156078917O-1547497444-Proforma of The Allotment Letter and Agreement For Sale
156078917O-1547497444-Proforma of The Allotment Letter and Agreement For Sale
156078917O-1547497444-Proforma of The Allotment Letter and Agreement For Sale
AGREEMENT
BETWEEN
AND
1) MR./MRS./SMT. ..............................................
age about __ years, Occupation .......................
(PAN : ___________)
2) MR./MRS./SMT. ..............................................
age about __ years, Occupation ............
(PAN : ___________)
Both Residing at _______________________________
______________________________________________
WHEREAS
(A) All that piece and parcel of the property bearing Sub Plot No. 69 out of Final
Plot No. 548, corresponding to City Survey No. 1187/69/1, admeasuring 834 sq.mtr.
situated at village Bhamburda (Shivajinagar) of City of Pune, Tal. Pune City, Dist.
Pune within the limits of Pune Municipal Corporation, Pune, which is more
particularly described in the SCHEDULE - I written hereunder and hereinafter
referred to as the SAID PROPERTY / SAID LAND is owned and possessed by the
Promoters. The Promoters purchased the said property from its erstwhile owner viz.
Chandan Ventures by Sale Deed dated 9/7/2010 and same document is registered
at Sr.No. 6820 on even date in the office of Sub Registrar, Haveli No. 11, Pune and
the Promoters have become the Owners and Possessors of the said property. The
Title and Rights of the Developer to the said property are detailed in the Note on Title
annexed hereto and marked as ANNEXURE “A” annexed hereto and is to be read
as a part and parcel of these presents.
(B) The said Property was constructed one even prior to 17-2-1976 i.e. before the
commencement of Urban Land (Ceiling and Regulation) Act, 1976. The previous
Owner was not under obligation to file any returns under the said Act. The Promoters
herein purchased the said Property after the abolition of Urban Land (Ceiling and
Regulations) Act, and as such there is no impediment of the said Act or its provisions
to the present transactions.
(C) The Promoter herein had obtained from Pune Municipal Corporation, Pune
sanction to the building plans of the building which is under construction on the said
land vide Commencement Certificate No. CC/0697/17 dated 13/06/2017.
(D) The Developer has obtained registration from the Real Estate Regularity
Authority vide Registration No. ____________. The Developer has provided all the
documents mentioned in Sec. 4 (2) of the Real Estate (Regulation and Development)
Act to the said authority along with its application for registration. The Developer has
also submitted his declaration under Sec. 4 (2) (l) to the said authority. The
Developer has opened a separate Bank Account in the __________ Bank for the
deposit of the 70% of the consideration under these presents. The Developer shall
abide by its declaration and the provisions of the said Act. The Developer has
created a web page on the web site of the said authority and has entered all details
of the proposed project as provided under Sub Sec. (2) of Sec. 4 of the Real Estate
(Regulation and Development) Act which is available for public viewing.
3
(E) The Developer has completed all the legal formalities with respect to the
right, title and interest in respect of the said property on which the said project is to
be constructed. The Developer has further disclosed to the Purchaser that the
Developer shall have right to change, amend and revise the sanctioned layout plans,
construction plans and the Purchaser shall not withhold his consent without any
reasonable objection. The Developer has annexed the sanctioned layout plan to this
Agreement as an Annexure F. Without disturbing the area and the location of the
said unit, the Developer shall have right to change, amend and revised the said
layout plan, the construction plans and got the same sanctioned and the Purchaser/s
shall not withhold his / her / their consent for the same.
(F) The Developer has disclosed to the Purchaser/s that the Promoter is
constructing multi storied building consisting many commercial/ residential
tenements on the said property. The Promoters herein has decided to form an
Association of Apartments under name and style “SAI SQUARE APARTMENTS /
SAI SQUARE CONDOMINIUM” of all Accommodations holders in the said building
which is under construction on the said property and adjacent properties. Whenever
the additional FSI in future in the form of either paid FSI, premium FSI, amenity
handover FSI, TDR and/or due to amalgamation of adjoining land, Then the
additional FSI/TDR is sanctioned by local authority to be used in the project the
Developer has applied / shall be applying for revision to consume the available FSI
as well as the paid and premium FSI and thereafter the Developer shall get sanction
of additional floors and units. The Developer through this Agreement is giving the
Purchaser full knowledge that after receiving the revised sanction, if required, the
project and the building size may be increased. The Developer has given the
Purchaser/s full knowledge about the same and the Purchaser/s shall issue a No
Objection Certificate / Consent Deed for the additional construction, if any, in case of
the revision of the sanctioned plan.
(G) As a result of the aforesaid, the Developer herein alone is entitled to develop
and construct buildings on the said property and have exclusive right to sell, lease,
mortgage etc. the, shops, commercial units, flats, tenements, car parkings, adjoining
terraces, reserved/restricted areas, garden area, garage/outhouse, etc. in the
building/s which are under construction or to be constructed on the said property by
the Developer and to enter into agreements with the Purchasers, Mortgages,
Lessees, etc. and receive sale price/consideration and deposit and other charges in
respect thereof.
(H) The Developer have already initiated steps to acquire additional land
adjoining the said property and the said additionally acquired land shall be
amalgamated into the said property for effectual development of the said property
and successful completion of the said project being developed by the Developer to
4
be known as “SAI SQUARE”. The Developer reserves his absolute right to develop
all other adjoining lands which may be taken for development or which are already
been developed by the Developer, however for the integrity of the project the layout
of the buildings have been prepared on the said property together with the intended
land to be taken for development and common areas & amenities agreed to be
provided herein shall be for the entire project on the said property and all other
adjoining lands taken for development by the Developer to be collectively known as
“SAI SQUARE”. The Developer also reserve his right to amalgamate the said
property and all other adjoining lands that may be acquired for development and also
to utilise all the benefits arising there from either jointly or solely on any of the said
property or the newly acquired lands.
