in the
accordance with the conditions of contract will entirely rest on the main contracts. The
main contractors will therefore always have the very responsible member, preferably a
technical hand present on the works with power to sign all work orders issued on the site
of work and to take requisite actions in the interest of very efficient execution of work.
However, the subletting of the contract can be made only with the prior approval of the
competent authority of the Corporation.
64. OTHERCONTRACTS FOR THE WORK SUSPENSION STOPPAGEOR
CURTAILMENTS OF WORK
If during the tendency of the contract the Engineer-in-charge shall for any reasons
(which shall be unquestioned) whatsoever require the whole or any part of the work as
specified in the contract to be suspended for any period or shall not require the whole or
any part of the work as specified in the contract to be carried out at all by the
contractor, he shall give notice in writing of the fact to the contractor who shall thereupon
suspend or stop the work totally or partially as the case may be. In any, case, except
as provided hereunder, the contractor shall have no claim to any payment or
compensation whatsoever on account of any profit or advantage which he might have
derived from the execution of the work in full but which he did not so derive in
consequence of the full amount of the work not having being carried out, or on account
54
of any loss that he may be put to on account of materials purchased or agreed to be
purchased or for unemployment of labour recruited by him. He shall not also have any
claim for compensation by reason of any alterations having been made in the original
specifications, drawings, designs and instruction which may involve any curtailment of
the work as originally contemplated. Where, however, materials have already been
purchased or agreed to be purchased by the contractor, before receipt by him of the
aforesaid notice, the contractor shall be paid for such materials at the rate
determined by the Engineer-in-charge, provided they would have been useful for the
work curtailed or stopped are not in excess of requirements, are of approved quality and
cannot be used on other contract works or otherwise by the contractor and/or shall be
compensated for the loss if any, that he may be put to, in respect of materials agreed
to be purchased by him, the amount of such compensation to be determined by the
Engineer-in-charge, whose decision shall be final.
The Engineer-in-charge may grant extension of time for the execution of any item or
items of work affected by such suspension of work. The decision for the Engineer-in-
charge, regarding the granting of extension and the period thereof shall be final. The
Engineer-in-charge may order the contractor to suspend any work on account of bad
weather; rain or storm and such other adverse climate conditions and the contractor
shall comply with the same.
The contractor shall not be entitled to a compensation for such suspension of work,
concrete lining at the junctions of the different works under different contract shall be
done with particular care regarding forms, construction joints, interconnecting
reinforcement etc. if any and the joint planning of such work shall be with prior approval
of the Engineer-in-charge.
65. OTHER CONTRACTORS
Apart from this work, the other works connected with the power house will be
simultaneous going on either departmentally or through agencies inside or outside the
power house. Each contractor or agency shall co-operate with others to the fullest extent
and shall allow to each other every facility and co-ordination for execution of their works
simultaneously and satisfactorily, during their action of machinery or execution of any
other co-ordination works of the power house, the contractor will have to work only at
places as directed by the Engineer-in-charge. He will have some time to suspend his
work partially or totally in the interest of the work at large.
In such cases and at such time, he will be informed from time to time and directed by the
Engineer-in-charge where to work. He may also be required to remove the scaffolding or
to erect the scaffolding and shuttering in such a manner as to be of little obstruction and
inconvenience for erection of machinery. In such cases he shall not be given any
compensation on account of reduction or stoppage or labour force or removal and
reinstatement of scaffolding shuttering etc. It will be seen that contractor is not put to
unnecessary inconvenience.
In the matter of dumps, haul, roads, drainage, diversion and the like, each contractor
shall take into consideration the needs and requirements of the other constructors, if any
working in the vicinity. Further no contractor shall take or cause to be taken any stops or
action that may cause disruption, discontent or disturbance to the work, labour of
arrangements etc. or other contractors in the neighboring project localities.
Any action, by any contractor, which the Engineer-in-charge in his unquestioned
discretion may consider as infringement of the above code, would be considered as a
breach of the contract conditions and the Engineer-in-charge may take such action as
he may deem fit against the contractor and the action taken shall be considered as final
and binding.
66. SPEED OF WORK
55
The contractor shall at all times maintain the speed of work to confirm to the latest
operative progress schedule but the Engineer-in-charge may at any time with sufficient
notice in writing direct the contractor to slow down any part or the whole of the work for
any reason (which shall not be question whatsoever, and the contractor shall comply
with such orders of the Engineer-in-charge. The compliance of such orders shall not
entitle the contractor to any claim or compensation.
67. CONTRACT DOCUMENT AND MATTERS TO BE TREATED AS CONFIDENTIAL
All documents, correspondence, decisions and other matter concerning the contract
shall be considered as of confident and restricted nature by the contractor and he shall
not divulge or allow access there to any unauthorized persons of any kind.
68. ACCESS TO THE CONTRACTOR'S BOOK
Whenever it is considered necessary by the Engineer-in-charge to ascertain the actual
cost for execution of any particular item of work of supply of plant or material shall direct
the contractor to produce the relevant documents such as pay rolls records of
personnel, invoices of materials and any other data relevant to the item or necessary to
determine its cost etc. and the contractor to the aforesaid items in the mode and manner
that may be specified.
69. INTEREST ON MONEY DUE TO THE CONTRACTOR
The contractors shall not be entitled to get interest on any amount either of their bills or
arrears whatsoever because of delay in payment by the Corporation. Similarly they shall
not be entitled for any interest on amount of bank guarantees given by them. Non-
payment of interest by the Corporation therefore, shall not cause breach of contract.
70. MEASUREMENTS TO BE PROVISIONAL AND SUBJECT TO CORRECTION
Every measurements for running payment on account of work, done or supplies made,
shall be subject to adjustment or final measurements. In case of disagreement between
such intermediate and final measurements, the latter shall prevail. All works shall be
measured, met by standard measure and according to rules and custom and usual in
the use in Gujarat State Electricity Corporation Ltd., and no proposal to adopt alternative
method will be accepted, the Executive Engineer’s decision as to what is “the usual
method in use in the Gujarat State Electricity Corporation Ltd.” shall be final.
71. BREACH ON PART OF CORPORATION NOT TO ANNUAL CONTRACT
No breach or non-observance on the part of the Corporation of any of the agreements
contained herein, shall annul this contract or discharge the contractor from the
observance and performance thereof, or of any part thereof, but on application by the
contractor and in the unfettered discretion of the Engineer-in-charge an extension of
time may be given to the contractor in respect of such breach or non-observance by the
Corporation.
72. PROFORMA RETURNS
The contractor shall maintain Performa, charts and details regarding machinery
equipment materials, labour personnel and other matters as may be specified by the
Engineer-in-charge. He shall further, submit returns of Performa and details as may be
specified by the Engineer-in-charge from time to time.
73. LOCAL LAWS
All local laws in force at the time of entering into the contract and those enacted
thereafter shall be binding on the contractor and he shall abide by the same.
56
All import duties, sales tax and other local taxes shall be borne by the contractor and
they shall be deemed to have been covered by this quoted tender rate.
74. WORKS IN SHIFT DUTY
Works shall be planned in shift duties, if possible in three shifts, depending on
emergency of the work with prior approval of Eng. - in- charge. 0n Sunday or any other
holidays work shall be continued in order to maintain progress with prior permission of
Eng.-in -charge. Such works shall not form any grounds for complaint, compensation or
extension of time limit.
If on the other hand, the Engineer-in-charge directs that the work shall be proceeded
with on days and during hours which are not permissible under this contract, the
contractor shall proceed with the work as directed without in any way vitiating this
contract or forming any grounds for compensation of claim.
The contractor shall in his dealing with labour, at all times, during the period of this
contract, have due regard to local festivals and religious and other customs.
A working day shall consist of two shifts each of eight hours, a working day shall
constitute any day on which in the opinion of the Engineer-in-charge, work can be
carried out in one or more shifts.
75. LIENS
Final payment to the contractor shall not be made until the contractor shall deliver to the
purchaser or receipts in full in lieu thereof, and in either case, an affidavit that so far he
has knowledge or information the releases and receipts include all the labour and
material for which in lien could be filed. If any lien remains unsatisfied after all payments
are made, the contractor shall refund to the purchaser all moneys that the latter may be
compelled to pay in discharging such a lien, including all costs and a reasonable
attorney's.
76. MISCELLANEOUS
(a) In case of conflict / discrepancies among clauses of different specifications
given in this document, the stringent specification shall be followed and under
such circumstances, the decision of the EIC shall be final and binding to the
Contractor
(b) The Notice inviting tender, general instruction to bidders and all other documents of
this tender shall form part of the contract
(c) No receipt for any payment alleged to have been made by a Contractor in regard
to any matter relating to tender of the contract shall be valid and binding on the
Corporation unless it is signed by the Engineer-in-Charge.
(d) As per provisions of Income Tax Act, Corporation shall deduct Income Tax at the
applicable rate.
(e) Agency has to note that the extension of Time limit/excess saving in the works if
required to approve, than it shall be processed as per the provision of DoP and
will take time for process the same.
(f) The contract is inclusive of the cost of materials required to complete the work in
totality.
(g) It will be absolutely incumbent on the contractors to have on the site of work only
such of the materials as have been duly passed by the Engineer-in-charge.
Materials that have been rejected must on no account be allowed to remain on
the site, and in spite of written order to do so, any such rejected materials is on
57
the site beyond a period of 48 hours’ notice, the Engineer-in-charge shall have
the right to remove it, at the risk and cost of the contractors and even to destroy
it.
(h) It must be distinctly understood that conditions of contract and of claims in
respect of extra work, will not be allowed unless the works to which they relate is
clearly without the spirit and meaning of the specifications or unless such works
are ordered in writing by the Engineer-in-charge and claimed for in specified
manner.
(i) Contractor will be asked to present the sample of materials, and the approved
samples will be preserved at the site of work, and no change in the approved
sample will be allowed, without the written permission of the Engineer-in-charge.
(j) The department reserves the right to make any change in the design and the
plans of the works. The contractor shall be bound to carry them out at the rates
tendered. No claim or compensation will be allowed on this account.
(k) The contractor shall keep instruction book on site, for taking site instructions from
time to time. This book shall be made available on site whenever asked for.
(l) Above construction equipment brought to site shall be allowed to be taken out
only after the work for which it has been brought is over. The equipment shall be
taken out only with the specific permission in writing from the E.I.C. Only the
equipment required for the work and in fit condition shall be brought to the site.
The Contractor shall ensure that proper documentation is followed at entry gate
of GSECL's premises for such items which shall be carried back by Contractor
after completion of work.
(m) The Contractor shall provide all temporary ladders, scaffolding materials,
platforms, supports and other necessary facilities required for trimming & cutting
of trees. The Contractor shall provide sufficient, strong and safe staging so as to
ensure safety of the laborers.
(n) The Contractor shall provide sufficient fencing, notice Corporations and lights to
protect and warn others as may be considered necessary by the GSECL and
safety authority.
(o) The GSECL may during the progress of work, order the removal of part or whole
of the work executed, found not in accordance with the approved drawings,
specifications/ instructions. No extra claims shall be entertained for re-executing
or altering of such work.
(p) On completion of the work, the site shall be left in good order and the excess
materials, scraps, debris, if any shall be removed and dumped by the Contractor
at place/places as designated by the GSECL. The Contractor shall also dismantle
and remove the staging and other temporary facilities like stores, offices, labor
camp etc. on completion of work.
(q) Contractor is required to maintain proper records at site of work in addition to
normal routine requirement of own office. The records to be maintained shall
include but not limited to the following:
1) Daily Progress Record.
2) Work Site Order Book.
3) Instruction by GSECL's Officers.
4) Test Registers of other materials/fittings, fixtures, equipment as
stipulated in the tender.
58
5) Register for Working Details.
6) Log Book of Defects.
7) Hindrance Register giving details of commencement and removal of
each hindrance.
8) Supply and consumption registers of all materials shall be maintained.
9) Day to day Record of used/received materials shall be entered in the
register and signed by the Site Engineer of the GSECL as well as
contractors' representative at site.
10) Measurement Book.
59
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-D
60
SPECIAL CONDITIONS FOR USE OF CEMENT IN WORK
1 The rates in Schedule – ‘B’ is inclusive of cement cost. Contractor has to purchase
fresh 43 grade cement confirming to as per IS 8112 Or PPC IS 1489 (Part-I) or as per
tender condition.
2 Contractor has to construct pucca Go down at site of work so that cement bags can
be properly preserved to avoid damage due to any kind of water/Humidity.
5 To bring sufficient & timely cement at site is full responsibility of contractor. Nothing
extra will be paid on account of any reason to maintain progress of work and to
complete the work in schedule time.
6 Contractor has to submit material A/c. For consumption of cement used with every
bills. In case of not submitting the same, bill will not be passed. Party has to submit
the copy of cement purchased bill and Challan/invoice along with each RA Bill/Final
Bill.
7 No negative variation will be allowed for consumption in cement less then prescribed
as per R & B SoR OR Corporation/mix design and nothing will be paid extra for over
consumption.
8 Contractor is fully responsible for safety of cement at site; nothing will be paid extra
on account of safety.
10 Contractor has to maintain day to day cement consumption / balance account at site.
11 As far as possible, contractor has to maintain supply of cement of only one brand &
grade throughout the work and on account of closer/shortage of approved brand,
cement of other brand in accordance of condition No. (1) Will be allowed by
Engineer – in – Charge.
12 Minimum cement consumption considered for cement concrete having grade of M–15
/ M – 20 / M – 25 / is 320 Kgs. / 375 Kgs / 400 Kgs. respectively. Contractor has to
use minimum cement as above. Contractor should not use less than the prescribed
quantities of cement even in the case of mix design recommends lower quality. For
other items cement consumption shall be as per provisions of SoR without any
negative variation. Nothing will be paid extra for over consumption.
13 Contractor will be allowed to carry out work only after physical verification of cement
brought at site.