(I) The Developer herein has appointed Architect M/s. VOW5 Vinay Wakalkar
having office at Office at 501, Saiket Apartment, Prabhat Road, Lane No. 15, Opp.
Symbiosis School, Pune 411 004 as its Architect and Spectrum Consultants, having
office at 759/25, behind Goodluck Hotel, Bhandarkar Road, Deccan Pune 411004,
as its Structural Engineer for the preparation of the drawings and structural design of
the building which is under construction on the said property. The Developer herein
has reserved right to change aforesaid Architects and Engineers before the
completion of the building/s
(J) The Developer has accordingly commenced work of the said building to be
known as “SAI SQUARE” on the said property.
(K) The copy of the Certificate of Title issued by the Advocate of the Developer
is annexed hereto as “ANNEXURE A”, floor plans of the unit/s agreed to be
purchased by the Unit Purchaser approved by the Pune Municipal Corporation is
annexed hereto as “ANNEXURE B”, Commencement Certificate issued by Pune
Municipal Corporation is annexed hereto as "ANNEXURE C", Details of the said
accommodation are mentioned in SCHEDULE II, Common Areas of the said
accommodation and common amenities are mentioned in SCHEDULE III, the
specifications of the said accommodation are mentioned in SCHEDULE IV, Property
Card extract of said property showing the title of the Owner and Developer is
annexed hereto as “ANNEXURE D”, the consent letter of the Purchaser is annexed
hereto as “ANNEXURE E”, The sanctioned layout plan of the said property is
annexed hereto as 'ANNEXURE 'F'. Any other relevant revenue records showing the
nature of the title of the Developer to the said property, on which the units are
constructed, are separately shown to the Purchasers.
(L) For development of the said property, the Consenting Party has not taken
any financial assistance from any financial institution and the said Property is free
from encumbrances.
5
(M) The Purchaser/s herein demanded from the Developer and the Developer
has given inspection to the Purchaser/s and has also provided the Purchaser/s with
one set of all the documents relating to the said property and the plans, designs and
specifications prepared by the Architect of the Developer and such other documents
as are specified under the Maharashtra Ownership Flats (Regulation of the
Promotion of Construction, Sale, Management and Transfer) Act, 1963 and The
Provisions of The Real Estate (Regulation and Development) Act, 2016 (hereinafter
referred to as “the said Acts”) and rules made thereunder.
(N) After the Purchaser‟s inquiry, the Developer herein has requested the
Purchaser/s to carryout independent search by appointing his/her their own
Advocate and to ask any queries, he/she/they has/have regarding the marketable
title and nature of the title and rights of the Developer. The Purchaser/s has/have
satisfied himself/herself/themselves in respect of the marketable title and rights of the
Developer herein and therefore has/have approached the Developer for allotment
and have agreed to purchase the shop / commercial premises / Unit / tenement / car
parking more particularly described in the SCHEDULE II hereunder written and
delineated in red color boundary line on the Annexure “B” annexed hereto
(hereinafter referred to or called as “THE SAID ACCOMMODATION / UNIT”).
(O) The Developer herein has agreed to provide Specifications & amenities in the
said unit, which are more particularly described in the “SCHEDULE IV” hereunder
written.
(P) The Purchaser/s herein is/are aware of the fact that the Developer herein
have entered or will enter into similar or separate agreements/s with several other
person/s and party/ies in respect of other shop/s, commercial premise/s
Flat/Shop/Office/s, adjacent terrace/s, garage/s, office unit/s, tenement/s, basement,
car parking/s under the stilt and land adjacent to the building/s.
(Q) Relying upon the said offer and subject to whatever stated herein the
Developer have agreed to sell to the Purchaser/s the said Accommodation/Unit at
the price and on the terms and conditions herein appearing.
(R) This agreement does not preclude, diminish the rights of any financial
institutions, fund, registered money lender for which finance has been taken for the
project and the same can be claimed by them under the statutory claims and that this
does not in any way affect the right of the allotted in respect of his unit in the said
project.
6
The above mentioned price is a unit price which is escalation-free, save and except
increases which the Unit Purchaser/s hereby agree/s to pay, due to increase on
account of development charges payable to the competent authority and/or any other
increase in charges which may be levied or imposed by the competent authority from
time to time. The Developer undertakes and agrees that while raising a demand on
the Unit Purchaser/s for increase in development charges, cost/charges imposed by
the competent authorities, the Developer shall enclose the said
notification/order/rule/regulation to that effect along with the demand letter being
issued to the Unit Purchaser/s, which shall only be applicable on subsequent
payments. The Developer may charge the Unit Purchaser/s separately for any up
gradation/ changes specifically requested or approved by the Unit Purchaser/s in
fittings, fixtures and specifications and any other facility which have been done on
the Unit Purchaser/s request or approval but which have not been agreed upon
herein or as shown in the website of the registered authority and the area mentioned
is for the purpose of paying Stamp Duty as prescribed by the registration authorities
and this is not a Sq. Ft. deal but a package deal and on the terms and conditions
hereinafter appearing. It excludes the amount of stamp duty, registration charges,
amount of G.S.T. and Legal Charges and amount of maintenance, as applicable
which shall be paid by the Purchaser/s to Developer as and when asked for. The
Developer and the Unit Purchaser/s agreed not to question or challenge the said
consideration since the same having been settled on lump sum basis considering all
aspects and other terms of the agreement. The present Agreement is not a
construction agreement or works contract of service contract and the Property in the
said building as well as in the said unit would vest only with the Developer and would
pass on to the Unit Purchaser/s only on the execution of the Conveyance Deed or
Deed of Apartment. Despite the said legal position, if any taxes are levied on the
present agreement then the Unit Purchaser/s shall be liable to pay the same.