61
Approved name of Manufacturers: Allowing using steel / cementing being supplied by
contractors in civil works
The list of adopting cement and steel of companies / suppliers / manufacturers are shown
below:-
Sr. Name of approved Cement Company & their Brand Name in Market
No.
1 A.C.C. Cement A.C.C.
2 Ambuja Cement Ambuja
3 Binani Cement Binani
4 Birla Cement Birla A-1
5 Gujarat Sidhee Cement Sidhee
6 J.K. Cement J.K.
7 J.K. Laxmi Cement J.K. Laxmi
8 Sanghi Cement Sanghi
9 Saurastra Cement Hathi
10 Digvijay Cement (DCC) Lotus
11 India Cement Corromandal King
12 Ultratech Cement (L&T) Ultra-tech
13 Jaypee Cement Jaypee
14 Wonder Cement Wonder
Sr.
Name of approved Steel Manufacturer
No.
1 Tata Iron & steel Co. Ltd
2 Jindal
3 Lloyds
4 Essar Steel Ltd
5 Ispat
6 Shah Alloys Ltd., Ahmedabad
7 Utkarsh Bars Pvt Ltd.Ahmedabad
8 Bhawalka Steel Industries, Mumbai
9 Sun Vijay Rolling and Engineering Ltd., Nagpur
10 Shri Bajrang Alloys Ltd., Rajpur
11 Unique Structures and Towers Ltd., Rajpur
12 Sanghi Industries Ltd., Kutch
13 Hans Ispat Ltd., Ta. Anjar- Kutch
14 Varsana Ispat Ltd., Ta. Anjar- Kutch
15 Steel authority of India.
16 GK TMT Bars,M/s Real Ispat & Power Ltd, Raipur[C.G]
17 Parmeshwar Steel Pvt ltd. Ahmedabad.
18 Electrothem ET TMT
19 Gallant Metal Ltd, Bhachau
20 MONO brand TMT Steel
21 Akshar Ispat Ltd.,Bavsar,Himmatnagar-TMT Bars 8 mm dia. To 32 mm dia.
22 Aditya Ultra Steel Pvt. Ltd.,-Fe 500 grade TMT Bars 8 mm dia. To 32 mm dia.
23 Ashiyana Rolling Mills, Bavla- Fe 500 grade TMT Bars 8 mm dia. To 32 mm dia.
24 H.K.Ispat Pvt.Ltd, Godhara- TMT Bars 8 mm dia. To 32 mm dia.
62
SPECIAL CONDITIONS OF THE WORK
01. The work is to be executed at any height for any leads and lifts with all tools, tackles,
equipments, brooms, brushes, buckets, ladder, cloths, sanitary acid, sticks, powder,
cleaning material, phenyl, soap solution etc. Dusters for cleaning purpose shall have to be
brought by the contractor at his own cost.
02. If any areas are left out in descriptions, it shall be cleaned as per instructions of the EIC
and it will be paid in respective items.
03. Any modification in timing of period of cleaning shall be agreed upon by the contractor
without any extra cost.
04. Readily available stock of cleaning materials, equipments, and solution for one month
shall be kept on site store well in advance, shall be shown to GSECL supervisory staff,
and shall be drawn from GSECL store. If contractor fails to credit the one month stock of
require cleaning materials to credit the 1 month stock of require cleaning materials in the
time the GSECL will purchase the same from the Market at risk and cost of contractor and
necessary recovery will be imposed with 15% supervision charges from the bills.
05. The workers, supervisory staff and manager or contractors authorized representative of
contractor himself shall be available full time on site of work.
06. The daily report of work done on each day and same checked and signed by GSECL
supervisor JE / DE shall be submitted by contractor in prescribed printed forms shall be
brought by the contractor at his own cost for such reports. The contractor shall submit the
daily report regularly.
07. Contractor shall be responsible for any accident or damage to road, gutter, manholes,
dustbins, water closets, pipe line, etc. or any inconveniency caused by contractor for
which the necessary compensation shall be paid by the contract or recovered from the bill
as deem fit by the GSECL.
08. This contract shall be continued till the new agency is fixed without any extra rate or
increase in rates and the time limit of the work shall be considered accordingly.
09. It is the responsibility of the contractor to get the work done satisfactorily by engaging the
full strength of manpower as per the work requirement failing to that the reduced rates
shall be paid and necessary action shall be taken as per GSECL rules.
10. The contractor or his authorized representative and his supervisor shall remain present
during working hours.
11. Any description is left out in specification the work shall be executed as per the instruction
of EIC.
12. If the work is not completed in time satisfactorily, the recovery for the same shall be made
as per mentioned in tender specification.
13. If work is not carried out by contractor, same will be get done at risk and cost of contractor
with 15% supervision charges will be recovered from the next R.A. Bill.
14. If any dispute arise the booklet of “TENDER AND CONTRACT FOR WORKS’ may be
referred and it will be treated as part of the contract.
15. Contractor has to carry out the work as per quantity allotted to him every month. If he fails
to carry out the work 100% then the recovery will be made at 10% of the left out quantities
at A/T rate, at the discretion of E.E.(C)
16. Contractor should keep the instruction book readily available at site.
17. Successful contractor shall have to arrange required labour strength for cleaning works
daily for execution of respective items of the tender.
18. Contractor shall be held fully responsible for any accident or damage to GSECL assets or
persons or inconvenience is caused for the work, the necessary compensation shall be
paid by the contractor or recovered from his bill. The contractor shall engage all the
labours / personals at his own risk and cost and shall comply binding with all the labour
laws, acts, securities, all types of insurances, regulation of compensation for accident etc.
at his own risk and cost.
19. Weekly off to labours shall be given in staggered manner.
63
20. Labours engaged for cleaning work can be delivered at any other place for any type of
work by the EIC and for that work payment shall be made and no recovery shall be made
for left out cleaning work by particular labours, which are shifted elsewhere.
21. Contractor shall engaged new labours with the prior approval of GSECL.
22. Looking to the urgency of the particular work, the EIC will instruct to take up and complete
that particular job / work in specified time. Otherwise for incomplete work the EIC will
arrange to execute the same without giving any notice or intimation and work will be
executed through any other agency and recovery will be made as per actual payment
made to other agency plus 15% supervision charges and this will be recovered from R.A.
Bills.
23. The contractor shall be responsible for proper behavior of his labours / persons. Also he
should instruct his person / labours to work as per the instruction of EIC.
24. For execution of the work as per schedule – B, if additional labours over and above the
labours deputed on regular basis than have to be arranged by the contractor with required
tools and tackles as per instruction of EIC.
25. If contractor fails in arranging sufficient labours as per instructions, it will be get done
through other agency at contractor’s risk and cost and recovery shall be effected as per
prevailing labour rates fixed by Govt.
26. The GSECL shall not supply any material for this work and Schedule – A is to be treated
as ‘NIL’.
27. Quantities shown in the Tender are approximate. No claim shall be entertained for
quantities of work executed being more or less than those entered in the Schedule –B of
the Tender..
28. The GSECL reserves the right to terminate this contract at any time, without assigning
any reason whatsoever by giving a notice period of one month from the date of notice of
termination of the contract. Contractor will not be entitled for any compensation / damages
/ losses. Whatsoever, on account of such termination of the contract.
29. Actual payment made to the workers engaged under the running contract as per agencies
record endorsed by GSECL welfare office (i.e. work wise actual labour payment in
presence of LWO/IRO or bank through payment. It should be verified with Biometric
presence of all workers, supervisor and should be certified by LWO/IRO. At plant gate and
at Colony gate, biometric punching system is adopted by GSECL. Agency has to ensure
that their labours shall punch while entry and exit from the premises.
64
GENERAL GUIDELINES RELEVANT TO IS
Please refer latest edition of relevant Indian Standard Specification of Code i.e. B.I.S. General
relevant I.S. of B.I.S. shall prevail for all items including materials, measurements etc.
The Item wise detailed specifications are intended for full description of items covered by
Schedule “B”. The specifications are not however intended to cover every detail and the works
shall be executed according to the spirit of the specifications below and the best prevailing
P.W.D. practice. The clarification to any clause in detailed specifications shall be sought from the
latest edition of relevant I.S. specification and codes. Where these specifications are at variance
with the specification laid down in the I.S. Books stated above, the former will be applicable. As
regarded matters not covered by any of the above specification, the decision of the Engineer-in-
charge shall be treated as final and shall be binding upon the contractor. The contractor is
expected to get clarified any doubt about specification, etc. before tendering by discussing with
Engineer-in-charge.
For detail technical specification, the item wise description along with above general
specifications shall hold good.
65
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-E
66
TENDER & CONTRACT FOR WORKS
I/We hereby tender for the Gujarat State Electricity Corporation Ltd. (herein Referred as
“Corporation”) of the work specified in the underwritten memorandum within the time specified
in Schedule B (memorandum showing items of work to be carried out) and in accordance, in all
respect, with the specifications, design, drawings and instructions in writing and as per
annexed conditions of contract and agree that when the materials for works are provided by the
Corporation, such materials and rates to be paid for them shall be as provided in Schedule A
hereto.
MEMORANDUM
(a) General description of work : Construction of collapsed/Tilted compound wall
of P.H. due to Tauktae Cyclone at BLTPS.
(b) Estimated cost : 86,65,678.50
(c) Earnest money : 1 % of Estimate cost.
(d) Security deposit : 5 % of Estimate cost.
(e) Time allowed for the completion of work from date of written order to commence.
Should this tender be accepted, I/We hereby agree to abide by and fulfill all the terms and
provision of the conditions of contract annexed hereto as applicable and in default thereof
forfeit and pay to the Corporation, the sums of money mentioned in the said conditions.
Receipt No. Date from the Gujarat State Electricity Corporation Ltd. in respect of the sum of
Rs_______________________________________________________(The amount to be
specified in figures and words) is herewith forwarded representing the earnest money (the
full value of which is to be absolutely forfeited to the Corporation, should I/We not deposit the
full amount of security deposit specified in above memorandum in accordance with clause (d).
Security Deposit of the said conditions/otherwise the said sum of Rs…………………. shall be
refunded on surrendering the original receipt, in case of non-awardance of contract.
Signature of the Contractor:
Address of the Contractor:
Dated__________________day of _______________year
Signature of Witness:
Address of the Witness:
Occupation:
Dated__________________day of _______________year
The above tender is hereby accepted by me on behalf of the Gujarat State Electricity
Corporation Ltd.
67
GENERAL SAFETY RULES & LIST OF SAFETY TOOLS
“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTORS”
All the contractors working in Gujarat State Electricity Corporation Limited Factory like
Coal/Lignite/Gas/Hydro/Pumping Station shall have to strictly observe the following Safety
Rules. Concern principle contractors are responsible for informing & observance of these rules
by their supervisors/contract workers as well as the owner/supervisors/ workers of sub-
Contractors engaged, if any, by them for the work contract awarded to them. Prior to
commencement of the work, Contractor shall have to submit a written assurance on their
letterhead to the concerned Sectional Head / Engineer-in-charge that they have thoroughly
gone through these Rules, have educated their employees / workers of their sub contractor
and will strictly observe the said Rules while execution of work under work contract awarded to
them. They will have to indemnify the company for any loss or damage / accident / injury to the
company’s property / employee or employee of their own in default of non - observing these
rules.
(01) Contractor should issue photo gate pass for their workers from GSECL Factory
Manager as per Gujarat Factories rules, 1963 & details shall be filled up in GSECL gate pass
format as per Aadhar card /Election card id proof & to follow the gate pass issue procedure
through concern department EE & SE, Security Officer, LWO/IRO/DGM, Factory Medical
Officer, Safety Officer/Dy. Safety Officer & Factory Manager.
(02) In case of emergency, temporary photo gate pass shall be issued by Security Officer
only for three days with prior permission of Factory Manager only. More than three days,
Permanent photo gate pass procedure shall be completed by contract agency for their contract
workers.
(03) Certificate of Fitness of employment in hazardous process & operations in form no.33 of
Gujarat Factories rules, 1963 shall be issued by GSECL Factory Medical Officer for all
contractor workers before commencement of work & examination responsibility shall be taken
by contractor as well as concerned Head of Department .Pre-employment & Periodical medical
examination of contractor workers shall be carried out in form no.32 from GSECL Factory
Medical Officer after every six (06) months of contractor with their contractor workers.
Contractor shall be fulfilled all health requirements before commencement of work. After
completion of medical examination in form no.32/33, GSECL Factory Medical Officer shall be
signed in contract worker gate pass procedure format.
(04) Contract worker gate pass will issue after completion of safety induction 3D animation
movie & Training record is to be maintained in IMS/OHSAS training format by TK Office/LWO.
(05) As per Gate pass format of GSECL, Safety Officer/Dy. Safety Officer shall be checked
the issue PPE to contract workers as per nature of job, Form no.10 of lifting tools and tackles,
Driving license, Electrical contractor license, Electrical trade qualifications, Safety induction
training, SOP, supervisor qualifications etc. After fulfillment of all Safety compliances, Safety
Officer/Dy. Safety Officer shall be signed in Contract worker Gate pass procedure format.
(06) Work Contract shall be completed by principle contractor/agency/person who is
awarded the work order. Subletting of contract shall be allowed only if prior approval of Power
station chief before execution of work. Contractor/agency shall be submitted the entire
subletting contract documents with gate pass application through concern department EE &
SE, LWO/DGM, Safety Officer/Dy. Safety Officer & Factory Manager.
(07) Under The Conditions Framed Under Rule-45 Of The Indian Electricity Rules,
1956, Valid Electrical contractor License shall be submitted to concern electrical department
EE/SE/Electrical Safety Officer/ Safety Officer/Factory Manager at the time of apply gate pass
by agency/party with latest renewal from Chief Electrical Inspector, Gandhinagar- Gujarat.
Electrical License photocopy shall be checked by Concerned HOD of Electrical
Department/Electrical Safety Officer/Dy.Safety Officer/ Safety Officer/Factory Manager.
(08) As per nature of job/work, Qualified supervisor (Diploma (Electrical/
Mechanical/Civil/C&I) + 3 years experiences or ITI + 10 years) shall be engaged by contract
agency & qualification certificate with experience certificate shall be submitted to concern
EE/SE/LWO/IRO/DGM/ Dy. Safety Officer /Safety Officer/Factory Manager at the time of apply
gate pass.
68
(09) As per rule 3 of CEA regulation ,2010: Designating person(s) to operate and carry
out the work on electrical lines and Apparatus, Contract person/worker possesses a
certificate of competency or electrical work permit, issued by the Appropriate Government.
That means, Electrical trade Qualification of contract worker/person like ITI-wireman/
Electrician, Diploma (Elect), BE/B. TECH (Elect), ME/ M. TECH (Elect) shall be submitted to
concern EE/SE/LWO/IRO/DGM, Dy. Safety Officer/ Safety Officer/Factory Manager at the time
of apply for photo gate pass procedure.
(10) As per nature of job/work & during capital overhauling work /Annual overhauling work
/24X7 round the clock work/major shut down work, Qualified Safety
Officer/Manager/Supervisor (BE/Diploma (Elect/Mech/Civil) + PDIS-Post Diploma in Industrial
Safety) shall be engaged by contractor during dangerous operations/dangerous works as well
as day to day dangerous activities, safety supervision, tool box talk, Safety awareness
programme, SOP preparation with hazards & its control measures with each step , checking of
lifting tools & tackles, hydra mobile crane, Safety precautions, coordination with Safety
Department etc.
(11) License of driver shall be submitted with gate pass issue application as per nature of
vehicles & to follow the Motor vehicle Act,1988,the Central Motor Vehicles (Amendment)
Rules,2016 as well as Gujarat Motor Vehicles rules,1989 & driver license shall be checked
every day by security shift in charge before entry in the Factory premises.
(12) SOP with JSA (Job Safety Analysis) shall be prepared by contractor through competent
person as per GFR, 1963 or Qualified Safety Officer as per GFR, 1963 with 05 years
experiences. SOP will review & approve by concern JE/DE/EE/SE/Elect. Safety Officer/Dy.
Safety Officer /Safety Officer/Factory Manager before execution of work.
(13) It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as per
the job requirement. Do not work without use of required P.P.Es. Contractor is responsible to
provide standard make (ISI/DGMS/CE/EN/ANSI approved) & to checked standard/make in
PPE issue format by concern JE/DE/EE/SE/Safety Officer/Factory Manager. Personal
Protective Equipments / Safety Gadgets suitable to give sufficient protection against hazards
involved in their work / job to their staff, as per the job requirement and insist / enforce their
workers to put on the same while at works.
The ongoing work is liable to be stopped at any time if your contract workers/staffs found
working without P.P.Es. Following is the list of various P.P.Es (as per ISI/DGMS/CE/ EN/ ANSI
approved only) to be used for various works / worksites.
In any work, Contractor shall be issued the minimum 05 nos. of PPEs like Safety Shoes,
Safety Helmet, Safety goggles, Mask & Reusable Ear plug to their workers/supervisor
compulsory & it will check by concern section HOD & Dy. Safety Officer /Safety Officer at the
time of gate pass procedure.
69
List of safety equipments
Industrial Safety Helmet For protection of head against falling objects or during
fall of person from height. Yellow Colour helmet is
used for contract worker with agency logo.
Safety Goggles/welding For protection of eyes against flying particles / dust,
goggles/chemical splash chemical splash, welding spark, arc, flashover etc.
goggles
Full Face shield For protection of face against flying particles / dust,
chemical splash, spark, arc, flashover etc.
Reusable Earplug / Ear muffs. For ear / hearing system protection while working in
high noise level area.
Chemical suit/Gas tight suit For body protection against chemicals, oils, sharp
/Fire proximity suit/FR Boiler edged objects, heat, hot objects etc.
Suit
Safety Hand Gloves For protection of hands against chemicals, oils, sharp
edged objects, heat, hot metals/objects, electricity etc.
Safety shoes/ Gum Boots with For protection of leg/feet against falling objects, sharp
Oil/Chemical/water/heat/ edged objects, heat, hot metals/objects, electricity etc..
Electrical resistance etc.
Safety Belt(full body hardness For fall prevention while working at heights or in depth,
with double lanyard & shock working in vessel or in confined space.
absorber) / Rope / Life line /
Fall arrestor etc.
Dust Mask/Respirator with Protection of respiratory system against dust.
valve(FFP2)
Chemical Cartridge Respirator Protection against toxic chemical fumes /
with full face mask type gases/vapors/dust etc.
A2B2E2K2
Trolley mounted Air line Working in oxygen deficient zone or confine space
respirators with full face mask area
Portable Single gas detector Working in hazardous storage/process area
like Chlorine, Ammonia,
Hydrogen, etc
Portable Multi gas Detector Working in oxygen deficient zone & use in entry of
( LEL,O2,CO,H2S,SO2, etc) confine space & Major fire
Automatic voltage detector To check the present voltage or induction voltage of
electrical equipments/ bus/switch gears from 01 (one)
feet distance before starting the any electrical work .
Auto darkening welding helmet The new auto darkening welding helmet combines
(EN 379 & EN 175 Level-B) legendary Speed glass quality and auto darkening
with PAPR as per EN technology with an innovative wide-view grinding visor
12941:1998, class TH2 and to give welders an all-in-one solution for more flexibility,
AS/NZS 1716 precision, and efficiency.
Respiratory System is a combined face and breathing
protection device, for increased comfort and safety in
welding. The unit is equipped with a particle filter which
removes particles from the air. The unit provides a
constant airflow independent of filter combinations and
clogging. The unit can also be equipped with a gas
filter (for example A1B1E1). The unit supplies air to the
head top via the connecting breathing tube. The airflow
creates a slight positive pressure which together with
the sealing to the face prevents particles and other
contaminants from entering the head top.
70
(14) All PPEs (as per ISI/DGMS/CE/EN/ANSI approved only) Should issued by
party/agency/contractor to their contractor workers as per nature of job and allotment of PPE
list shall be submitted to Safety Officer, BLTPS on his letter head as per below mentioned
format by Contractor before commencement of work through concerned JE,DE,EE/SE .
Sub: Issue of PEE to Contractor workers
Sub of work Order:
Work order no.
Name of Agency:
Date of Commencement:
Time limit for work order:
Sr. Name Designatio Name of Name of IS Mak Qty Unit Date Recei
no of n Section PPE :Code e of of ving
. workers under no. of PPE issue signat
work PPE ure
execution
A B C D E F G H I J K
Safety Nos.
01 Helmet
Safety Nos.
goggles
Reusable Pair
Ear Plug
Dust Nos.
Mask
Safety Pair
Shoes
(15) Shift Security Inspector/Security Officer shall be checked Safety Shoes & Safety Helmet
of all contractor workers at entry gate of Factory Premises & shall entered contractor workers
with Safety Shoes & Safety Helmet with photo ID Gate Pass.
(16) Shift Security Inspector/Security Officer shall be checked validity of Gate pass of all
contractor workers on daily basis.
(17) During the work execution, one trained & competent supervisor of agency should always
remain present at work site. Concern JE/DE of GSECL shall be supervised the contract work
as per SOP.
(18) Approved NABL laboratory calibration certificates of
electrical/mechanical/Civil/C&I/Environment survey/Chemical etc measuring /testing
equipments/instruments which are used during contract work shall be submitted before starting
the work & shall be checked by concern JE/DE/EE before starting work & it’s record shall be
maintained in concern section.
(19) The contractor shall take all the required safety measures prior to commencement of
work on dangerous substances, machineries or area at which cautionary notice is displayed
and obtain “Line Clear” or “Work Permit” through the concern Department / Section JE/DE and
shall be informed to concern section JE/DE for closed/ returned after completion of work.
(20) Safety talk/Safety work instructions shall be given to contractor workers by concern
JE/DE regarding hazards of specific work, risk & it’s control measure (mentioned in HIRA)
before starting the job work and records shall be maintained for each & every job works.
(21) Display Safety instructions shall be strictly followed by all workers who are working in
factory premises.
(22) Material Safety Data Sheet (MSDS) of each chemical shall be available with Chief
Chemist/Control room & work related Chemical information shall be taken by contractor &
contractor workers from Concern EE/Chief Chemist before starting of chemical handling work.
(23) The contractor shall be checked & securely covered or securely fenced any opened fixed
vessel, sump, tank, pit or opening in ground or in floor which, by reason of its depth, situation,
construction or contents, is or may be a source of danger before starting the work each &
every days or after interval/recess. Contractor supervisor shall be informed to concerned HOD
regarding any unsafe conditions.
71
(24) Prohibition of smoking, fires, lights, spontaneous ignition substance, matches; fuses,
mobile phone etc are to be strictly followed by all workers who are working in factory premises.
(25) Prior to carrying out welding, gas cutting, furnace heating or any other hot work job,
remove all the inflammable material lying at or nearby worksite or cover it properly by suitable
protective covering. Also, special care shall be taken before carrying out such job & see that all
possible contributing factors to set fire shall be removed / vanished prior to commencement of
the work. Advance intimation shall be given to concerned section / fire section to commence
the work in fire prone areas. They should also keep ready all the First Aid Fire Extinguishers /
equipments & fire extinguishing media / material like sand / water buckets or other appropriate
equipment at such place.
(26) While carrying out work in confined space or inside vessel, obtain necessary “Confined
Space / Vessel Entry Permit” from concerned department prior to commencement of the
work.
For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp shall be
used. For taking care of the persons working inside the confined space / vessel, a supervisor /
person capable to keep continuous watch on person(s) working inside, assist them in case of
emergency or arrange to get immediate outside help, shall remain present at entry point. Use
full body safety belt without failed.
While working inside sewage, trench or in-depth, a person to warn outsiders / entrants /
passers etc shall remain available near entry point or the entry point shall be cordoned by a
barricaded tape with a cautionary notice. After completion of the works, all the lids / covers /
grills / grits opened, shall be re-fixed / re-placed in the original position as it were prior to
commencement of the work and leave the work place in safe condition in all respect, so as to
prevent accident to fellow workers.
(27) The contractor shall see that he / his persons do not work on or block (by stacking
material, spare parts, tools-tackles, equipments etc), any passages / walkways / gangways /
aisles / staircases / ladders / lifts or any other approaches / roads leading to plans or its
auxiliaries, on which there is traffic movements or possible traffic movements in case of
emergency. Such passages are meant for safe escape in the event of emergency. If it is
utmost necessary to carry out work in such area with blocking of passage, prior permission of
Competent Authority or the Engineer-In-Charge shall be obtained. To demarcate / declare the
area as “UNSAFE”, cordon it using barricading tape & display suitable caution notice or keep
a person to restrict / divert the traffic on this route through other safe passage.
(28) The contractor shall see that he / his persons do not work on or block (by stacking
material, spare parts, tools-tackles, equipments etc), any passages / walkways / gangways /
aisles / staircases / ladders / lifts or any other approaches / roads leading to plans or its
auxiliaries, on which there is traffic movements or possible traffic movements in case of
emergency. Such passages are meant for safe escape in the event of emergency. If it is
utmost necessary to carry out work in such area with blocking of passage, prior permission of
Competent Authority or the Engineer-In-Charge shall be obtained. To demarcate / declare the
area as “UNSAFE”, cordon it using barricading tape & display suitable caution notice or keep
a person to restrict / divert the traffic on this route through other safe passage.
(29) Prior to use power / electrically operated hand tools / equipments / machines / gadgets
like welding machine, hand grinder, hand drill etc, ensure for its safe operation & use it only if it
is found safe to use. Do not use defective, unsafe or improperly maintained equipments.
The electrical power supply required to run such equipments shall not be taken directly at their
own but shall be obtained through concerned Electrical Maintenance Departments or their
authorized persons or under their observations / guidance only. The Electrical Section shall
provide temporary electrical connection up to contractor’s Mains Board on which it is
compulsory to install mains switch, ELCB & fuses of adequate capacity. All such equipments
shall invariably be earthed adequately to prevent electrical shock, sparking, short circuit etc.
Power cord to be used shall be of adequate capacity, without any joint & shall consist of earth
wire also. Hence, it is necessary to use adequate capacity 3-wire power cord for single & 5-
wire power cord for three phase power connections. The plugs, receptacles, pins, holders etc
shall be of adequate capacity & safe to use.
72
All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting machine,
Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used during work execution
shall be of standard make & bear ISI certification mark on it.
The consumables like welding electrodes, grinding wheels / discs etc which has specific
prescribed life span shall not be used in any case if its expiry date is over.
(30) Non-Sparking Non-Magnetic electrical hand tools and tool kits shall be used by Electrical
contractor for safe use in areas where hazardous, flammable, or combustible vapors, liquids,
dusts, or residues may be present in Gas Based power plant and list of tools and tackles shall
be submitted with technical bid. Non-Sparking Non-Magnetic electrical hand tools and tool kits
shall be checked by JE/DE before commencement of Electrical work.
(31) Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift, mobile
crane, EOT crane etc) & its attachments (like D-shackles, slings, U-clamps, Eye bolts or any
fixtures), it shall be checked and used only if found safe to use. Also, ensure that these are
tested, examined & certified in form no.10 by Competent Person as per the Factory act-1948 &
Gujarat Factories Rules and its validity do not expire. Further, it shall be fixed properly and
firmly prior to lifting the weight. Valid Test certificate of all Lifting machines used by
Contractor to be submitted to Dy. Safety Officer/ Safety Officer before commencement of
work through concerned EE/SE.
(32) Metal Scaffoldings to be used for working at height shall be of adequate size & capacity.
Obtain the work permit when working at height. While climbing on such scaffolding or working
on any structure at height, use of full body safety belt /full body hardness with double lanyard &
Fall arrestor & Helmet is compulsory. It is also necessary to fasten chinstraps of the helmet.