The Unit Purchaser/s has/have agreed to pay the GST by separate payments to the
Developer. It is also agreed between the parties hereto that, the Unit Purchaser/s
herein shall bear and pay the amount of GST as applicable on every installment of
payment of consideration.If at any time, after execution of this agreement, the
increase in GST under respective statue by the central and state government
respectively and further at any time before or after execution of this agreement any
8
additional taxes/ duty/ charges/ premium/ cess/ surcharge etc., by whatever name
called, is levied or recovered or becomes payable under any statue/rule /regulation
notification order/either by the Central or the State Government or by the local
authority or by any revenue or other authority, in respect of the said property or the
said accommodation/unit or this agreement or the transaction herein, shall
exclusively be paid/borne by the Purchaser/s. The Purchaser/s hereby, always
indemnifies the Developer from all such levies, cost and consequences. The agreed
consideration of the said unit / accommodation has been fixed by the parties hereto
by considering the set off of GST as may be applicable from time to time and the
Developer has already passed on the benefit of set off of GST to the Unit
Purchaser/s by way of reduction/discount. It is therefore agreed between the parties
hereto that the Developer shall be entitled to get the set off / credit of the GST paid
on these presents and the Unit Purchaser/s shall not have any claim over the same.
The Developer shall intimate the Unit Purchasers about the imposition of any other
taxes that may be levied due to construction of the present Agreement or by any
amendment to any of the tax laws by the Government. The Unit Purchaser shall pay
the said tax to the Developer within 7 days from the date of intimation. If the Unit
Purchaser/s fail/s to pay the said tax within the stipulated period then there shall
remain a lien or charge of the said arrears on the said unit in favour of the Developer
and the Developer shall be entitled to recover the same from the Unit Purchaser/s
with interest thereon.
3 PAYMENT IN INSTALLMENTS:-
The Purchaser/s herein is well aware that construction of the Building on the said
property is in progress and considering this aspect the Purchaser/s has/have agreed
to pay the aforesaid agreed consideration to the Developer s herein the following
manner
Sr. No. % Amount in Rs. Particulars
1. 10 Before signing the Agreement
2. Not exceeding Paid by the Unit Purchaser/s to the
30 % Developer on signing the Agreement
by way of Cheque bearing No.
________ dated __________ drawn
on ___________ Bank, _________
Branch.
3. Amount Not Within 8 days from the
more than 45 % Commencement of PLINTH WORK
of transaction of the building in which said
price accommodation is situated i.e. on or
before _______.
9
The Developer shall have a first charge/ lien on the said Unit to the extent of all
amounts receivable by the Developer from the Purchaser/s under the terms hereof.
It is hereby clarified that the Developer shall be at liberty to vary the chronological
order of the various stages of construction/ Items of Work of the said Building in
which the said Unit is housed and of the said Unit itself and the Developer shall also
be at liberty to simultaneously undertake two or more stages of construction/ Items of
Work set out hereinabove in the table and to demand from the Purchaser/s the
aggregate of the installments towards the agreed consideration amount mentioned
hereinabove in the table to be paid as per the stages of construction/Items of Work.
The Purchaser/s shall pay the aforesaid amount of consideration on due date without
any intimation from the Developer and in case the Developer gives the written
intimation to the Purchaser/s calling upon the Purchaser/s to make the payment then
the Purchaser/s shall pay the aforesaid amount within 07 days from the receipt of
intimation. Payment is the essence of contract. The Purchaser/s shall make payment
of all installments towards the agreed consideration amount to the Developer by
Demand Draft or by local Cheques. If the Purchaser/s makes payment of any of such
installments by way of Out-station Cheques, then in such event, the date of payment
of the amount represented by such Cheques shall be the date when such amount is
credited in the account of the Developer after deducting there from the amount of
commission charged for clearance of any such Cheques by the Bank to the
Developer. The Unit Purchaser/s shall issue cheques / D.D.s for the each of the
installments and after the realizations of the said Cheques / D.D.s, the Developer
shall instruct his bankers to bifurcate such amounts in the proportion of 70:30 and
the 70% amount shall be transferred to the separate account as per the provisions of
RERA. The Developer shall deposit the 70 % of each of the above mentioned
installments against the said consideration received from the Unit Purchaser / s in
the separate Bank Account as mentioned hereinabove and shall provide certificates
from Engineer, Architect and the Chartered Accountant at the time of withdrawal of
the amounts as per the RERA. The remaining 30% of the amount shall be deposited
by the Developer in his own account. The said total amount of consideration is
11
5. UTILIZATION F.S.I: -
The Developer has shown the sanctioned plan to the Unit Purchaser which shows
the Floor Space Index (FSI) presently available & unutilized F.S.I in respect to the
said property. The Developer hereby declares that the Floor Space Index available
as on date in respect of the said property is _______square meters only and the
Developer has planned to utilize future construction potential of _________ by
availing of FSI available on payment of premiums or FSI available as incentive FSI
by implementing various scheme or F.S.I. that may become available due to the
handing over of roads etc. as mentioned in the Development Control Regulation or
based on execution of increased FSI which may be available in future or modification
to Development Control Regulations which are applicable to the said project and the
T.D.R. The Developer has disclosed the construction potential as proposed to be
utilized by him on the said property and the Unit Purchaser/s has agreed to purchase
the said accommodation based on the proposed construction and sale of
accommodations to be carried out by the Developer by utilizing the proposed FSI
and on the understanding that the declared proposed FSI shall belong to Developer
only. The plan of the said Accommodation/Unit is subject to amendments and
changes as may be stipulated by the sanctioning authorities, Government, local
authority and / or the requirements of the Developer. The Unit Purchaser/s has/
12
have agreed to purchase the said Apartment based the proposed construction and
sale of apartments to be carried out by the Developer by utilizing the proposed FSI /
TDR and on the understanding that the declared proposed FSI shall belong to
Developer only. The Purchaser hereby agrees and gives his specific irrevocable
consent, through the present Deed by executing a No-Objection Certificate/ Consent
Deed, is attached ANNEXURE E, to the Developer to carry out such amendments,
alterations, modifications and / or variations in constructing the said
Accommodation/Unit, said Building on the said property and / or to the layout plan
and / or to the Building plans (whether or not envisaged and / or constructed at
present), provided that the location and the area / size of the said
Accommodation/Unit agreed to be purchased by the Purchaser is not in any
manner adversely affected. The Purchaser agrees that the said consent is
irrevocable. It is disclosed by the Developer to the Purchaser/s that the amenity
space in the said layout or in the proposed layout shall be developed by the
Developer by getting the construction plans sanctioned from the appropriate
authority and the Unit Purchaser/s consent/s to the same. The Developer shall be
entitled to obtain appropriate additional F.S.I. for construction on the said property.