(33) Contractor or their employee shall not interfere in day-to-day routine plant activities /
works except the work assigned to them, shall not loiter in the areas other than their work
jurisdiction, as well as shall not temper / operate / touch the
machineries/equipments/auxiliaries with which they are not concerned. Also, the contractor
shall strictly instruct their staff for not to sit or take rest at/near/below running plants, auxiliaries,
systems or any place which is risky, hazardous & prone to accident.
(34) The cylinders containing poisonous / toxic or inflammable / explosive gas like Oxygen,
Acetylene, LPG, Hydrogen, Ammonia, Chlorine, CO2 etc shall be handled safely taking due
care. To handle / shift such cylinders a special trolley /cage meant for it must be used but in no
case it should be rolled.
(35) In Gas Based Power station/Hydrogen storage area /Hydro carbon fumes-vapour
generated area, Spark arrestor (as per approved manufacturer of CCOE, Nagpur) shall be
provided on each vehicle by party/agency and it will check by shift security in charge before
entry of vehicles in the factory premises.
(36) No women or young person shall be employed or permitted to work in Lead-compound
area like battery room etc. as per schedule VI of GFR 1963.
(37) No women or young person shall be allowed to clean, lubricate or adjust any part of a
prime mover or of any transmission machinery while the prime mover or transmission
machinery is in motion. Examination or operation of motion machinery shall be made or carried
out only by a specially trained adult male worker wearing tight fitting clothing as per section 22
of factories act 1948.
(38) In all risky job, before start the work, contractor should obtain General Safety Work
Permit through concerned section from Shift –in-charge well in advance.
(39) In case of noticing smoke or fire during their work execution, they shall make immediate
efforts to extinguish / control it and simultaneously inform the Fire Station Mobile No as well as
Station Fire Officer or Emergency Control room no which is displayed at prominent place of
factory like Main Security Gate, All unit control room, Canteen area, Safe Assembly points,
Fire Station, All security gates, Occupational Health Centre.
(40) In case of any injury / accident while working, it shall immediately be reported to Safety
Department through concerned Sectional Head / Engineer. The prescribed Form No. 21 &
ANNEXURE may be obtained from concerned section or Dy. Safety Officer/Safety Officer.
In case of any electrical accident, it shall immediately be reported to Electrical Safety Officer
through concern Sectional Head / Engineer. The prescribed Electrical accident form no. A
as per electricity act-2003 & Form No. 21 & ANNEXURE as per Gujarat Factories rules
shall be filled up by concern department JE/DE with written consent of contractor. The Form
73
may be obtained from concerned Electrical section or Electrical Safety Officer. Electrical
accident investigation shall be carried out by Electrical Safety Officer with Factory Manager.
After any reportable accident, Contract agency shall be submitted the fitness certificate of
injured person with endorsement of GSECL factory Medical Officer to LWO/Dy.Safety
Officer/Safety Officer/Electrical Safety Officer then after injured person may allow for work.
(41) For any incident occurred but have no injury to any persons should also reported as per
GSECL format and informed to Dy. Safety Officer/Safety Officer as Near Miss Incident.
(42) Safety penalty shall be imposed against Offences by contract workers: If any
contract worker worked in a factory contravenes any provision of Factories act or any rules or
orders made there under, imposing any duty or liability on workers, contractor/agency shall be
punishable with fine which mentioned as under.
Sr. Description of penalty Amount
No.
(i) Work without PPEs Rs.300/- per
person
(ii) Work without work Safety permit like working at height, confine Rs.1000/- per
space entry, hot work etc. day
(iii) License of driver as per type of vehicles not registered. Rs.750/- per
person
(iv) Welding work without flashback arrestor/double gauge regulator set Rs.1000/- per
set
(v) Operate Portable power tool without ELCB Rs.1000/-per
equipment
(vi) Work without qualified Supervisor as per nature of job like Rs.1000/-per
mechanical, electrical, civil, C&I, chemical etc. day
(vii) Work without SOP & JSA Rs.2000/-per
day
(viii) Work without test report of lifting machines / tackles (like C.P.Bs., Rs.2000/- per
Hook chooks, winch, forklift, mobile crane, EOT crane etc) & its equipment
attachments (like D-shackles, slings, U-clamps, Eye bolts or any
fixtures) in Form No.10 of Gujarat Factories Rules,1963
(ix) Work without Double lynyer Safety belt during working at Height Rs.3000/-per
work, work without anchoring in hook/line line person
(x) Work without 24 Volt supply in Confine space area Rs.3000/-per
person
Safety Penalty is to be imposed directly by individual Dy. Safety Officer/Safety
Officer/Electrical Safety Officer and Factory Manager/Occupier against violation of statutory
requirements and penalty will be recovered through RA bill. Photograph/CCTV camera footage
is to be put up with penalty note by imposed individual officer.
(43) Party will damage any fire equipments or property or machinery in factory during
execution of work, total damage cost will be recovered from party RA bill and recovery Office
note put up by concern HOD.
(44) All the relevant labour and industrial laws shall also be followed compulsorily.
(45) After completion of work, cotton waste, grease, oil, unused material, welding rod pieces,
scrap etc. are to be removed by contractor and scrap shall be deposited to scrap yard of Main
Store.
(46) For performance evaluation of contractor, safety factors of work accident, fire incident &
near miss accident will be considered. Steps can be taken to review the job assignment up to
cancellation for negligence.
(47) Over & above these, contractor shall have to follow all the safety requirements /rules &
regulations / norms and legal provisions laid down in various statutes. Particularly the
provisions of The Factories Act-1948 & the Gujarat State Factories Rules-1963 (Amended up
to date), The Electricity Act-2003 & rules, BOCW Act/Rules shall be followed strictly. The
contractor shall also obey the rules / regulations / instructions of the local Competent Authority
for safety & health requirements.
74
The above rules shall be scrupulously followed and where required, Contractor /contractor
workers may contact to the Dy. Safety Officer/Safety Officer/Electrical Safety Officer in case of
any ambiguity or needs further guidance in this regard
75
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-F
INTEGRITY PACT
ANNEXURE - I
CERTIFICATE – A (FROM-1)
CIRCULAR – I
76
ON STAMP PAPER OF RS.300/-
FORM OF BANKER'S UNDERTAKING
(For Performance Guarantee (PBG) towards execution / Supply period
as per Commercial Terms and Conditions of Tender)
This agreement shall be valid and binding on this Bank up to and inclusive of
________________ (Date of validity of the Bank Guarantee) and shall not be terminable by
notice or by change in the constitution of the Bank or the firm of Contractors / Suppliers or by
any other reasons whatsoever and our liability hereunder shall not be impaired or discharged
by any extension of time or variations or alterations made, given conceded or agreed, with or
without our knowledge or consent, by or between parties to the said within written contract.
Notwithstanding anything contrary contained in any law for the time being in force or banking
practice, this Guarantee shall not be assignable, transferable by the beneficiary (i.e. GUVNL or
Subsidiaries). Notice or invocation by any person such as assignee, transferee or agent of
beneficiary shall not be entertained by the Bank. Any invocation of the Guarantee can be made
only by the beneficiary directly.
NOTWITHSTANDING anything contained herein before, our liability under this guarantee is
restricted to Rs.________________ (Rupees ______________________________ only). Our
guarantee shall remain in force until __________________ (Date of validity of the Bank
Guarantee). Unless demands or claims under this Bank Guarantee are made to us in writing on
or before _____________ (Date of Validity of the Bank Guarantee), all rights of Beneficiary
under this Bank Guarantee shall be forfeited and we shall be released and discharged from all
liabilities there under.
Place:
Date:
77
NAME OF DESIGNATED BANKS:
(A) Guarantees issued by following banks will be accepted as SD/EMD on permanent basis:
All Nationalized Banks
(B) Guarantees issued by following Banks will be accepted as SD/EMD for the period up to
March 31, 2022. The validity cut-off date in GR is with respect to date of issue of Bank
Guarantee irrespective of date of termination of Bank Guarantee.
The Mehsana Urban Co-Operative Bank Ltd.
The Ahmedabad Mercantile Co-Pp. Bank Ltd.
Nutan Nagarik Sahakari Bank Ltd.
Kalupur Commercial Co-Operative Bank Ltd.
RBL Bank
Axis Bank
ICICI Bank
HDFC Bank
Kotak Mahindra Bank
IndusInd Bank
Rajkot Nagrik Sahakari Bank Limited
The Gujarat State Co-Operative Bank
Sarswat Bank
Saurashtra Gramin Bank
DCB Bank
Tamilnadu Mercantile Bank
Ujjivan Samll Finance Bank
A U Samll Finance Bank
Federal Bank
Equitas Samll Finance Bank
Bandhan Bank
Standard Chartered Bank
City Union Bank
Yes Bank
Note: The Banks shall be the Banks recognized / notified by the Finance Department,
Government of Gujarat (GoG) from time to time.
78
E. M. D. BANK GUARANTEE FORMAT.
We, ____________________________ (name of the Bank and address of the Branch giving
the Bank Guarantee) having our Registered Office at
___________________________________ (address of Bank’s Registered Office) hereby give
this Bank Guarantee No. ________________ dated _________ and hereby agree
unequivocally and unconditionally to pay immediately on demand in writing from the Gujarat
Urja Vikas Nigam Ltd. or any Officer authorized by it in this behalf any amount not
exceeding Rs. ______________ (amount of E.M.D.), (Rupees ____________________
_________________ (in words) to the said Gujarat Urja Vikas Nigam Ltd. on behalf of the
Tenderer.
This agreement shall be valid and binding on this Bank up to and inclusive of
____________________ (mention here the date of validity of Guarantee) and shall not be
terminable by notice or by Guarantor change in the constitution of the Bank or the firm of
Tenderer Or by any reason whatsoever and our liability hereunder shall not be impaired or
discharged by any extension of time or variations or alternations made, given, conceded with or
without our knowledge or consent by or between the Tenderer and the GUVNL.
“Notwithstanding anything contrary contained in any law for the time being in force or
banking practice, this Guarantee shall not be assignable, transferable by the beneficiary
(i.e. GUVNL or Subsidiaries). Notice or invocation by any person such as assignee,
transferee or agent of beneficiary shall not be entertained by the Bank. Any invocation of
the Guarantee can be made only by the beneficiary directly.”
Place:
Date:
(A) Guarantees issued by following banks will be accepted as SD/EMD on permanent basis:
All Nationalized Banks
(B) Guarantees issued by following Banks will be accepted as SD/EMD for the period up to
March 31, 2022. The validity cut-off date in GR is with respect to date of issue of Bank
Guarantee irrespective of date of termination of Bank Guarantee.
The Mehsana Urban Co-Operative Bank Ltd.
The Ahmedabad Mercantile Co-Pp. Bank Ltd.
Nutan Nagarik Sahakari Bank Ltd.
Kalupur Commercial Co-Operative Bank Ltd.
RBL Bank
Axis Bank
ICICI Bank
HDFC Bank
Kotak Mahindra Bank
IndusInd Bank
Rajkot Nagrik Sahakari Bank Limited
The Gujarat State Co-Operative Bank
Sarswat Bank
Saurashtra Gramin Bank
DCB Bank
Tamilnadu Mercantile Bank
Ujjivan Samll Finance Bank
A U Samll Finance Bank
Federal Bank
Equitas Samll Finance Bank
Bandhan Bank
Standard Chartered Bank
City Union Bank
Yes Bank
Note: The Banks shall be the Banks recognized / notified by the Finance Department,
Government of Gujarat (GoG) from time to time.
To create an environment where Business Confidence is built through Best Business Practices
and is fostered in an atmosphere of trust and respect between providers of goods and services
and their users for the ultimate benefit of society and the nation.
Name : Name:
Designation:
Name : Name:
Designation:
81
ANNEXURE- I
Financial Department, GR.No. EMD/10/2018/18/DMO Dtd.16/04/2018
(A) Guarantees issued by following banks will be accepted as SD/EMD on permanent basis:
All Nationalized Banks
(B) Guarantees issued by following Banks will be accepted as SD/EMD for the period up to
March 31, 2022. The validity cut-off date in GR is with respect to date of issue of Bank
Guarantee irrespective of date of termination of Bank Guarantee.
The Mehsana Urban Co-Operative Bank Ltd.
The Ahmedabad Mercantile Co-Pp. Bank Ltd.
Nutan Nagarik Sahakari Bank Ltd.
Kalupur Commercial Co-Operative Bank Ltd.
RBL Bank
Axis Bank
ICICI Bank
HDFC Bank
Kotak Mahindra Bank
IndusInd Bank
Rajkot Nagrik Sahakari Bank Limited
The Gujarat State Co-Operative Bank
Sarswat Bank
Saurashtra Gramin Bank
DCB Bank
Tamilnadu Mercantile Bank
Ujjivan Samll Finance Bank
A U Samll Finance Bank
Federal Bank
Equitas Samll Finance Bank
Bandhan Bank
Standard Chartered Bank
City Union Bank
Yes Bank
Note: The Banks shall be the Banks recognized / notified by the Finance Department,
Government of Gujarat (GoG) from time to time.
82
On Non-Judicial Stamp Paper of Rs. 300
I, ______ proprietor / owner / partner / Authorized Agent of M/s. ______ do hereby declare and
undertake as under:
SIGNATURE OF CONTRACTOR
83
On Firm’s Letter Head [FORM -01]
CERTIFICATE – A
Place:
Date:
84
DEVIATION FROM BIDDER (IF ANY) [FORM -02]
FORM-02
Name of Construction of collapsed/Tilted compound wall of P.H.
Work due to Tauktae Cyclone at BLTPS.
NOTE:-
1. GSECL does not bind to accept the deviation offered by bidder for evaluation of tender.
2. If there is any deviation from bidder, it should be clearly mentioned on this page.
3. Deviation mentioned on other page should not be considered and order will be placed
according to the tender documents.