a. Any scheme or reservation affecting the said property or any part or parts
thereof made or to be made by any Authority concerned including the terms
covenants stipulations and conditions contained in the Agreement/s relating to
the said property.
b. Its present user as residential and / or non-residential and / or other permissible
users. Any relevant and necessary covenants as may be stipulated by the
Developer for the more beneficial and optimum use and enjoyment of the said
property (i.e. the said property together with the building thereon) in general and
for the benefit of any class of holders of any Flat/Shop/Office/s and other
Flat/Shop/Office/s as the case may be or any part thereof including the absolute
and irrevocable right of the Developer to exclusively and absolute use and
utilized as above enumerated the benefit of any enhanced FSI / FAR or to
absorb and consume the TDR rights, if any, acquired on any portion/s of the
said property.
c. All rights of water, drainage, water course, light and other easement and quasi
or reputed easements and rights of adjoining land Owner/s and their prospective
members affecting the same and to any liability to repair or contribute to the
repair of roads, ways, passages, sewers, drains, gutters, fences and other like
matters. The Developer shall not be required to show the creation of or define or
apportion any burden.
d. All the covenants and conditions ensuring for the benefit of the said person / s
as contained in the Agreement / s made between them and / or the Developer,
Order of Layout and / or sub-division relating to the said property, Order of
conversion and all terms and conditions stipulated by the Developer in respect
of the common areas and facilities and amenities to be provided for the benefits
of the said property or any part / s thereof.
e. For the aforesaid purpose and all purposes of and incidental thereto, and / or for
the more beneficial and optimum use and enjoyment of the various portions of
the said property and / or any part / s thereof of the Developer in such manner
as may be desired by the Developer, the Developer shall be entitled to grant,
over, upon or in respect of any portion/s of the said property, all such rights,
benefits, privileges, easements etc. including right of way, right of draw from or
connect to all drains, sewers, water, electricity, telephone lines / connections
and/or installations and other service in the said property and/or any part/s
thereof right of use and enjoyment of all amenities and facilities provided and/or
agreed to be provided in the said property and/or any part/s thereof for the more
beneficial and optimum use and enjoyment of the same in such manner as may
be desired by the Developer. The Developer shall, if they so desire, be also at
liberty to form and incorporate one ultimate body hereinafter referred to in
respect of the said property and/or any part/s thereof subject to the same being
14
8. DECLARATION OF PURCHASER/S : -
The Purchaser/s hereby declare/s that before execution of this Agreement, the
Developer has made full and complete disclosure and the Purchaser/s has/have
taken full and free inspection of, inter-alia, the following:
a) Nature of the title of the Developer to their respective holdings in the said
property along with the relevant Documents.
b) All the plans sanctioned by the Pune Municipal Corporation in respect of the
said building to be constructed on the said property and the specifications of
the said project.
c) Nature and particulars of fixtures, fittings, and amenities to be provided in the
Unit hereby agreed to be sold.
d) The nature of organization of persons to be constituted of all purchasers of
Units in the said project to be known as SAI SQUARE and to which title is to
be passed being one or more Association of Apartment governed by the
provisions of the Maharashtra Apartments Ownership Act 1970 and rules
made thereunder.
e) The fact that after the said Unit has been completed and the Purchaser/s put
in possession thereof, the Purchaser/s shall be obliged to bear and pay the
Municipal / Grampanchayat Property Taxes in respect of the said Unit as may
be assessed and levied by the Planning Authority, any other taxes or
charges, Electricity Charges and Water Charges as may be applicable from
time to time.
15
The Purchaser/s hereby declare/s that after reading and having understood the
contents of the aforesaid documents and all the disclosures made by the Developer,
the Purchaser/s, with full knowledge thereof, has/have entered into this Agreement.
In the event of the ultimate body being formed and registered before the sale and
disposal of all the Units by the Developer in the said building the power and authority
of the Association so formed or of the Unit holders and the Unit Purchasers of the
other Flat/Shop/Offices in the building shall be subject to the overall authority and
control of the Developer in respect of any of the matters concerning the said
building/s, the construction and completion thereof and all amenities pertaining to the
same and in particular the Developer shall have absolute authority and control as
regards the unsold Units and other premises and the disposal thereof.
The Developer shall be liable to pay only the Grampanchayat Taxes/statutory taxes,
at actual, in respect of the unsold Flat/Shop/Offices and other premises and the
16
token sum of Rs.11/- (Rs. Eleven Only) per month towards out goings in respect of
the unsold Units. In case of Deed of Declaration is executed in favour of the Ultimate
Body, the disposal by the Developer of all the Flat/Shop/Offices and other premises
in the said building/s, then and in such case the Developer/Member in respect of
such unsold premises and as and when such premises are sold, to the person of the
choice and at the discretion of the Developer (the realizations belonging to the
Developer alone) the Ultimate Body shall admit as members the Purchasers of such
premises without charging any premiums or any other extra payment of whatsoever
nature. The Developer shall not and will not be liable or required to pay any transfer
fees, entrance fees or any fees or charges under any head and also will not be liable
or required to contribute towards the common expenses or maintenance charges or
any amount under any head towards the share in common expenses in respect of
the unsold units other than the token sum of Rs. 11/- per month as mentioned above
and also the allottees of such unit shall be liable to pay maintenance from the date of
allotment and delivery of possession. The Developer shall either form a Apartment
Condominium or Co-operative Society or Private Limited Company of the Unit
Purchaser/s in the building to be constructed by the Developer on the said property
and to convey the said property to such Apartment Condominium / society / Private
Limited Company. The provisions here in above contained in the further clause, for
conveying the said building/s and the said property shall be subject to the provision
of this clause.
Provided always that the power of termination hereinabove contained shall not
be exercised by the Developer unless and until the Developer shall have
given to the Purchaser/s fifteen days prior notice in writing of his intention to
terminate this agreement by Registered Post A.D. at the address given in this
Agreement for service or by e-mail of the specific breach or breaches of terms
and conditions in respect of which it is intended to terminate the agreement
and default shall have been made by the Purchaser/s in remedying such
breach or breaches within the time mentioned in such notice. If Purchaser/s
fail/s to remedy the said breach within 15 days from the receipt of notice, then the
Developer shall be entitled to terminate these presents and shall refund the amount
17
received till then by the Developer from the Purchaser/s after the deductions of the
administrative charges of amount Rs. 50,000/- and the liquidated damages, if any,
and after deducting the amount paid towards the Stamp Duty, Registration, Legal
Charges and the amount paid towards the taxes such as G.S.T., T.D.S. on all the
amounts. The Developer shall not be liable to pay any interest on such refund
amount. Upon termination of this agreement and refund of aforesaid amount
by the Developer and the Purchaser / s shall execute and register a Cancellation
Deed in favour of the Developer canceling the present Agreement. Further the
Developer shall be at liberty to dispose off and sell the said Accommodation
to such person and at such price as the Developer may in their absolute
discretion think fit after the execution and registration of the Cancellation Deed with
the Purchaser/s.
Without prejudice to the right of the Developer to take action for breach arising out of
delay in payment of the installments on the due dates, the Purchaser/s shall be
bound and liable to pay interest as prescribed under the Rules i.e. the State Bank of
India Highest marginal cost of lending rate plus 2 % with quarterly rests on the
installments which become due and payable by the Purchaser/s to the Developer till
date of actual payment and the Developer may continue with these presents.
Without prejudice to the aforesaid, the Developer may at its absolute discretion
accept payment with interest as mentioned hereinabove on the amounts of
installments in respect whereof a delay / default has been committed by the
Purchaser for the delayed period. However this will not amount to waiver of
any right or authority of the Developer including the right of the Developer to
terminate the agreement and forfeit the earnest money nor will the same
amount to waiver of specific condition that payment on time is the essence of
the contract.
Development) Act, then Purchaser/s shall have right to terminate this Agreement and
the Developer shall be liable on demand to refund to the Purchaser the amount
received by them in respect of the Unit along with interest as prescribed under the
Rules i.e. the State Bank of India Highest marginal cost of lending rate plus 2 %
from the date the Developer has received the sum till the date the amount and
interest is repaid. If the Unit Purchaser/s does/do not intent to withdraw from the
project then the Developer shall pay the interest as specified in the rule on all the
amounts paid by the Unit Purchaser/s every month of delay, till the handing over the
possession. The Purchaser shall take possession of the said Premises within
fifteen days of the Developer giving written notice to the Purchaser intimating
the said Premises is ready for use and occupation, failing which the
Flat/Shop/Office Purchaser shall be liable to pay Rs. _____/- per sq. ft. per month
towards the maintenance of the said Accommodation/Unit.
Provided that the Developer shall be entitled to reasonable extension of time for
giving possession of said Unit on the aforesaid date, if the completion of building in
which the Unit is to be situated is delayed on account of:
(i) War, civil commotion or local riots, heavy rain fall, fire, or act of God.
(ii) Any notice, order, rules, notification of the Government and / or public or Competent
Authority including the authorities under the Urban Land (Ceiling and Regulation)
Act, 1976, Collector, or any disputes or matters relating to the property pending final
determination by the courts or any other authorities.
(iii) Changes in any rules, regulations and bye-laws of various statutory bodies and
authorities from time to time then affecting the development and the project.
(iv) Delay in grant of any NOC / permission / license / connection / installation of any
services such as lifts, electricity & water connections and meters to the scheme /
Flat/Shop/Office, Road NOC or Completion Certificate from appropriate Authority.
(v) Delay or default in payment of dues by the Unit Purchaser under these presents.
(Without prejudice to the right of Developer to terminate this agreement)
(vi) Pendency of any litigation.