4. If there is no any deviation from bidder, than it must be clearly mentioned in this page “NO
DEVIATION OFFERRED”
85
UNDERTAKING IN REGARD TO STOP DEAL / BLACK
LIST THEREOF) –[FORM -03]
FORM-03
Name of Construction of collapsed/Tilted compound wall of P.H.
Work due to Tauktae Cyclone at BLTPS.
All Bidders will have to furnish the following Undertaking duly filled in, signed and stamped
for each quoted item of the Tender along with the Technical Bid.
Sub:- Undertaking in regard to Stop Seal / Banned for Business Dealing / Black List
Thereof.
I / We __________________________________________________________________
Authorized signatory of M/s. _________________________________
_________________
Hereby certify that
M/s._______________________________________________________
And their proprietor / any partner / any directors of the firm is not stop deal and/or banned
for business dealing and/or black listed by GUVNL and/or their any subsidiary company
viz. GSECL / GETCO / DGVCL / MGVCL / UGVCL / PGVCL”.
86
UNDERTAKING TO BE SUBMITTED ON LETTERHEAD
We, the supplier / contractor of GUVNL/ or subsidiary company hereby unconditionally agree to
transfer the amount as determined as the benefit available to us in the form of higher input tax
credit due to introduction of GST law.
We hereby unconditionally agree that GUVNL/ or subsidiary company has the absolute right to
recover the net amount so determined from payments payable by GUVNL/or subsidiary
company by way of clause no. ____ of statutory Variation and clause no. ____ of excise duty of
our AT/WO/PO which has been agreed to and accepted by us & also as per the clause 171 of
the GST law referring to Anti – Profittering law wherein the Govt. has made it compulsory to
transfer the benefit on account of higher ITC available due to introduction of GST to the
consumers.
SIGNATURE OF CONTRACTOR
87
CIRCULAR – I
The following are the major obligations to be fulfilled by the Contractors as per the Contract
Labour (R&A) Act 1970 and rule mentioned there under:
1. License to be obtained before starting the Work where number of contract laborers is
ten or more.
2. Payment to contract labourers has to be made in presence of IRO/LWO. Wages rates
for contract labourers are applicable as per the terms and conditions of the license.
Minimum rate of the wages for unskilled labour is Rs. 340.20 for semiskilled labour is
Rs. 348.20 and for skilled labour is Rs. 356.20 w.e.f. 01.04.2021 to 30.09.2021 or as
per the circular of GoG time to time.
3. Every contractor shall have to maintain the muster roll and wages register in respect of
his contract labour.
4. Every contractor is required to issue employment card, wages slip and attendance card
to their laborers.
5. The contractor has to maintain the register No. 13 containing details of contract labors
employed by him.
6. Earned leave register/ card as per the Factories Act and Rules.
7. Other registers required under Contract Labour Rules and the Factories Act and Rules.
8. Every contractor shall have to obtain insurance policy in respect of the contract labors
engaged by him to cover them under workmen’s Compensation Act.
9. To send half yearly return to licensing officer as per Rule 82 (1) as per schedule time.
10. Before starting the work as per the contract awarded to him, he should make
arrangement to enter into the agreement in the prescribed format on the stamp paper as
applicable. Before fulfilling the above requirement the contractor is instructed not to start
the work. The responsibility will be on his head in case he fails.
11. Contractor should possess separate P.F. code on their firm, name otherwise their offer
may not be considered.
12. Contractors shall have to pay wages as may be revised from time to time as may be
declared by GOVERNMENT All the contractors are informed to adhere to the rules and
regulations applicable to them, particularly in respect of the laborers engaged by them,
the contractor not fulfilling the obligations will not be allowed or continue with work/not
be held qualified to carry out the work at BHAVNAGAR LIGNITE TPS.
88
89
90
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SECTION-G
GENERAL SPECIFICATIONS
TECHNICAL SPECIFICATION
91
GENERAL SPECIFICATIONS
01. In the specifications, “as directed”/”Approved” shall be taken to mean “as
directed”/”approved” by the Engineer-in-charge.
02. Wherever a reference to any Indian Standard appears in the specifications, it shall be
taken to mean as a reference to the latest edition of the same in force on the date of
agreement.
03. In “Mode of Measurement” in the specification wherever a dispute arises in the absence
of specific mention of a particular point or aspect, the provisions on these particular
points or aspects in the relevant Indian Standards shall be referred to.
04. All measurements and computations, unless otherwise specified, shall be carried out as
per Latest IS: 1200.
05. The distance which constitutes lead shall be determined along the shortest practical
route and not necessarily the route actually taken. The decision of the Engineer-in-
charge in this regard shall be taken as final.
06. Where no lead is specified, it shall mean “all leads”.
07. Lift shall be measured from plinth level.
08. Up to “floor two level” means actual height of floor up to 6.5 Mt. Above plinth level.
09. Definite particulars covered in the items of work, though not mentioned or elucidated in
it, specification shall be deemed to be included therein.
10. Reference to specifications of materials as made in the detailed specification of the
items of work is in the form of a designation containing the number of the specification of
the material and prefix ‘M’ e.g. ‘M-5’.
11. Approval to the samples of various materials given by the Engineer-in-charge shall not
absolve the contractor from the responsibility of replacing defective material brought on
site or materials used in the work found defective at a later date. The contractor shall
have no claim to any payment or compensation whatsoever on account of any such
materials being rejected by the Engineer-in-charge.
12. The contract rate of the item of work shall be for the work completed in all respects.
13. No collection of materials shall be made before it is got approved from the Engineer-in-
charge.
14. Collection of approved materials shall be done at site of work in a systematic manner.
Materials shall be stored in such a manner as to prevent damage, deterioration or
intrusion of foreign matter and to ensure the preservation of their quality and fitness for
the work.
15. Cement, reinforcements bars & all other materials to be used shall be got approved from
EIC before starting of work. The cement, reinforcement steel & other materials to be
brought at site shall be entered at BLTPS main entry gate.
16. Materials, if and when rejected by the Engineer-in-charge, shall be immediately removed
from the site of work.
17. No materials shall be stored prior to, during and after execution of a structure in such a
way as to cause or lead to damage or overloading of the various components of the
structure.
18. All works shall be carried out in a workmanlike manner as per the best techniques for
the particular item.
19. All tools, templates, machinery and equipment for correct execution of the work as well
as for checking lines, levels, alignment of the works during execution shall be kept in
sufficient numbers and in good working condition on the site of the work.
20. The mode, procedure and manner of execution shall be such that it does not cause
damage or over loading of the various components of the structure during execution or
after completion of the structure.
92
21. Special modes of construction not adopted in general Engineering practice, if proposed
to be adopted by the Contractor, shall be considered only if the contractor provides
satisfactory evidence that such special mode of construction is safe, sound and helps in
speedy construction and completion of work to the required strength and quality.
Acceptance of the same by the Engineer-in-charge shall not, however, absolve the
contractor of the responsibility of any adverse effects and consequences of adopting the
same in the course of execution of completion of the work.
22. All installations pertaining to water supply and fixtures thereof as well as drainage lines
and sanitary fittings shall be deemed to be completed only after giving satisfactory tests
by the Contractor.
23. The contractor shall be responsible for observing the rules and regulations imposed
under ‘Minor Minerals Act’ and such other laws and rules prescribed by Government
from time to time.
24. All necessary safety measures and precaution [including those laid down in the various
relevant Indian Standards shall be taken to ensure the safety of men, materials and
machinery on the works as also of the work itself.
25. The testing charge of all materials shall be borne by the Contractor unless recovery at
one percent towards using charges is separately made.
26. Approval to any of the executed items for the work does not in any way relieves the
contractor of his responsibility for the correctness, soundness and strength of the
structure as the drawings and specification.
93
TECHNICAL SPECIFICATIONS
NAME OF WORK : Construction of collapsed/Tilted compound wall of
P.H. due to Tauktae Cyclone at BLTPS.
MATERIAL SPECIFICATION
M-1 Water:
1.1 Water shall not be salty or brackish and shall be clean, reasonably clear and free from
objectionable quantities of silt and traces of oil and injurious alkalies, salts, organic matter and
other deleterious material which will either weaken the mortar or concrete or cause
efflorescence or attack the steel in R.C.C Container for transport, storage and handling of
water shall be clean. Water shall conform to the standards specified I.S 456-1978.
1.2 If required by Engineer-in-charge it shall be tested by comparison with distilled water.
Comparison shall be made by means of standard cement tests for soundness, time of setting
and mortar strength as specified in I.S.269-1976. Any indication of unsoundness, change in
time of setting by 30 minutes or more or decrease of more than 10 per cent in strength of
mortar prepared with water sample when compared with the results obtained with mortar
prepared with distilled water shall be sufficient cause for rejection of water under test.
1.3 Water for curing mortar, concrete or masonry should not be too acidic or too alkaline. It
shall be free of elements which significantly affect the hydration reaction or otherwise interfere
with the hardening of concrete during curing or those which produce objectionable stains or
other unsightly deposits on concrete or mortar surfaces.
1.4 Hard and bitter water shall not be used for curing.
Potable water will be generally found suitable for curing mortar or concrete.
M-3 Cement:
Cement shall be ordinary Portland slag cement as per I.S. 269-1976 or Portland slag cement
as per I.S. 455-1976.
M-6 Sand:
6.1 Sand shall be natural sand, clean, well graded, hard strong durable and gritty particle free
from injurious amounts of dust clay, kankar nodules, soft or flaky particles shale, alkali, salts
organic matter, loam, mica or other deleterious substance and shall be got approved from the
Engineer-in-charge. The sand shall not contain more that 8 percent of silt as determined by
field test. If necessary the sand shall be washed to make it clean.
6.2 Coarse Sand: The fineness modulus of coarse sand shall not be less than 2.5 and shall not
exceed 3.0.
The sieve analysis or coarse shall be as under:
M-15 Bricks :
15.1 The bricks shall be hand or machine molded and made from suitable soils and klin-
burnt. They shall be free from crack and nodules of free lime. They shall have smooth
rectangular faces with sharp corners and shall be of uniform color.
The bricks shall be molded with a frog of 100 mm. X 40 mm. And 10 mm. To 20 mm. Deep on
one of its flat sides. The bricks shall not break when thrown on the ground from a height of 600
mm.
15.2 The size of modular bricks shall be 190 mm. X 90 mm. X 90 mm.
The size of the conventional bricks shall be as under :
(9” x 4 ⅜ “ x 2 ¾ “) 225 x 110 x 75 mm.
15.3 Only bricks of one standard size shall be used on one work. The following tolerances
shall be permitted in the conventional size adopted in a particular work.
Length : 1.8(3.0 mm.) Width : 1/6” (1.51 mm.) Height : 1/6” (1.50 mm.)
15.4 The crushing strength of the bricks shall not be less than 50 Kg./Sq. Cm. The average
water absorption shall not be more than 20 percent by weight. Necessary tests for crushing
strength and water absorption etc. Shall be carried out as per I. S. 3495 (Part-I to IV) 1976.
1. 6 mm 0.22Kg./Rmt. 8. 20 mm 2.47Kg./Rmt.
2. 8 mm 0.39Kg./Rmt. 9. 22 mm 2.98Kg./Rmt.
96
3. 10 mm 0.62Kg./Rmt. 10. 25 mm 3.85Kg./Rmt.
4. 12 mm 0.89Kg./Rmt. 11. 28 mm 4.83Kg./Rmt.
5. 14 mm 1.21Kg./Rmt. 12. 32 mm. 6.31Kg./Rmt.
6. 16 mm 1.58Kg./Rmt. 13. 36 mm. 7.99Kg./Rmt.
7. 18 mm 3.00Kg./Rmt. 14. 40 mm. 9.86Kg./Rmt.
M-26 Shuttering:
26.1 The shuttering shall be either of wooden planking of 30 mm. Minimum thickness with or
without steel lining or of steel plates stiffened by steel angles. The shuttering shall be
supported on battens and beams and props of vertical bellies properly cross braced together
so as to make the centering rigid. In places of bullies props, brick pillar of adequate section
built in mud mortar may be used.
26.2 The form work shall be sufficiently strong and shall have camber, so that it assumes
correct shape after deposition of the concrete and shall be able to resist forces caused by
vibration of live load of men working over it and other incidental loads associated with it. The
shuttering shall have smooth and even surface and its joints shall not permit leakage of cement
grout.
26.3 If at any stage of work during or after placing concrete in the structure, the form work
sags or bulges out beyond the required shape of the structure, the concrete shall be removed
and work redone with fresh concrete and adequately rigid form work. The complete form work
shall be got inspected by and got approved from the Engineer-in-charge, before the
reinforcement bars are placed in position.
26.4 The props shall consist of bullies having 100 mm. Minimum diameters measured at mix
length and 80 mm. At thin end and shall be placed as per design requirement. These shall rest
squarely on wooden sole plates 40 mm. Thick and minimum bearing area if 0-10 sq. M. Laid on
sufficiently hard base.
26.5 Double wedges shall further be provided between the sole plate and the wooden props
so as to facilitate tightening and easing of shuttering without jerking the concrete. -The timber
used in shuttering shall not be so dry as to absorb water from concrete and swell or bulge nor
so green or wet as to shrink after erection. The timber shall be properly sawn and planed on
the sides and surface coming in contact with concrete. Wooden form work with metal sheet
lining or steel plates stiffened by steel angles shall be permitted.
26.6 As far as practicable, clamps shall be used to hold the forms together and use of nails
and spikes avoided.
26.7 The surface of timber shuttering that would come in contact with concrete shall be well
wetted and coated with soap solution before the concreting is done. Alternatively coat of raw
linseed oil or oil of approved manufacturer may be applied in place of soap solution. In case of
steel shuttering either soap solution or raw linseed oil shall be applied after thoroughly cleaning
the surface. Under no circumstances black or burnt oil shall be permitted.