(vii) Any act beyond control of the Developer.
project being found to be insufficient even within / before the end of Twenty Four
months as mentioned herein above, the Purchaser/s shall be obliged to make up /
pay the shortfall as and when called upon by the Developer to do so. It is agreed by
and between parties hereto the above mentioned amenities shall be completed by
the Developer s simultaneously with completion of the whole of the project.
The abovementioned facilities and amenities are provided by the Developer for the
use and enjoyment of the unit purchasers and as such any untoward incident and/or
accident takes place or occurs, the Developer shall not be responsible for the same.
The Project / Building will be maintained by the Developer for the tenure of 2 years
from the date of first 5 possessions of the particular building/building/s and the
expenses occurred in this respect are Non Accountable & Non Refundable.
After the formation of the Apartment Condominium of Unit Purchasers all the
permissions in respect of Lifts, water and in respect of all the amenities provided by
the Developer which requires renewal of permissions from the central government,
state government, local authorities, Maharashtra Pollution Control Board and
permissions from fire department shall be renewed by the said Apartment
Condominium at its own costs and the said facilities and formalities shall be
maintained by the said Apartment Condominium and its own expense.
a). The Developer shall be entitled to transfer, assign, attach, dispose off and / or sell in
any manner as they deem proper the said open spaces, adjacent terraces, and other
23
specified and unspecified spaces to anybody on the terms and conditions mentioned
in the proceeding clause/s. The Unit Purchaser/s along with the other Purchaser/s or
Purchaser/s of whatsoever kind in respect of the rights, title, interest of the Developer
and/or its nominees or assigns in respect of matter mentioned in the proceedings
clause/s hereby gives their consent to the same.
b). The Developer shall became member of the Apartment Condominium, if the
Developer transfers, assigns and disposes off unattached covered car parking,
terrace or other specified or unspecified spaces at any time to anybody the
assignees, transferee and / or the Purchaser / s thereof shall be admitted as
member/s of the Apartment Condominium. The other Unit Purchaser / s will have no
right to raise any objection to admit such assignee or transferee or allottee or
Purchaser/s as member of Apartment Condominium.
d). The Developer has reserved the right to change and alter the building plan, the
elevation, the amenities, the facilities at their sole discretion, provided however if
there is any major change or changes on account of such revision of plan in the Unit
of the Unit Purchaser, the same shall be communicated to the Unit Purchaser. The
revision/modification/ changes in respect of such additions / alterations etc. shall be
binding on the Unit Purchaser and the Unit Purchaser shall not be entitled to claim
any damages or compensation from the Developer.
e). The top terraces on the buildings shall always the common for all the Unit Holders
but the Developer right and authority to depute its representative to go to the terrace
for the regular check up and upkeep, maintenance and for repairing the water
storage tanks and lifts, T.V. / Dish Antenna etc. at all reasonable time.
24
f) The Developers shall be entitled to connect the drainage / water line of the said
building which shall pass through the said property and the Unit Purchaser/s shall
have no objection for the same.
G) The Unit Purchaser/s is/are aware and has/have agreed that the Developers
shall be entitled to sell, transfer, assign the said construction on the said property in
favour of any third party / parties and shall be entitled to accept the consideration
thereof.
a) To maintain the said Unit by the Unit Purchaser/s at their own cost & keep the same
in good tenantable repair and condition from the date of possession of the
Flat/Shop/Office / garage / parking place is taken and shall not do or cause to be
done anything in or to the building in which the Flat/Shop/Office is situated, staircase
or any passage which may be against the rules, regulations or bye-laws or
concerned local or any other authority or change / alter or make addition in the Unit
itself and / or the building in which the Unit is situated or any part thereof.
b) Not to store in / outside the said Unit / building / surrounding area any goods which
are of hazardous, combustible or dangerous nature or are so heavy as to damage
the construction or structure of the building in which the unit is situated or storing of
which goods is objected to by the concerned local or other authority and shall not
carry or cause to be carried heavy packages to upper floors, which may damage or
likely to damage the staircase, common passage or any other structure of the
building and in case any damage is caused to the building or the Unit in account of
negligence or default of the Unit Purchaser / s in their behalf, the Unit Purchaser / s
shall be liable for the consequences of the Breach.
c) To carry at his / her / their own costs all internal repairs to the said unit and maintain
the said Unit in the same conditions, state or order in which it was delivered by the
Developer to the Unit Purchaser / s and shall not do or cause to be done anything in
or to the building in which the Unit is situated or the Unit itself which may be contrary
to the given rules & regulations and bye-laws of the concerned local authority or
other public authority. And in the event of the Unit Purchaser / s committing any act
in contravention of the above provision, the Unit Purchaser / s shall be responsible
25
and liable for the consequence thereof to the concerned local authority and / or other
public authority.
d) Not to demolish or cause to demolished the Unit or any part thereof, not at any time
make or cause to be made any addition or alteration of whatsoever nature in or to
the said Unit or any part thereof, or in or to the building in which said Unit is situated
and not to make any alteration in the elevation and outside colour scheme of the
building in which the Unit / s is situated and shall keep the portion, sewers, drains,
pipes in the Unit/s and appurtenances thereto in good tenantable repair and
condition, and in particular, so as to support the shelter and protect the other parts of
the building and shall not chisel or in any other manner damage the columns, beams,
walls, slabs or RCC, paradise other structural members in the said Unit without the
prior written permission of the Developer and / or from the managing Committee of
the “SAI SQUARE” as the case may be.
e) Not to do or permit to be done any act or thing which may render void or voidable
any insurance of the said property and building or any part thereof or whereby any
increase premium shall become payable in respect of the insurance.
f) Not to hang clothes at the conspicuous places of the building, not to throw dirt,
rubbish, rags, garbage or other refuse or permit the same to be thrown from the said
Unit etc. in the compound or any portion of the said property and the building in
which the Unit / s are situated.
g) To install the Cooling Units/ Compressors of “Split Type” Air Conditioners
appurtenant to the said Unit only at such places as shall be prescribed therefor by
the Developer s.
h) Not to lay/ install over the exterior of the said Building or the Common Areas thereof
such as staircases, landings and ducts thereof, grills, chimney, neon signboards or
electronic board/s any Electrical, Telecom Lines or Conduits. The Purchaser/s will
not affix a grill outside the main door or at any location therein which such grill will be
visible from the exterior of the said Accommodation/Unit or the said building without
taking the prior written permission of the Developer / Ultimate body.
i) Not to install any Dish or other Antennae for reception of Radio, Telecom or
Television Signals in such manner in the said Unit whereby such Dish or other
Antennae projects outside the said Unit or on any part of the exterior of the said
Building or any of the Common Areas thereof, including on the terrace thereof
without the prior written permission of the Developer s and/or the apartment
condominium.
j) To bear and pay all local taxes, water charges, insurance and such other levies, if
any, and any increase as applicable, which are imposed by the concerned local
authority and / or Govt. or other public authority, on account of change of user of the
26
Unit by the Unit Purchaser/s viz user for any purpose other than for the purpose
allowed.
k) The Unit Purchaser / s shall not let, sub-let, transfer, assign or part with other
Purchaser / s interest or benefit factor of this Agreement or part with the possession
of the Unit / s until all the dues payable by the Unit Purchaser / s to the Developer
under this agreement are fully paid up and only if the Unit Purchaser / s has not been
guilty of breach of or non-observance of any of the terms and conditions of this
Agreement and until they have intimated in writing to the Developer and obtain their
written consent
l) The Unit Purchaser / s shall permit the Developer and their surveyors and agents
with or without workmen and others, at all reasonable items, to enter into and upon
the said Unit and the said property and buildings or any part thereof to view and
examine the state and condition thereof.
m) Any obstruction, objection, nuisance etc, created or caused by the Unit Purchaser
shall forth will be removed as asked for by the Builder & Developer / by the body
members thereof suffering inconvenience on account of such cause.
n) The Unit Purchaser/s shall not complain that any nuisance is being caused to him /
her / them by reason of the fact that the Developer are carrying out the construction
in respect of the Unit / Building / s and Structures nor shall he / she / they be entitled
to complain about any loss of light and air or any other facilities on account of any
construction by the Developer or his nominee / s.
o) The covenants contained in this agreement to be performed on the part of the Unit
Purchaser/s is / are enforceable not only against him / her / them but in case of his /
her / their legal representative and against his / her / their estate. However the
covenants contained in this agreement to be performed on the part of the Developer
are personal and shall be enforceable only against the Developer, and only by the
Unit Purchaser/s and no other person.
p) The Unit Purchaser/s shall not decorate the exterior of his / her / their premises
otherwise than in the manner agreed to by the Developer or in the manner as near
as may in which the same as previously decorated nor will the Unit Purchaser/s hang
out clothes, enclose balconies, paint walls, put planters or do such exterior
treatments so as to change the elevation of the Building.
q) The Unit Purchaser/s shall not demand to be compensate for any loss, damage
caused by fire, riot, shrikes, earthquakes, fluctuations in the temperatures, abnormal
heavy rains or due to any other cause whatsoever after handing over possession of
the Unit to the Unit Purchaser.
27
r) The Unit Purchaser/s shall observe and perform all the rules and regulations which
the Apartment Condominium, may adopt at its inception and the additions,
alterations or amendments thereof that may be made from time to time for protection
and maintenance of the said building and the Units therein and for the observance
and performance of the Building Rules, Regulations and Bye-Laws for the time being
of the concerned local authority and of the Government and other public bodies. The
Unit Purchaser / s shall also observe and perform all the stipulations and conditions
lay down by the Apartment Condominium regarding the occupation and use of the
Unit Building and shall pay and contribute regularly and punctually towards the taxes,
expenses or other outgoings in accordance with the terms and conditions of this
agreement.
said warranty period and the Developer shall not be liable for the same. The
structural defect liability means the RCC structure and slabs but will not include the
outer plaster, inner plaster, paints, tiles, other fixtures and fittings provided in the
Bathroom and W.C. etc..
It is hereby agreed that the areas mentioned in Schedule III written hereunder under
the head of common facilities only shall be the common areas facilities and the
Developer shall be entitled to declare all other areas as restricted or reserved areas
and facilities or to alienate and dispose off other areas and facilities in such manner
as the Developer thinks fit. The open space if any in the said project shall be
developed by the Developer as per the Rules and Bye-laws and the Developer shall
be entitled to sell the units therein to any Third Party at any consideration as he
deems fit and the Unit Purchaser/s shall not have any concern with it. The amenities
and facilities mentioned herein shall be completed simultaneously with the
completion of the project.
If common TV antenna is not provided then unit purchaser/s shall be entitled to erect
TV antenna (not dish antenna) on the terrace on top of the building at the place
convenient and suitable for the said other unit purchaser/s.