The shuttering for beams and slabs shall have camber of 4 mm. Per meter (1 in 250) or as
directed by the Engineer-in-charge so as to offset the subsequent deflection. For cantilevers,
the camber at free end shall be 1/50 of the projected length or as directed by the Engineer-in-
charge.
97
ITEM SPECIFICATION
Part-A(Pile foundation)
ITEM NO 1. Boring/drilling 300mm dia all kinds of soil using bentonite slurry to prevent side
collapse to the pile termination level as shown in the tender drawing and concreting the bore
hole to the ground level using concrete, grade M30, using 20 mm downgraded aggregate,
using minimum of 400 kg of cement per cubic meter of concrete, limiting W.C. ratio to 0.45.
Adding plasticizing admixture of approved brand to proportion recommended by manufacturer
to increase slump to ensure proper flow of concrete through tremie pipes, & cage lowering, the
payment for still separately in item no 4.etc. complete. Pile will be concreted to height of
500mm above of ground level, as per direction by site in charge or as per PWD booklet.
ITEM NO 02. Providing TMT Bar FE 500 reinforcement for RCC work including bending, binding
and placing in position complete up to floor two level etc completed as directed by EIC. (more
than 10 ton)
The TMT bars shall be of approved brand as specified in the tender elsewhere.
TMT BARS shall confirm to I.S. 1786-1985 of Fe-500 Grade.
Materials: shall conform to M-18,19
1.Workmanship :
2.1 The work shall consist of furnishing and placing reinforcement to the shape and dimensions
shown as on the drawings or as directed.
1.2 Steel shall be clean and free from rust and loose mill scale at the time of fixing in position
and subsequent concreting.
2.2 Reinforcing steel shall conform accurately to the dimensions given in the bar bending
schedules shown on relevant drawings. Bars shall be bent cold to specified shape and
dimensions or as directed using a proper bar bender, operated by hand or power to attain
proper radius of bends. Bars shall not be bent or straightened in a manner that will injure the
material. Bars bent during transport or handling shall be straightened before being used on the
work. They shall not be heated to facilitate bending. Unless otherwise specified a ‘U’ type hook
at the end of each bar shall invariably be provided to main reinforcement. The radius of the
bend shall not be less than twice the diameter of the round bar and the length of straight part of
the bar beyond the end of the curve shall be at least four times the diameter of the round bar.
In case of bars which are not round and in case of deformed bars, the diameter shall be taken
as the diameter of circle having an equivalent effective area. The hooks shall be suitably
encased to prevent any splitting of the concrete.
2.3 All the reinforcement bars shall be accurately placed in exact position shown on the
drawings and shall be securely held in position during placing of concrete by annealed binding
wire not less than 1 mm. In size and by using stay blocks or metal chair spacers, metal
hangers, supporting wires or other approved devices at sufficiently close intervals. Bars shall
not be allowed to sag between supports nor displaced during concreting or any other
operations of the work. All devices used for positioning shall be of non-corrodible material.
Wooden and metal supports shall no extend to the surface of concrete, except where shown on
drawings. Placing bars on layers of freshly laid concrete as the work progress for adjusting bar
spacing shall not allowed. Pieces of broken stone or brick and wooden blocks shall not be
used. Layers of bars shall be separated by spacebars, precast mortar blocks or other approved
devices. Reinforcement after being placed in position shall be maintained in a clean condition
until completely embedded in concrete. Special care shall be exercised to prevent any
displacement of reinforcement in concrete already placed. To prevent reinforcement from
corrosion, concrete cover shall be provided as indicated on drawings. All the bars producing
from concrete and to which other bars are to be spliced and which are likely to be exposed for
a period exceeding 10 days shall be protected by a thick coast of neat cement grout.
2.4 Bars crossing each other where required shall be secured by binding wires (annealed) of
size not less than 1 mm. In such manner that they do not slip over each other at the time of
fixing and concreting.
2.5 As far as possible bars of full length shall be used. In case this is not possible, overlapping
of bars shall be done as directed. When practicable, overlapping bars shall not touch each
98
other but be kept apart by 25 mm. Or 1.25 times the maximum size of the coarse aggregate
whichever is greater by concrete between them. Where not feasible overlapping bars shall be
bound with annealed wires not less than 1 mm. Thick twisted tight. The overlaps shall be
staggered for different bears and located at points along the span where neither movement is
maximum.
2.6 Whenever indicated on the drawings or desired by the Engineer-in-charge bars shall be
joined by couplings which shall have a cross section sufficient to transit the full stresses of
bars. The ends of the bars that are joined by coupling shall be upset for sufficient length so that
the effective cross section at the base of threads is not less than normal cross-section of the
bar. Threads shall be standard threads. Steel for coupling shall conform to I. S. 226.
When permitted or specified on the drawings joints of reinforcement bars shall be butt-welded
so as to transmit their full stresses. Welded joints shall preferably be located at points when
steel will not be subject to more than 75 per cent of the maximum permissible stresses and
welds so staggered that at any one section not more than 20 percent of the rods are welded.
Only electric arc welding using a process which excludes air from the molten metal and
conforms to any or all other special provisions for the work shall be accepted. Suitable means
shall be provided for holding bars securely in position during welding. It shall be ensured that
no voids are left in welding and when welding is done in two or three stages previous surface
shall be cleaned properly. Ends of the bars shall be cleaned of all loose scale, rust, grease,
paint and other foreign matter before welding. Only competent welders shall be employed on
the work. The M. S. Electrodes used for welding shall conform to I. S. 814. Welded pieces of
reinforcement shall be tested. Specimen shall be taken from the actual site and their number
and frequency of test shall be as directed.
3. Mode of measurement and payment:
3.1 Reinforcement shall be measured in length wise in RMT including overlaps, separately for
different diameters as actually used in the work. Where welding or coupling is resorted to in
place of lap joints such joints shall be measured for payment as equivalent length of overlap as
per design requirement. From the length so measured the weight if reinforcement shall be
calculated in Metric Ton. Wastage and annealed steel wire for binding shall not be measured
and the cost of these items shall be deemed to be included in the rate for reinforcement.
3.2 The rate for reinforcement includes cost of steel, binding wires its cutting, bending, placing,
binding and fixing in position as shown on the drawings and as directed. It shall also include all
devices for keeping reinforcement in approved position cost of joining as per approved method
and all wastage and spacer bars.
3.3 The rate shall be for a unit of MT.
Item No 02 Demolition of Brick work and stone masonry including stacking of serviceable
materials and disposal of unserviceable materials with all lead and lift.(ii) In Cement Mortar.
1.0. Workmanship :
1.1. The demolition shall consist of demolition of one or more parts of the building as specified
or shown in the drawings. Demolition implies taking up or down or breaking up. This shall
99
consist of demolishing whole or part of work including all relevant item as specified or shown in
the drawings.
1.2. The demolition shall always be planned before hand and shall be done in reverse order of
the one in which the structure was constructed. This scheme shall be got approved from the
Engineer-in-charge before starting the work. This however will not absolve the contractor from
the responsibility of proper and safe demolition.
1.3. Necessary dropping, shoring and under pinning shall be provided for the safety of the
adjoining work or property, which is to be left intact, before dismentaling and demolishing is
taken up and the work shall be carried out in such a way that no damages is caused to the
adjoining property.
1.4. Wherever required, temporary enclosures or partitions shall also be provided. Necessary
precautions shall be taken to keep the dust nuisance down as and where necessary.
1.5. Dismantling shall be commenced in a systematic manner. All materials which are likely to
be damaged by dropping from a height or demolishing, masonry etc. Shall be carefully
dismantled first. The dismantled articles shall be properly stacked as directed.
1.6. All materials obtained from demolition shall be the property of Government unless
otherwise specified and shall be kept in safe custody until handed over to the Engineer-in-
charge.
1.7. Any serviceable material, obtained during dismantling or demolition shall be separated out
and stacked properly as directed, with all lead and loft. All unserviceable materials, rubbish etc.
Shall be disposed up to any lead as directed by the Engineer-in-charge.
1.8. On completion of work, the site shall be cleared of all debris rubbish and cleaned as
directed.
Item No.03 Excavation for foundation up to 1.5m depth including sorting out and
stacking of useful materials and disposing of the excavated stuff up to 50M.lead etc
completed as directed by EIC. (A) Loose or Soft Soil
1.0 General: 1.1 Any soil which generally yields to the application of pickaxes and shovels,
phawaras, rakes or any such ordinary.
Excavating implement or organic soil, gravel, silt, sand turf loam, clay, peat etc fall under this
category.
2.0 Clearing the site : 2.1 The site on which the structure is to be built shall be cleared and all
obstructions, loose stone, materials and rubbish of all kind, bush, wood and trees shall be
removed as directed. The materials so obtained shall be properly of the Government and be
conveyed and stacked as directed within 50 M. Lead. The roots of the trees coming in the sides
shall be cut and Coated with a hot asphalt.
2.2 The rate of site clearance is deemed to be included in the rate of earth work for which no
extra will be paid.
100
3.0 Setting out: After clearing the site, the centerlines will be given by the Engineer-in-charge.
The contractor shall assume full Responsibility for alignment, elevation and dimension of each
and all parts of the tractor shall assume full responsibility for alignment Elevation and
dimension of each and all parts of the work. Contractor shall supply laborers, materials, etc.
Required for setting out the Reference marks and bench marks and shall maintain them as
long as required and directed.
4.0 Excavation: The excavation in foundation shall be carried out in true line and level and
shall have the width and depth as shown In the drawings or as directed. The contractor shall do
the necessary shoring and shutting or providing necessary slopes to a safe angle,
At his own cost. The payment for such precautionary measures shall be paid separately if not
specified. The bottom of the excavated Area shall be 1evelled both longitudinally and
transversely as directed by removing and watering as required. No earth filling will be
Allowed for bringing it to level, if by mistake or any other reason excavation is made deeper or
wider that shown on the plan or directed. The extra depth or width shall be made up with
concrete of same proportion as specified for the foundation concrete at the cost of the
contractor. The excavation up to 1.5 m. Depth shall be measured under this item.
5.0 Disposal of the excavated stud:
5.1 The excavated stuff of the selected type shall be used in filling the trenches and plinth or
Leveling the ground in layers including ramming and watering etc.
5.2 The balance of the excavated quantity shall be removed by the contractor from the site
of work to a place as directed with lead up to 50 M. And all lift.
6.0 Mode of measurement and payment:
6.1 The measurement of excavation in trenches for foundation shall be made according to
the sections of trenches shown on the drawing or as per sections given by the Engineer-in-
charge. No payment shall be made for surplus excavation made in excess of above
requirements or due to slopping back as found necessary on account of conditions of soil and
requirements of safety.
6.2 The rate shall be for a unit of one cubic meter.
Item No.04 Providing and laying cement concrete 1:4:8 (1- Cement: 4- coarse sand : 8- hand
broken stone aggregates 40 mm nominal size) and curing complete excluding cost of formwork
in (A) Foundation and Plinth (up to 10 ton)
1.0 Materials:
1.1 Water shall conform to M-1. Cement shall conform to M-3. Sand shall conform to M-6.
Stone aggregate 40 mm. Nominal size shall conform to M-12.
2.0 Workmanship:
2.1 General :
2.1.1 Before starting concrete bed of foundation teaches shall be cleared of all loose materials,
leveled, watered and rammed as directed.
2.2 Proportion of Mix:
2.2.1 The Proportion of cement, sand and coarse aggregate shall be one part of cement, 4
parts of sand, 8 parts of stone aggregates and shall so measured by volume.
2.3 Mixing :
2.3.1 The concrete shall be mixed in a mechanical mixer at the site of work. Hand mixing may
however be allowed for smaller quantity of work if approved by the Engineer-in-charge. When
hand mixing is permitted by the Engineer-in-charge in case of break-down of machineries and
in the interest of the work, it shall be carried out on a water tight platform and care shall be
taken to ensure that mixing is continued until the mass in uniform in color and consistency.
However in such cases 10% more cement than otherwise required shall have to be used
without any extra cost. The mixing in mechanical mixer shall be done for a period 1 to 2
minutes. The quantity of water shall be sufficient to produce a dense concrete of required
workability for the purpose.
2.4 Transporting & Placing the concrete :
2.4.1 The concrete shall be handled from the place of mixing to the final position in not more
than 15 minutes by the method as Directed and shall be placed into its final position,
compacted and finished within 30 minutes of mixing with water i.e. before the setting
commences.
101
2.4.2 The concrete shall be laid in layers of 15 cms. To 20 cms.
2.5 Compacting:
2.5.1 The concrete shall be rammed with heavy iron rammers and rapidly to get the required
compaction and to allow all the interstices to be filled with mortar.
2.6 Curing:
2.6.1 After the final set, the concrete shall be kept continusoly wet, if required by pounding for a
period of not less than 7 days from the date of placement.
3.0 Mode of measurement and payment:
3.1 The concrete shall be measured for its length, breadth and depth, limiting dimensions to
those specified on plans or directed.
3.2 The rate shall be for a unit of one cubic meter.
Item No:05 Providing and laying controlled cement concrete M.250 exposed work with curing
etc. complete including the cost of formwork but excluding the cost of reinforcement for R.C.C.
work in (A) BEAMS , column, footing ,tie beam and top couping &as per the instruction of Site-
in charge Engineer.
1.0 Materials: All materials like cement, sand, aggregate, water, steel is to be used as per
materials relevant specification of detail specification of GOG. Admixture is confirm to the
manufacture specification.
2.0 General:
2.1 The relevant specifications of ordinary concrete shall be followed except that the concrete
mix shall be designed from preliminary tests, the proportioning of cement and aggregates shall
be done by weight and necessary precautions shall be taken in the production to ensure that
the required work cube strength is attained and maintained. The controlled concrete shall be in
grades of M-100, M-150, M-200, M-250, M-300, and M-350 & M-400 with prefix controlled
added to it. The letter ‘M’ refers to mix and numbers specify 28 days works cube compressive
strength. Cubes of the mix expressed in Kg. /Cmt.