Flat/Shop/Office purchaser/s hereby agree/s that in the event of any amount by way
of tax, Premium betterment charges, value added tax or services tax or development
or tax or Educational cess or any other tax or payment of a similar nature becoming
payable to the local authority or to the state and / or central Govt. or any authority, on
the purchase, development / construction of the said property and / or sale of the
Flat/Shop/Office, etc. and / or any of the incidents of this transfer of property in good
involved in works contraction, etc. by the Developer either before or delivery of
possession of the said Accommodation/Unit the same shall be paid by the purchaser
in advanced to the Developer, as and when charged and demanded by the
Developer. The Developer shall not be liable to pay the same. If purchaser/s fail/s to
pay the amount within seven days from demanded then Flat/Shop/Office purchaser/s
shall be liable to pay interest @ 24% p.a. until the payment is made. Also in the said
event there shall be a charge of the amount due on the said Accommodation/Unit
and income there from and till payment of said dues purchaser/s shall not be entitled
assign, shall or transfer the said Accommodation/Unit in any manner. It is understood
that interest shall not cover the damages/losses that will be suffered by the
Developer due to non-payment. Therefore, purchaser/s shall be further liable to pay
damages and losses that will be suffered by the Developer due to non-payment and
the purchaser/s shall keep the Developer harmless and indemnified there from. The
Flat/Shop/Office purchaser/s has/have hereby agreed to execute separate Indemnity
Bond/s for this purpose, before taking possession of the said Accommodation/Unit.
In case of dispute regarding above the same shall be referred to a single arbitrator to
be appointed by the Developer. The Arbitrator shall dispense with oral evidence, give
only one date for hearing both parties which will be informed to the parties on the
address given below (and deemed as valid communication) and arbitrator shall give
award maximum within 30 days from accepting the appointment. The award given as
above shall be final and binding on both parties.
31. RESTRICTED AREA, TERRACE, DUCT AREA, PARKING & OPEN SPACE: -
The Terrace, Duct and / or Parking space and / or open space specifically attached
to the particular Unit holder shall exclusively be used by the concerned Unit holder
and the same shall be a restricted area for other Unit holder subject to the entry for
maintenance of building, drainage, water line and or for any service or amenities and
this entry will not be obstructed by the Unit holders on the pretext of any reason or
reasonable cause.
the said purpose the Developer is entitled to amend, to alter and to modify the
building/s plans with or without modifications as and when Developer feels
necessary and Unit Purchaser gives her/their/his consent for the same. The
utilization of T.D.R. / paid F.S.I. / additional F.S.I. when sanctioned and constructing
structures by using T.D.R. / paid F.S.I. / additional F.S.I. shall be the part of the
project.
37. ARBITRATION: -
In case of any dispute between the Developer and the Unit Purchaser / s regarding
interpretation of any of the terms of this agreement or regarding any aspect of the
transaction including quality of construction work, defective service by the Developer,
delay in construction work and or sale deed, alteration in the plan, parking
arrangements, grant of exclusive uses, rendering of account etc, then such dispute
shall be referred to the arbitration of CREDAI Pune Metro who shall be sole
arbitrator. The Unit Purchaser/s shall give notice of minimum period of 30 days to the
Developer in case of any such dispute before invoking the Arbitration Clause. If
reference of dispute to the CREDAI is held as not correct or legal by any Court or
authority then the dispute shall be referred to the three arbitrators, one to be
appointed by each party and third arbitrator shall be appointed by such two
arbitrators and decision given by majority by arbitrators shall be final and binding on
all the parties.
33
39. CONSTRUCTION: -
The Promoter is constructing multi storied building consisting many commercial/
residential tenements on the said property. The Promoters herein has decided to
form an Association of Apartments under name and style “SAI SQUARE
APARTMENTS / SAI SQUARE CONDOMINIUM” of all Accommodations holders in
the said building which is under construction on the said property and adjacent
properties. The Unit Purchaser/s consents and authorizes the Developer to utilities
and take connections from water, electricity, sewage or drainage lines and other
convenience in the said building as and when they require to do so for carrying on
further development.
the responsibility of the Purchaser/s to deduct and pay the TDS under this
Agreement on the stipulated dates.
Consisting of ____________
38
2. Adjacent terraces as shown on the Annexure C shall be restricted and shall be for
exclusive use of such respective tenement holders.
3. The Promoters herein shall have exclusive right to convert terraces of the building as
per present sanctioned building plan into constructed accommodation/s by using
remaining FSI of the said land or by bringing in TDR if any on the said land.
4. Top Terrace of the building shall be restricted and the Promoters herein shall have
exclusive right to allot the same to the tenement holder in the building, or has a right
to use the same for any purpose including as the terrace or to install hoardings/
space for advertisement or for installing or for installing Tower and cabin for
Mobile/WLL Companies on the terms and conditions as the Promoters may think fit
and proper.
5. The space being duct is restricted areas and the Promoters herein shall have
exclusive right to allot the same to the tenement holder in the building for open to sky
parking purpose or otherwise.
6. All areas etc. which are not covered under aforesaid head “Common areas and
Facilities” are restricted areas and facilities which include, the marginal open spaces,
39
terraces, car-parkings within the said land and in the building/s which is/are under
construction on the said land is reserved and Promoters shall have exclusive rights
to attach the same in part or in full to any unit or to convert the Restricted Area into
Common Area or vice-versa.
IN WITNESS WHEREOF the parties hereto have unto set and subscribed their
respective hands and seals this day and year first herein above mentioned.
1) _________________________
2) _________________________
“THE PURCHASER/S”
In the presence of Witnesses :-
1. Sign _____________________________
Name _____________________________
Add. _____________________________
_____________________________
2. Sign _____________________________
Name _____________________________
Add. _____________________________
41
Annexure “A”
Title Certificate
Annexure “B”
Copy of the Floor Plan
Annexure “C”
Commencement Certificate
Annexure “D”
Copies of the Property Card extract
Annexure “E”
Letter of Consent
Annexure “F”
Layout Plan