2.2 The proportion of cement sand and coarse aggregates shall be determined by weight, the
weight batch machine shall be used for maintaining proper control over the proportion of
aggregates as per mix design. Minimum cement consumption for design mix concrete shall be
considered as M-25 as 400 Kg.
The strength requirements of different grades of concrete shall be as under:
Compressive strength of 15 cms.x 15 cm Cubes
Grade of in Kg./Cmt.at 28 days conducted in accordance Work test Min.
Concrete with I. S. 516-1959. Preliminary test Min.
M-150 200 150
M-200 260 200
M-250 320 250
M-300 380 300
M-350 440 350
M-400 500 400
;In all cases the 28 days compressive strength specified in above table the criteria for
acceptance or rejection of the concrete.
Where the strength of a concrete mix as indicated by tests, line in between the strength of any
two grades specified in the above table, such concrete shall be classified in for all purpose as
concrete belonging to the lower of the two grades between which its strength lies. General:
The water cement ratio shall not more than those specified in Design mix. The cement content
of the mix specified shall be increased if the quantity of water in a mix has to be increased to
overcome the difficulties of placement and compaction so that the water-cement-ratio specified
is not exceeded.
Workability of the concrete shall be controlled by maintaining a water-cement-ratio that is
bound to give a concrete mix which is just sufficiently wet to be placed and compacted without
difficulty with the means available.
102
For reinforced concrete work, coarse aggregates having a nominal size of 20 mm. Are
generally considered satisfactory.
Admixture may be used in concrete only with approval of Engineer-in-charge upon the
evidence that with the passage of time, neither the compressive strength of concrete is
reduced nor are other requisite qualities of concrete and steel impaired by the use of such
admixtures.
Workmanship:
2.3 The proportions for ingredients chosen shall be such that concrete has adequate
workability for conditions prevailing on the work in question and can be properly compacted
with means available except where it can be shown to the satisfaction of the Engineer-in-
charge that the supply of properly graded aggregate of uniform quality can be maintained till
the completion of work. Grading of aggregate shall be controlled by obtaining the coarse
aggregates in different sizes and mixing them in the right proportions as required. Aggregate of
different sizes shall be stocked in separate stockpiles. The required quantity of material shall
be stock piled several hours, preferably a day before use. The grading of coarse and fine
aggregate shall be checked as frequently as possible the frequency for a given job being
determined by the Engineer-in-charge to ensure that the suppliers are maintaining the uniform
grading as approved for samples used in the preliminary tests.
2.4 In proportioning concrete the quantity of both cement and aggregate shall be determined by
weight. Where the weight of cement is determined by accepting the maker’s weight per bag a
reasonable number of bags shall be weighted separately to check the net weight. Where
cement is weighted from bulk stocks at site and not by bags it shall be weighted separately
from the aggregates. Water shall either be measured by volume in calibrated tanks or weighed.
All measuring equipments shall be maintained in clean and serviceable condition. Their
accuracy shall be periodically checked.
It is most important to keep the specified water cement ratio constant and at its correct value.
To this end moisture content in both fine and coarse aggregates shall be
Determined by the Engineer-in-charge according to the weather conditions the amount of
mixing water shall then be adjusted to compensate for variations in the moisture content. For
the determination of moisture content in the aggregates I. S. 2389 (Part-III) shall be referred to
suitable adjustments shall also be made in the weights of aggregates due to variation in their
moisture content.
Mixing:
3.2.1 For all work. Concrete shall be mixed in a mechanical mixer which along with other
accessories shall be kept in first class working condition and so maintained throughout the
construction. Measured quantity of aggregate, sand, cement required for each batch shall be
poured into the drum of the mechanical mixer while it is continuously running. After about half a
minute of dry mixing, measured quantity of water required for each batch of concrete mix shall
be added gradually and mixing continued for another one and a half minute. Mixing shall be
continued till materials are uniformly distributed and uniform color of the entire mass is
obtained and each individual particle of the coarse aggregate shows complete coating of
mortar containing its proportionate amount of cement. In no case shall the mixing be done for
less than 2 minutes after all ingredients have been put into the mixer.
3.2.2 When hand mixing is permitted by the Engineer-in-charge for small jobs or for certain
other reasons, it shall be done on the smooth watertight platform large enough to allow efficient
turning over the ingredients of concrete before and after adding water. Mixing platform shall be
so arranged that no foreign materials get mixed with concrete nor does the mixing water flow
out. Cement in required number of bags shall be placed in a uniform layer on top of the
measured quantity of fine and coarse aggregate, which shall also be spread in a layer of
uniform thickness on the mixing platform. Dry coarse and fine aggregate and cement shall then
be mixed thoroughly by turning over to get a mixture to uniform color. Specified quantity of
water shall then be added gradually through a rose-can and the mass turned over till a mix of
required consistency is obtained. In hand mixing, quantity of cement shall be increased by 10
percent above that specified.
3.2.3 Mixers which have been out of use for more than 30 minutes shall be thoroughly
cleaned before putting in a new batch. Unless otherwise agreed to by the Engineer-in-charge
the first batch of concrete from the mixture shall contain only two thirds of normal quantity of
103
coarse aggregate. Mixing plant shall be thoroughly cleaned before changing from one type of
cement to another.
Item No:06 Providing TMT Bar FE 500/500D reinforcement for R.C.C. work including bending,
binding and placing in position complete up to floor two level (up to 10 ton), as per the
instruction of Site-in charge Engineer.
Item No: 07 Brick work using common burnt clay building bricks having crushing strength not
less than 50kg./Sq.cm in foundation and plinth in Cement Mortar 1:5. (1- Cement: 5 -fine
sand)(C) Fly Ash Bricks (more than 10 tan)+ extra for brick in superstructure above plinth level
up to floor two level a) fly Ash Brick
1.0 Materials:
Water shall confirm to M-1,Cement shall confirm to M-3, Sand shall confirm to M-6,.
Admixture is confirm to the manufacture specification
2.0 Workmanship :
Fly ash bricks (cement bonded) shall be locally made. Bricks shall have smooth
rectangular faces with sharp and square corners. Bricks shall be hand or machine moulded
and shall be made from the admixture of suitable good quality of fly ash, sand and cement as
per the composition mentioned below:
FLY ASH: 50-60%
SAND: 32-40%
CEMENT: 8-12%
The fly ash bricks will be as per latest relevant IS code. The bricks will be of dimension
as per standard clay brick, suitable for making 230mm thick full brick wall, 115mm thick half
brick wall and 75mm thick minor partition walls, as applicable, as per
drawing/specification/BOQ. A maximum tolerance of (+/-) 2mm shall be allowed as the
manufacturing tolerance. The bricks shall have frog of 100 mm in length 40 mm in width and 10
to 20 mm deep of one of its flat sides.
The bricks when tested in accordance with the procedure laid down in IS 3495 (part 2):
1992 after immersion in cold water for 24 hrs. water absorption shall be within 13-15% by
weight. Similarly, the porosity of the fly ash bricks shall be within 12-20%. The bricks shall have
a minimum crushing strength of 50 Kg/CmSq. Bricks shall be tested in a Govt. Approved
laboratory at the cost of contractor. Bricks shall be allowed to use after satisfactory result.
Mortar that can be utilized within initial setting time of the cement shall be mixed with water.
Mortar shall be prepared on pucca platform or on steel plate’s platform. Mortar shall be
uniformly mixed dry and then required quantity of water shall be added. If work demands
mixing or mortar in mixture, same shall have to be arranged without any extra cost
All joints vertical and horizontal shall be properly racked out to a depth of 12mm when
mortar is green and soft. The exposed faces of walls are to be provided with flush joint.
Brickwork shall be cured with water for a period of 10 days, keeping constantly moist. During
rainy season green work shall have to be protected from rain, by covering it with suitable
covering.
Work shall be measured in volume any opening more than 0.5 sq. Meter areas shall be
deducted. No payment shall be made for keeping in masonry any pipe, and sleeves etc.,
supplied by department. Thickness of brickwork shall be paid as per standard practice half
brick, full brick, 1 ½ bricks etc. as shown on drawings.
2.1 Proportion :
2.1.1 The proportion of the cement mortar shall be 1: 5(1 cement: 5 fine sand) by volume.
104
2.2 Wetting of bricks: The bricks required for masonry shall be thoroughly wetted with clean
water for about two hours before use or as directed. The cessation of bubbles, when the bricks
are wetted with water is an indication of through wetting of bricks.
2.3 Laying :
2.3.1 Bricks shall be laid in English bond unless directed otherwise. Half or cut bricks shall not
be used except where necessary to complete to bond closers in such case shall be cut to
required size and used near the ends of walls.
2.3.2 A layer of mortar shall be spread on full width for suitable length of the lower course,
each brick shall first be properly bedded and set home by gently tapping lapping with handle of
trowel or wooden mallet. It side face shall be flushed with mortar before the next brick is laid
and pressed against it. On completion of course, the vertical joints shall be fully filled from the
top with mortar.
2.3.3 The walls shall be taken up truly in plumb. All courses shall be laid truly horizontal and
all vertical joint shall be truly vertical. Vertical joints in alternate course shall generally be
directly one over the other. The thickness of brick course shall be kept uniform.
2.3.4 The brick shall be laid with frog upwards. A set of tools comprising of wooden straight
edges, mason’s sprit level, square half meter rub, and pins, string and plumb, shall be kept on
the site of work for frequent checking during the progress of work.
2.3.5 Both the faces of walls of thickness greater than 23 cms. Shall be kept in proper place.
All the connected brick work shall be kept not more than one meter over the rest of the work.
Where this is not possible the work shall be raked back according to bond (and not left toothed)
at an angle not steeper than 45 degrees.
2.3.6 All fixtures, pipes, outlets of water, hold fasts of doors and windows etc. Which are
required to be built in wall shall be embedded in cement mortar.
2.4 Joints:
2.4.1 Bricks shall be so laid that all joints are quite flush with mortar. Thickness of joints shall
not exceed 12 mm. The face joints shall be raked out as directed by taking tools daily during
the progress of work, when the mortar is still green so as to provide key for plaster or pointing
to done.
2.4.2 The face of brick shall be cleaned the very day on which the brick work is laid and all
mortar dropping removed.
2.5 Curing: Green work shall be protected from rain suitably. Masonry work shall be kept moist
on all the faces for a period of seven days. The top of masonry work shall be kept well wetted
at the close of the day.
2.6 Preparation of foundation bed: If the foundation is to be laid directly on the excavated
bed the bed shall be leveled, cleared of all loose materials, cleaned and wetted before starting
masonry. If masonry is to be laid on concrete footing the top of concrete shall be cleaned and
moistened. The contractor shall obtain the engineer’s approval for the foundation bed, before
foundation masonry is started. When puccas flooring is to be provided flush with the top to
plinth the inside plinth offset shall be kept lower than the outside plinth top by the thickness of
the flooring.
3.1 Mode of measurement and payment:-
3.1.1 Measurement shall be made per CMT of Brickwork at site.
3.1.2 Rate shall be for unit of one CMT of Brickwork at site.
Item No:08 Providing 20mm thick cement plaster in single coat on single or half brick walls for
interior plastering up to floor two level and finished even and smooth in (i) Cement mortar 1:3
(1-cement:3-sand)
1.0. Materials: 1.1. Water M-1. The cement mortar proportion 1:3 shall conform to M-13.
2.0. Workmanship :
2.1. Scaffolding: Wooden ballics, bamboos, planks, treatles and other scaffolding shall be
sound. These shall be properly examined before erection and use. Stage scaffolding shall be
provided for ceiling plaster which shall be independent of the walls.
2.2. Preparation of back-ground:
2.2.1. The surface shall be cleaned of all dust, loose mortar droppings, traces of algae,
efflorescence and other foreign matter by water or by brushing. Smooth surface shall be
roughened by wire brushing if it is not hard and by racking if it is hard. In case of concrete
105
surface, if a chemical retarder has been applied to the form work, the surface shall be
roughened by wire brushing and all the resulting dust and loose particles cleaned off and care
shall be taken that none of the retarders is left on the surface. Trimming of projections on
brick/concrete surface where necessary shall be carried out to get an even surface.
2.2.2. Racking of joints in case of mansonry where necessary shall be allowed to dry out for
sufficient period before carrying out the plaster work.
2.2.3. The work shall not be soaked but only damped evenly before applying the plaster. If the
surface becomes dry such area shall be moistened again.
2.2.4. For external plaster, the plastering operation shall be started from top floor and carried
downwards. For internal plaster, the plastering operations may be started whenever the
building frame and cladding work are ready and the temporary supporting ceiling resting on the
wall of the floor have been removed. Ceiling plaster shall be completed before starting plaster
to walls.
2.3. Applications of plaster :
2.3.1. The plaster about 15 x 15 cms. Shall be first applied horizontally and vertically at not
more than 2 metres intervals over the entire surface to serve as gauge. The surfaces of these
gauges shall be truly inplane of the finished plastered surface. The mortar shall then be
applied in uniform surface slightly more than the specified thickness, then brought to a true
surface by working a wooden straight edge reaching across the gauges with small upward and
sideways movement at a time. Finally, the surface shall be finished off true with a trowel or
wooden float according as a smooth or a sandy granular texture is required. Excessive
trowelling or overworking the float shall be avoided. All corners, arrises, angles and junctions
be truly vertical or horizontal as the case may be and shall be carefully finished. Rounding or
chamfering corners, arrises junctions etc. Shall be carried out with proper templates to the size
required.
2.3.2. Cement plaster shall be used within half an hour after addition of water. Any mortar or
plaster which is partially set shall be rejected and removed forthwith from the size.
2.3.3. In suspending the work at the end of the day, the plaster shall be left out clean to the line
both horizontally and vertically. When recommending the plaster, the edges of the old work
shall be scraped clean and wetted with cement putty before plaster is applied to the adjacent
areas to enable the two to properly join together. Plastering work shall be closed at the end of
the day on the body of the wall and nearer than 15 cm. To any corners or arrises. Horizontal
joints in plaster work shall not also occur on parapet tops and copings as these invariably load
to leakage. No portion of the surface shall be left out initially to be packed up later on.
2.3.4. Each coat shall be kept damp continuously till the next coat is applied or for a minimum
period of 7 days. Moistening shall commence as soon as plaster is hardened sufficiently.
Soaking of walls shall be avoided and only as much water as can be readily absorbed shall be
used, excessive evaporation on the sunny or windward side of building in hot air or dry
weather shall be prevented by handing mattings or gunny bags on the outside of the plaster
and keeping them wet.
3.0. Mode of measurements & payment :
3.1. The rate shall include the cost of all materials, labour and scaffolding etc. Involved in the
operations described under workmanship.
3.2. All plastering shall be measured in square meters unless, otherwise specified, Length,
breath or height shall be measured correct to a centimeter.
3.3. Thickness of the plaster shall be exclusive of the thickness of the key i.e. Grooves or open
joints in brick work, stone work etc. Or space between laths. Thickness of plaster shall be
average thickness with minimum 10 mm. At any point on this surface.
3.4. This item includes plastering upto floor two level.
3.5. The measurement of wall plastering shall be taken between the walls or partition
(dimensions before plastering being taken) for length and from the top of floor or skirting to
ceiling for height. Depth of cover of cornices if any shall be deducted.
3.6. Soffits of stairs shall be measured as plastering on ceilings. Flowing soffits shall be
measured separately.
3.7. For jambs, soffits, sills etc. For openings not exceeding 0.5 sq.mt. Each in area for ends of
joints, beams, posts, girders, steps, etc. Not exceeding 0.5 sq. Mt. Each in area and for
106
openings exceeding 0.5 sq. Mt. And not exceeding 3.00 sq. Mt. In each area deductions and
additions shall be made in the following manner:
(a) No deductions shall be made for ends of joints, beams, posts etc. And openings not
exceeding 0.5 sq.mt. Each and no addition shall be made for reveals, jambs, soffits, sills etc.
Of these opening for finish to plaster around ends of joints, beams, posts etc.
(b) Deduction for openings exceeding 0.5 sq.mt. But not exceeding 3 sq.mt. Each shall be
made as follows and no addition shall be made for reveals, jambs, soffits, sills etc. Of these
openings.
(i) When both faces of all wall are plastered with same plaster, deduction shall be made for
one face only.
(ii) When two faces of wall are plastered with different types of plaster or if one faces is
plastered and the other pointed, deductions shall be made from the plaster or pointing on the
side of frame for door, window etc. On which width of reveals is less than that on the other side
but no deductions shall be made on the outer side. Where width of reveals on both faces of all
are equal, deductions of 50% of area of opening on each face shall be made from area of
plaster and/or pointing as the case may be.
3.8. For openings having door frames equal to projecting beyond the thickness of wall, full
deduction for opening shall be made from each plastered face of the wall.
3.9. In case of openings of area above 3 sq.mt. Each, deduction shall be made for opening but
jambs, soffits and sills shall be measured.
3.10. The rate shall be for a unit of one sq.mt.
Item No: 09 Providing & laying 8''(100mm) dia. pvc pipe higher of approved make .fixing in
under wall .both side of wall 1.5 rmt etc. as per the instruction of Site-in charge Engineer.
All the materials shall get approved. Work is to be carried out as per manufacture’s
specification.
Mode of measurements & payment:-
The rate includes cost of all labor, materials, tools and plant etc. Required for satisfactory
completion of this item.
Payment shall be made per Running Meter fixed with necessary fixtures.
Item No:10 Providing and applying one coat of water based exterior primer of approved brand
and make as mentioned below on wall surfaces after thoroughly brushing the surface free from
mortar droppings and other foreign matter. Item includes making the surface even and smooth
by sand papers. Rates are inclusive of all the material and laborers and scaffolding work,
cleaning of the floors etc. required for the work. (Basic rate including taxes per litre Rs. 105.00)
-
1. Asian Paint : Exterior Wall Primer
2. Nerolac Paint : Nerolac Exterior Primer
3. ICI Dulux (Akzo Nobel) : Weather guard Acrylic Primer
4 .Berger Paint : Berger BP weather coat Exterior Wall Primer
Item NO: 11 providing & applying two coats of exterior premium emulsion paint (excluding
priming coat) of approved brand and make as mentioned below on existing plastered surface
including finishing & thinning as per manufacturer’s specifications. A gap of 6 hrs. Should be
given between 2 subsequent coats. The work should be carried out strictly as per
manufacturer’s specifications and requirement including scaffolding, jhoolas etc., complete as
directed by E.I.C.
(Basic rate including taxes per litre Rs.280.00)
1.Asian Paint :Apex Ultima
2.Nerolac Paint: Excel Total
107
3. ICI Dulux (Akzo Nobel) : Weathersheild Max
4. Berger Paint : Weather Coat Allguard
Item No: 12 Providing and fixing Y angle fencing with (size of .45mmx.45mmx.6mm=1.5m total
length) Y angle M.S. Angle posts 50 mm. X 50 mm. X 5 mm. And oil painting 3 coats fixed at
3mt. C/c including fixing posts in wall column etc. complete.as per the instruction of Site-in
charge Engineer
Mode of Measurement
The rate shall be for a unit of running meter.
Item no:13 Providing and fixing in position spiral turns 55/56 in each 9 Mtr. Of recommended
stretched(laid) length & 610mm effective dia (after laying) hot deep galvanized cross spire type
razor tape concertina coil wire using a central core wire high carbon spring steel(high tensile
wire) made up of 2.6mm dia as per IS:4454,part-1, grade-II having minimum galvanizing of
230-250 GMS per mm2. Around which a tape of razor sharp barbs strip of 0.5mm thick &
19mm width conforming to IS: 513 DD quality having minimum galvanizing coating of
12microns with series of barbs punched along the length at regular interval.(approximately 160
barbs per running meter of concertina coil is machine crimped with 4 to 5 no of clips per each
spire made up of steel(SS304).including fixing of concertina coil on 3 runs of support fixed
through out the compound wall with the help of required U-nails/split pin, scaffolding etc.
Completed as per detailed specification & as directed by engineer in charge, Rates are
inclusive of 3 Nos of runs of support of RBT (Razor barbed tape) made of 2.6 MM dia. As per
IS:4454 Part-I, grade-II having minimum galvanizing of 230-250 GMS per Sqmm fixed on angle
support of compound wall with the help U-nails/split pin including scaffolding etc. completed as
directed by engineer in charge
1.0 Materials:
1.1. Contractor shall use concertina wire as per general description of item with detail
specification as under.
TETCHNICAL DETAIlS OF CONCERTINA COILS
1.1.
1.2. Contractor shall use support of RBT (Razor barbed tape) made of 2.6 mm dia as per IS:
4454, Part-1, Grade-II having minimum galvanizing of 230-250 GMS per SQMM.
1.3. Contractor shall use GI U-NAILS / SPLIT PIN.
1.4 Support of RBT shall be got approved before collecting on site. It shall be bright, galvanized
and confirming to I. S. Specifications.
1.5 Support shall be fixed in 4 rows fixed with G.I. U-NAILS / SPLIT PIN in case of M.S. Angle
posts & at every @ 50 meter interval each row of support shall be locked after stretching.
Fixing shall be done as directed.
1.6 Care shall be taken to see that the labours engaged on job are not injured during fixing of
support of RBT.
1.7 Contractor shall be used full length of support not less then 50 meter.
1.8 The work shall be carried out over the boundary wall, at all heights inclusive required all
materials, labours, tools & tackles.
2.0 Workmanship:
2.1. Razor tape concertina coil shall be got approved before collecting on site.
2.2. Effective dia. of Razor tape concertina coil after recommended stretched length shall be
610 mm.
2.3. Numbers of spiral turns & nos of clips shall be 72+/-3 & 180 respectively per
recommended stretched length.
2.4. Series of sharp barbs shall be at uniform intervals. (Approximately 160 barbs per running
meter of Razor tape concertina coil.
2.5. Minimum 5 clips shall be fixing per spiral turns.
2.6. The razor strip shall be mounted on the central core wire by mechanical crimping.
2.7. Razor tape concertina coil shall be fixed in position on the 3 Nos of support lying angle
to angle by means of clips. Care shall be taken to see that the labours engaged on job
are not injured during fixing of coil.
2.8. The work shall be carried out over the boundary wall, at all heights inclusive required all
materials, labours, tools & tackles.
2.9. Support of RBT shall be got approved before collecting on site. It shall be bright,
galvanized and confirming to I. S. Specifications.
2.10. Support shall be fixed in 4 rows fixed with G.I. U-NAILS / SPLIT PIN in case of M.S.
Angle posts & at every @ 50 meter interval each row of support shall be locked after
stretching. Fixing shall be done as directed.
2.11. Care shall be taken to see that the labours engaged on job are not injured during fixing
of support of RBT.
2.12. Contractor shall be used full length of support not less then 50 meter.
2.13. The work shall be carried out over the boundary wall, at all heights inclusive required all
materials, labours, tools & tackles.
109
3.0 Mode of measurement & payment:
3.1. The rate shall be for a one running meter of actual work done.
Note: - Please refer general specification of PWD (R & B) GOG and contractors are bound
to work accordingly.
110
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station. At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar. Pin: 364050.
Ph: 0278-2931375, FAX: 0278-2931175, e-mail: [email protected], Website: www.gsecl.in
CIN: U40100GJ1993SGC019988.
SECTION –H
SCHEDULE-B
111
GUJARAT STATE ELECTRICITY CORPORATION LIMITED
Bhavnagar Lignite Thermal Power Station, At & PO: Padva, Ta: Ghogha, Dist: Bhavnagar – 364050.
Ph. 0278-2931375 / 0278-2931175 e-mail: [email protected] Website: www.gsecl.in
CIN: U40100GJ1993SGC019988
SCHEDULE - B
NAME OF WORK : Construction of collapsed/Tilted compound wall of P.H.
due to Tauktae Cyclone at BLTPS.
Part -A(Pile Foundation)
113
10 Providing and applying one coat of water
based exterior primer of approved brand
and make as mentioned below on wall
surfaces after thoroughly brushing the
surface free from mortar droppings and
other foreign matter. Item includes
making the surface even and smooth by
sand papers. Rates are inclusive of all
the material and laborers and scaffolding
work, cleaning of the floors etc. required SQM 9250.00 29.00 268250.000
for the work. (Basic rate including taxes
per litre Rs. 105.00) -
1. Asian Paint : Exterior Wall Primer
2. Nerolac Paint : Nerolac Exterior Primer
3. ICI Dulux (Akzo Nobel) : Weather
guard Acrylic Primer
4 .Berger Paint : Berger BP weather coat
Exterior Wall Primer
114
13 Providing and fixing in position spiral turns 55/56
in each 9 Mtr. Of recommended stretched(laid)
length & 610mm effective dia (after laying) hot
deep galvanized cross spire type razor tape
concertina coil wire using a central core wire high
carbon spring steel(high tensile wire) made up of
2.6mm dia as per IS:4454,part-1, grade-II having
minimum galvanizing of 230-250 GMS per mm2.
Around which a tape of razor sharp barbs strip of
0.5mm thick & 19mm width conforming to IS: 513
DD quality having minimum galvanizing coating
of 12microns with series of barbs punched along
the length at regular interval.(approximately 160
barbs per running meter of concertina coil is
machine crimped with 4 to 5 no of clips per each
RMT 1500 243.67 365506.5
spire made up of steel(SS304).including fixing of
concertina coil on 3 runs of support fixed through
out the compound wall with the help of required
U-nails/split pin, scaffolding etc. Completed as
per detailed specification & as directed by
engineer in charge, Rates are inclusive of 3 Nos
of runs of support of RBT (Razor barbed tape)
made of 2.6 MM dia. As per IS:4454 Part-I,
grade-II having minimum galvanizing of 230-250
GMS per Sqmm fixed on angle support of
compound wall with the help U-nails/split pin
including scaffolding etc. completed as directed
by engineer in charge
Total amount B 7475541.10
Net Estimate Amount In Rs 8665678.50
NOTE:
(1). Bill / Invoice are required as per GST rules of Government.
(2). Payment will be made after work to be carried out satisfactory by agency and as per
actual work done only.
(3). The quantity shown is approximately. No claim shall be entertained on account of non-
operation/part operation of above items.
(4). The entire work shall be executed as per detail Technical specification of Items, scope
of work.
(5). GST will be applicable as per Govt. Notification. It will be paid extra.
(6). Payment will be made within 30 days after recording of bill.
(7). All royalties, Sales tax, Toll tax, Local tax, development charges, VAT tax, & any other
including work contract tax etc. in respect of this contract & also any statutory variation
in future towards above mentioned taxes & any other taxes if levied in future by statutory
authority applicable to the this contract shall be payable by the contractor & GSECL will
not entertain any claim what so ever in this respect.
(8). TDS (as per GST rules) will be deducted from your bills w.e.f. 01.10.2018 as per
government rules.
(9). The rates of all above items are for any heights to carry out the various works at
different elevation or location irrespectively of quantum of work.
(10). In case of any dispute the decision of the undersigned will be final & binding to the
contractor.
(11). Agency has to provide following documents pertain to BLTPS along with each RA bills in
triplicate for verification of compliance of Labour laws:-
* Attendance register
* Duly paid wage Register (if paid through Bank then along with Bank Statement or Bank
name and A/c no. of concern employee is required to mention in the register or
115
disbursed in present of GSECL officer & certification of GSECL officer in wage register
is required to taken).
* Copy of Paid PF Challan along with copy of ECR.
* Bonus and Leave encashment register as per applicability.
____________________________________________________________ % Lower
than Estimated Cost for Sr. No: 1 & 2 (% should be written in Figure as well as in Words.)
116